IMPLEMENTATION OF MACHIKE TARU JABBA OIL …isgs.com.pk/wp-content/uploads/2018/02/Section-3... ·...
Transcript of IMPLEMENTATION OF MACHIKE TARU JABBA OIL …isgs.com.pk/wp-content/uploads/2018/02/Section-3... ·...
BUILD, OWN, OPERATE AND TRANSFER CONTRACT –v2
1
[OPERATOR NAME]
AND
INTER STATE GAS SYSTEMS (PRIVATE) LIMITED
BUILD, OWN, OPERATE AND TRANSFER CONTRACT
RELATING TO
IMPLEMENTATION OF MACHIKE TARU JABBA OIL PIPELINE PROJECT
FOR SECTION 3
MADE AT [], ISLAMIC REPUBLIC OF PAKISTAN
ON [], 2018
TO THE EXTENT POSSIBLE, THIS DRAFT IS CONSISTENT WITH THE HEADS OF
AGREEMENT AND SHALL SUBSTITUTE THE HEADS OF AGREEMENT. ISGS RESERVES
THE RIGHT TO AMEND THIS DRAFT DURING THE PROCESS OF CLARIFICATIONS. ISGS
DOES NOT ENVISAGE NEGOTIATIONS ON MATERIAL PROVISIONS POST ISSUANCE OF
LOI. 1
1 The final agreed draft of the BOOT Contract shall depend on the Design submitted by the Selected Bidder and the provisions of the draft
shall be tailored for Section 3 of the Project, as necessary.
BUILD, OWN, OPERATE AND TRANSFER CONTRACT –v2
2
TABLE OF CONTENTS
1. DEFINITIONS ......................................................................................................................... 1
1.1 DEFINITIONS ........................................................................................................... 1
1.2 RULES OF INTERPRETATION ................................................................................. 12
2. EFFECTIVE DATE, CONDITIONS SUBSEQUENT AND LONG STOP DATE ......... 13
2.1 EFFECTIVE DATE AND LONG STOP DATE ............................................................. 13
3. CONDITIONS SUBSEQUENT ............................................................................................ 13
3.1 CONDITIONS SUBSEQUENT ................................................................................... 13
3.2 WAIVER OF CONDITIONS SUBSEQUENT ............................................................... 14
3.3 NOTICE OF SATISFACTION/WAIVER ..................................................................... 14
3.4 LONG STOP DATE ................................................................................................. 14
3.5 CONSEQUENCES OF TERMINATION ....................................................................... 14
3.6 OBLIGATION TO SATISFY CONDITIONS SUBSEQUENT .......................................... 14
3.7 EXTENSION OF LONG STOP DATE ......................................................................... 14
4. TERM AND COMPLETION ............................................................................................... 15
4.1 TERM .................................................................................................................... 15
4.2 PROGRAMME AND SCHEDULED COMMERCIAL OPERATIONS DATE ..................... 15
4.3 COMMERCIAL OPERATIONS DATE ........................................................................ 16
5. IMPLEMENTATION OF THE PIPELINE SYSTEM ...................................................... 16
5.1 RESPONSIBILITIES OF THE OPERATOR .................................................................. 16
5.2 RESPONSIBILITIES OF ISGS .................................................................................. 18
5.3 AUTHORISED REPRESENTATIVES ......................................................................... 19
5.4 OPERATOR’S PROJECT MANAGER ........................................................................ 19
5.5 APPOINTMENT OF INSPECTION ENGINEER ............................................................ 19
5.6 APPLICATIONS BY THE OPERATOR FOR REQUIRED CONSENTS ............................ 20
5.7 ROLE OF THE ISGS CONSULTANT ........................................................................ 20
6. CONSTRUCTION, TESTING AND COMMISSIONING OF THE PIPELINE
SYSTEM ................................................................................................................................. 20
6.1 TECHNICAL REQUIREMENTS ................................................................................ 20
6.2 APPOINTMENT OF EPC CONTRACT; AMENDMENTS TO EPC CONTRACT ............. 21
6.3 REVIEW OF AGREEMENTS WITH CONTRACTORS .................................................. 21
6.4 PROGRESS REPORTS ............................................................................................. 21
6.5 MONITORING OF PIPELINE SYSTEM CONSTRUCTION ........................................... 22
6.6 NOTICE OF TESTS AND TRIALS; REPORTS ............................................................ 22
6.7 RESTRICTION ON USAGE ...................................................................................... 22
6.8 ADDITIONAL CHANGES ........................................................................................ 22
BUILD, OWN, OPERATE AND TRANSFER CONTRACT –v2
3
6.9 OPERATOR'S RESPONSIBILITY .............................................................................. 23
6.10 TESTING AND COMMISSIONING ............................................................................ 23
6.11 FAILURE TO PASS PERFORMANCE TESTS ............................................................. 24
6.12 DELAYS IN IMPLEMENTATION .............................................................................. 26
7. OPERATION AND MAINTENANCE OF PIPELINE FACILITY ................................. 26
7.1 OPERATION AND MAINTENANCE OF THE PIPELINE SYSTEM ................................ 26
7.2 O&M AGREEMENT; O&M CONTRACTOR ............................................................ 27
7.3 OPERATION OF THE PIPELINE SYSTEM BY THE OPERATOR .................................. 27
8. TRANSFER ............................................................................................................................ 27
8.1 SCOPE OF TRANSFER ............................................................................................ 27
8.2 TRANSFER UPON EXPIRY ..................................................................................... 28
8.3 TRANSFER UPON EARLY TERMINATION .............................................................. 30
8.4 COMPENSATION UPON EARLY TERMINATION...................................................... 30
8.5 PROVISIONS APPLICABLE TO TRANSFERS GENERALLY ....................................... 31
9. ROUTE AND ROUTE MODIFICATION .......................................................................... 32
9.1 ROUTE .................................................................................................................. 32
9.2 ROUTE MODIFICATION ......................................................................................... 32
10. REPRESENTATIONS AND WARRANTIES .................................................................... 32
10.1 ISGS’S REPRESENTATIONS AND WARRANTIES .................................................... 32
10.2 OPERATOR’S REPRESENTATIONS AND WARRANTIES ........................................... 32
11. LIABILITY ............................................................................................................................ 33
11.1 LIMITATION OF LIABILITY .................................................................................... 33
11.2 INDEMNIFICATION FOR FINES AND PENALTIES .................................................... 33
12. INSURANCE .......................................................................................................................... 33
12.1 INSURANCE COVERAGE ........................................................................................ 33
12.2 APPLICATION OF PROCEEDS ................................................................................. 34
12.3 INSURERS .............................................................................................................. 34
13. ASSIGNMENT AND SECURITY ....................................................................................... 34
13.1 ASSIGNMENT ........................................................................................................ 34
13.2 CREATION OF SECURITY ....................................................................................... 34
14. LIQUIDATED DAMAGES .................................................................................................. 35
14.1 LIQUIDATED DAMAGES FOR TRANSFER CONDITION ........................................... 35
15. GUARANTEES ...................................................................................................................... 35
15.1 IMPLEMENTATION PERFORMANCE BOND ............................................................. 35
15.2 OPERATIONS PERFORMANCE BOND ..................................................................... 35
15.3 SBLC .................................................................................................................... 36
16. FORCE MAJEURE ............................................................................................................... 36
BUILD, OWN, OPERATE AND TRANSFER CONTRACT –v2
4
16.1 DEFINITION OF FORCE MAJEURE .......................................................................... 36
16.2 NOTIFICATION OBLIGATIONS ............................................................................... 37
16.3 DUTY TO MITIGATE .............................................................................................. 38
16.4 DELAY CAUSED BY FORCE MAJEURE .................................................................. 38
17. TERMINATION .................................................................................................................... 38
17.1 TERMINATION FOR DEFAULT ............................................................................... 38
17.2 TERMINATION AS A RESULT OF FORCE MAJEURE EVENT .................................... 40
17.3 VOLUNTARY TERMINATION ................................................................................. 40
17.4 TERMINATION NOTICES ........................................................................................ 40
17.5 OBLIGATIONS UPON TERMINATION ..................................................................... 41
17.6 OTHER REMEDIES ................................................................................................. 41
18. RESOLUTION OF DISPUTES ............................................................................................ 41
18.1 RESOLUTION BY PARTIES ..................................................................................... 41
18.2 EXPERT ................................................................................................................. 41
18.3 ARBITRATION ....................................................................................................... 43
18.4 PERFORMANCE TO CONTINUE DURING DISPUTE ................................................. 43
19. TAXES .................................................................................................................................... 44
19.1 TAXES APPLICABLE TO THE OPERATOR ............................................................... 44
19.2 TAXES APPLICABLE TO ISGS ............................................................................... 44
20. INVOICING; PAYMENT AND DISPUTED AMOUNTS ................................................ 44
20.1 INVOICING ............................................................................................................ 44
20.2 PAYMENTS AND DISPUTED AMOUNTS ................................................................. 44
21. MISCELLANEOUS PROVISIONS ..................................................................................... 45
21.1 NOTICES................................................................................................................ 45
21.2 ACCOUNTS AND REPORTS .................................................................................... 46
21.3 FOSSIL AND ARCHAEOLOGICAL FINDS ................................................................. 46
21.4 GOVERNING LAW AND JURISDICTION .................................................................. 47
21.5 AMENDMENT ........................................................................................................ 47
21.6 THIRD PARTIES ..................................................................................................... 47
21.7 NO WAIVER .......................................................................................................... 47
21.8 RELATIONSHIP OF THE PARTIES ........................................................................... 47
21.9 SURVIVAL ............................................................................................................. 47
21.10 LANGUAGE ........................................................................................................... 47
21.11 ENTIRETY ............................................................................................................. 48
21.12 CONFIDENTIALITY ................................................................................................ 48
21.13 SUCCESSORS AND ASSIGNS .................................................................................. 48
21.14 NO LIABILITY FOR REVIEW .................................................................................. 48
BUILD, OWN, OPERATE AND TRANSFER CONTRACT –v2
5
21.15 AFFIRMATION/ INTEGRITY PACT .......................................................................... 48
21.16 COUNTERPARTS .................................................................................................... 49
SCHEDULE 1 – PIPELINE SYSTEM DESIGN AND SPECIFICATIONS ................................ 51
SCHEDULE 2 – DESIGN CAPACITY SCHEDULE ..................................................................... 52
SCHEDULE 3 – ROUTE ................................................................................................................... 53
SCHEDULE 4 – PROGRAMME ...................................................................................................... 54
SCHEDULE 5 – INTEGRITY PACT ............................................................................................... 55
SCHEDULE 6 – SBLC ....................................................................................................................... 56
SCHEDULE 7 – FORM OF PRE-COMMISSIONING TEST REPORT ..................................... 60
SCHEDULE 8 – FORM OF CERTIFICATE OF ACCEPTANCE ............................................... 61
SCHEDULE 9 –WHITE OIL SPECIFICATIONS ......................................................................... 62
SCHEDULE 10– REQUIRED CONSENTS ..................................................................................... 64
SCHEDULE 11 –TRANSFER COMPENSATION UPON EARLY TERMINATION ............... 65
SCHEDULE 12 – FORM OF IMPLEMENTATION PERFORMANCE BOND ......................... 67
SCHEDULE 13 – FORM OF OPERATIONS PERFORMANCE BOND .................................... 69
SCHEDULE 14 – ENTRY POINT, EXIT POINT AND OFFTAKE POINT(S) .......................... 72
SCHEDULE 15 –TECHNICAL REQUIREMENTS ....................................................................... 73
SCHEDULE 16 – FORM OF SPONSOR UNDERTAKING .......................................................... 74
1
THIS BUILD, OWN, OPERATE AND TRANSFER CONTRACT is made on [], 2018
BETWEEN:
[●], a company incorporated under the laws of Pakistan and having its registered address at [●]
("Operator", which term shall be deemed to include its successors and assigns);
-AND-
INTER STATE GAS SYSTEMS (PRIVATE) LIMITED, a company incorporated under the laws
of Pakistan and having its registered office at 8th Floor, Petroleum House, Ataturk Avenue, G-5/2,
Islamabad, Pakistan ("ISGS", which term shall be deemed to include its successors and assigns);
(the Operator and ISGS are hereinafter referred to individually as a "Party" and collectively as the
"Parties"),
WHEREAS:
(A) ISGS intends to implement the Project based on a “Build-Own-Operate-Transfer” model
(“BOOT Model”).
(B) The Operator is a project company, created by the Sponsor(s) solely for the purpose of
developing, owning and operating the Pipeline System on a BOOT Model for ultimate transfer to
ISGS or its nominee in terms of the Pipeline System Documents as provided for in this BOOT
Contract at the end of Term.
(C) The Operator has agreed to develop the Pipeline System on the terms and conditions set forth in
the Pipeline System Documents.
NOW THEREFORE, in consideration of mutual benefits to be derived and the representations and
warranties, conditions and undertakings herein contained and intending to be legally bound hereby,
the Parties agree as follows:
1. DEFINITIONS
1.1 Definitions
Whenever the following capitalised terms appear in this BOOT Contract, the recitals or in the
Schedules, whether in the singular or in the plural, present, future or past tense, they shall have the
respective meanings stated below:
"Acceptable Long-Term Credit Rating" –
(a) with respect to Persons that are incorporated or organised outside of Pakistan or to unsecured,
unguaranteed and unsubordinated instruments issued by such Persons, A- or higher by S&P, A3
or higher by Moody’s or A- or higher by Fitch; and
(b) with respect to Persons that are incorporated or organised in Pakistan or to instruments issued by
such Persons established in Pakistan:
(i) in relation to such a Person, that is rated AA or higher by PACRA or AA or higher by JCR-
VIS or any equivalent mutual fund rating assigned by MUFAP; and
(ii) in relation to such an instrument, that it is rated AA or higher by PACRA or AA or higher by
JCR-VIS or any equivalent mutual fund rating assigned by MUFAP,
provided that where a Person or any instruments are rated by more than one of S&P, Moody’s or Fitch or
by PACRA or JCR-VIS or the equivalent mutual fund rating assigned by MUFAP, as applicable, then the
lowest rating will apply for determining whether the Person or instrument has an Acceptable Long-Term
Credit Rating.
2
"Acceptable Short-Term Credit Rating" –
(a) with respect to Persons that are incorporated or organised outside of Pakistan or to unsecured,
unguaranteed and unsubordinated instruments issued by such Persons, A-1+ or higher by S&P or
P-1 by Moody’s or F1+ or higher by Fitch; and
(b) with respect to Persons that are incorporated or organised in Pakistan or to instruments issued by
such Persons established in Pakistan, A1 or higher by PACRA or A1 by JCR-VIS or the
equivalent mutual fund rating assigned by MUFAP,
provided that where a Person or any instruments (or as the case may be, a mutual fund) are rated by more
than one of S&P, Moody’s or Fitch or by PACRA or JCR-VIS or the equivalent mutual fund rating
assigned by MUFAP, as applicable, then the lowest rating will apply for determining whether the Person
or instrument has an Acceptable Short-Term Credit Rating.
“Acceptance Option” – The meaning ascribed thereto in Clause 6.11(a).
"Affiliate" – In relation to any Person, where such Person controls twenty percent (20%) or more of
the Ordinary Share Capital of another Person directly or indirectly through one or more
intermediaries.
“Agreement Year” – As provided/ to be provided for in the Transportation Agreement.
“Adjusted Annual Reserved Capacity” – As provided/ to be provided for in the Transportation
Agreement.
"BOOT Contract" – This Build, Own, Operate and Transfer Contract, together with all Schedules
attached hereto, dated as of the date first written above, by and between ISGS and the Operator, as
may be amended or supplemented by the Parties from time to time.
“BOOT Direct Agreement” - The agreement to be entered into between the Operator, ISGS and any
Lender(s) in respect of this BOOT Contract.
"Business Day" – Any day that banks in Pakistan are legally permitted to be open for business, as
well as when offices of the Federal Government of the GOP are open and functioning.
“Cancelling Date” – The meaning ascribed thereto in Clause 6.12.
"Certificate of Acceptance" – The meaning ascribed thereto in Clause 6.10.2 (Performance Tests).
“Certificate of Readiness for Commissioning” – The certificate to be issued by the Inspection
Engineer confirming that the Pipeline System is available for the purpose of carrying out the
Performance Tests, which shall be duly endorsed and witnessed by the ISGS Consultant.
“Certificate of Readiness for Pre-Commissioning” – The certificate to be issued by the Inspection
Engineer confirming that the Pipeline System is ready for the purpose of carrying out the Pre-
Commissioning Tests, which shall be duly endorsed and witnessed by the ISGS Consultant.
"Change in Law" –
(a) The adoption, promulgation, repeal, modification or reinterpretation after the date of this BOOT
Contract by any Public-Sector Entity of any Law of Pakistan (including a final, binding and non-
appealable decision of any Public-Sector Entity);
(b) the imposition by a Relevant Authority of any term or condition in connection with the issuance,
renewal, extension, replacement or modification of any Required Consent after the date of this
BOOT Contract; or
3
(c) the imposition by a Relevant Authority of any additional Required Consent;
that in the case of each of clause (a), (b), or (c) above results in either a substantial increase in cost or
substantial decrease in revenue as a consequence of any requirement for the design, construction,
operation or maintenance of the Pipeline System that is more restrictive than the most restrictive
requirements (i) under the Laws of Pakistan as in effect as of the date of this BOOT Contract (ii)
specified in any applications, or other documents filed in connection with such applications, for any
Required Consent filed by the Operator, and (iii) agreed to by the Operator under any of the Pipeline
System Documents.
"Commercial Operations Date – The Day immediately following the date on which the Pipeline
System and the Project is Commissioned, as stated in the Certificate of Acceptance.
"Commissioned" – The successful completion of the Performance Tests as confirmed by the
Certificate of Acceptance.
“Compensation Amounts” – The compensation amounts mentioned in Schedule 11.
"Conditions Subsequent" – The Conditions Subsequent provided for in Clause 3 (Conditions
Subsequent).
“Connected System” – Any White Oil Product transportation or distribution system or section
thereof that is interconnected with the Pipeline System.
"Continuing Contracts" – The meaning ascribed thereto in Clause 8.2.7.
"Contractors" – The contractors and suppliers engaged by the Operator to carry out and perform the
activities required under the Principal Documents, including the EPC Contractor, the O&M
Contractor, and any other direct contractors and any of their direct sub-contractors integrally involved
in Implementation and Operations of the Pipeline System.
“Construction Commencement Date” – The date on which the construction of the Pipeline System
is started.
"Custody Transfer"– The Custody Transfer between the relevant parties as mentioned in the Custody
Transfer and Interface Agreement for the Section of the Project during the stage of Operations
contemplated under the Transportation Agreement.
"Custody Transfer and Interface Agreement"– The Custody Transfer and Interface Agreement, in
relation to each Section of the Project, to be entered into between ISGS, the Operator and such other
parties between whom Interface and Custody Transfer issues may arise, to deal with the Interface and
Custody Transfer issues during the Implementation Period and Operations of the Pipeline System.
“Custody Transfer and Interface Direct Agreement” – The agreement between the Operator, ISGS
and the parties to the Custody Transfer and Interface Agreement and, where relevant, the Lender(s) in
respect of the Custody Transfer and Interface Agreement.
"Day" - means a continuous period of twenty-four (24) hours beginning at 12:00 midnight and
“Daily” shall be construed accordingly.
“Delayed Payment Rate” – One (01) month KIBOR on any amounts payable in Pak Rupees and
calculated for the actual number of Days for which the relevant amount remains unpaid on the basis of
a three hundred and sixty five (365) Day year, prevailing on the date that payment first becomes due.
"Design Life" – The period of time for which the Pipeline System is designed to operate in
accordance with the requirements of the BOOT Contract, which in this case shall be a period of forty
(40) Years from the Commercial Operations Date.
4
“Design Capacity” – The transportation capacity of the Pipeline System over the Term, as per the
Design Capacity Schedule attached as Schedule 2 hereto.
“Direct Agreements” – Together, the BOOT Direct Agreement, the Transportation Agreement
Direct Agreement, EPC Direct Agreement, O&M Direct Agreement and Custody Transfer and
Interface Direct Agreement2.
"Dispute" – Any dispute or disagreement or difference arising under, out of, or in connection with
this BOOT Contract, including, without limitation, any dispute or difference concerning the existence,
legality, validity or enforceability of this BOOT Contract or any provision hereof or the obligations or
performance of a Party under any provision hereof.
"Dispute Notice" – The meaning ascribed thereto in Clause 18.1.1 (Resolution by Parties).
"Effective Date" – The meaning ascribed thereto in Clause 2.
“Entry Point” – The point at which White Oil Products are received from the OMCs and/ or from
any Connected System (as applicable) at the beginning of the Section, as per Schedule 14.
"Environmental Liabilities" – All Losses (including, without limitation, reasonable costs of
investigation, testing, containment, removal, clean-up, abatement or remediation, and reasonable
attorney’s fees and costs), whether or not quantified in amounts relating to the presence in the
environment of Hazardous Materials attributable to the Pipeline System or any liabilities or
obligations arising from any violation by the Operator, its Contractors or their employees or agents of
any environmental Laws of Pakistan.
"Environmental Standards" – Collectively, the environmental guidelines and occupational health
and safety standards established by the Pakistan Environmental Protection Agency and the relevant
Environmental Protection Agency of the relevant Provincial Governments relating to the Pipeline
System.
"EPC" – Engineering, procurement and construction.
