SOUTH EASTERN RAILWAY - ser.indianrailways.gov.in · page 1 of 58 दण प ूव रेलवे...

of 58

द��ण पूव रेलवे

SOUTH EASTERN RAILWAY

न�वदा न�वदा न�वदा न�वदा कागजातकागजातकागजातकागजात

TENDER DOCUMENT

Tender Notice No. : TRD/ADA/OT-2015/4/ TW/ Mark-II , dtd 17.07.2015

Name of the Work: : Replacement of 5 nos. Perkins Make Engine of Four Wheeler Mark II Tower wagon by TATA Engine and Repair of 02 nos. of Mark II Tower wagon of Adra Division of S.E.Railway

Cost of Tender form : Rs 3,420/- ( Rupees Three Thousand Four Hundred Twenty only ) ( Tender paper cost: Rs 3,000/- & Service Tax of Rs 420/- )

Date of Opening Of tender : 27.08.2015

Approximate Tender Value : Rs 44,08,106/- ( Rupees Forty Four Lakh Eight Thousand One Hundred Six only )

Earnest Money: : Rs. 88,170/- (Rupees Eighty Eight Thousand One Hundred Seventy only).

SOLD TO :

M/s ---------------------------

---------------------------------

MONEY RECEIPT NO. -----

Date :

व*र+ मडंल �व/ुत अ2भयतंाव*र+ मडंल �व/ुत अ2भयतंाव*र+ मडंल �व/ुत अ2भयतंाव*र+ मडंल �व/ुत अ2भयतंा( ( ( ( कककक....�व�व�व�व.).).).)

दददद....पूपपूूपू....रेलवे रेलवे रेलवे रेलवे ////आ8ाआ8ाआ8ाआ8ा Sr. Divl. Elect. Engineer (TRD)

S.E.Railway/Adra

of 58


ADRA DIVISION Description of Work: Replacement of 5 nos. Perkins Make Engine of Four

Wheeler Mark II Tower wagon by TATA Engine and Repair of 02 nos. of Mark II Tower wagon of Adra Division of S.E.Railway

Sr. No. Contents Page No.

1 Tender paper Money receipt form 1

2 Index 2

3 Tender Notice 3-5

4 Instructions to Tenderers & Terms and Conditions

6-20

5 Conditions of Prices and Payment Terms 21-22

6 Special Conditions -I 23-26

7 Performance Report Sheet 27-28

8 Indemnity Bond 29

9 Bank Guarantee Bond 30

10 Tender Offer Letter 31

11 Quoted Tender Rate – Sheet 32

12 Tender Schedule 33-46

13 Special Conditions -II 47-48

14 Explanatory Notes on Schedule of items 49-58

15 Total Pages 58

Sr. Divisional Electrical Engineer (TRD)

S. E. Railway, Adra

of 58


OPEN TENDER NOTICE NO:TRD/ADA/OT-2015/4/ TW/Madk-III , dtd 17.07.2015 Sr. Divisional Electrical Engineer (Traction Distribution), S.E.Railway, Adra, for and

on behalf of the President of India, invites sealed tenders for the following work, from

the reputed firms/contractors with sufficient experience and financial capabilities

including those registered with any Government Department or Public Undertakings

and have executed similar nature of works.

1 Description of Work Replacement of 5 nos. Perkins Make Engine of Four Wheeler Mark II Tower wagon by TATA Engine and Repair of 02 nos. of Mark II Tower wagon of Adra Division of S.E.Railway

2 Approximate Tender Value Rs 44,08,106/- ( Rupees Forty Four Lakh Eight Thousand One Hundred Six only )

3 Earnest Money Deposit Rs. 88,170/- (Rupees Eighty Eight Thousand One Hundred Seventy only).

4 Cost of the Tender Forms Rs 3,420/- ( Rupees Three Thousand Four Hundred Twenty only ) ( Tender paper cost: Rs 3,000/- & Service Tax of Rs 420/- )

5 Completion Period 06 months from the date of issue of LOA.

6 Date, Time & Place of Selling of tender

Tender Forms can be obtained from the Office of the Sr. Divl. Elect. Engineer (TRD), S.E.Railway, Adra and Chief Elect. Engineer S.E.Railway, Garden Reach during working hrs. from 28.07.2015 to 27.08.2015 (14:00 Hrs) on production of original money receipt for Rs 3,420/- (non-refundable)

7 Date, Time & Place of Closing

Up to 15:00 hrs. of 27.08.2015 The Tender may be dropped in the special box available in the office of the Sr. DEE(TRD)/S. E. Railway , Adra or office of the CEE/GRC/S.E.Railway during office hours.

8 Date, Time & Place of Opening of tender

At office of the Sr.DEE (TRD)/S.E.Railway, Adra and office of the CEE/GRC/S.E.Railway. 15:30 hrs. of 27.08.2015 simultaneously

9. The following documents should be specified for submission along with tender.

a) List of Personnel, Organization available on hand and proposed to be engaged for the subject work.

b) List of Plant & Machinery available on hand (own) and proposed to be inducted (own hired to be given separately) for the subject work.

c) List of works completed in the last three financial years giving description of work, organization for whom executed, approximate value of contract at the

of 58

time of award, date of award and date of scheduled completion of the work. Date of actual start, actual completion and final value of contract should also be given with supportive documents/certificates from the organizations with whom they worked/are working should be enclosed. No certificate from private individual for whom such works are executed/being executed would be accepted.

d) List of works on hand indicating description of work contract value, approximate value of balance work yet to be done and date of award with supportive documents/certificates from the organizations with whom they worked/are working should be enclosed. No certificate from private individual for whom such works are executed/being executed would be accepted.

11. Tenders must be accompanied with prescribed amount of earnest money in acceptable form as mentioned in the tender document. Earnest money in the form of Guarantee Bond will not be accepted. Tender without prescribed earnest money will liable to be summarily rejected.

12. Tender Documents should not be sent by Ordinary Post. Tenders received in this office by Registered Post on or before 15:00 hrs. of 27.08.2015 will be deposited in the Tender Box before the closer.

13. In case the office remains closed on the date of opening of the tender for any unforeseen circumstances, the tenders will be received and opened on the next working day at the same time and place.

14. The Railways reserves the right to accept or reject any bid including the lowest one or all the Tenders or part thereof and split the contract without assigning any reason. Conditional bids incomplete/delayed offers for any reason shall stand rejected.

15. Request for issue of tender paper through post is not acceptable. 16. Tender forms are not transferable. 17. The tenderer can also download the tender documents from the NIC’s web site

http://tenders.gov.in , S.E.Railway’s website www.ser.indianrailways.gov.in and can also be dropped in the tender box .However, Tenderer/s will have to deposit non-refundable Demand Draft in favour of FA & CAO, Garden Reach, S.E. Railway or Money Receipt for requisite amount issued by Chief cashier /GRC or Divnl. Cashier/Adra or Chief booking Clerk /Adra as a cost of Tender Form which will have to be attached with the tender Form otherwise the tender Form will be summarily rejected.

Railway administration will not be responsible for any delay/difficulties/ inaccessibility of the downloading facility for any reason whatsoever. In case of any discrepancy between the tender documents downloaded from internet and the master copy available in the office of Sr. DEE (TRD)/ADA, the latter shall prevail and will be binding on the tenderers. No claim on this account shall be entertained.

Sr. Divl.Elect.Engineer (TRD)/ADA

For and on behalf of The President of India

of 58


ADRA DIVISION

Four -Wheeler Mark-II TW Repairing Works

Tender Notice No & Description of Work Approx. value (Rs) E.M.D (Rs.)

1. TRD/ADA/OT-2015/4/ TW/Madk-III , dtd 17.07.2015

Replacement of 5 nos. Perkins Make Engine of Four Wheeler Mark II Tower wagon by TATA Engine and Repair of 02 nos. of Mark II Tower wagon of Adra Division of S.E.Railway

Rs 44,08,106/- Rs. 88,170/-

Cost of Tender Forms :

Rs 3,420/- ( Rupees Three Thousand Four Hundred Twenty only ) ( Tender paper cost: Rs 3,000/- & Service Tax of Rs 420/- )

Selling of Tender :

Tender form can be obtained from the office of Sr. Divisional Electrical Engineer (TRD)/ADA or the office of CEE/GRC, S.E. Railway from 28.07.2015 to 27.08.2015 (14:00 hrs.)

Date, Time & Place of Closing

Up to 15:00 hrs. of 27.08.2015 The Tender may be dropped in the special box available in the office of the Sr. DEE(TRD)/S. E. Railway , Adra or office of the CEE/GRC/S.E.Railway during office hours.

Date of Opening of Tender :

27.08.2015 (15:30hrs.) at the office of Sr. Divisional Electrical Engineer (TRD)/ADA and the office of CEE/GRC, S.E.Railway

Completion Period : 06 months from the date of issue of L.O.A.

Tender Notice is available at NIC’s web site http://tenders.gov.in , S.E.Railway’s website www.ser.indianrailways.gov.in . Tenderers can also download the tender document from the above website from 28.07.2015 and up to 14:00 hrs. on 27.08.2015 . Tender notice is also available at the notice board of Sr. DEE/TRD/ADA’s office.

Sr. Divl. Elect. Engineer (TRD)/ADA For and on behalf of The President of India

of 58

CHAPTER-I

INSTRUCTION TO TENDERERS AND TERMS AND CONDITION OF TENDERING. (To be signed by the Tenderer and submitted along with the tender)

1.1.1 TENDER PAPER DOCUMENT. The tender paper/documents are divided into Two parts. The part-I consists of Tender notice, instructions to tenderer and terms and condition for tendering including conditions of pricing and payment. Part-II consists of the following.

a) Special conditions of tendering b) Tender form c) Schedule of Price with its explanatory note

1.1.2 GENERAL INSTRUCTIONS It may be noted here that the conditions of General conditions of contract (G.C.C.)(with the latest amendment, if any) of S. E. Railway, all provisions of relevant codes, manual etc.( with the latest amendment, if any), are generally applicable unless specifically mentioned otherwise in this paper. The intending tenderer before submission of tender is advised that in his own interest to study the tender papers carefully without prejudice to the generally of the foregoing and the tenderer shall inspect the site and surrounding of the works specified in the tender documents and shall satisfy himself by careful examination before submission of the tender as the nature of site , soil and local conditions, availability of labour and materials for execution of work, the means of access to site supply of power, water, availability of accommodation etc. and shall make local and independent inquiries as to matters for and things referred to or implied in the tender documents Railways shall not entertain the tenderer in any form or plea of ignorance, difficulties doubts, misconception and mis-appreciation thereof effecting the execution and completion of work. 1.1.3 ALTERNATIVE PROPOSALS: Should the tenderer have alternative proposals for arrangement design and specification which the tenderer considers would reduce the cost of the installation, improve the performance and reliability he should incorporate them in the tender (form 5) for consideration by the purchaser. He shall clearly indicate the technical and financial advantage which would accrue to the purchaser for such alternative proposals suggested by him. Such proposals, shall however be given without any loss of generally of the specification and drawing obtained herein. 1.1.4 SUBMISSION OF TENDER: The tender must be submitted in sealed envelope marked with the tender No. and the name of the work and should dropped in the sealed TENDER BOX’ kept for the purpose at the time as mentioned in the Tender Notice for this purpose. Tenders, sealed and super scribed as above, may also be sent by Registered post addressed to the above mentioned office so as to reach earlier to the date and time of the closing of the tender, No tender which is received after the time and date specified above will be considered under any circumstances. Any tender delivered or sent otherwise will be at the risk of the tenderer. All documents to be submitted in connection with the tender shall be written in English and in ink. 1.1.5 RATES: The tenderer(s) should quote only uniform percentage (ABOVE/BELOW) the rates of all items given in schedule of prices any tender received with different percentage for different items of the schedule stands; summarily rejected. CONDITIONAL OFFERS WILL BE SUMMARILY REJECTED. 1.1.6 CLARIFICATION Clarification required by the tenderer may be obtained from the office of the Sr. Divisional Electrical Engineer (TRD), Adra or as prescribed. 1.1.7 INCOME TAX AND SALES TAX CLEARANCE CERTIFICATE: The tenderer is required to produce along with his tender the current and valid income tax and sales tax clearances certificate, in original (which will be returned when done with) without which the tender will be rejected. The successful tenderer shall have to send current income tax and sales tax clearances along with the bill without which no payment would be made to him.

of 58

1.1.8 TAX DEDUCTION: Income Tax @ 2% plus surcharges as applicable on the amount to be paid by the contractor in pursuance of the contract which will be deducted from the bills preferred by him in accordance with section 1204C of the Income Tax Act.1961 as introduced through finance Act of 1972 or as amended from time to time, @ 4% OWST/JWST/WBST will be recovered where it is applicable. In addition to 1% C.Cess is also recoverable if the site of work falls under the Railway settlement limit. 1.1.9 LICENCE AND ELECTRICAL CONTRACTORS CERTIFICATE. Deleted 1.1.10 SIGNING OF TENDERS AND POWER OF ATTORNEY: In case of a firm not registered under partnership Act, all the partners or the attorney duly authorized by all of them should sign the tender and other connected documents. A copy of the document empowering the individual to sign should also be sent with the tender. In any case, tender should disclose his constitution fully and copies of all necessary legal documents in support thereof should be submitted with the tender and originals thereof should be produced as and when called for.

1.1.10.1 Any individual signing the tender or other documents connected therewith should specify whether he is signing.

(i) As sole proprietor of concerned or his attorney or (ii) As a partner or partners of the firm or (iii) For the firm per procreations or (iv) As a director, Manager or Secretary in the case of limited company.

1.1.11 TENDER ADDRESSES: Every tenderer shall state in the tender his postal address fully and clearly. Any communication sent to the tenderer by post at his said address shall be deemed to have reached the tenderer duly and in time notwithstanding the fact that the communication did not reach the tenderer at all or in time for the reasons whatsoever Important document shall be sent by Registered post.

1.1.12 ERASURES OR ALTERNATION: No erasure or alternation in the text of the tender paper is permitted and any such erasure and/or alternation will either be disregarded or render the whole tender void at the option of the Railway Administration. Any correction made in rates for the work shall be initiated in ink and dated. 1.1.13 COMPLIANCE WITH INSTRUCTIONS: Tender which do not comply with the instructions detailed above shall not be considered. 1.1.14 RESULTS OF TENDER : The acceptance of the tender will rest with Sr. Divisional Electrical Engineer (TRD), S.E.Railway, Adra for and on behalf of the president of India who reserves the right to decide the tender amongst more than one tenderer, if deemed necessary and also to reject any or all tenders received without assigning any reasons and does not bind himself to accept the lowest or any tender. 1.1.15 VALIDITY OF TENDER : The contractor shall keep the offer viz. the tender and/or tenders as may be modified by negotiations open for acceptance for a period of 120 days from the date on which tender/tenders is/are opened and in default, the Earnest Money deposited by him shall be forfeited to the Railway. 1.1.16 TIME SCHEDULE AND PROGRAMME: The contractor shall strictly follow the time schedule for all works under this as mentioned in the tender notice if the contractor fails to execute the work completely within the time specified or an authorized extensions thereof, Railway Administration is entitled to recover from the contractor a sum of half percent of the price of that portion of the work not completed by the due date for each and every week or part of the week taken extra by the contractor to complete the work . The amount of damages recovered shall in no case exceed 10% of the value of the contract. If such a failure as aforesaid shall have arisen from any cause which the purchaser may admit as being a reasonable ground for extension of time, the purchaser shall allow such additional time as he may in his absolute discretion consider to be reasonably justified by the circumstances of the case.

of 58

1.1.17 TERMINATION OF CONTRACT: Notwithstanding the provisions under other papers the Railway Administration may at any time by a notice in writing summarily terminate the contract without liability to pay any compensation to the contractor in respect thereof in any of the following event: i) INSOLVENCY : The contractor being an individual or a firm any partner in the Contractor’s firm shall at any time be adjudged insolvent or shall have a receiving order for administration of his estate made against him or shall take any proceeding for liquidation on composition under any law relating to insolvency for time being enforce or make any conveyance or assignment of his assets or enter into any arrangements or composition with his Creditors or suspend payment or is the firm be dissolved under the partnership Act. ii) LIQUIDATION : If the contractor being company shall pass a resolution or the court shall make an order for the liquidation of its affairs or a receivers or a manager on behalf of debenture holders shall be appointed or circumstances shall have arisen which entitled the court or debenture holders to appoint a receiver or manager. iii) BREACH OF CONTRACT : If the contractor commits any breach of this contract not herein specifically provided always that such termination shall not prejudice any right of action or remedy which shall have accrued or accrue thereafter to the Railway administration and provided also that the contractor shall be liable to purchase any extra expenditure which the Railway Administration is thereby put to but shall not be entitled to any gain on repurchase in the event of such termination without prejudice to the other right and remedies of the Railway administration including the rights for forfeiting the security deposit, the Railway administration shall be entitled to have the work or the undone portion thereof performed, executed and/or carried out by any other agency at the cost and risk of the contractor liable for reimbursement in the event of any loss on this account. 1.1.17.2 EXCEPTIONS : Termination of contract will not arise in case of voluntary liquidation meant for alternation or reorganization provided with the newly formed company takes over the fully responsibility and Liabilities of the liquidated firm and it is acceptable to the Railway Administration. 1.1.17.3: Termination of contract under this Para will not arise in case of breaches or defects of a minor nature . The Sr.Divl.Elect.Engineer (TRD)/ADA shall be the sole authority, to decide whether breaches and defects are of minor nature. 1.1.18 EARNEST MONEY: Along with his tender the tenderer should deposit cash with the Divisional Cashier, S. E. Railway, Adra (West Bengal). The amount as specified in tender notice or below as Earnest money. The tenderer shall be required to deposit earnest money with the tender for the due performance with the stipulation to keep the offer open till such date as specified in the tender, under the conditions of tender. This earnest money shall be applicable for all modes of tendering. The amount of earnest money to be deposited with tender shall be as indicated below:

Value of the work (Tender value ) EMD

For works estimated to cost up to Rs. 1 Crore

: 2% of the estimated cost of work

For works estimated to cost more than Rs. 1 Crore

: Rs. 2 Lakhs plus ½ % (Half percent ) of the excess of estimated cost of work beyond Rs. 1 crore subject to a maximum of Rs. 1 crore

EMD in the form of bank guarantee bonds is not acceptable. No PEMD is acceptable for the tenders. 1.1.18.1 Earnest money shall be paid in cash or in any of the following forms: i) Pay orders, Deposit receipt or demand draft in favour of FA & CAO/ S.E.Railway, Garden Reach, and Kolkata (WB). These forms of earnest money could be either of the State Bank of India or of any of the nationalized banks. No confirmatory advice from the Reserve Banks of India will be necessary. ii) The documents as referred to this tender document must be attached with the tender without which the tender will not be considered and summarily rejected.

of 58

(iii) The Earnest Money should be in cash or Banker’s Cheques /Demand Drafts in favour of FA & CAO of S.E.Railway , executed by State Bank Of India or any of the nationalized Banks or by a Scheduled Bank”.

