FOOD CORPORATION OF INDIA ZONAL OFFICE (WEST) 2ND...
Transcript of FOOD CORPORATION OF INDIA ZONAL OFFICE (WEST) 2ND...
ZO CCTV Tender Finalization Committee (Sec/CCTV Performance Report/WZ/2014 dated 19.10.2015
FOOD CORPORATION OF INDIA
ZONAL OFFICE (WEST)
2ND FLOOR, RAJENDRA NAGAR, DATTAPADA ROAD, BORIVALI (EAST), MUMBAI – 400 066
LIMITED e-TENDER
Food Corporation of India invites Limited Bid enquiries through e-Tendering for Supply, Installation, Testing, Commissioning and Maintenance of CCTV surveillance system at warehouse/Depots of Food Corporation of India
which are specified in Annexure VI, from CPSUs listed below:
List of CPSUs:
1. M/s Broadcasting Engineering Consultants India Ltd., New Delhi.
2. M/s Electronics Corporation of India Ltd., New Delhi
3. M/s Bharat Electronics Limited, Bangalore.
4. M/s ITI Ltd. New Delhi.
5. M/s Telecommunications Consultants India Ltd., New Delhi
6. M/s Central Electronics Ltd., Sahibabad, UP.
ZO CCTV Tender Finalization Committee (Sec/CCTV Performance Report/WZ/2014 dated 19.10.2015
DISCLAIMER
Food Corporation of India (FCI) invites Tender for supply, installation, testing, commissioning and maintenance of CCTV surveillance system at Warehouse/Depots of Food Corporation of India (FCI) which are listed in
Annexure VI.
This document has been prepared on the basis of information available with the
CORPORATION and other publicly available documents which CORPORATION
believes to be reliable. The sole objective of this Bid document is to solicit Techno-
commercial offers from interested parties. While this document has been
prepared in good faith, no representation or warranty, express or implied, is or
will be made, and no responsibility or liability will be accepted by the
CORPORATION or any of their employees, advisors or agents as to or in relation
to the accuracy or completeness of this document and any liability thereof is
hereby expressly disclaimed. Interested Parties may carry out their own
study/site visit(s)/analysis/ investigation as required before submitting their
Techno commercial proposals.
This document does not constitute an offer or invitation, or solicitation of an
offer, nor does this document or anything contained herein, shall form a basis of
any contract or commitment whatsoever. The Corporation may in its absolute
discretion, but without being under any obligation to do so, update, amend or
supplement the information in this Bid document. By downloading the
document, the interested party is subjected to the confidentiality clauses.
ZO CCTV Tender Finalization Committee (Sec/CCTV Performance Report/WZ/2014 dated 19.10.2015
INDEX
Sr. No. Name of the Content Page No.
From TO
1 Notice Inviting Tender 4 7
2 Section–I General Instructions , Terms And Conditions
8 14
3. Section –II Terms And Conditions Governing The Contract
15 22
4. Section -III
Scope Of work 23 26
5. Section –IV (Technical Bid, Price bid) Pro-forma for compliance of Technical specifications (Annexure –I)
27 29
6. Pro-forma for Price bid (Annexure –II)
30 31
7. Pro-forma for Agreement
( Annexure –III)
32 32
8. Pro-forma for Performance Bank Guarantee (Annexure-IV)
33 35
9. Undertaking for unconditional acceptance of terms and conditions of the tender document
(Annexure-V)
36 37
10. List of warehouse/Depots ( Annexure VI) 38 42
ZO CCTV Tender Finalization Committee (Sec/CCTV Performance Report/WZ/2014 dated 19.10.2015
NOTICE INVITING LIMITED E-TENDER
Bid Notification No.: Sec/CCTV Performance Report/WZ/2014 Dated: 09.11.2015 “THROUGH LIMITED TENDER PROCESS”
I. Food Corporation of India (FCI) invites Bid enquiries through e-tendering from six CPSUs
listed at point no. 2.0 below, for supply, installation, testing, commissioning and maintenance of CCTV surveillance system at warehouse/Depots of Food Corporation of India (FCI) mentioned at Annexure VI.
Items Details
Scope of work For Supply, Installation, Testing,
Commissioning And Maintenance of CCTV surveillance system at warehouse/Depots of Food Corporation of India (FCI) and as detailed in Section – III
Tender Type Limited e-tendering under two bid system.
Tender Notice Tender document shall be available at /downloaded from www.fciweb.nic.in & eprocure.gov.in
Estimated Value of the Contract Rs 5.12 Crore [Rs Five Crore and twelve lakh only]
Earnest Money Deposit Rs 10.00 Lakhs [Rs Ten Lakh only] through Electronic Clearing System(ECS)
Pre-bid Meeting 17-11-2015 (11 AM)
Schedule of Bid Submission
Last date and time for submission of Technical & Price bids
30-11- 2015
(up to 3 pm)
Date and time for opening of the Technical bid
30-11- 2015
(3:30 pm)
Date and time for opening of the Price bid
Will be intimated later
Bid validity period 60 days [+ 30 days] from the bid opening date
ZO CCTV Tender Finalization Committee (Sec/CCTV Performance Report/WZ/2014 dated 19.10.2015
Note:
1. FCI is using services of e-Procurement platform of CPP Portal for the
purpose of this tender. The Bidders who wish to participate in the e-Tender shall have to register themselves in the e-Procurement platform
https://eprocure.gov.in/eprocure/app which is free and shall complete necessary formalities as prescribed.
2. The Bidders may contact CPP Portal help line , with regard to technical
issues relating to functioning of their e-Procurement platform or any doubts regarding online submission of Tender document may contact toll
free number : 1800 233 7315.
3. The Tender Document and other detailed terms & conditions are available
in the Food Corporation of India website www.fciweb.nic.in (for reference only) as well as at https://eprocure.gov.in/eprocure/app (for reference and online tendering).
4. The bid can only be submitted online after uploading all the mandatory document(s)/appendices of tender, as specified. Bidder shall upload all
the document(s) duly signed in the form of JPG format and/or PDF format. All the supporting documents shall be duly signed, scanned &
uploaded by the bidder accurately in a legible format. Any alterations/over-writing should be duly signed by the authorized signatory. Corporation may call for original document(s) for verification
purpose(s) at any point of time.
5. Bid(s) not accompanied by duly signed mandatory document(s) shall not
be accepted. Bid(s) which do not comply given instructions shall be summarily rejected.
6. Tender shall be electronically submitted (on-line through internet) within
the prescribed date and time as mentioned in the Tender document and
e-Procurement portal.
7. After opening of the bid, the BIDDERS‟ can login and see the bidding
process & the bidder will receive the competitor bid sheet.
8. Complete Tenders under TWO BID SYSTEM to be received ONLY on CPP
Portal, website „https://eprocure.gov.in/eprocure/app‟, at the fixed time and the date as indicated above. The Bidder will be at liberty to be present either in person or through an authorized representative at the
time of opening of the Bid.
ZO CCTV Tender Finalization Committee (Sec/CCTV Performance Report/WZ/2014 dated 19.10.2015
9. Bidders are advised to follow the instructions provided in the „Instructions
to the Bidders for the e-submission of the tenders online through the Central Public Procurement Portal for e-Procurement at
„https://eprocure.gov.in/eprocure/app‟.
10. Bank details of FCI ,ZO, Mumbai for remitting EMD:
Name of Bank : STATE BANK OF INDIA, BORIVALI (EAST) IFSC Code : SBIN0004666
Account No : 00000010816217209
Type of A/C : Cash Credit Account
11. Food Corporation of India reserves the right to reject any or all the tenders and / or cancel the Tender enquiry at any stage without assigning
any reason.
12. No negotiations will be entertained with any of the bidder(s).
ZO CCTV Tender Finalization Committee (Sec/CCTV Performance Report/WZ/2014 dated 19.10.2015
II. Following documents duly signed and scanned to be uploaded along with Technical bid:
1. Authorization letter/Resolution from the Competent Authority/Board of
Directors‟ in favor of the officer signing the bid declaring him/her as Authorized Signatory
2. Compliance of Technical specifications i.e. Annexure –I of Section IV
duly signed by authorized signatory.