"EPC Contract" – The agreement or agreements to be entered into between the Operator and the
EPC Contractor for the design, engineering, procurement, construction, completion, start-up, testing,
and commissioning by the EPC Contractor of the Pipeline System, as may be amended from time to
time.
"EPC Contractor" – The engineering, procurement and construction Contractor or Contractors
appointed by the Operator and not objected to by ISGS pursuant to Clause 6.2.
“EPC Direct Agreement” means the agreement to be entered into between the Operator, ISGS, the
EPC Contractor and, where applicable, the Lender(s) in respect of the EPC Contract.
“Exit Point” – Point at which the White Oil Products are transferred from the Section to the
Connected System (where applicable), as per Schedule 14.3
"Expert" – The meaning ascribed thereto in Clause 18.2.
"Expiry Date" – The last Day of the Term.
2 This is subject to amendment depending on the financing structure of the selected bidder and pipeline system documents. 3 This subject to modification, depending on the Section of the Pipeline System.
5
"Financial Closing" –The execution and delivery of the Financing Documents that evidence
sufficient financing for the construction, testing, completion and commissioning of the Pipeline
System (following the resolution of any objections raised by ISGS to the Term Sheet in accordance
with this BOOT Contract) and the satisfaction, waiver or deferment of conditions precedent for the
initial availability of funds under the Financing Documents.
"Financial Closing Date" – means the date by which Financial Closing is to be achieved as per
Clause 3.1(b)(ii), as may be extended from time to time.
"Financing Documents" – Any and all loan or facility agreements, bonds, indentures, security
agreements, mortgages, subordination agreements, participation agreements, letters of credit, direct
agreements, note or bond purchase agreements, interest rate hedging arrangements, currency hedging
arrangements and other related documents (including Islamic financing agreements), for which the
respective Term Sheets have not been objected to by ISGS, entered into by the Operator with respect
to the financing of the Pipeline System of the Section and any refinancing thereof.
“Fixed Tariff” – The Fixed Tariff, as provided/ to be provided for in the Transportation Agreement.
"Force Majeure Events” – The meaning ascribed thereto in Clause 16.
"Foreign Currency" − The legal currency of any country or countries other than Pakistan.
"Good Industry Practice" – At a particular time, those practices, methods and acts as are in
accordance with good standards of prudence applicable to the international projects akin to the Project
which would be expected to accomplish the desired result at the lowest reasonable cost consistent
with reliability, safety and expedition.
"GOP" − The Government of Pakistan.
"Hazardous Material" – Any pollutant, contaminant, solid waste, toxic or hazardous substance or
waste, any explosive or radioactive materials regulated under, or subject to any Laws of Pakistan.
"HSD" – High Speed Diesel.
"Implementation "– shall comprise of activities arising during the Implementation Period up to the
Commercial Operations Date under this BOOT Contract, in relation to the Pipeline System, including
but not limited to all management, engineering, procurement, including purchasing, supply and
transportation, erection, construction, installation, inspection and testing, completion, including
Mechanical Completion, Pre-commissioning, Performance Tests, start-up, initial operation, and
performing all other works required to achieve the issuance of the Certificate of Acceptance for the
Pipeline System, such activities being provided for in greater detail in Clause 6 below.
“Implementation Performance Bond” – The Performance Bond for the Section to be issued by the
Operator in favour of ISGS in terms of Clause 15.1.1 of the BOOT Contract, to secure the obligations
of the Operator during the Implementation Period in the form set out in Schedule 12 to this BOOT
Contract.
“Implementation Period” – The period beginning from the Effective Date of the BOOT Contract
and ending on the Commercial Operations Date, which shall be twenty-four (24) Months from the
Effective Date of the BOOT Contract or such extended duration as may be determined pursuant to the
terms of this BOOT Contract.
"Inspection Engineer" – The independent engineer appointed by the Operator in accordance with
Clause 5.5 for verification of the Pre-Commissioning Tests, Performance Tests and issuance of the
Certificate of Readiness for Pre- Commissioning, Certificate of Readiness for Commissioning and the
Certificate of Acceptance.
6
“Integrity Pact” – The Integrity Pact in the form set out in Schedule 5 to this BOOT Contract.
"Interface"– The Interface between the relevant parties as mentioned in the Custody Transfer and
Interface Agreement for the Section of the Project during the Implementation Period under this BOOT
Contract.
“Invoice Dispute” - The meaning ascribed thereto in Clause 20.2.1.
“Invoice Dispute Notice” - The meaning ascribed thereto in Clause 20.2.1.
"ISGS Consultant" – The consultant appointed by ISGS in order to provide the services set out in
Clause 5.7.
"ISGS Event of Default”" – The meaning ascribed thereto in Clause 17.1.2 (Termination for
Default).
“ISGS Margin” – The margin of ISGS comprising of the administrative and management charge of
ISGS for the purposes of facilitating and managing the Implementation and Operations of the Pipeline
System, as well as charges for provision of Permanent ROW.
“KIBOR” – The average Karachi Inter Bank Offered Rate, ask side, for the relevant tenor, as
published on Reuters page “KIBOR” or as published by the Financial Markets Association of
Pakistan in case the Reuters page is unavailable.
"Lapse of Consent" – Any Required Consent: (a) ceasing to remain in full force and effect and not
being renewed or replaced within the time period prescribed by the applicable Laws of Pakistan; or
(b) not being issued upon application having been properly and timely made and diligently pursued;
or (c) being made subject, upon renewal or otherwise, to any terms or conditions that materially and
adversely affect the Party’s ability to perform its obligations under any document included within the
Pipeline System Documents, in each of the above instances despite such Party’s compliance with the
applicable procedural and substantive requirements.
"Laws of Pakistan" – Federal, provincial and local laws of Pakistan, and all orders, rules, regulations,
statutory regulatory orders, executive orders, decrees, judicial decisions, notifications, or other similar
directives issued by any Public-Sector Entity pursuant thereto, including the Environmental
Standards, as any of them may be amended from time to time.
“LDs Cap” – An amount of 6.12(c).
"Lenders" – The Person or Persons, including any financial institutions issuing the Term Sheet and
providing financing to the Operator and party to the Financing Documents, or subsequent financial
institutions that become parties to the Financing Documents not objected to by ISGS in accordance
with the terms of this BOOT Contract or the BOOT Direct Agreement, together with their respective
successors and assigns, including any agent or trustee for such Person or Persons.
“Licenses” – The licenses required to be obtained under the applicable Laws of Pakistan, including
the OGRA Rules, in relation to the Implementation and Operations of the Pipeline System.
"Lien" – Any mortgage, pledge, lien, security interest, conditional and instalment sale agreement,
encumbrance, claim or charge of any kind.
"Line Fill" – The minimum volume of White Oil Product required to fill the pipeline, tank bottoms
and working stock in the Pipeline System for the purposes of conducting the Performance Tests and
throughout the period of Operations.
“Long Stop Date” – The date falling [one hundred and eighty (180)] Days from the Effective Date,
as may be extended in accordance with the provisions of Clause 3.7 below.
7
"Loss" – Any loss, damage, liability, payment or obligation (excluding any indirect or consequential
loss, damage, liability, payment or obligation), and all expenses (including, without limitation,
reasonable legal fees).
“Mechanical Completion” – The date on which all the components of the Pipeline System have been
installed in accordance with the Technical Requirements as per Schedule 15.
"Minimum Credit Rating" – Acceptable Long-Term Credit Rating or Acceptable Short-Term Credit
Rating, as the case may be.
"Month" – A calendar month according to the Gregorian calendar, beginning at 12:00 midnight on
the last day of the preceding month and ending at 12:00 midnight on the last day of that month.
"MMTPA"-Million Tonnes per Annum.
"MTPA"-Metric Tonnes per Annum.
"MS" – Motor Spirit.
“MUFAP” – Mutual Funds Association of Pakistan.
“New Scheduled Commercial Operations Date” – The meaning ascribed thereto in Clause
6.12(a)(ii).
“Notice” – Any notice, communication or other document to be given or made by one Party to the
other Party pursuant to this BOOT Contract.
"Notice of Intent to Terminate" – The meaning ascribed thereto in Clause 17.3.1 (Termination
Notices).
“Offtake Point” – Point at which the White Oil Products are delivered to the OMCs at the end of the
Section, as per Schedule 14.
"O&M Agreement" – The operation and maintenance agreement to be entered into between the
Operator and the O&M Contractor, where applicable, for the operation and maintenance of the
Pipeline System.
"O&M Contractor" – Any operation and maintenance contractor or contractors, and any successors
thereto, appointed by the Operator and not objected to by ISGS pursuant to Clause 7.2 (Operation and
Maintenance; Appointment of O&M Contractor).
“O&M Direct Agreement” – The agreement to be entered into between the Operator, ISGS, the
O&M Contractor and, where applicable, the Lender(s) in respect of the O&M Agreement.
"O&M Manual" – As provided for in Clause 8.1.1 below.
“OGRA” – The Oil and Gas Regulatory Authority established pursuant to the Oil and Gas Regulatory
Authority Ordinance, 2002 (Ordinance No. XVII of 2002).
“OGRA Rules” – The Pakistan Oil (Refining, Blending, Transportation, Storage and Marketing)
Rules, 2016, including any re-enactment thereof or any amendments thereto.
“OMC(s)”- oil marketing company(ies).
"Operations"– shall comprise of activities arising from the Commercial Operations Date (i) in
relation to transportation under and in terms of the Transportation Agreement; and (ii) in relation to
O&M activities under this BOOT Contract, in relation to the Pipeline System.
“Operations Performance Bond” – The Performance Bond for the Section to be issued by the
Operator in favour of ISGS in terms of Clause 15.1.2 of the BOOT Contract, to secure the obligations
8
of the Operator during the Operations Period as required under this BOOT Contract and the
Transportation Agreement, in the form set out in Schedule 13 to this BOOT Contract.
“Operations Period” - The period commencing on the Commercial Operations Date and ending on
the last Day of the Term.
"Operator Event of Default" – The meaning ascribed thereto in Clause 17.1.1 (Termination for
Default).
“Ordinary Share Capital” – Such shares comprising the issued share capital of the Operator which
carry voting rights, as per the Laws of Pakistan.
"Other Force Majeure Event" – The meaning ascribed thereto in Clause 16.1.1 (Definition of Force
Majeure).
"Pakistan" − The Islamic Republic of Pakistan.
"Pak Rupee" and "PKR" −The lawful currency of Pakistan.
“Payment Date” - The meaning ascribed thereto in Clause 20.1.2.
"Performance Bonds" – Collectively the Implementation Performance Bond and the Operations
Performance Bonds.
"Performance Tests" – The prescribed tests performed by the Operator under the BOOT Contract in
respect of the Section to establish readiness of the Pipeline System for Operations in accordance with
the Technical Requirements as per Schedule 15 and for the Section to meet the requirements of the
Design Capacity Schedule as set out in Schedule 2.
“Permanent ROW” – The meaning ascribed thereto in Clause 5.2.1.
"Person" – Any natural person, firm, company, corporation, society, government, state or agency of a
state (including any Public-Sector Entity), or any association or partnership (whether or not having
separate legal personality) of two or more of the foregoing.
"Pipeline Ancillary System" – Each of the computers, equipment, machinery, vehicles, spares,
infrastructure, installation, buildings, structures, power generating equipment, telecommunication
equipment together with tele-metering and tele-control facilities, civil works, and system necessary
for the efficient design, construction, operation, and maintenance of the Pipeline System in
accordance with Good Industry Practices.
"Pipeline System" -The pipeline and related facilities and infrastructure, including but not limited to,
storage tanks (operational, batch and transmix), pumps (mainline, booster and transfer), pigging
system, block valve stations, metering system, transmix processing facility, gantry, SCADA and
telecommunication and integrated control & safety system thereto as provided under this BOOT
Contract including all required facilities, equipment and installations, as well as the Pipeline Ancillary
System for the Section.
“Pipeline System Design and Specifications” – The Pipeline System Design and Specifications set
out in Schedule 1 hereto.
"Pipeline System Documents" – Each of the following agreements/ documents relating to the
Pipeline System:
(a) this BOOT Contract;
(b) the Transportation Agreement;
(c) the EPC Agreement;
9
(d) the O&M Agreement;
(e) the ROW Documents;
(f) the Financing Documents;
(g) the Direct Agreements;
(h) the Option Agreement;
(i) the Custody Transfer and Interface Agreement;
(j) the Performance Bonds;
(k) the SBLC; and
(l) the [insurances specified in Clause 12].
Provided that the documents forming the Pipeline System Documents are to be taken as mutually
explanatory of one another, but in case of ambiguities or discrepancies, specific provisions will
prevail over general provisions and the provisions of a document executed later in time will prevail
over provisions of a document executed earlier in time, unless otherwise provided in a Pipeline
System Document.
"Pre-Commissioned" – The successful completion of the Pre-Commissioning Tests as confirmed by
the Pre-Commissioning Report.
“Pre-Commissioning” – The undertaking of the Pre-Commissioning Tests once Mechanical
Completion of the Pipeline System has been achieved.
“Pre-Commissioning Test Report” – The meaning ascribed in Clause 6.10.1(c).
"Pre-Commissioning Tests" – The prescribed tests performed by the relevant EPC Contractor(s) and
the Operator under the relevant EPC Contract(s) for the Section at the time of Pre-Commissioning in
accordance with the Technical Requirements as per Schedule 15 and for the Section to meet the
requirements of the Design Capacity Schedule as set out in Schedule 2.
"Principal Documents" – Each of the following agreements/ documents relating to the Pipeline
System:
(a) this BOOT Contract; and
(b) the Transportation Agreement.
"Programme" – The meaning ascribed thereto in Clause 4.2 and as provided for in Schedule 4.
“Progress Report” – The meaning ascribed thereto in Clause 6.4.
"Project" – means the “Machike – Taru Jabba Oil Pipeline Project” extending over the Route, having
a Design Capacity to transport White Oil Products as per the Design Capacity Schedule and divided
into three (03) Sections, namely, Section-1, Section-2 and Section-3 comprising of the respective
Pipeline Systems.
"Project Documents" – The Pipeline System Documents for all the Sections of the Project.
"Proposed Material Amendment" – The meaning ascribed thereto in Clause 6.2.2.
"Public-Sector Entity" – (a) The GOP, the relevant Provincial Governments, any subdivision of
either, or any local governmental authority with jurisdiction over the Operator, the Project, or any part
thereof, or (b) any department, authority, instrumentality, agency, or judicial body of the GOP, the
Provincial Governments or any such local governmental authority, (c) courts and tribunals in
10
Pakistan, and (d) any commission or independent regulatory agency or body having jurisdiction over
the Operator, the Project or any part thereof.
“Repair Option” – The meaning ascribed thereto in Clause 6.11(b).
“Rejection Date” – The meaning ascribed thereto in Clause 6.11.3.
“Rejection Option” – The meaning ascribed thereto in Clause 6.11(c).
"Relevant Authority" – The department, authority, instrumentality, agency or other relevant entity
from which a Required Consent is to be obtained and any authority, body or other Person having
jurisdiction under the Laws of Pakistan with respect to the Project, this BOOT Contract and the other
Pipeline System Documents or any part thereof, as the case may be.
"Required Consents" – All such valid approvals, consents, authorisations, notifications, concessions,
acknowledgements, agreements, licences, permits, decisions or similar items which is or are required
by the Operator or its Contractors or Lenders for the purposes of the Pipeline System, or to fulfil their
obligations under the Pipeline System Documents.
“Route” – The meaning ascribed thereto in Clause 9 and as set out in Schedule 3 hereto.
"ROW " – Right of Way.
"ROW Documents" – The meaning ascribed thereto in Clause 5.2.1.
“Sanctions” – The meaning ascribed thereto in Clause 10.2.2.
"Section" – The Section of the Project being implemented under this BOOT Contract, namely
Section-3.
"Section-1" –The part of the Project extending from Machike (Sheikhupura) to Chakpirana (Gujrat).
"Section-2" – The part of the Project extending from Chakpirana (Gujrat) to Rawat (Rawalpindi).
"Section-3" – The part of the Project extending from Rawat (Rawalpindi) to Taru Jabba (Peshawar).
"Sections" –Section-1, Section-2 and Section-3 of the Project.
"Sales Tax" − Sales tax levied under the Sales Tax Act 1990, and applicable provincial sales tax on
services.
“SBLC” – The Standby Letter of Credit to be issued by a bank/ financial institution, on behalf of
ISGS in favour of the Operator in terms of Clause 5.2.3 of the BOOT Contract, to secure the
obligations of ISGS during the Operations Period under the Transportation Agreement, in the form set
out in Schedule 6 to this BOOT Contract.
"Scheduled Inspection Date" – As provided for in Clause 8.2.2.1.
“Scheduled Commercial Operations Date” – The date reasonably estimated by the Operator as the
Commercial Operations Date, as notified to ISGS, in terms of the Programme.
“Shareholder” – A shareholder of the Operator holding Ordinary Share Capital in the Operator.
“Sponsor(s)” - The shareholders of the Operator, namely [names to be inserted].
11
“Sponsor Undertakings”4 - Undertaking(s) from the Sponsor(s) , in the form attached hereto as
Schedule 16, in favour of ISGS that the Sponsor(s) will not during the Implementation Period and a
period of five (05) Years from the Commercial Operations Date initiate a change in ownership of the
Operator and will not divest more than forty-nine per cent (49%) of its total shareholding in the
Operator for the remainder of the Term.
“Tariff” – The composite tariff comprising of the Fixed Tariff and the Variable Tariff, as provided/ to
be provided for in the Transportation Agreement, shall be inclusive of all applicable Taxes but
exclusive of Sales Tax.
“Tariff Structure” – The Tariff plus the ISGS Margin.
"Tax" or "Taxes" – means all forms of taxation whether direct or indirect and whether levied by
reference to income, profits, gains, net wealth, excise, import, asset values, turnover, added value or
other reference and statutory, governmental, federal, state, provincial, local governmental or
municipal impositions, duties, contributions, rates and levies (including without limitation social
security contributions and any other payroll taxes), whenever and wherever imposed (whether
imposed by way of a withholding or deduction or otherwise) and in respect of any person as well as
all penalties, fines, charges, costs and interest relating thereto.
“Temporary ROW” – The meaning ascribed thereto is Clause 5.1.6.
"Term" – The period of seventeen (17) Years commencing from the Effective Date (as may be
extended in terms of the provisions of this BOOT Contract) and ending on the earlier of the Expiry
Date or Termination Date of this BOOT Contract.
"Termination Date" – The meaning ascribed thereto in Clause 17.4 (Termination Notices).
"Termination Notice" − A written notice of termination of this Agreement issued by ISGS or the
Operator, as the case may be, pursuant to Clause 17.4 (Termination Notices).
“Term Sheet” – The meaning ascribed thereto in Clause 3.1(b)(i) (Financial Closing).
“Testing” –. As provided for in Clause 6.
"Transfer Date" – The date when the Pipeline System is transferred by the Operator to ISGS upon
the earlier of the Expiry Date or the Termination Date.
"Transfer Conditions" – The meaning ascribed thereto in Clause 8.1.1 (Scope of Transfer).
"Transfer Examiner" – The engineer appointed by ISGS to inspect and examine the Pipeline System
in accordance with Clause 8.2.2 (Transfer).
"Transfer Inspection" – The meaning ascribed thereto in Clause 8.2.2.1.
"Transfer Kick-off Meeting" – The meaning ascribed thereto in Clause 8.2.4.
"Transfer Operator" – A Person designated by ISGS in accordance with Clause 8.1.1 to operate and
maintain the Pipeline System during the Transfer Period.
"Transfer Period" – The period beginning on the Transfer Period Commencement Date and
continuing through and including, and terminating on, the Expiry Date.
"Transfer Period Commencement Date" – The date which is three hundred and sixty (360) Days
before the Expiry Date for the Term.
4 The final form of the Sponsor Undertaking(s) is subject to the composition of the Selected Bidder/ SPV.
12
"Transfer Price" – Pak Rupees One only (PKR 1/-).
"Transfer Process" – The process for effecting the handover and transition of the Pipeline System to
ISGS (or a Transfer Operator), to be undertaken during the Transfer Period, in accordance with the
provisions of Clause 8.
"Transfer Requirements" – The meaning ascribed thereto in Clause 8.2.3.1.
"Transfer Transition Plan" – The meaning ascribed thereto in Clause 8.2.3.1.
"Transfer Warranty" – The Pipeline System will be transferred to ISGS or its nominee with a
warranty for the Design Life of the Pipeline System as provided in Clause 8.1.1.
"Transportation Agreement"– The Oil Transportation Agreement to be entered into between the
Operator and ISGS in connection with the Transportation of White Oil Products through the Pipeline
System.
“Transportation Agreement Direct Agreement” – The agreement between the Operator, ISGS and,
the Lender(s) relating to the rights of the Lenders under the Transportation Agreement.
“Transporter Event of Default”- As provided/ to be provided for in the Transportation Agreement.
“Variable Tariff” – The Variable Tariff, as provided/ to be provided for in the Transportation
Agreement.
"White Oil Product(s)" – HSD and MS, as per the White Oil Specifications provided for in Schedule
9 hereto.
"Year" – Each twelve (12) Month period commencing on 12:00 midnight on the 31st of December
and ending on 12:00 midnight the following 31st of December during the Term.