1.1.18.2 The Government securities (Stock securities, Bearer Bonds, Promissory notes, Cash certificates etc.) shall not be accepted as Earnest money.

1.1.18.3 It is stated that the Earnest money as specified is to be submitted in full as initial security.

1.1.18.4 No interest will be allowed or paid for Earnest Money above; the amount will be refunded to the unsuccessful tenderer as soon as possible after the tender is finally decided.

1.1.18.5 It shall be understood that the tender documents have been sold/issued to the tenderer and he has agreed to the tender taking into consideration the stipulation on his part that after submitting the tender will not resile from his offer or modify his conditions thereof in a manner not acceptable to the purchaser.

1.1.18.6 Should the tenderer fail to observe or comply with this stipulation, the amount of security deposit referred to in clause 1.1.18.3 above shall be forfeited to the Government.

1.1.19 SECURITY DEPOSIT 1.1.19.1 Unless otherwise specified in the special conditions, if any, the Security Deposit/rate

of recovery/mode of recovery shall be as under :- a) Security Deposit for each work should be 5% of the contract value, b) The rate of recovery should be at the rate of 10% of the bill amount till the full

security deposit is recovered. c) Security Deposit shall be returned to the contractor after the physical

completion of the work as certified by the Competent Authority. The Competent Authority shall normally be the authority who is competent to sign the contract. If this Competent Authority is of the rank of lower than JA Grade, then a JA Grade Officer (concerned with the work) should issue the certificate. The certificate inter alia, should mention that the work has been completed in all respects and that all the contractual obligations have been fulfilled by the contractors and that there is no due from the contractor to Railways against the contract concerned. Before releasing the SD, an unconditional and unequivocal no claim certificate from the contractor concerned should be obtained.

1.1.19.2 The Earnest money of the successful Tenderer will be retained by the Railway as a part of security for due fulfillment of the contract by the Contractor.

1.1.19.3 The National plan load certificate, Government securities (Stock certificate, Bearer bonds, Promissory notes, cash certificates) will not be accepted.

1.1.19.4 No cheque will be accepted towards Security Deposit, even if it is guaranteed by the Bank.

1.1.19.5 Request for transfer of security deposit of any work even if the same is free of all obligations will not be accepted for the purpose of the security deposit of this case.

1.1.19.6 No interest will be allowed or paid for the amount deposited in cash or deducted through bills.

1.1.19.7 As far as practicable tenderer should in their own interest deposit security deposit in cash with Divl. Chief Cashier/S. E. Railway, Adra to facilitate prompt refund of the deposited amount on fulfillment of the terms of the contract.

1.1.19.8 PERFORMANCE GUARANTEE: The procedure for obtaining performance guarantee is outlined below : a) The successful bidder shall have to submit a performance guarantee (PG) with in 30(Thirty) days from the date of issue of letter of acceptance (LOA) extension of time for submission of PG beyond 30 (Thirty) days and up to 60 days from the date of issue of LOA may be given by the authority who is competent to sign the contract agreement . However a panel interest of 15% per annum shall be charged for the delay beyond 30 (Thirty) days i.e. from 31st day after the date of issue of LOA. In case the contractor fails to submit the requisite PG even after 60 days from the date of issue of LOA, the contract shall be terminated duly forfeiting EMD and other dues, if

of 58

any payable against that contract . The failed contractor shall be debarred from participating in re-tender for that work. b)The successful bidder shall submit the performance guarantee (PG) in any of the following forms amounting to 5% of the contract value : i)A deposit of cash. ii)Irrevocable Bank Guaranty. iii)Government securities including state loan bond at 5% below the market value . iv)Deposit receipts, Pay orders, Demand drafts and Guarantee bonds . These forms of Performance Guarantee could be either of the State Bank of India or of any of the Nationalized Bank. v)Guarantee bond executed or deposits receipts tendered by all scheduled Banks. vi)A deposit in the post office Saving Bank . vii)A deposit in the National Saving certificates. viii)Twelve years National Defense certificates. ix)Ten years Defense Deposits. x)National Defense Bond and xi)Unit Trust Certificates at 5% below market value or at the face value whichever is less. Also FDR in favour of FA&CAO (free from any encumbrance) may be accepted. NOTE : The instrument as listed above will also be acceptable for Guarantees in case of Mobilization Advance. c)The performance guarantee shall be submitted by the successful bidder after the Letter of Acceptance (LOA) has been issued ,but before signing of the contract agreement. This PG shall be initially valid up to the stipulated date of completion plus 60 days beyond that. In case the time for completion of work gets extended, the contractor shall get the validity of PG extended to cover such extended time for completion of work plus 60 days. (d)The value of PG to be submitted by the contractor will not change for variation up to 25% (either increase or decrease).In case during the course of execution, value of the contract increases by more than 25% of the original contract value, an additional Performance guarantee amounting to 5% (Five percent) for the excess value over the original contract value shall be deposited by the contractor. (e)The performance Guarantee (PG) shall be released after physical completion of the work based on ‘completion certificate’ issued by the competent authority stating that the contractor has completed the work in all respect satisfactorily. The security deposit shall however be released only after expiry of the maintenance period and after passing the final bill based on “NO CLAIM CERTIFICATE” from the contractor . (f) Whenever the contract rescinded the Security Deposit shall be forfeited and the performance guarantee shall be encashed. The balance work shall be failed contractor shall be debarred from participating in the tender for executing the balance work. If the failed contractor is a JV or partnership firm then every member / partner of such a firm debarred from participating in the tender for the balance work in his/her individual capacity or as a partner of any other JV/partnership firm. (g) The engineer shall not make a claim under the Performance Guarantee expect for amounts to which the President of India is entitled under the contract (not withstanding and/or without prejudice to any other provisions in the contract agreement) in the event of: (i)Failure by the contractor to extend the validity of the performance guarantee as described here in above in which event the engineer may claim the full amount of the Performance Guarantee. (ii)Failure by the contractor to pay President of India any amount due, either as agreed by the contractor or determined under any of the Clauses/Conditions of the agreement, within 30 days of the service of notice to this effect by engineer. (iii)The contract being determined under provision of the GCC, the Performance guarantee shall be forfeited in full and shall be absolutely at disposal of India.

1.1.20 ADDITIONS AND ALTERATIONS: Railway Administration may require modifications to be carried out on the works Considered necessary either during the execution or after a part of whole of the installations coming within

of 58

the purview of the contract such modifications shall be carried out, only after the additional prices , if any proposal by the contractor are accepted by the Railway Administration. 1.1.20.1 If any additional quantum of the works specified in the schedule becomes necessary during the course of execution , the contractor may be called upon to carry out such , additional works to the extent of 25% of the original contract quantity at the same rates, terms and conditions without inviting any fresh quotations . 1.1.21 SAFETY MEASURES: The contractor shall take all precautionary measures in order to ensure the Protection of his own personal moving about or working in the Railway premises, but shall then conform to the rules and regulations of the Railways . The contractor shall abide by all Railway regulations in force for the time being and ensure that the same are followed by his Representatives , agent or sub-contractor of workmen . He shall give due notice to his employees and workers about the provisions of the Para. The contractor shall indemnify and keep the Railway Administration indemnified and harmless against all actions, suits , claims, demands, other charges or expenses arising in connection with any accidents , death or injury sustained by any person(s) within the Railway premises and any loss or damage to Railway property sustained , due to the acts or omissions of the contractor, or his staff during the execution of this contract irrespective of whether such liability arising under the workmen’s compensation Act 1923 or fatal accidents Act or any other stature in force for the time being . 1.1.22 EXECUTION OF AGREEMENT The contractor is required to execute a formal agreement in prescribed form (Form 7) with the Railway Administration on the lines of the Tender conditions and until the formal agreement is executed , the LOA by the Railway Administration shall be valid and binding on the contractor in all respects . 1.1.23 RAILWAY PASSES: No free Railway passes will be issued for the contractor. 1.1.24 SPECIFIED RAILWAY STORES: Materials which are to be supplied by the Railways as specified in Annexure for Execution of the work will be handed over to the contractor by the consignee from his store against Indemnity Bond (Form 6) . The loading, handling and transportation of such materials to the work sites shall have to be done by the contractor at his own cost. All other materials as may be required to execute the work and to make the installation, complete in all respects according to the specification and schedule of work shall be supplied by the contractor and cost thereof included in the schedule of prices . The transportation of the materials to the work site shall be borne by the contractor. 1.1.25 REFUND /FORFIETURE OF EARNEST MONEY: The Earnest money including the amount taken as security deposit for the due performance of the stipulation to keep the offer open till the date specified in the tender under clause 1.1.15(i.e Minimum validity of offer ) hereof shall be refunded to the unsuccessful tenderer(s) within a reasonable time after finalization of the tender case . The earnest money deposited by the successful tenderer(s) shall be retained towards the security deposit for the due and faithful fulfillment of the contract but shall be forfeited by the purchaser without prejudice to any other rights or remedies available to it if the contractor fails to execute the Agreement bond or start the work within a reasonable time (to be determined by the Engineer at site) after notification of the acceptance of his/their tender. 1.1.26 COMMUNICATION TO BE IN WRITING : All notices communications, reference and complaints made by the purchaser of his Engineer or the Engineer’s representative or the contractor in tense concerning the works shall be in writing and no notice communications reference or complaint not in writing shall be recognized. The list of addresses to which correspondence and documents relating to the contract should be sent are indicated in the tender papers in Part-II. 1.1.27 SERVICE OF NOTICES ON CONTRACTORS: The contractor shall furnish to the Engineer the name, designation and address of his authorized agent and all complaints , notices, communications and references shall be deemed to have been so duly given to the contractor if delivered to the contractor left at or posted to the address so given and shall be deemed to have been so given in the case of posting on the day on which would have reached such address in the ordinary course of post or on the day on which they were so delivered or left in the case of contract by partners, any change in the constitute of the firm shall be forthwith notified by the contractor to the Engineer. Important documents may be sent by “REGISTERED POST”. 1.1.28 SUBLETTING OF CONTRACT :

of 58

The contractor shall not assign or sublet the contractors any part thereof or allow any person to become interested therein any manner whatsoever without the special permission of the purchaser. Any breach of this condition shall entitle the purchaser to rescind the contract under clause 1.1.45 (i.e Right to Railway to determine contract ) of these conditions and also render the contractor liable for payment to the purchaser in respect of any loss or damage arising or ensuring from such cancellation. 1.1.29 APPROVAL OF SUBCONTRACTOR OR VENDORS: The name of all sub contractors proposed to be employed on execution of work or any part thereof including manufacture of components shall be submitted by the Contractor to the purchaser and got approved by him before the contractor enters into an agreement with sub-contractor/or vendor for the purpose . The permitted subletting of work by the contractor shall not establish any contractual relationship between the sub-contractor and the purchaser and shall not relieve the contractor of any responsibility under the contract. 1.1.30 RETURN OF UNUTILISED MATERIALS OF THE PURCHASER: Such materials as have been issued to the contractor but left behind with him UNUTILISED, shall be determined after reconciliation with the actual quantum of issued vis-à-vis utilized for execution of the work and returned by the contractor to the purchaser’s depot at no extra cost in the same shape and condition of the materials as were issued to the contractor(s). If the contractor fails to return such materials, the cost of such will be recovered at a rate at twice the book rate or twice the market rate enhanced by 20.38% whichever is higher. Every effort will be made by the purchaser to supply the materials as listed in part-II at the appropriate time. However suitable extension of time will be granted to the contractor in case of delay for supply of said materials by the purchaser any reason whatsoever and no claim of compensation from the contractor for such delay by the purchaser will be entertained. NOTE: The contractor shall hand over all empty drums, wooden carats and other packing materials used for the issue of purchaser’s materials to the purchaser’s depot. CARRIAGE OF MATERIALS : No forwarding orders shall be issued by the purchaser for the transportation of Contractor’s materials, tools and plant by rail or by road to the work site which may be required for use in the works and the contractor shall pay full freight charges at public tariff /rates there for. No Road permit for contractor’s supply material will be issued by Railways. 1.1.31 PROVISION OF EFFICIENT AND COMPETENT SUPERVISOR : The erection of all equipments according to the specification will be done by the contractor at his cost. For this purpose, the contractor shall place and keep on the works at all times efficient and competent representatives to give necessary directions to his workmen and see that they execute their work in sound and proper manner and shall employ only such supervisors, workmen and labour in or about the execution of any of the works as are careful and skilled in their various trades and callings. The said representative shall be present at site during work in hours and any written orders or instructions which the engineer may give to the said representatives of the contractor shall be deemed to have been duly given or communicated to the contractor. The contractor shall furnish the name and address of his agent or representatives for the purpose of this clause. The contractor or his agent or representative will accompany the engineer/s on inspection and/or proceed to their offices whenever called upon to do so. The Contractor shall at once remove from the works any representative, permitted sub-contractor supervisor, workmen or labour who shall be objected to by the engineer and he shall submit a correct return showing the names of all staff and workmen employed by him . In the event of the engineer being of the opinion that the contractor is not employing on the works a sufficient number of staff and worker as is necessary for the proper completion of the work within the time prescribed , the contractor shall forthwith on receiving intimation to this effect take on the additional number of staff and labour specified by the engineer within seven days of being so required . Failure on the part of the contractor to comply with the above instructions will entitle the purchaser to rescind the contract under clause 1.1.45 i.e. Right of Railway to determine contractor of the conditions thereof . 1.1.32 ACCIDENTS AND DAMAGES TO INSTALLATIONS ETC The contractor shall be responsible for all repairs and rectification of damage to installations erected or under erection due to accident or any other cause during the course of the contractors work at site inclusive of the guarantee period at no extra cost to the purchaser. All costs, damages or expense which the purchaser may incur, for which under the terms of contract, the contractor is liable may be either deducted by the purchaser at his discretion from any money due or to become due to refundable by the purchaser to the contractor

