BOARD NOTICE - c.ymcdn.com · categories of registration for Construction Quantity Surveyor and...
Transcript of BOARD NOTICE - c.ymcdn.com · categories of registration for Construction Quantity Surveyor and...
Board Notice XXXX 2015 Page 1 of 36
BOARD NOTICE NOTICE XXX OF 2015
CALL FOR PUBLIC COMMENT
THE SOUTH AFRICAN COUNCIL for the
QUANTITY SURVEYING PROFESSION Established in terms of the Quantity Surveying Profession Act 2000 (Act 49 of 2000)
PROPOSED SUPPLIMENTORY SPECIFIED QUANTITY SURVEYING REGISTRATION
CATEGORIES
SACQSP is empowered in terms of section 36 (1) of the Quantity Surveying Profession Act, 2000 (Act No.49 of 2000) hereinafter referred to as "the Act" to make rules with regard to any matter that is required or permitted to be prescribed in terms of the Act and any other matter for the better execution of the Act. Council has in terms of Section 18 (1) (c) prescribed two (2) specified categories of registration for Construction Quantity Surveyor and Technician Quantity Surveyor. Notice is hereby given that the South African Council for the Quantity Surveying Profession ("SACQSP") is proposing to include Construction Quantity Surveyor and Technician Quantity Surveyor as specified categories of registration in the Quantity Surveying profession, together with the preparatory Candidacy tier for each proposed specified category. The Notice is hereby given in terms of Section 36 (2) (a) of the Act to allow interested and affected persons within 30 days from the date of the publication of this notice to make written representation on the proposed registration categories for Construction and Technician Quantity Surveyors. It must be noted that SACQSP must in terms of Section 26(2) of the Act must identify the type of work to be undertaken for the proposed specified category of registration to the CBE in terms of the Act and the CBE shall identify the scope of work for the proposed category and consult the Competition Commission as required by the CBE Act, 2000 (Act No.43 of 2000). The proposed draft of the identity of work of the current category of Professional and the proposed Construction and Technician categories of registration is listed below, together with their designated competency requirement enabling the person to undertake the scope of work. Closing date for the submission of comments is XXXXXX 2015. Submission details: The Registrar Email: [email protected] Tel: 011 312-2560
Board Notice XXXX 2015 Page 2 of 36
Postal address: South African Council for the Quantity Surveying Profession P.O Box 654, Halfway House 1685
Physical address: Suite C27 Lone Creek, Waterfall Park, Bekker Road, Vorna Valley – Midrand
Board Notice XXXX 2015 Page 3 of 36
Rule in terms of section 36 (1) The purpose of the rule is to provide two new specified categories of registration for persons suitably qualified in terms of the below specified Route to Registration for either Construction or Technician Quantity Surveyor. 1. Categories of registration In terms of Section 18(1), the current categories in which a person may register in the quantity Surveying profession are-
a) Professional Quantity Surveyor b) Candidate Quantity Surveyor;
2. Council Resolution South African Council for the Quantity Surveying Profession (SACQSP) resolved to prescribe two new categories of registration for Construction and Technician Quantity Surveyors. The SACQSP proposes that persons so qualified will be divided into the following categories-
a) Construction Quantity Surveyor b) Candidate Construction Quantity Surveyor c) Technician Quantity Surveyor d) Candidate Technician Quantity Surveyor;
Board Notice XXXX 2015 Page 4 of 36
PROPOSED NEW SPECIFIED TIER OF REGISTRATION
TO BE PERFORMED BY PERSONS REGISTERED IN TERMS OF THE QUANTITY SURVEYING PROFESSION ACT 2000
(ACT NO. 49 OF 2000)
TABLE OF CONTENTS
PAGE
1 INTRODUCTION 4
2 DEFINITIONS 4 3 GOALS AND OBJECTIVES 6 4 GENERAL INFORMATION: WORK TO BE PERFORMED BY PERSONS
REGISTERED IN TERMS OF ACT 49/2000 7
4.1 Description of the Quantity Surveying Profession 4.2 Nature and Type of Projects 4.3 Application of the Provision of this Document 4.4 Project Work Stages 4.5 General Notes 5 QUANTITY SURVEYING WORK 9 6 PROVISIONS OF THE QUANTITY SURVEYING PROFESSION ACT 11 6.1 Compliance with the Quantity Surveying Profession Act, 2000 6.2 Improper Conduct
ANNEXURES ANNEXURE A SACQSP GUIDELINES: ASSESSMENT OF PROFESSIONAL 12 COMPETENCE ANNEXURE B LIMITING SCOPE OF SERVICES TO BE UNDERTAKEN BY EACH 22 CATEGORY OF REGISTERED QUANTITY SURVEYOR ANNEXURE C SACQSP REGISTRATION ROUTES FOR CANDIDATE QUANTITY 29 SURVEYORS OF EACH CATAGORY ANNEXURE D LIST OF ACCREDITED PROGRAMMES OFFERED BY TERTIARY
INSTITUTIONS IN SOUTH AFRICA 35
Board Notice XXXX 2015 Page 5 of 36
1.0 INTRODUCTION
The following are detailed descriptions of standard activities and functions inherent in delivering registered Quantity Surveying (QS) services. In essence, this document defines the work set aside for persons registered as Quantity Surveyors in the specified categories of registration
The contents of this document describe standard services which are generic to most Built Environment projects.
There is often a lack of comprehension of the work performed by Quantity Surveyors. This is to the general detriment of the construction industry macro economy and the micro-economy of the individual projects in terms of profitability / feasibility, cost management and value for money derived by clients of the industry.
Identification of work for persons registered in terms of Section 18 of Act 49/2000 - optimises the application of scarce, highly-skilled human resources, - minimises a client’s financial risk, - promotes best value for money spent, - protects the Public
Section 26 of the Act requires SACQSP to make recommendations to the Council for the Built Environment (CBE), regarding the work identified in terms of subsection (2) and prohibits a person not registered in terms of this Act to perform any kind of work identified for any category of professional registered in terms of this Act.
2.0 DEFINITIONS
“Built Environment” refers to the functional field in which registered persons practice. The Built Environment includes all structures that are planned and/or erected above or underground, as well as the land utilised for the defined purposes and the provision of supporting infrastructure. “Quantity Surveying” is the provision of expert, professional services and advice on construction procurement, contracting and costs. Quantity surveyors are trained, experienced specialists who have acquired comprehensive knowledge of construction procurement and contracting methods, finance and economics. They advise, collaborate and co-operate with members of other Built Environment Professions. To protect their clients’ interests, Quantity Surveyors, depending on their tier of registration:
advise on construction procurement methods and evaluation of tenders, contracting strategies and conditions of contract
advise on and provision of construction cost planning, cost analysis and cost control of projects
advise and undertake value engineering and life cycle costing exercises and estimation of replacement cost for insurance purposes
undertake financial feasibility ( viability / profitability) studies to predict possible rates of return on commercial investment projects
prepare and compile procurement documentation including tender, pricing and contract data, bills of quantities / activity schedules / schedules of rates and other tender documents including main-, sub- contract and specialist services agreements
evaluate tenders and make recommendations on suitability and pricing of tenders and report findings accordingly
manage all the financial aspects of construction projects including the preparation of valuations for payment certificates in order to ensure that projects are constructed within approved budgets
prepare valuation of variations to the scope of work including negotiation of rates and prices and the preparation and conclusion of financial final accounts with main- and subConstructions
advise on contractual matters including resolution of contractual claims and disputes
act as principal agents in terms of construction contracts
Board Notice XXXX 2015 Page 6 of 36
“Quantity Surveyor” is a person who is registered as such in terms of the Quantity Surveying Profession Act, 2000 (Act No. 49 of 2000) hereinafter referred to as “the Act”.
“Quantity Surveying Work” means the work identified under section 4 of this Identification of Work for Quantity Surveyors policy document
“Works” means all work executed or intended to be executed in accordance with a construction contract.
“Principal Agent” means a person or entity appointed by a client, and who has full authority and obligation to act on behalf of that client in terms of a construction contract.
“Principal Consultant” means a person or entity appointed by a client to manage and administer the services of all other consultants appointed to provide professional services on a specific project.
“Construction Contractor” means any person or legal entity entering into a contract with a client for the execution of the works or part thereof of a specific project.
“Construction Project” means a project where quantity surveying work of a construction nature, be it of architectural or engineering design, is undertaken by the quantity surveyor .
“Nominated Sub-Contractor” are specialists and other sub-contractors who are nominated by a Principal Consultant to execute work or supply and fix any goods in terms of a specific contract.
“Selected Sub-Contractors” are specialists and other sub-contractors who are selected by a Construction Contractor in consultation with a Principal Consultant to execute work or supply and fix any goods in terms of a specific contract.