1.2 Rules of Interpretation
a) In this BOOT Contract, headings are only for convenience and shall be ignored in construing
this BOOT Contract and the singular includes the plural and vice versa;
b) References to Clauses, Sections and Schedules are, unless the context otherwise requires,
references to Clauses, Sections and Schedules to this BOOT Contract;
c) Except as expressly provided to the contrary herein, references to times and dates are, and
shall be construed to be, references to Pakistan standard time;
d) Except as expressly provided to the contrary herein, whenever a consent or approval is
required by one (1) Party from the other Party, such consent or approval shall not be
unreasonably withheld or delayed;
e) In carrying out its obligations and duties under this BOOT Contract, each Party shall have an
implied obligation of good faith;
f) A reference to any legislation or legislative provision includes any reference to statutory
modification or re-enactment of, amendment to or legislative provision substituted for, and
any subordinate legislation under, that legislation or legislative provision;
g) Reference to any document, instrument or agreement are references to that document,
instrument or agreement as amended, consolidated, supplemented, novated or replaced from
time to time; and
h) Except as expressly provided to the contrary herein, nothing herein shall be construed or
interpreted as limiting, diminishing or prejudicing in any way the rights of the Operator, to
claim any benefit provided under the Laws of Pakistan (whether in effect now or in the
future).
13
2. EFFECTIVE DATE, CONDITIONS SUBSEQUENT AND LONG STOP DATE
2.1 Effective Date and Long Stop Date
a) This BOOT Contract will become effective upon signing of both Parties (“Effective
Date”).
b) Simultaneously with the execution by the Parties of this BOOT Contract, the Operator
shall provide to ISGS the Implementation Performance Bond, the Sponsor Undertakings,
the Integrity Pact and all relevant incorporation documents relating to the Operator.
3. CONDITIONS SUBSEQUENT
3.1 Conditions Subsequent
The relevant Party shall ensure that the following conditions for which it is responsible
("Conditions Subsequent") have been satisfied on or before the Long Stop Date:
(a) Licencing and Tariff Notification
The procurement of the necessary Licenses from the Relevant Authorities, as well as the
notification of the Tariff Structure by OGRA, as required under the applicable Laws of
Pakistan.
(b) Term Sheet and Financing Documents
i. The delivery by the Operator to ISGS of a term sheet reflecting the proposed material terms
of the project financing, namely, the project cost, the financing amount, the tenor, the equity
commitments, the pricing, the financial charges payable to the financing parties and the
principal debt repayment schedule, as well as any step-in rights that may be required by the
relevant Lender (the “Term Sheet”). If ISGS has any reasonable objections to the Term
Sheet, it shall, within [●] ([●]) Days of receipt thereof, inform the Operator of its objections
in writing. In the event that ISGS does not raise any objection within the aforesaid [●] ([●])
Day period, ISGS shall be deemed to have no objection to the Term Sheet and the Operator
may proceed with the execution of the Financing Documents, at its own discretion.
ii. The achievement of Financial Closing by the Long Stop Date and delivery to ISGS of written
confirmation from the Lender(s) of the achievement of Financial Closing and the date on
which Financial Closing was achieved, which shall be the Financial Closing Date.
(c) Transportation Agreement
The execution of the Transportation Agreement by both Parties in accordance with the Laws
of Pakistan.
(d) Appointment of EPC Contractor
The appointment of the EPC Contractor and the notification by the Operator of the identity of
the EPC Contractor in accordance with the provisions of Clause 6.2.
(e) Execution of remaining Pipeline System Documents
The delivery by the Operator to ISGS of the following remaining Pipeline System Documents
duly executed by the parties thereto other than ISGS:
i. Direct Agreements (other than the BOOT Direct Agreement);
ii. Option Agreement; and
14
iii. Custody Transfer and Interface Agreement.
(f) Provision of the SBLC
ISGS shall provide the SBLC to the Operator in the form attached hereto as Schedule 6 in
accordance with the provisions of Clause 5.2.3.
(g) Required Consents
The procurement by the Operator of all Required Consents, including but not limited to the
consents and approvals mentioned in Schedule 10 hereto.
(h) Appointment of the O&M Contractor
The appointment of the O&M Contractor and the notification by the Operator of the identity of
the O&M Contractor in accordance with the provisions of Clause 7.2.
3.2 Waiver of Conditions Subsequent
The Conditions Subsequent in Clause 3.1 (a) – (e) and (g) – (h) are inserted for the benefit of
ISGS and may only be waived by ISGS. The Condition Subsequent in Clause 3.1 (f) is
inserted for the benefit of the Operator and may only be waived by the Operator.
3.3 Notice of Satisfaction/Waiver
Upon satisfaction or waiver of any of the Conditions Subsequent referred to above, the Party
for whose benefit such Condition Subsequent has been inserted shall promptly give notice to
the other Party, stating that the relevant Condition Subsequent have been satisfied or waived
(as applicable) and the date of such satisfaction or waiver (as applicable).
3.4 Long Stop Date
If any of the Conditions Subsequent set out in Clause 3.1 have not been satisfied, or waived in
accordance with Clause 3.2 by the Long Stop Date, this BOOT Contract may be terminated
by ISGS by issuing a Termination Notice in accordance with Clause 17.4.
3.5 Consequences of Termination
Except as set for the in Clause 21.9 or in relation to any other provision of this BOOT
Contract that is stated to survive termination, upon termination of this BOOT Contract under
Clause 3.4 above, the Parties shall be discharged from any further obligations or liabilities
under this BOOT Contract, without prejudice to any rights, obligations or liabilities that have
accrued up to the date of termination.
3.6 Obligation to Satisfy Conditions Subsequent
The Parties shall use its best endeavours to satisfy the Conditions Subsequent for which they
are responsible prior to the Long Stop Date.
3.7 Extension of Long Stop Date
If any of the Conditions Subsequent set out in Clause 3.1 have not been satisfied, or waived in
accordance with Clause 3.2 by the Long Stop Date, the Parties may by mutual consent agree
to extend the Long Stop Date, without prejudice to the Scheduled Commercial Operations
Date.
15
4. TERM AND COMPLETION
4.1 Term
This BOOT Contract shall become effective immediately upon the Effective Date, and shall,
unless terminated earlier in accordance with the terms of this BOOT Contract, continue in full
force and effect for the Term.
4.2 Programme and Scheduled Commercial Operations Date
(a) The Operator has prepared and submitted to ISGS a draft programme of work (covering all
the activities for the Implementation of the Pipeline System) setting out the sequence and the
dates by which the Operator intends to perform its obligations and achieve all relevant
milestones, which has been approved by ISGS and is attached as Schedule 4 (the
"Programme").
(b) The Programme, along with the Technical Requirements, shall govern the activities to be
performed by the Operator during the Implementation Period, including, but not limited to,
the following:
(i) the order in which the Operator shall carry out each activity, part and stage of the
Implementation of the Pipeline System, to meet the Technical Requirements as given
in Schedule 15;
(ii) timelines for the following:
A. execution of the Financing Documents (if not already signed);
B. execution of EPC Agreement (if not already signed);
C. execution of the O&M Agreement;
D. execution of each Direct Agreement;
E. execution of the Option Agreement (where applicable);
F. obtaining the Insurance Policies as per Clause 12;
G. obtaining the Required Consents, in accordance with Clause 5.1.7; and
H. based on the timelines for the above activities, the anticipated Financial Closing
Date, Construction Commencement Date, date for Mechanical Completion, date
for Pre-Commissioning, date for Commissioning and the Scheduled Commercial
Operations Date.
(iii) the estimated times when the Inspection Engineer, ISGS Consultant or ISGS's
Representative (as the case may be) will be required to provide approvals, consents
and issue certificates, in each case in accordance with this BOOT Contract.
(c) The Scheduled Commercial Operations Date shall be no later than twenty four (24) Months
from the Effective Date, unless extended in accordance with the terms of this BOOT
Contract.
(d) Without prejudice to the foregoing, efforts shall be made to synchronize the timelines for the
Programme in respect of all Sections of the Project in terms of and in accordance with the
provisions of this BOOT Contract as well as the Custody Transfer and Interface Agreement
16
and the Parties shall cooperate in good faith and utilise their best endeavours to make such
adjustments to the Programme as may be necessary in order to ensure synchronisation of the
Commissioning of all Sections of the Project.
4.3 Commercial Operations Date
(a) The Operator shall achieve the Commercial Operations Date no later than the Scheduled
Commercial Operations Date.
(b) The Scheduled Commercial Operations Date (as stated in the Programme), shall be extended
if there is a delay in the actions to be undertaken pursuant to the Programme as result of: (i)
ISGS’s failure to perform its obligations under the Pipeline System Documents including, but
not limited to, issuance of the SBLC, provision of the ROW Documents, signing of the Direct
Agreements and Option Agreement and issuance of certificates, approvals and consents in
accordance with the provisions of the relevant Pipeline System Documents; (ii) the
occurrence of a Force Majeure Event; or (iii) for any other reason expressly provided for in
this BOOT Contract.
(c) The Parties shall:
(i) utilize their best endeavours to meet the intermediate dates stated in the Programme;
and
(ii) provide evidence to the Inspection Engineer so that the Inspection Engineer may issue
the certificates contemplated in this BOOT Contract.
(d) Subject to successful completion of the Performance Tests, the Commercial Operations Date
shall be the Day, as stated in the Certificate of Acceptance issued by the Inspection Engineer.
5. IMPLEMENTATION OF THE PIPELINE SYSTEM
5.1 Responsibilities of the Operator
The Operator shall cause and be responsible for all activities that are required, directly and
indirectly, for the Implementation of the Pipeline System, Operations and maintenance of the
Pipeline System for the Term and transfer of the Pipeline System to ISGS or its nominee, as
per the terms of this BOOT Contract and in each case, in accordance with all applicable Laws
of Pakistan and the Pipeline System Documents, including but not limited to the following:
5.1.1. Construction and allied activities
The design, engineering, development, procurement, supply, erection, construction,
installation, completion, Testing, Commissioning, Performance Testing of the Pipeline
System, including but not limited to the following activities:
a) The completion of all engineering for the procurement, construction, completion and
operation of the Pipeline System;
b) The provision of management, co-ordination, engineering and supervision services for
of all aspects of the works relating to Implementation;
c) The performance of necessary site surveys and geo-hazard assessments and any other
engineering studies as required for the design and construction of the Pipeline System;
17
d) The preparation and issue of all necessary material take offs, bill of quantities, material
requisitions, material data sheets and other technical documents and evaluation for the
procurement of all necessary equipment including transport, handling and installation;
e) The procurement of all procurement items, including materials, equipment,
consumables, spare parts and any other items required for the construction and
completion of the Pipeline System;
f) The construction of the Pipeline System including but not limited to preparatory
works, clearing, grading, hauling and stringing, welding of pipes, backfilling,
construction of storage tanks and terminal piping, SCADA & Telecommunication
system, etc. in accordance with international and national codes and standards and as
required to ensure the integrity and functionality of the Pipeline System;
g) The completion of the Pipeline System, including pre-commissioning, Commissioning
and start-up and the performance of all tests on completion;
h) The clean-up of all sites and the ROW including the removal of all temporary
attachments, supports and the like as well as the removal of waste and debris and
restoration of all areas in accordance with the requirements and as requested by the
relevant Authorities, affected landowners and ISGS;
i) The provision of services and facilities to ISGS throughout the Implementation Period;
j) Operator’s engineering is subject to review and approval by ISGS and the Operator
shall co-ordinate the review of engineering documents prepared by the Operator with
ISGS, pursuant to which the Operator shall incorporate all relevant comments of ISGS
prior to the re-submission of the relevant documents;
k) To carry out surveillance of the Section of the Pipeline System and ensure its security
and worksite security shall be the sole responsibility of the Operator;
l) To provide all health and safety and environmental protection requirements and any
temporary equipment, fixtures and facilities as required for the execution of the works;
m) The coordination of all internal interface matters with other BOOT operators for the
Project and all external interface matters with external third parties, such as OMCs, in
relation to the Project;
n) Recognise all interface matters resulting from, or otherwise connected with, Project
interfaces and Connected Systems and prepare and issue all engineering documents
including for tie-ins and isolation points and the like;
o) Carrying out the Environmental Impact Assessment study(ies) as per the requirements
of the Relevant Authorities; and
p) The compilation, production and provision of all As-Built documentation of the
Pipeline System.
5.1.2. Financing
Arranging financing for the Implementation of the Pipeline System, notwithstanding any right
of ISGS to review the Term Sheet or otherwise.
18
5.1.3. Operation & Maintenance
Operations and maintenance of the Pipeline System including the operation and maintenance
of all construction sites and all construction equipment, including all health and safety and
environmental protection requirements.
5.1.4. Services and facilities
The provision of such services and facilities as ISGS may reasonably request throughout the
Implementation and Operations period.
5.1.5. Transfer of the Pipeline System
The Transfer of the Pipeline System to ISGS or its nominee at the end of the Term in
accordance with Clause 8.
5.1.6. Temporary ROW
Acquiring such ownership or usage rights of land as are necessary or sufficient to obtain land
for handling and movement of the construction equipment, stringing & welding of pipes,
temporary stores & offices etc. necessary access for the Implementation of the Pipeline
System, including access roads, [●] and [●], other than the Permanent ROW in relation to the
Route (“Temporary ROW”). The Operator shall, whenever required, facilitate ISGS and
provide such information as ISGS may request, from time to time, in order to secure or, where
necessary, modify the Permanent ROW. All costs incurred in relation to the Temporary ROW
shall be borne by the Operator.
5.1.7. Required Consents
Applying for and obtaining all Required Consents and maintaining the same for the Term and
liaise with all third parties and obtain all permits, licenses and approvals required from all
Authorities of Pakistan for the Implementation and the operation of the Pipeline System in
terms required under this BOOT Contract.
5.1.8. Upgrade of the Pipeline System
The Operator may upgrade the Pipeline System in accordance with the frequency and
requirements of the Design Capacity Schedule, in order to fulfill the requirements of the
Design Capacity of the Section for the given period. For the purposes of any upgrade, the
Operator shall be required to submit an upgrade programme to ISGS setting out the tasks and
timelines relating to the upgrade, including but not limited to all activities related to
engineering, procurement, construction, implementation, Mechanical Completion, Pre-
Commissioning, Testing and Commissioning, in the manner set out in Clause 6, which shall
be subject to the prior approval of ISGS. The Operator may hire a Contractor for the
purposes carrying out the upgrade of the Pipeline System, such Contractor being acceptable to
ISGS.
5.2 Responsibilities of ISGS
ISGS shall be responsible for the following activities in relation to the Implementation of the
Pipeline System in accordance with all applicable Laws of Pakistan and the Pipeline System
Documents:
19
5.2.1. Permanent ROW
Procuring all necessary land use and/or ownership rights in relation to the Route
(“Permanent ROW”) in accordance with the Programme and the requirements of the
Operator. The procurement of the Permanent ROW shall commence from the date agreed to
between the Parties in terms of the Programme and shall continue, as required, up to the stage
of Mechanical Completion. ISGS shall be responsible for all payments to be made in
connection with the procurement of the Permanent ROW in its own name along the Route in
accordance with the Laws of Pakistan. Upon acquiring the Permanent ROW in its own name,
ISGS shall grant the Operator a right to use the Permanent ROW in terms of the ROW
documents (“ROW Documents”) in respect of the Permanent ROW or each part thereof.
5.2.2. Facilitation in Relation to Required Consents
Where possible, facilitating the Operator in obtaining the issuance and renewal of the
Required Consents, provided the Operator shall make proper, timely and complete
applications for the Required Consents (and any renewal thereof) throughout the Term.
5.2.3. SBLC
Delivering the SBLC to the Operator by the Long Stop Date.
5.3 Authorised Representatives
In order to facilitate the efficient and timely implementation and progress of the Pipeline
System, and in order to ensure efficient communication between the Parties, each of the
Parties shall designate representative(s) to act as its contact liaison and coordinator to
progress the Project (each called a "Representative" and collectively the "Representatives").
Each Party shall notify the other Party in writing of the appointment of a Representative and
provide details including the name, designation and CNIC/passport number of each
Representative. The Representatives shall act as the principal contacts between the Parties and
shall use their best endeavours to resolve all issues which arise in respect of the
administration or performance of this BOOT Contract. Each Party shall notify the other Party
in writing of its decision to replace its Representative.
5.4 Operator’s Project Manager
On or before the Effective Date, the Operator shall, for a period of at least [five (5)] Years
from the Effective Date or until the [third (3rd)] anniversary of the Commercial Operations
Date (whichever period is longer), employ a senior manager for the Implementation and
Operations of the Pipeline System, who shall be entrusted by the Operator to inter alia
manage and execute the Implementation of the Pipeline System so that to ensure that all
milestones set out in the Programme (or otherwise agreed between the Parties) are
delivered in such a manner and within such time periods as prescribed by the Programme and
the BOOT Contract.
5.5 Appointment of Inspection Engineer
5.5.1. Not later than [●] Days after the Effective Date, the Operator shall appoint an Inspection
Engineer in consultation with, and subject to the approval of ISGS, (and shall by such date be
available to perform the duties of the Inspection Engineer provided herein and shall thereafter
remain appointed and available for as long as may be necessary to discharge the duties of the
Inspection Engineer under this BOOT Contract) to carry out the duties of the Inspection
Engineer specified in this BOOT Contract in accordance with the highest professional
standards and duty of care, both to the Operator and to ISGS. The Operator shall not replace
any Person appointed as the Inspection Engineer without the prior written consent of ISGS.
20
5.5.2. The terms and conditions of appointment of the Inspection Engineer shall oblige the
Inspection Engineer to act independently and impartially, on the basis of his expertise,
experience and knowledge in relation to all matters referred to him pursuant to this BOOT
Contract and in carrying out all other duties ascribed to him under this BOOT Contract. The
costs and remuneration to which the Inspection Engineer is entitled under his terms and
conditions of appointment shall be borne by the Operator. The terms of the appointment of
the Inspection Engineer shall clearly define the relationship of the Inspection Engineer to the
Operator as that of an independent contractor and not as an employee of the Operator.
5.6 Applications by the Operator for Required Consents
The Operator shall make or cause to be made, in a timely fashion, all applications (whether
initial or renewal applications) for the Required Consents to the appropriate Relevant
Authority and shall diligently pursue all such applications. The information supplied in the
applications shall be complete and accurate and shall satisfy the substantive and procedural
requirements of the applicable Laws of Pakistan.
5.7 Role of the ISGS Consultant
The ISGS Consultant, as appointed by ISGS, shall on behalf of ISGS, review, approve,
inspect (as the case may be) all detail design parameters, construction works, operation and
maintenance plans and procedures and activities performed or carried out by the Operator
throughout the Implementation Period of the BOOT Contract and verify that the same are in
accordance with the BOOT Contract including but not limited to, relevant standards,
Technical Requirements/specifications and the provisions of the Transportation Agreement,
as applicable, and in accordance with the provisions of Schedule 15 (Technical
Requirements).
6. CONSTRUCTION, TESTING AND COMMISSIONING OF THE PIPELINE
SYSTEM
6.1 Technical Requirements
6.1.1. The Operator shall develop, engineer, design, procure, supply, erect, construct, install,
conduct Testing and Commission the Pipeline System in all material respects in accordance
with the technical specifications relating to the Pipeline System set forth in Schedule 15 (the
"Technical Requirements").
6.1.2. Subject to Clause 5.2 (Responsibilities of ISGS) of this BOOT Contract, the Operator shall
work to advance the Implementation of the Pipeline System and to construct and Commission
the Pipeline System, and do all other things necessary so as to meet the Scheduled
Commercial Operations Date.
6.1.3. The Operator shall keep ISGS apprised of the progress of the Implementation of the Pipeline
System and shall notify ISGS of any material deviations or anticipated material deviations
from the Scheduled Commercial Operations Date, promptly upon becoming aware of any
such deviation or anticipated deviation. The aforementioned notice shall identify:
6.1.3.1. the nature of the deviation;
6.1.3.2. the reason for the deviation;
6.1.3.3. the impact which such deviation has had, or in the reasonable opinion of the
Operator, is likely to have or will have, on its ability to achieve the Scheduled
Commercial Operations Date; and
21
6.1.3.4. the steps which the Operator has taken, is taking, and will take, to mitigate the
adverse consequences of such failure.
A deviation pursuant to the aforesaid provision shall become effective and enforceable only
upon receipt of prior consent of ISGS.
6.2 Appointment of EPC Contract; Amendments to EPC Contract
6.2.1 Prior to the date of execution of the EPC Contract, the Operator shall provide ISGS with a
certificate of a duly authorized officer of the Operator setting out name and nationality of the
EPC Contractor, no later than [thirty (30)] Days prior to the execution of any proposed EPC
Contract. ISGS shall then have the right, but not the obligation, to review the certificate, and
may notify the Operator prior to the proposed execution date that it objects to the proposed
EPC Contract because, in its sole discretion, the proposed EPC Contractor or its nationality is
adverse to the national security interests of Pakistan; provided, however, that, by not objecting
to the EPC Contract, ISGS shall not be construed as having approved of the EPC Contract nor
as in any way of having relieved the Operator of its obligations to complete Implementation
of the Pipeline System under this BOOT Contract.
6.2.2 The Operator shall provide ISGS with a certificate of a duly authorized officer of the Operator
setting out any proposed amendment (a “Proposed Material Amendment”) to the EPC
Contract that would result in (i) a change in the EPC Contractor, or (ii) a change in a major
piece of equipment as to either its company or country of manufacture, no later than [twenty-
one (21)] Days prior to execution thereof, setting forth the proposed changes. If ISGS does
not object to such certificate on or before the end of the [twenty-one (21)] Days period
provided for herein, as the case may be, ISGS shall be deemed not to have objected to the
Proposed Material Amendment.