of 58

under the contract , or may be recovered by action of law or otherwise from the contractor . The purchaser reserve the right and shall be entitled to retain payments due to the contractor under this contract and to set off the same against all claims whether arising out of this contractor out of any other transaction whatever with the contractor. 1.1.33 PROVISION OF PAYMENT OF WAGES ACT : The contractor shall comply with the provision of payment of wages Act 1936 as amended up to date and the rules made thereunder in respect of all employees employed by him in the works, if in compliance with the terms of the contract , the contractor directly or through the petty contractors or subcontractors shall supply any labour to be used wholly or partly under the direct orders and control of the engineer whether in connection with the work to be executed here under or otherwise for the purpose of the engineer such labour shall never the less be deemed to be , comprise of person employed by the contractor and any money which may ordered to be paid by the engineer on behalf of the contractor and engineer may on failure by the contractor to repay such moneys due to the contractor in terms of the contractor. The purchaser shall be entitled to deduct from any moneys due to the contractor (whether under the contract or any other of compensation of aforesaid or for costs of expense in connection with any claim there) and the decision of the engineer upon any question arising out of the effect or force of this clause shall be final and binding upon the contractor. 1.1.34 WAGES TO LABOUR The contractor shall be responsible to ensure compliance with the provisions of the Minimum Wages Act, 1948 as modified up to date (therein after referred to as the said act), and the rules made there under in respect of any employees employed by him directly or through petty contractors , sub-contractors for the purpose of carrying out this contract. If, in compliance with the terms of the contract , the contractor directly or through petty contractors or sub-contractor supplies any labour to be used , wholly or partly under the direct orders and control of the purchaser whether in connection with any work being executed by the contractor or otherwise for the purpose of the purchaser such labour shall for the purpose of this clause shall be deemed to be persons employed by the contractor. If any money , shall be a result of any claim or application and under the said act be directly to be paid by the purchaser such money shall be deemed to be payable to the purchaser by the contractor and on failure by the contract or to repay the purchaser and moneys paid by it as aforesaid within seven days after the same shall have been demand the purchaser shall be entitled to recover the same from any moneys due or accruing to the contractor under this or any other contract with the purchaser. 1.1.35 POWER OF MODIFICATION TO CONTRACT : The engineer in charge of the execution of the work on behalf of the purchaser shall be entitled by order in writing to enlarge or extend, diminish or reduce the works or make any alternations in their design , character , position site quantities , dimensions or in the method of their execution or in the combination and use of materials for the execution or thereof or to order any additional works to be done or any works not to be done and the contractor will not be entitled to any compensation for any increase/reduction in the quantities of work but will be paid only for the actual amount of work done and for approved materials supplied against a specific order . 1.1.35.1 Unless otherwise specified in the special conditions of the contract, the accepted variation in quantities for the contract overall would be up to 25 % of the quantity originally contracted . The contractor shall be bound to carry out the work at the agreed rates and shall not be entitled to any claim or any compensation whatsoever up to the limit of 25% variation on the contract value originally contracted. 1.1.35.2 The enlargement , extensions, diminution, reductions, alternations or additions referred to in clause in no degree affect the validity of the contract but shall be performed by the contractor as provided therein and be subject to the same conditions, stipulations and obligations as if they had been originally and therein and be subject to the same conditions stipulations and obligations as if they had been originally and expressly included and provided for in the specifications and drawings and the amount to be paid therefore shall be calculated in accordance with the accepted schedule of rates, any extra items/ quantities of work failing outside the purview of the provisions of the sub-clause 1.1.36 above shall be paid for at the rates determined (i.e. rates for the extra items of work of these conditions) 1.1.36 COMPLIANCE TO ENGINEER’S INSTRUCTIONS : The Engineer shall direct the order in which the several parts of the works shall be executed and contractor shall execute without delay all orders given by the engineer from time to time but the contractor shall not be relieved thereby from responsibility for the due performance of the works in all respects.

of 58

Alternations to be authorized: No alternations in or additions to or commission or abandonment of any part of the works shall be deemed authorized except under instructions from the engineer and the contractor shall be responsible to obtain such instruction in each and every case. EXTRA WORK: Should works over and above those included in the contract required to be executed at the site the contractor shall have no right to entrust with the execution of such works which may be carried out by another contractor or contractors or by other means at the options of the purchaser. Separate contract in connection with works: The purchaser shall have the right to let other contractors in connection with the works the contractor shall afford other contractor reasonable opportunity for the storage of their materials and the execution of their works and shall properly connect and co-ordinate his works there. If any part of the contractor work depends for proper execution or result upon the work of another contractor, the contractor shall inspect and accordingly report to the engineer any defects in such work that render it unsuitably for such proper execution and result . The contractor’s failure so to inspect and report shall constitute acceptance of the other contractor’s work except as to defects which may have developed in the other contractor’s work after the execution of his work. 1.1.37 ILLEGAL GRATIFICATION : Any bribe, commission, gifts or advantages given, promised or offered by or on behalf of the contractor or his partner, agent or servant or any one of his or on their, behalf in relation to the obtaining or the execution of this or any other contract with purchaser shall in addition to any original liability which he may incur , subject to the contractor to the recession, of the contract and all other contracts with the purchaser and to the payment of any loss or damage resulting from such rescission and the purchaser or damage resulting from such rescission and the purchaser shall be entitled to deduct the amount so payable from any money due to the contract under the contract or any other contracts with the purchaser. The contractor shall not lend or borrow from or have or enter into any monetary dealings or transactions either directly or indirectly with any employee of the purchaser and if he shall do so the purchaser shall be entitled forthwith to rescind the contracts and all other contracts with the purchaser. Any question or dispute as to the commission of any offence or compensation payable to the purchaser under this clause shall be settled by the General Manager in such manner as he shall consider fit and sufficient and his decisi on shall be final and conclusive. 1.1.38 ADHERENCE TO SPECIFICATION AND DRAWINGS: The whole of the works shall be executed in perfect conformity with specifications and drawings of the contract. If the contractor performs any work in manner contrary to the specifications or drawings or any of them and without such reference to the engineer, shall have to bear all the costs arising of ensuring and shall be responsible for the losses to the purchaser. 1.1.39 WORKS BY OTHER AGENCIES: Any other works undertaken at the same time by the purchaser direct or through some other agency at the same site where the contractor is carrying out his work, will not entitle the contractor to prefer any claim regarding any delays or hindrances he may have to face on this account . The contractor shall comply with any instruction which may be given to his by the purchaser in order to permit simultaneous execution of his own works and of those undertaken by other contractors or the purchaser without being entitled on this account to any extra charge. 1.1.40 If the purchaser is unable to supply materials to the contractor as specified in the contract in time, the contractor shall not be entitled to any extra payment on account of such delay in supply, however such delays in supplies will be reasonable ground for extension of completion dates for the works. 1.1.41 All materials will be subjected to inspection and test either by the purchaser or by an agency appointed for this purpose for individual items as below, at the manufacturer’s work before dispatch and no materials shall be dispatched from the manufacturer’s works until these are inspected and or approved . These materials may also again be inspected at the contractor’s depot/work site . The purchaser or his representative shall have the right to be present during all stages of manufacture and shall be afforded free of charge all reasonable facilities for inspection and testing so as to satisfy himself/themselves that the materials are in accordance with specifications, approved drawings and designs. Any

of 58

reasonable delay in inspection will be a reasonable ground for extension of time for completion of works. 1.1.42 PROVISIONAL ACCEPTANCE : Immediately after the completion of an installation the contractor will certify and advice the purchaser in writing that the installation is :

i) Complete . ii) Ready for satisfactory regular service and iii) Ready to be handed over. He will also place at disposal of the purchaser the

required staff for inspection, testing and putting it into operation. The test or test specified in part III will be conducted jointly by the purchaser and contractor as soon as possible after receipt of advise of completion of an installation by the purchaser from the contractor.After the purchaser is satisfied with the satisfactory working of the installation, he will issue a “Provision Acceptance Certificate” which would be signed by both the parties. Should the results of inspection and tests be not satisfactory an extension of time for one month will be granted to make good defects and deficiencies pointed out by the purchaser. A fresh inspection and tests will then be carried out after the contractor has attended to the defects and deficiencies . If these are not satisfactory , the purchaser may proceed at the contractor’s expense by all means deemed expedient to have the installation made approved drawings and designs. In such a case or in case of delay in completing the work under this contracts within the time limit the purchaser reserves the right if he deems it possible to use in a reasonable manner any part of the installation even if the work is not completely erected. The purchaser will give to the contractor for this purpose seven days previous notices. The contractor shall then take at his own expenses all necessary steps to complete the works in accordance with the provisions of the contract. In case it becomes impossible to proceed with the above mentioned taking over tests, for reasons other than for which the contractor is responsible, the provisional acceptance certificate shall be issued at or within a mutually agreed reasonable period not exceeding six months after completion of an installation. NOTE: The issue of provisional acceptance certificate will not be withheld for rectification of minor defects as distinct from rejected equipment, which may not be essential for energisation and operation of the installation in such cases, only the value of materials and cost of rectification of the minor defects shall be withheld from payments on provisional acceptance until rectification is completed. 1.1.43 WARRANTY: The contractor shall warranty satisfactory working of the installation erected by him , for a period of twelve months from the date of provisional acceptance of each installation(Para 1.1.42 i.e. provisional acceptance by the purchaser ). During this period the contractor shall make available an experienced Engineer and necessary equipment to attend to any defective installation and be responsible for satisfying himself that the purchaser’s staff follow the prescribed procedure for operation and maintenance of equipment . The contractors shall bear the cost of all modifications, additions or substitutions that may be considered necessary due to faulty materials , designs or workmanship for the satisfactory working of the equipment. The final decision shall rest with the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra. During the period of guarantee the contractor shall be liable for the replacement of any parts which may be found defective in the equipment whether such equipments be of his own manufacturer or those of his sub-contractors whether arising from faulty design, materials, workmanship or negligence in any manner on the part of the contractor provided always that such defective parts as are not repairable at site are promptly returned to the contractor if so required by him at site(contractor’s own expenses). The contractor shall bear the cost of repairs carried out on his behalf by the purchaser at site. In such a case the contractor shall be informed in advance of the works proposed to be carried out by purchaser. If it becomes necessary for the contractor to replace or renew any defective portion of the equipment under the clause aforesaid then the provision of the said clause shall also apply to the portions of the equipments so replaced or renewed until the expiration of six months from the date of such replacement or until the end of the above mentioned period of twelve months, whichever is later, such extension shall not apply in case of defects of a minor nature, the decision of the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra being final in the matter, if any defects be not remedied within a reasonable time during the aforesaid period the purchaser may proceed to do the work at the contractor’s risk and expense, but

of 58

without prejudice to any other rights and remedies which the purchaser may have against the contractor in respect of such defects or faults. The repaired or renewed parts shall be delivered and erected at site free of charges to the purchaser. Any materials supplied shall also be covered by the provisions of this clause. The liability of the contractor under the guarantee will be limited to re-supply of materials made under clause 1.1.36 such supply shall be effected at the contractor’s depot or in the event of closure of the depot at the stores depot of the engineer at site covered by the contract. In case of materials supplied by the purchaser under clause 1.1.36 no liability will rest on the contractor for failure on account of defects inherent in such materials . 1.1.44 FINAL ACCEPTANCE: The final acceptance of the installation shall take effect from the date of expiration of the period of guarantee as defined in clause 1.1.43 warranty provided the installation previously accepted provisionally are still in good working order . If on the other hand the installation is not in good working order at the end of the guarantee period the purchaser may either extend the period of guarantee until, necessary works are carried out by the contractor or carry out those works or have them carried out successfully on behalf of the contractor and at his expenses . A certificate of final acceptance shall then be issued under the signature of both the parties – The purchaser and the contractor . 1.1.45 RIGHT TO RAILWAY TO DETERMINE CONTRACT: 1.1.45.1 The purchaser shall be entitled to determine and terminate the contractor at any time should in the purchaser’s opinion , the cessation of work become necessary owing to paucity of funds or from any other cause whatsoever in which case the value of approved materials at site and of work done by the contractor will be paid for in full at the rates specified in the contract . Notice in writing from the purchaser of such determination and the reason therefore shall be conclusive evidence thereof. Should the contract be determined under sub-clause 1.1.45.1 of this clause and the contractor claims payment for expenditure incurred by him in the expectation of completing the whole of the works the purchaser shall admit and consider such claims as he deemed reasonable and are supported by vouchers to the satisfaction of the engineer. The contractor shall have no claim to any payment of compensation or otherwise whatsoever on account of any profit of advantage which he might have derived from the execution of the works in full but which he might have derived from the execution of the works in full but which he did not derive in consequence of determination of contract . The purchaser’s decision on the necessity and propriety or such expenditure shall be final and conclusive . 1.Determination of contract owing to default of contractor if the contractor should i) become bankrupt or insolvent or ii) make an arrangement with or assignment in favour of his creditors , or agree to carryout the contract under the committee or

iii) being a company or corporation go into liquidation (other than a voluntary liquidation for the purpose of amalgamation or reconstruction) or iv) have an execution levied on his goods or property on the works , or v) assign the contract or any part thereof otherwise than as provided as terms or these

conditions, or vi) abandon the contract or vii) persistently disregard the instruction of the engineer or contravene any provision

of the contract viii) fail to adhere to the agreed programme of work by a margin of 10% of the stipulated

period or ix) fail to remove materials from the site or to pull down and replace work after receiving

from the engineer notice to the effect that the said materials or works have been condemned or rejected under clause or

x) fail to take steps to employ competent or additional staff and labour as required for supervision of these conditions or

xi) fail to afford the engineer or engineer’s representative proper facilities for inspection the works or any part thereof as required under clause 1.1.41(i.e. inspection and testing ) of these condition, or

xii) promise offer or give any bribe , commission , gift or advantage either himself or through his partner agent himself or through his partner agent or servant to any officer or employee of the purchaser or to any person or his or on their behalf in relation to the executive of this or any other contract with the purchaser or

of 58

xiii) At any time after the tender relating to the contract has been signed and submitted by the contractor being a partnership firm, admit as one of its partners or employee under it or being an incorporated company elect or nominate or allow to set as one of its director or employees under it in any capacity whatsoever retired Engineer of the gazetted rank or any other retired gazetted officer working before his retirement whether in the executive or administrative capacity or whether holding any personable post or not , in the engineering department of the any of the railway for the time being owned and administered by the President of India before two year from the date of retirement from the said service of such engineer or officer unless such engineer or officers has obtained permission from the President of India or any officer duly authorized by him in his behalf to become a partner or a director or take employment under the contractor , as the case may be OR

xiv) Fail to give at the time of submitting the said tender . a) the correct information as to the date of retirement of such retired engineer or retired officer from the said service as to whether any such retired engineer or retired officer under the employment of the contractor at the time or submitting the said tender .

b) being a partnership firm , the correct information as to whether any or its partners was such a retired engineer or retired officer or

c) the correct information as to such engineer or officer obtaining permission to take employment under the contractor .

d) being an incorporated company , a correct information as to whether any of its directors was such a retired engineer or a retired officer or

e) being such a retired engineer or retired officer suppress and not disclose at the time of submitted the said tender the fact of his being such a retired engineer or a retired officer or make at the time of submitting the said tender a wrong statement in relation to his obtaining permission to take the contract.

If the contractor be a partnership firm or an incorporated company to be a partner or director of such firm or company as the case may be or so seek employment under the contractor. Then and in any of the said cases, the engineer on behalf of the purchase may serve the contractor with a notice in writing to that effect and if the contractor does not within 7 days after the delivery to him of such notice proceed to make good his default in so far as the same is capable of being made good and carry on the work or comply with such direction as aforesaid to the entire satisfaction of the engineer , the purchaser shall be entitled after giving 48 hrs notice in writing under the hand of the engineer to rescind the contract as a whole or in part or parts (as may be specified in such notice).

2. Right of Railways after rescission of contract owing to default of contractor In the event of any or several of the course referred to clause 1.1.45.3 of these conditions adopted. i) The contractor shall have no claims to compensation for any loss sustained by him by reason of his having purchased or procured any materials or entered into any commitments or made advance account of or with a view to the execution of the work , or the performance of the contract and contractor shall not be entitled to recover or be paid any sum for any work thereof for actually performed under the contract unless and until the engineer shall have certified the performance of such work and the value payable in respect thereof and the contractor shall only be entitled to be paid the value so certified .

ii) The engineer or the engineer’s representative shall be entitled to take possession if any materials , tools, implements machinery and building on the works or on the property on which these are being or ought to have been executed and to retain and employ the same in the further execution of the works without the contractor being entitled to any compensation for the use and employment thereof for wear and tear or destruction thereof.

iii) The engineer shall as soon as may be practicable after removal of the contractor fix and determine expert or by or after reference to the parties or other such investigation or inquiries as he may consider fit to make or institute and shall certify what amount (if any ) and at the time of rescission of the contract been reasonably earned by or would reasonably accrue to the contractor in respect of the work then actually done by him under the contract and what was value of any unused , or partially used materials, any constructional plant and any temporary works upon the site. The legitimate amount due to the contractor after making necessary deductions and certified by the Engineer should be released expeditiously.