“Domestic Sub-Contractors” are specialists and other sub-contractors who are selected and appointed by a Construction Contractor to execute work or supply and fix any goods in terms of a specific contract.
“Direct Contractors” are contractors appointed by a client to execute work other than the works related to a specific contract.
“Suppliers” are persons or entities appointed by a client or Construction Contractor to supply goods and products for incorporation into the works related to a specific contract.
“Construction Programme” is an appropriately detailed programme for the works related to a specific contract, which
is used for monitoring the progress of those works and
indicates the logical sequence and duration of all activities to be completed by the Construction Contractor, sub-contractors and suppliers.
“Contract programme” is a construction programme for the works related to a specific contract, agreed between the Construction Contractor and the Principal Agent.
“The South African Council for the Quantity Surveying Profession” means the South African Council for the Quantity Surveying Profession established as a juristic person by section 2 of the Quantity Surveying Profession Act, 2000 (Act No. 49 of 2000, as amended), and “SACQSP” has the same meaning.
“Quantity Surveying Profession Act” means the Quantity Surveying Profession Act, 2000 (Act No. 49 of 2000, as amended).
Board Notice XXXX 2015 Page 7 of 36
“Quantity Surveying Work” means the work identified under section 4 of this Identification of Work for Quantity Surveyors policy document.
“Improper Conduct” contemplated in section 27(3) of the Quantity Surveying Profession Act, 2000, as amended), means failure to comply with the code of conduct for registered quantity surveyors.
“Public” means any person or group of persons who is, or whose environment is either directly or indirectly affected by any quantity surveying activity, or by an outcome or influence of a quantity surveying activity, or by a service provided in terms of quantity surveying activity, which may impact on the health, safety and interest of such person or group of persons
“Substantially Practice” means
regularly and consistently executing or performing quantity surveying work identified in section 4 of this document,
charging fees for such work and
accruing professional responsibility to a client or an employer for the performance of such work and related functions.
“The Council for the Built Environment” means the juristic person established by section 2 of the Council for the Built Environment Act, 2000 (Act No 43 of 2000) ) and “CBE” has the same meaning
“South African Quality Authority” means the juristic person established by section 3 of the South African Quality Authority Act, 1995 (Act 58 of 1995) and “SAQA” has the same meaning
3.0 GOALS AND OBJECTIVES
The goal of this document is to make recommendations to the CBE regarding the work that is to be Identified for the quantity Surveying profession.
The objective of identifying this work is to verify the required competence of registered quantity surveyors to achieve the following requirements of the Quantity Surveying Professions Act to:
comply with legislative requirements,
protect the public by defining the work that each registration category of the quantity Surveying professionals can undertake,
protect the environment and promote effective environmental management,
promote the sustainability of the developments,
provide a framework for the identification of work and the demarcation of identified work between professionals,
provide an effective and efficient mechanism for addressing and recognising overlaps and duplication between work identified by different professions,
ensure that where work is to be carried out by different categories of professionals, there are clear and transparent ways of determining the category of professional to carry out the work, and
promote the transparency and accountability of the identification of work process
Board Notice XXXX 2015 Page 8 of 36
4.0 GENERAL INFORMATION: WORK TO BE PERFORMED BY PERSONS REGISTERED IN TERMS OF ACT 49/2000
4.1 Description of the Quantity Surveying Profession
Quantity Surveying comprises a variety of services performed by skilled technical persons with defined competencies depending on their tier of registration. Quantity Surveyors appointed or employed by clients who wish to invest in property developments or undertake as contactors built environment construction projects. Professional Quantity Surveyor (PrQS) work is undertaken by specialist, formally educated professionals with specific training and experience that provides a special range of skills that are applied to a wide range of problem-solving situations, predominantly related to project costs and construction contracts. Professional Quantity Surveyors offer consultative advice to clients, architects, engineers and other service providers on all financial and contractual matters arising from built environment construction projects from inception to close out. Professional Quantity Surveyors have a full understanding of various systems and methods of construction, specialised services and installations, construction materials, plant (machinery) and labour as well as the many forms of contract and sub-contract agreements available for use in the construction industry. Professional Quantity Surveyors are also competent to advise their clients and other consultants regarding alternative procurement and contracting strategies, methods of construction, material, life cycle costs, value engineering alternatives and valuations of structures for insurance or other purposes. Construction Quantity Surveyor (RCQS) work is undertaken by formally educated persons with specific training and experience that provides a special range of skills that are applied to a wide range of problem-solving situations, predominantly related to project costing, estimating, cost control and construction contracts. Construction Quantity Surveyors offer consultative advice to contractor clients or employers and other contractor service providers on all financial and contractual matters arising from built environment construction projects from tender to close out. Construction Quantity Surveyors have a full understanding of various systems and methods of construction, specialised services and installations, construction materials, plant (machinery) and labour as well as limited forms of contract and sub-contract agreements available for use in the construction industry. Construction Quantity Surveyors are also competent to advise their clients and employers regarding alternative procurement and contracting strategies, methods of construction, material handling, health and safety, procurement and cost control. Technician Quantity Surveyor (TechQS) work is undertaken by formally educated persons with generic training and experience that provides a limited range of skills that are applied as a supportive roll to Professional or Construction Quantity Surveyors, predominantly related to project costing, estimating, cost control and site measurement. Technician Quantity Surveyors may not offer advice to contractor clients or employers and other contractor service providers, except via their supervisory employer. Technician Quantity Surveyors have a limited understanding of various systems and methods of construction, specialised services and installations, construction materials, plant (machinery) and labour.
4.2 Nature and Types of Projects
The nature and types of projects to be implemented in terms of the Quantity Surveying Profession Act 2000 (Act No 49 of 2000) shall be all construction work within the Built Environment.
4.3 Application of the Provisions of this Document
The provisions of this document shall be applicable in respect of :-
1. Any quantity surveying work performed within the borders of the Republic of South Africa (RSA), whether or not the intended outcome of such work is to be executed outside the RSA
2. Any person who is not ordinarily resident in the Republic of South Africa, but who performs quantity surveying work within the RSA
4.4 Project Work Stages Typical construction projects comprise the following Project Work stages:
Board Notice XXXX 2015 Page 9 of 36
4.4.4. Documentation and Procurement Preparing the construction and procurement documentation, confirm and implement the procurement strategies and procedures for effective and timeous procurement of necessary resources for the execution of the project 4.4.5. Construction Preparation and co-ordination of the procedures and documentation to facilitate practical completion of the works; managing, administering and monitoring the contracts and processes, including the preparation and co-ordination of the procedures and documentation to facilitate practical completion of the works 4.4.6. Close Out Fulfilling and completing the project close-out including the preparation of the necessary documentation to facilitate effective completion, handover and operation of the project
The generic scope of Work that a quantity surveyor may undertake in each of the above Stages is identified in Annexure B. and the competencies required to carry out such work is outlined in Annexure A and C.
4.5 General Notes
4.5.1 As these stages might overlap, the generic services stated in section 5 of this document, may be required to be undertaken during any one of the Project Work Stages
4.5.2 The order of the generic services does not necessarily reflect the actual sequence of
implementation.
Board Notice XXXX 2015 Page 10 of 36
5 QUANTITY SURVEYING WORK
IDENTIFICATION OF WORK TO BE PERFORMED BY QUANTITY SURVEYORS REGISTERED IN TERMS OF THE QUANTITY SURVEYING PROFESSION ACT, 2000 (ACT NO 49 OF 2000)
The competency areas required of a person registered as one of the three categories of Quantity Surveyors to perform the work identified through delivering the generic services as set out in Annexure “B”, are encapsulated in the unit standards as registered under the Quantity Surveying Standard Generating Body (SGB) with the South African Qualifications Authority (SAQA). The required qualification for registration of each category is noted in the Route to Registration as specified in Annexure C.