3. Undertaking For Unconditional Acceptance of Terms & Conditions of the Tender Document as per Annexure-V of Section IV duly signed by the
authorized signatory 4. One copy of Cancelled Cheque as a reference for e-payment by the
Corporation 5. Proof of remittance of EMD.
III. Price bid as per Annexure-II of Section IV of the tender should be uploaded in the prescribed format.
IV. The Tenders will be opened in Zonal Office(W), Food Corporation of India, 2nd Floor,
Rajendra Nagar, Dattapada Road, Borivali, Mumbai – 400 066 on the date and time as
mentioned in Tender, in the presence of bidders‟ representatives who wish to be present at their own cost.
1. In case the day for opening of Tender becomes holiday, the Tenders will
be opened at the same specified time on next working day. Further, in case of any change of venue, date & time, the same will be intimated
separately. Bidder shall submit the Bid in accordance with clause no. 9 of Section-I of Bid Document.
2. Corporation reserves the right to extend the last date and time for
submission of filled Bid.
Executive Director (West Zone), Food Corporation of India, 2nd Floor, Rajendra Nagar,
Dattapada Road, Borivali (East),
Mumbai – 400 066
Tel: 022 – 28702171 022-28707084
Email ID: [email protected]
8
SECTION–I
GENERAL INSTRUCTIONS, TERMS AND CONDITIONS
1. COMPANY PROFILE
The Food Corporation of India was setup under the Food Corporation's Act 1964 in order to fulfill following objectives of the Food Policy: (i) Effective price support operations for safeguarding the interests of the farmers. (ii) Distribution
of food-grains throughout the country for public distribution system & (iii) Maintaining satisfactory level of operational and buffer stocks of food-grains to
ensure National Food Security.
2. OBJECTIVE OF CONTRACT
To ensure uninterrupted, effective, clear and proper capturing of video images of identified locations for the designated depot premises, so as to have continuous display/storage of such image/data and its retrieval as and when required for
effective security surveillance.
3. SCOPE OF WORK
1. Supply, Installation, Testing, Commissioning and Maintenance of CCTV surveillance system at warehouse/Depots of Food Corporation of India (FCI)
which are listed in Annexure VI of this bid document as per the technical specifications mentioned herein. However, the number of CCTVs to be installed may be increased/ decreased at the discretion of the FCI depending
upon the operational/site requirement. Please refer Section –III of the tender for detailed scope of work.
2. The scope of the proposal shall be on the basis of a single Bidder's
responsibility, completely covering all the works as specified under the scope of work mentioned in the Bid Documents. Bids not covering the entire Scope of Work shall be treated as incomplete and shall be rejected.
4. PLACE OF WORK
Warehouse/Depots of Food Corporation of India, as per the list given at
Annexure -VI of Section-IV.
5. PERIOD OF CONTRACT:
The entire CCTV System shall be under comprehensive onsite warranty for a
period of (01) one year from the date of successful commissioning of CCTV
surveillance system. Thereafter the CCTV System shall be under comprehensive
onsite Annual Maintenance Contract (AMC) for a period of (04) four years
commencing from the date of completion of warranty period.
9
6. DUE DILIGENCE
The Bidder is expected to examine all instructions, forms, terms, conditions and specifications in this Bid document. Bid shall be deemed
to have been made after inspection of various sites and careful study and examination of this document with full understanding of its implications. The Bid should be precise, complete and strictly in the prescribed format
as per the requirement of this tender. Failure to furnish all information required by this bid document or submission of a Bid not as per this
document will be at the bidder‟s risk and shall result in rejection of the Bid and the decision of the Corporation in this regard will be final, conclusive and binding.
7. AUTHORIZED SIGNATORY
7.1 Persons signing the tender shall have the authority/authorization by way of Board Resolution/Authorization Letter of competent authority
and shall state in what capacity he/she or they is / are signing the tender e.g. as a Secretary/Manager/Director etc., of a Central Public
Sector Unit. Bid should be signed by authorized officer and shall affix the Seal of the CPSU.
7.2 The bidders shall authorize a person(s) who will be responsible for the
management and control of the work relating to the contract during the tenure of the contract. The person so authorized shall be deemed to have power of attorney from the bidders in respect of the contract
and whose act shall be binding on the bidders.
8. ESTIMATED VALUE OF THE CONTRACT, EARNEST MONEY DEPOSIT(EMD) &
PERFOMANCE BANK GUARANTEE (PBG)
8.1 The estimated value of the contract is Rs 5.12 Crore [Rs Five Crore and twelve lakh only].
8.2 Each tender must be accompanied by an Earnest Money Deposit of
Rs 10,00,000/- [Rs Ten Lakh only] through Electronic Clearing
System(ECS) in favour of “Food Corporation of India”, Mumbai [State Bank of India, Borivali(East) (Account No.
00000010816217209 IFSC Code: SBIN0004666)].
8.3 The bidder shall be permitted to bid on the express condition that in
case he resiles or modifies his offer, or terms & conditions thereof, after submitting his tender, for him/her is found to be incorrect or false, the Earnest Money Deposited by him shall stand forfeited,
without prejudice to any other rights and remedies of the Corporation
10
under the Contract and Law, and the Bidder will be liable for any loss
suffered by the Corporation on account of its withdrawal/modification etc. besides forfeiture of EMD. He will also be debarred for participating in any other Tender Enquiry with FCI
for a period of three years.
8.4 The Earnest Money shall be returned to all technically disqualified
bidders within a period of 15 (fifteen) days from the date of their technical disqualification. In case of other unsuccessful bidders, EMD shall be returned within a period of 15 (fifteen) days from the
date of opening of price bid(s). The EMD in case of the successful bidder shall be returned within 15 (fifteen) days from the date of submission of Performance Bank Guarantee (PBG). No interest,
whatsoever, shall be payable on the EMD.
8.5 The successful Bidder shall have to submit a performance bank guarantee as per Annexure-IV from a Scheduled bank in India equivalent to 15% of the actual tendered value. This will be
submitted within 30 (thirty) days from the date of issuance of acceptance letter by the Corporation and shall remain valid for the
entire contract period, including the extended period (if any), plus for a period of 90 (ninety) days after the expiry of the contract period. In case of failure of the successful bidder to furnish the PBG within the
prescribed time-frame, EMD is liable to be forfeited, without prejudice to any other rights and remedies of the Corporation under the Contract and Law, and the Bidder will be liable for any loss suffered
by the Corporation on this account. The bidder shall also be debarred from participating in any other Tender Enquiry with FCI for a period
of three years.
8.6 All incidental charges whatsoever such as premium; commission etc. with respect to the performance bank guarantee (PBG) shall be borne
by the bidder. If the project implementation period is delayed, the PBG shall be extended by the bidder for such additional duration. The performance bank guarantee may be discharged/ returned by
FOOD CORPORATION OF INDIA upon being satisfied that there has been due performance of the obligations of the bidder under the agreement. However, no interest shall be payable on the performance
bank guarantee.
8.7 In the event of the bidder being unable to service the agreement for
whatever reason, FOOD CORPORATION OF INDIA would invoke the PBG. Notwithstanding and without prejudice to any rights whatsoever of FOOD CORPORATION OF INDIA under the agreement
in the matter, the proceeds of the PBG shall be payable to FOOD CORPORATION OF INDIA as compensation resulting out of the
bidder‟s failure to perform/comply its obligations under the
11
agreement. FOOD CORPORATION OF INDIA shall notify the bidder
in writing of the exercise of its right to receive such compensation within 15 (Fifteen) days, indicating the contractual obligation(s) for which the bidder is in default.
8.8 The Performance Bank Guarantee would be invoked by the Corporation under the following conditions:-
i) The Bidder fails to conform to the terms and conditions of the tender document to the complete satisfaction of the Corporation.
ii) The Bidder fails to maintain strict confidentiality of all the
documents, information, data coming in possession of the Bidder
as a result of awarding the contract and also any oral, written or other information disclosed for evaluation or for any other purposes.
