Blueberry Park School Playing Fields PRELIMStcm21-100237
Transcript of Blueberry Park School Playing Fields PRELIMStcm21-100237
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
1/94
Blueberry Park School Playing Fields Prelims
20 August 2007
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
2/94
Table of Contents
Title Page
A JCLI Agreement for Landscape Works 4
6PROJECT PARTICULARSA10
8TENDER AND CONTRACT DOCUMENTSA11
10THE SITE/ EXISTING BUILDINGSA12
13DESCRIPTION OF THE WORKA13
15JCLI AGREEMENT FOR LANDSCAPE
WORKS
A20
19TENDERING/ SUBLETTING/ SUPPLYA30
24PROVISION, CONTENT AND USE OFDOCUMENTS
A31
30MANAGEMENT OF THE WORKSA32
34QUALITY STANDARDS/ CONTROLA33
40SECURITY/ SAFETY/ PROTECTIONA34
47SPECIFIC LIMITATIONS ON METHOD/SEQUENCE/ TIMING
A35
49FACILITIES/ TEMPORARY WORK/SERVICES
A36
51OPERATION/ MAINTENANCE OF THEFINISHED WORKS
A37
53WORK/ PRODUCTS BY/ ON BEHALF OFTHE EMPLOYER
A50
55PROVISIONAL WORK/ ITEMSA54
57DAYWORKSA55
A(2) JCLI Agreement for LandscapeMaintenance Works
58
60PROJECT PARTICULARSA10
62TENDER AND CONTRACT DOCUMENTSA11
64THE SITE/ EXISTING BUILDINGSA12
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
3/94
66DESCRIPTION OF THE WORKA13
68JCLI AGREEMENT FOR LANDSCAPEMAINTENANCE WORKS
A20
71TENDERING/ SUBLETTINGA30
75PROVISION, CONTENT AND USE OFDOCUMENTS
A31
78MANAGEMENT OF THE WORKSA32
81QUALITY STANDARDS/ CONTROLA33
84SECURITY/ SAFETY/ PROTECTIONA34
89SPECIFIC LIMITATIONS ON METHOD/SEQUENCE/ TIMING
A35
91FACILITIES/ TEMPORARY WORK/SERVICES
A36
94PROVISIONAL WORK/ ITEMSA54
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
4/94
A
JCLI Agreement for Landscape Works
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
5/94
A10
PROJECT PARTICULARS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
6/94
A10 PROJECT PARTICULARS
110 THE PROJECT Name: Blueberry Park Playing Fields. Nature: removal of existing ground and replacement
with approved soils. Formation of new playing fieldswith underground drainage..
Location: Dunchurch Road, Liverpool, L14. Timescale for completion of the 'construction work': co
mpletion by 11 weeks after comencement.
120 EMPLOYER (CLIENT) Name: Rob Gilland. Address: Liverpool City Council Children's Services,
Brougham Terrace, 1-7 West Derby Road, Liverpool
L6 1AE. Telephone: 0151 225 6270.
130 PRINCIPAL CONTRACTOR Name: The Contractor. Address: to be advised. Telephone: to be advised.
140 CONTRACT ADMINISTRATOR (HEREINREFERRED TO AS 'CA')
Name: Michael Morgan. Address: 2020 Liverpool, West House, Mercury Court,
Tithbarn Street, Liverpool L2 2QP.
Telephone: 0151 237 4258.
150 PLANNING SUPERVISOR Name: Derek Bradshaw. Address: 2020 Liverpool, West House, Mercury Court,
Tithebarn Street Liverpool, L2 2QP. Telephone: 0151 237 4100.
180 LANDSCAPE ARCHITECT Name: 2020 Liverpool. Address: West House, Mercury Court, Tithbarn
Street, Liverpool L2 2QP. Telephone: 0151 237 4258.
190 CLERK OF WORKS Name: 2020 Knowsley. Address: 9 West Street, Prescot, Knowsley,
Merseyside, L34 1LF. Telephone: 0151 477 2012.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
7/94
A11
TENDER AND CONTRACT DOCUMENTS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
8/94
A11 TENDER AND CONTRACT DOCUMENTS
110 TENDER DRAWINGS The tender drawings are: 801638-01 Site Location,
801638-02-C General Arrangement Drawing-rev C,801638-03-B Land Drainage and Soakaway Details-rev B; 801638-4 Mowing Strip Detail.
120 CONTRACT DRAWINGS The Contract Drawings: The same as the tender
drawings.
130 QUANTITIES DRAWINGS The drawings from which the quantities included in
the specification/ schedules have been prepared are:
- the tender drawings.
160 PRE-TENDER HEALTH AND SAFETY PLAN Format: A separate Pre-tender Health and Safety
Plan is included with the tender documents.
180 OTHER DOCUMENTS Inspection: Drawings and other documents relating to
the Contract but not included in the tender documentsmay be seen by appointment during normal officehours at the office of 2020 Liverpool.
The documents include: Site investigation report;Services drawings.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
9/94
A12
THE SITE/ EXISTING BUILDINGS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
10/94
A12 THE SITE/ EXISTING BUILDINGS
110 THE SITE Description: The site is an area of land which has
been recently cleared of housing. The site adjoins aschool playground to the east of which it will form apart upon completion of the playing field construction.On the northern, western and southern sides the siteis bordered by local estate roads with housing locatedon the opposite side of the road. A new steel fenceforms the current boundary of the site.
130 SITE CLEARANCE Works: Carried out under a separate contract and
completed before the Date of Possession for this
Contract. Description: Housing demolition and clearance.
140 EXISTING MAINS AND SERVICES Drawings: (Information shown is indicative only): statu
tory services drawings are available for inspection byappointment at 2020 Liverpool Offices.
Other information: all mains and services entering thesite have been disconnected, however Contractorsmust satisfy themselves that the site is safe to carryout works by appropriate investigation/detectionmeasures.
200 ACCESS TO THE SITE Description: Access to the site is from adjoining local
road. Removal of two fencing panels plus theintermediate fence post from the boundary fence isrequired to create vehicular access to the site.
Limitations: Adequate measures to secure theentrance point should be submitted to the CA forapproval. Measures should be taken to protect thefootway crossover from site traffic.
220 USE OF THE SITE General: Do not use the site for any purpose other
than carrying out the Works. Limitations: Do not use any areas of the school
grounds other than that within the site boundary. Useof other areas of the school grounds may be availablefor use if required by pre-agreement with a schoolrepresentative with appropriate authority.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
11/94
230 SURROUNDING LAND/ BUILDING USES General: Adjacent or nearby uses or activities are as
follows:- A school is located to the east of the site. Housinglies to the north, west and south.
240 HEALTH AND SAFETY HAZARDS General: The nature and condition of the site/ building
cannot be fully and certainly ascertained before it isopened up. However the following hazards are or maybe present:- contaminated land and underground structures.
Information: The accuracy and sufficiency of thisinformation is not guaranteed by the Employer or theEmployer's representative. Ascertain if any additionalinformation is required to ensure the safety of allpersons and the Works.
Site staff: Draw to the attention of all personnelworking on the site the nature of any possiblecontamination and the need to take appropriateprecautionary measures.
250 SITE VISIT Before tendering: Ascertain the nature of the site,
access thereto and all local conditions and restrictionslikely to affect the execution of the Works.
Arrangements for visit: by appointment with school.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
12/94
A13
DESCRIPTION OF THE WORK
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
13/94
A13 DESCRIPTION OF THE WORK
110 PREPARATORY WORK BY OTHERS Works: Carried out under a separate contract and
completed before the Date of Possession for thisContract.
Description: Housing demolition and clearance.
120 THE WORK Description: excavation of existing surface and
removal to licensed tip. Importing topsoil to make uplevels. Creation of new school playing fields includingsub- surface land drainage. 1 years groundsmaintenace of completed works.
130 WORK BY OTHERS CONCURRENT WITH THECONTRACT
Scope: See section A50.
140 COMPLETION WORK BY OTHERS Description: Topographical surveys; Site invetigatios.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
14/94
A20
JCLI AGREEMENT FOR LANDSCAPE WORKS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
15/94
A20 JCLI AGREEMENT FOR LANDSCAPEWORKS
JCLI AGREEMENT FOR LANDSCAPE WORKS The contract: JCLI Agreement for Landscape Works,
February 2002 revision of 1998 Edition and includingSupplemental Conditions.
Requirement: Allow for the obligations, liabilities andservices described therein against the followingheadings:
THE RECITALS
1st - WORKS, CONTRACT ADMINISTRATOR ANDCONTRACT DOCUMENTS
The work comprises: excavation of existing surfaceand removal to licensed tip. Importing topsoil to makeup levels. Creation of new school playing fieldsincluding sub- surface land drainage. 1 years groundsmaintenace of completed works.
Contract Administrator: See clause A10/140. Contract documents: The following have not been
prepared and will be deleted from the recitals:- Bills of Quantities and schedule of rates.