COMPETENCY AREAS: Provision of advanced quantity Surveying expertise within the following competency areas and delivery of the full scope of professional services
ASSOCIATED COMPETENCIES: Associated competencies (Unit Standard Numbers registered with SAQA) Details of each Unit Standard can be found on the SAQA or SACQSP website; www.saqa.org.za See Registered Unit Standards www.sacqsp.org.za See Documents – Programme Accreditation
Pro
fes
sio
nal
Co
nstru
ctio
n
Tech
nic
ian
1.0 CORE COMPETENCY AREAS
1.1 Interacting with relevant stakeholders in the construction industry
BC14415 (Describe and interpret the composition, role-players, processes and role of the construction industry)
Competence is demonstrated by being able to:
describe the role of the construction industry and its impact on the South African economy
identify role-players and describe their positions and duties
develop an understanding of the impact of legislation, regulations and codes of practice across construction practices
identify major construction activities
apply communication techniques
X X
1.2 Interpreting construction drawings and specifications
BC14426 (Read, interpret and use construction drawings and specifications)
Competence is demonstrated by being able to:
identify drawings and symbols to be used for taking off quantities for construction projects
safeguard and store construction drawings
apply information from drawings in taking off activities
interpret specifications during the taking off process
demonstrate an understanding of the role of drawings and specifications in construction contracts
X X X
1.3 Basic setting-out of construction works, using appropriate
BC14428 (Set out construction work areas)
Competence is demonstrated by being able to:
understand and apply Surveying techniques and principles
X X X
Board Notice XXXX 2015 Page 11 of 36
survey equipment understand setting out works by using only measuring tapes and a spirit level
understand setting out and be able to check levels and profiles
understand setting out work using a theodolite
1.4 Understand price determination documents and the utilisation of the information in project administration applications
QS27 (Understand the uses of price determination documentation)
Competence is demonstrated by being able to:
understand the format of typical price determination documents
understand standard terminology used in price determination documentation
understand and describe uses of price determination documents
understand and describe the processes adopted in compiling price determination documents
understand and demonstrate formula usage for mensuration
X X X
1.5 Taking off quantities and preparing price determination documents for small/simple load bearing structures, framed structures and specialised elements of complex buildings
QS28 (Basic descriptive quantification), QS29 (Intermediate descriptive quantification) and QS30 (Advanced descriptive quantification) Competence is demonstrated by being able to:
critically appraise design plans of projects
develop a logical approach to the sequence of measurement
apply measuring principles described in industry measuring guides
utilise standard industry procedures in ‘booking’ of dimensions
communicate with industry participants in regard to ‘booked’ dimensions
convert measurements into fully descriptive unpriced price determination documents using appropriate specialist computer packages
X X X
1.6 Implementing appropriate budgetary processes related to built environment projects, cash flow forecasting and management, and preparing financial reports
QS2 (Undertake budgetary reporting on and monitoring of built environment projects)
Competence is demonstrated by being able to:
develop strategies for gathering data and conducting research on current trends in construction prices and costs
establish budgets for built environment projects
analyse and interpret data relating to contract performance and cashflows
design and implement appropriate project cost reporting systems
provide cost reports to relevant stakeholders
combine facts, ideas and proposals into a complex whole
understand and apply basic computer skills
demonstrate problem-solving ability
demonstrate communication and presentation skills
X X
1.7 Preparing cost estimates for built environment projects, including advising on design-cost alternatives,
QS3 (Prepare cost estimates for built environment projects):
Competence is demonstrated by being able to:
assemble, analyse and utilise cost-related data for cost estimating purposes
X X
Board Notice XXXX 2015 Page 12 of 36
undertaking project cost norm analyses, and preparing replacement cost valuations
develop cost estimates for built environment projects
provide design-to-cost advice for design alternatives
demonstrate the ability to compile unit rates for a variety of cost estimating methods
provide advice on cost norms relating to built environment projects
combine facts, ideas and proposals into a complex whole
understand and apply basic computer skills
demonstrate problem-solving ability
demonstrate communication and presentation skills
1.8 Undertaking the cost planning and cost control of built environment projects
QS4 (Prepare for and implement cost planning processes related to built environment projects):
Competence is demonstrated by being able to:
establish cost objectives and parameters e.g. cost limits for Built environment projects
develop cost planning and cost control systems for built environment projects
prepare cost plans for built environment projects and undertake cost control
evaluate Built environment projects in terms of key performance indicators
combine facts, ideas and proposals into a complex whole
understand and apply basic computer skills
demonstrate problem-solving skills
demonstrate communication and presentation skills
X X
1.9 Providing procurement advice for built environment projects, including matching clients’ strategic objectives with procurement system characteristics
QS6 (Provide procurement advice for built environment projects)
Competence is demonstrated by being able to:
establish clients’ strategic objectives
demonstrate a clear understanding on the characteristics, advantages and disadvantages associated with different procurement systems
evaluate alternative procurement (project delivery) systems
demonstrate the ability to match procurement system characteristics with clients’ strategic objectives
analyse methods of construction-related buildability
demonstrate an understanding of the constructability implications for procurement system choice
combine facts, ideas and proposals into a complex whole
understand and apply basic computer skills
X
1.10 Managing payment processes during built environment project construction
QS10 (Managing payment processes during built environment project construction)
Competence is demonstrated by being able to:
prepare priced cost management documentation
design and implement an appropriate interim payment process
value the work done for certification purposes
evaluate and process fluctuations in built environment project costs
recommend the amounts to be certified for progress payment purposes
develop strategies for gathering data and conducting research on current trends in contract administration
combine facts, ideas and proposals into a complex whole
understand and apply basic computer skills
X X X
Board Notice XXXX 2015 Page 13 of 36
demonstrate problem-solving skills
demonstrate communication and presentation skills
1.11 Identifying and managing the effects of scope-change on built environment projects
QS11 (Manage the effect of change in the nature and scope of built environment projects)
Competence is demonstrated by being able to:
evaluate the nature and extent of project scope change
establish the cost and delivery consequences of project scope change
manage cost claims during the construction phase of projects
communicate the cost and delivery consequences of project scope change to relevant stakeholders
combine facts, ideas and proposals into a complex whole
understand and apply basic computer skills
X X X
1.12 Determining the resources required by built environment project production processes
QS14 (Determine resource requirements for built environment projects)
Competence is demonstrated by being able to:
determine resource requirements
understand construction programmes
interpret resource and productivity usage reports
prepare material order lists
develop and implement appropriate procedures for resource-based data gathering
X X X
1.13 Undertaking the contractual management of built environment projects
QS20 (Apply legal principles to the contractual management of built environment projects)
Competence is demonstrated by being able to:
acquire knowledge of the development of construction contracts in historical and comparative perspective
demonstrate knowledge of building contracts for targeted procurement and community involvement
demonstrate knowledge of standard construction contract forms in common usage
ensure project compliance with legislative and planning requirements, including environmental and occupational health and safety issues
understand alternative dispute resolution procedures and evidentiary norms applied in legal proceedings within the built environment
X X
1.14 Undertaking the strategic planning of built environment projects, including contributing to brief development, cost / benefit analyses and economic and financial analyses
QS1 (Strategic planning of built environment projects)
Competence is demonstrated by being able to:
establish project objectives and parameters and the format of the report
provide strategic planning advice on the costs and benefits of various courses of action which could be taken on built environment projects
conduct economic and financial analyses related to built environment projects
provide input into the development of a built environment project brief
demonstrate awareness and understanding of regulatory compliance
X
Board Notice XXXX 2015 Page 14 of 36
1.15 Providing advice on appropriate types of contract documents and price determination methods
QS8 (Providing advice on contract documents and price determination methods for built environment projects)
Competence is demonstrated by being able to:
advise clients on alternative types of contract documents appropriate to the built environment project under consideration
recommend and agree with client and consultant team the choice of price determination method, associated method of measurement, and input document requirements
access and distribute input documents
X
1.16 Managing the production / preparation of price determination and cost management documents for built environment projects
QS9 (Manage price determination production processes for built environment projects)
Competence is demonstrated by being able to:
develop strategies for gathering data and conducting research on project delivery systems, Construction selection and forms of contract
demonstrate an understanding of price determination enquiry documents
understand built environments project award processes
apply evaluation processes to built environment project bids
demonstrate an understanding of bid negotiation for built environment projects
combine facts, ideas and proposals into a complex whole
understand and apply basic computer skills
demonstrate problem-solving skills
demonstrate communication and presentation skills
X X
1.17 Resolving claims, preparing the final account and applying close-out procedures
QS12 (Resolve claims, settle disputes and apply close-out procedures on built environment projects)
Competence is demonstrated by being able to:
collect data relevant to construction claims
evaluate construction claims
communicate the financial consequences of construction claims to relevant stakeholders
incorporate the financial consequences of construction claims into the final account