6.3 Review of Agreements with Contractors
Prior to entering into any agreements with Contractors in relation to the Implementation of
the Pipeline System, the Operator shall submit to ISGS final drafts of the same (redacted to
remove pricing information) so as to permit ISGS with sufficient allowance of time, to
determine whether the Operator has secured to itself the means to provide and perform its
obligations under the BOOT Contract. ISGS shall perform such review promptly and without
undue delay. Notwithstanding anything to the contrary in this BOOT Contract, neither the
exercise nor the non-exercise (nor anything done or not done in the exercise or non-exercise)
by ISGS of any right to review the Operator’s agreements with Contractors shall (i) create or
impose any obligation or liability whatsoever on ISGS with respect to such agreements, (ii) in
any way affect or alter the Operator's obligations or liabilities under this BOOT Contract or
(iii) in any way affect or alter the obligations or liabilities of the Operator or the Contractors
under the relevant agreements.
6.4 Progress Reports
Throughout the Implementation Period, the Operator shall provide ISGS with a [Monthly]
report (each a "Progress Report") advising on the status of the development of each
component of the Pipeline System, including, where applicable, the Operator's estimate of the
period of any delay in delivery and acceptance of the relevant component relative to the
agreed timetable for commissioning under the Programme and any other material
developments relating to the construction of the relevant component. The first Progress
Report shall be provided by the Operator no later than the date which is [●] after the Effective
Date. The Operator shall also be responsible to provide any information that ISGS might need
in relation to the Pipeline System from time to time, within a reasonable period of time,
giving due consideration to the urgencies/ exigencies of the matter.
22
6.5 Monitoring of Pipeline System Construction
6.5.1. As and when requested in writing by ISGS, the Operator shall meet with ISGS’s
representatives at the facilities of the Operator (or such other place mutually acceptable to the
Parties) for the purpose of evaluating the progress of the construction of the Pipeline System.
Where applicable, the Operator shall procure that the Contractor shall permit a reasonable
number of ISGS’s Representatives (as determined by ISGS) to be present at the relevant
location for such purposes; provided that any such meetings shall occur during ordinary
working hours and shall not unduly obstruct the normal or orderly construction of the Pipeline
System or any part thereof.
6.5.2. Notwithstanding anything to the contrary in this BOOT Contract, neither the exercise nor the
non-exercise (nor anything done or not done in the exercise or non-exercise) by ISGS of any
right to monitor the construction of the Pipeline System or any component thereof, or any
right of inspection or attendance or otherwise (including the receipt and review of any plans,
drawings or instruction manuals relating to the Pipeline System or any component thereof) in
relation thereto shall (i) create or impose any obligation or liability whatsoever on ISGS with
respect to the construction of the Pipeline System or any such component, or (ii) in any way
affect or alter the Operator's obligations or liabilities under this BOOT Contract.
6.6 Notice of Tests and Trials; Reports
The Operator shall promptly notify ISGS of all tests and trials (including the relevant Pre-
Commissioning Tests and Performance Tests) of each component of the Pipeline System, its
equipment and parts and procure that the relevant Contractor permits ISGS and ISGS’s
representatives, at the cost and expense of Operator, to attend such tests and trials. The
Operator shall provide ISGS with copies of all reports it receives from each Contractor and its
sub-contractors in respect of such tests and trials.
6.7 Restriction on Usage
Other than in connection with the tests and trials or Operations or as otherwise permitted
under the Principal Documents, the Operator shall not, unless otherwise directed by ISGS,
direct or permit the Pipeline System to be used for any purpose until the Commercial
Operations Date or, if the Pipeline System is not accepted by ISGS, the date this BOOT
Contract terminates.
6.8 Additional Changes
The Operator shall approve and shall use all reasonable endeavors to procure that the relevant
Contractor undertakes to change or modify the construction or modification of any
component of the Pipeline System as may be approved in writing by ISGS; provided that any
such changes are compatible with the Pipeline System Design and Specifications and will not,
in the Operator's reasonable opinion, if made, cause it to be in breach of any of the
representations and warranties or obligations relating to the Pipeline System contained in this
BOOT Contract. All cost impacts incurred by the Operator and previously agreed to by ISGS
with respect to such changes shall be proportionately reflected by an adjustment in the Tariff,
as permitted by the Laws of Pakistan. In the event that such changes cause delay in the
construction of the relevant component of the Pipeline System, the Scheduled Commercial
Operations Date shall be extended by the period of delay directly resulting from such changes
and ISGS shall reimburse the Operator for any reasonable documented costs directly
attributable to such delay that were economically and efficiently incurred by the Operator.
23
6.9 Operator's Responsibility
Except as expressly provided otherwise in this BOOT Contract, the exercise by ISGS of any
rights it may have under this BOOT Contract in relation to the Pipeline System shall not
affect or alter (a) the responsibility of the Operator to deliver and operate the Pipeline System
in accordance with this BOOT Contract or (b) any other rights ISGS may have hereunder or
thereunder.
6.10 Testing and Commissioning
6.10.1. Pre-Commissioning Tests
(a) Once Mechanical Completion has been achieved and the Operator and the relevant
Contractor(s) are satisfied that the Pipeline System is in a fit state to conduct the Pre-
Commissioning Tests, the Operator shall request the Inspection Engineer to issue the
Certificate of Readiness for Pre-Commissioning.
(b) Within [●] Days of issuance of the Certificate of Readiness for Pre-Commissioning, the
Operator shall provide notification to ISGS, the ISGS Consultant and the Inspection Engineer
of its programme for carrying out the Pre-Commissioning Tests. ISGS shall, within [●] Days
of receipt of programme for the Pre-Commissioning Tests, confirm its own and the ISGS
Consultant’s attendance, or, alternatively, request an alternative date which shall be not more
than [●] Days after the date proposed by the Operator, provided that for each Day the Pre-
Commissioning Tests are delayed pursuant to ISGS’s request, the Scheduled Commercial
Operations Date shall be commensurately extended.
(c) Following the completion of the Pre-Commissioning Tests, if the Operator, the relevant
Contractor(s), the ISGS Consultant and the Inspection Engineer consider that the Pipeline
System has passed the Pre-Commissioning Tests, the Inspection Engineer shall issue a report
certifying that the Pre-Commissioning Tests have been passed ("Pre-Commissioning Test
Report") substantially in the form of Schedule 7 (Form of Pre-Commissioning Test Report)
for the Pipeline System stating that the Pipeline System has passed the Pre-Commissioning
Tests. The Pre-Commissioning Test Report shall be verified and, if appropriate, endorsed by
the ISGS Consultant. In the event of a dispute between the Independent Engineer and the
ISGS Consultant in relation to the results of the Pre-Commissioning Tests, such dispute will
be referred for resolution to an Expert in accordance with the provisions of Clause 18.2.
6.10.2. Performance Tests and Acceptance
(a) Once the Operator is satisfied that the Pipeline System is in fit state to conduct the
Performance Tests, it shall request the Inspection Engineer to issue the Certificate of
Readiness for Commissioning.
(b) Within [●] Days of issuance of the Certificate of Readiness for Commissioning, the Operator
shall provide notification to ISGS and the Inspection Engineer of its programme for carrying
out the Acceptance Test. ISGS shall, within [●] Days of receipt of programme for the
Acceptance Test, confirm its own and the ISGS Consultant’s attendance and the availability
of Line Fill for the Section at the Entry Point, or alternatively request an alternative date
which shall be not more than [●] Days after the date proposed by the Operator, provided that
for each Day the Acceptance Tests are delayed pursuant to ISGS’s request (“Testing Delay
Period”), the Scheduled Commercial Operations Date shall be extended for a period equal to
the Testing Delay Period (in addition to any period of delay under Clause 6.10.1 (b)),
provided the Certificate of Readiness for Commissioning has been issued. The Line Fill of the
Pipeline System shall be supplied by ISGS to the Operator, however, in the event that there is
24
any spillage or wastage of Line Fill by the Operator, any associated costs including
replacement or top up of Line Fill shall be borne by the Operator.
(c) Following the completion of the Performance Tests, if the Operator and the Inspection
Engineer consider that the Pipeline System has passed the Performance Tests, the Inspection
Engineer shall issue an acceptance certificate report ("Certificate of Acceptance")
substantially in the form of Schedule 8 (Form of Acceptance Certificate Report) for the
Pipeline System certifying that the Pipeline System has passed the Performance Tests and
providing therein the Commercial Operations Date. The Certificate of Acceptance shall be
verified and, if appropriate, endorsed by the ISGS Consultant. In the event of a dispute
between the Inspection Engineer and the ISGS Consultant in relation to the results of the
Performance Tests, such dispute will be referred for resolution to an Expert in accordance
with the provisions of Clause 18.2.
6.10.3. Interface Issues
Interface issues relating to Testing, Commissioning and achieving the Commercial Operations
Date in respect of the Pipeline System will be governed by the applicable provisions of the
Custody Transfer and Interface Agreement, as well as the Project Documents, which shall be
read in conjunction with this BOOT Contract and the Operator undertakes to take into
account all Interface issues during the Implementation Period under this BOOT Contract.
6.11 Failure to Pass Performance Tests
(a) Where the Performance Tests are completed but the Pipeline System does not meet
all of the required performance levels in accordance with the Technical
Requirements or where any of the Performance Tests are not completed within [●]
Days of the commencement of the Performance Tests (in each case, other than at the
request of ISGS or due to the occurrence of a Force Majeure Event), ISGS may elect
to either: subject to Clause 6.12, accept the Pipeline System ("Acceptance Option");
(b) require the Operator to make the necessary repairs or modifications to the Pipeline
System in order to meet the Technical Requirements ("Repair Option"); or
(c) reject the Pipeline System ("Rejection Option").
6.11.1 Acceptance Option
(a) Where ISGS elects to exercise the Acceptance Option, then ISGS shall accept the Pipeline
System as being Commissioned under the BOOT Contract and the Parties shall cause the
Certificate of Acceptance to be executed and delivered in accordance with Clause 6.10.2,
provided that the Tariff under the Transportation Agreement shall be subject to reductions in
accordance with Clause 6.11.1(b) below.
(b) Where ISGS elects to exercise the Acceptance Option in circumstances where the Pipeline
System does not meet the applicable Design Capacity but where the proven capacity of the
Pipeline System is greater than or equal to ninety per cent (90%) of the applicable Design
Capacity, then the Adjusted Annual Reserved Capacity as provided/ to be provided for under
the Transportation Agreement shall be reduced in accordance with the formula below:
25
T= R/A
Where:
T = Adjusted Annual Reserved Capacity
A = Annual Reserved Capacity of the Agreement Year
R = Actual Capacity for the Agreement Year
For the avoidance of doubt, such reduction in the Adjusted Annual Reserved Capacity shall
be in addition to the deductions provided/ to be provided for in Clause 7.5 of the
Transportation Agreement.
Where this Clause 6.11.1 applies, the Operator shall have the right (from time to time during
the Term) upon giving not less than seven (7) Days' notice to demonstrate to ISGS that the
Pipeline System is capable of meeting the required Design Capacity and, if required by ISGS,
the Performance Tests shall be re- performed to confirm the capability of the Pipeline System.
Where the Pipeline System satisfies the Performance Tests, the original Fixed Tariff under the
Transportation Agreement shall apply from the date the Pipeline System passes such
Performance Test.
6.11.2 Repair Option
Where ISGS elects to exercise the Repair Option, then ISGS shall promptly notify the
Operator of its decision and the Operator shall repair or modify (or shall procure the repair
and modification of) the Pipeline System in order to meet the Technical Requirements. When
such repairs or modifications are completed, the Operator shall notify ISGS in writing and the
Parties shall select a mutually acceptable date as soon as practicable thereafter on which the
Operator shall re-tender the Pipeline System for purposes of re-performing the Performance
Tests, which shall be performed as soon as practicable after the retendering. If the Pipeline
System meets the Technical Requirements, ISGS shall accept the Pipeline System as being
Commissioned and the Parties shall cause the Certificate of Acceptance to be executed and
delivered in accordance with Clause 6.10.2. If the Pipeline System does not meet the
Technical Requirements following completion of the relevant repairs or modifications, then
ISGS may again elect to exercise any of the Rejection Option, Acceptance Option or Repair
Option and the same procedures set forth in Clause 6.11 shall apply.
6.11.3 Rejection Option
Where ISGS rejects the Pipeline System the date of rejection being the "Rejection Date"),
then:
(a) no Tariff or other fees shall be payable by ISGS to the Operator under the Transportation
Agreement or this BOOT Contract;
(b) the Operator shall pay to ISGS liquidated damages in an amount not exceeding the LDs
Cap;
(c) the Operator shall promptly notify ISGS in writing of the amount of White Oil Product
remaining within the Pipeline System, if any, on the Rejection Date (the "Remaining
Product"). So long as the Pipeline System is then capable of doing so and without
breaching any applicable Law of Pakistan, ISGS shall have the right to have the Remaining
Product delivered to it at the Exit Point and/or Offtake Point and to recover reasonable
costs, if any, in doing so from the Operator; and
26
(d) ISGS’s rejection of the Pipeline System shall entitle it to terminate this BOOT Contract but
this shall not in any manner adversely affect ISGS’s rights under this BOOT Contract, but
for the avoidance of doubt ISGS’s sole right of recourse against the Operator as a
consequence of the termination of this BOOT Contract under this Clause 6.11.3 (other than
termination resulting from gross negligence or wilful misconduct by the Operator) shall be
to recover the liquidated damages referred to in Clause 6.11.3(b) and costs referred to in
Clause 6.11.3(c).
6.12 Delays in Implementation
(a) In the event that the Pipeline System does not successfully pass the Performance Tests within
a period of [●] Days from the Scheduled Commercial Operations Date (“Cancelling Date”),
then ISGS shall have the right within a further [●] Days of the Cancelling Date to:
(i) terminate this BOOT Contract by serving a Notice of Intent to Terminate in
accordance with the provisions of Clause 17.3.1 ; or
(ii) allow the Operator additional time for the Implementation of the Pipeline System and
agree in writing to a new date by which the Pipeline System shall be Commissioned
(“New Scheduled Commercial Operations Date”).
(b) If ISGS elects to terminate the BOOT Contract in accordance with Clause 6.12 (a) (i), then
such termination shall be treated as a termination triggered by an Operator Event of Default
and shall entitle ISGS to receive compensation from the Operator in an amount not exceeding
the LDs Cap.
(c) If ISGS elects to allow the Operator additional time for the Implementation of the Pipeline
System, then, in consideration of ISGS agreeing to a New Scheduled Commercial Operations
Date, the Operator shall pay to ISGS an amount calculated at the rate of [1.25 multiplied by
the Fixed Tariff] per Day for each Day commencing from the Day immediately after the
original Scheduled Commercial Operations Date until the Commercial Operations Date
(“LDs Cap”). Provided that, in the event that the Pipeline System is not Commissioned on or
before the New Scheduled Commercial Operations Date, then ISGS may exercise either of
the options available to it under Clause 6.11 above within [●] Days of the New Scheduled
Commercial Operations Date.
(d) Any amounts payable under Clause 6.11 shall be invoiced and paid in accordance with the
provisions of Clause 20.
7. OPERATION AND MAINTENANCE OF PIPELINE FACILITY
7.1 Operation and Maintenance of the Pipeline System
The Operator shall operate and maintain the Pipeline System in accordance with the
provisions of the Pipeline System Documents. Subject to Clause 7.2, the Operator may
contract with the O&M Contractor to operate and maintain the Pipeline System; provided that
the appointment of the O&M Contractor by the Operator shall not relieve the Operator of any
of its obligations or potential liability regarding the Operations or maintenance of the Pipeline
System under the Principal Documents. The Operator shall, in cooperation with ISGS,
establish and issue to ISGS an operating manual, setting out detailed technical requirements
and operating procedures (consistent with Good Industry Practices, applicable standards and
Laws relating to the use of the Pipeline System by ISGS and such other matters as are
contemplated in this BOOT Contract (“O&M Manual”) before the Commercial Operations
Date.
27
7.2 O&M Agreement; O&M Contractor
No later than thirty (30) Days prior to execution of the O&M Agreement, the Operator shall
deliver to ISGS a certificate of a duly authorized officer of the Operator, describing any
proposed O&M Agreement and setting out the name and nationality of the O&M Contractor
and any major subcontractor. ISGS shall then have the right, but not the obligation, to review
the certificate, and may notify the Operator prior to the proposed execution date that it objects
to the O&M Contractor because, in its sole discretion, the appointment of the proposed O&M
Contractor would be adverse to the national security interests of Pakistan; provided, however,
that by not objecting to the O&M Agreement, ISGS shall not be construed as having
approved of the O&M Agreement nor as in any way having relieved the Operator of its
obligations to undertake the operations and maintenance of the Pipeline System in terms of
the Pipeline System Documents. If ISGS does not object to the certificate on or before the end
of the thirty (30) Days provided for herein, ISGS shall be deemed not to object to the O&M
Agreement.
7.3 Operation of the Pipeline System by the Operator
(a) In order to ensure smooth operation of the Pipeline System as provided/ to be provided for
under the Transportation Agreement, (i) the Operator agrees that it shall notify ISGS of the
first maintenance programme of annual planned works to be undertaken by the Operator in
respect of the Pipeline System [•] Days prior to the Commercial Operations Date and which
planned works shall not exceed a maximum of eleven (11) days for the respective annual
maintenance programme; and (ii) ISGS agrees to notify the Operator of the first annual
nomination estimate [eighty (80)] Days before the Commercial Operations Date of the
requirements for transportation and delivery of the Product to the Off Take Point and the Exit
Point, for each Month in the following Year.
(b) Notwithstanding anything contained above, the Operator shall be entitled to engage its own
personnel and operate the Pipeline System or, if the O&M Agreement has been terminated,
engage some or all of the personnel of the former O&M Contractor and operate the Pipeline
System, in either case with prior notice to ISGS.
8. TRANSFER
8.1 Scope of Transfer
8.1.1. Pipeline System
On the Transfer Date, the Operator shall deliver and transfer title of the Pipeline System, to
ISGS or its nominee (“Transfer Operator”) (through an asset transfer agreement), with the
“Transfer Warranty” such that, at the time of such transfer and as at the Expiry Date, the
Pipeline System shall be in a condition to permit such Pipeline System to operate for the
remainder of the Design Life, excluding normal wear and provided that all procedures as per
the O&M Manual are adhered to in the operations and maintenance of the Pipeline System
("Transfer Conditions"). Additional equipment acquired by the Operator from time to time
over the Term in respect of the Pipeline System shall be included and transferred to ISGS or
its nominee within the Transfer Price.
8.1.2. Training
Six (6) Months prior to the Expiry Date, or immediately upon but no later than fourteen (14)
Days from the date of issuance of the Notice of Intent to Terminate, the Operator shall at its
own cost arrange and implement training to be provided for the designated personnel of ISGS
28
or the Transfer Operator to ensure smooth handing over and transfer of the Pipeline System
on the Transfer Date.
8.1.3. Books and Records (financial and operational)
Sixty (60) Days prior to the Expiry Date or immediately upon but no later than seven (7) Days
from the date of issuance of the Notice of Intent to Terminate, the Operator shall provide to
ISGS all material information that is reasonably necessary to ensure efficient operation of the
Pipeline System and relating generally to the Pipeline System (including, but not limited to,
lists of assets, inventory records, lists of capital spares, financial and operational books and
records).
8.1.4. Know-How Transfers
Subject to the rights of any third party and proprietary rights permitted under this BOOT
Contract, the Operator shall transfer to ISGS rights to use all such Pipeline System related
intellectual property and all technical documents, including functional specifications,
operational procedures, and business processes charts, necessary in the opinion of the
Operator to support continued operation of the Pipeline System.
8.2 Transfer Upon Expiry
8.2.1. General Transfer Provisions
8.2.1.1. At the end of the Term, the Operator (or any assignee or nominee or transferee who
has assumed or otherwise acquired the rights, title and interests of the Operator in the
Project) shall transfer the Pipeline System to ISGS or its nominee (complete lock,
stock and barrel) in consideration of the Transfer Price in accordance with the transfer
provisions in this Clause 8.
8.2.1.2. The Operator shall coordinate with ISGS to effect, upon the Expiry Date, a transfer
and handover of the Pipeline System (through an asset transfer agreement) to ISGS
or, if directed by ISGS (in its reasonable discretion), to a Transfer Operator, in
accordance with the requirements of this Clause 8, including without limitation the
applicable Transfer Conditions and the Transfer Requirements with respect to the
Pipeline System.
8.2.2. Within thirty (30) Days after the occurrence of the Transfer Period Commencement Date, the
“Transfer Examiner” shall be appointed to inspect and examine the Pipeline System with
the highest professional standards and duty of care, both to the Operator and to ISGS. The
terms and conditions of appointment of the Transfer Examiner shall oblige the Transfer
Examiner to act independently and impartially, on the basis of his expertise, experience and
knowledge in relation to all matters referred to him pursuant to this BOOT Contract and in
carrying out his other duties ascribed to him under this BOOT Contract. The costs and
remuneration to which the Transfer Examiner is entitled under his terms and conditions of
appointment shall be borne by ISGS or its nominee.