1.1.46 SUPPLY OF SPARE PARTS :

of 58

The supply of spare parts, components, standby equipments shall be so regulated that all the necessary items that have been ordered shall be delivered at site only after the erection of the main equipments but before the testing and commissioning of system. If the spare parts standby equipments are to be supplied in advance, necessary written and specific permission shall be taken from the engineer 1.1.47 ARBITRATION: 1.1.47.1 In the event of any dispute of difference between the parties hereto as to the construction or operation of this contract or the respective rights and liabilities of the parties on any matter in question dispute or difference on any account or as to the withholding by the railways of any certificate to which the contractor may claim to be entitled to or if the railways fails to make a decision within a reasonable time the n and in any case save the expected matters referred to in clause 63 of the General Conditions of the contract and standard specification 1976 of S.E.Railway the contractor after 90 days but within 180 days of his presenting his final claim on disputed matters shall demand in writing that the dispute or difference is to be referred to arbitration .

1.1.47.2 The demand for arbitration shall specify the matters which are in question, dispute/difference only such disputes and differences in respect of which the demand has been made shall be referred to arbitration and other matters shall not be included in the reference. 1.1.47.3 If the contractor(s) does/do not prefer his/their specific and final claims in writing within a period of 90 days of receiving the intimation from the government that the final bill is ready for payment he/they will be deemed to have waived his/their claim(s) and the railway shall be discharged and released of all liabilities under the contract in respect of these claims. 1.1.47.4 All questions, disputes and/or difference arising under or in connection with this contract or in any way attaching or relating to or concerning the erection, meaning or effect of these conditions or the special conditions of contract (except as to any matter the opinion and/or decision regarding which has been otherwise provided for these conditions or the special conditions of the contract to be final and also except as to any matter regarding which the contractor has given no claim certificate or such Railway officer (Retired or in service) as shall be appointed to be the arbitrator by the General Manager for the time being of the South Eastern Railway in his sole and absolute discretion and the decision of such arbitrator shall be final and conclusive under provision of the Indian Arbitration Act 1948 and of the rules thereunder and all statutory modification thereof. 1.1.47.5 If the sole arbitrator appointed under sub-clause(iv) or one both the Arbitrators/appointed under sub-clause (v) above resigns his appointment or resign their appointments or vacates his office/vacate their office or is /are unable or unwilling to act for any reason whatsoever or arbitrator/arbitrators to act in his/their place /places in accordance with the provisions of sub-clause (iv) or sub-clause (v) above as the case may be shall be entitled to proceed with the reference from the stage at which it was left by the previous arbitrator/arbitrators. The arbitrator / arbitrators umpire so appointed as the case may be shall give the award on all matters referred to arbitration indicating therein break up of the sum awarded separately on each individual item of disputes.

1.1.48 ACCOMMODATION : The contractor shall make his arrangements for the accommodation of his staff, materials, tools etc, electricity for the purpose of execution of the work against this contract may be arranged by railway from its sources , if available near the work site on payment of railway’s specified charges. 1.1.49 LAWS OF INDIA : This contract shall be governed by the laws for the time being in force in the Republic of India. 1.1.50 DEFAULT AND DELAY : The contractor shall execute the work with due diligence and expedition keeping to the approved time schedule . Should he refuse or neglect to comply with any reasonable orders given to him in writing by the purchaser’s engineers in connection with the work or contrivance the provision of the contract or the progress of work lags persistently behind the time schedule due to his neglect , the purchaser shall be at liberty to be given seven days notice in writing to the contractor requiring him to make good the neglect or contravention, complained of or should the contract fail to comply with the requisition made in the notice within seven days from the receipt thereof, it shall be lawful for the purchase to take the work wholly or in part out of the contractor’s hands without any further reference and get the work or any part thereof as the case may, completed by other agencies at the expense of the contractor without prejudice to any other right or remedy of the purchaser .

of 58

1.1.51 LOSS SUSTAINED DUE TO DEFAULT AND DELAY: a)In the event of any loss to the purchaser on account of execution and/or completion of the work or any part thereof by agencies other than the contractor, in terms of Para 1.1.50, the contractor shall be liable to reimburse the loss to the purchaser without prejudice to the other rights and remedies of the purchaser, and the reimbursement in full or in part as the case may be, shall be met, at the option of the purchaser, from out of all or any of the following sources viz. i) Any amount due and payable to the contractor by the purchaser on any account whatsoever. ii)The contractor’s security deposit in the hands of the purchaser as far as Available and

iii) Any other assets whatsoever of the contractor. b) In the event of reimbursement from out of sources (i) and or (ii) above mentioned, the purchaser shall have the right of appropriation sue motto.

1.1.52 CORRECTNESS OF WORK AND MATERIALS: a) All designs and drawings submitted by the contractor shall be based on a thorough study and shall be such that the contractor is satisfied about their suitability . The purchaser’s approval will be based on these considerations . Notwithstanding approval communicated by the purchaser, during the progress of the contract , for designs and drawings prototype samples of components , materials and equipments after inspection and adjustments to installations. The ultimate responsibility for correct design and execution of work shall rest with the contractor unless the purchaser insists on adoption of his own designs in spite of the contractor not being agreeable to its . b) If any dimension figured upon a drawing differs from that obtained by sealing

the drawings the figures dimension should be normally taken as correct unless it is prima facie a mistake but all such cases shall be brought to the notice of the purchaser’s engineers and the discrepancy set right before execution .

1.1.53 CONTRACTOR’S RESPONSIBILITY FOR DISCREPANCY : a) All designs and drawings submitted by the contractor shall be based on a Thorough study

and shall be such that the contractor is satisfied about their suitability . The purchaser‘s approval will be based on these considerations. Not withstanding approval communicated by the purchaser , during the progress of the contract , for designs and drawings, prototype samples of components , materials and equipments after inspection and adjustments to installations, the ultimate responsibility for correct design and execution of work shall rest with the contractor unless the purchaser insists on adoption of his own designs in spite of the contractor not being agreeable to its.

b) The contractor shall be responsible for and shall bear and pay the costs for any alternation of works arising from any discrepancies , errors or omissions in the designs and drawings have been approved by the purchaser or not .

1.1.54 ADDITIONS AND ALTERATIONS TO ERECTED EQUIPMENTS: The purchaser may require additional installations or modifications to be carried Out on the works he deems necessary, either during the execution or after a part or whole of the installations coming within the purview of the contract has been put into commercial service. In case the prices for such additional works or modifications are not covered by the Schedule of prices and are such that either partly consider additional prices for such Works justified , such additional works or modification shall be carried out, only after the additional prices proposed by the contractor are accepted by the purchaser In case additional installations or modifications are required to be carried out under this para, the purchaser shall grant a reasonable extension of time, should this be considered necessary. 1.1.55 CONTRACT LABOUR ACT: The contractor is liable to observe the provisions of contract labour Act and get himself registered under the concerned labour officer as per provision of the Act. He has to state the number of labour engaged by him for carrying out the work before signing of agreement . For any violation of the said Act , the contractor is liable for prosecution by the Labour Enforcement Officer (Central) under whose jurisdiction the Work is being executed and the amount of penalty if any , will be deducted from contractor’s final bill on advise of the labour court. 1.1.56 ISSUE OF TOOLS AND PLANTS TO THE CONTRACTOR: For the purpose of carrying out the work , Railway will not issue any tools and plants. However, if the executive officer in charge of the work is of the opinion that in the interest of faster progress of the work, any tools and plants items are to be provided to the contractor, the same may be provided to the contractor on fulfilling of an indemnity bond and the book value

of 58

of the materials will kept deducted from running bills of the contractor till return of the tools and plants. The determination of book value of the T&P items is as per the Railways book or the cost of procurement of the item with normal escalation @ 10% per year added to it, whichever is higher. 1.1.57 TRANSPORTATION: All materials connected with this work whether to be supplied by the railways or the contractors have to be transported from the railway stores depot to the site by the contractors only. The contractor has also to arrange for transportation of Railway staff and supervisors connected with the work to the site of work from the Railway station during execution of the work.

1.1.58 Employment of diploma holder/Engineer Graduate : The contractor shall be required to employ un-employed Electrical Engineering graduate/Diploma holder or Engineering graduate/Diploma holder in any stream as per instruction of Sr. DEE/TRD/ADRA on monthly salary during execution or works as indicated below.

Contract Value No. of Engg. Diploma holder/Graduate holder

Duration

a. Above Rs. 5 Lakhs & upto Rs. 15 Lakhs

One qualified diploma holder. During the period of currency of contract.

b. Rs. 15 lakhs and above. One qualified Electrical Engineer Graduate.

During the period of currency of contract.

In case, the contractor fails to employ the technical staff as aforesaid, he shall be liable to pay a reasonable amount not exceeding a sum of Rs. 20,000/- for diploma holder and not exceeding a sum of Rs. 40,000/- for Electrical Engineer or Graduate Engineering graduate/Diploma holder in any stream for the month or a part of default. The decision of the Engineer-in-Charge as to the period for which the required technical staff was not employed by the contractor as to the reasonableness of amount to be deducted on this account shall be final and binding on the contractor. The deputed staff of the contractor has to keep good liaison with the Railway for execution of work . 1.1.59 Conservancy cess charges shall be deducted from on account bills in accordance with

Rly Board letter No. F(X)I-95/1/1 dt.16.07.2012 which is as follows.

Description of category Average no. of Labourer or Workman Employed per day.

Proposed conservancy Cess Charges to be recovered PER MONTH

1. Railway Contractors: a.Engg. Works Contractors (Engg, Elect. Mech. Signal etc.)

1 to 5 5 to 10 11 to 25

Rs. 106/- Rs. 208/- Rs. 523/-

b. Genl. Goods handling Contractors including contractors awarded by stores department

26 to 50 51 to100 101 to 200

Rs. 762/- Rs.1,023/- Rs.1,285/-

c. Coal handling ash pit cleaning contractors

201 to 300

Rs. 1,546/-

d. Railway siding used by the Contractor

301 to 750 751 to 1500

Rs. 1,785/- Rs. 3,590/-

e. Contractor supplying water to Engines

1501 to 3000 3000 & over

Rs.7,182/- Rs. 14,345/-

1.1.60 Imposition of token penalty for delay in the completion work. The existing clause 17(B) of GCC provides for recovery of liquidated damages from the contractor for delay in completion of work. It has now been decided that the Competent authority while granting extension to the currency of contract under clause 17(B) of GCC may also consider levy of token penalty as deemed fit based on the merit of the case.

--------------------- x-------------------------

of 58

CHAPTER-2

1.2 CONDITIONS OF PRICES AND PAYMENT TERMS: 1.2.1 SCOPE This chapter deals with prices to be paid for supply and erection including testing , commissioning of various plants/equipments for items of works or for supplies and other amounts payable in accordance with accepted schedules of prices and rates and terms and conditions of payment mentioned herein. 1.2.1.1 This is a composite works contract. The total prices for the completed items of work are the actual prices to the contractor as per the terms and conditions of the contract. 1.2.2. UNIT PRICES: 1.2.2.1 The rate quoted by the tenderer and accepted by the purchaser shall hold good till the completion of the work and no additional individual claim will be admissible on account of fluctuation in market rates etc. or due changes in tax structures 1.2.2.2. The rate quoted by the tenderer shall include the cost of materials, all taxes and ED Erection, testing and commissioning including all incidental charges like freight, Transport, loading /unloading, handling of materials, lifting , descent, insurance Coverage or bankers charges, indemnity bond etc. 1.2.2.3 The rate quoted by the tenderer shall include the cost of materials including all incidental charges mentioned in 1.2.2.2. Above in case specifically directed by Railway for supply only. 1.2.2.4 The rate quoted by the tenderer shall include the cost of erection ,testing and commissioning including all incidental charges in case of the materials supplied by the purchaser as indicated in the schedule. 1.2.3 EXPLANATORY NOTES : Explanatory notes for various items of works included in the schedule are given in Part II of the tender paper. Tenderer should carefully read and include all the Cost of materials and erection testing and commissioning as clearly explained in the explanatory notes . 1.2.4 TERMS OF PAYMENT: (i) Subject to any deduction or recoveries which the purchaser may be entitled to make under the contract, the contractor shall unless otherwise agreed to be entitled to get the payments subject to conditions stipulated in the subsequent clauses. (ii) Payment will be arranged by Sr. Divisional Finance Manager, S.E.Railway, Adra for the bills submitted to Sr. Divisional Electrical Engineer (TRD)/Adra, through Depot-in-charge, subject to following :- i) Execution of indemnity bond on stamp duty in case of any materials taken by contractor from Railways. The bills for payment should accompany a copy of penalty imposed during the execution of the work for which payment is claimed and clearing certificate from the Depot-in-charges, indicating the successful job completed by tenderer. 1.2.5 ON ACCOUNT PAYMENT On account payment to the extent of 90% will be made on the total unit price of such items included in the schedule of prices only for those items included in the schedule of prices and executed in terms of this contract for which Sr. Divisional Electrical Engineer (TRD), S. E. Railway, Adra considers appropriate and acceptable to make the on account payment. All invoices shall be accompanied by the : i) Contractor’s challan along with manufacturer’s challan for supply of items only. ii) Inspection certificate granted by the Inspecting authority as authorized by Sr. Divisional

Electrical Engineer (TRD), S. E. Railway, Adra. iii) Execution of indemnity bond on stamp duty in case of materials supplied by the

Railways. iv) Certificate of current statutory taxes and duties. v) Detailed entries made in the Measurement Book. 1.2.6 FINAL PAYMENT : Balance 10% payment will be made through the final bill only after satisfactory completion of the entire contractual work , satisfactory operation and handing over of the assets to the Railway duly tested and commissioned subject to compliance of the following application:

i) On supply of catalogue and operation manual/instruction books wherever applicable, if any .

ii) On supply of “as Erected Drawing “ of the equipment/installation, if applicable. iii) A “No claim” certificate in favour of Railway is issued by the contractor.

of 58

1.2.7 PAYMENT FOR SPARES AND FOR ADDITIONAL SUPPLIES: The contractor shall be eligible for receipt of full 90% payment for supply of spares and additional supplies ordered on him in accordance with prices included in the schedule after handing over of the spares to the Railway in good working condition. Balance 10% payment will be made through final bill. 1.2.8 PAYMENT OF PRICE VARIATION : No Price variation clause will be applicable . All prices to be quoted shall be firm. 1.2.9 PAYMENT OF STATUTORY VARIATION IN TAXES AND DUTIES: The unit prices quoted by the tenderer and accepted by the Railway Administration Shall be firm. Also the purchaser will not be responsible for payment of duties and taxes made by the tenderer under misappropriation of law. 1.2.10 FINAL SETTLEMENT AND REFUND OF SECURITY DEPOSIT: On expiry of the warranty period and issue of the certificate for final acceptance produced all the dues payable by the contractor to the Railway have been duly paid or otherwise made good by the contractor, the security deposit will be refunded to the contractor on production and surrender of the relative original receipts granted by the Railway in case it was paid in cash, and where the security deposit is in the form of bank guarantee will terminate the contract. 1.2.10.1 The security deposit shall however , be liable to the forfeited in case of any breach by the contractor of any of the conditions of the contract or for non completion of the full contract without prejudice to other rights and remedies of the Railway whether specifically provided for herein or otherwise. 1.2.11 POST PAYMENT AUDIT: It is an agreed term of the contract that the Railway reserves to itself the right to carryout a post payment audit and or technical examination of the works and the final bills, including all supporting vouchers, abstracts etc. and to make a claim on the contractor for the refund of any excess amount paid to him if as a result of such examination any over payment to him is discovered to have been made in respect of any work done or alleged to have been done by him under the contract. 1.12.12 MEASUREMENT: Payment for the work shall be made in accordance with the specifications, approved designs and drawings and measured in relevant units . The measurement will be made generally in accordance with Tender schedule in conformity with the explanatory notes of the Tender schedule , specification and standard engineering practices. 1.2.12.1 MEASUREMENT OF WORK : The contractor shall be paid for the works at the rates in the accepted schedule of rates and on the measurement taken by the Engineer or the Engineer’s representative in accordance with the rules prescribed for the purpose of the Railway: i) The quantity for items the unit for which it is prevalent ,accepted schedule of rates shall be recorded . ii)Such measurement will be taken of the work in progress from time to time and at such intervals as in the opinion of the engineer or his representative shall be proper having regard to the progress of work . The date and time on which the measurement are to be made shall be communicated . The contractor who shall be present at the site and shall sign the results of the measurement which shall also be signed by the Railway’s Engineer or the Engineer ‘s representative recorded in the official measurement book as an acknowledgement of his acceptance of the accuracy of the measurement . In the event of failure, on the part of the contractor to attend the work may be measured in his absence and such measurements shall not withstanding such absence be binding upon the contractor whether or not he shall have sign the measurement book , provided always that any objection made by him to any measurement shall be duly investigated and considered in the manner set out below :- a) It shall be open to the contractor to take specific objection to any recorded measurement or classification on any ground within 3 days from the date of measurement . Any measurement taken by the Engineer or his representative in the presence of the contractor or in his absence after due notice has been given to him on consequence of the objection made by the contractor , shall be final and binding on the contractor and no claim whatsoever shall thereafter be entertained regarding the accuracy and classification of the measurement . b) If any objection raised by the contractor is found by the Engineer to be incorrect, the contractor shall be liable to pay the actual expenses incurred in the measurements

--------------------------------X---------------------------------

of 58

SPECIAL CONDITION-I

1 Any specifications/conditions stated by the tenderer in the covering letter submitted

along with his tender shall be deemed to be a part of contact only to such extent has been explicitly accepted by the Railway.