2nd - PRICED DOCUMENTS The references to Bills of Quantities and schedule of
rates will be deleted.
4th - QUANTITY SURVEYOR The 4th Recital will be deleted.
5th - CDM REGULATIONS Alternative B1 will apply. Alternatives A, B2 and B3
will be deleted.
THE ARTICLES
3 - CONTRACT ADMINISTRATOR Contract Administrator: See clause A10/140.
4 - PLANNING SUPERVISOR Alternative B will apply. Alternative A will be deleted. Planning Supervisor: See clause A10/150.
5 - PRINCIPAL CONTRACTOR Alternative A will apply. Alternative B will be deleted.
7A - DISPUTE OR DIFFERENCE ARBITRATION Article 7A applies. Article 7B will be deleted.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
16/94
THE CONDITIONS
2 - COMMENCEMENT AND COMPLETION
2.1 - COMMENCEMENT AND COMPLETION The Works may be commenced three weeks from
date of receipt of tenderand shall be completed by 11eeks aftercommencement.
2.3 - DAMAGES FOR NON COMPLETION Damages for non completion (liquidated damages): At
the rate of 443.84 per week or pro-rata theretobetween the aforesaid completion date and the dateof practical completion.
2.5 - DEFECTS LIABILITY Defects liability period: 12 months.
2.8A - PLANTS DEFECTS LIABILITY AND POSTPRACTICAL COMPLETION CARE BYCONTRACTOR
Clause 2.8B will be deleted. Post Practical Completion defects liability periods will
be:- Grass: 6 months.- Shrubs, ordinary nursery stock trees or other
plants: 12 months.- Semimature advanced or extra large nursery stock
trees: 2 years.
2.9A - MALICIOUS DAMAGE OR THEFT (BEFOREPRACTICAL COMPLETION)
Clause 2.9B will be deleted.
3 - CONTROL OF THE WORKS
3.6 - VARIATIONS Clause 3.6: Will be amended in accordance with the
deletions in the 1st and 2nd Recitals.
4 - PAYMENT
4.1 - CORRECTION OF INCONSISTENCIES Clause 4.1 will be amended in accordance with the
deletions in the 1st recital.
4.2 - PROGRESS PAYMENTS AND RETENTION Progress payment: 95%.
4.3 - PENULTIMATE CERTIFICATE Penultimate certificate percentage: 97.5%.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
17/94
4.5 - FINAL CERTIFICATE Period for supply of documentation: six months.
4.6 - CONTRIBUTION, LEVY AND TAX CHANGES Clause 4.6 will be deleted.
5 - STATUTORY OBLIGATIONS
5.2 - VALUE ADDED TAX Clause B1.1 of the Supplemental Conditions does
apply.
5.6, 5.7, 5.8 and 5.9 - PROVISIONS FOR USEWHERE ALTERNATIVE B1 IN THE 5TH RECITALAPPLIES.
If in the 5th Recital either Alternative A or B2 or B3applies, clauses 5.6, 5.7, 5.8 and 5.9 will be deleted.
6 - INJURY, DAMAGE AND INSURANCE
6.2 - INJURY OR DAMAGE TO PROPERTY Insurance cover, for any one occurrence or series of
occurrences arising out of one event, to be not lessthan: 1,000,000.
6.3A - INSURANCE OF THE WORKS BYCONTRACTOR FIRE ETC.
Clause 6.3B will be deleted. Clause 6.3A will apply. The insurance being for the full reinstatement value
plus 20% to cover professional fees.
7 - DETERMINATION
8 - SETTLEMENT OF DISPUTES
EXECUTION The Contract: Will be executed under hand.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
18/94
A30
TENDERING/ SUBLETTING/ SUPPLY
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
19/94
A30 TENDERING/ SUBLETTING/ SUPPLY
MAIN CONTRACT TENDERING
110 SCOPE General: These conditions are supplementary to
those stated in the Invitation to Tender and on theform of tender.
145 TENDERING PROCEDURE General: In accordance with JCT Practice Note 6
(Series 2) 'Main Contract Tendering'. Errors: Alternative 2 is to apply.
160 EXCLUSIONS
Inability to tender: Immediately inform if any parts ofthe work as defined in the tender documents cannotbe tendered.
Relevant parts of the work: Define those parts, statingreasons for the inability to tender.
170 ACCEPTANCE OF TENDER The Employer and Employer's representatives:
- Offer no guarantee that any tender will berecommended for acceptance or be accepted.
- Will not be responsible for any cost incurred in thepreparation of any tender.
190 PERIOD OF VALIDITY Period: After submission or lodgement, keep tender
open for consideration (unless previously withdrawn)for not less than 3 months.
Date for possession/ commencement: See sectionA20.
PRICING/ SUBMISSION OF DOCUMENTS
210 PRELIMINARIES IN THE SPECIFICATION The Preliminaries/ General conditions sections (A10-
A56 inclusive) must not be relied on as complyingwith SMM7.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
20/94
250 PRICED DOCUMENTS Alterations: Do not alter or qualify the priced
documents without written consent. Tenderscontaining unauthorised alterations or qualificationsmay be rejected.
Measurements: Where not stated, ascertain from thedrawings.
Deemed included: Costs relating to items, which arenot priced, will be deemed to have been includedelsewhere in the tender.
Submit: With tender.
300 QUANTITIES IN THE PRICED DOCUMENT Quantities: Where included in the priced document,
these have been prepared in accordance with SMM7only where and to the extent stated.
Other items, descriptions and measurements not
prepared in accordance with SMM7: Must be pricedtaking account of the information given elsewhere inthe tender documents, including for all associated andancillary work shown or clearly apparent as beingnecessary for the complete and proper execution ofthe work.
310 TENDER General: Tenders must include for all work shown or
described in the tender documents as a whole orclearly apparent as being necessary for the completeand proper execution of the Works.
440 SCHEDULE OF RATES Schedule of rates (unpriced): Included with the tender
documents. The Contractor may insert additionalitems. All items must be fully priced.
Fully priced copy: Submit with the tender.
480 PROGRAMME Programme of work: Prepare a summary showing the
sequence and timing of the principal parts of theWorks and periods for planning and design. Itemizeany work which is excluded.
Submit: With tender.
500 TENDER STAGE METHOD STATEMENTS Method statements: Prepare, describing how and
when the following is to be carried out:- Proposals for removal of excavated ground fromsite; arrangement fornecessary on site surveys duringthe works;top soil and subsoil reinstatement.
Statements: Submit with the tender.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
21/94
515 ALTERNATIVE TIME TENDERS General: In addition to and at the same time as
tendering based upon the date or period specified insection A20, an alternative tender based upon adifferent date for completion or period may be
submitted. Date for completion: If any such tender is accepted
the date for completion inserted in the Contract will bethe date stated in the alternative tender or determinedfrom the period stated in the alternative tender.
530 SUBSTITUTE PRODUCTS Details: If products of different manufacture to those
specified are proposed, submit details with the tendergiving reasons for each proposed substitution.Substitutions, which have not been notified at tenderstage, may not be considered.
Compliance: Substitutions accepted will be subject tothe verification requirements of clause A31/200.
538 SUBSTITUTE PLANTS/ TREES Details: If plants/ trees differing from those specified
are proposed, submit details with the tender givingreasons for each proposed substitution includingorigin and provenance. Substitutions, which have notbeen notified at tender stage, may not be considered.
550 HEALTH AND SAFETY INFORMATION Content: Describe the organisation and resources to
safeguard the health and safety of operatives,
including those of subcontractors, and of any personwhom the Works may affect.
Include:- A copy of the contractor's health and safety policy
document, including risk assessment procedures.- Accident and sickness records for the past five
years.- Records of previous Health and Safety Executive
enforcement action.- Records of training and training policy.- The number and type of staff responsible for health
and safety on this project with details of theirqualifications and duties.
Submit: With the Tender.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
22/94
SUBLETTING/ SUPPLY
710 APPROVED FIRMS General: The work listed below is to be carried out by
the firm stated or, where alternatives are given, one of
the firms of the Contractor's choice.- Description: Site investigation and topographical
surveys.- Carried out by: Merseyside Engineers Laboratory
Services (MELS), Cambridge Road Depot,Cambridge Road, Seaforth, Liverpool L21 1EZ. Tel:0151 928 2643. Contact: Colin Salmon or BillLarner.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
23/94
A31
PROVISION, CONTENT AND USE OF DOCUMENTS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
24/94
A31 PROVISION, CONTENT AND USE OFDOCUMENTS
DEFINITIONS AND INTERPRETATIONS
110 DEFINITIONS Meaning: Terms, derived terms and synonyms used
in the preliminaries/ general conditions andspecification are as stated therein or in theappropriate British Standard or British Standardglossary.
120 COMMUNICATION Definition: Includes advise, inform, submit, give
notice, instruct, agree, confirm, seek or obtain
information, consent or instructions, or makearrangements.