8.2.2.1 Within [fifty (50)] Days after the occurrence of the Transfer Period Commencement
Date, the Operator agrees to perform a major inspection, along with the Transfer
Examiner and the representative of ISGS or its nominee of the Pipeline System in
order to determine the condition of the Pipeline System ("Transfer Inspection").
The Operator shall notify ISGS and the Transfer Examiner of its intention to carry out
the Inspection at least [thirty (30)] Days prior to the intended date therefor. The
Operator will thereafter notify ISGS of the Day(s) of the Transfer Inspection (the
"Scheduled Inspection Date"). If a representative of ISGS or the Transfer Examiner
cannot attend the Scheduled Inspection Date then the Parties and the Transfer
Examiner shall mutually agree such a reasonable day, which shall not be later than
29
fourteen (14) Days after the originally notified Scheduled Inspection Date. The
Transfer Examiner together with the representatives of the Operator and ISGS shall
make a joint inspection of the Pipeline System with a view to ISGS or the Transfer
Operator taking over the Pipeline System.
8.2.2.2. The Pipeline System shall be transferred to ISGS on the Expiry Date in accordance
with the terms of this BOOT Contract. The Operator shall ensure that the Pipeline
System are free of all encumbrances, liabilities, liens, mortgages or the like, other
than those approved by ISGS at the Expiry Date. The Operator agrees to fully
indemnify and hold ISGS or its nominees harmless against every and all claims,
damages, losses, demands, actions, judgments, liabilities, costs, fees and expenses
arising out of any obligation or liability of the Operator (whether by statute, contract
or otherwise) or any act or omission of the Operator provided any said claims,
damages, losses, demands, actions, judgments, liabilities, costs, fees and expenses,
etc. arise from the breach of the Operator’s obligations. In furtherance of the
foregoing, the Operator agrees to execute or cause to be executed by banks such
bonds, assurances and guarantees (in the form and substance acceptable to ISGS) in
order to secure the foregoing indemnity.
8.2.2.3. If the Transfer Inspection reveals that the Pipeline System requires remedial
maintenance to be carried out so that it is fit to continue to meet the Transfer
Conditions and regular operations, the Operator shall promptly carry out whatever
remedial maintenance is so required prior to the Expiry Date. The Operator shall
provide ISGS with such evidence and information as ISGS may reasonably request
regarding the implementation of the remedial maintenance referred to above. Within
[●] Days of receipt of such information, ISGS shall have the right to carry out another
Transfer Inspection to determine whether the Operator has carried out the remedial
maintenance as requested by ISGS.
8.2.2.4. If the Transfer Inspection reveals that the Pipeline System is not in accordance with
the Transfer Conditions and the Operator has not remedied the Pipeline System to
comply with the Transfer Conditions prior to the Expiry Date, ISGS shall be entitled
to claim such liquidated damages as determined by an Expert in terms of Clause 18.2.
8.2.3. Transfer Transition Plan
8.2.3.1 By no later than the Transfer Period Commencement Date, the Operator shall submit
to ISGS, for its review and comment, a draft comprehensive transition plan
("Transfer Transition Plan") outlining the particulars of all responsibilities and
obligations in relation to the transfer of the Pipeline System to ISGS or to a Transfer
Operator, as applicable. The Transfer Transition Plan shall deal with, inter alia, the
requirements for transfer of the Pipeline System ("Transfer Requirements").
8.2.3.2 ISGS shall provide its comments on the draft Transfer Transition Plan, or any
amendments thereof, no later than [three hundred (300)] Days prior to the Expiry
Date, and the Operator shall submit the final version of the Transfer Transition Plan,
reflecting such comments and/or amendments, to ISGS no later than [two hundred
and seventy (270)] Days prior to the Expiry Date.
8.2.4. Transfer Process; Timing
Promptly after delivery of the first draft of the Transfer Transition Plan (as contemplated by
Clause 8.2.3.1 (Transfer Transition Plan)) but in no event later than [two hundred and eighty
five (285)] Days prior to the Expiry Date, ISGS shall meet with the Operator to discuss the
orderly transfer of the Pipeline System to ISGS in accordance with the Transfer Requirements
30
(the "Transfer Kick-off Meeting"). The objective of the Transfer Kick-off Meeting will be to
agree on the detailed procedures and milestones for the Transfer Process.
8.2.5. Cooperation
The Parties agree to cooperate to the maximum extent possible throughout the Transfer
Process in order to achieve an orderly, smooth and efficient transfer of the Pipeline System
and the movable and immovable assets related to the Pipeline System to ISGS or a designated
Transfer Operator.
8.2.6. Transfer Operator
ISGS may, at any time during, or prior to the commencement of, the Transfer Period, may
appoint a Transfer Operator. In such event, ISGS shall promptly notify the Operator of such
appointment, specifying in the notice the name of the Transfer Operator and the individual
who will serve as the Transfer Operator's point of contact throughout the Transfer Process.
8.2.7. Continuing Contracts
8.2.7.1. The scope of transfer of contracts/agreements signed by the Operator with
business, trade, employees and labour covers contracts/agreements which include
periods after the Expiry Date ("Continuing Contracts"), but only to the extent
that the Operator’s obligations and liabilities thereunder will become due and
payable on or after the Expiry Date.
8.2.7.2. The Operator shall be responsible for all obligations and liabilities in respect of the
Continuing Contracts and shall indemnify and hold ISGS and each of its officers
and/or directors, representatives, agents or employees, harmless from and against
any and all losses, damages, expenses or liabilities due, or arising out of,
Continuing Contracts.
8.2.7.3. The Operator shall be responsible for clearing all liabilities/payments concerning
the Continuing Contracts that have accrued and are payable on or before the
Expiry Date.
8.2.7.4. The Operator shall obtain prior written consent of ISGS for all Continuing
Contracts before entering into such Continuing Contracts.
8.3 Transfer Upon Early Termination
8.3.1 Subject to Clause 8.2.7 of this BOOT Contract, in the event that this BOOT Contract is
terminated prior to the Expiry Date, in accordance with Clause 17 (Termination), the Operator
and ISGS shall, within fifteen (15) Days from the date of Notice of Intent to Terminate,
prepare a report setting forth a list of completed works as of the effective date of such
termination which fall under the scope of the Pipeline System, together with the value of the
completed works along with the relevant supporting documentation in respect of costs
incurred by the Operator.
8.3.2 Upon preparation of the said report, ISGS shall pay such amounts to the Operator as
determined pursuant to Clause 8.4 of this BOOT Contract for all Pipeline System related
infrastructure.
8.4 Compensation Upon Early Termination
8.4.1 Operator Event of Default. In the event ISGS terminates this BOOT Contract pursuant to
Clause [17.1] (Termination for Default) as a result of an Operator Event of Default, the
Operator shall transfer the Pipeline System to ISGS or its nominee and ISGS or its nominee
31
shall acquire the Pipeline System. Simultaneously ISGS shall pay to the Operator the
Compensation Amount set forth in Row 1 of Schedule 11 of this BOOT Contract.
8.4.2 ISGS Event of Default. In the event the Operator terminates this BOOT Contract pursuant to
Clause [17.1(b)(i) through (ix)] (Termination for Default) as a result of an ISGS Event of
Default, the Operator shall transfer the Pipeline System to ISGS or its nominee and, in such
event, the Pipeline System shall be transferred to ISGS or its nominee and ISGS shall
simultaneously pay the Operator the Compensation Amount set forth in Row 2 of Schedule
11 of this BOOT Contract.
8.4.3 Termination Following a Force Majeure Event. If, following a Force Majeure Event, ISGS or
the Operator terminates this BOOT Contract in terms of Clause 17.2, the Operator shall
transfer the Pipeline System to ISGS or its nominee and, in such event, the Pipeline System
shall be transferred to ISGS or its nominee and ISGS shall simultaneously pay the Operator
the Compensation Amount set forth in Row 3 of Schedule 11 of this BOOT Contract.
8.4.4 Termination by ISGS under Clause 17.3 (Voluntary Termination). In the event the ISGS
terminates this BOOT Contract pursuant to Clause 17.3 (Voluntary Termination), the
Operator shall transfer the Pipeline System to ISGS or its nominee and ISGS shall
simultaneously pay the Operator the Compensation Amount set forth in Row 4 of Schedule
11 of this BOOT Contract.
8.5 Provisions Applicable to Transfers Generally
8.5.1 Transfer Costs and Expenses
ISGS shall be responsible for bearing all costs and expenses of transfer, including stamp
duties, legal, appraisal and other charges and the fees of the Transfer Examiner. ISGS shall at
its own cost obtain or effect all consents and take such other action as may be necessary for
the transfers contemplated in this Clause 8 (Transfer).
8.5.2 Conditions of Transfer
8.5.2.1 Not later than the Transfer Date, the Operator shall, at its sole cost and expense,
provide to ISGS a report by a reputable and qualified engineer or engineering
consulting firm, approved by ISGS, certifying that as of the date of the report the
Pipeline System meet the Design Life and are in the condition and state of repair and
maintenance required by this BOOT Contract (including, without limitation, spare
parts inventory of the Pipeline System adequate for two years Operation), together
with such inspection reports, tests and other data reasonably adequate to substantiate
the conclusions reached in such report or, if such is not the case, a list of any
discrepancies and/or deficiencies in such condition and a remediation plan and a cost
estimate of the work required to remedy such discrepancies and/or deficiencies as
soon as reasonably practicable and in any event prior to the Transfer Date. The
Operator, at its sole cost and expense, shall cause any such discrepancies and/or
deficiencies to be fully corrected in accordance with the engineer’s remediation plan,
if any, contained in the report prior to the date of transfer.
8.5.2.2 Any transfer of the Pipeline System to ISGS shall be free and clear of all Liens
(except as are contained and maintained in accordance with the terms of this BOOT
Contract and all applicable Laws of Pakistan, and have been notified to ISGS) and
free and clear of all Environmental Liabilities and any Hazardous Materials.
32
9. ROUTE AND ROUTE MODIFICATION
9.1 Route
9.1.1 The Pipeline System shall be constructed along the Route which is attached hereto as
Schedule 3. The costs associated with any increase in the length of the Section along the
Route up to five per cent (5%) of the given length of the Section shall be borne by the
Operator and the Operator shall not be entitled to any revision of the Tariff under the
Transportation Agreement as the result of such increase in the length of the Section.
9.2 Route Modification
In the event that any modifications are required to be made at any stage to the Route,
including any increase in length of the Section in excess of five per cent (5%), the proposed
modifications to the Route shall be agreed to by mutual consent between the Parties, subject
to necessary approvals, pursuant to which this modified route shall become the “Route” for
the purposes of this BOOT Contract. Any increase in the Route above five per cent (5%) of
the length of the Section shall be considered an additional modification only to the extent of
any increase beyond five per cent (5%) and shall be addressed in accordance with the
provisions of Clause 6.8 (Additional Modifications).
10. REPRESENTATIONS AND WARRANTIES
10.1 ISGS’s Representations and Warranties
ISGS represents and warrants to the Operator that:
10.1.1 ISGS is duly incorporated, existing and in good standing under the Laws of Pakistan and has
all requisite power and authority to conduct its business and to execute, to deliver and to
perform its obligations under this BOOT Contract; and
10.1.2 this BOOT Contract has been duly authorised, executed and delivered by it and constitutes the
legal, valid and binding obligation of it.
10.2 Operator’s Representations and Warranties
10.2.1 The Operator represents and warrants to ISGS that:
10.2.2 neither the Operator nor any of its Contractors or any Affiliate or subsidiary, or any director,
officer, employee, or agent, of the Operator is a Person that is, or is owned or controlled by
Persons that are: (a) the subject of any sanctions administered or enforced by the United
Nations Security Council, the Government of Pakistan, or any other relevant sanctions
authority (collectively, "Sanctions"), or (b) located, organized or resident in a country or
territory that is, or whose government or government-owned entities are, the subject of
Sanctions;
10.2.3 the Operator is duly incorporated, existing and in good standing under the Laws of Pakistan
and has all requisite power and authority to conduct its business and to execute, to deliver and
to perform its obligations under this BOOT Contract;
10.2.4 there are no proceedings pending, in any jurisdiction or at any forum against the Operator or
any Contractor, that threaten the liquidation of any Contractor or the Operator, or that could
materially adversely affect the performance by the Operator of its obligations under this
BOOT Contract;
33
10.2.5 this BOOT Contract has been duly authorised, executed and delivered by it and constitutes the
legal, valid and binding obligation of it;
10.2.6 on or before the Commercial Operations Date, the Operator has procured and maintains all
Required Consents;
10.2.7 the execution and delivery of, and performance of its obligations under this BOOT Contract
by the Operator does not and will not constitute a violation of any statute, judgment, order,
decree or regulation or rule of any court, governmental authority or arbitrator of competent
jurisdiction applicable or relating to it, its assets or its businesses; and
10.2.8 it has adequate resources, expertise and personnel to comply with its obligations under this
BOOT Contract for the Implementation of the Pipeline System and the Operations of the
Pipeline System in terms required under this BOOT Contract.
11. LIABILITY
11.1 Limitation of Liability
11.1.1 Neither Party shall be liable to the other Party in contract, tort, warranty, strict liability, or any
other legal theory for any indirect, consequential, incidental, punitive, or exemplary damages.
Neither Party shall have any liability to the other Party except pursuant to, or for breach of
this BOOT Contract or the Transportation Agreement; provided, however, that this provision
is not intended to constitute a waiver of any rights of one (1) Party against the other with
regard to matters unrelated to this BOOT Contract or to any activity not contemplated by this
BOOT Contract.
11.1.2 The limitation of liability provided for in Clause 11.1.1 shall not:
(c) apply in relation to any provision of the BOOT Contract which expressly provides
for an indemnity; or
(d) affect any provision of this BOOT Contract which provides for a Party to make a
payment to the other Party (including payment of liquidated damages); or
(e) where such liability was caused by the gross negligence or wilful misconduct of the
relevant Party.
11.2 Indemnification for Fines and Penalties
Any fines or other penalties incurred by the Operator for non-compliance with applicable
Laws of Pakistan or other governmental directions issued pursuant thereto and in accordance
therewith or the Required Consents shall not be reimbursed by ISGS but shall be the sole
responsibility of the Operator.
12. INSURANCE
12.1 Insurance Coverage
Subject to the relevant insurances being available on commercially reasonable terms in the
international insurance market, the Operator shall obtain and maintain in effect such insurance
policies and coverage as is required by the Financing Documents and Good Industry Practice
in the amounts and on the terms set forth herein and therein and during the periods mentioned
therein; provided, however, that such amounts and terms may be changed from time to time
with the prior written consent of the other Party, which consent shall not be unreasonably
withheld. Nothing shall prevent the Operator, at its sole cost and expense, from procuring
insurance coverages in addition to those specified herein. In that regard, the Operator shall
apprise ISGS of the insurance requirements proposed by the financing parties (including draft
documentation with appropriate explanations thereto).
34
12.2 Application of Proceeds
Subject to the Financing Documents, for the Term, the Operator shall apply any and all
insurance proceeds received by it under any physical damage insurance in connection with the
damage to or loss of the Pipeline System, toward the repair, reconstruction or replacement of
the Pipeline System to the condition existing immediately prior to the event giving rise to
such insurance claim and proceeds.
12.3 Insurers
All the Insurance obtained and maintained by the Operator in accordance with this Clause 12
(Insurance) shall be with creditworthy insurers reasonably acceptable to the other Party and
the financing parties [with a PACRA LT rating or a rating of JCR-VIS Credit Rating Co. Ltd.
of at least A].
13. ASSIGNMENT AND SECURITY
13.1 Assignment
No assignment or transfer by a Party of this BOOT Contract or such Party’s rights or
obligations hereunder shall be effective without the prior written consent of the other Party,
except as provided in Clause 13.2 (Creation of Security).
13.2 Creation of Security
13.2.1. Notwithstanding the provisions of Clause 13.1 (Assignment), for the purpose of financing the
Pipeline System for the Section, the Operator may, with the prior approval of ISGS, assign
pursuant to the Financing Documents to, or create a security interest in favour of, the Lenders
in the Operator’s rights and interests under or pursuant to:
(a) this BOOT Contract;
(b) the Pipeline System Documents, or any agreement or document included within or
contemplated by the Pipeline System Documents;
(c) the Pipeline System;
(d) the present and future movable and immovable property of the Operator;
(e) the present and future revenues or any of the rights or assets or actionable claims of
or debts owed to, the Operator; and
(f) any other present or future interest, right, property or asset of the Operator of any
kind and wherever situated.
13.2.2. The Operator may also create security interests in its rights and assets in favour of financial
institutions acting as short-term lenders providing working capital or other short-term credit
facilities by the Operator, provided such security interests on the Pipeline System shall be (i)
limited to the working capital requirements for the Pipeline System and (ii) subject to an
undertaking furnished by the short-term lenders in favour of and delivered to ISGS stipulating
vacation of such security interest on Pipeline System ipso facto upon payment of
Compensation Amounts by ISGS to the Lenders (and to the Operator where applicable) in
connection with the transfer of the Pipeline System to ISGS or its nominee.
35
14. LIQUIDATED DAMAGES
14.1 Liquidated Damages for Transfer Condition
14.1.1. In the event that the Pipeline System does not conform with the Transfer Conditions at the
time of Transfer, the Operator shall pay liquidated damages as determined by an Expert in
terms of Clause 18.2.
14.1.2. Liquidated damages payable under this BOOT Contract shall be paid by the Operator in
accordance with Clause 20 (Invoicing and Payment Procedure). Failing such payment by the
Operator, the Liquidated Damages due to ISGS shall be drawn from the Implementation
Performance Bond, or deducted from any sums due to the Operator.
14.1.3. Payment of liquidated damages shall be to the exclusion of any other remedy of ISGS in
respect of delays under this BOOT Contract but shall not relieve the Operator from its overall
obligations of the Pipeline System or from any of its other obligations, risks, or liabilities
under this BOOT Contract.
14.1.4. The liquidated damages provided for in this BOOT Contract shall be payable in all events
without set-off or counter claim by the Operator and the Parties hereby agree that the amounts
thereof are reasonable and have been mutually agreed as the pre-determined loss of ISGS in
the circumstances.
15. GUARANTEES
15.1 Implementation Performance Bond
15.1.1. The Operator shall provide to ISGS an unconditional, irrevocable and on-demand
Implementation Performance Bond on or prior to the Effective Date, in the form attached
herewith as Schedule 12 (Form of Implementation Performance Bond), issued by a bank
having a Minimum Credit Rating at all times, for proper performance by the Operator of its
obligations, in the amount of PKR 500,000,000 (Pak Rupees Five Hundred Million only) in
relation to its obligations for Implementation under this BOOT Contract.
15.1.2. The Implementation Performance Bond shall only be cashed by ISGS in the event the
Operator fails to pay any liquidated damages due from the Operator in terms of this BOOT
Contract. The Implementation Performance Bond shall remain in full force and effect until
the Commercial Operations Date, provided that where the original Scheduled Commercial
Operations Date (before any extension) has been extended (i) for delay or default on the part
of ISGS under the Pipeline System Documents, the cost associated with extending the
Performance Bond shall be borne by ISGS; and (ii) due to a Force Majeure Event, the cost
associated with extending the Implementation Performance Bond shall be borne by equally by
ISGS and the Operator.
15.1.3. In the event that ISGS draws against the Implementation Performance Bond and it is
subsequently determined that ISGS was not entitled to do so, then ISGS shall repay such
amount to the Operator, together with all costs and expenses incurred by the Operator in
connection with such drawing (including reasonable attorneys’ fees), plus interest thereon
from the date of the draw through the date of repayment at the Delayed Payment Rate.
15.2 Operations Performance Bond
15.2.1. The Operator shall provide to ISGS an unconditional, irrevocable and on-demand Operations
Performance Bond on or prior to the Effective Date, in the form attached herewith as
Schedule 13 (Form of Operations Performance Bond), issued by a bank having a Minimum
Credit Rating at all times, for proper performance by the Operator of its obligations, in the
amount of PKR 500,000,000 (Pak Rupees Five Hundred Million only) in relation to its
obligations for Operations under this BOOT Contract and the Transportation Agreement.
36
15.2.2. The Operations Performance Bond shall only be cashed by ISGS in the event the Operator
fails to pay any amounts due from the Operator in terms of this BOOT Contract and/or the
Transportation Agreement. The Operations Performance Bond shall remain in full force and
effect from the Commercial Operations Date until the end of the Term, provided that where
there is (i) any delay or default on the part of ISGS under the Pipeline System Documents, the
cost associated with extending the Operations Performance Bond shall be borne by ISGS; and
(ii) due to a Force Majeure Event, the cost associated with extending the Operations
Performance Bond shall be borne by equally by ISGS and the Operator.
15.2.3. In the event that ISGS draws against the Operations Performance Bond and it is subsequently
determined that ISGS was not entitled to do so, then ISGS shall repay such amount to the
Operator, together with all costs and expenses incurred by the Operator in connection with
such drawing (including reasonable attorneys’ fees), plus interest thereon from the date of the
draw through the date of repayment at the Delayed Payment Rate.
15.3 SBLC
15.3.1. ISGS shall provide to the Operator the SBLC which shall be an unconditional, irrevocable
and on-demand SBLC on or prior to the Commercial Operations Date, in the form attached
herewith as Schedule 6 (Form of SBLC), for proper performance by ISGS of its obligations,
in the amount of PKR [●] (the "SBLC").