9. BIDDING PROCESS
9.1 Bidders are advised to study the Bid Document carefully.
Submission of the Bid will be deemed to have been done after careful study and examination of all instructions, terms and required specifications in the tender document with full understanding of its
implications. Bids not complying with all the given clauses in this tender document are liable to be rejected. Failure to furnish all
information required in the tender Document or submission of a bid not substantially responsive to the tender document in all respects will be at the bidder‟s risk and may result in the rejection of the bid.
9.2 FCI is using services of e-Procurement platform of CPP Portal for the purpose of this tender. The Bidders who wish to participate in the e-Tender shall have to register themselves in the e-Procurement
platform https://eprocure.gov.in/eprocure/app which is free and shall complete necessary formalities as prescribed.
9.3 The Bidders may contact CPP Portal help line , with regard to technical issues relating to functioning of their e-Procurement
platform or any doubts regarding online submission of Tender document may contact toll free number : 1800 233 7315.
9.4 The Tender Document and other detailed terms & conditions are available in the Food Corporation of India website www.fciweb.nic.in
(for reference only) as well as at https://eprocure.gov.in/eprocure/app (for reference and online tendering).
12
9.5 The bid can only be submitted online after uploading all the
mandatory document(s)/appendices of tender, as specified. Bidder shall upload all the document(s) duly signed in the form of JPG format and/or PDF format. All the supporting documents shall be
duly signed, scanned & uploaded by the bidder accurately in a legible format. Any alterations/over-writing should be duly signed by
the authorized signatory. Corporation may call for original document(s) for verification purpose(s) at any point of time.
9.6 Bid(s) not accompanied by duly signed mandatory document(s) shall not be accepted. Bid(s) which do not comply given instructions shall
be summarily rejected.
9.7 Tender shall be electronically submitted (on-line) within the
prescribed date and time as mentioned in the Tender document and e-Procurement portal.
9.8 After opening of the bid, the BIDDERS‟ can login and see the details of bidding & the bidder will receive the competitor bid sheet.
9.9 Complete Tenders under TWO BID SYSTEM to be received ONLY on
CPP Portal, website „https://eprocure.gov.in/eprocure/app‟, at the
fixed time and the date as indicated above. The Bidder will be at liberty to be present either in person or through an authorized
representative at the time of opening of the Bid.
9.10 Bidders are advised to follow the instructions provided in the
„Instructions to the Bidders for the e-submission of the tenders online through the Central Public Procurement Portal for e-Procurement at „https://eprocure.gov.in/eprocure/app‟.
9.11 Food Corporation of India reserves the right to reject any or all the
tenders and / or cancel the Tender enquiry at any stage without assigning any reason.
9.12 No negotiation will be entertained with any of the bidder(s).
10. MODIFICATION AND WITHDRAWAL OF BIDS
No Bid can be withdrawn or modified in the interval between the Bid submission deadline and the expiration of the Bid validity period specified
in Bid documents. Withdrawal or modification of a Bid during this interval shall result in Bidder‟s forfeiture of its EMD.
13
11. BID OPENING AND EVALUATION
11.1 The Corporation will open Technical Bid in the presence of Bidder‟s
representatives who choose to attend the opening at the time, on the date and at the place specified in the bid at their own cost.
Bidder‟s representatives shall sign a register as a proof of their attendance. In the event of the specified date for the opening of tenders being declared holiday for the FCI, the Tenders will be
opened at appointed time on the next working day.
11.2 Prior to the detailed evaluation, the Corporation will determine
whether each Bid is prima facie complete and is substantially responsive to the bidding documents. For purposes of this
determination, a substantially responsive Bid is one that conforms to all the terms, conditions and specifications of the bidding documents.
11.3 Bids with any deviations, objections to or reservations on provision of terms and conditions of tender will be treated as non-responsive.
12. ACCEPTANCE OF BIDS
12.1 The Executive Director, Zonal Office (West), Mumbai for and on behalf of the Corporation reserves the right to reject any or all the bids, without assigning any reasons thereof and does not bind
himself to accept the lowest or any other tender. When a Bid is accepted, the successful Bidder will be advised for the acceptance of
his Bid by a letter as formal „Acceptance of bid‟.
12.2 The Corporation reserves the right to award the work for all items of
schedule or anyone/few of them by dropping the rest of items of schedule of operations for which rates are called for herein. The decision of the Executive Director, Zonal Office (West), Mumbai, shall
be final and binding on the bidder.
13. VALIDITY OF THE BID
13.1 The Bid should be kept valid for a period of 60 days from the date
set for opening of Technical Tenders.
13.2 In exceptional circumstances, prior to expiry of the original Bid
validity period, the Corporation, at its discretion, may extend the validity period beyond 60 days for a further period of 30 days and the same shall be binding on the Bidder.
14
13.3 The Bid valid for a period shorter than specified period shall
be rejected.
14. LIQUIDATED DAMAGES POST COMMISSIONING AND ACCEPTANCE OF
CCTV SYSTEM (FOR NON-PERFORMANCE)
In case of any item becoming out of order or defective, or major defects noticed which cause complete/partial dislocation of system during the
currency of the contract and the defects are not attended and rectified by the contractor within a period of 48 (FORTY EIGHT) hours from the time of receipt of intimation from the Corporation or its authorized
representative, a penalty at Rs.200/- per day for the number of days for which the system remains out of order or the expenditure incurred by the
FCI for rectification of the system through other agencies beyond the period of 48 (FORTY EIGHT) hours whichever is higher will be levied on the bidder. The compensation for such rectification of system got done by the
FCI will be made within 10 (ten) days by the bidder failing which the said amount will be adjusted from any amount due / withheld under terms of
payment. If the defect is rectified by replacing the item (defective) by compatible and equivalent or higher specification, the defect shall be considered to be resolved. However, in such cases, the penalty levied on
account of delay in attending the defect(s) shall not be refunded.
15. EXECUTIVE DIRECTOR(WEST ZONE)’S DECISION 15.1 In respect of all matters which are left to the decision of
EXECUTIVE DIRECTOR (WEST ZONE) including the granting or with-holding of the certificates, the EXECUTIVE DIRECTOR (WEST ZONE) shall, if required to do so by the bidder, give in
writing a decision thereon.
15.2 If, in the opinion of the Bidder, a decision made by the EXECUTIVE DIRECTOR (WEST ZONE) is not in accordance with the meaning
and intent of the Contract, the Bidders may file with the EXECUTIVE DIRECTOR (WEST ZONE) within seven (7) days after receipt of decision, a written objection to the decision.
Failure to file an objection within the allotted time will be considered as an acceptance of the EXECUTIVE DIRECTOR (WEST ZONE) decision and the decision shall become final and
binding.
EXECUTIVE DIRECTOR (WEST ZONE)
15
SECTION –II
TERMS AND CONDITIONS GOVERNING THE CONTRACT
1. DEFINITIONS
(i) Supply, Installation, Testing, Commissioning & Maintenance of CCTV
surveillance system shall mean the supply, installation, testing,
commissioning & Maintenance of CCTV surveillance system as per
the Corporation requirement and complete in all respects.
(ii) The term „CONTRACT‟ shall mean and include the invitation to Bid,
incorporating also the instructions to bidders, the Bid, its Annexures, appendices and schedules, acceptance of Bid and such general and special conditions as may be added to it.
(iii) Contractor / Supplier / Bidder/ Vendor shall mean the Bidder whose Bid will be accepted by the Corporation for the award of the Works and shall include such successful Bidder‟s legal representatives,
successors and permitted assigns.
(iv) The term „CORPORATION‟ or „FOOD CORPORATION OF INDIA‟ wherever occurs shall mean the FOOD CORPORATION OF INDIA
established under FOOD CORPORATION ACT 1964 and shall include its administrators, successors and assigns. It will also be called FCI.
(v) „EXECUTIVE DIRECTOR‟ shall mean the Executive Director (West
Zone) of FOOD CORPORATION OF INDIA or any person authorized by him on his/Corporation‟s behalf.
(vi) „SERVICES‟ shall mean the performance of any of the items of work
enumerated in schedule of services including such auxiliary, additional and incidental duties, services and operations as may be indicated by the Executive Director, Zonal Office (West), Mumbai or
any person authorized by him on his/Corporation‟s behalf.