2. CLAIMS: Contractor shall have no claim on account of any expenditure incurred by

them other than specifically agreed to in this contract. The contractor shall not be entitled for any advance on account of the work to be undertaken by them.

3. STATUTORY LEVIES: Any statutory levies imposed by the State or Central Government from time to time

during the currency of the contract shall be borne by the contractor. 4. CURRENCY OF THE CONTRACT: The currency of the contract will be 03 ( three ) months from the date of receipt of a

letter of acceptance. The Railway reserves the right to extend the contract period, if necessary.

The contractor has to bring his own labour to undertake work. 5. The contractor shall execute the contract as per the scope of work to the entire satisfaction of Sr.DEE/TRD/ADRA, South Eastern Railway. 6. Indemnity Bond: On acceptance of the tender, it will be obligatory on the part of the

contractor to execute an indemnity bond, on non-judicial stamp paper of Rs.100/- at his own cost for the full cost of the engine assembly, before taking the same.

7. Warranty:- The contractor shall ensure a warranty of 12 months from the date of delivery or 1800 hrs. from the date of commissioning of the Tower wagon, whichever is earlier. If any components of Tower wagons gets damaged due to repairing /replacement of any component/items defect within the warranty period, the same should be repaired by the contractor free of cost.

8. The work should be completed within 90 days from the date of Handing over the TW to the contractor for the work. 9. Penalty Clause : (a) If the work is found to be unsatisfactory /incomplete at any stage, the work shall be

terminated by railway and concluded as pre-existing guidelines. (b) In case stipulated time of 90 calendar days for the work is exceeded, a penalty of Rs

0.5% of the cost of running contract towards dismantling, repair, over-hauling calibration , fitment testing commissioning and trial of engine assembly per week of delay , maximum up to 10% of the contract value, shall be levied on the contractor. The decision of the Railway administration will be final in this regard. The above (b) shall be in addition to “No Payment” to the contractor for work not attended or attended unsatisfactorily. The decision of railway in this regard shall be final and binding on contractor.

(c ) Non compliance/unsatisfactory compliance of any provision lid down in the terms and

condition for the contract will render the contractor liable for imposition of penalty. For each case of non-compliance/non-standard compliance a penalty from 2% to 5% of the cost related to the accepted rate of schedule for particular item can be imposed by Sr.DEE/TRD/ADRA. The penalty so imposed will be recovered from contractor’s work done bill or from his S.D money. Payment will made for doing of the work under the schedule only. And no payment will be made for the work ,if not standard ,by the Contractor. Report of concerned SSE/RRD/ADRA or authorized representative of Railway nominated by the Sr. DEE/TRD/ADRA will be considered in this respect. If SSE/RRD/ADRA or authorized representative of Railway make any report regarding unsatisfactory work by the contractor ,this will also is liable for imposition of penalty.

(d) Any loss or damages caused to any of the asset/property of the respective Tower

wagons due to negligent working of the contractor or his deputed staff will be stand debitable and recoverable from the contractor’s work done from bill or from his Security Deposit Money or any other dues as the case may be.

10. Inspection of work:- The railways will not provide staff, material and man power . It should be ensured that

all the materials used in the above running contract towards dismantling, repair, overhauling, calibration, fitment, testing, commissioning and trial of engine assembly fitted on tower wagons shall conform to the specification mentioned in the manufacturer drawings and manuals.

of 58

11. This contract is governed by General conditions of the contract (GCC) of South Eastern

Railway as amended from time to time .The existing GCC are forming the part of this document. In addition, these special condition are applicable to this tender . In case of conflict between special condition and GCC, the special condition will prevail. Decision of Sr.DEE/TRD/ADRA shall be final and binding in case of any dispute.

12. The tenderer shall sign on every page of tender document and submit along with there offer. Submission of duly signed tender document shall be deemed to imply that he has read understood and abided by the conditions laid down in the tender document.

13. Quoted rates should be firm and inclusive. Price variation is not acceptable. 14. Tenderer should give their full address of correspondence including telephone, fax and

name of contact person clearly in their offer. 15. Tenderer in their own interest may inspect site of work before submission of their offer,

in order to assess the difficulties likely to face during the course of execution of work. Any plea in this regard will not be entertained after wards.

16. Quantity of any item may vary during execution of the work as decided by Sr.DEE/TRD/ADA or his authorized representative minus 25% or plus 25% of total value of the work mentioned in acceptance letter as per the following:

The procedure detailed below shall be adopted for dealing with variation in quantities during execution of contracts :

1. Individual NS items in contracts shall be operated with variation of plus or minus 25% and payment would be made as per the agreement rate. For this no finance concurrence is required.

2. In case an increase in quantity of an individual items by more than 25% of the agreement quantity is considered unavoidable, the same shall be got executed by floating a fresh tender. If floating a fresh tender for operating that items is considered not practicable, quantity of that items may be operated in excess of 125% of the agreement quantity subject to the following conditions:

(a) Operation of an item by more than 125% of the agreement quantity needs the approval of an officer of the rank not less than S.A. Grade.

(i) Quantities operated in excess of 125% but upto 140% of the agreement quantity of the concerned item, shall be paid at 98% of the rate awarded for that item in that particular tender.

(ii) Quantities operated in excess of 140% but upto 150% of the agreement quantity of the concerned item shall be paid at 96% of the rate awarded for that item in that particular tender.

(iii) Variation in quantities of individual items beyond 150% will be prohibited and would be permitted only in exceptional unavoidable circumstances with the concurrence of associated finance and shall be paid at 96% of the rate awarded for that item in that particular tender .

(b) The variation in quantities as per the above formula will apply only to the Individual

items of the contract and not the overall contract value. (c) Execution of quantities beyond 150% of the overall agree mental value should not be

permitted and ,if found necessary, should be only through fresh tenderers or by negotiating with existing contractor, with prior personal concurrence of FA&CAO/ FA&CAO(C) and approval General Manager.

3. In case where decrease is involved during execution of contract: (a) The contract signing authority can decrease the item upto 25% of individual item with

out finance concurrence. (b) For decrease beyond 25% for individual items or 25% of contract agreement value, the

approval of an officer not less than rank of S.A.Grade may be taken, after obtaining ‘No claim certificate’ from the contractor and with finance concurrence, giving detailed reasons for each such decrease in the quantities.

(c) It should be certified that the work proposed to be reduced will not be required in the same work.

4. The limit for varying quantities for minor value items shall be 100% (As against 25 prescribed for other items). A minor value item for this purpose is defined as an item whose original agreement value is less than 1% of the total original agreement value.

5. No such quantity variation limit shall apply for foundation items. 6. As per SOR items are concerned, the limit of 25% would apply to the value of SOR

schedule as a whole and not on individual SOR items. However, in case of NS items,

of 58

the limit of 25% would apply and the individual items respective of the manner of quoting the rate( Single percentage rate or individual item rate).

7. Decision of Sr.DEE/TRD/ADA regarding minus variation as per the Railway’s requirement will be final and binding on the contractor.

17. The tenderer is required to submit a plan for executing the work so as to complete the job in the specified period along with offer.

18. The tenderer should survey the site/location and get himself acquainted with all the details site conditions before making the offer.

19. The tenderer must submit along with the offer an undertaking clearly specifying the period by which all materials will be made available to the custody of the Railway, where equipments are to be supplied by the tenderer. Such undertaking will be independent of the actual progress of the work as envisaged in the offer. The failure to supply equipments or materials due to failure of tenderers, sub-contractor will not be accepted as excuse for delay in execution and for extension.

20. The LD Clause will be applicable in Phase wise both for non-completion of work as detailed in the plan for execution of the job and non-supply of materials by the tenderer/contractor in time.

21 If there is any item which is not covered by the special conditions of contract or by the terms and conditions mentioned elsewhere in the tender, the terms and conditions mentioned in the general conditions applicable to works contract of S.E. Railway shall apply.

22. The following documents should be specified for submission along with tender. a) List of personnel organization available on hand and proposed to be engaged for the

subject work. b) List of Plan and machinery available on hand (own) and proposed to be inducted

(own and hired to be given separately) for the subject work. c) List of work completed in the last three financial years giving description of work,

organization for whom executed, approximate value of contract at the time of award, date of award and date of schedule completion of work. Date of actual start, actual completion and final value of contract should also be given.

d) List of works on hand indicating description of work contract value, approximate value of balance work yet to be done and date of award.

NOTE: 1)In case of items (c) and (d) above, supportive documents/ certificates from the organization with whom they worked/are working should enclosed.

2) Certificate from private individuals for whom such works are executed/being executed should not be accepted.

23. References to previous deposition of credentials in any tender will not be accepted and the credentials , if any ,should be submitted with each tender separately.

24. Transportation of all materials issued by Railway has to be carried out by the

contractor with own arrangement at his own cost to work sites and Railway will provide neither any assistance towards transportation of materials nor any cost towards transportation of materials required in connection with the execution of work. The materials will be supplied from purchasers’ depot at RRD/Adra or other sections under jurisdiction of Adra Division.

25. The Railway will not provide any drawings/specifications etc. required in connection with the execution of work as mentioned in the tender document. The contractor has to arrange all drawing and documents at his own cost .

26 .All materials to be supplied by the contractor have to be duly inspected by RITES or a

Competent Railway official as appointed by Sr.DEE/TRD/ADA. No payment will be made unless the inspection certificate has been submitted along with Manufacturer’s original challans and test certificates. The materials have to be procured only from CORE/RDSO approved sources wherever applicable or from reputed sources or OEMs as applicable or as per instruction of Railway. Before placement of order for supply of materials under schedule-I the contractor has to obtain approval of Sr.DEE/TRD/ADRA for supply of such materials .

of 58

27. If the tenderer does not quote above/below percentage, then in such cases ‘above’ will be

considered. If the quoted rate in words & figures are not tallying in such cases tender will be rejected. (Ref. CVO (E)/GRC’s letter No. GM/V/System Improvemet/45,dtd: 29.11.2002).

28. Rates to be quoted by the tenderer should be inclusive of all taxes including Service Tax /charges, Lead, Lifts, Transportation and other charges leviable by the Govt. from time to time.

29. Any change in statutory levies ( plus or minus , addition or abolishing ) by state or central Government will be borne by Railway during execution of contract and at the time of billing

30. Any instructions issued by the Railway from time to time regarding payment of wages to labour will be adhered to by the contractor and Decision of Sr.DEE/TRD/ADA regarding this will be final and binding on the contractor.

of 58

PERFORMANCE REPORT SHEET To be filled in and the documents in support to be attached by the tenderer.

1. Name and address of the firms :

a) Individual/Proprietorship firm : b) Partnership firm : c) Private Ltd/Public Ltd :

d) Government undertaking : 2. Financial Capacity : a) Audited annual turnover for the

i) 2012-2013 ii) 2013-2014 iii) 2014-2015

b) Banker’s solvency certificate from a schedule bank to be attached.

3. Detailed plants and machineries owned by the tenderer and proof thereof :

Sl. No.

Name and make of Machinery with capacity

Date of purchase

Condition of machinery

Place deployed presently

Whether the machinery can be deployed immediately If contract awarded.

1 2 3 4 5 6

4. Experience of Tenderer’s :

a) Details of works executed and completed in the last 3 years(Enclose separate sheet if required)

Sl. No.

Name of work and contract No.

Agreemental value

Final completion value of work

Name and address of Employer

Completion time as per Agreement

Actual time take to complete the and regarding to details if any

Remarks

1 2 3 4 5 6 7 8

b) Works in hand:

Sl. No.

Name of work and contract No.

Agreemental Value

Name and address of Employer

Completion time as per original agreement and whether extension given or not, if extended furnish the reasons of extension

% of progress of principal items of

1 2 3 4 5 6

5. Particulars of contracts terminated with RISK & COST on the contractor , if any :-

of 58

6. Details of arbitration cases with Railway administration and other organization, Signature of the Tenderer/Contractor Seal & Date Note : Documentary evidence regarding above declaration are to be attached by the Tenderer and if found incorrect after verification of the declarations , their offers may be rejected without any further correspondence in this regard with the tenderers. 7. UNDERTAKING I/We __________________________________ in my/our capacity as ___________________________ Of the tenderer hereby declare that the above mentioned particulars are true and correct to the best of my /our knowledge and belief. I/We understand that action can be taken against the firm within the preview of the contract any of the particulars declared by above are found to be misleading or incorrect.

----------------------x-----------------------

of 58

FORM 6

INDEMNITY BOND FOR ON ACCOUNT PAYMENTS

We, M/s _________________________ hereby undertake that we hold at _____________ (fill in the name of location) for and on behalf of the president of India acting in the premises through the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra ( herein after referred to as the “Purchaser” and as his property in trust for him all materials works for which on account payments have been made to us against the contract for _______vide letter of acceptance of tender No.__________ dated ___________ until such time the materials/works are duly installed /and communicated or otherwise handed over to him. We shall be entirely responsible for the safe custody and protection of the said materials against all risk till they are duly delivered as installed / and commissioned to the purchaser or as he may direct otherwise and shall indemnity the purchaser against any loss, damage or deterioration whatsoever in respect of the said materials while in our possession. The said materials/works shall at all time be open inspection by officer authorized by the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra..

Should any loss, damage or deterioration of materials/works occur and refund become due, the purchaser shall be entitled to recover from us the full cost without prejudice to any other remedies available to him by deduction from any sum due or any such which at any time hereafter become due to us under the said or any other contract. Dated___________day of ______200… For and on behalf of M/s________________(contractor) Signature of witness Name of witness in Block letters_________ Address_______________

of 58

(FORM No. 3)

REVISED MODEL FORM OF BANK GUARANTEE BOND

GUARANTEE BOND

1) In consideration of the president of India acting through --------------------- (hereinafter called “the said Government”) having agreed to exempt ____________(hereinafter called the said contractor(s)”) from the demand under the terms and conditions of an __________at ________________ dated ___________ made between __________ and __________ for _________ (hereinafter called the said contractor(s) of the terms and conditions contained in the said agreement , on production of a Bank only we __ hereinafter referred to as (The Bank) at the request of _______(Contractor(s) do hereby undertake to pay to the government and amount not exceeding Rs ___________against any loss or damage caused to or suffered or would be caused to or suffered by the govt. by reason of any breach by the said contractor(s) of any of the terms and conditions contained in the said agreement . 2. We_______(indicate the name of the bank) do hereby undertake to pay the amount due and payable under this guarantee without and demur, merely on a demand from the Govt . stating that the amount claimed is due by way of less or damage caused to or suffered by the Govt. by reason of breach by the said contractor(s) of any of the terms and conditions contained in the said agent or by reasons of the contractor(s) failure to perform the said agent, any such demand made on the bank shall be conclusive as regard the amount due and payable by the bank under this guarantee . However our liability under this guarantee shall be restricted to an amount not exceeding Rs.___________________. 3. We undertake to pay the government any money so demanded not withstanding any dispute or disputes raised by the contractor(s)/supplier(s) in any suit or proceeding pending before any court or Tribunal relating thereto our liability under this present being absolute and unequivocal . The payment so made by us under this bond shall be a valid discharge of our liability for payment there under and contractor(s)/supplier(s) shall have no claim against us for making such payment. 4. We______(indicate the name of the bank ) further agree that the guarantee herein contained shall remain in full force and effect during the period that would be taken for the performance of the said agreement and that it shall continue to be enforceable till all the dues of the government under or virtue of the said agent , have been fully paid and its claims satisfied or discharged or till _______(Office /department) Ministry of ________certifies that the terms and conditions of the paid agent have fully and properly carried out by the said contractor(s) and accordingly discharges this guarantee, unless a demand or claim under this guarantee is make on us in writing on or before the ____ we shall be discharged from all liabilities under this guarantee thereafter. 5. We_____(indicate the name of bank) further agree with the Govt. shall have the fullest liberty without our consent to vary any of the terms and conditions of the said agent or to extend time of performance by the said contractor(s) form time to time any of the powers exercisable by the govt. against the said contractor(s) and to forbear or enforce any of the terms and conditions relating to the said agent and we shall not be relieved from our liability by reason of any such variation , or extension being granted to the said contractor(s) or by any such indulgence by the government to the said contractor(s) or by any such matter or thing whatsoever which under the law relating to sureties would, put for this provision, have effect of so relieving us.