prepare and settle the final account
implement all project close-out procedures
combine facts, ideas and proposals into a complex whole
understand and apply basic computer skills
demonstrate problem-solving skills
demonstrate communication and presentation skills
X X
1.18 Developing and implementing project service quality assurance procedures
QS13 (Implement project service quality assurance on built environment projects)
Competence is demonstrated by being able to:
establish roles and responsibilities, organisational structures and communication channels
evaluate the quality of project documentation
develop project information management systems
prepare project close-out system
X
1.19 Undertaking financial feasibility
QS16 (Undertake financial feasibility studies for built environment projects):
X
Board Notice XXXX 2015 Page 15 of 36
studies for Built environment projects, including market need, risk and return analyses
Competence is demonstrated by being able to:
gather data related to the collection of predictive information
analyse data related to property cycles
implement appropriate methodologies to analyse supply and demand statistics
interpret market need surveys related to the proposed projects
apply appropriate analysis and evaluation techniques, including discounted cash flows and sensitivity analyses
demonstrate knowledge of the construction and financial practices of the industry, including relevant tax-related issues
appropriately record and document information, particularly the compilation of data on completed projects
understand and apply appropriate computer skills
demonstrate communication and presentation skills
1.20 Planning and managing environmental initiatives for construction projects
BC114656 (Manage environment initiatives on a construction project)
Competence is demonstrated by being able to:
understanding environmental management practices
consider environmental management initiatives during pre-construction planning and decision making
understanding the management of environmental initiatives during construction activities
understanding the management of environmental initiatives during post- construction activities
X X
1.21 Understand the management and administration construction projects on site
AC&D115119 (Monitor and evaluate design projects) and BC115449 (Manage construction projects)
Competence is demonstrated by being able to:
accurately identify problems within construction design projects
analyse the implementation of construction design projects
assess and evaluate construction design projects
monitor the construction design process
understand the management of resources on construction projects
understand the management of occupational health and safety on construction projects
understand quality management on construction projects
understand risk management of construction project
X X
1.22 Understand the management of construction organisational assets
BC115444 (Manage construction organizational assets)
Competence is demonstrated by being able to:
identify and maintain an asset database
identify and implement maintenance requirements
review alternative asset and technology availability
control assets
monitor and evaluate asset usage
evaluate asset management in terms of organizational strategy
X X
1.23 Designing, compiling and utilising project cost information
QS5 (Compile a project cost information database for built environment projects)
Competence is demonstrated by being able to:
X X X
Board Notice XXXX 2015 Page 16 of 36
databases for the financial management of built environment projects e.g. elemental cost analyses
define the requirements of a built environment project cost information database
access relevant information
set up and maintain database
apply project cost information databases to the financial management of built environment projects
1.24 Managing the price determination, awarding and evaluation processes associated with built environment projects e.g. tender process management
QS7 (Manage price determination processes for built environment projects)
Competence is demonstrated by being able to:
prepare price determination enquiry documentation for built environment projects
initiate built environment project award process
advise on the selection of bidders for built environment projects
Negotiate bids for built environment projects
X X
1.25 Managing cost-related risk on built environment projects by identifying, analysing and responding to risk events
QS15 (Manage cost-related risk on built environment projects)
Competence is demonstrated by being able to:
engage in the identification of risk events
analyse risk events with regard to the risk exposure of clients and other relevant stakeholders
respond to risk events to minimise the impact on clients and stakeholders
capture risk knowledge for use on future projects
combine facts, ideas and proposals into a complex whole
understand and apply basic computer skills
demonstrate problem-solving skills
demonstrate communication and presentation skills
X
1.26 Undertaking whole life appraisal of built environment projects
QS17 (Undertake whole life appraisal of built environment projects)
Competence is demonstrated by being able to:
implement strategies for accessing data related to life cycle and costs-in-use information and conducting research
analyse data for the preparation of whole life appraisal
apply appropriate analysis and evaluation techniques
demonstrate a clear understanding of the whole life appraisal practices of the construction industry
appropriately record and document information, particularly as applied to whole life appraisal
understand and apply appropriate computer skills
demonstrate communication and presentation skills
X
1.27 Contributing to the sustainability assessment of built environment projects
QS18 (Understand the principles of sustainability assessment for built environment projects)
Competence is demonstrated by being able to:
describe the scoping study to establish the nature and extent of sustainability assessment exercise
understand the environmental sustainability assessment of projects
understand the economic sustainability assessment of projects
understand the social sustainability assessment of projects
understand the technological sustainability assessment of
X
Board Notice XXXX 2015 Page 17 of 36
projects
communicate outcomes of sustainability assessment to the client, other role players and stakeholders
1.28 Undertaking value management exercises for built environment projects
QS21 (Understand value management processes on built environment projects)
Competence is demonstrated by being able to:
identify project objectives
undertake value management assessment exercise
record and distribute the results of the value management exercise
recommend to client how outcomes of the value management assessment can be adopted
X
1.29 Undertaking professional practice management in a quantity Surveying enterprise, including structuring the enterprise, negotiating quantity surveyor-client agreements, and applying relevant fee scales
QS (Understand professional practice management procedures in a quantity Surveying enterprise)
Competence is demonstrated by being able to:
understand the content and objectives of professional legislation for the built environment
understand principles of practice structuring
prepare contractual and fee reimbursement schedules for professional services
apply principles of developing a competitive business strategy
X
2. SPECIALISED SERVICES COMPETENCY AREAS
2.1 Designing and implementing specialised service quality assurance procedures
QS22 (Design and implement specialised quality assurance procedures)
Competence is demonstrated by being able to:
develop corporate quality policies
develop service provision quality procedures
undertake internal audits of service quality
undertake service provision quality debriefing (feedback) with clients and other relevant stakeholders
X
2.2 Conducting tax assessments on built environment projects, including tax depreciation, and Value Added Tax (VAT) and Capital Gains Tax (CGT) assessments
QS23 (Conduct tax assessments on built environment projects)
Competence is demonstrated by being able to:
confirm the specialized tax assessment service objectives and strategy
conduct tax depreciation assessments
conduct value added tax assessment
conduct capital gains tax assessment
develop schedule and prepare report
X
2.3 Conducting land and related tax assessments of built environment projects
QS24 (Conduct land and related tax assessments of built environment projects)
Competence is demonstrated by being able to:
confirm the specialised tax service objectives and strategy
confirm interface with other professional consultants
X
Board Notice XXXX 2015 Page 18 of 36
assessment of land tax
stamp duty assessment
local authority rates assessment
establish reporting detail
2.4 Conducting premises-, energy-, maintenance- and asset register audits
QS25 (Conduct specialised audits of built environment projects)
Competence is demonstrated by being able to:
establish project objectives and parameters
conduct premises audit
complete energy and maintenance audit
complete asset registers audit
develop audit schedules and prepare report
X
6 PROVISIONS FOR REGISTRATION CATEGORIES IN TERMS OF THE QUANTITY SURVEYING PROFESSION ACT NO 49 OF 2000
6.1 Compliance with the Quantity Surveying Profession Act, 2000
6.1.1. Section 18(2) states that a person may not practice in any of the registration categories unless he or she is registered in that category. Two categories are currently recognised viz. Professional Quantity Surveyor (PrQS) and Candidate Quantity Surveyor (CanQS). In addition, the Act allows for any other Specified Category, which includes Candidate Construction Quantity Surveyor (CanCQS), Registered Construction Quantity Surveyor (RCQS), Candidate Technician Quantity Surveyor (CanTechQS) and Registered Technician Quantity Surveyor (TechQS). See Annexures A and C.
6.1.2. Section 18(3) states that a person who is registered in the category of candidate must perform quantity surveying work only under the supervision and control of a fully registered person within the category of registration as prescribed. Refer ‘Annexure A’ for Assessment of Professional Competence which clearly illustrates the aspects that differentiates the competencies between a registered Quantity Surveyor (PrQS/RCQS/TechQS) and Candidate Quantity Surveyor (CanQS/CCQS/CTQS).
6.1.3. Section 26(3)(a) states that a person who is not registered in terms of this Act, may not perform any kind of work identified for any category of registered persons. However section 26(4) states clearly that this may not be construed as prohibiting any person form performing work identified in terms of section 26, if such work is performed in the service of or by order of and under the direction, control, supervision of or in association with a registered person entitled to perform the work identified and who must assume responsibility for any work so performed.
6.1.4. Clients/consumers/contractors are under no obligation to appoint a quantity surveyor on a built environment project, but should a person represent him/herself as a quantity surveyor, then that person requires to be assessed competent and registered with the SACQSP, and should conduct his/her work within the parameters set out in this policy document, adhering to the Act. Other titles or descriptions that infer or are calculated to lead a person to infer, that a person is a quantity surveyor, or that a person or firm provides ‘quantity Surveying services’ would also require assessment and registration with SACQSP, in terms of the Act 49
6.2 Improper Conduct
Section 27(3) states that all registered persons must comply with the prescribed code of conduct of quantity surveyors and failure to do so constitutes improper conduct.