15.3.2. The SBLC shall only be drawn on by the Operator in the manner as provided for in the
Transportation Agreement.
15.3.3. In the event that the Operator draws against the SBLC and it is subsequently determined that
the Operator was not entitled to do so, then the Operator shall repay such amount to ISGS,
together with all costs and expenses incurred by ISGS in connection with such drawing
(including reasonable attorneys’ fees), plus interest thereon from the date of the draw through
the date of repayment at the Delayed Payment Rate.
16. FORCE MAJEURE
16.1 Definition of Force Majeure
A “Force Majeure Event” shall mean any event or circumstance or combination of events or
circumstances in the nature of natural disasters, beyond the reasonable control of a Party
which (or the effects of which), materially and adversely affects the performance by that
Party of its obligations under or pursuant to the Principal Documents; provided, however,
that, such event or circumstances, or combination of events or circumstances, not constitute a
“Force Majeure Event” hereunder to the extent that it could have been prevented, or
overcome, or remedied by the affected Party through the exercise of such diligence and
reasonable care as would be exercised by a prudent person under similar circumstances, it
being understood and agreed that reasonable care includes acts or activities to protect a
Party’s facilities or operations from a casualty or other reasonably foreseeable event, which
acts or activities are reasonable in the light of likelihood of such event, the probable effect of
such event if it should occur, and the likely efficacy of the protection measures. Without
limiting the generality of the foregoing, “Force Majeure Events” hereunder shall include each
of the following events and circumstances, but only to the extent that each satisfied the above
requirements:
16.1.1. events beyond the reasonable control of the affected Party (each an “Other Force Majeure
Event”), including, but not limited to:
16.1.1.1. lightning, fire, earthquake, tsunami, flood, storm, cyclone, typhoon, or tornado; or
16.1.1.2. any Lapse of Consent that shall have existed for thirty (30) consecutive Days or
more; or
37
16.1.1.3. any strike, work-to-rule, go-slow, or analogous labour action that is not politically
motivated and is not widespread or nationwide; or
16.1.1.4. fire, explosion, chemical contamination, radioactive contamination, or ionizing
radiation;
16.1.1.5. Change in Law;
16.1.1.6. epidemic or plague; or
16.1.1.7. any event of force majeure under transportation agreements between ISGS and
OMCs in relation to the Pipeline System.
16.1.2. Force Majeure Events shall expressly not include the following conditions:
16.1.2.1 late delivery or interruption in the delivery of supplies, materials, machinery,
equipment materials, spare parts or consumables except where the same is caused
by a Force Majeure Event;
16.1.2.2 a delay in the performance of any Contractors not caused by a Force Majeure; or
16.1.2.3 breakdown in machinery or equipment;
16.1.2.4 normal wear and tear or random flaws in supplies, materials and equipment or
breakdown in equipment; or
16.2.1.1. theft.
16.2 Notification Obligations
16.2.1. If, by reason of a Force Majeure Event, a Party is wholly or partially unable to carry out its
obligations under this BOOT Contract, the affected Party shall (i) give the other Party notice
of the Force Majeure Event as soon as practicable, but in any event, no later than the later of
forty eight (48) hours after the affected Party becomes aware of the occurrence of the Force
Majeure Event or six (6) hours after the resumption of any means of providing notice between
the Operator and ISGS, and (ii) give the other Party a second notice, describing the Force
Majeure Event in reasonable detail and, to the extent which can reasonably be determined at
the time of such notice, providing a preliminary evaluation of the obligations affected, a
preliminary estimate of the period of time that the affected Party shall be unable to perform
the obligations and other relevant matters as soon as practicable, but in any event, no later
than seven (7) Days after the initial notice of the occurrence of the Force Majeure Event is
given by the affected Party or six hours after the resumption of any means of providing such
notice between the Parties. When appropriate, or when reasonably requested so to do by the
other Party, the affected Party shall provide further notices to the other Party, more fully
describing the Force Majeure Event and its cause(s) and providing or updating information
relating to the efforts of the affected Party to avoid and/or to mitigate the effect(s) thereof and
estimates, to the extent practicable, of the time that the affected Party reasonably expects it
shall be unable to carry out any of its affected obligations due to the Force Majeure Event.
16.2.2. The affected Party shall also provide notice to the other Party of (i) the cessation of the Force
Majeure Event; (ii) (ii) the affected Party’s ability to recommence performance of its
obligations under this BOOT Contract by reason of the cessation of the Force Majeure Event
and the effects thereof, which notice shall be given as soon as possible, but in any event, no
later than seven (7) Days after the occurrence of each of the clauses (i) and (ii) above.
16.2.3. Failure by the affected Party to give written notice of a Force Majeure Event to the other
Party within the forty-eight (48) hour period or six (6) hour period required under Clause
16.2.1 shall not prevent the affected Party from giving such notice at a later time; provided,
however, that in such case, the affected Party shall not be excused pursuant to Clause 16.4
(Delay Caused by Force Majeure) for any failure or delay in complying with its obligations
under or pursuant to this BOOT Contract until such notice has been given. If such notice is
given within the forty-eight (48) hour period or six (6) hour period required by Clause 16.2.1,
the affected Party shall be excused for such failure or delay pursuant to Clause 16.4 (Delay
38
Caused by Force Majeure) from the date of commencement of the relevant Force Majeure
Event.
16.3 Duty to Mitigate
The affected Party shall use all reasonable efforts (or shall ensure that its Contractors use all
reasonable efforts) to mitigate the effects of a Force Majeure Event, including, but not limited
to, the payment of reasonable sums of money by or on behalf of the affected Party (or such
Contractor), which sums are reasonable in light of the likely efficacy of the mitigation
measures.
16.4 Delay Caused by Force Majeure
Upon the occurrence, and during the continuance of a Force Majeure Event and the effects
thereof, (i) the affected Party shall not be liable for any failure or delay in performing its
obligations (other than an obligation to make a payment) under or pursuant to this BOOT
Contract, and (ii) any performance deadline that the affected Party is obligated to meet under
this BOOT Contract shall be extended; provided, however, that no relief, including without
limitation, extension of performance deadlines, shall be granted to the affected Party pursuant
to this Clause 16.4 (Delay Caused by Force Majeure) to the extent that such failure or delay
would nevertheless have been experienced by the affected Party had the Force Majeure Event
not occurred or that such failure or delay was caused by the failure of the affected Party to
comply with the required obligations. The Party which is not affected by the Force Majeure
Event, shall not bear any liability for any loss or expense suffered by the affected Party as a
result of a Force Majeure Event, except that, notwithstanding the foregoing:
17. TERMINATION
17.1 Termination for Default
17.1.1. Operator Event of Default; Termination by ISGS. Each of the following events shall be an
event of default by the Operator (each a " Operator Event of Default"), which, if not cured
within the time period permitted (if any) to cure, shall give rise to the right on the part of
ISGS to terminate this BOOT Contract pursuant to Clause 17.4 (Termination Notices);
provided, however, that no such event shall be an Operator Event of Default if it results from
a breach or default of any of the Pipeline System Documents by a party thereto (other than the
Operator) or if it occurs as a result of a Force Majeure Event:
17.1.1.1. failure of the Operator to achieve the Commercial Operations Date within [●]
Days after the Scheduled Commercial Operations Date;
17.1.1.2. other than the assignments to and by the Lenders contemplated under Clause 13.2
(Creation of Security), the assignment or transfer of the Operator’s rights or
obligations in the assets identified in Clause 13.2 without obtaining the prior
written consent of ISGS or the transfer, conveyance, loss, or relinquishment of the
Operator’s right to own and/or operate the Pipeline System or any material part
thereof or to occupy the Route, to any Person (other than ISGS) without the prior
written approval of ISGS;
17.1.1.3. except for the purpose of amalgamation or reconstruction (provided, that such
amalgamation or reconstruction does not affect the ability of the amalgamated or
reconstructed entity, as the case may be, to perform its obligations under this
BOOT Contract and further provided that such amalgamation has been agreed to
by ISGS), the occurrence of any of the following events: (a) the passing of a
resolution by the shareholders of the Operator for the winding up of the Operator;
(b) the voluntary filing by the Operator of a petition for bankruptcy, moratorium,
or other similar relief; (c) the appointment of a provisional liquidator in a
proceeding for the winding up of the Operator after notice to the Operator and due
hearing, which appointment has not been set aside or stayed within ninety (90)
Days of such appointment; (d) the making by a court with jurisdiction over the
39
Operator of an order winding up the Operator that is not stayed or reversed by a
court of competent authority within ninety (90) Days;
17.1.1.4. the Operator gives or offers to give (directly or indirectly) to any person any bribe,
gift, gratuity, commission or any other thing of value, as an inducement or reward:
(a) for doing or forbearing to do any action in relation to this BOOT Contract, or
(b) for showing or forbearing to show favour or disfavour to any person in relation
to this BOOT Contract,
17.1.1.5. any statement, representation, or warranty by the Operator in this BOOT Contract
proving to have been incorrect, in any material respect, when made or when
deemed to have been made, and such failure or incorrect statement, representation,
or warranty having a material adverse effect on the Operator’s ability to perform
its obligations under this BOOT Contract or on the obligations or liabilities of
ISGS under this BOOT Contract;
17.1.1.6. if the Operator has repudiated this BOOT Contract or abandons its obligations
under this BOOT Contract;
17.1.1.7. in the event of the termination of the Transportation Agreement and/ or any other
Pipeline System Document, due to a breach of or non-performance by the
Operator of any of its obligations under this BOOT Contract;
17.1.1.8. if the Operator fails to furnish, keep valid and maintain in full effect the
Performance Bonds in accordance with this BOOT Contract and the
Transportation Agreement;
17.1.1.9. if there is breach of the Sponsor(s) Undertaking(s);
17.1.1.10. If the Operator fails to maintain Required Consents for the Implementation and the
operation of the Pipeline System in terms required under this BOOT Contract;
17.1.1.11. if the Operator fails to maintain the required insurances;
17.1.1.12. exercise by the Lenders of their remedies under the Financing Documents with
respect to either the Pipeline System, its assets or the pledged Ordinary Share
Capital, such that either the Operator or its management are removed by the
Lenders from control of the Pipeline System or the Operator and the failure by the
Lenders to deliver an Election Notice within two hundred and forty (240) Days
thereafter;
17.1.1.13. any material breach or material default by the Operator of or under this BOOT
Contract that is not remedied within ninety (90) Days after notice from ISGS,
stating that a material breach of such agreement has occurred that could result in
the termination of this BOOT Contract and identifying the material breach in
question in reasonable detail; or
17.1.1.14. the occurrence of a Transporter Event of Default, under the Transportation
Agreement.
17.1.2. ISGS Event of Default; Termination by the Operator. Each of the following events shall be
deemed an event of default by ISGS (each an "ISGS Event of Default"), which, if not cured
within the time period permitted (if any) to cure, shall give rise to the right on the part of the
Operator to terminate this BOOT Contract pursuant to Clause 17.4 (Termination Notices);
provided, however, that no such event shall be an ISGS Event of Default if it results from a
breach or default of any of the Pipeline System Documents by the Operator or if it occurs as a
result of an Other Force Majeure Event:
17.1.2.1 any material breach or default by ISGS of or under this BOOT Contract that is not
remedied within thirty (30) Days after notice from the Operator to ISGS stating that
a material breach of this BOOT Contract has occurred that could result in the
termination of this BOOT Contract, identifying the material breach in reasonable
detail and demanding remedy thereof;
17.1.2.2 the occurrence of any of the following events:
40
(A) any proceeding being validly instituted under the laws of Pakistan for
the dissolution of ISGS that is not stayed or suspended;
(B) the passing of a resolution for the dissolution or winding up of ISGS;
(C) the voluntary filing by ISGS of a winding up petition;
(D) the appointment of a provisional liquidator in a proceeding for the winding
up of ISGS after notice to ISGS and due hearing, which appointment has
not been set aside or stayed; or
(E) the making by a court with jurisdiction over ISGS of an order winding up
ISGS that is not stayed or reversed by a court of competent jurisdiction;
17.1.2.3 any statement, representation or warranty made by ISGS under any of the Pipeline
System Documents proving to have been incorrect, in any material respect, when
made or when reaffirmed and such incorrect statement, representation or warranty
having a material adverse effect on ISGS’s ability to perform its obligations under
any of the Pipeline System Documents or having a material adverse effect on the
rights or obligations of the Operator under the Pipeline System Documents;
17.2 Termination as a result of Force Majeure Event
If, as a result of a Force Majeure Event, the Operator is prevented from performing its
obligations under this BOOT Contract for a period which exceeds or can with reasonable
certainty be foreseen to exceed a period of [six (06)] continuous Months, either the Operator
or ISGS may terminate this BOOT Contract by giving a Termination Notice to the other of
not less than [two (02)] Months.
17.3 Voluntary Termination
ISGS shall have the right at any time after the tenth (10th) anniversary of the Commercial
Operations Date to serve a Notice of Intent to Terminate on the Operator which shall take
effect no earlier than twelve (12) Months following the date of issue of the Notice of Intent to
Terminate or, if later, on the date specified therein.
17.4 Termination Notices
17.4.1. Upon the occurrence of an ISGS Event of Default or an Operator Event of Default, as the case
may be, that is not cured within the applicable cure period, if any, the non-defaulting Party may,
at its option, initiate termination of this BOOT Contract by delivering a notice (a "Notice of
Intent to Terminate") of its intent to terminate this BOOT Contract to the defaulting Party. The
Notice of Intent to Terminate shall specify in reasonable detail the Operator Event of Default or
the ISGS Event of Default, as the case may be, giving rise to such notice.
17.4.2. Following delivery of the Notice of Intent to Terminate, the Party in default may continue to
undertake efforts to cure the Operator Event of Default or the ISGS Event of Default, as the
case may be, for a period of thirty (30) Days commencing on the delivery date of such notice
in the case of a failure by either Party to make payments, or for a period of ninety (90) Days
commencing on the delivery of such notice in the case of any other Operator Event of Default
or ISGS Event of Default, as the case may be, (or such longer period as the Parties may
mutually agree) and if the default is cured at any time prior to the delivery of a Termination
Notice in accordance with Clause 17.4, then the non-defaulting Party shall have no right to
41
terminate this BOOT Contract in respect of such cured Operator Event of Default or ISGS
Event of Default, as the case may be.
17.4.3. Upon expiration of any cure period from the Notice of Intent to Terminate, and unless the
Parties shall have otherwise agreed or unless the Operator Event of Default or ISGS Event of
Default, as the case may be, giving rise to the Notice of Intent to Terminate shall have been
remedied, the Party having given the Notice of Intent to Terminate ISGS or the Operator, as
the case may be, may terminate this BOOT Contract by delivering a Termination Notice to
the other Party whereupon, this BOOT Contract shall terminate on the date (the
"Termination Date") specified in the Termination Notice, which date shall not be earlier than
the date that is ten (10) Business Days following the date on which the Termination Notice is
delivered to the other Party or later than thirty (30) Days following the date of such delivery
of the Termination Notice to the other Party, [and the provisions of Clause 17.5 (Obligations
Upon Termination) shall apply.
17.5 Obligations Upon Termination
Upon expiration or earlier termination of this BOOT Contract, the Parties shall have no
further obligations (including but not limited to payments of any compensation payments
accruing prior to termination) hereunder except for obligations that arose prior to or arise
upon such expiration or termination and obligations that survive such expiration or
termination pursuant to this BOOT Contract.
17.6 Other Remedies
The exercise of the right of a Party to terminate this BOOT Contract, as provided herein, does
not preclude the Party from exercising other remedies that are provided herein or are available
at law. Remedies are cumulative, and the exercise of, or failure to exercise, one or more
remedy by a Party shall not limit or preclude the exercise of, or constitute a waiver of, other
remedies by that Party; provided, that the remedies and Compensation Amounts are the
exclusive remedies available to each Party with respect to any termination of this BOOT
Contract as a consequence of the events described therein.
18. RESOLUTION OF DISPUTES
18.1 Resolution by Parties
18.1.1. If a dispute arises in respect of this BOOT Contract, a Party may inform the other Party of
such a dispute under this Clause 18 (Resolution of Parties) by written notice ("Dispute
Notice").
18.1.2. The representatives of the Parties shall promptly meet on a without prejudice basis to
endeavour to resolve the dispute:
18.1.2.1 the Representatives of the Parties within 10 Business Days of the date of the
Dispute Notice; and
18.1.2.2 failing resolution under paragraph (i), the Chief Executive Officer of each Party,
within a further 10 Business Days.
18.1.3. The Parties shall act in good faith and use reasonable endeavours to resolve the dispute in all
meetings conducted in accordance with this Clause 18 (Resolution by Parties).
18.2 Expert
18.2.1. In the event that the Parties are unable to resolve a Dispute in accordance with Clause 18.1
(Resolution by Parties) within the time periods set forth therein, then either Party, in
accordance with this Clause 18.2 (Expert), may refer the Dispute to an Expert for
consideration of the Dispute and to obtain a determination from the Expert in the matter.
Notwithstanding the foregoing, either Party may require that any Dispute be referred for
42
resolution to arbitration pursuant to Clause 18.3 (Arbitration) without first referring it to an
Expert.
18.2.2. The Party initiating submission of the Dispute to the Expert shall provide the other Party with
a notice stating that it is submitting the Dispute to an Expert and nominating the person/entity
it proposes to be the Expert, who shall:
(i) in respect of matters or disputes of a commercial or financial nature, as mutually
agreed between the Parties, and in the event the Parties fail to agree within seven (7)
Days from any Party’s notice to the other for appointment of the Expert, the
following order of precedence shall apply:
a. [C/F Expert 1];
b. [C/F Expert 2]; or
c. [C/F Expert 3]; and
(ii) in respect of matters or disputes of a technical nature, as mutually agreed between the
Parties, and in the event the Parties fail to agree within seven (7) Days from any
Party’s notice to the other for appointment of the Expert, the following order of
precedence shall apply:
a. [Technical Expert 1];
b. [Technical Expert 2]; or
c. [Technical Expert 3].
18.2.3. Within ten (10) Days after appointment of an Expert, the Party seeking consideration of
dispute by an Expert shall submit the following to the Expert and the other Party:
(i) a description of the Dispute;
(ii) a statement of the initiating Party’s position, and whether a hearing is requested by
such Party; and
(iii) copies of records.
18.2.4. Within ten (10) Days of the date that a Party has submitted the materials described in Clause
above, the other Party may submit to the Expert, with copies to the other Party:
(i) a description of the Dispute;
(ii) a statement of such Party’s position and, if not already requested, whether a hearing is
requested by such Party; and
(iii) copies of any relevant record.
18.2.5. The Expert shall consider any such information submitted by the Parties and any additional
information submitted by either Party at a later date but, in such event, the other Party shall be
concurrently provided with such information and shall be allowed reasonable opportunity to
respond thereto.
18.2.6. Each Party shall have access to the other Party’s relevant records and be entitled to receive
copies of the records submitted by the other Party.
18.2.7. Each Party shall designate one person knowledgeable about the issues in Dispute who shall be
available to the Expert to answer questions and provide any additional information requested
by the Expert. Except for such person, a Party shall not be required to, but may, provide oral
statements or presentations to the Expert or make any particular individuals available to the
Expert. If a hearing is requested by either Party, the Expert shall nominate a time and place
for a hearing of the Parties on the Dispute.
43
18.2.8. The Expert shall provide a determination within thirty (30) Days after the ten (10) Day
response period provided in Clause above has expired, or within such further time as is agreed
in writing by the Parties. If the Expert’s determination is given within such thirty (30) Day
period, as may be extended by the Parties, the Parties may review and discuss the
determination with each other in good faith for a period of ten (10) Days following delivery
of the determination before proceeding with any other actions.
18.2.9. The proceedings shall be without prejudice to any Party, and any evidence given or
statements made in the course of this process may not be used against a Party in any other
proceedings. The process shall not be regarded as an arbitration and the laws relating to
commercial arbitration shall not apply.
18.2.10. Unless the Parties agree in writing at the time the Expert is selected that the determination of
the Expert shall be binding, the determination of the Expert shall not be binding; provided,
however, that if arbitration proceedings in accordance with Clause 18.3 (Arbitration) have not
been commenced within seventy-five (75) Days from the date the Expert’s determination was
received by the Parties in accordance with Clause 18.2 the Expert’s determination shall be
final and binding on the Parties, and any right of such Parties to resort to arbitral, judicial or
other proceedings in relation to the subject matter of the determination shall stand waived to
the fullest extent permitted by law.
18.2.11. If a Party does not accept the determination of the Expert with respect to the Dispute (where
such determination is not binding or if the Expert has not provided a determination within the
time period specified, any Party may initiate arbitration proceedings in accordance with
Clause 18.3.
18.2.12. The costs of engaging an Expert shall be borne by the Party in default, however in the event
that the determination does not relate to a default by a Party, then the cost of engaging the
Expert shall be borne equally by the Parties and notwithstanding the same, each Party shall
bear its respective costs in preparing materials for, and making presentations to, the Expert.
18.3 Arbitration
18.3.1. Any Dispute arising out of or in connection with this BOOT Contract that has not been
resolved following the procedures set forth in Clause 18.1 (Resolution by Parties) or Clause
18.2 (Expert) has been required by a Party to be referred to arbitration, shall be settled by
arbitration in accordance with the provisions of the Arbitration Act, 1940 (or any re-
enactment thereof) ("Arbitration Act") by two (2) arbitrators, one to be appointed by each of
the Parties, which together shall appoint an umpire, whose decision shall be final in the
matter. The arbitration proceedings shall be conducted, and the award shall be rendered, in the
English language. Unless otherwise provided for in the award, each Party shall bear its own
costs of arbitration and where there are shared costs, the same shall be borne equally between
the Parties.