Format: In writing to the person named in clauseA10/140 unless specified otherwise.
Response: Do not proceed until response has beenreceived.
130 PRODUCTS Definition: Materials, both manufactured and naturally
occurring, and goods, including components,equipment and accessories, intended for thepermanent incorporation in the Works.
Includes: Goods, plant, materials, site materials and
things for incorporation into the Works.
135 SITE EQUIPMENT Definition: All appliances or things of whatsoever
nature required in or about the construction forcompletion of the Works but not materials or otherthings intended to form or forming part of thePermanent Works.
Includes: Construction appliances, vehicles,consumables, tools, temporary works, scaffolding,cabins and other site facilities.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
25/94
160 TERMS USED IN SPECIFICATION Remove: Disconnect, dismantle as necessary and
take out the designated products or work andassociated accessories, fastenings, supports, liningsand bedding materials. Dispose of unwanted
materials. Excludes taking out and disposing ofassociated pipework, wiring, ductwork or otherservices.
Fix: Unload, handle, store, place and fasten inposition including all labours and use of siteequipment.
Supply and fix: Includes all labour and site equipmentfor unloading, handling, storing and execution. Allproducts to be supplied and fixed unless statedotherwise.
Keep for reuse: Do not damage designated productsor work. Clean off bedding and jointing materials.Stack neatly, adequately protect and store untilrequired by the Employer or for use in the Works asinstructed.
Make good: Execute local remedial work todesignated work. Make secure, sound and neat.Excludes redecoration and/ or replacement.
Replace: Supply and fix new products matching thoseremoved. Execute work to match original new state ofthat removed.
Repair: Execute remedial work to designatedproducts. Make secure, sound and neat. Excludesredecoration and/ or replacement.
Refix: Fix removed products. Ease: Adjust moving parts of designated products or
work to achieve free movement and good fit in openand closed positions.
Match existing: Provide products and work of thesame appearance and features as the original,excluding ageing and weathering. Make jointsbetween existing and new work as inconspicuous aspossible.
System: Equipment, accessories, controls, supportsand ancillary items, including installation, necessaryfor that section of the work to function.
170 MANUFACTURER AND PRODUCT REFERENCE
Definition: When used in this combination:- Manufacturer: The firm under whose name theparticular product is marketed.
- Product reference: The proprietary brand nameand/ or reference by which the particular product isidentified.
Currency: References are to the particular product asspecified in the manufacture's technical literaturecurrent on the date of the invitation to tender.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
26/94
200 SUBSTITUTION OF PRODUCTS Products: If an alternative product to that specified is
proposed, obtain approval before ordering theproduct.
Reasons: Submit reasons for the proposed
substitution. Documentation: Submit relevant information,
including:- manufacturer and product reference;- cost;- availability;- relevant standards;- performance;- function;- compatibility of accessories;- proposed revisions to drawings and specification;- compatibility with adjacent work;- appearance;- copy of warranty/ guarantee.
Alterations to adjacent work: If needed, advise scope,nature and cost.
Manufacturers' guarantees: If substitution is accepted,submit before ordering products.
210 CROSS REFERENCES Accuracy: Check remainder of the annotation or item
description against the terminology used in thesection or clause referred to.
Related terminology: Where a numerical cross-reference is not given the relevant sections and
clauses of the specification will apply. Relevant clauses: Clauses in the referred tospecification section dealing with general matters,ancillary products and execution also apply.
Discrepancy or ambiguity: Before proceeding, obtainclarification or instructions.
220 REFERENCED DOCUMENTS Conflicts: Specification prevails over referenced
documents.
230 EQUIVALENT PRODUCTS Inadvertent omission: Wherever products are
specified by proprietary name the phrase 'orequivalent' is to be deemed included.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
27/94
240 SUBSTITUTION OF STANDARDS Products specified to British Standard or European
Standard: Substitution may be proposed of productscomplying with a grade or category within a nationalstandard of another Member State of the European
Community or an international standard recognised inthe UK.
Before ordering: Submit notification of all suchproposals.
Documentary evidence: Submit for verification whenrequested as detailed in clause A31/200. Anysubmitted foreign language documents must beaccompanied by certified translations into English.
250 CURRENCY OF DOCUMENTS Currency: References to published documents are to
the editions, including amendments and revisions,
current on the date of the Invitation to tender.
260 SIZES General dimensions: Products are specified by their
co-ordinating sizes. Timber: Cross section dimensions shown on drawings
are:- Target sizes as defined in BS EN 336 for structural
softwood and hardwood sections.- Finished sizes for non-structural softwood or
hardwood sawn and further processed sections.
DOCUMENTS PROVIDED ON BEHALF OF
EMPLOYER
410 ADDITIONAL COPIES OF DRAWINGS/DOCUMENTS
Copies: Two of each contract drawing and contractdocument will be issued free of charge (not countingany certified copies).
Additional copies: Issued on request and charged tothe Contractor.
440 DIMENSIONS Scaled dimensions: Do not rely on.
460 THE SPECIFICATION Coordination: All sections must be read in conjunction
with Main Contract Preliminaries/ General conditions.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
28/94
DOCUMENTS PROVIDED BY CONTRACTOR/SUBCONTRACTORS/ SUPPLIERS
610 PRODUCTION INFORMATION Contractor/ Domestic subcontractor provide: drawings
for drainage and infiltration tanks assembly. Submit:
- For comment and make any necessaryamendments.
- Sufficient copies of final version for distribution to allaffected parties.
630 TECHNICAL LITERATURE Information: Keep on site for reference by all
supervisory personnel:- Manufacturers' current literature relating to all
products to be used in the Works.
- Relevant British, EN or ISO Standards.
640 MAINTENANCE INSTRUCTION AND GUARANTEES Components and equipment: Obtain or retain copies,
register with manufacturer and hand over on or beforecompletion of the Works.
Emergency call out services: Provide subcontractorstelephone numbers for use after completion.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
29/94
A32
MANAGEMENT OF THE WORKS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
30/94
A32 MANAGEMENT OF THE WORKS
110 SUPERVISION General: Accept responsibility for coordination,
supervision and administration of the Works, includingsubcontracts.
Coordination: Arrange and monitor a programme witheach subcontractor, supplier, local authority andstatutory undertaker, and obtain and supplyinformation as necessary for coordination of the work.
120 INSURANCE Documentary evidence: Before starting work on site
submit details, and/ or policies and receipts for theinsurances required by the Conditions of Contract.
130 INSURANCE CLAIMS Notice: If any event occurs which may give rise to any
claim or proceeding in respect of loss or damage tothe Works or injury or damage to persons or propertyarising out of the Works, immediately give notice tothe Employer, the person named in clause A10/140and the Insurers.
Failure to notify: Indemnify the Employer against anyloss, which may be caused by failure to give suchnotice.
140 CLIMATIC CONDITIONS
Information: Record accurately and retain:- Daily maximum and minimum air temperatures
(including overnight).- Delays due to adverse weather, including
description of the weather, types of work affectedand number of hours lost.
150 OWNERSHIP Alteration/ clearance work: Materials arising become
the property of the Contractor except where otherwisestated. Remove from site as work proceeds.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
31/94
205 TENDER PROGRAMME Content: Include details of dates for commencement,
completion, end of defects periods and periods for:- Acceptance of tender:Commencement on site:
Topographical surveys:Site Investigations:Removal of existing ground:Topsoiling:Seeding operations:Drainage installation:Practical completion:End of maintenance period:.
210 PROGRAMME Master programme: Immediately when requested and
before starting work on site submit in an approved
form a master programme for the Works, which mustinclude details of:- Planning and mobilisation by the Contractor.- Subcontractor's work.- Work resulting from instructions issued in regard to
the expenditure of provisional sums.- Work by others concurrent with the Contract.
Submit two number copies.
250 MONITORING Progress: Record on a copy of the programme kept
on site.
Avoiding delays: If any circumstances arise whichmay affect the progress of the Works submitproposals or take other action as appropriate tominimize any delay and to recover any lost time.
260 SITE MEETINGS General: Site meetings will be held to review progress
and other matters arising from administration of theContract.
Frequency: Every two weeks. Location: on site. Accommodation: Ensure availability at the time of
such meetings.
Attendees: Attend meetings and informsubcontractors and suppliers when their presence isrequired.
Chairperson (who will also take and distributeminutes): Contract Administrator.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
32/94
290 NOTICE OF COMPLETION Requirement: Give notice of the anticipated dates of
completion of the whole or parts of the Works. Associated works: Ensure necessary access, services
and facilities are complete. Period of notice (minimum): Two weeks.
420 REMOVAL/ REPLACEMENT OF EXISTING WORK Extent and location: Agree before commencement. Execution: Carry out in ways that minimize the extent
of work.
430 PROPOSED INSTRUCTIONS Estimates: If a proposed instruction requests an
estimate of cost, submit without delay and in any casewithin seven days.