Board Notice XXXX 2015 Page 19 of 36
ANNEXURE A
SACQSP GUIDELINES: ASSESSMENT OF QUANTITY SURVEYING COMPETENCE This is an overview of the Registration Policy as published as a Rule in terms of the Act 1. STRUCTURED EXPERIENCE TO BE GAINED BY THE CANDIDATE QUANTITY SURVEYORS
Candidates must demonstrate that they have gained appropriate, supervised, mentored experience in either the building or the engineering construction industry. Experience in the building industry includes building-related engineering services. For the purpose of assessment, engineering construction incorporates both civil engineering and mechanical/electrical engineering associated with engineering construction Section 2 (i) to (iv) herein presents activities which are fundamental to quantity surveying, in which candidates are required to demonstrate their competence Section 2 (v) herein covers specialised activities, some of which may not be undertaken by all firms or employer organisations, and while candidates may be exposed to certain aspects of specialised services, they will not be expected to have achieved competence in all the listed activities Experience recorded must be referenced in terms of the SACQSP schedule of activities listed in the on-line QS Diary application. Some activities may be recorded under more than one heading and should reflect a balanced distribution of practical experience If candidates are unable to obtain sufficient experience in a particular skills category, simulation offers an acceptable alternative. They should undertake assignments based on previously-completed tasks performed within their offices and submit their completed assignments for evaluation by their supervisors / mentors. Alternatively, they should be permitted to observe / assist their supervisors / mentors in the latter’s’ performance of such tasks Candidates must obtain the council’s approval of any quantity surveying experience which does not fall within the areas specified in section 2 herein Candidates who change their
place of employment or
the type of industry in which they are employed (building to engineering or vice versa)
supervisor / mentor must submit full details of such changes to the council for approval
2. SUPERVISED / MENTORED QUANTITY SURVEYING EXPERIENCE TO BE GAINED BY A CANDIDATE UNDER THE GUIDANCE OF A REGISTERED MENTOR, APPOINTED IN TERMS OF THE DECLARATION OF THE CANDIDATE’S EMPLOYER
(i) Cost advice and cost planning (PrQS only) o Preparing and using cost data o Preparing estimates o Undertaking financial feasibility and comparative studies o Preparing and using detailed budgets and cost plans, cost checking during design development;
compiling and using cost limits o Preparing and applying cost-in-use studies; life cycle costing o Preparing and interpreting turnover/cash flow projections and profit/loss forecasts o Cost control and reporting during pre-contract period
(ii) Contract documentation (PrQS and RCQS – TechQS where indicted) o Preparing bills of quantities for principal or sub-contracts of supply including the measurement and
description of work, drafting of preliminaries, preambles and contract conditions (TechQS) o Preparing bills of measurement for final accounts if measured from drawings (TechQS) o Preparing specifications and/or schedules of rates (TechQS) o Contractual correspondence
Board Notice XXXX 2015 Page 20 of 36
(iii) Tendering and contractual arrangements (PrQS and RCQS only) o Formulating or implementing procedures on tendering and contractual arrangements for principal or sub-contracts or contracts of supply o Advising on selection of tenders; evaluation of and reporting on tenders o Preparing tenders including compilation of rates for work and preliminaries (iv) Contract services (PrQS and RCQS – TechQS as indicated) The following are applicable to principal contracts or sub-contracts: o Advising on cost during progress of the works, estimating final costs and reporting on the financial aspects o Monitoring of proposed construction methods or sequences and reporting on actual requirements; preparing cost benefit reports on alternative construction methods o Cost control during progress of the works (TechQS) o Preparing valuations for interim certificates (TechQS) o Analysing contract price relative to cost recording methods (TechQS) o Preparing and agreeing final accounts and contra charges o Reporting on, evaluating and negotiating contractual and extra-contractual issues; contract correspondence; attending site meetings (TechQS) o Preparing or interpreting cost/value and other reconciliation statements for management purposes o Surveying, measuring and recording site information (TechQS only) (v) Specialisations (PrQS only) o Taxation allowances and grants o Planning or programming of contract works o Resource determination, scheduling and purchasing o Procurement of plant and materials o Production cost/quality control, time standards and operational methods o Productivity methods and evaluation o Project planning and project management o Insurance o Litigation and arbitration o Insolvency and liquidation o Planned preventative maintenance o Schedules of dilapidation o Technical audits o Office management including resource allocation, fees and budgets o Maintenance of buildings o Research and development
Details of any other specialisations that Candidates may wish to include must be submitted to the Council for prior approval
3. SUBMISSION OF INTERIM (PrQS only) OR FINAL REPORTS (RCQS and PrQS only):
Candidates and their Employers / Supervisors must complete the application form for Inspection of Reports (Interim / Final), and enclose the following documents for submission to the Registrar’s office
(a) General Report (b) Project Specific Report (PrQS only) (c) Structured Workplace Experience - Activity Schedule
(i) Submissions are submitted electronically for ease of distribution to assessors, sponsors and quality assurance regulators
(ii) Assessors appointed by the Council, evaluate the content, scope and quality of the supervised / mentored experience gained by a Candidate based on these submissions.
(iii) Assessors’ reports on INTERIM submissions are advisory and intended to advise if the;
scope and standard of the supervised / mentored technical or professional experience gained during the first phase of the in-training period is satisfactory,
Board Notice XXXX 2015 Page 21 of 36
the content, format and standard of presentation of the formal project specific report (PrQS Only) is acceptable for FINAL submissions or should be enhanced / improved in respect to content / format / standard of presentation
(iv) An Assessor’s recommendation to the Registration Committee, based on evaluation of a FINAL submission, is the determining factor on which the Committee will approve a Candidate’s
admission to Assessment of Professional Competence (APC) interview (PrQS only)
registration as a RCQS
registration as a TechQS
(v) If an Assessor recommends that a PrQS Candidate’s admission to an APC interview is to be deferred, a detailed, written motivation is to be provided for approval by the Registration Committee. The Candidate will be advised of the deferral and is to resubmit their FINAL report based the assessors recommendations for re-evaluation.
(viii) If an Assessor recommends that a RCQS Candidate’s submission is unacceptable, a detailed,
written motivation is to be provided for approval by the Registration Committee. The Candidate will be advised of the deferral and to resubmit their FINAL report resubmit based the assessors recommendations for re-evaluation.
4. APPLICATION BY A REGISTERED CANDIDATE QUANTITY SURVEYOR FOR
BACKDATING OF EXPERIENCE (RECOGNITION OF PRIOR LEARNING)
The following information should be submitted for consideration by the Registration Committee: (i) a comprehensive business / project CV which lists all the projects on which the Candidate has
worked during the previous years as stipulated in the Route to Registration. The CV is to provide explicit details of the Candidate’s personal quantity surveying roles and responsibilities on each of those projects, with a. each role / function, on each project referenced to the SACQSP skills competencies b. the contents of the business / project CV / personal QS roles and functions verified by the
Candidate’s previous and current Employers / Supervisors if any changes in employment have occurred during the previous 3 years
(ii) signed letters of commendation, presented on their original letterheads, from clients and registered consultants with whom the Candidate has worked on the projects listed in the business / project CV. Commendation must be referenced to specific SACQSP skills competencies. Each client and registered professional consultant should be given a copy of the SACQSP Skills Competencies to be used for defining references in attesting to the Candidate’s quantity surveying competence
(iii) When received by the Registrar's office, the foregoing information will be submitted to the Registration Committee for adjudication and a recommendation that the Candidate (a) acquires additional experience in certain areas of quantity surveying skills to be recorded
electronically in the QS Diary application; or (b) is permitted a shortened supervised / mentored in-training period, but that all other conditions
stated in the Route to Registration are to be met; or (c) is to be admitted to an APC interview without further practical in-training requirements; or (d) is to be registered in the specified tier of registration befitting their experience without further
intervention.
5. MEMBER OF THE ROYAL INSTITUTION OF CHARTERED SURVEYORS
In terms of the Mutual Recognition of Professional Competence agreement between the SACQSP and the RICS; Professional Quantity Surveyor registration will be automatically be granted to a MRICS QS in good standing who meet the minimum prescribed quantity surveying educational level, subject to a professional peer interview of competency on South African built environment circumstances.
6. EMPLOYER’S RESPONSIBILITY
It is the Employer’s responsibility to ensure that the Candidate acquires the necessary technical / professional experience. The Candidate must be given guidance, advice and encouragement to fulfil the requirements of the QS Registration process.
When a Candidate applies to register, the Employer (usually a principal, partner or person responsible for training) must prepare a programme and sign a declaration that the appropriate experience and supervision will be provided.
Board Notice XXXX 2015 Page 22 of 36
Candidates are required to obtain the specified hours of workplace skills within the specified period allowed as a candidate for each specified category of registration as detailed in the Registration Policy.