6. This guarantee will not be discharged due to the charge in the constitution of the bank or the contractor(s)/supplier(s). 7. We________lastly undertake not to revoke this guarantee during its currency except with the previous consent of the government in writing . Dated ___________day of 200… For________________________ (indicate the name of the bank)

of 58

TENDER FORM

OFFER LETTER

To The President of India,

Acting through the Divisional Electrical Engineer (TRD),

South Eastern Railway

Adra.

1. I/We M/s………………………………………………… have read the various conditions to tender attached hereto and hereby agree to abide by the said conditions. I/We also agree to keep this tender open for acceptance for a period of …………days from the date fixed for opening the same and in default thereof, I/We will be liable for forfeiture of my/our security deposit. I/We offer to do the works as detailed in the attached schedule of prices. 2. I/We hereby bind myself /our self to complete the work within the time limits specified in the conditions of tender. I/We also hereby agree to abide by the general and special conditions of contract and to carry out the works according to the specifications of materials and work laid down by the Railway for the present contract.

3. I/We hereby declare that I/We possess a copy of the S.E.Railway schedule of labour and materials rate, revised section 1974, volume (1) and general conditions of contract and standard specification 1994, Volume (2) corrected upto date have gone through the rates , regulations , for tender and contracts , general conditions, standard specifications and other particulars embodied therein and have fully understood and abide by them .

4. A sum of Rs……… ………….. (Rupees ……………………………………………………….) only vide………………………………………. is hereby forwarded as earnest money . The full value of the earnest money shall stand forfeited without prejudice to any other rights for remedies if :

a) I/We withdraw my/our offer within the validity of tender. b) I/We do not execute the contract documents within seven days after receipt

of notice issued by the Railways that such documents are ready , c) I/We do not commence the work within ten days after receipt of order to

that effect. 5. Until a formal agreement is prepared and executed acceptance of this tender shall constitute a binding contract between us subject to modifications as may be mutually agreed to between us indicated in the letter of acceptance of my/our offer for this work. 6. I/We enclosed the Income Tax , sales tax clearance certificate or a declaration to that effect as required under Para 1.1.7 of the tender papers pertaining to me/us for the year. Tenderer’s Address: Signature of Tenderrer/s Date: Signature of witnesses 1. 2.

of 58


ADRA DIVISION

QUOTED TENDER RATE (PERCENTAGE ABOVE/BELOW)

Name of work : Replacement of 5 nos. Perkins Make Engine of Four Wheeler Mark II Tower wagon by TATA Engine and Repair of 02 nos. of Mark II Tower wagon of Adra Division of S.E.Railway

Completion period: 06 months from the date of issue of LOA. OPEN TENDER NOTICE NO: TRD/ADA/OT-2015/4/ TW/ Mark-II , dtd 20.07.2015

Sl. No.

Description of the works Quoted Tender Rate (%age ABOVE/BELOW in figures and

words)

1

Schedule Of work (Schedule Value: Rs 44,08,106/- ) ( Rupees Forty Four Lakh Eight Thousand One Hundred Six

only )

_______ ____ABOVE/BELOW (%age in figure)

______________________ABOVE/BELOW (%age in words)

BASIC RATES GIVEN IN SCHEDULE OF PRICES NOTE: i) Conditional Tenders will be summarily rejected without any condition

Whatsoever. Tenderer should not quote any Percentage ABOVE/BELOW in the schedule of prices.

ii) Tax and levies will be deducted at source as applicable.

iii) The rates quoted should be inclusion of all taxes, ED etc including Service Tax applicable .

iv) The tenderer should quote single percentage for the Schedule of work

Signature of the Tenderer (s) with seal

of 58

South Eastern Railway

ADRA DIVISION

Schedule Of Price

Name of the work : Replacement of 5 nos. Perkins Make Engine of Four Wheeler Mark II Tower wagon by TATA Engine and Repair of 02 nos. of Mark II Tower wagon of Adra Division of S.E.Railway

(The schedule of price shall be read in conjunction with the explanatory notes attached with it. )

Schedule:I (Supply component )

Sr. No.

Description Unit Qty. Rate (in Rs.)

Total Cost ( in Rs)

1

Supply of materials required for Opening , cleaning and refiling of fuel tank assembly and all the suction and delivery pipes to be renewed and brass net to be provided for filtering of HSD oil.

Lot 2 1555.51 3111.02

2

Supply of materials required for Clutch & gear operating linkage rods, levers bushes & joint connections to be renewed and worn out spares & joint connections to be renewed and worn out spares to be replaced, If necessary.

Lot 2 11666.33 23332.65

3

Supply of materials required for Provision of additional cross member arrangement to be provoded at the rear portion of gear box for better strength and to stop vibration of gear box.

Lot 2 11666.33 23332.65

4

Supply of materials required for Accelerator system to be renewed with supply of clamps, rods, ends, bushes, yoke & cable and necessary welding & machining work to be done

Lot 2 5055.41 10110.82

of 58

5

Supply of materials required for Renewal of all worn out channel of size (3X2X1/4) and Angles (2X2X1/4) of the inside roof (Ceilling) and under floor of the Tower Wagon and necessary welding providing 'L' support with each other better strength. All the worn out nuts & bolts to be replaced

Lot 2 5444.29 10888.57

6

Supply of materials required for renewal of all - Worn out wooden frame and damaged wooden cross runner of size (3X3X72)X14 nos. under chassis of the Tower Wagon with sal wood with supply and fitment of heavy duty nut bolts, Supply of materials required for Worn out wooden planks of the entire floor to be renewed with aluminium checkered plate,Supply of materials required for Engine cover (dala) has to be newly constructed,Supply of materials required for replacing bolt the existing hinges by heavy duty new hinges duly fitted,Supply of materials required for both side driver's cab to be newly constructed.Supply of materials required for All the inside damaged wooden pillar and runner to be replaced for better strength.Supply of materials required for ,Besides any wooden planks, runner etc. not mentioned above to be renewed. All the damaged wooden planks, runner, cross, pillars of the entire roof will be renewed with the supply of new sal wood.

Lot 2 66498.05 132996.11

7

Supply of materials required for The ladder of the both side of the Tower wagon to be newly constructed with supply of required M.S. pipe(1¼" X 1¼" X 14 SWG), with M.S. checkered plate and necessary nuts & bolts to be fied properly.

Lot 2 6175.37 12350.75

of 58

8

Supply of materials required for Defective sunmica fitted in inner side of the cabin and its roof to be fitted by new one with 1½" aluminium heavy duty strip & angle. Supply of materials required store room plateform two stage to be constructed newly sal wood and necessary nuts & bolts properly fitted and to be covered.

Lot 2 22166.02 44332.04

9

Supply of materials required for 02 nos. driver siting arrangement with lower bracket by new one in both side driver cab end

Lot 2 3111.02 6222.04

10

Supply of materials required for Collapsible gate to be repaired properly with supply & fitting of side iron grill with nuts & bolts

Lot 2 1555.51 3111.02

11

Supply of materials required for Complete inside steel structure to be renewed including necessary welding and providing necessary 'L' support for better strength and all the worn out nuts & bolts to be replaced

Lot 2 5055.41 10110.82

12

Supply of materials required for Top roof assembly Of Tower Wagon to be constructed newly by M.S Sheet (8"X4"X14" SWG) 14 nos. fitted and welded providing angle support for better strength bituminous so that leaking of rain water is arrested

Lot 2 52109.59 104219.17

13

Supply of materials required for Both side of sliding door to be constructed newly with supply of required wooden planks etc. sliding arrangement to be renewed properly

Lot 2 5444.29 10888.57

14

Supply of materials required for All damaged wooden planks on the roof top to be dismantled and replaced by new planks of sal wood with necessary nuts & bolts for better support and also Roof top to be covered with TARFELT

Lot 2 11044.12 22088.24

of 58

15

Supply of materials required for The lifting and lowering arrangement of the platform to be renewed with supply of worm our required angles (1½"X1½"X1¼") & channel (3"X1½"X1¼") and for all the worm out required pulleys, wire rope, pins and nuts & bolts to be replaced with new one

Lot 2 31110.20 62220.40

16

Supply of materials required for cat walk including fencing to avaid slipping of staff working on roof with supply of required M.S angle (1½"X1½"X1 ¼"), M.S. plate (2mm) square pipe(1:X1"X14 SWG)

Lot 2 27221.43 54442.85

17

Supply of materials required for Fixing of aluminium checking plate sixe (8'X4'X3mm) with supply a of aluminium checkered plates and necessary nuts bolts.

Lot 2 27221.43 54442.85

18

Supply of materials required for deck fencing with new pocket 10 nos. for each car suitable for new fencing with supply of M.S angle (2"X2"X¼") square pipe (1½"X1½"X14 SWG) and necessary nuts & bolts

Lot 2 13999.59 27999.18

19

Supply of materials required for Repairing & overhauling of swivelling platform including supply of worn out gear pinion, shaft, bearing and all the worn out nuts & bolts

Lot 2 18821.67 37643.34

20

Supply of materials required for Entire Tower Wagon to be painted (i.e. inside, outside and roof and under frame potion) with good quality paint, colour of painting to be selected by the completent authority, As per usual practice the surface to be applied on those portion where it required, After that finally two coats of paint to be done.

Lot 2 13999.59 27999.18

of 58

21

Supply of materials required for Hand brake system to be renewed with supply of new bushes, pin and cotter pins and necessary machining & grinding work to be done

Lot 2 9333.06 18666.12

22

Supply of materials required for Dismantling of pantograph and refitted with worn out wooden pieces as per requirement along with necessary nuts & bolts

Lot 2 1944.39 3888.78

23

Supply of materials required for Electrical wiring in both cabins to be renewed with fitment of TATA type dash board with all switches like head light, S/L, P/L, Serch light, horn and starting switch and also supply of The new head light with halogen bulb, side light assembly And packing light assembly Etc.

Lot 2 9721.94 19443.88

24

Supply of materials required for New heavy duty wiper motor assembly With arm & blade along with spindle kit, extension rod, link assembly Etc. to be provided

Lot 2 4666.53 9333.06

25

Supply of materials required for Additional arrangement of cut-off switch along with necessary cable to be provided to disconnected the battery connection as and when required

Lot 2 2722.14 5444.29

26

Supply of materials required for fitting of 06 nos. new LED type roof lamp inside floor (ceiling) of the cabin and The cable hamessing to be renewed and all the switches to be replaced

Lot 2 3111.02 6222.04

27

Supply of new heavy duty air horn assembly With allied fittings and necessary connections of pipe to be provided on both side of Tower Wagon

Lot 2 1088.86 2177.71

of 58

28

Supply of materials required for All the couplings and joints connections of air compressor to be supplied and filted

Lot 2 2177.71 4355.43

29

Supply of materials required for The complete heavy duty air pipes/hoses along with joints and connexctions to be provided and the pipes will be properly fitted on the chassis of Tower Wagon and necessary clamps to be provided to stop vibration.

Lot 2 9721.94 19443.88

30

Supply of a new brake change over valve and other materials required for the vaccum type changeover valve to be replaced with a new brake change over valve along with necessary allied fittings and connections(Make: CD/TVS).

Lot 2 4666.53 9333.06

31 Supply of New unload valve with allied fittings to be provided(Make:CD/TVS)

Lot 2 2177.71 4355.43

32

Supply of 02 nos brake chamber assembly To be provided and mounted on chasis with heavy duty bracket and bolts with nuts along with allied fittings and accessories (Make: CD/TVS)

Lot 2 29554.69 59109.38

33

Supply of materials required for On the both sides of drivers cab 02 nos. of foot valve operating lever along with allied fittings will be connected with brake pedal(Make: CD/TVS)

Lot 2 18666.12 37332.24

34

Supply of materials required for Modification/detachment of reduction gear box system with supply and fittings (Make: PALPAR)

Lot 2 24888.16 49776.32

of 58

35

Supply of Modified TATA type propeller shaft assembly With crossing bearing and flange (Make:DD), to be provided with replacement of gear box flange(Heavy duty) and direction box flange(Heavy duty) along with necessary nuts and bolts and lock (Make: TVS)

Lot 2 6222.04 12444.08

36

Supply of materials required for Modification of old/obsolete model iron brake into latest model composite brake block and necessary machining works to be done for above modification works with supply of pins, clamps and bracket (Latest model composite brake block to be supplied by Railway)

Lot 2 12444.08 24888.16

37

Supply of new Diesel engine Model no. TATA1613 (Modified) along with fuel insection pump with injector Nozzle (New model ) Air compressor assembly , Lubrication Oil Filter Assembly, Fuel Filter, Water Pump Assembly, clutch Housing and Fly Wheel with Ring Gear , Exhaust manifold with front and rear cross member and 4 nos. Front and Rear Mounting self Starter 12 Volt and Alternator 12 Volt (Lucas-TVS make)

Nos. 5 423507.00 2117535.00

38

Supply of new 5 Speeds Gear box assembly GBS-40-5/7.51A -model make -Telco with attachment and Clutch Pressure Plate , clutch plate , and Clutch brg. With fork and housing kit

Nos. 5 98201.68 491008.40

39

Supply of new radiator Assembly complete with inlet and outlet pipe and house with clip and bracket including thermostat and silencer Assembly for TELCO Engine

Nos. 5 27045.28 135226.40

Total for schedule -I 3711825.89

of 58

Schedule-II ( Works /Erection component )

Sr. No.

Description Unit Qty. Rate (in Rs.)

Total Cost ( in Rs)

1

Opening , cleaning and refiling of fuel tank assembly and all the suction and delivery pipes should be renewed and brass net should be provided for filtering of HSD oil.

Lot 2 388.88 777.76

2

Clutch & gear operating linkage rods, levers bushes & joint connections to be renewed and worn out spares & joint connections to be renewed and worn out spares to be replaced, If necessary.

Lot 2 3344.35 6688.69

3

Provision of additional cross member arrangement should be provoded at the rear portion of gear box for better strength and to stop vibration of gear box.

Lot 2 1633.29 3266.57

4

Accelerator system should be renewed with clamps, rods, ends, bushes, yoke & cable and necessary welding & machining work to be done

Lot 2 894.42 1788.84

5

Commissioning with assembly of all the above parts in the engine including testing and refitting inTower car including funning complete, watering is to be done for freeness of bearings

Lot 2 9721.94 19443.88

6

Dismantle of all worn out sunmica, plywood, M.S. Iron sheet, wooden plank and angles with all wooden cross runner of the entire Tower Wagon body both inside and outside.

Lot 2 12832.96 25665.92

7

Renewal of all worn out channel of size (3X2X1/4) and Angles (2X2X1/4) of the inside roof (Ceiling) and under floor of the Tower Wagon and necessary welding providing 'L' support with each other better strength. All the worn out nuts & bolts to be replaced

Lot 2 1477.73 2955.47

of 58

8

Worn out wooden frame and damaged wooden cross runner of size (3X3X72)X14 nos. under chassis of the Tower Wagon are to be renewed bt sal wood with supply and fitment of heavy duty nut bolts. Worn out wooden planks of the entire floor to be renewed with aluminium checkered plate. Engine cover (dala) has to be newly constructed, replacing bolt the existing hinges by heavy duty new hinges duly fitted, both side driver's cab to be newly constructed. All the inside damaged wooden pillar and runner will be replaced for better strength. Besides any wooden planks, runner etc. not mentioned above should be renewed. All the damaged wooden planks, runner, cross, pillars of the entire roof will be renewed with the supply of new sal wood.

Lot 2 12716.29 25432.59

9

The ladder of the both side of the Tower wagon to be newly constructed with supply of required M.S. pipe(1¼" X 1¼" X 14 SWG), with M.S. checkered plate and necessary nuts & bolts to be fied properly.

Lot 2 2068.83 4137.66

10

Defective sunmica fitted in inner side of the cabin and its roof to be fitted by new one with 1½" aluminium heavy duty strip & angle. The store room platform two stage to be constructed newly sal wood and necessary nuts & bolts properly fitted and to be covered.