(vii) „Warehouse or Depot‟ shall mean Storage Complexes comprising of Godowns/Sheds where food-grains are stored, Weigh-bridge, office
block etc.
(viii) „Depot Manager‟ shall mean the officer-in-charge of the Warehouse or Depot.
16
2. COMMISSIONING OF CCTV SURVEILLANCE SYSTEM AT ALL THE
LOCATION
The bidder shall complete the work including training within 04
(four) months from the date of signing of the agreement.
3. WARRANTY
The successful bidder shall provide a comprehensive onsite warranty for duration of one year for the material supplied &
installed from date of commissioning.
4. EXTENSION
On completion of one year warranty period and four year AMC period, Corporation shall be free either to continue with the bidder
by extending the arrangements for another one year or to part ways with the bidder after giving three month advance notice and engage
another agency as may be decided by it. The payment for the extension period shall be released as per mutually agreed rate and other terms and conditions shall remain same.
5. PAYMENT TERMS
5.1 The payment shall be made as per following schedule:
Sl. No.
Activity Payment to be released
Documents to be submitted by the bidder 1 Supply,
Installation, Testing and Commissioning
60% of total cost Submission of bill along with certificate regarding successful completion of work issued by Depot Manager and counter signed by concerned Area Manager.
2 On completion of 1st
year
8% of total cost Submission of certificate of successful operation during the time period issued by Depot Manager and counter signed by concerned Area Manager.
3 On completion of 2nd
year
8% of total cost Submission of certificate of successful operation during the time period issued by Depot Manager and counter signed by concerned Area Manager.
17
4 On completion of 3rd
year
8% of total cost Submission of certificate of successful operation during the time period issued by Depot Manager and counter signed by concerned Area Manager.
5 On completion of 4th
year
8% of total cost Submission of certificate of successful operation during the time period issued by Depot Manager and counter signed by concerned Area Manager.
6 On completion of 5th
year
8% of total cost Submission of certificate of successful operation during the time period issued by Depot Manager and counter signed by concerned Area Manager.
5.2 No advance payments will be made.
5.3 The payment shall be made through E-Payment system only.
5.4 The bidder should submit bills as per clause 5.1 above but not later than
two months from the date of expiry of the contract to the concerned
General Manager (Region), FCI, Raipur/Bhopal/Mumbai/Ahmedabad.
5.5 Taxes as applicable from time to time as per the Income Tax Act will be
deducted from the bills. In case the bidder is exempted from deduction of
Income Tax, then he is required to produce a certificate from the Income
Tax Authority indicating clearly that no tax at source be deducted from
the bidder against the said contract. Such a certificate shall have to be
obtained at the commencement of each Financial Year.
5.6 Service Tax or any other Tax in lieu thereof levied by the Central Govt.
from time to time on the Services rendered by the Contractor to FCI shall
be paid by Corporation to the Contractor over and above the Schedule
of Rates, subject to the Contractor submitting his Bills/Invoices thereof
in the Format prescribed under Rule 4A (1) of the Service Tax Rules,
1994 or other relevant Laws, as the case may be.
18
5.7 The bidder may raise Region-wise bill for Supply, Installation, Testing &
Commissioning after completion of work in a particular Region.
5.8 The rates quoted by the bidder and accepted by the Corporation and
incorporated in the contract agreement shall remain applicable during
the period of the contract.
5.9 The Corporation shall not be liable for payment of any interest on any
bill outstanding for payment for any reasons, whatsoever.
6. TERMINATION
6.1 Corporation may terminate this agreement at any point of time in the
event of material breach of the agreement by the other party.
Corporation may also terminate the contract in the event of the
bidder having been adjudged insolvent or going into liquidation or
winding up their business or making arrangements with their
creditors or failing to observe any of the provisions of this contract or
any of the terms and conditions governing the contract.
6.2 Corporation without prejudice to any other rights or remedies under
the contract shall have the right to get balance work at the risk and
cost of the bidder and to claim from the bidder any resultant loss
sustained or costs incurred besides forfeiting Performance Bank
Guarantee for the balance work.
6.3 In the event corporation terminates the contract in whole or in part,
pursuant, corporation may procure, upon such terms and in such
manner, as it deems appropriate, Goods or Services similar to those
undelivered, and the Bidder shall be liable to corporation for any
excess costs for such similar goods or services. However, the bidder
shall continue the performance of the contract to the extent not
terminated.
7. NON-PERFORMANCE
The non-performing and defaulting Bidder shall be DEBARRED and shall
be suspended / banned from participating in all the Corporation Bid inquiries for a period of three years. The decision of the Executive Director
(West Zone) shall be final and binding in this regard.
19
8. FORCE MAJEURE
8.1 The Bidder shall not be liable for forfeiture of its Performance Bank
Guarantee (PBG), liquidated damages or termination for default, if and
to the extent that it‟s delay in performance or other failure to perform its obligations under the contract is the result of an event of force
majeure.
8.2 For purposes of this clause, “Force Majeure” means an event beyond the control of the Bidder and not involving bidder‟s fault or negligence.
Such events may include, but are not limited to wars or revaluations, fires, floods, epidemics, quarantine restrictions and freight embargoes.
8.3 The party unable to fulfill its obligations due to Force Majeure will immediately:
a) Notify the other in writing of the reasons within 10 days for its failure to fulfill its obligations and the effect of such failure;
b) Use all responsible endeavours to avoid or remove the cause and
perform its obligations.
9. LAWS GOVERNING THE CONTRACT
The contract will be governed by the laws of the country in force from time
to time. The Contract shall be interpreted in accordance with the law of the land & will be under the jurisdiction of courts in Mumbai.
10. AGREEMENT
The successful Bidder shall execute a formal agreement as per Annexure III with the Executive Director (West), Zonal Office, Mumbai within the
fifteen (15) days of award of contract.
11. TAXES AND DUTIES
Except as otherwise specifically provided in the Contract, the Bidder shall
bear and pay all taxes, duties, levies and charges assessed on the bidder,
by all municipal, state or central government authorities
As regards the Indian Income Tax, Surcharge on Income Tax, Education
Cess and any other Corporate Tax, Corporation shall not bear any tax liability whatsoever. The bidder shall be liable and responsible for payment of such tax, if attached under the provisions of the law present
or future and Corporation will make deduction at source as applicable.
20
12. AVAILABILTY OF REQUISITE PERMISSIONS AND LICENSES AND
COMPLIANCE WITH THE STATUTORY PROVISIONS
The bidder is required to follow all the statutory acts as may be applicable
for such type of work which may also involve manpower/links/ services provided/ intellectual property right and other IT Acts, Labour Acts, PF Acts. The bidder merely by filling the bid confirms that the bidder has all
the requisite permissions and licenses to carry out all the works as stipulated by this tender. Further, merely by filling the tenders, the bidder
reconfirms that the bidder has complied with all the statutory provisions of the central, state, local and municipal laws enforce. The bidder also confirms merely by filling the tenders, to comply with any future laws that
may be enforced upon by the statute. Agencies which do not have requisite permissions / licenses or who do not comply with the statutory provisions are requested to fill in the bids only if they are eligible in this
respect. Valid registrations viz. Sales Tax / VAT / Central Excise and with any other authorities as per requirement should be available with the
bidder and be produced as and when required. The bidder shall obtain such permits and licenses as may be required under any law in force for the time being for his business.
13. LIQUIDATED DAMAGES (DELAYED COMMISSIONING & NON-DELIVERY)
Time is the essence of the contract and the milestones/ delivery dates are
binding on the bidder. In the event of delay or any gross negligence, for causes attributable to the bidder, in meeting the milestones/deliverables
as per tender, the Corporation shall be entitled at its option to recover from the bidder as agreed, liquidated damages, a sum of 0.5% of the actual contract value for every week of delay or part of a week for initial
04 (four) weeks. Thereafter, a sum of 1% of the actual contract value for every week or part of a week after initial 04 (four) weeks of delay would be
recovered, subject to the maximum value of the Liquidated Damages being not higher than 10% of the actual contract value. This right to claim any liquidated damages shall be without prejudice to other rights and
remedies available to Corporation under the contract and/or any other law.