The Candidate and the Employer must satisfy the Council that the Candidate has received reasonably balanced technical / professional training and experience. Some Employers’ will not be able to provide the full breadth of experience required in the registration process, and Candidates must be warned if this is the case, Employers could temporarily second their Candidates (for an agreed period) to another office or contractor where the prerequisite technical or professional experience will be gained, and the Employer may consider taking a substitute Candidate from the secondment office or contractor in exchange.
Work in certain specialised areas may not normally be carried out (unaided) by Candidates
The Candidate’s on-line record of workplace experience is to be checked and electronically signed-off by the designated mentor/supervisor on a periodic basis.
The workplace experience captured electronically is benchmarked against industry expectation, indicating any areas of potential deficiencies.
Reports required of a PrQS Candidate are designed to demonstrate not only Candidates’ experience, but also their ability to express themselves formally. Interim submissions will be evaluated by SACQSP-appointed assessors and Candidates will be informed of any shortcomings in experience or in report-writing skills.
Employers and Candidates must ensure compliance with the Registration Rules and that the purpose of the process is not undermined.
7. SUPERVISORS
The Employer must appoint a supervisor for every Candidate. A supervisor can mentor more than one Candidate simultaneously.
The supervisor is responsible to the Employer and to the Candidate for ensuring that the Candidate receives appropriate training and the promised experience (or a suitable alternative) and that the Candidate develops the confidence to perform the required QS tasks independently. The supervisor must electronically countersign the Candidate’s Diary submissions and certify the interim and final reports (if required), which must be submitted to the Council. The Candidate should discuss any problems with the supervisor.
The supervisor must certify that the Candidate has achieved the required period of training together with the necessary breadth and quality of experience in all areas.
Supervisors must be a fully Registered person in good-standing in the same category of registration that the Candidate is striving to achieve (but not necessarily the Employer) or a senior person within the Employer’s own organisation
The supervisor is also responsible for overseeing the Candidate’s day-to-day work. The supervisor must electronically countersign the Candidate’s Diary each week, and certify the interim and final reports as applicable.
If the Candidate changes employment or if the supervisor is changed, the Council must be notified immediately.
Board Notice XXXX 2015 Page 23 of 36
ANNEXURE B - 1 GENERIC SCOPE OF SERVICES TO BE PROVIDED BY A REGISTERED QUANTITY SURVEYOR
PROFESSIONAL QUANTITY SURVEYOR:
B1 Stage 1: Inception
This stage is in broad terms defined as follows: Establish the client requirements and preferences, assess user needs and options, appointment of necessary consultants, establish the project brief including project objectives, priorities, constraints, assumptions, aspirations and strategies B1.1 Stage 1 services
Assist in developing a clear project brief
Attend project initiation meetings
Advise on procurement policy for the project
Advise on other consultants and services required
Define the consultant’s scope of work and services
Conclude the terms of the agreement with the client
Advise on economic factors affecting the project
Advise on appropriate financial design criteria
Provide necessary information within the agreed scope of the project to the other consultants
Agreed scope of work, agreed services, signed client/quantity surveyor professional services agreement are deliverables applicable to the above
B2 Stage 2: Concept and Viability
This stage is in broad terms defined as follows: Prepare and finalize the project concept in accordance with the brief including the scope, scale, character, form, function and preliminary programme and viability of the project B2.1 Stage 2 services
Agree the documentation programme with the principal consultant and other consultants
Attend the design and consultants’ meetings
Review and evaluate design concepts and advise on viability in conjunction with the other consultants
Receive relevant data and cost estimates from other consultants
Prepare preliminary and elemental or equivalent estimates of construction cost
Assist the client in preparing a financial viability report
Audit space allocation against the initial brief
Liaise, co-operating and providing necessary information to the client, principal consultant and other consultants
Preliminary estimate(s) of construction costs
Elemental or equivalent estimate(s) of construction costs
Space allocation audit for the project
B3 Stage 3: Design Development This stage is in broad terms defined as follows: Develop the approved concept to finalise the design, outline specifications, cost plan, financial viability and programme for the project
Board Notice XXXX 2015 Page 24 of 36
B3.1 Stage 3 services
Review the documentation programme with the principal contractor and other consultants
Attend design and consultants’ meetings
Review and evaluate design and outline specifications and exercise cost control in conjunction with the other consultants
Receive relevant data and cost estimates from the other consultants
Prepare detailed estimates of construction cost
Assist the client in reviewing the financial viability report
Comment on space and accommodation allowances and prepare an area schedule
Liaise, co-operate and provide necessary information to the client, principal contractor and other consultants
Detailed estimate(s) of construction cost
Area schedule
B4 Stage 4: Documentation and Procurement This stage is in broad terms defined as follows: Prepare the construction and procurement documentation, confirm and implement the procurement strategies and procedures for effective and timeous procurement of necessary resources for the execution of the project B4.1 Stage 4 services
Attend design and consultants’ meetings
Assist the principal consultant in the formulation of the procurement strategy for Contractor, sub-contractors and suppliers
Review working drawings for compliance with the approved budget of construction cost and/or financial viability
Prepare documentation for both principal and subcontract procurement
Assist the principal consultant with calling of tenders and/or negotiation of prices
Assist with financial evaluation of tenders
Assist with preparation of contract documentation for signature
B5 Stage 5: Construction
This stage is in broad terms defined as follows: Manage, administer and monitor the contracts and processes, including the preparation and co-ordination of the procedures and documentation to facilitate practical completion of the works B5.1 Stage 5 services
Attend the site handover
Prepare schedules of predicted cash flow
Prepare pro-active estimates for proposed variations for client decision-making
Attend regular site, technical and progress meetings
Adjudicate and resolve financial claims by the Contractor(s)
Assist in the resolution of contractual claims by the Contractor(s)
Establish and maintain a financial control system
Prepare valuations for payment certificates to be issued by the principal agent
Prepare final account(s) for the works on a progressive basis
Schedule(s) of predicted cash flow
Estimates for proposed variations
Financial control reports
Board Notice XXXX 2015 Page 25 of 36
B6 Stage 6: Close-Out This stage is in broad terms defined as follows: Fulfil and complete the project close-out including the preparation of the necessary documentation to facilitate effective completion, handover and operation of the project B6.1 Stage 6 services
Valuations for payment certificates to be issued by the principal agent
Conclude final account(s)
Close-out procedures Further deliverables:
ADDITIONAL REQUIREMENTS The services to be provided by the Professional Quantity Surveyor in the event that they are required to provide services as the Principal Consultant and/or Principal Agent are as follows: Stage 1 services
Facilitate the development of a clear project brief
Establish the procurement policy for the project
Assist the client in the procurement of necessary and appropriate other consultants including the clear definition of their roles and responsibilities
Establish in conjunction with the client, other consultants and all relevant authorities, the site characteristics, rights and constraints for the proper design of the intended project
Define the consultant’s scope of work and services
Conclude the terms of the agreement with the client
Facilitate a schedule of the required consents and approvals
Prepare, co-ordinate and monitor a project initiation programme
Facilitate client approval of all Stage 1 documentation Stage 2 services
Assist the client in procurement of other consultants
Advise the client on the requirement to appoint a health and safety consultant
Communicate the project brief to other consultants and monitor the development of the concept and viability
Agree format and procedure for cost control and reporting by other consultants
Prepare a documentation programme and indicative construction programme
Co-ordinate concept and viability documentation for presentation to the client for approval
Facilitate approval of the concept and viability by the client
Facilitate approval of the concept and viability by statutory authorities Stage 3 services
Agree and implement communication processes and procedures for the design development of the project
Assist the client in the procurement of the necessary other consultants including the clear definition of their roles and responsibilities
Prepare, co-ordinate, agree and monitor a detailed design and documentation program