Lot 2 2022.16 4044.33

11 Erection of 02 nos. driver siting arrangement with lower bracket by new one in both side driver cab end

Lot 2 777.76 1555.51

12 Collapsible gate to be repaired properly with supply & fitting of side iron grill with nuts & bolts

Lot 2 388.88 777.76

of 58

13

Complete inside steel structure should be renewed including necessary welding and providing necessary 'L' support for better strength and all the worn out nuts & bolts to be replaced

Lot 2 1166.63 2333.27

14

Top roof assembly Of Tower Wagon is to be constructed newly by M.S Sheet (8"X4"X14" SWG) 14 nos. fitted and welded providing angle support for better strength bituminous so that leaking of rain water is arrested

Lot 2 5833.16 11666.33

15

Both side of sliding door to be constructed newly with supply of required wooden planks etc. sliding arrangement to be renewed properly

Lot 2 1166.63 2333.27

16

All damaged wooden planks on the roof top to be dismantled and replaced by new planks of sal wood with necessary nuts & bolts for better surport. Roof top should be convered with TARFELT

Lot 2 2955.47 5910.94

17

The lifting and lowering arrangement of the platform to be renewed with supply & erection of worm our required angles (1½"X1½"X1¼") & channel (3"X1½"X1¼") and all the worm out required pulleys, wire rope, pins and nuts & bolts to be replaced with new one

Lot 2 3888.78 7777.55

18

Fabrication & erection of cat walk including fencing to avaid slipping of staff working on roof with erection of required M.S angle (1½"X1½"X1 ¼"), M.S. plate (2mm) square pipe(1:X1"X14 SWG)

Lot 2 5833.16 11666.33

19

Fixing of aluminium checking plate sixe (8'X4'X3mm) with supply and erection of aluminium checkered plates and necessary nuts bolts.

Lot 2 6222.04 12444.08

of 58

20

Fabrication and erection of deck fencing with erection new pocket 10 nos. for each car suitable for new fencing with supply and erection of M.S angle (2"X2"X¼") square pipe (1½"X1½"X14 SWG) and necessary nuts & bolts

Lot 2 4666.53 9333.06

21

Repairing & overhauling of swiveling platform including worn out gear pinion, shaft, bearing and all the worn out nuts & bolts

Lot 2 1788.84 3577.67

22

Entire Tower Wagon should be painted(i.e. inside, outside and roof and under frame potion) with good quality paint, colour of painting will be selected by the competent authority. As per usual practice the surface should be applied on those portion where it required. After that finally two coats of paint will be done.

Lot 2 6222.04 12444.08

23

Hand brake system should be renewed with supply & erection of new bushes, pin and cotter pins and necessary machining & grinding work should be done

Lot 2 2955.47 5910.94

24

Dismantling of pantograph and refitted with supply of worn out wooden pieces as per requirement along with necessary nuts & bolts

Lot 2 1399.96 2799.92

25

Electrical wiring in both cabins to be renewed with fitment of TATA type dash board with all switches like head light, S/L, P/L, Serch light, horn and starting switch. The new head light with halogen bulb, side light assembly And packing light assembly Etc.

Lot 2 2488.82 4977.63

26

New heavy duty wiper motor assembly With arm & blade along with spindle kit, extension rod, link assembly Etc. to be provided

Lot 2 1944.39 3888.78

of 58

27

Additional arrangement of cut-off switch along with necessary cable should be provided to disconnected the battery connection as and when required

Lot 2 622.20 1244.41

28

Fitting of 06 nos. new LED type roof lamp inside floor (ceiling) of the cabin. The cable hamessing to be renewed and all the switches to be replaced

Lot 2 777.76 1555.51

29

Erection of new heavy duty air hom assembly With allied fittings and necessary connections of pipe to be provided on both side of Tower Wagon

Lot 2 311.10 622.20

30

Old/Defective Exhauster assembly With allied connections to be opened from Tower Wagon. All the old/defective vaccum system pipe line and valves to be dismantled/opened from the Tower Wagon

Lot 2 1944.39 3888.78

31 All the couplings and joints connections of air compressor to be supplied and fitted

Lot 2 855.53 1711.06

32

The complete heavy duty air pipes/hoses along with joints and connections to be provided and the pipes will be properly fitted on the chassis of Tower Wagon and necessary clamps to be provided to stop vibration.

Lot 2 1788.84 3577.67

33

The vacuum type changeover valve will be replaced with a new brake change over valve along with necessary allied fittings and connections(Make: CD/TVS).

Lot 2 311.10 622.20

34 New unload valve with allied fittings to be provided(Make:CD/TVS)

Lot 2 155.55 311.10

35

02 nos. brake chamber assembly To be provided and mounted on chasis with heavy duty bracket and bolts with nuts along with allied fittings and accessories (Make: CD/TVS)

Lot 2 3655.45 7310.90

of 58

36

On the both sides of drivers cab 02 nos. of foot valve operating lever along with allied fittings will be connected with brake pedal(Make: CD/TVS)

Lot 2 2722.14 5444.29

37 Testing, commissioning and trial run of air brake system

Lot 2 22088.24 44176.48

38 Modification/detachment of reduction gear box system with fitting (Make: PALPAR)

Lot 2 2177.71 4355.43

39

Modified TATA type propeller shaft assembly With crossing bearing and flange (Make:DD), should be provided with replacement of gear box flange(Heavy duty) and direction box flange(Heavy duty) along with necessary nuts and bolts and lock (Make: TVS)

Lot 2 1866.61 3733.22

40

Modification of old/obsolete model iron brake into latest model composite brake block and necessary machining works should be done for above modification works with erection of pins, clamps and bracket (Latest model composite brake block to be supplied by Railway)

Lot 2 1944.39 3888.78

41

Erection of new Diesel engine Model no. TATA1613 (Modified) along with fuel insection pump with injector Nozzle (New model ) Air compressor assembly , Lubrication Oil Filter Assembly, Fuel Filter, Water Pump Assembly, clutch Housing and Fly Wheel with Ring Gear , Exhaust manifold with front and rear cross member and 4 nos. Front and Rear Mounting self Starter 12 Volt and Alternator 12 Volt (Lucas-TVS make)

Nos. 5 56631.00 283155.00

42

Erection of new 5 Speeds Gear box assembly GBS-40-5/7.51A -model make -Telco with attachment and Clutch Pressure Plate , clutch plate , and Clutch brg. With fork and housing kit

Nos. 5 21199.00 105995.00

of 58

43

Erection of new radiator Assembly complete with inlet and outlet pipe and house with clip and bracket including thermostat and silencer Assembly for TELCO Engine

Nos. 5 6217.80 31089.00

Total for schedule -II:Rs 696279.80

Total for Schedule-I & II : Rs 4408105.70

Roundd off : Rs 44,08,106.00

( Rupees Forty Four Lakh Eight Thousand One Hundred Six only )

Sr.DEE/TRD/ADRA

of 58


Special Conditions -II 1. Whenever an item of work covers supply of materials/erection/installation etc such

item will include supply of all associated accessories (such as bolts, nuts, washer of GI & SS clamps, foundation bolts etc or any other ancillary materials as per CORE/RDSO latest specification and drawings) which will be required to complete the work in all respect as per site condition to the satisfaction of Railway as well as to maintain the relevant standard, code of practice ensuring safe working. No separate payment for fastener is admissible.

2. (a) Erection/Installation of equipment (in respect of supply either by Railway or by the contractor) will include testing, satisfactory functioning as well as detail briefing regarding erection/maintenance/periodical schedules etc for the beneficial use of the Railways, such briefing will include as necessary with four copies of drawings literature/notes/operating manuals/maintenance manuals etc. on demand by the Railways.

(b) The basic quantity of components and materials require to make up a unit of work for the selected items are indicated for guidance only. There may be minor variation to suit erection but no adjustment in prices shall be made on that account.

3. (a) The tenderer should read the tender schedule along with explanatory notes in respect of the work and site condition carefully and seek clarification if any before submitting the tender paper. No clarification/dispute will be entertained afterwards. Any clarification/disputes after opening of tender in this regard will be decided by Sr.DEE/TRD/ADA and his decision shall be final and binding on the contractor.

(b) Tender should carefully understand the tender schedule along with explanatory notes and inspect the site to satisfy himself in all respect to complete the project/work before submitting the offer. After submission of offer it will be deemed that the contractor has understood the project/work and will complete the project/work at the quoted rate. It is understood and agreed that the contractor has, by carefully examination, satisfied himself as to the nature and location of the work, the conformation of the ground, the character, quality and quantity of the materials to be encountered, the character of equipment and facilities needed preliminary to and during the progress of the works, the general and local conditions, the labour conditions prevailing therein and all other matters which can in any way affect the works under the contract.

(c) The rates entered in the accepted schedule of rates of the contract are intended to provide for works duly and properly completed in accordance with general and special (if any) conditions of the contract and the specifications and drawings together with such enlargements, extensions, diminutions, reductions, alterations or additions as may be ordered in terms of clause 42 of G.C.C and without prejudice to the generality thereof.

4. All the machines, components, equipment (including ancillary parts/components) shall be of should be of reputed make/brand subject to prior approval to be obtained from Sr.DEE/TRD/ADA before its supply irrespective of such stipulation mentioned against the items in the schedule or not.

5. Tenderer should quote only the uniform percentage above or below or at par to the total cost of the schedule and not for individual item. Price variation is not acceptable.

6. Machines/Components/Equipments shall be as per relevant Railway specification and where Railway’s specification is not available relevant IS specification to be observed.

7. In every case the quoted cost should cover the transportation cost of materials by the contractor at his own risk from any depot of S.E.Railway to site and contractor will have to return all released/unused materials from the site of work to Railway store at no extra cost.

8. All the works shall be carried out duly observing the relevant standard/code of practice, IR rules and specification and drawings approved by Railways. The successful tenderer on receipt of the LOA and after observing all the basic formalities must provide a detailed planning for the execution of work with time limit and got the approval before commencement of work.

9. The special condition for schedule items are enclosed and tenderer shall go through them thoroughly before submitting offer.

10. The work is Replacement of 5 nos. Perkins Make Engine of Four Wheeler Mark II Tower wagon by TATA Engine and Repair of 02 nos. of Mark II

of 58

Tower wagon of Adra Division of S.E.Railway. The contractor has to undertake the work for Replacement of 5 nos. Perkins Make Engine & Repair of 02 nos. of Mark II Tower wagons. As soon as “The Letter of Acceptance ’’ (LOA) is issued, the contractor should carry out the detailed survey of work-site and should prepare and submit plan of action in Bar- chart .

11. After submission of the said plan of action in Bar-Chart the Railway will scrutinize the same and necessary approval will be given on the plan of action in Bar-Chart within Seven days of its submission.

12. The contractor should make preliminary arrangement for execution of work immediately after issue of LOA and should start the work immediately after approval of plan of action in Bar-Chart .

13. After assessing the requirement of material as per site, the contractor should place order for procurement of all materials within seven days from approval of plan of action in Bar-Chart as per schedule of work/or as per instruction of the Railway, if any and purchase order copy of materials should be submitted to Sr. DEE/TRD/ADRA’s office, accordingly.

14. Procurement action of the materials should invariably be in accordance with requirement of site i.e. it must be ensured by the contractor to supply materials first which will be required first in course of execution of work.

15. All the materials duly inspected should be supplied within three months from the date of approval of plan of action in Bar-Chart.

16. Any delay in submission of plan of action in Bar-Chart for approval or in supply & delivery of materials shall be recorded in your performance for future necessary action.

17. The LD Clause will be applicable in Phase wise both for non-completion of work as detailed in the plan for execution of the job and non-supply of materials by the contractor in time.

18 The contractor has to undertake the work for Repairing of Tower Wagon ( Mark-II) in ADRA Divison of S.E.Railway Replacement of 5 nos. Perkins Make Engine of Four Wheeler Mark II Tower wagon by TATA Engine and Repair of 02 nos. of Mark II Tower wagon of Adra Division of S.E.Railway at nominated place as decided by the Sr. DEE/TRD/ADRA and will have to deploy sufficient men and materials for each Mark-II Tower wagons in order to complete and hand over respective Tower Wagon within Two months from the date receipt of particular Tower wagon.

18. The work should be completed within stipulated completion period as per tender notification. Erection of any item of equipment whether supplied by Railway or contractor will include testing, commissioning and bringing the equipment into operation to the entire satisfaction of Railway .

of 58

EXPLANATORY NOTES FOR OF ITEMS OF SCHEDULE -I Item No.1

Price shall cover Supply of materials required for Opening , cleaning and refiling of fuel tank assembly and all the suction and delivery pipes to be renewed and brass net to be provided for filtering of HSD oil. Item No.2

Price shall cover Supply of materials required for Clutch & gear operating linkage rods, levers bushes & joint connections to be renewed and worn out spares & joint connections to be renewed and worn out spares to be replaced, If necessary. Item no. 3 Price shall cover Supply of materials required for Provision of additional cross member arrangement to be provoded at the rear portion of gear box for better strength and to stop vibration of gear box. Item no. 4 Price shall cover Supply of materials required for Accelerator system to be renewed with supply of clamps, rods, ends, bushes, yoke & cable and necessary welding & machining work to be done Item no. 5 Price shall cover Supply of materials required for Renewal of all worn out channel of size (3X2X1/4) and Angles (2X2X1/4) of the inside roof (Ceilling) and under floor of the Tower Wagon and necessary welding providing 'L' support with each other better strength. All the worn out nuts & bolts to be replaced Item no. 6 Price shall cover Supply of materials required for renewal of all - Worn out wooden frame and damaged wooden cross runner of size (3X3X72)X14 nos. under chassis of the Tower Wagon with sal wood with supply and fitment of heavy duty nut bolts, Supply of materials required for Worn out wooden planks of the entire floor to be renewed with aluminium checkered plate,Supply of materials required for Engine cover (dala) has to be newly constructed,Supply of materials required for replacing bolt the existing hinges by heavy duty new hinges duly fitted,Supply of materials required for both side driver's cab to be newly constructed.Supply of materials required for All the inside damaged wooden pillar and runner to be replaced for better strength.Supply of materials required for ,Besides any wooden planks, runner etc. not mentioned above to be renewed. All the damaged wooden planks, runner, cross, pillars of the entire roof will be renewed with the supply of new sal wood. Item no. 7

Price shall cover Supply of materials required for The ladder of the both side of the Tower wagon to be newly constructed with supply of required M.S. pipe(1¼" X 1¼" X 14 SWG), with M.S. checkered plate and necessary nuts & bolts to be fitted properly.

Item no. 8

Price shall cover Supply of materials required for Defective sunmica fitted in inner side of the cabin and its roof to be fitted by new one with 1½" aluminium heavy duty strip & angle. Supply of materials required store room plateform two stage to be constructed newly sal wood and necessary nuts & bolts properly fitted and to be covered.

of 58

Item no. 9 Price shall cover Supply of materials required for 02 nos. driver siting arrangement with lower bracket by new one in both side driver cab end Item no. 10 Price shall cover Supply of materials required for Collapsible gate to be repaired properly with supply & fitting of side iron grill with nuts & bolts Item no. 11 Price shall cover Supply of materials required for Complete inside steel structure to be renewed including necessary welding and providing necessary 'L' support for better strength and all the worn out nuts & bolts to be replaced

Item no. 12 Price shall cover Supply of materials required for Top roof assembly Of Tower Wagon to be constructed newly by M.S Sheet (8"X4"X14" SWG) 14 nos. fitted and welded providing angle support for better strength bituminous so that leaking of rain water is arrested

Item no. 13 Price shall cover Supply of materials required for Both side of sliding door to be constructed newly with supply of required wooden planks etc. sliding arrangement to be renewed properly

Item no. 14 Price shall cover Supply of materials required for All damaged wooden planks on the roof top to be dismantled and replaced by new planks of sal wood with necessary nuts & bolts for better support and also Roof top to be convered with TARFELT

Item no. 15 Price shall cover Supply of materials required for The lifting and lowering arrangement of the platform to be renewed with supply of worm our required angles (1½"X1½"X1¼") & channel (3"X1½"X1¼") and for all the worm out required pulleys, wire rope, pins and nuts & bolts to be replaced with new one

Item no. 16 Price shall cover Supply of materials required for cat walk including fencing to avoid slipping of staff working on roof with supply of required M.S angle (1½"X1½"X1 ¼"), M.S. plate (2mm) square pipe(1:X1"X14 SWG)

Item no. 17 Price shall cover Supply of materials required for Fixing of aluminium checking plate sixe (8'X4'X3mm) with supply a of aluminium checkered plates and necessary nuts bolts.