440 MEASUREMENT Covered work: Give notice before covering work
required to be measured.
460 INTERIM VALUATIONS Applications: Include details of amounts due under
the Contract together with all necessary supportinginformation.
Submission: At least seven days before establisheddates.
470 PRODUCTS NOT INCORPORATED INTO THEWORKS
Ownership: At the time of each valuation, supplydetails of those products not incorporated into theWorks which are subject to any reservation of titleinconsistent with passing of property as required bythe Conditions of Contract, together with theirrespective values.
Evidence: When requested, provide evidence offreedom of reservation of title.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
33/94
A33
QUALITY STANDARDS/ CONTROL
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
34/94
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
35/94
150 INSPECTIONS Products and executions: Inspection or any other
action must not be taken as approval unlessconfirmed in writing referring to:- Date of inspection.
- Part of the work inspected.- Respects or characteristics which are approved.- Extent and purpose of the approval.- Any associated conditions.
160 RELATED WORK Details: Provide all trades with necessary details of
related types of work. Before starting each new typeor section of work ensure previous related work is:- Appropriately complete.- In accordance with the project documents.- To a suitable standard.
- In a suitable condition to receive the new work. Preparatory work: Ensure all necessary preparatorywork has been carried out.
170 MANUFACTURER'S RECOMMENDATIONS/INSTRUCTIONS
General: Comply with manufacturer's printedrecommendations and instructions current on the dateof the Invitation to tender.
Changes to recommendations or instructions: Submitdetails.
Ancillary products and accessories: Use thosesupplied or recommended by main product
manufacturer. Agrment certified products: Comply with limitations,
recommendations and requirements of relevant validcertificates.
180 WATER FOR THE WORKS Mains supply: Clean and uncontaminated. Other: Do not use until:
- Evidence of suitability is provided.- Tested to BS EN 1008 if instructed.
SAMPLES/ APPROVALS
210 SAMPLES Products or executions: Comply with all other
specification requirements and in respect of the statedor implied characteristics either:- To an express approval.- To match a sample expressly approved as a
standard for the purpose.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
36/94
220 APPROVAL OF PRODUCTS Submissions, samples, inspections and tests:
Undertake or arrange to suit the Works programme. Approval: Relates to a sample of the product and not
to the product as used in the Works. Do not confirm
orders or use the product until approval of the samplehas been obtained.
Complying sample: Retain in good, clean condition onsite. Remove when no longer required.
230 APPROVAL OF EXECUTION Submissions, samples, inspections and tests:
Undertake or arrange to suit the Works programme. Approval: Relates to the stated characteristics of the
sample. (If approval of the finished work as a whole isrequired this is specified separately). Do not conceal,or proceed with affected work until compliance with
requirements is confirmed. Complying sample: Retain in good, clean condition onsite. Remove when no longer required.
320 SETTING OUT General: Submit details of methods and equipment to
be used in setting out the Works. Levels and dimensions: Check and record the results
on a copy of drawings. Notify discrepancies andobtain instructions before proceeding.
Inform: When complete and before commencingconstruction.
330 APPEARANCE AND FIT Tolerances and dimensions: If likely to be critical to
execution or difficult to achieve, as early as possibleeither:- Submit proposals; or- Arrange for inspection of appearance of relevant
aspects of partially finished work. General tolerances (maximum): To BS 5606, tables 1
and 2.
340 CRITICAL DIMENSIONS Critical dimensions: Set out and construct the Works
to ensure compliance with the tolerances stated. Location: Detailed on drawings 801638-02 General
Arrangement Drawing, 801638-03 Drainage andEdging Construction Details.
410 SERVICES REGULATIONS New or existing services: Comply with the Byelaws or
Regulations of the relevant Statutory Authority.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
37/94
420 WATER REGULATIONS/ BYELAWS NOTIFICATION Requirements: Notify Water Undertaker of any work
carried out to or which affects new or existing servicesand submit any required plans, diagrams and details.
Consent: Allow adequate time to receive Undertaker's
consent before starting work. Inform immediately ifconsent is withheld or is granted subject to significantconditions.
430 WATER REGULATIONS/ BYELAWSCONTRACTOR'S CERTIFICATE
On completion of the work: Submit (copy where alsorequired to the Water Undertaker) a certificateincluding:- The address of the premises.- A brief description of the new installation and/ or
work carried out to an existing installation.
- The Contractor's name and address.- A statement that the installation complies with therelevant Water Regulations or Byelaws.
- The name and signature of the individualresponsible for checking compliance.
- The date on which the installation was checked.
450 MECHANICAL AND ELECTRICAL SERVICES Final tests and commissioning: Carry out so that
services are in full working order at completion of theWorks.
540 DEFECTS IN EXISTING WORK
Undocumented defects: When discovered,immediately give notice. Do not proceed with affectedrelated work until response has been received.
Documented remedial work: Do not execute workwhich may:- Hinder access to defective products or work; or- Be rendered abortive by remedial work.
560 TESTS AND INSPECTIONS Timing: Agree and record dates and times of tests
and inspections to enable all affected parties to berepresented.
Confirmation: One working day prior to each such test
or inspection. If sample or test is not ready, agree anew date and time.
Records: Submit a copy of test certificates and retaincopies on site.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
38/94
610 DEFECTIVE PRODUCTS/ EXECUTIONS Proposals: Immediately any work or product is known,
or appears, to be not in accordance with the Contract,submit proposals for opening up, inspection, testing,making good, adjustment of the Contract Sum, or
removal and re-execution. Acceptability: Such proposals may be unacceptable
and contrary instructions may be issued.
710 WORK BEFORE COMPLETION General: Make good all damage consequent upon the
Works.Temporary markings, coverings and protectivewrappings: Remove unless otherwise instructed.
Cleaning: Clean the Works thoroughly inside and out,including all accessible ducts and voids. Remove allsplashes, deposits, efflorescence, rubbish and
surplus materials. Cleaning materials and methods: As recommendedby manufacturers of products being cleaned, andmust not damage or disfigure other materials orconstruction.
COSHH dated data sheets: Obtain for all materialsused for cleaning and ensure they are used only asrecommended by their manufacturers.
Minor faults: Touch up in newly painted work,carefully matching colour and brushing out edges.Repaint badly marked areas back to suitable breaksor junctions.
Moving parts of new work: Adjust, ease and lubricate
as necessary to ensure easy and efficient operation,including doors, windows, drawers, ironmongery,appliances, valves and controls.
720 SECURITY AT COMPLETION General: Leave the Works secure with, where
appropriate, all accesses closed and locked. Keys: Account for and adequately label all keys and
hand over to Employer with itemised schedule,retaining duplicate schedule signed by Employer as areceipt.
730 MAKING GOOD DEFECTS
Remedial work: Arrange access with Employer. Rectification: Give reasonable notice for access to the
various parts of the Works. Completion: Notify when remedial works have been
completed.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
39/94
A34
SECURITY/ SAFETY/ PROTECTION
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
40/94
A34 SECURITY/ SAFETY/ PROTECTION
110 PRETENDER HEALTH AND SAFETY PLAN Location: Integral with the project Preliminaries,
including but not restricted to the following sections:- Description of project: Sections A10 and A11.- Client's consideration and management
requirements: Sections A12, A13 and A36.- Environmental restrictions and on-site risks: Section
A12, A35 and A34.- Significant design and construction hazards:
Section A34.- The Health and Safety File: Section A37.
120 EXECUTION HAZARDS
Common hazards: Not listed. Control by goodmanagement and site practice. Significant hazards: The design of the project includes
the following:- Hazard: deep excavations.- Precautions assumed: ensure plant and machinery
is manouvered approipriately and safely arounddeep excavations with adequate warning andprotection for both machine handlers and sitepersonnel.
- Specification reference: R13,620A.- Drawing reference: 801638-02-C General
Arrangement Drawing-rev C, 801638-03-B Land
Drainage & Soakaway Details-rev B.
130 PRODUCT HAZARDS Hazardous substances: Site personnel levels must
not exceed occupational exposure standards andmaximum exposure limits stated in the current versionof HSE document EH40: Occupational ExposureLimits.
Common hazards: Not listed. Control by goodmanagement and site practice.
Significant hazards: Specified construction materialsinclude the following:
- Hazard: epidermal damage.- Material: cementitious materials.- Specification reference: E10,60.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
41/94
140 CONSTRUCTION PHASE HEALTH AND SAFETYPLAN
Submission: Present to the Employer/ Client not lessthan two weeks before commencement on site.
Confirmation: Do not start construction work until the
Employer has confirmed in writing that theConstruction Phase Health and Safety Plan includesthe procedures and arrangements required by CDMRegulation 15(4).
Content: Develop the plan from and draw on theOutline Construction Phase Health and Safety Plan,clause A30/570, and the Pre-tender Health andSafety Plan.