Conduct and record consultants’ and management meetings
Facilitate input required by health and safety consultant
Facilitate design reviews for compliance and cost control
Facilitate timeous technical co-ordination
Facilitate client approval of all Stage 3 documentation Stage 4 services
Board Notice XXXX 2015 Page 26 of 36
Recommend and agree procurement strategy for Contractors, sub-contractors and suppliers with the client and other consultants
Prepare and agree the procurement programme
Advise the client, in conjunction with the other consultants on the appropriate insurances
Co-ordinate and monitor preparation of procurement documentation by consultants in accordance with the project procurement programme
Manage procurement process and recommend Contractors for approval by the client
Co-ordinate the assembly of the contract documentation for signature Stage 5 services
Arrange site handover to the Contractors
Establish the construction documentation issue process
Agree and monitor issue and distribution of construction documentation
Instruct the Contractor on behalf of the client to appoint sub-contractors
Conduct and record regular site meetings
Monitor, review and approve the preparation of the construction programme by the Contractor
Regularly monitor performance of the Contractor against construction programme
Adjudicate entitlements that arise from changes required to the construction programme
Receive, co-ordinate and monitor approval of all contract documentation provided by the Contractor(s)
Agree quality assurance procedures and monitor implementation thereof by the other consultants and the Contractor
Monitor preparation and auditing of the Contractor’s health and safety plan and approval thereof by the health and safety consultant
Monitor preparation of the environmental management plan by the environmental consultant
Establish procedures for monitoring scope and cost variations
Monitor, review, approve and issue certificates
Receive, review and adjudicate any contractual claims
Monitor preparation of financial control reports by the other consultants
Prepare and submit progress reports
Co-ordinate, monitor and issue practical completion lists and the certificate of practical completion
Facilitate and expedite receipt of occupation certificates Stage 6 services
Co-ordinate and monitor rectification of defects
Manage procurement of operations and maintenance manuals, guarantees and warrantees
Manage preparation of as-built drawings and documentation
Manage procurement of outstanding statutory certificates
Monitor, review and issue payment certificates
Issue completion certificates
Manage agreement of final account(s)
Prepare and present a project close-out report
Board Notice XXXX 2015 Page 27 of 36
ANNEXURE B - 2 GENERIC SCOPE OF SERVICES TO BE PROVIDED BY A REGISTERED QUANTITY SURVEYOR
CONSTRUCTION QUANTITY SURVEYOR The generic services offered by the CONSTRUCTION QUANTITY SURVEYOR to the Contractor environment and Contractor clients. These services exclude services related to project initiation, in-depth feasibility and viability studies, mediation, arbitration and/or litigation. Clients are restricted to persons or employers who are directly involved in the construction of projects. The following items are extracted from the PROCSA agreement as described as the scope of work of a Quantity Surveyor; B.3 STAGE 3: DESIGN DEVELOPMENT This stage is in broad terms defined as follows: Develop the approved concept to finalise the design, outline specifications, cost plan, financial viability and programme for the project B.3.1 Stage 3 services B.3.1.1 Review the documentation programme with the principal consultant and other consultants B.3.1.5 Prepare detailed estimates of construction cost B.3.1.6 Assist the client in reviewing the financial viability report B.3.1.7 Comment on space and accommodation allowances and prepare an area schedule B.4 STAGE 4: TENDER DOCUMENTATION AND PROCUREMENT This stage is in broad terms defined as follows: Prepare the construction and procurement documentation, confirm and implement the procurement strategies and procedures for effective and timeous procurement of necessary resources for the execution of the project B.4.1 Stage 4 services B.4.1.1 Attend design and consultants’ meetings B.4.1.2 Assist the Contractor in the formulation of the procurement strategy for the Contractor, their sub-
contractors and suppliers B.4.1.3 Review working drawings for compliance with the approved budget of construction cost and/or
financial viability B.4.1.4 Prepare documentation for sub-contract procurement for contactors B.4.1.5 Assist the contactor with calling of tenders and / or negotiation of prices B.4.1.6 Assist with financial evaluation of tenders B.4.1.7 Assist with preparation of contract documentation for signature B.5 STAGE 5: CONSTRUCTION This stage is in broad terms defined as follows: Manage, administer and monitor the Construction and processes, including the preparation and co-ordination of the procedures and documentation to facilitate practical completion of the works B.5.1 Stage 5 services B.5.1.1 Attend the site handover B.5.1.2 Prepare schedules of predicted cash flow B.5.1.3 Prepare pro-active estimates for proposed variations for the client’s project team decision-making B.5.1.4 Attend regular site, technical and progress meetings B.5.1.5 Submit and resolve financial claims for and on behalf of the Contractor(s) B.5.1.6 Assist in the resolution of contractual claims by the Contractor(s) and sub-contractor B.5.1.7 Establish and maintain a financial control system
Board Notice XXXX 2015 Page 28 of 36
B.5.1.8 Prepare valuations for payment certificates to be submitted on behalf of the Contractor to the principal agent
B.5.1.9 Prepare final account(s) for the works on a progressive basis B.6 STAGE 6: CLOSE-OUT This stage is in broad terms defined as follows: Fulfil and complete the project close-out including the preparation of the necessary documentation to facilitate effective completion, handover and operation of the project B.6.1 Stage 6 services B.6.1.1 Prepare valuations for payment certificates to be submitted on behalf of the Contractor(s) B.6.1.2 Conclude final account(s)
Board Notice XXXX 2015 Page 29 of 36
ANNEXURE B - 3 GENERIC SCOPE OF SERVICES TO BE PROVIDED BY A REGISTERED QUANTITY SURVEYOR
TECHNICIAN QUANTITY SURVEYOR The generic services offered by the TECHNICIAN QUANTITY SURVEYOR to the Contractor or Professional QS employer. These services exclude services related to project initiation, in-depth feasibility and viability studies, mediation, arbitration and/or litigation. Technician Quantity Surveyors may not work for their own account and are required to work under the full-time supervision of a RCQS or PrQS. The following items are extracted from the PROCSA agreement as described as the scope of work of a Quantity Surveyor; B.3 STAGE 3: DESIGN DEVELOPMENT This stage is in broad terms defined as follows: Develop the approved concept to finalise the design, outline specifications, cost plan, financial viability and programme for the project B.3.1 Stage 3 services B.3.1.5 Assist the RCQS or PrQS to prepare detailed estimates of construction cost B.4 STAGE 4: TENDER DOCUMENTATION AND PROCUREMENT This stage is in broad terms defined as follows: Prepare the construction and procurement documentation, confirm and implement the procurement strategies and procedures for effective and timeous procurement of necessary resources for the execution of the project B.4.1 Stage 4 services B.4.1.5 Assist the RCQS or PrQS with calling of tenders and / or negotiation of prices B.4.1.6 Assist the RCQS or PrQS with financial evaluation of tenders B.4.1.7 Assist the RCQS or PrQS with preparation of contract documentation for signature B.5 STAGE 5: CONSTRUCTION This stage is in broad terms defined as follows: Manage, administer and monitor the Construction and processes, including the preparation and co-ordination of the procedures and documentation to facilitate practical completion of the works B.5.1 Stage 5 services B.5.1.1 Attend the site handover B.5.1.2 Assist with preparing schedules of predicted cash flow B.5.1.3 Assist with preparing estimates for proposed variations for client decision-making B.5.1.4 Attend regular site, technical and progress meetings B.5.1.6 Assist in the resolution of contractual claims by the Contractor(s) and sub-contractors B.5.1.8 Assist with the preparation of valuations for payment certificates B.5.1.9 Assist with the preparation of final account(s) for the works on a progressive basis B.6 STAGE 6: CLOSE-OUT This stage is in broad terms defined as follows: Fulfil and complete the project close-out including the preparation of the necessary documentation to facilitate effective completion, handover and operation of the project
B.6.1 Stage 6 services - Nil.
Board Notice XXXX 2015 Page 30 of 36
ANNEXURE C - 1: SACQSP ROUTES TO REGISTRATION:
Professional Quantity Surveyor Entry threshold / eligibility: Registration as a Candidate Professional Quantity Surveyor in terms of Section 18 of the Quantity Surveying Profession Act 2000 (Act No 49 of 2000) (i) The curricula of all SACQSP-accredited 480-credit / NQF Level 8 quantity surveying programmes would
be accepted as the prerequisite entry-level to Candidacy (without any further Professional Skills Modules)
(ii) All other qualification programmes (whether SACQSP-accredited or not) would be analysed to ascertain
their “shortfalls” of SACQSP Professional Skills Modules
(iii) With effect from 1st January 2013, holders of all 240 credit / NQF Level 6 National Diploma in Building qualifications would not be eligible to apply for an academic registration as candidates and would require to follow the Recognised Prior Learning (RPL) route to registration.
(iv) Details of all Professional Skills Modules applicable to all tiers of registration are contained in the
prescribed Professional Skills Module Policy available on the SACQSP website.