In case of delay in achieving any of the targets/milestones solely not
attributable to bidder, Corporation may consider condoning or reducing part of the liquidated damages. Corporation has the exclusive right to
exercise this provision.
The decision of the competent authority i.e. Executive Director (West)
Food Corporation of India, Zonal Office, Borivali, Mumbai for imposing Liquidated Damages will be final and binding upon the party and no
21
correspondence in this regard will be entertained by Food Corporation of
India.
14. TRAINING
User training will be provided to the FCI user staff by the successful
bidder free of cost as given in scope of work at Section-III of the tender
document.
15. OPERATIONAL ACCEPTANCE AND FINAL ACCEPTANCE
Upon successful completion of entire work in each Warehouse/Depot
including testing by the bidder, the concerned Depot Manger shall issue a Certificate to the bidder as a proof of the final acceptance. Such certificate
shall not relieve the bidder of any of his obligations which otherwise survive, by the terms and conditions of the Contract after issuance of
such certificate.
16. LIMITATION OF LIABILITY:
16.1 The Contractor shall arrange all safety precautions for this representatives and workmen during the contract period and FCI shall
not be responsible for any consequences due to his failure to do so. The contractor shall ensure that no electric hazards/fire are caused due to
his negligence or improper usage of materials etc.
16.2 Bidder‟s aggregate liability for actual damages shall be capped at 100%
of the total value of the contract. However, in the following cases, the liability of the Bidder‟s shall be as per actual damages: 1) the bodily injury (including death) and damage to real property and tangible
personal property caused by Bidder‟s negligence and/or 2) the intellectual property infringement claims.
16.3 Bidder shall not in any event be liable for any indirect or consequential
damages, or for loss of profit, business, revenue, goodwill, anticipated savings or Data, or third party claims except with respect to bodily injury (including death) and damage to real and tangible personal
property.
16.4 Neither this Contract nor the Services delivered by Bidder under this Contract grants or creates any rights, benefits, claims, obligations or causes of action in, to or on behalf of any person or entity (including
any third party) other than between the respective Parties to this Contract, as the case may be.
16.5 Title and Risk of Loss: Bidder shall bear the risk of loss on Project
22
Assets; up to the time they are transferred and handed over to the FCI -
after which it shall stand transferred to the FCI. Bidder shall arrange and pay for insurance to cover such item until it is transferred.
23
SECTION-III
SCOPE OF WORK
Tender for Supply, Installation, Testing, Commissioning and Maintenance
of CCTV surveillance system at warehouse/Depots listed at Annexure -VI of Food Corporation of India, Zonal Office (West), Mumbai.
a) Each entry/exit gate(s) of the warehouse/Depots, as the case may be, shall be covered by 02 (two) Analog IR Vari-focal Bullet Cameras.
b) Weigh bridge shall be covered with 02 (two) Analog IR Vari-focal
Bullet Cameras.
c) 02 (two) Analog IR Vari-focal Bullet Cameras (one on each side of the Godown) to cover the passage as well as platform of the
Godown/Shed.
d) All the cameras shall be connected through network to DVR placed
in control room (Office of the Warehouse /Depot Manager) connected to a 32 inch LED Monitor (Resolution 1920*1080) display unit for
monitoring & managing the CCTV functions.
e) CCTV footage recording of 30 days has to be provisioned initially
with scalability to enhance the recording period as and when required.
f) Two days onsite training program for up to the seven officials for
operations of CCTV Systems at each warehouse/Depot will be
arranged by the vendor.
g) The complete CCTV System should be under warranty for 01 (one)
year and AMC for 04 (four) years.
h) The Vendor shall supply, installation, testing & commissioning of
CCTV Surveillance System along with required accessories, software,
DVR , UPS, cables, accessories etc
i) Bill of Material including cabling shall be indicative only, the
successful bidder shall visit the warehouse/Depot and arrive at the
actual requirement & location of placing the cameras in consultation
with the Warehouse/Depot Manager and Area Manager. Accordingly
payment shall be released on actual bill of material deployed based
on completion certificate & satisfactory report submitted by
warehouse/Depot manager through respective Area Manager(s) to
the concerned General Manager (Region).
24
j) Any enhancement/addition of the CCTV system within the
warehouse/Depot shall be taken up as per unit rate of the items
during contract period.
k) Time period for installation, testing & commissioning of CCTV system along with cabling in warehouse/Depots shall be 04 (four) months
from the date of award of contract.
l) An extended period of 03 (three) months shall be allowed to the contractor with leviable liquidated damages as mentioned in Clause 13 of Section II beyond the scheduled period of 04 (four) months for
completion of the installation, testing & commissioning of CCTV system along with cabling in warehouse/Depots. No further delay
shall be allowed beyond the extended period of 03 (three) months. Failure to complete the installation, testing & commissioning of CCTV system along with cabling in warehouse/Depots shall result in
invocation of PBG and will also be debarred for participating in any other Tender Enquiry with FCI for a period of 03 (three) years.
m) The price quoted by the bidder should include all the expenses in commissioning of all cameras with power supply, accessories and other devices complete with software.
n) The bidder shall make his own arrangements for supply and installation of the equipments at the designated warehouse/Depot
and no road permit shall be issued by FCI.
o) Specifications of camera offered by bidder should capture the number plate of the vehicle from a reasonable distance at gate,
Godown & weighbridge. Accordingly bidder has to provision required specifications of the lenses/items.
p) The batteries for UPS shall be under warranty for two years. Since the batteries are consumables, FCI to provide the same after
warranty period of two years, if required. The bidder has to install the batteries as per requirement.
q) Bidder shall quote separate price, each for UPS and Batteries as given in the price bid.
r) The bidder may survey the site for understanding of requirements, before bidding.
25
SCOPE FOR ONSITE COMPREHENSIVE WARRANTY AND AMC:
a) The period of warranty on all electronic equipment i.e. cameras, DVR etc. and allied materials, supplied by successful contractor, shall be 12 (twelve) months from the date of taking over certificate issued by
FCI.
b) The contractor shall ensure that the entire CCTV System including its components and all allied materials are working properly and continuously without fail during the currency of the contract. The
contractor shall also ensure visit by service Engineer/skilled technical personnel bi-monthly and submit the entire CCTV System
working reporting to the concerned Area Manager.
c) Annual Maintenance Charges will commence from the date of expiry of warranty period of 12 (twelve) months from date of commissioning with the same terms and conditions. It shall be the
responsibility of the bidder to carry out repairing/replacement of part(s), if any, during the period of warranty as well as AMC, without
any extra cost to FCI.
d) It shall be the responsibility of the contractor to ensure uninterrupted and proper functioning of the CCTV Setup during the currency of the contract period. In case of continued failure of the
CCTV system or contractor failing to provide satisfactory / uninterrupted functioning of CCTV System during the contract
period, Executive Director (West) will be at liberty to terminate the contract at any time and appoint new contractor at his risk and cost without prejudice to other right and remedies as per contract and
law. The Executive Director (West) shall have the sole authority to judge the performance of the Contractor in such cases and his decision shall be binding on the Contractor.
e) All materials and equipments etc. required by the contractor for the works, during On-site comprehensive warranty and AMC, will be arranged by him, without any extra cost to FCI.
f) FCI will neither provide foreign exchange nor any assistance whatsoever for import of equipments involved in the contract, if any.
g) Before handing over the system to the Corporation, the contractor will submit the following for each set of equipment to the concerned
Depot Manager.
i. Operation manual
26
ii. Servicing manual
iii. Equipment‟s Guarantee/Warranty certificates.
h) The contractor shall be responsible for any acts of commission or omission on the part of their work men in respect of any damage or loss to FCI property.
i) Any liability arising out of accident or death of any personnel during the execution of work shall be upon the contractor.
j) The contractor shall be responsible to comply with all the statutory obligations including Labour/Taxation/Octroi etc.
k) The contractor shall deploy only well experienced and qualified workmen for execution of the work.
l) All persons employed by the contractor shall be engaged by him as own employees in all respects, and all rights & liabilities under the workmen‟s compensation act, or EPF act and other applicable
enactments, in respect of all such personnel shall exclusively be that of the contractor. Contractor shall also comply with all rules and regulations/ enactments made by the State Government/ Centre
Government from time to time pertaining to the contract including all labour laws.