18.3.2. The venue and seat of arbitration shall be Islamabad, Pakistan.
18.4 Performance to Continue During Dispute
Notwithstanding any reference of a Dispute under Clause 18 the Parties shall (to the extent
practicable) continue to perform their respective obligations under the Agreement, unless they
mutually agree otherwise.
44
19. TAXES
19.1 Taxes Applicable to the Operator
All present and future Taxes applicable to the Operator, the Pipeline System and the
Operator’s other assets shall be paid by the Operator as and when required under the Laws of
Pakistan.
ISGS will apply applicable Taxes, comprising of withholding taxes while making payment of
Tariff to the Operator.
It is clarified that Tariff is inclusive of all Taxes but exclusive of Sales Tax applicable on
Tariff charged by Operator to the extent it is adjustable for ISGS.
It is further clarified that any liability on account of Tax imposed on ISGS arising in respect
of Operator’s obligations under the relevant Laws not properly discharged, shall be
recoverable from the Operator along with any litigation cost suffered by ISGS to defend its
position.
19.2 Taxes Applicable to ISGS
All present and future Taxes applicable to ISGS arising from or in connection with its rights
and obligations under this BOOT Contract shall be paid by ISGS as and when required under
the Laws of Pakistan. Provided that Tax on account of income tax applicable on income/
turnover shall be limited to tax on account of income tax applicable on the ISGS Margin.
It is clarified that Tariff is inclusive of all Taxes but exclusive of Sales Tax applicable on
Tariff charged by Operator to the extent it is adjustable for ISGS.
20. INVOICING; PAYMENT AND DISPUTED AMOUNTS
20.1 Invoicing
20.1.1. With respect to any payments due from ISGS to the Operator or from the Operator to ISGS
under this BOOT Contract, the Party seeking payment shall issue an invoice to the other Party
as soon as reasonable after such payment falling due, detailing amounts due in terms of this
BOOT Contract in respect of the relevant period.
20.1.2. Payment against each correct and complete invoice issued by the Operator or ISGS, as
applicable, shall be made within thirty (30) Days of receipt by the Operator or ISGS, as
applicable, of the relevant invoice (each a “Payment Date”).
20.1.3. All payments to the Operator or ISGS, as applicable, shall be made in PKR to the designated
accounts of the Operator or ISGS, as applicable in Pakistan.
20.1.4. Any amount under any invoice that is not paid in accordance with this Clause 20 (Invoicing
and Payments) on or before the Payment Date shall accrue interest at the Delayed Payment
Rate calculated from, but excluding, the relevant Payment Date to, and including, the Day on
which such payment is made.
20.2 Payments and Disputed Amounts
20.2.1. If either Party disputes any amount in an invoice (“Invoice Dispute”), it shall:
(i) make payment of the amount not in dispute in accordance with Clause 20.1;
45
(ii) notify the other Party, within twenty-eight (28) Days of receipt of such invoice of the
nature of the dispute and the disputed amount(s) (“Invoice Dispute Notice”).
20.2.2. ISGS and Operator shall, within seven (7) Days of the Invoice Dispute Notice, furnish to the
other copies of all records and documents relevant to the Invoice Dispute.
20.2.3. If the Invoice Dispute is not resolved after furnishing the records and documents, as per
Clause 20.2.2, the Parties shall resolve the Invoice Dispute through the mechanism set out in
Clause 18 (Dispute Resolution).
20.2.4. Upon resolution of Invoice Dispute, the relevant Party shall make payment within five (05)
Days of the resolution of the dispute.
21. MISCELLANEOUS PROVISIONS
21.1 Notices
21.1.1. Except as otherwise expressly provided in this BOOT Contract, all notices or other
communications to be given or made hereunder shall be in writing, shall be addressed for the
attention of the persons indicated herein below, and shall either be delivered personally or
sent by courier, registered or certified mail or facsimile. The addresses for service of the
Parties and their respective facsimile numbers shall be:
21.2.1.1 If to ISGS:
Inter State Gas (Private) Limited
8th Floor, Petroleum House,
Ataturk Avenue
G-5/2, Islamabad
Pakistan
Attn: Managing Director, ISGS
21.2.1.2 If to the Operator:
[●]
21.1.2. All notices shall be deemed delivered (i) when presented personally, (ii) if received on a
Business Day for the receiving Party, when transmitted by facsimile to the receiving Party’s
facsimile number specified hereabove and, if received on a Day that this is not a Business
Day for the receiving Party, on the first Business Day of the receiving Party following the
date transmitted by facsimile to the receiving Party’s facsimile number specified hereabove,
(iii) two (2) Days after being delivered to a courier for overnight delivery, addressed to the
receiving Party, at the address indicated hereabove or, (iv) five (5) Days after being deposited
in a regularly maintained receptacle for the postal service in Pakistan, , registered or certified,
return receipt requested, addressed to the receiving Party, at the address specified hereabove
(or such other address as the receiving Party may have specified by written notice delivered to
the delivering Party at its address or facsimile number specified above). Any notice given by
facsimile shall be confirmed in writing delivered personally or sent by registered or certified
mail, but the failure to provide such confirmation shall not void or invalidate the original
notice if it is in fact received by the Party to which it is addressed.
21.1.3. Any Party may by notice change the addressee and/or address to which such notices and
communications to it are to be delivered or mailed.
46
21.2 Accounts and Reports
21.2.1. Appointment of Auditors
The Operator shall, at its own cost, make arrangements with respect to the installation and
operation of an accounting and cost control system and for the appointment, as auditors, of a
reputed firm of independent chartered accountants acceptable to ISGS.
21.2.2. Right of Inspection
The Operator shall, during the Term, permit representatives of ISGS at any time to enter upon
and inspect the Pipeline System.
21.2.3. Periodic Reports
21.2.3.1 The Operator shall, as soon as available but in any event within ten (10) Days of
filing, furnish to ISGS two (2) copies of all documents filed in compliance with
the requirements of the Companies Act, 2017 as amended or superseded from time
to time.
21.2.3.2 The Operator shall, as soon as available, furnish to ISGS: (A) a report on any
factors materially and adversely affecting, or that might materially and adversely
affect, the Project or the Operator’s business and operations; (B) bi-annual audit
reports from either A.F. Ferguson & Co., Ernst & Young Ford Rhodes Sidat
Hyder, or KPMG Taseer Hadi & Co; and (C) copies of the Monthly progress
reports and any other construction related reports given to ISGS in the form and
substance satisfactory to ISGS, which shall include but not be limited to, reports
on inventory of spare parts and Project Ancillary System used or required by the
Operator for the design, construction, operation, and maintenance of the Pipeline
System.
21.2.4. Reporting of Changes
The Operator shall not without the prior written consent of ISGS make any (i) material
change in its Memorandum and Articles of Association; (ii) change in its fiscal year; (iii)
change in the constitution of its Board of Directors; (iv) change in its Chief Executive Officer,
and (v) registration of a transfer of Ordinary Share Capital to any Person who thereby
becomes a registered holder of greater than five (5) percent of the issued Ordinary Share
Capital, or of a transfer of Ordinary Share Capital to or from a Person or entity who,
immediately prior to such transfer, held greater than five (5) percent of the issued Ordinary
Share Capital.
21.2.5. Information Regarding Statutory Notice/Winding Up Proceedings
21.2.6.1 The Operator shall, within seven (7) Days of receipt thereof, provide a copy of any
notice that the Operator may be served under the relevant provisions of the
Companies Act, 2017 (or any re-enactment thereof) by any of the Lenders or its
creditors.
21.2.6.2 The Operator shall provide to ISGS all information in respect of any further actions
taken by the Lenders or its creditors following any notice under the relevant
provisions of the Companies Act, 2017 (or any re-enactment thereof).
21.3 Fossil and Archaeological Finds
All fossils, coins, articles of value or antiquity, and structures and other remains or things of
geological or archaeological interest discovered on or along the Route shall (as between the
Parties) be the property of ISGS. The Operator shall take reasonable precautions to prevent its
staff, labour or other Persons from removing or damaging any such article or thing. The
47
Operator shall, immediately upon discovery of such article or thing, notify ISGS’s
Representative, who may issue instructions for dealing with it. ISGS shall be responsible for
any coordination / liaison with a third party for evacuation of such above mentioned articles
or things.
21.4 Governing Law and Jurisdiction
This BOOT Contract and the rights and obligations of the Parties hereunder shall be governed
by and construed in accordance with the laws of Pakistan. The competent Courts of Pakistan
shall have jurisdiction in all matters relating to the BOOT Contract.
21.5 Amendment
This BOOT Contract can be amended only by agreement between the Parties in writing,
executed by a duly authorized representative of each of the Parties. No amendment of the
Transportation Agreement shall increase the liability of ISGS under this BOOT Contract,
unless such amendment is approved in writing by ISGS.
21.6 Third Parties
This BOOT Contract is intended solely for the benefit of the Parties, and nothing in this
BOOT Contract shall be construed to create any rights in, duty to, standard of care to, or any
liability to, any Person not a Party.
21.7 No Waiver
21.7.1. No waiver by either Party of any default or defaults by the other Party in the performance of
any of the provisions of this BOOT Contract:
21.7.1.1 shall operate or be construed as a waiver of any other or further default whether of a
like or different character; or
21.7.1.2 shall be effective unless in writing duly executed by a duly authorized representative
of such Party.
21.7.2. Neither the failure by either Party to insist on any occasion upon the performance of the
terms, conditions and provisions of this BOOT Contract, nor time or other indulgence granted
by one (1) Party to the other, shall act as a waiver of such breach or acceptance of any
variation or the relinquishment of any such right or any other right hereunder, which shall
remain in full force and effect.
21.8 Relationship of the Parties
This BOOT Contract shall not be interpreted or construed to create an association, joint
venture, or partnership between the Parties or to impose any partnership obligation or liability
upon either Party. Neither Party shall have any right, power or authority to enter into any
agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative
of, or to otherwise bind the other Party.
21.9 Survival
Cancellation, expiration or earlier termination of this BOOT Contract shall not relieve the
Parties of obligations that, by their nature, should survive such cancellation, expiration or
termination, including, without limitation, warranties, remedies, promises of indemnity and
confidentiality.
21.10 Language
The language for the purpose of administering this BOOT Contract shall be English.
48
21.11 Entirety
Upon the occurrence of the Effective Date, this BOOT Contract shall be the full and final
expression of the agreement between the Parties on the matters contained herein. All written
or oral representations, understandings, offers or other communications of every kind between
the Parties in relation to the Pipeline System prior to this BOOT Contract are hereby
abrogated and withdrawn.
21.12 Confidentiality
21.12.1. Each of the Parties and their Contractors, subcontractors, consultants and agents and each of
their respective successors and permitted assigns shall hold in confidence all documents and
other information, whether technical or commercial, supplied to it by or on behalf of the
other Party, relating to the design, construction, insurance, operation, maintenance, transfer,
management and financing of the Pipeline System and/or the Project, and all information and
documents obtained by it in the course of any inspection performed in accordance with the
terms of this BOOT Contract , and shall not, without the consent of the other Party, save as
required by law or appropriate regulatory authorities, prospective lenders to, or investors in
the Operator and their professional advisers, publish or otherwise disclose or use the same
for its own purposes otherwise than as may be required to perform its obligations under this
BOOT Contract . Notwithstanding the above, nothing herein contained shall preclude the
use of provisions similar to those contained in this BOOT Contract and the other Pipeline
System Documents referred to herein and in agreements prepared and issued or to be
prepared and issued in connection with other projects by ISGS.
21.12.2. The provisions of paragraph (a) hereinabove shall not apply to:
21.12.2.1 any information in the public domain otherwise than by breach of this BOOT
Contract; and/or
21.12.2.2 information in the possession of the receiving Party thereof before divulgence as
aforesaid, and which was not obtained under any obligation of confidentiality.
21.13 Successors and Assigns
This BOOT Contract shall be binding upon, and inure to the benefit of, the Parties and their
respective successors and permitted assigns.
21.14 No Liability for Review
No review, non-objection or approval by ISGS or any Relevant Authority of any agreement,
document, instrument, drawing, specifications or design proposed by the Operator shall
relieve the Operator from any liability that it would otherwise have had for its negligence in
the preparation of such agreement, document, instrument, drawing, specification or design or
failure to comply with the applicable Laws of Pakistan with respect thereto, or to satisfy the
Operator’s obligations under this BOOT Contract, nor shall ISGS be liable to the Operator or
any other Person by reason of its review and approval of an agreement, document, instrument,
drawing, specification, or design.
21.15 Affirmation/ Integrity Pact
21.15.1. The Operator has as of the Effective Date provided the Integrity Pact as per Schedule 5 and
further hereby declares that it has not obtained or induced the procurement of this BOOT
Contract, the Transportation Agreement or any contract, consent, approval, right, interest,
privilege or other obligation or benefit related to this BOOT Contract or the Pipeline System
from ISGS or any Public-Sector Entity through any corrupt or illegal business practice.
21.15.2. Without limiting the generality of the foregoing, the Operator represents and warrants that it
has fully disclosed in writing all commissions, brokerage and other fees, and other
49
compensation (other than compensation paid to employees of the Operator for services
provided) paid or payable to any Person within or outside Pakistan in relation to the Pipeline
System and has not given or agreed to give and shall not give, or agree to give to any Person
within or outside Pakistan either directly or indirectly through any natural or juridical Person,
including its Affiliates, employees, agents, associates, brokers, consultants, officers, directors,
promoters, shareholders, sponsors or subsidiaries (and any of their employees, agents,
associates, brokers, consultants, officers, directors, promoters, shareholders or sponsors), any
commission, gratification, bribe, finder’s fee or kickback, whether described as consultation
fee or otherwise, with the object of obtaining or inducing the procurement of this BOOT
Contract or the Transportation Agreement or any contract, right, interest, privilege or other
obligation or benefit related to this BOOT Contract or the Pipeline System from ISGS or any
Public-Sector Entity, except that which has been expressly declared pursuant hereto.
21.15.3. The Operator accepts full responsibility and strict liability for making any false declaration,
not making full disclosure, misrepresenting facts or taking any action likely to defeat the
purpose of the representations and warranties contained herein and the declarations required
hereby. It agrees that any contract, consent, approval, right, interest, privilege or other
obligation or benefit obtained or procured as aforesaid shall, without prejudice to any other
right and remedies available to ISGS, shall be voidable and without legal effect at the option
of ISGS.
21.15.4. Notwithstanding any rights and remedies that are available to and may be exercised by ISGS
in this regard, the Operator agrees to indemnify ISGS for any loss or damage incurred by it on
account of its corrupt business practices and further pay compensation to ISGS in an amount
equivalent to ten (10) times the amount of any commission, gratification, bribe, finder’s fee or
kickback paid or given by the Operator (either directly or indirectly through any natural or
juridical Person, including its Affiliates, employees, agents, associates, brokers, consultants,
officers, directors, promoters, shareholders, sponsors or subsidiaries (and any of their
employees, agents, associates, brokers, consultants, officers, directors, promoters,
shareholders or sponsors), as aforesaid for the purpose of obtaining or inducing the
procurement of this BOOT Contract or the Transportation Agreement or any contract,
consent, approval, right, interest, privilege or other obligation or benefit related to this BOOT
Contract or the Project from ISGS or any Public-Sector Entity.
21.16 Counterparts
This BOOT Contract may be executed in two (2) or more original copies and each such copy
may be executed by each of the Parties in separate counterparts, each of which copies when
executed and delivered by the Parties, shall constitute an original, but all of which shall
together constitute one (1) and the same instrument.
[REMAINDER OF PAGE INTENTIONALLY LEFT BLANK]
50
IN WITNESS WHEREOF, the Parties have entered into this BOOT Contract as of the date first
hereinabove written.
INTER STATE GAS SYSTEMS (PRIVATE) LIMITED
____________________________________________
By:
Title: [Managing Director]
Witness: _____________________________________
Name: _______________________________________
OPERATOR
__________________________________
By:
Title: [Chief Executive Officer]
Witness: _____________________________________
Name: _______________________________________
51
SCHEDULE 1 – PIPELINE SYSTEM DESIGN AND SPECIFICATIONS 5
5 To be added as per Design of selected bidder for the Section.
52
SCHEDULE 2 – DESIGN CAPACITY SCHEDULE AND ANNUAL RESERVED CAPACITY
DESIGN CAPACITY:
[•]6
ANNUAL RESERVED CAPACITY:
1-5 Years 6-10 Years 11-15 years
Annual Reserved Capacity 1.5 MMTPA 2 MMTPA 2.5 MMTPA
6 As per the design submitted by the Selected Bidder.
53
SCHEDULE 3 – ROUTE7
7 To be added as per the relevant Section.
54
SCHEDULE 4 – PROGRAMME8
8 Will be incorporated as submitted by successful bidder in its Technical Bid.
55
SCHEDULE 5 – INTEGRITY PACT
(INTEGRITY PACT)
DECLARATION OF FEES, COMMISSION AND BROKERAGE ETC.
Contract No. Dated
Contract Value:
Contract Title:
by and between:
Inter State Gas Systems (Pvt.) Limited
And
[●]
[●] hereby declares that it has not obtained or induced the procurement of any contract, right, interest,
privilege or other obligation or benefit from Government of Pakistan or any administrative
subdivision or agency thereof or any other entity owned or controlled by it (hereinafter collectively
referred to as the “GOP”) through any corrupt business practice.
Without limiting the generality of the foregoing, [●] represents and warrants that it has fully declared
the brokerage, commission, fees etc. paid or payable to anyone and not given or agreed to give and
shall not give or agree to give to anyone within or outside Pakistan either directly or indirectly
through any natural or juridical person, including its affiliate, agent, associate, broker, consultant,
director, promoter, shareholder, sponsor or subsidiary, any commission, gratification, bribe, finder's
fee or kickback, whether described as consultation fee or otherwise, with the object of obtaining or
inducing the procurement of a contract, right, interest, privilege or other obligation or benefit in
whatsoever form from GOP, except that which has been expressly declared pursuant hereto.
[●] certifies that it has made and will make full disclosure of all agreements and arrangements with
all persons in respect of or related to the transaction with GOP and has not taken any action or will
not take any action to circumvent the above declaration, representation or warranty.
[●] accepts fixed responsibility and strict liability for making any false declaration, not making full
disclosure, misrepresenting facts or taking any action likely to defeat the purpose of this declaration,
representation and warranty. It agrees that any contract, right, interest, privilege or other obligation or
benefit obtained or procured as aforesaid shall, without prejudice to any other right and remedies
available to GOP under any law, contract or other instrument, be voidable at the option of GOP.
Notwithstanding any rights and remedies exercised by GOP in this regard, [●] agrees to indemnify
GOP for any loss or damage incurred by it on account of its corrupt business practices and further pay
compensation to GOP in an amount equivalent to ten time the sum of any commission, gratification,
bribe, finder's fee or kickback given by [●] as aforesaid for the purpose of obtaining or inducing the
procurement of any contract, right, interest, privilege or other obligation or benefit in whatsoever form
from GOP.
Chief Executive Officer
(Operator)
[●]
Managing Director,
Inter State Gas Systems
(Pvt.) Limited
56
SCHEDULE 6 – SBLC
FORM OF STAND BY LETTER OF CREDIT
(to be finalised by ISGS’ Bank(s))
[Date of issue]
STANDBY LETTER OF CREDIT NUMBER [ ]
Dear Sirs,
OIL TRANSPORTATION AGREEMENT DATED [ ]
We refer to the above agreement (“Agreement”) between yourselves (the “Beneficiary”
under this Standby Letter of Credit) and Inter State Gas Systems (Private) Limited (the “Applicant”).
We, [Insert name of the Bank], a banking company incorporated under Companies Ordinance,
1984 (now the Companies Act, 2017) and having valid licence from the State Bank of Pakistan
having its registered office at [Insert address] (the “Issuer”) hereby establish our irrevocable Standby
Letter of Credit No. __________ (“SBLC”), subject to clause 6 below, in the sum of PKR _______/=
(Pak Rupees __________________) (“SBLC Amount”) in favour of the Beneficiary under the
instructions of the Applicant to secure all obligations of the Applicant under the Agreement and we
undertake as follows:
i. to make unconditional payment on demand upon presentation of a signed statement in the
form set out below at (A) of the amount due set out in such statement notwithstanding any
objection or dispute with the Applicant;
ii. to make such payment within two (2) business days of demand;
iii. to permit partial drawings and multiple presentations; and
This SBLC is subject to the following terms:
1. Presentation must be made by paper document in the form set out at Schedule (A) below, at
[insert name of branch] signed by the Beneficiary, for the attention of the Applicant’s account
manager, unless we agree that electronic presentation may be made subject to an authorisation
code provided by us.
2. The expiry date is [ ] ([ ]) months from date of issue (“Expiry Date”) and all claims under
this SBLC must be received on or before the Expiry Date failing which we shall stand
released of all liability hereunder irrespective of whether the original instrument is returned to
us or not.
3. The foregoing cumulative aggregate limit or Expiry Date may be increased or extended by
amendment by notice to the Beneficiary in the form set out below at (B).
4. This SBLC is subject to [UCP 600].
5. Issuer will issue a notice to the Beneficiary thirty (30) days prior to expiry of the SBLC, that
the SBLC is due to expire in 30 days.