150 SECURITY Protection: Safeguard the site, the Works, products,
materials, and any existing buildings affected by the
Works from damage and theft. Access: Take all reasonable precautions to preventunauthorized access to the site, the Works andadjoining property.
Special requirements: site works to be co-ordinatedwith opening times of school unless alternativearrangements can be made direct with the school.Special care should be taken to ensure that access byschool pupils is controlled when the school is active.
170 OCCUPIED PREMISES Extent: The premises will be occupied and/ or used
during the Contract as follows: Monday to Friday
during school opening/use times. Contractor toconfirmed exact times with school.
Works: Carry out without undue inconvenience andnuisance and without danger to occupants and users.
Overtime: If compliance with this clause requirescertain operations to be carried out during overtime,and such overtime is not required for any otherreason, the extra cost will be paid to the Contractor,provided that such overtime is authorized in advance.
180 PASSES Controlled areas: Passes will be required for access
to school grounds.
Authorised persons: Submit a list of the names of allpersons requiring passes together with any otherrelated information reasonably required.
Return of passes: When requested or on completionof the work to which the pass relates.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
42/94
210 EMPLOYER'S REPRESENTATIVES SITE VISITS Safety: Submit details in advance, to the Employer or
the person identified in clause A10/140, of safetyprovisions and procedures (including those relating tomaterials, which may be deleterious), which will
require their compliance when visiting the site. Protective clothing and/ or equipment: Provide and
maintain on site for the Employer and the personstated in clause A10/140 and other visitors to the site.
330 NOISE CONTROL Standard: Minimize noise levels during execution of
the works. Equipment: Fit compressors, percussion tools and
vehicles with effective silencers of a typerecommended by manufacturers of the compressors,tools or vehicles.
Restrictions: Do not use radios or other audioequipment or permit employees to use in ways or attimes that may cause nuisance.
340 POLLUTION Prevention: Protect the site, the Works and the
general environment including streams andwaterways against pollution.
Contamination: If pollution occurs inform immediately,including to the appropriate Authorities and providerelevant information.
345 FUEL, LUBRICANTS AND HYDRAULIC FLUIDS
Restrictions:- Storing, handling and refuelling: On hard standing
or other approved areas. Keep away fromwatercourses, drains, soil, planting and grassedareas.
- Vehicles and equipment: Ensure there is noleakage or spillage. If spillage occurs, informimmediately and take appropriate emergencyaction.
350 PESTICIDES Use: Not permitted.
360 NUISANCE Duty: Prevent nuisance from smoke, dust, rubbish,
vermin and other causes. Surface water: Prevent hazardous build-up on site, in
excavations and to surrounding areas and roads.
400 BURNING ON SITE Burning on site: Not permitted.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
43/94
430 WASTE Includes: Rubbish, debris, spoil, containers and
surplus material. Minimize: Keep the site and Works clean and tidy. Remove: Frequently and dispose off site in a safe and
competent manner:- Non-hazardous material: In a manner approved by
the Waste Regulation Authority.- Hazardous material: As directed by the Waste
Regulation Authority and in accordance withrelevant regulations.
Voids and cavities in the construction: Removerubbish, dirt and residues before closing in.
Waste transfer documentation: Retain on site.
510 EXISTING SERVICES Confirmation: Notify all service authorities, statutory
undertakers and/ or adjacent owners of proposedworks not less than one week before commencingsite operations.
Identification: Before starting work, check and markpositions of mains/ services. Where positions are notshown on drawings obtain relevant details fromservice authorities, statutory undertakers or otherowners.
Work adjacent to services:- Comply with service authority's/ statutory
undertaker's recommendations.- Adequately protect, and prevent damage to
services: Do not interfere with their operation
without consent of service authorities/ statutoryundertakers or other owners. Identifying services:
- Below ground: Use signboards, giving type anddepth;
- Overhead: Use headroom markers. Damage to services: If any results from execution of
the Works:- Immediately give notice and notify appropriate
service authority/ statutory undertaker.- Make arrangements for the work to be made good
without delay to the satisfaction of service authority/statutory undertaker or other owner as appropriate.
- Any measures taken to deal with an emergency willnot affect the extent of the Contractor's liability. Marker tapes or protective covers: Replace, if
disturbed during site operations, to service authority's/statutory undertakers recommendations.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
44/94
520 ROADS AND FOOTPATHS Duty: Maintain roads and footpaths within and
adjacent to the site and keep clear of mud and debris. Damage caused by site traffic or otherwise
consequent upon the Works: Make good to the
satisfaction of the Employer, Local Authority or otherowner.
530 EXISTING TOPSOIL/ SUBSOIL Duty: Prevent over compaction of existing topsoil and
subsoil in those areas which may be damaged byconstruction traffic, parking of vehicles, temporary siteaccommodation or storage of materials and which willrequire reinstatement prior to completion of theWorks.
Protection: Before starting work submit proposals forprotective measures.
540 RETAINED TREES/ SHRUBS/ GRASSED AREAS Protection: Preserve and prevent damage, except
those not required. Replacement: Mature trees and shrubs if uprooted,
destroyed, or damaged beyond reasonable chance ofsurvival in their original shape, as a consequence ofthe Contractor's negligence, must be replaced withthose of a similar type and age at the Contractor'sexpense.
550 RETAINED TREES Protected area: Unless agreed otherwise do not:
- Dump spoil or rubbish, excavate or disturb topsoil,park vehicles or plant, store materials or placetemporary accommodation within an area which isthe larger of the branch spread of the tree or anarea with a radius of half the tree's height,measured from the trunk.
- Sever roots exceeding 25 mm in diameter. Ifunintentionally severed give notice and seekadvice.
- Change level of ground within an area 3 m beyondbranch spread.
560 EXISTING FEATURES Protection: Prevent damage to existing buildings,
fences, gates, walls, roads, paved areas and othersite features, which are to remain in position duringexecution of the Works.
Special requirements: protect pavement andboundary fencing from vehicles entering and leavingsite.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
45/94
620 ADJOINING PROPERTY Permission: Obtain as necessary from owners if
requiring to erect scaffolding on or otherwise useadjoining property.
625 ADJOINING PROPERTY RESTRICTIONS Precautions:
- Prevent trespass of workpeople and takeprecautions to prevent damage to adjoiningproperty.
- Pay all charges.- Remove and make good on completion or when
directed. Damage: Bear cost of repairing damage arising from
execution of the Works.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
46/94
A35
SPECIFIC LIMITATIONS ON METHOD/ SEQUENCE/TIMING
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
47/94
A35 SPECIFIC LIMITATIONS ON METHOD/SEQUENCE/ TIMING
130 METHOD/ SEQUENCE OF WORK Specific Limitations: Include the following in the
programme:- Topographical surveys are required for the areacontaining contaminated ground before excavationscommence; when excavations have been carried outand upon completion of the works. This will have animpact on work sequencing and should be adressedwithin the work programme in consultation with theappointed Site Investigation consultant.
160 USE OR DISPOSAL OF MATERIALS
Specific limitations: any contaminated excavatedmaterial removed from site should be taken to a tipappropriately licensed for the level of contaminationprevalent.
170 WORKING HOURS Specific limitations: 8.30 to 17.30.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
48/94
A36
FACILITIES/ TEMPORARY WORK/ SERVICES
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
49/94
A36 FACILITIES/ TEMPORARY WORK/SERVICES
110 SPOIL HEAPS, TEMPORARY WORKS ANDSERVICES
Location: Give notice of intended siting. Maintenance: Alter, adapt and move as necessary.
Remove when no longer required and make good.
230 TEMPORARY ACCOMMODATION Proposals for temporary accommodation and storage
for the Works: Submit two weeks prior to theCommencement Date.
Details to be included: Type of accommodation andstorage, its siting and the programme for site
installation and removal.
340 NAME BOARDS/ ADVERTISEMENTS Name boards/ advertisements: Not permitted.
430 WATER Supply: Clean fresh water for the execution of the
Works. Approval: Obtain before using a supply other than
potable mains water.
435 WATER RESTRICTIONS Emergency legislation: If the water supply is or is
likely to be restricted inform without delay andascertain the availability and additional cost of waterfrom alternative sources.
440 TELEPHONES Direct communication: As soon as practicable after
the Date of Possession provide the Contractor'sperson in charge with a mobile telephone.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
50/94
A37
OPERATION/ MAINTENANCE OF THE FINISHEDWORKS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
51/94
A37 OPERATION/ MAINTENANCE OF THEFINISHED WORKS
120 THE HEALTH AND SAFETY FILE Content: to be as prescribed in Pre-tender Health and
Safety Plan. Number of copies: Submit 2 to the Planning
Supervisor. last date for submission: 2 weeks before the date for
completion stated in the contract.
180 MAINTENANCE INFORMATION Content: Include:
- Printed instructions of procedures to be adopted bythe Employer for the maintenance of the Works.