27
SECTION –IV
ANNEXURE-I
A. TECHNICAL BID: Supply, installation, testing, commissioning and maintenance of CCTV
surveillance system at warehouse/Depots of Food Corporation of India (FCI) listed in Annexure - VI
Sr. No.
Items Documentary Proof to be enclosed
Compliance (Y/N)
1. Authorized signatory (As per Clause No. 7 of
Section-I)
Authorization letter/Board Resolution in favour of the
officer signing the bid
2. Undertaking For
Unconditional
Acceptance of Terms &
Conditions of the
Tender Document
Bidder to submit Undertaking for
Unconditional Acceptance of Terms & Conditions of the Tender Document as per
Annexure-V duly signed by the authorized signatory.
3. Compliance of Technical Specifications:
Sr. No
Details Items/Work with specifications Compliance Yes/No
1 Analog IR Vari Focal Bullet Camera
i Sensor 1/3 " Progressive Scan CMOS or
higher
ii Effective Pixels 2 MP or higher
iii Effective Resolution 1930 x 1088 or more
iv Illumination 0.01 lux @ (F1.2, AGC ON), 0 Lux
with IR ON
v Shutter Speed 1/25 to 1/50000 second or better
vi Focal Length 4 mm or better
vii SNR 50 dB or more
viii Frame rate minimum 25 fps
ix Weather Rating IP 66
x IR Range minimum 30 m
xi Working Temp (-) 10 to (+) 60 degree Celsius
xii Horizontal Resolution 700 TVL or higher
28
xiii Certification UL / NABL ; FCC ; CE /EN
2 Digital Video
Recorder DVR
i Channels 16
ii Video Compression H.264
iii Output
HDMI/VGA output -
1920x1080/60Hz, 1280x1024/60Hz,
1280x720/60Hz, 1024x768/60Hz.
iv Minimum recording
period 30 days SD recording storage
v Playback 16 channels
vi Network Interface Yes
vii USB Ports Yes
viii Serial Interface Yes
ix Working Temp (-) 10 to (+) 60 degree Celsius or
better
x Certification UL / NABL ; FCC ; CE /EN
3A UPS 1 KVA UPS without battery
3B Battery 60 minutes battery backup for above
1 KVA UPS
4 Coaxial cable RG 11 Coaxial Copper Cable ISI
mark
5 Power cable 3 C x 1.5 sq mm Copper power cable
ISI
6 Monitor 32" LED Monitor resolution 1920 *
1080
7 PVC Pipe 32 mm PVC Pipe Heavy ISI Marked
8 GI Pipe 50 mm GI pipe medium ISI Mark
9 Supply of 6 U Network Rack with Power strip & related
accessories of Standard Make
10 Supply of 12 V Power Adaptors 4 AMP SMPS, Input Voltage -
90 to 285, Voltage variation + _ 10%, over voltage & short circuit protection
11 Supply of L Shape Angles Iron Bracket of required
specifications with provision of mounting bullet cameras on
the gate, weighbridge and godown walls
12 Supply of Cage for protection of the camera with barbed wire of suitable size
13 Provision for fixing of PVC pipe on wall, Laying of RG
armoured cable, Fixing of GI pipe under road, Fixing of L
shape iron angle brackets including installation of above
equipments complete with testing and commissioning
14
The Specifications parameters listed are minimum
requirement and any item of higher specification will be
accepted.
15 The proposed solution should be modular and scalable so
that at later date the additional requirement can be met by
add-on components based on rates quoted in price bid and
shall be valid for contract period.
29
16 All components of the CCTV System should be compatible
with one another
17 The proposed CCTV System‟s components must not be
obsolete
18
The sizing of DVR should be commensurate with the number of cameras and number of days to record the video
etc.
19 The specified items must be current/ recent in the
Supplier's/OEM product line
20 All the items shall be branded and reputed 21 All CCTV Cameras, housing and DVR should be of the same
OEM.
Signature of bidder
30
ANNEXURE-II
B. PRICE BID: C. Supply, Installation, Testing, Commissioning and Maintenance of CCTV surveillance
system at warehouse/Depots of Food Corporation of India (FCI) listed in Annexure VI
(Amount in Rupees)
Sr. No
Details Items/Work with specifications (including testing and commissioning)
Unit Rate per
unit
Quantity Amount
In figures
In words
1 Analog IR Vari-Focal Bullet Camera Each
2 Digital Video Recorder DVR
Each
3A UPS 1 KVA UPS without battery Each
3B Battery 60 minutes battery backup
for above 1 KVA UPS
Each
4 Coaxial cable RG 11 Coaxial Copper
Cable ISI mark
Meter
5 Power cable
3 C x 1.5 sq mm Copper power cable ISI
Meter
6 Monitor 32" LED Monitor
resolution 1920 * 1080
Each
7 PVC Pipe
32 mm PVC Pipe Heavy ISI
Marked
Meter
8 GI Pipe
50 mm GI pipe medium ISI
Mark
Meter
9 Supply of 6 U Network Rack with Power strip
& related accessories of Standard Make
Set
10 Supply of 12 V Power Adaptors 4 AMP SMPS, Input Voltage -90 to 285, Voltage variation +
_ 10%, over voltage & short circuit protection
Set
11 Supply & Installation of L Shape Angles Iron
Bracket of required specifications with
provision of mounting bullet cameras on the
gate, weighbridge and godown walls
Set
12 Supply of Cage for protection of the camera
with barbed wire of suitable size
Set
13 A Installation charges for fixing of PVC pipe on
wall including cabling
Meter
13 B Installation charges for fixing of PVC/GI
pipe underground including cabling
Meter
14 AMC charges for First year
NA
15 AMC charges for Second year
16 AMC charges for third year
17 AMC charges for forth year
Grand Total
31
Note: 1. The lowest of Grand Total above shall be considered as L1 bidder.
2. All accessories to be included in above quoted rates. Rates for all the items must be quoted. The items for which Bidder does not quote the price or indicates as „Nil‟ or puts a (-) mark or indicates „NA‟ etc. in the rate/amount column; cost of
that item shall be considered as „ZERO‟ and inclusive for Bid evaluation for such items.
3. The Specifications parameters listed are minimum requirement and any item of
higher specification will be accepted.
4. The bidder may survey the site(s) before bidding for understanding of requirements.
5. The solution should be modular and scalable so that at later date the additional
requirement can be met by add-on components based on rates quoted in price bid and shall be valid for contract period.
6. All components of the CCTV System should be compatible with one another. 7. The proposed CCTV System‟s components must not be obsolete. 8. The sizing of DVR should be commensurate with the number of cameras and
number of days to record the video etc. 9. The specified items must be current/ recent in the Supplier's/OEM product line.
10. All the items shall be branded and reputed. 11. All CCTV Cameras, housing and DVR should be of the same OEM.
12. Price quoted is inclusive of all applicable taxes. However, service tax shall be paid extra at applicable rate as per rules.
13. AMC charges to be quoted shall be lump sum amount for all the Depots.
Signature of bidder
32
ANNEXURE-III
AGREEMENT
The agreement made on this day of 201_ between the Food Corporation of India through its Executive Director, Zonal Office(West), Datta Pada Road, Rajendra Nagar, Borivali (East), Mumbai - 400 066,
established under Food Corporations‟ Act, 1964 (herein after called the Corporation) and ________________________________________________ (herein after called Contractor) which term shall include, unless repugnant to the context,
his/heirs and legal representatives, executers/ administrators and successors.
WHEREAS the Corporation being in requirement of __________________________ had
invited tenders for supply thereof vide tender No. AND WHEREAS the rate/rates submitted by the Contractor in his/their/its
letter dated has/ have been accepted by the Corporation vide communication No. dated .
It is hereby witnessth: The terms & conditions incorporated in tender No. form an integral
part of this agreement and will be sole repository of the terms and conditions governing the supply of to be made by the Contractor, and the said letter of the
Contractor is to be referred to only for the purpose of rates.