Board Notice XXXX 2015 Page 31 of 36
THE SOUTH AFRICAN COUNCIL for the
QUANTITY SURVEYING PROFESSION
Routes To Registration for Candidate Quantity SurveyorEstablished in terms of the Quantity Surveying Profession Act 49 of 2000
Effective 1st January 2013
Entry Qualifying ProgrammeMRICS / FRICS
QS Pathway Only
Route Code 1 A 1 B 2 A 2 B 3 A 3 B 4
NQF Credit 480 360 480 360 480 360 480 Equivalent
SAQA / NQF Exit Level Level 8 Level 7 Level 8 Level 7 Level 8 Level 7 Level 8 Equivalent
Professional Skills Modules * Nil 18Programme
Dependant18
Programme
Dependant18 Nil
Minimum duration under a PrQS supervision** 3-Years 4-Years 4-Years 5-Years 4-years 5-years N/A
Maximum Candidate Registration Period *** 10-years 10-years 10-years 10-years 10-years 10-years N/A
Compulsory Interim Submission 1 off 1 off 1 off 2 off 1 off 2 off N/A
Compulsory Final Submission Yes Yes Yes Yes Yes Yes N/A
Daily Diary Yes Yes Yes Yes Yes Yes N/A
Log Book Yes 3-yr Yes 4-yr Yes 4-yr Yes 5-yr Yes 4-yr Yes 5-yr N/A
General report - current Yes 3-yr Yes 4-yr Yes 4-yr Yes 5-yr Yes 4-yr Yes 5-yr N/A
Detailed Resume' Yes
Project Report Yes Yes Yes Yes Yes Yes N/A
APC Interview Yes Yes Yes Yes Yes Yes N/A
PrQS Peer Interview Yes
Applicable to New registrations from 1st January 2013 - Approved Council Meeting 7th March 2013
Notes to Above
* If registered before 2013, the Candidate has 3-years to complete the specified list of PSM allocated per their official letter of registration
** This period may include secondment, external appointed PrQS supervision or whilst working under a PrQS in an construction company. Minimum of 12-months in RSA.
*** This period commences from date of initial registration. Candidates registered before 2007 will be given 5-years to complete their PrQS registration process.
+ Limited to BSc Construction Management and BSc Property Studies from (UP) and (UCT)
Maximum of 50% of the proven duration under PrQS Supervision may be backdated.
A c a d e m I c R o u t e SACQSP Accredited
Quantity Surveying
Degrees
SACQSP Accredited
Cognate Degrees +
Non Accredited QS
Degree
Board Notice XXXX 2015 Page 32 of 36
THE SOUTH AFRICAN COUNCIL for the
QUANTITY SURVEYING PROFESSION
Routes To Registration for RPL CandidatesEstablished in terms of the Quantity Surveying Profession Act 49 of 2000
Effective 1st January 2013
Entry QualifyingMatric + Other
Certificates
Non-QS Tertiary
Diplomas + Degrees
National Diploma in
Building
Route Code 5 6 7
NQF Credit 120 240 / 360 / 480 240
SAQA / NQF Exit Level Level 4 + 5 Level 6-8 Level 6
Professional Skills Modules * 18 18 18
Minimum duration under a PrQS supervision prior to
application*15-Years # 10-Years # 5-Years #
Additional duration under a PrQS supervision with
diaries and logbook 3-Years 3-Years 3-Years
Maximum Candidate Registration Period 5-Years 5-Years 5-Years
Compulsory Interim Submission 1 off 1 off 1 off
Compulsory Final Submission Yes Yes Yes
General report - current Yes Yes Yes
Detailed Resume' Yes 10-yr Yes 10-yr Yes 5-yr
Project Report Yes Yes Yes
APC Interview Yes Yes Yes
Applicable to New registrations from 1st January 2013 - Approved Council Meeting 7th March 2013
Notes to Above
* This period may include secondment, external appointed PrQS supervision or whilst working under a PrQS in an construction company. Minimum of 12-months in RSA.
# This period of RPL requires to be proven on application.
Recognised Prior Learning
Board Notice XXXX 2015 Page 33 of 36
ANNEXURE C - 2: SACQSP ROUTES TO REGISTRATION:
Construction Quantity Surveyor
ProgrammeNational
Diplomas in
Building
Matric +
Certificates in
Construction
Programmes
Other
Cognative
Diplomas +
Degrees
FAST TRACK
Acredited/NonAccr
edited QS Specific
Diploma/Degree
Minimum NQF Credit Level 480 360 240 360 / 480 120 240 / 360 240 / 360 / 480
SAQA / NQF Exit Level Level 8 Level 7 Level 6 Level 7 / 8 Level 4 + 5 Level 6 - 7 Level 6 - 7 - 8
Minimum duration under a CQS or PrQS prior
to application5-Years 3-Years 10-Years
Minimum duration under a CQS or PrQS as a
Candidate1-Year 2-Years 3-Years 3-Years 2-Years 2-Years Nil
Professional Skills Modules Nil 1, 2, 3, 4, 5, 17 1, 2, 3, 4, 5, 6, 17 1, 2, 3, 4, 5, 6, 17 1, 2, 3, 4, 5, 6, 17 1, 2, 3, 4, 5, 6, 17
2, 3, 4, 5, 6, 17
Interim assessment
level only
Maximum period as a Candidate to complete
professional registration3-years 5-years 5-years 5-years 5-years 5-years 3-years
Compulsory Interim Submission 1 off 1 off 1 off 1 off 1 off 1 off Nil
Compulsory Final Submission Yes Yes Yes Yes Yes Yes Yes
Daily Diary 1900 hrs 3800 hrs 5700 hrs 5700 hrs 3600 hrs 3600 hrs Nil
Log Book (Stage 3 / 4 / 5 / 6 ) Yes 1-yr Yes 2-yr Yes 3-yr Yes 3-yr Yes 2-yr Yes 2-yr Nil
General report Yes 1-yr Yes 2-yr Yes 3-yr Yes 3-yr
Yes 6-yr with
letters of
commendation
Yes 6-yr with
letters of
commendation
Yes 10-yr with letters
of commendation
R P L
SACQSP Accredited
Quantity Surveying Degree
(BTech / BSc)
Non Accredited
QS Degree
ACADEMIC
Board Notice XXXX 2015 Page 34 of 36
Upgrade from RCQS to PrQS Registration
R P L
ProgrammeMatric +
Certificates
Minimum NQF Credit Level 480 360 N / A
SAQA / NQF Exit Level Level 8 Level 7 N / A
Minimum duration as a registered Construction
Quantity Surveyor prior to application2-Years 2-Years 2-Years
Minimum duration under a PrQS as a Candidate 2-Year 2-Years 2-Years
Additional Professional Skills Modules to be
completedNil
7, 8, 9, 10, 11,
12, 13, 14, 15,
16, 18
7, 8, 9, 10, 11,
12, 13, 14, 15,
16, 18
Maximum period as a Candidate to complete
professional registration5-years 5-years 5-years
Compulsory Interim Submission (12-month) 1 off 1 off 1 off
Compulsory Final Submission Yes Yes Yes
Daily Diary 3800 hrs 3800 hrs 3800 hrs
Log Book Yes 2-yr Yes 2-yr Yes 2-yr
General report Yes 2-yr Yes 2-yr Yes 2-yr
Project Specific Report Yes Yes Yes
APC Interview Yes Yes Yes
ACADEMIC
SACQSP Accredited
Quantity Surveying Degree
(BTech / BSc)
Board Notice XXXX 2015 Page 35 of 36
ANNEXURE C - 3: SACQSP ROUTES TO REGISTRATION:
TECHNICIAN QUANTITY SURVEYOR
Board Notice XXXX 2015 Page 36 of 36
ANNEXURE D:
ACCREDITED QS PROGRAMMES OFFERED BY TERTIARY INSTITUTIONS IN SOUTH AFRICA:
1.0 UNIVERSITIES QUALIFICATIONS OFFERED NQF CREDITS
1.1 Cape Town BSc (Construction Studies)
BSc (Hons) Quantity Surveying
360
480
1.2 Free State Certificate in Quantity Surveying (QCP)
BSc (Quantity Surveying)
BSc (Hons) Quantity Surveying
240
360
480
1.3 Johannesburg National Diploma (Building) - up to 2015
B-Tech (Quantity Surveying) - up to 2015
240
360
1.4 KwaZulu-Natal BSc (Quantity Surveying) - up to 2014
BSc (Hons) Quantity Surveying - up to 2014
360
480
1.5 Nelson Mandela
Metropolitan
National Diploma (Building)
B-Tech (Quantity Surveying)
BSc (Construction Economics)
BSc (Construction Studies)
BSc (Hons) Quantity Surveying
240
360
360
360
480
1.6 Pretoria BSc (Quantity Surveying)
BSc (Hons) Quantity Surveying
360
480
1.7 Walter Sisiulu National Diploma (Building)
National Diploma (Extended Programme)
120
240
1.8 Witwatersrand BSc (Construction Studies)
BSc (Hons) Quantity Surveying
360
480
2.0 UNIVERSITIES OF
TECHNOLOGY
2.1 Durban National Diploma (Building)
B-Tech (Quantity Surveying)
240
360
2.2 Mangosuthu National Diploma (Building) - up to 2016 240
2.3 Tshwane National Diploma (Building)
B-Tech (Quantity Surveying)
240
360
2.4 Central National Diploma (Building)
B-Tech (Quantity Surveying)
240
360
2.5 Cape Peninsula National Diploma (Building)
B-Tech (Quantity Surveying)
240
360