Item no. 18 Price shall cover Supply of materials required for deck fencing with new pocket 10 nos. for each car suitable for new fencing with supply of M.S angle (2"X2"X¼") square pipe (1½"X1½"X14 SWG) and necessary nuts & bolts

of 58

Item no. 19 Price shall cover Supply of materials required for Repairing & overhauling of swiveling platform including supply of worn out gear pinion, shaft, bearing and all the worn out nuts & bolts

Item no. 20 Price shall cover Supply of materials required for Entire Tower Wagon to be painted (i.e. inside, outside and roof and under frame potion) with good quality paint, colour of painting to be selected by the completent authority, As per usual practice the surface to be applied on those portion where it required, After that finally two coats of paint to be done.

Item no. 21 Price shall cover Supply of materials required for Hand brake system to be renewed with supply of new bushes, pin and cotter pins and necessary machining & grinding work to be done Item no. 22 Price shall cover Supply of materials required for Dismantling of pantograph and refitted with worn out wooden pieces as per requirement along with necessary nuts & bolts

Item no. 23 Price shall cover Supply of materials required for Electrical wiring in both cabins to be renewed with fitment of TATA type dash board with all switches like head light, S/L, P/L, Serch light, horn and starting switch and also supply of The new head light with halogen bulb, side light assembly And packing light assembly Etc.

Item no. 24 Price shall cover Supply of materials required for New heavy duty wiper motor assembly With arm & blade along with spindle kit, extension rod, link assembly Etc. to be provided

Item no. 25 Price shall cover Supply of materials required for Additional arrangement of cut-off switch along with necessary cable to be provided to disconnected the battery connection as and when required

Item no. 26 Price shall cover Supply of materials required for fitting of 06 nos. new LED type roof lamp inside floor (ceiling) of the cabin and The cable hamessing to be renewed and all the switches to be replaced

Item no. 27 Price shall cover Supply of new heavy duty air horn assembly With allied fittings and necessary connections of pipe to be provided on both side of Tower Wagon

Item no. 28 Price shall cover Supply of materials required for All the couplings and joints connections of air compressor to be supplied and filted

Item no. 29 Price shall cover Supply of materials required for The complete heavy duty air pipes/hoses along with joints and connections to be provided and the pipes will be properly fitted on the chassis of Tower Wagon and necessary clamps to be provided to stop vibration.

of 58

Item no. 30 Price shall cover Supply of a new brake change over valve and other materials required for the vacuum type changeover valve to be replaced with a new brake change over valve along with necessary allied fittings and connections(Make: CD/TVS).

Item no. 31 Price shall cover Supply of New unload valve with allied fittings to be provided(Make:CD/TVS)

Item no. 32 Price shall cover Supply of 02 nos brake chamber assembly To be provided and mounted on chasis with heavy duty bracket and bolts with nuts along with allied fittings and accessories (Make: CD/TVS)

Item no. 33 Price shall cover Supply of materials required for On the both sides of drivers cab 02 nos. of foot valve operating lever along with allied fittings will be connected with brake pedal(Make: CD/TVS)

Item no. 34 Price shall cover Supply of materials required for Modification/detachment of reduction gear box system with supply and fittings (Make: PALPAR)

Item no. 35 Price shall cover Supply of Modified TATA type propeller shaft assembly With crossing bearing and flange (Make:DD), to be provided with replacement of gear box flange(Heavy duty) and direction box flange(Heavy duty) along with necessary nuts and bolts and lock (Make: TVS)

Item no. 36 Price shall cover Supply of materials required for Modification of old/obsolete model iron brake into latest model composite brake block and necessary machining works to be done for above modification works with supply of pins, clamps and bracket (Latest model composite brake block to be supplied by Railway)

Item no. 37 Price shall cover Supply of new Diesel engine Model no. TATA1613 (Modified) along with fuel insection pump with injector Nozzle (New model ) Air compressor assembly , Lubrication Oil Filter Assembly, Fuel Filter, Water Pump Assembly, clutch Housing and Fly Wheel with Ring Gear , Exhaust manifold with front and rear cross member and 4 nos. Front and Rear Mounting self Starter 12 Volt and Alternator 12 Volt (Lucas-TVS make)

Item no. 38 Price shall cover Supply of new 5 Speeds Gear box assembly GBS-40-5/7.51A -model make -Telco with attachment and Clutch Pressure Plate , clutch plate , and Clutch brg. With fork and housing kit

Item no. 39 Price shall cover Supply of new radiator Assembly complete with inlet and outlet pipe and house with clip and bracket including thermostat and silencer Assembly for TELCO Engine

Spare parts under schedule-I are to be procured as per instruction of railway .

of 58

Explanatory Note On Schedule –II

The price shall also include repair, overhauling, calibration, fitment, testing and successful commissioning and trial of engine fitted on 4 wheeler Tower Wagon, Mark-II. The price shall cover dismantling of all necessary components for repair, overhauling & fitment and commissioning work. Price shall also cover the cost of waste cotton, HSD oil, Patrol, lubricants and other consumable items for their use during repair and overhauling of Tower Wagon. Price shall include Erection/ replacement/ installation / fitment of spares/ components as mentioned under schedule-II item no.1 to 43 of Mark-II , 4-wheeler tower wagons The price shall also include following activities under schedule –II:

Item no. 1 The price shall cover Opening , cleaning and refiling of fuel tank assembly and all the suction and delivery pipes should be renewed and brass net should be provided for filtering of HSD oil.

Item no. 2 The price shall cover Clutch & gear operating linkage rods, levers bushes & joint connections to be renewed and worn out spares & joint connections to be renewed and worn out spares to be replaced, If necessary.

Item no. 3 The price shall cover Provision of additional cross member arrangement should be provoded at the rear portion of gear box for better strength and to stop vibration of gear box. Item no. 4 The price shall cover Accelerator system should be renewed with clamps, rods, ends, bushes, yoke & cable and necessary welding & machining work to be done

Item no. 5 The price shall cover Commissioning with assembly of all the above parts in the engine including testing and refitting inTower car including funning complete, watering is to be done for freeness of bearings

Item no. 6 The price shall cover Dismantle of all worn out sunmica, plywood, M.S. Iron sheet, wooden plank and angles with all wooden cross runner of the entire Tower Wagon body both inside and outside.

Item no. 7 The price shall cover Renewal of all worn out channel of size (3X2X1/4) and Angles (2X2X1/4) of the inside roof (Ceilling) and under floor of the Tower Wagon and necessary welding providing 'L' support with each other better strength. All the worn out nuts & bolts to be replaced

of 58

Item no. 8 The price shall cover Worn out wooden frame and damaged wooden cross runner of size (3X3X72)X14 nos. under chassis of the Tower Wagon are to be renewed bt sal wood with supply and fitment of heavy duty nut bolts. Worn out wooden planks of the entire floor to be renewed with aluminium checkered plate. Engine cover (dala) has to be newly constructed, replacing bolt the existing hinges by heavy duty new hinges duly fitted, both side driver's cab to be newly constructed. All the inside damaged wooden pillar and runner will be replaced for better strength. Besides any wooden planks, runner etc. not mentioned above should be renewed. All the damaged wooden planks, runner, cross, pillars of the entire roof will be renewed with the supply of new sal wood.

Item no. 9 The price shall cover The ladder of the both side of the Tower wagon to be newly constructed with supply of required M.S. pipe(1¼" X 1¼" X 14 SWG), with M.S. checkered plate and necessary nuts & bolts to be fied properly.

Item no. 10 The price shall cover Defective sunmica fitted in inner side of the cabin and its roof to be fitted by new one with 1½" aluminium heavy duty strip & angle. The store room plateform two stage to be constructed newly sal wood and necessary nuts & bolts properly fitted and to be covered.

Item no. 11 The price shall cover Erection of 02 nos. driver siting arrangement with lower bracket by new one in both side driver cab end

Item no. 12 The price shall cover Collapsible gate to be repaired properly with supply & fitting of side iron grill with nuts & bolts

Item no. 13 The price shall cover Complete inside steel structure should be renewed including necessary welding and providing necessary 'L' support for better strength and all the worn out nuts & bolts to be replaced

Item no. 14 The price shall cover Top roof assembly Of Tower Wagon is to be constructed newly by M.S Sheet (8"X4"X14" SWG) 14 nos. fitted and welded providing angle support for better strength bituminous so that leaking of rain water is arrested

Item no. 15 The price shall cover Both side of sliding door to be constructed newly with supply of required wooden planks etc. sliding arrangement to be renewed properly

Item no. 16 The price shall cover All damaged wooden planks on the roof top to be dismantled and replaced by new planks of sal wood with necessary nuts & bolts for better support. Roof top should be convered with TARFELT

of 58

Item no. 17 The price shall cover The lifting and lowering arrangement of the platform to be renewed with supply & erection of worm our required angles (1½"X1½"X1¼") & channel (3"X1½"X1¼") and all the worm out required pulleys, wire rope, pins and nuts & bolts to be replaced with new one

Item no. 18 The price shall cover Fabrication & erection of cat walk including fencing to avaid slipping of staff working on roof with erection of required M.S angle (1½"X1½"X1 ¼"), M.S. plate (2mm) square pipe(1:X1"X14 SWG)

Item no. 19 The price shall cover Fixing of aluminium checking plate sixe (8'X4'X3mm) with supply and erection of aluminium checkered plates and necessary nuts bolts.

Item no. 20 The price shall cover Fabrication and erection of deck fencing with erection new pocket 10 nos. for each car suitable for new fencing with supply and erection of M.S angle (2"X2"X¼") square pipe (1½"X1½"X14 SWG) and necessary nuts & bolts

Item no. 21 The price shall cover Repairing & overhauling of swivelling platform including worn out gear pinion, shaft, bearing and all the worn out nuts & bolts

Item no. 22 The price shall cover Entire Tower Wagon should be painted(i.e. inside, outside and roof and under frame potion) with good quality paint, colour of painting will be selected by the completent authority. As per usual practice the surface should be applied on those portion where it required. After that finally two coats of paint will be done.

Item no. 23 The price shall cover Hand brake system should be renewed with supply & erection of new bushes, pin and cotter pins and necessary machining & grinding work should be done

Item no. 24 The price shall cover Dismantling of pantograph and refitted with supply of worn out wooden pieces as per requirement along with necessary nuts & bolts

Item no. 25 The price shall cover Electrical wiring in both cabins to be renewed with fitment of TATA type dash board with all switches like head light, S/L, P/L, Serch light, horn and starting switch. The new head light with halogen bulb, side light assembly And packing light assembly Etc.

of 58

Item no. 26 The price shall cover New heavy duty wiper motor assembly With arm & blade along with spindle kit, extension rod, link assembly Etc. to be provided

Item no. 27 The price shall cover Additional arrangement of cut-off switch along with necessary cable should be provided to disconnected the battery connection as and when required

Item no. 28 The price shall cover Fitting of 06 nos. new LED type roof lamp inside floor (ceiling) of the cabin. The cable hamessing to be renewed and all the switches to be replaced

Item no. 29 The price shall cover Erection of new heavy duty air hom assembly With allied fittings and necessary connections of pipe to be provided on both side of Tower Wagon

Item no. 30 The price shall cover Old/Defective Exhauster assembly With allied connections to be opened from Tower Wagon. All the old/defective vaccum system pipe line and valves to be dismantled/opened from the Tower Wagon

Item no. 31 The price shall cover All the couplings and joints connections of air compressor to be supplied and fitted

Item no. 32 The price shall cover The complete heavy duty air pipes/hoses along with joints and connections to be provided and the pipes will be properly fitted on the chassis of Tower Wagon and necessary clamps to be provided to stop vibration.

Item no. 33 The price shall cover The vaccum type changeover valve will be replaced with a new braalong with necessary allied fittings and connections(Make: CD/TVS).

Item no. 34 The price shall cover New unload valve with allied fittings to be provided(Make:CD/TVS)

Item no. 35 The price shall cover 02 nos brake chamber assembly To be provided and mounted on chasis with heavy duty bracket and bolts with nuts along with allied fittings and accessories (Make: CD/TVS)

Item no. 36 The price shall cover On the both sides of drivers cab 02 nos of foot valve operating lever along with allied fittings will be connected with brake pedal(Make: CD/TVS)

of 58

Item no. 37 The price shall cover Testing, commissioning and trial run of air brake system

Item no. 38 The price shall cover Modification/detachment of reduction gear box system with fitting (Make: PALPAR)

Item no. 39 The price shall cover Modified TATA type propeller shaft assembly With crossing bearing and flange (Make:DD), should be provided with replacement of gear box flange(Heavy duty) and direction box flange(Heavy duty) along with necessary nuts and bolts and lock (Make: TVS)

Item no. 40 The price shall cover Modification of old/obsolete model iron brake into latest model composite brake block and necessary machining works should be done for above modification works with erection of pins, clamps and bracket (Latest model composite brake block to be supplied by Railway)

Item no. 41 The price shall cover Erection of new Diesel engine Model no. TATA1613 (Modified) along with fuel insection pump with injector Nozzle (New model ) Air compressor assembly , Lubrication Oil Filter Assembly, Fuel Filter, Water Pump Assembly, clutch Housing and Fly Wheel with Ring Gear , Exhaust manifold with front and rear cross member and 4 nos. Front and Rear Mounting self Starter 12 Volt and Alternator 12 Volt (Lucas-TVS make)

Item no. 42 The price shall cover Erection of new 5 Speeds Gear box assembly GBS-40-5/7.51A -model make -Telco with attachment and Clutch Pressure Plate , clutch plate , and Clutch brg. With fork and housing kit

Item no. 43 The price shall cover Erection of new radiator Assembly complete with inlet and outlet pipe and house with clip and bracket including thermostat and silencer Assembly for TELCO Engine

Notes on Schedule: I & Schedule: II: In addition to the terms and conditions as explained in explanatory of Schedule –I & II as mentioned above the following are to be adhered to 1. The prices shall cover supply all materials required for repair and overhauling of Tower

Wagon old existing engine. Price shall also cover commissioning of existing engine to bring the Tower Wagon into successful operation. Price shall also include supply of all necessary fastener and accessories pertaining to the Tower Wagon. The work is to be done as per instruction of Railway

2. The prices shall cover supply of all necessary accessories related to transmission

system (Gear, Clutch etc) for replacement of old transmission system of T.W. Price shall also cover dismantling of existing old transmission system of the tower wagon and Erection of new transmission system.Price shall also cover commissioning of new

of 58

erected transmission system in the Tower Wagon to bring it into successful operation. Price shall also include supply of all necessary fasteners for erection and commissioning purpose. The work is to be done as per instruction of Railway

3. The prices shall cover supply of all necessary accessories related to air break system for replacement of existing vacuum break system of T.W. Price shall also cover dismantling of existing old vacuum break system of the tower wagon and Erection and commissioning of new air break system in the tower wagon to bring it into successful operation .Price shall also included supply of all necessary fasteners for erection and commissioning . The concern representative will carry out inspection of the new air break system. The work is to be done as per instruction of Railway

4. The prices shall cover supply of electrical control board with all accessories and

associated wiring materials for replacement of the old existing electrical control board of T.W as mentioned in the respective Schedule –I & II. Price shall also cover dismantling of existing old electrical control board (if any) including associated wiring as per instruction of Railway . Price shall also cover erection and commissioning of the electrical control board in the tower wagon including associated wiring and related connection to bring it into successful operation as per instruction of Railway. Price shall also included supply of all necessary fasteners for erection and commissioning of new electrical control board . Inspection of new electrical control board and associated wiring (Like cable/wires, pipes etc) will be carried out by the concerned Rly. representative. The work is to be done as per instruction of Railway

5. Price shall cover commissioning of the said tower wagon as per instruction of Railway after replacing the old engine, transmission system ,vacuum brake and electrical control board with associated wiring by new item to bring it into successful operation in all respect of all the items as mentioned above should be suitable for the Tower wagon.

6. All claims under schedule: I & II have to be supported by the following certificate to

be furnished by the contractor on the connected bills. a) The modifications are not on account of non-compliance of specifications approved

and instructions given by the Railways for execution of works. b) The quantities of work involved for Repair and Overhauling of Tower Wagons have

been finalized jointly with the Railway’s Engineers before taking the work in hand. c) The dismantled/ released materials where applicable have been handed over to the

Railway’s representative at Store Depot. The price is inclusive of transporting all the dismantled materials/ released materials to the Railway’s representative stores depot.

7. Regarding Any dispute during execution of workthe decision of sr. DEE/TRD/ADA shall be final and binding on the contractor

______________________-X_______________

SOUTH EASTERN RAILWAY - ser.indianrailways.gov.in · page 1 of 58 दण प ूव रेलवे...

Documents

Transcript of SOUTH EASTERN RAILWAY - ser.indianrailways.gov.in · page 1 of 58 दण प ूव रेलवे...