In witnesses whereof the parties have set their hands on the date herein before mentioned above written.
WITNESS Signature ____________
(Name & address of Contractor)
Seal
WITNES
S 1.
2. General Manager (Sec.) FOOD CORPORATION OF INDIA
33
Annexure-IV
BANK GUARANTEE FOR BID SECURITY (PERFORMANCE BANK GUARANTEE) (To be stamped in accordance with Stamp Act)
Bank Guarantee No. ……….. Date
………………………...
To [FCI's Name & Address]
Dear Sir,
In consideration of the …………….. [FCI's Name]…………. (hereinafter referred to
as the 'FCI,' which expression shall unless repugnant to the context or meaning
thereof, include its successors, administrators and assigns) having awarded to
……………..[Contractor's Name]
………..with its Registered/Head Office at …………………………..……………………
(Hereinafter referred to as the 'Contractor', which expression shall unless
repugnant to the context or meaning thereof, include its successors,
administrators, executors and assigns), a Contract by issue of FCI's Letter of
Award No. …………….. Dated ………….. and the same having been unequivocally
accepted by the Contractor, resulting in to a contract bearing No…………. dated
…………. Valued at……………….. for ……………… and the Contractor having
agreed to provide a Performance Guarantee for the faithful performance of the
entire Contract equivalent to 15% of contract value to the FCI.
We ……………….. [Name & Address of the Bank] …..………. having its Head
Office at
………………………….. (hereinafter referred to as the 'Bank', which expression
shall, unless repugnant to the context or meaning thereof, include its
successors, administrators, executors and assigns) do hereby guarantee and
undertake to pay the FCI, on demand any and all monies payable by the
contractor to the extent of 15% of contract value as aforesaid at any time upto
……………. (@) ………… [days/month/year] without any demur, reservation,
context, recourse or protest and/or without any reference to the Contractor. Any
such demand made by the Corporation on the Bank shall be conclusive and
binding notwithstanding any difference between the Corporation and the
Contractor or any dispute pending before any Court, Tribunal, Arbitrator or any
other authority. The Bank undertakes not to revoke this guarantee during its
currency without previous consent of the Corporation and further agrees that
34
the guarantee herein contained shall continue to be enforceable till the
Corporation discharges this guarantee.
The Corporation shall have the fullest liberty, without affecting in any way the
liability of the Bank under this guarantee, from time to time to extend the time
for performance of the Contract by the Contractor. The Corporation shall have
the fullest liberty, without affecting this guarantee, to postpone from time to
time the exercise of any powers vested in them or of any right which they might
have against the Contractor, and to exercise the same at any time in any
manner, and either to enforce or to forbear to enforce any covenants, contained
or implied, in the Contract between the Corporation and the Contractor or any
other course or remedy or security available to the FCI. The Bank shall not be
released of its obligations under these presents by any exercise by the
Corporation of its liberty with reference to the matters omission or commission
on the part of the Owner or any other indulgence shown by the Corporation or
by any other matter or thing whatsoever which under law would, but for this
provision, have the effect of relieving the Bank.
The Bank also agrees that the Corporation at its option shall be entitled to
enforce this Guarantee against the Bank as a principal debtor, in the first
instance without proceeding against the Contractor and notwithstanding any
security or other guarantee that the Corporation may have in relation to the
Contractor's liabilities.
Notwithstanding anything contained hereinabove, our liability under this
guarantee is restricted to …………. (*) ……….. and it shall remain in force up to
and including…………. (@) ……… and shall be extended from time to time for
such period, as may be desired by M/s………….. [Contractor's Name] ………... on
whose behalf this guarantee has been given.
In witness where of the Bank, through its authorized officer, has set its hand
and stamp on this
………………………… day of ……………….. 201_ at …………………… This
………………. day of ………….. 201_ at …………………………...
WITNESS …………………………..… (Signature) ……….…………
(Signature) ……………………………..
(Name) (Name) ………………….…. …………………………….. ………………………………
35
(Official Address) (Designation with Bank
Stamp)
Attorney as per Power of Attorney No……………… Dated
…………………….
Notes: 1. The validity of the Performance Bank Guarantee will be ninety (90)
days beyond the CONTRACT period as specified in the Contract.
2. The stamp papers of appropriate value shall be purchased in the name of Guarantee issuing Bank.
36
Annexure -V
Undertaking For Unconditional Acceptance of Terms & Conditions of the
Tender Document.
[Date]
To,
Executive Director (Zone),
Zonal Office (West)
Food Corporation of India,
2nd Floor, FCI Building,
Rajendra Nagar, Dattapada
Road,
Borivali (E),
Mumbai – 400 066
Dear Sir,
Subject: Tender notice for Supply, Installation, Testing, Commissioning and
Maintenance of CCTV surveillance system at Warehouses/Depots of Food Corporation of India under the jurisdiction of Zonal Office (West), Mumbai
We, the undersigned have thoroughly examined the tender document, and
have understood the Terms and Condition(s) of the Tender notice for Supply, Installation, Testing, Commissioning And Maintenance of CCTV surveillance system at warehouses/Depots of Food Corporation of India under the
jurisdiction of Zonal Office (West), Mumbai.
We confirm that the information contained in this response or any part
thereof, including its exhibits, and other documents and instruments delivered
or to be delivered to Food Corporation of India is true, accurate, verifiable and
complete. This response includes all information necessary to ensure that the
statements therein do not in whole or in part mislead the Corporation in its
short-listing process.
We fully understand and agree to comply that on verification, if any of the
information provided here is found to be misleading the short listing process, we
are liable to be dismissed from the selection process or termination of the
agreement during the project, if selected to do so.
We agree for unconditional acceptance of all the terms and conditions set
out in the tender document including annexures and corrigendum if any and
37
also agree to abide by this tender response for a period of 90 days from the date
fixed for bid opening.
We hereby declare that in case the agreement is awarded to us, we shall
submit the Performance Bank Guarantee in the form of bank guarantee in the
form prescribed at Annexure-IV.
We agree that FCI is not bound to accept any tender response that they
may receive. We also agree that FCI reserves the right in absolute sense to reject
all or any of the services specified in the tender response.
It is hereby confirmed that I/We are entitled to act on behalf of our
company/ corporation/ firm/ organization and empowered to sign this
document as well as such other documents, which may be required in this
connection.
We understand that it will be the responsibility of our organization to keep
Food Corporation of India informed of any changes in respect of authorized
person and we fully understand that Food Corporation of India shall not be
responsible for non-receipt or non-delivery of any communication and/or any
missing communication in the event reasonable prior notice of any change in
the authorized person of the company is not provided to Food Corporation of
India.
Dated: ___ Day of 201_
(Signature)
(Name)
(In the capacity of)
Duly authorized to sign the Tender for and on behalf of:
(Name and Address of Company)
Seal/Stamp of bidder
ANNEXURE – VI LIST OF DEPOTS/WAREHOUSES Sr.
No.
Region
Sr. No.
Name of the
Depot
Capacity
in MT
No. of
Cameras
proposed
to be
installed
Complete Address of the Depot
along with Pin Code
Name of Depot
Manager
Contact No. of
Depot Manager
Area Office
REGIONAL OFFICE – AHMEDABAD (GUJARAT REGION)
1 1 FSD
Sabarmati 80000 46
Near Lalita Mahal Cinema,
Kaligam, Sabarmati, Ahmedabad-
380009 Nikunj Katara 7574802120
DO-
Ahmedabad
2 2 FSD
Viramgam 35000 18
Raiyapur Railway Crossing,
Rampura Bhakoda Road,
Viramgam-382150 J C Jadhav 9574511151
3 3 FSD Baroda 12220 08 Alembic Road, Nr. Priyalaxmi
mill, Vadodara-390003 Deepak Meena 7574802133
DO -
Baroda
4 4 FSD
Bhomaiya 55000 32
A'bad-Dakor Road, Post:
Bhomaiya, Taluka, Bhomaiya,
Dist: Panchmahal-389001 Saurabh Porwal 7574802131
5 5 FSD
Gandhidham 50000 31 Opp. Kandla Economic Zone, NH
8 A Gandhidham-370201 K V Maheshwari 7574802143
DO -
Adipur
6 6 FSD
Wadhwan 10000 08
Kharva Road, Wadhwan, Dist.