57
6. All payments under this SBLC shall be free and clear of, and without deduction for or on
account of, any present or future taxes, duties, charges, fees or withholdings of any nature and
by whomsoever imposed.
ANY CLAIM MADE UNDER THIS SBLC MUST BE IN WRITING AND DELIVERED
TO THE ISSUER'S OFFICE AT ON OR BEFORE UPTO 1.30 P.M.
FOR COMPLETION OF OUR RECORDS, WE REQUEST THE BENEFICIARY TO
RETURN THE ORIGINAL SBLC ON ITS EXPIRY OR UPON FULFILLMENT OF THE
TERMS OF THE SBLC WHICHEVER MAY FIRST OCCUR.
THIS SBLC SHALL BE CONSTRUED IN ACCORDANCE WITH THE LAWS OF
PAKISTAN.
THIS SBLC IS ASSIGNABLE AND TRANSFERRABLE BY THE BENEFICIARY TO ITS
LENDERS. IT MUST BE ENSURED THAT THE TRANSFEREE IS NOT UNDER ANY
SANCTIONS OR EMBARGOES OF THE UNITED NATIONS ORGANISATION,
UNITED STATES OF AMERICA, EUROPEAN MEMBER STATES OR ANY OTHER
ENTITY OR NATION.
OTHER THAN THE CLAUSES MENTIONED ABOVE THE SBLC INSTRUMENT
MIGHT BE ALTERED AT THE TIME OF ISSUANCE TO INCORPORATE THE
POSSIBILITY OF THE ISSUER BEING A SYNDICATE OF FINANCIAL
INSTITUTIONS ACCEPTABLE TO THE BENEFICIARY.
_____________________________
Signature of an authorised signatory
For and On behalf of the Issuer
58
Schedule (A)
Format of Drawing Certificate
[Date]
Drawing under Standby Letter of Credit No. ________________of
(Name of Issuing Bank)
We, ______________, the Beneficiary, hereby make drawing under the subject Standby
Letter of Credit in the sum of ________ (________ only) payable to us as per the provisions of the
Oil Transportation Agreement dated ________ (“Agreement”) executed between us and Inter State
Gas Systems (Private) Limited. The amount of our drawing represents the amount payable by Inter
State Gas Systems (Private) Limited to us in respect of non payment of tariff. In view of the default of
Inter State Gas Systems (Private) Limited to make payment of the applicable amounts due under the
Agreement and pursuant to Standby Letter of Credit No. ____________, we hereby request you to
make payment to our Account No. ______________ with __________ under telex advice to us.
_____________________________
Signature of an authorized signatory
For and on behalf of the Beneficiary
59
Schedule (B)
Form of Notice to the Beneficiary for Extension of the SBLC
[Date of extension]
We refer to our Standby Letter of Credit Number [ ] (“SBLC”). The expiry date
has been extended to [{at least 9 months from date of extension}], and the cumulative aggregate limit
available for drawing under this SBLC is [{being the then current PKR ____________}].
_____________________________
Signature of an authorised signatory
For and on behalf of the Issuer
60
SCHEDULE 7 – FORM OF PRE-COMMISSIONING TEST REPORT9
9 To be as per Technical Requirements.
61
SCHEDULE 8 – FORM OF CERTIFICATE OF ACCEPTANCE10
10 To be as per Technical Requirements and will be design specific. The final format will be approved by ISGS.
62
SCHEDULE 9 –WHITE OIL SPECIFICATIONS
MS SPECIFICATION
Test Title
Specification Limits Test Method
Min. Max.
Color Pink Visual
Appearance Clear and free from
Suspended impurities Visual
Distillation 1 BP 45 °C
ASTM D-86
10% Vol. Recovered @ °C … 80
50% Vol. Recovered @ °C … 125
90% Vol. Recovered @ °C … 180
End Point °C … 205
Residue: Vol.% … 2
Reid Vapour Pressure, @ 37.8°C
9.0 (Mar - Oct)
ASTM D-323
10.0 (Nov - Feb)
Existent Gum, ( Air Jet ) mg/100ml … ASTM D-381
Oxidation Stability, minutes. 240 … ASTM D-525
Total Sulphur wt.% … 0.05 ASTM
D-1266/4294
Lead Content gm pb / Litre … 0.013 IP-352
Copper Corrosion 3Hrs.@ 50 °C … 1 ASTM D-130
Research Octane No. (RON) 87 … ASTM D-2699
Mercaptan Sulphur wt.ppm … 10 ASTM D-3227
Doctor Test Negative ASTM D-4952
Specific Gravity 60/60 °F To be reported ASTM D-1298
Benzene , Vol % … 5 ASTM D-5134
Odour Marketable
63
HSD SPECIFICATION
Test Title
Specification Limit Test Method
Min. Max
Specific Gravity @ 15.6/15.6 °C … 0.87 ASTM D-1298
Distillation 50% Vol. Recovery °C Report ASTM D-86
Distillation 90% Vol. Recovery °C … 365 ASTM 0-86
Colour ASTM … 3 ASTM D-1500
Kinematic Viscosity @ 40°C, cSt 1.5 6.5 ASTM D-445
Flash Point °C 54 … ASTM D-93
Pour Point °C
+6 (March - Oct) ASTM D-97
… +3 (Nov - Feb)
Cloud Point °C
+9 (March - Oct) ASTM D-2500
… +6 (Nov - Feb)
Cold Filter Plugging Point (CFPP). °C
To be reported ASTM D-6371
Conradson Carbon Residue on 10% Distillation Residue, wt.%
… 0.2 ASTM
D-189/4530
Sulphur wt.% / (ppm) … 0.05%
500 ASTM D-4294
Copper strip Corrosion, 3hr @ 100°C
… 1 ASTM D-130
Ash, wt.% … 0.01 ASTM D-482
Water Content, Vol. % … 0.05 ASTM D-95
Sediment by Extraction, wt. % … 0.01 ASTM D-473
Cetane lndex 45 … ASTM D-976
Strong Acid No.mg KOH/g Nil … ASTM
D-974/664
Total Acid No.mg KOH/g … 0.5 ASTM
D-974/664
64
SCHEDULE 10– REQUIRED CONSENTS11
11 As identified by selected bidder and agreed to by ISGS.
65
SCHEDULE 11 –TRANSFER COMPENSATION UPON EARLY TERMINATION
This Schedule explains in a matrix format the amounts payable by the ISGS in connection with a
transfer of the Pipeline System following a termination in accordance with Clause [•]. The
calculations with respect to each such compensation element shall be verified by an international
accounting firm acceptable to the Parties.
TERMINATION EVENT COMPENSATION PAYABLE
1. Termination for an Operator Event of Default
The Operator shall be not be
entitled to any compensation
following an Operator Event of
Default.
[2. Termination for an ISGS Event of Default
ISGS shall pay the depreciated
value of the Pipeline System. For
the purpose of calculation of
depreciated value of the Pipeline
System, the total cost of the
Pipeline System shall be reduced
on straight line basis from the
Commercial Operations Date
through the term of this BOOT
Contract.
3. Termination by the Operator or ISGS following a
Force Majeure Event
ISGS shall pay the depreciated
value of the Pipeline System. For
the purpose of calculation of
depreciated value of the Pipeline
System, the total cost of the
Pipeline System shall be reduced
on straight line basis from the
Commercial Operations Date
through the term of this BOOT
Contract.]
4. Voluntary Termination by ISGS In case ISGS terminates the BOOT
Contract pursuant to the Clause [●]
(Voluntary Termination), ISGS
shall pay the depreciated value of
the Pipeline System. For the
purpose of calculation of
depreciated value of the Pipeline
System, the total cost of the
Pipeline System shall be reduced
on straight line basis from the
Commercial Operations Date
through the term of this BOOT
Contract.
66
Formula:
The depreciated value of the Pipeline System shall be calculated as under:
DV = TC – (TC/15 x (N/12))
Where
DV = Depreciated value of the Pipeline System
TC = Total Cost of the Pipeline System
N = No of Months from the Commercial Operations Date till the time of termination.
67
SCHEDULE 12 – FORM OF IMPLEMENTATION PERFORMANCE BOND
FORMAT OF PERFORMANCE BOND FOR IMPLEMENTATION/ CONSTRUCTION PHASE OF
MACHIKE – TARU JABBA OIL PIPELINE PROJECT (MTOPP)
FOR SECTION 3
(ON NON-JUDICIAL STAMP PAPER @ APPLICABLE RATE, BASED ON
GUARANTEE VALUE)
Inter State Gas Systems (Private) Limited Guarantee No……..……
8th Floor, Petroleum House
Ataturk Avenue, G-5/2, Islamabad, Date of Issue……………
Date of Expiry………….
Amount…………………
Dear Sirs,
Ref: Our Guarantee No. _____________________ in the sum of PKR 500,000,000/- (Pak Rupees
Five Hundred Million Only)_ on behalf of ________________ (“Company”) as Performance Bond
under the BOOT Contract for design, construction and commissioning of Section [•] of Machike –
Taru Jabba Oil Pipeline Project.
In consideration of you having issued the Letter of Intent for implementation of the subject Project the
Company shall furnish you a Performance Bond in the form of bank guarantee for an amount of PKR
500,000,000/- (Pak Rupees Five Hundred Million Only) having validity of twenty-five (25) months
from the date of issue.
AND WHEREAS in consideration of value received from we have agreed to
give the Company the required bank guarantee and we, ____________________ (a banking
company incorporated under ______________ and having valid license from the State Bank of
Pakistan) which expression shall mean and include its successors, administrators and legal
representatives, whether jointly or severally, having its registered office at
______________ (hereinafter called the “Surety”) hereby agree and undertake as follows:
1. To make unconditional, immediate and forthwith payments to you as called upon of an amount
of Pak Rupees 500,000,000/- (Pak Rupees Five Hundred Million Only) on your written FIRST
and SIMPLE demand without further recourse, question, query, deferment, contestation or
reference to the Company or any other person in the event of default, non-performance or non-
fulfillment by the Company of its obligations, liabilities, responsibilities under the said BOOT
Contract of which you shall be the sole and absolute judge.
2. To accept written intimation from you as conclusive, sufficient and final evidence of the
existence of a default or breach as aforesaid on the part of the Company and to make payment
immediately and forthwith upon receipt of your FIRST and SIMPLE written intimation.
3. The Performance Bond shall come into force on the date of the BOOT Contract and shall remain
in full force, operative, effective and binding upon us for up to the Expiry Date, as this may be
extended by the Company from time to time. The Surety shall notify Inter State Gas Systems
(Private) Limited (ISGS) in the event that the Company does not apply for renewal of this
Performance Bond thirty (30) days prior to the Expiry Date of this Performance Bond, as this
may be extended from time to time.
68
4. That no grant of time or other indulgence to, amendment in the terms of the BOOT Contract, or
imposition of the BOOT Contract with the Company in respect of the performance of its
obligation under and in pursuance of said BOOT Contract with or without notice to us, shall in
any manner discharge or otherwise however affect this guarantee and our liabilities and
commitments there under.
5. This Performance Bond shall be binding on us and our successors-in-interest and shall be
irrevocable.
6. This Performance Bond shall not be affected by any change in the constitution of the guarantor
bank or the constitution of the Company.
7. The Surety warrants and represents that it is fully authorized, empowered and competent to issue
this Performance Bond.
8. No delay or failure to exercise any right or remedy under this Performance Bond by ISGS shall
constitute a waiver of such right or remedy. No single or partial exercise of any right or remedy
shall preclude any other or further exercise thereof or of any other right or remedy. No waiver by
ISGS shall be valid unless made in writing and duly signed by concerned representatives of the
ISGS.
9. No set-off counter claim, reduction, or diminution of any obligations that the Surety has or may
have against ISGS shall be available to the Surety against ISGS in connection with any of the
Surety’s obligations to ISGS under this Performance Bond. The Surety shall make all payments
under this Performance Bond in full, without set-off or counter claim and free and clear of any
deductions or withholdings in immediately available, freely transferable, cleared funds for value
on the due date to ISGS, provided that if the Surety is required to make any deduction or
withholding from such payments under applicable law, the Surety shall pay to ISGS such
additional amount necessary to ensure that ISGS receives an amount equal to the amount which
it would have received had no such deduction or withholding been made.
10. The Performance Bond shall be binding upon and inure to the benefit of ISGS and the Surety and
to their respective successors and assigns, provided that the Surety shall not assign or transfer all
or any of its rights, benefits and obligations under this Performance Bond except with the prior
written consent of ISGS. ISGS shall be free to assign its rights, benefits and obligations under
this Performance Bond without permission of the Surety.
11. No payment to ISGS under this Performance Bond pursuant to any judgement or order of any
court or otherwise shall operate to discharge the Surety’s obligations in respect of which it was
made unless and until payment in full shall have been received by ISGS.
12. If one or more of the provisions of this Performance Bond is held or found to be invalid, illegal,
or unenforceable for any reason whatsoever, in any respect, any such invalidity, illegality, or
unenforceability of any provision shall not affect the validity of the remaining provisions of this
Performance Bond.
13. On the anniversary of the issuance of this Performance Bond, or upon its renewal, the Surety will
issue its replacement guarantee or addendum to this effect.
SIGNATURE AND SEAL OF
THE GUARANTOR
69
SCHEDULE 13 – FORM OF OPERATIONS PERFORMANCE BOND
FORMAT OF PERFORMANCE BOND FOR OPERATIONS PHASE OF MACHIKE – TARU
JABBA OIL PIPELINE PROJECT (MTOPP)
FOR SECTION 3
(ON NON-JUDICIAL STAMP PAPER @ APPLICABLE RATE, BASED ON
GUARANTEE VALUE)
Inter State Gas Systems (Private) Limited Guarantee No……..……
8th Floor, Petroleum House
Ataturk Avenue, G-5/2, Islamabad. Date of Issue……………
Date of Expiry………….
Amount…………………
Dear Sirs,
Ref: Our Guarantee No. _____________________ in the sum of PKR 500,000,000/- (Pak Rupees
Five Hundred Million Only) on behalf of ________________ (“Company”) as Performance Bond
under the BOOT Contract for the operation of Section [•] of Machike – Taru Jabba Oil Pipeline
Project.
WHEREAS, in the BOOT Contract dated it has been stipulated that the
Company shall furnish you a Performance Bond in the form of bank guarantee for an amount of PKR
500,000,000/- (Pak Rupees Five Hundred Million Only) having validity of (15) years from the
effective date of the BOOT Contract. The amount of the Performance Bond will be reduced three (03)
percent after completion of each operational year as per attached Schedule.
AND WHEREAS, in consideration of value received from we have agreed to
give the Company the required bank guarantee and we, ____________________ (a banking company
incorporated under ______________ and having valid license from the State Bank of Pakistan)
which expression shall mean and include its successors, administrators and legal representatives,
whether jointly or severally, having its registered office at ______________ (hereinafter
called the “Surety”) hereby agree and undertake as follows:
1. To make unconditional, immediate and forthwith payments to you as called upon the
applicable amount, as per attached Schedule, in Pak Rupees on your written FIRST and
SIMPLE demand without further recourse, question, query, deferment, contestation or
reference to the Company or any other person in the event of default, non-performance or of
the non-fulfillment by the Company of its obligations, liabilities responsibilities under the
operation phase of the BOOT Contract of which you shall be the sole and absolute judge.
2. To accept written intimation from you as conclusive, sufficient and final evidence of the
existence of a default or breach as aforesaid on the part of the Company and to make payment
immediately and forthwith upon receipt of your FIRST and SIMPLE written intimation.
3. The Performance Bond shall come into force on commencement of the operation phase as
stipulated in the BOOT Contract and shall remain in full force, operative, effective and
binding upon us for up to the Expiry Date, as this may be extended by the Company from
time to time. The Surety shall notify Inter State Gas Systems (Private) Limited (ISGS) in the
70
event that the Company does not apply for renewal of this Performance Bond thirty (30) days
prior to the Expiry Date of this Performance Bond, as this may be extended from time to time.
4. That no grant of time or other indulgence to, amendment in the terms of the BOOT Contract
or imposition of the BOOT Contract with the Company in respect of the performance of its
obligation under and in pursuance of said BOOT Contract with or without notice to us, shall
in any manner discharge or otherwise however affect this guarantee and our liabilities and
commitments there under.
5. This Performance Bond shall be binding on us and our successors-in-interest and shall be
irrevocable.
6. This Performance Bond shall not be affected by any change in the constitution of the
guarantor bank or the constitution of the Company.
7. This Surety warrants and represents that it is fully authorized, empowered and competent to
issue this Performance Bond.
8. No delay or failure to exercise any right or remedy under this Performance Bond by ISGS
shall constitute a waiver of such right or remedy. No single or partial exercise of any right or
remedy shall preclude any other or further exercise thereof or of any other right or remedy.
No waiver by ISGS shall be valid unless made in writing and duly signed by concerned
representatives of the ISGS.
9. No set-off counter claim, reduction, or diminution of any obligations that the Surety has or
may have against ISGS shall be available to the Surety against ISGS in connection with any
of the Surety’s obligations to ISGS under this Performance Bond. The Surety shall make all
payments under this Performance Bond in full, without set-off or counter claim and free and
clear of any deductions or withholdings in immediately available, freely transferable, cleared
funds for value on the due date to ISGS, provided that if the Surety is required to make any
deduction or withholding from such payments under applicable law, the Surety shall pay to
ISGS such additional amount necessary to ensure that ISGS receives an amount equal to the
amount which it would have received had no such deduction or withholding been made.
10. The Performance Bond shall be binding upon and inure to the benefit of ISGS and the Surety
and to their respective successors and assigns, provided that the Surety shall not assign or
transfer all or any of its rights, benefits and obligations under this Performance Bond except
with the prior written consent of ISGS. ISGS shall be free to assign its rights, benefits and
obligations under this Performance Bond without permission of the Surety.
11. No payment to ISGS under this Performance Bond pursuant to any judgement or order of any
court or otherwise shall operate to discharge the Surety’s obligations in respect of which it
was made unless and until payment in full shall have been received by ISGS.
12. If one or more of the provisions of this Performance Bond is held or found to be invalid,
illegal, or unenforceable for any reason whatsoever, in any respect, any such invalidity,
illegality, or unenforceability of any provision shall not affect the validity of the remaining
provisions of this Performance Bond.
13. On the anniversary of the issuance of this Performance Bond, or upon its renewal, the Surety
will issue its replacement guarantee or addendum to this effect.
71
REDUCTION SCHEDULE OF
OPERATIONAL PHASE
PERFORMANCE BOND (BANK GUARANTEE)
S. No. End of Each Operational
Year Amount of Performance Bond
Reduced Available Amount of
Performance Bond
1. Start of Operational Phase
2. One (01)
3. Two (02)
4. Three (03)
5. Four (04)
6. Five (05)
7. Six (06)
8. Seven (07)
9. Eight (08)
10. Nine (09)
11. Ten (10)
12. Eleven (11)
13. Twelve (12)
14. Thirteen (13)
15. Fourteen (14)
16. Fifteen (15)
SIGNATURE AND SEAL OF
THE GUARANTOR
72
SCHEDULE 14 – ENTRY POINT, EXIT POINT AND OFFTAKE POINT(S)12
12 To be added for each Section.
73
SCHEDULE 15 –TECHNICAL REQUIREMENTS13
(As attached)
13 To be attached as per the Technical Requirements for the Pipeline System for each Section. The Technical Requirements are deemed modified to be consistent with the clarifications provided to the Prospective Bidders on Bidders’ queries.
74
SCHEDULE 16 – FORM OF SPONSOR UNDERTAKING
Undertaking
(Draft - to be issued by Sponsor)
This Undertaking is executed on this [●] day of [●], by [●] having its registered office at [●]
(hereinafter the “Sponsor”),
In favour of,
Inter State Gas Systems (Private) Limited, having its registered office at [●] (hereinafter “ISGS”),
WHEREAS, as required under the Build, Own, Operate and Transfer Contract (the “BOOT
Contract”) entered into or about to be entered into between ISGS and [●] (the “Operator”), the
Sponsor hereby undertakes to ISGS not to permit a Change of Ownership (as defined hereunder) as
set out in this Undertaking:
NOW THIS UNDERTAKING WITNESSETH AS UNDER:
1. All capitalized terms not defined herein shall be read in accordance with and as defined in the
BOOT Contract and provided that “Change of Ownership”, shall mean:
(a) any sale, transfer or disposal of, or the creation of, any legal, beneficial or equitable
interest in or over, any or all of the shares or shareholder loans in the Operator
(including the transfer or the ceding of control, whether by proxy, contract, agency or
otherwise, over the exercise of voting rights conferred on those shares, or over the
right to appoint or remove directors or other officers or over the rights to receive
distributions or the debt service in respect of such shareholder loans); and/or
(b) any other arrangements that have or may have or which result in the same effect as
above including, without limitation, the grant of security over any such shares or
rights attaching thereto or shareholder loans.
2. That the Sponsor shall not initiate during the Implementation Period and a period of five (05)
Years from the Commercial Operations Date, a Change of Ownership in the Operator, except
that the shares of the Operator may be pledged or charged to the Lenders, as permitted under
the BOOT Contract.
3. That the Sponsor shall not divest more than 49% of its shareholding in the Operator for the
remainder of the Term, except that the shares of the Operator may be pledged or charged to
the Lenders, as permitted under the BOOT Contract.
_____________________________
For [●]