- Copies of manufacturers current literature for allproducts for which the particular proprietary brandhas been chosen by the Contractor, includingwhere appropriate COSHH dated data sheets andmanufacturers recommendations for cleaning andmaintenance.
- Copies of all guarantees, warranties andmaintenance agreements offered by subcontractorsand manufacturers.
- Copies of all test certificates and reports required inthe specification.
Submit: At end of the maintenance period.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
52/94
A50
WORK/ PRODUCTS BY/ ON BEHALF OF THEEMPLOYER
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
53/94
A50 WORK/ PRODUCTS BY/ ON BEHALF OFTHE EMPLOYER
110 WORK BY/ ON BEHALF OF EMPLOYER Title: Remediation and validation of contaminated
ground. Description of work: Site investigation and
topographical surveys. Carried out by: Merseyside Engineers Laboratory
Services (MELS). Attendance: Allow for the following additional to those
reasonably required by the conditions of contract:- Appointment, management and co-ordination of siteinvestigation and topographical surveys within theoverall site works.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
54/94
A54
PROVISIONAL WORK/ ITEMS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
55/94
A54 PROVISIONAL WORK/ ITEMS
525 PROVISIONAL SUM NOT SPECIFICALLY FORWORK - SURETY
"The Contractorshall provide surety for the due andcomplete fulfilment of the Contrsct entered into by theContractor by way of procuring a Guarantee Bondfrom a Gaurantee Society, Bank or insuranceCompany to be approved by the Employer in the sumof 10% of the total amount of the tender plus interestthereon up to a maximum of 10% of the amount of thebond and legal fees up to a maximum of 5,000.00, orshall in lieu of finding such surety, deposit with theEmployer the same aamount in which case thebalance remaining thereof, if any, will, after satisfyingthe suretyship be returned to him but the Employerwill be entitled to retain any interest which may haveaccrued on the sum deposited".
590 CONTINGENCIES Provisional sum: Include: 6,500.00 (Six Thousand,
Five Hundred Pounds.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
56/94
A55
DAYWORKS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
57/94
A55 DAYWORKS
110 LABOUR Provisional sum: Include prime cost of labour incurred
before the Final Completion Date: One thousandpounds.- Percentage adjustment: Add to cover incidental
costs, overheads and profit: %. Provisional sum: Include prime cost of labour incurred
after the Final Completion Date: One thousandpounds.- Percentage adjustment: Add to cover incidental
costs, overheads and profit: %.
120 PRODUCTS
Provisional sum: Include prime cost incurred at anytime during the Contract five hundred pounds.- Percentage adjustment to cover incidental costs,
overheads and profit: %.
130 EQUIPMENT Provisional sum: Include prime cost of plant
(equipment) incurred before the Final CompletionDate: One thousand pounds.- Percentage adjustment to cover incidental costs,
overheads and profit: %. Provisional sum: Include prime cost of plant
(equipment) incurred after the Final Completion Date:
ive hundred pounds.- Percentage adjustment to cover incidental costs,
overheads and profit %. Plant (equipment) costs: Rates set out in the
Schedule of Basic Plant Charges published by theRICS current at the Date of Tender.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
58/94
A(2)
JCLI Agreement for Landscape Maintenance Works
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
59/94
A10
PROJECT PARTICULARS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
60/94
A10 PROJECT PARTICULARS
110 THE PROJECT Name: Blueberry Park Playing Fields. Nature: maintenance of new playing fields. Location: Dunchurch Road, Liverpool, L14. Timescale for completion of the 'construction work': o
ne year after completion.
130 PRINCIPAL CONTRACTOR Name: The Contractor. Address: to be advised. Telephone: to be advised.
140 CONTRACT ADMINISTRATOR (HEREIN
REFERRED TO AS 'CA') Name: Michael Morgan. Address: 2020 Liverpool, West House, Mercury Court,
Tithbarn Street, Liverpool L2 2QP. Telephone: 0151 237 4258.
150 PLANNING SUPERVISOR Name: Derek Bradshaw. Address: 2020 Liverpool, West House, Mercury Court,
Tithebarn Street Liverpool, L2 2QP. Telephone: 0151 237 4100.
180 LANDSCAPE ARCHITECT Name: Michael Morgan. Address: 2020 Liverpool, West House, Mercury Court,
Tithbarn Street, Liverpool L2 2QP. Telephone: 0151 237 4258.
190 CLERK OF WORKS Name: Frank Jones. Address: 2020 Knowsley,9 West Street, Prescot,
Knowsley, Merseyside, L34 1LF. Telephone: 0151 477 2012.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
61/94
A11
TENDER AND CONTRACT DOCUMENTS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
62/94
A11 TENDER AND CONTRACT DOCUMENTS
120 CONTRACT DRAWINGS The contract drawings are included with the tender
documents and are as follows:- 801638-01 Site Location Plan, 801638-02-C Generalarrangement Drawing-rev C.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
63/94
A12
THE SITE/ EXISTING BUILDINGS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
64/94
A12 THE SITE/ EXISTING BUILDINGS
110 THE SITES Locations: The site is a newly created school playing
field. The site adjoins a school playground to the east.On the northern, western and southern sides the siteis bordered by local estate roads with housing locatedon the opposite side of the road. A new steel fenceforms the boundary of the site on three sides with thefourth side being open to the rest of the schoolgrounds and the school building.
200 ACCESS TO THE SITE Description: Entrance to the site will be via the main
school gates and following a route through the school
grounds agreed with a school representative ofappropriate authority. Limitations: Maintenance operations to be carried out
during school opening hours unless alternativearrangements are agreed. Maintenance visits must beby arrangment and with advanced notification tonominated school representative.
220 USE OF THE SITE General: Do not use the site for any purpose other
than carrying out the Works. Limitations: Ensure all pavings are adequately
protected from damage which may be caused by
plant or arisings from the works. Locations of spoilheaps and storage areas to be agreed prior tobeginning work on site.
230 SURROUNDING LAND/ BUILDING USES General: Adjacent or nearby uses or activities are as
follows:- A school is located to the east of the maintenancearea. Housing lies to the north, west and south.
250 SITE VISIT Before tendering: Ascertain the nature of the site,
access thereto and all local conditions and restrictionslikely to affect the execution of the Works.
Arrangements for visit: by appointmant with school.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
65/94
A13
DESCRIPTION OF THE WORK
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
66/94
A13 DESCRIPTION OF THE WORK
120 THE WORK Description: maintenance of newly installed school
playing fields.
130 WORK BY OTHERS CONCURRENT WITH THECONTRACT
Scope: See section A50.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
67/94
A20
JCLI AGREEMENT FOR LANDSCAPEMAINTENANCE WORKS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
68/94
A20 JCLI AGREEMENT FOR LANDSCAPEMAINTENANCE WORKS
JCLI AGREEMENT FOR LANDSCAPEMAINTENANCE WORKS
The contract: JCLI Agreement for LandscapeMaintenance Works, February 2002 revision of 1998Edition (incorporating Amendment LMW1) andincluding Supplemental Conditions.
Requirement: Allow for the obligations, liabilities andservices described therein against the followingheadings:
THE RECITALS
1st - LOCATION OF WORK AND CONTRACTADMINISTRATOR
Landscape maintenance work to be carried out at:Blueberry Park Playing Fields.
Contract Administrator: See clause A10/140.
2nd - CONTRACT DOCUMENTS The references to list of items of maintenance work,
schedules and schedule of liquidated damages will bedeleted.
3rd - PRICED DOCUMENTS The references to schedules will be deleted.
THE ARTICLES
2 - CONTRACT SUM Alternative A will apply. Alternative B will be deleted. The contract sum will be divided as follows: quarterley
3 - CONTRACT ADMINISTRATOR Contract Administrator: See clause A10/140.
5A - DISPUTE OR DIFFERENCE ARBITRATION Article 5A applies. Article 5B will be deleted.
THE CONDITIONS
1 - INTENTIONS OF THE PARTIES
2 - COMMENCEMENT AND DURATION
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
69/94
2.1 - COMMENCEMENT AND DURATION The Works shall be carried out from: the date of
completion of the construction works (the'Commencement date')and shall continue until: 12 months after the date of
commencement (the 'End date').
3 - CONTROL OF THE WORKS
3.5 - CONTRACT ADMINISTRATOR'SINSTRUCTIONS
Period for compliance: five days.
4 - PAYMENT
4.2 - PERIODIC PAYMENTS Periodic payments: Payment intervals: quarterley.
4.5A - BONUS Clause 4.5A will be deleted.
4.5B - LIQUIDATED DAMAGES Clause 4.5B will be deleted.
4.6 - CONTRIBUTION, LEVY AND TAX CHANGES Clause 4.6 will be deleted.
5 - STATUTORY OBLIGATIONS
5.2 - VALUE ADDED TAX Clause B1.1 of the Supplemental Conditions does
apply.