Surendranagar-363030 L J Meena 7574802157
DO -
Rajkot
7 7 FSD
Bhavnagar 20000 10 Kumbharwada, Nari Road, Nr
IPCL, Bhavnagar-364006 Divyakant Mehta 7574802163
8 8 FSD Dared
(Jamnagar) 30000
16 Post Chela, Dared, Jamanagar-
361012 Shivpaul Yadav 7574802164
REGIONAL OFFICE – MUMBAI (MAHARASHTRA REGION)
9 1 FSD Borivali 134352
86
Food Corporation of India,
Rajendra Nagar, Dattapada road,
Borivali (East), Mumbai 400066
Shri R S Jodge 9619317150 DO –
Borivali
10 2 FSD
Bhiwandi 10000
10
Food Storage Depot, Food
Corporation of India, Anjur Patha,
Raval Vill., Bhiwandi, Thane -
401302
Shri. A S
Kukreja
9324823104
11 3 FSD Panvel 91700
48
Food Storage Depot, Food
Corporation of India, Kalamboli,
New Mumbai - 410218
Shri S.T. Kokare 9664030007 DO –
Panvel
12 4 FSD Goa 15000
08
Food Corporation of India,
Headland Sada, Near Sada jail,
Vasco Goa- 403804
Shri. A. K. Minz 8450970328 DO – Goa
13 5 FSD
Ratnagiri 10000
10
Food Corporation of India, C - 65,
MIDC, Mirjole, Ratnagiri -
415639
Shri A. S.
Kachare
9527643758 DO –Pune
14 6 FSD Pune 29100
22
Food Corporation of India,
94/102, South Main Road, Lane
no. 3, Koregaon Park, Pune -
411001
Shri. C.P.
Nadekar
8450970316
15 7 FSD
Ahmednagar 5000
06
Food Corporation of India, Near
Renuka Devi Mandir, Kedgaon,
Ahmednagar - 414005
Shri
R.K.Chintamani
9764771825
16 8 FSD Gondia 30000
18
Food Storage Depot, Food
Corporation of India, Murry
Village, Gondia - 415639
Shri Manoj
Verma
8450970352 DO -
Nagpur
REGIONAL OFFICE – BHOPAL (MADHYA PRADESH REGION)
17 1 FSD Betul 10000 08 ITARSI ROAD, SADAR NEAR
HMT BETUL -460001 Sh. P.S. Sakya, 9826086915
DO -
Bhopal
18 2 FSD Vidisha 10000 08 Ahmadpur Road, Vidisha - 464001
Sh. S S Chahar,
M(D) 7024213038
19 3 FSD
Ashoknagar 11920 08
Isha garh Road, Ashoknagar-
473331 Sh. Nilesh Soni,
Manager (D) 9993700926
DO -
Gwalior
20 4 FSD Datia 7500 08 CIVIL Line Datia 475661 Sh. Rohitash
Meena,
Manager(D) 9425775672
21 5 FSD Gwalior 12500 10 Jhansi road, Near by Hotel Land
mark, Gwalior-474001
Sh. Sumit
Chanderia,
Manager(D) 9725752896
22 6 FSD Sheopur 11280 10 Pali Road, nearby Dgree College,
Sheopur -476337 Sh. R P Meena,
Manager(D) 8171957175
23 7 FSD
Meghnagar 5000 06
Manager (Depot)
FCI, Opp. Govt. Hospital, Nr
Police station,Meghnagar-457779
District-Jhabua
Sh. R.K. Bansal 7024213045,
9098661560
DO - Indore
24 8 FSD Katni 8640 08
Food Corporation of India, FSD
Katni, Gram- Puraini, PO -Waka
Thana- Kuthla, District-Katni-
483501 (M.P.)
Shri B.N. Prasad,
Manager (D) 7024213055
DO -
Jabalpur
25 9 FSD Seoni 8340 08 Food Corporation of India, Seoni
Depot, Behind Yogiraj Talkies,
Manglipeth Seoni-480661 (M.P.)
Shri K K Yadav,
Manager (D) 9406753444
26 10 FSD Newari 18140 12 HARSHMAU NEAR Rail Station
Newari 472442 Sh. Himanshu
Meena, M(D) 7024213065
DO - Sagar
27 11 FSD
Tikamgarh 15000 10
FCI, Tikamgarh, Dhonga,
Gwaleschand Godown 472001 Sh. M.L. Kori,
M(D) 7683242368
28 12 FSD Ujjain 15000 10
Manager (Depot) ,
Food Corporation of India ,
FSD,Maksi Road, Ujjain (M.P)
Pin Code -456010
Shri K.L. Gome ,
Manager (Depot) 9424892371
DO - Ujjain
29 13 FSD Ratlam 9080 08
Manager (Depot) ,
Food Corporation of India ,
FSD, Mahu Neemuch Road,
Ratlam (M.P) - 457001
Shir M.K.
Mandloi,
Manager (Depot)
7024213047/
9993377866
REGIONAL OFFICE – RAIPUR (CHHATTISGARH REGION)
30 1 FSD
Jagdalpur 10640 10
MANAGER (D), FCI, KUMHAR
PARA CHAUK, JEYPORE
ROAD, JAGDALPUR (C.G.)-
494001
Shri. R K
Sadafal 7694810168
DO - Durg
31 2 Rajnanadgaon
AB Shed 10000 08
MANAGER (D), FCI, RAIPUR
NAKA, RAJNANDGAON (C.G.)-
491441
Sh. Praveen
Mishra 7694810167
32 3 FSD
Rajnandgaon 61625 36
MANAGER (D), FCI, RAIPUR
NAKA, RAJNANDGAON (C.G.)-
491441
Sh. Praveen
Mishra 7694810167
33 4 FSD Sakti 12500 10 MANAGER (D), FCI, SAKTI-
495689 Sh. R.K. SAHU 9981526826
DO -
Bilaspur
34 5 FSD Raigarh 10640 10 MANAGER (D), FCI,FSD,
RAIGARH ,JUTE MILL KABIR
CHOUK-496001
Sh. Puneet Singh
M(QC) 7694810186
35 6 FSD Belha 8340 10 MANAGER (D), FCI, BELHA-
495224 Sh. JOHN MINZ 8109387137
36 7 FSD
Bishrampur 13340 10
MANAGER (D), FCI, FSD,
BISHRAMPUR ,DIST-
SURAJPUR-4972226 Sh. T. LAKRA 9425290871
37 8 FSD
Kargiroad 15000 10
BELGAHANA ROAD 495113 Sh. NITIN SONI 7582829230
38 9 FSD Bilaspur 35120 26 MANAGER (D), FCI,
BILASPUR,TARBAHAR-495001 Sh. NITIN SONI 7582829230
39 10 FSD Neora
Old Complex 11920 14 MANAGER (D), FCI, FSD,
NEORA-493114
Sh. R.N.
Prajapati 7694810151
DO -
Raipur
40 11 FSD
Dhamtari 11640 20 MANAGER (D), FCI,
DHAMTARI-493773
Sh. ROHIT
VERMA 7694810153
41 12 FSD Arjuni
(Dtr) 15000 12 MANAGER (D), FCI,ARJUNI
DHAMTARI-493773
Sh. ROHIT
VERMA 7694810153
42 13 FSD Raipur
Own 25090 18 MANAGER (D), FCI, FSD,
RAIPUR-492001
Sh. M.K.
Rodekar 9617148272
43 14 FSD Rajim 15640 12 MANAGER (D), FCI, RAJIM-
493881
Sh. VINAY
KUMAR 7694810152
44 15 FSD
Bagbahra 10670 14 MANAGER (D), FCI,
BAGBAHARA-493449
Sh.
R.N.P.PANDEY 9424315159
45 16 FSD
Mahasamund 14233 12 MANAGER (D), FCI,
MAHASAMUND-493445
Sh. NITIN
AGRAWAL 7694810155