6 - INJURY, DAMAGE AND INSURANCE
6.2 - INJURY OR DAMAGE TO PROPERTY Insurance cover, for any one occurrence or series of
occurrences arising out of one event, to be not lessthan: 1,000,000.00.
7 - DETERMINATION
7.2 - DETERMINATION BY EMPLOYER Number of failure events: two. Period: one month.
7.3 - DETERMINATION BY CONTRACTOR Period of suspension: one month.
8 - SETTLEMENT OF DISPUTES
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
70/94
A30
TENDERING/ SUBLETTING
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
71/94
A30 TENDERING/ SUBLETTING
110 SCOPE General: These conditions are supplementary to
those stated in the Invitation to Tender and on theform of tender.
145 TENDERING PROCEDURE General: In accordance with JCT Practice Note 6
(Series 2) 'Main Contract Tendering'. Errors: Alternative 2 is to apply.
160 EXCLUSIONS Inability to tender: Immediately inform if any parts of
the work as defined in the tender documents cannot
be tendered. Relevant parts of the work: Define those parts, stating
reasons for the inability to tender.
170 ACCEPTANCE OF TENDER The Employer and Employer's representatives:
- Offer no guarantee that any tender will berecommended for acceptance or be accepted.
- Will not be responsible for any cost incurred in thepreparation of any tender.
190 PERIOD OF VALIDITY Period: After submission or lodgement, keep tender
open for consideration (unless previously withdrawn)for not less than 3 months.
Date for possession/ commencement: See sectionA20.
PRICING/ SUBMISSION OF DOCUMENTS
210 DESCRIPTIONS Scope: General requirements and full descriptions of
work and materials are not repeated in the listed orscheduled items of maintenance work and referenceshould be made to the Conditions of Contract,Preliminaries, Specification and Drawings.
215 TENDER DOCUMENTS Alterations and qualifications: Do not alter or qualify
tender documents without written consent. Tenderscontaining unauthorised alterations or qualificationsmay be rejected.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
72/94
300 QUANTITIES IN THE PRICED DOCUMENT Quantities: Where included in the priced document,
these have been prepared in accordance with SMM7only where and to the extent stated.
Other items, descriptions and measurements:
- Must not be relied upon as complying with apublished standard method of measurement.
- Must be priced taking account of the informationgiven elsewhere in the tender documents, includingfor all associated and ancillary work shown orclearly apparent as being necessary for thecomplete and proper execution of the work.
305 PRICING OF MAINTENANCE WORK Prices and rates: For all listed, specified or scheduled
items of maintenance work are deemed to beinclusive of all labour, materials, temporary works,
mechanical plant, overheads and profit. Includinggeneral liabilities, obligations and risks described orimplied in the tender documents.
Items not priced: Costs will be deemed to have beenincluded elsewhere.
Priced document: Submit with the tender.
440 SCHEDULE OF RATES Schedule of rates (unpriced): Included with the tender
documents. The Contractor may insert additionalitems. All items must be fully priced.
Fully priced copy: Submit with the tender.
480 PROGRAMME Content: As specified in clause A32/210 or a
summary. Submit: With the tender.
485 DESIGN/ MANAGEMENT OBJECTIVES Statement: To meet Employer's objectives in terms of
the evolution of the landscape and provision of aservice to public/ users.
Submit: With the tender.
550 HEALTH AND SAFETY INFORMATION Content: Describe the organisation and resources to
safeguard the health and safety of operatives,including those of subcontractors, and of any personwho may be affected by the maintenance work.
Submit: With the tender.
560 TRAINING OF OPERATIVES Training policy: Describe and submit with the tender. Training records: Prior to their starting work, the
training record and experience of each operative mustbe approved.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
73/94
SUBLETTING/ SUPPLY
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
74/94
A31
PROVISION, CONTENT AND USE OF DOCUMENTS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
75/94
A31 PROVISION, CONTENT AND USE OFDOCUMENTS
DEFINITIONS AND INTERPRETATIONS
110 DEFINITIONS Meaning: Terms, derived terms and synonyms used
in the preliminaries/ general conditions andspecification are as stated therein or in theappropriate British Standard or British Standardglossary.
120 COMMUNICATION Definition: Includes advise, inform, submit, give
notice, instruct, agree, confirm, seek or obtain
information, consent or instructions, or makearrangements.
Format: In writing to the person named in clauseA10/140 unless specified otherwise.
Response: Do not proceed until response has beenreceived.
130 PRODUCTS Definition: Materials, both manufactured and naturally
occurring, and goods, including components,equipment and accessories, intended for thepermanent incorporation in the Works.
Includes: Goods, plant, materials, site materials and
things for incorporation into the Works.
135 SITE EQUIPMENT Definition: All appliances or things of whatsoever
nature required in or about the construction forcompletion of the Works but not materials or otherthings intended to form or forming part of thePermanent Works.
Includes: Construction appliances, vehicles,consumables, tools, temporary works, scaffolding,cabins and other site facilities.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
76/94
210 CROSS REFERENCES Accuracy: Check remainder of the annotation or item
description against the terminology used in thesection or clause referred to.
Related terminology: Where a numerical cross-
reference is not given the relevant sections andclauses of the specification will apply.
Relevant clauses: Clauses in the referred tospecification section dealing with general matters,ancillary products and execution also apply.
Discrepancy or ambiguity: Before proceeding, obtainclarification or instructions.
220 REFERENCED DOCUMENTS Conflicts: Specification prevails over referenced
documents.
230 EQUIVALENT PRODUCTS Inadvertent omission: Wherever products are
specified by proprietary name the phrase 'orequivalent' is to be deemed included.
DOCUMENTS PROVIDED ON BEHALF OFEMPLOYER
410 ADDITIONAL COPIES OF DRAWINGS/DOCUMENTS
Copies: Two of each contract drawing and contractdocument will be issued free of charge (not countingany certified copies).
Additional copies: Issued on request and charged tothe Contractor.
440 DIMENSIONS Scaled dimensions: Do not rely on.
460 THE SPECIFICATION Coordination: All sections must be read in conjunction
with Main Contract Preliminaries/ General conditions.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
77/94
A32
MANAGEMENT OF THE WORKS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
78/94
A32 MANAGEMENT OF THE WORKS
GENERALLY
110 SUPERVISION General: Accept responsibility for coordination,
supervision and administration of the Works, includingsubcontracts.
Coordination: Arrange and monitor a programme witheach subcontractor, supplier, local authority andstatutory undertaker, and obtain and supplyinformation as necessary for coordination of the work.
120 INSURANCE Documentary evidence: Before starting work on site
submit details, and/ or policies and receipts for theinsurances required by the Conditions of Contract.
130 INSURANCE CLAIMS Notice: If any event occurs which may give rise to any
claim or proceeding in respect of loss or damage tothe Works or injury or damage to persons or propertyarising out of the Works, immediately give notice tothe Employer, the person named in clause A10/140and the Insurers.
Failure to notify: Indemnify the Employer against anyloss, which may be caused by failure to give suchnotice.
PROGRAMME/ PROGRESS
210 PROGRAMME Master programme: Immediately when requested and
before starting work on site submit in an approvedform a master programme showing the proposedsequence and timing of the principal maintenanceoperations.
Allow for: coordination of maintenance operations withthe schools use of the playing fields.
Submit: two number copies.
260 SITE MEETINGS General: Attend to review progress and other matters
arising from administration of the Contract. Location: on site. Frequency: as required. Chairperson (who will also take and distribute
minutes): Contract Administrator.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
79/94
CONTROL OF COST
430 PROPOSED INSTRUCTIONS Estimates: If a proposed instruction requests an
estimate of cost, submit without delay and in any case
within seven days.
460 PERIODIC PAYMENTS Applications: Include details of amounts considered
due under the Contract together with all necessarysupporting information.
Submission: At least seven days before establisheddates.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
80/94
A33
QUALITY STANDARDS/ CONTROL
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
81/94
A33 QUALITY STANDARDS/ CONTROL
110 INCOMPLETE DOCUMENTATION General: Where and to the extent that products or
work are not fully documented, they are to be:- Of a kind and standard appropriate to the nature
and character of that part of the Works where theywill be used.
- Suitable for the purposes stated or reasonably to beinferred from the project documents.Contract documents: Omissions or errors indescription and/ or quantity shall not vitiate theContract nor release the Contractor from anyobligations or liabilities under the Contract.
130 QUALITY OF PRODUCTS Generally: New. (Proposals for recycled products maybe considered).
Supply of each product: From the same source ormanufacturer.
Whole quantity of each product required to completethe Works:Consistent in kind, size, quality and overallappearance.
Source of supply: Submit evidence when requested.
170 MANUFACTURER'S RECOMMENDATIONS/INSTRUCTIONS
General: Comply with manufacturer's printedrecommendations and instructions current on the dateof the Invitation to tender.
Changes to recommendations or instructions: Submitdetails.
Ancillary products and accessories: Use thosesupplied or recommended by main productmanufacturer.
Agrment certified products: Comply with limitations,recommendations and requirements of relevant validcertificates.
180 WATER FOR THE WORKS
Mains supply: Clean and uncontaminated. Other: Do not use until:
- Evidence of suitability is provided.- Tested to BS EN 1008 if instructed.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
82/94
220 APPROVAL OF PRODUCTS Submissions, samples, inspections and tests:
Undertake or arrange to suit the Works programme. Approval: Relates to a sample of the product and not
to the product as used in the Works. Do not confirm
orders or use the product until approval of the samplehas been obtained.
Complying sample: Retain in good, clean condition onsite. Remove when no longer required.
230 APPROVAL OF EXECUTION Submissions, samples, inspections and tests:
Undertake or arrange to suit the Works programme. Approval: Relates to the stated characteristics of the
sample. (If approval of the finished work as a whole isrequired this is specified separately). Do not conceal,or proceed with affected work until compliance with
requirements is confirmed. Complying sample: Retain in good, clean condition onsite. Remove when no longer required.
510 SUPERVISION Replacement: Give maximum possible notice before
changing person in charge or site agent.
650 MAINTENANCE RECORD SHEETS Scope: Submit accurate records of maintenance
operations carried out including delays due to adverseweather or ground conditions.
Content: Descriptions of:
- weather.- ground conditions encountered.- work affected.- number of hours lost.
Frequency of submission: on request
660 MAINTENANCE DOCKETS Submit: On completion of the maintenance operation. Format: Maintenance dockets should include the
name of the site, date of visit, activity and becountersigned by a representative of the Employer ifthe site is occupied..
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
83/94
A34
SECURITY/ SAFETY/ PROTECTION
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
84/94
A34 SECURITY/ SAFETY/ PROTECTION
130 PRODUCT HAZARDS Hazardous substances: Site personnel levels must
not exceed occupational exposure standards andmaximum exposure limits stated in the current versionof HSE document EH40: Occupational ExposureLimits.
Common hazards: Not listed. Control by goodmanagement and site practice.
Significant hazards: Specified construction materialsinclude the following:- Hazard: poisoning.- Material: fertilizer and herbicide.- Specification reference: Q35.
150 SECURITY Protection: Safeguard the site, the Works, products,
materials, and any existing buildings affected by theWorks from damage and theft.
Access: Take all reasonable precautions to preventunauthorized access to the site, the Works andadjoining property.
Special requirements: Ensure security proposals areco-ordinated with specific arrangements operated bythe adjoining school.
170 OCCUPIED PREMISES Extent: The premises will be occupied and/ or used
during the Contract as follows: pupils and teachingstaff during the day and evening.
Works: Carry out without undue inconvenience andnuisance and without danger to occupants and users.
Overtime: If compliance with this clause requirescertain operations to be carried out during overtime,and such overtime is not required for any otherreason, the extra cost will be paid to the Contractor,provided that such overtime is authorized in advance.
180 PASSES
Controlled areas: Passes will be required for accessto School grounds.
Authorised persons: Submit a list of the names of allpersons requiring passes together with any otherrelated information reasonably required.
Return of passes: When requested or on completionof the work to which the pass relates.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
85/94
275 VANDALISM Vandalism or malicious damage: Give notice
immediately.
330 NOISE CONTROL Standard: Minimize noise levels during execution of
the works. Equipment: Fit compressors, percussion tools and
vehicles with effective silencers of a typerecommended by manufacturers of the compressors,tools or vehicles.
Restrictions: Do not use radios or other audioequipment or permit employees to use in ways or attimes that may cause nuisance.
340 POLLUTION Prevention: Protect the site, the Works and the
general environment including streams andwaterways against pollution. Contamination: If pollution occurs inform immediately,
including to the appropriate Authorities and providerelevant information.
345 FUEL, LUBRICANTS AND HYDRAULIC FLUIDS Restrictions:
- Storing, handling and refuelling: On hard standingor other approved areas. Keep away fromwatercourses, drains, soil, planting and grassedareas.
- Vehicles and equipment: Ensure there is no
leakage or spillage. If spillage occurs, informimmediately and take appropriate emergencyaction.
350 PESTICIDES Use: Not permitted.
360 NUISANCE Duty: Prevent nuisance from smoke, dust, rubbish,
vermin and other causes. Surface water: Prevent hazardous build-up on site, in
excavations and to surrounding areas and roads.
400 BURNING ON SITE Burning on site: Not permitted.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
86/94
430 WASTE Includes: Rubbish, debris, spoil, containers and
surplus material. Minimize: Keep the site and Works clean and tidy. Remove: Frequently and dispose off site in a safe and
competent manner:- Non-hazardous material: In a manner approved by
the Waste Regulation Authority.- Hazardous material: As directed by the Waste
Regulation Authority and in accordance withrelevant regulations.
Voids and cavities in the construction: Removerubbish, dirt and residues before closing in.
Waste transfer documentation: Retain on site.
520 ROADS AND FOOTPATHS Duty: Maintain roads and footpaths within and
adjacent to the site and keep clear of mud and debris. Damage caused by site traffic or otherwiseconsequent upon the Works: Make good to thesatisfaction of the Employer, Local Authority or otherowner.
530 EXISTING TOPSOIL/ SUBSOIL Duty: Prevent over compaction of existing topsoil and
subsoil in those areas which may be damaged byconstruction traffic, parking of vehicles, temporary siteaccommodation or storage of materials and which willrequire reinstatement prior to completion of theWorks.
Protection: Before starting work submit proposals forprotective measures.
560 EXISTING FEATURES Protection: Prevent damage to existing buildings,
fences, gates, walls, roads, paved areas and othersite features, which are to remain in position duringexecution of the Works.
Special requirements: none.
620 ADJOINING PROPERTY Permission: Obtain as necessary from owners if
requiring to erect scaffolding on or otherwise use
adjoining property.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
87/94
625 ADJOINING PROPERTY RESTRICTIONS Precautions:
- Prevent trespass of workpeople and takeprecautions to prevent damage to adjoiningproperty.
- Pay all charges.- Remove and make good on completion or when
directed. Damage: Bear cost of repairing damage arising from
execution of the Works.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
88/94
A35
SPECIFIC LIMITATIONS ON METHOD/ SEQUENCE/TIMING
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
89/94
A35 SPECIFIC LIMITATIONS ON METHOD/SEQUENCE/ TIMING
130 METHOD/ SEQUENCE OF WORK Specific Limitations: Include the following in the
programme:- co-ordinate maintenance operations to comply withschool requirements for use of pitches.
160 USE OR DISPOSAL OF MATERIALS Specific limitations: position of temporary stockpiles of
arisings to be agreed with school and to be removedfrom site at the end of maintenance visit.
170 WORKING HOURS
Specific limitations: maintenance to be carried outduring school opening hours. Co-ordinate with school.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
90/94
A36
FACILITIES/ TEMPORARY WORK/ SERVICES
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
91/94
A36 FACILITIES/ TEMPORARY WORK/SERVICES
110 SPOIL HEAPS, TEMPORARY WORKS ANDSERVICES
Location: Give notice of intended siting. Maintenance: Alter, adapt and move as necessary.
Remove when no longer required and make good.
230 TEMPORARY ACCOMMODATION Proposals for temporary accommodation and storage
for the Works: Submit two weeks prior to theCommencement Date.
Details to be included: Type of accommodation andstorage, its siting and the programme for site
installation and removal.
310 ROADS Permanent roads, hard standings and footpaths on
the site: The following may be used, subject to clauseA34/520:- Details: Car park and paths within school grounds
giving acces to the site to be maintained.- Restrictions on use: hours of use must be agreed
with appropriate school representative.- Protective or remedial measures: employ
appropriate protection of hard surfaces fromdamage and make good damage that occurs as a
consequence of the works.
340 NAME BOARDS/ ADVERTISEMENTS Name boards/ advertisements: Not permitted.
420 LIGHTING AND POWER Supply: Provide electricity and all equipment and
make temporary arrangements for distribution aboutthe site.
430 WATER Supply: Clean fresh water for the execution of the
Works. Approval: Obtain before using a supply other than
potable mains water.
435 WATER RESTRICTIONS Emergency legislation: If the water supply is or is
likely to be restricted inform without delay andascertain the availability and additional cost of waterfrom alternative sources.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
92/94
440 TELEPHONES Direct communication: As soon as practicable after
the Date of Possession provide the Contractor'sperson in charge with a mobile telephone.
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
93/94
A54
PROVISIONAL WORK/ ITEMS
-
8/4/2019 Blueberry Park School Playing Fields PRELIMStcm21-100237
94/94
A54 PROVISIONAL WORK/ ITEMS
580 ADDITIONAL WORK Action: Notify as soon as it becomes apparent that
additional maintenance or repair work is required. Donot commence additional work without a specificinstruction.
590 CONTINGENCIES Provisional sum: Include: 330.00 (Three Hundred
and Thirty Pounds).