Download - MANUAL / SPECIFICATIONS FOR . WESTON HIGH SCHOOL STADIUM FIELD . ARTIFICIAL TURF REPLACEMENT . WESTON HIGH SCHOOL . 115 School Road . Weston, CT 06883 . WESTON PUBLIC SCHO

PROJECT MANUAL / SPECIFICATIONS

FOR

WESTON HIGH SCHOOL STADIUM FIELD ARTIFICIAL TURF REPLACEMENT

WESTON HIGH SCHOOL 115 School Road Weston, CT 06883 WESTON PUBLIC SCHOOLS 24 School Road Weston, CT 06883 BID# 18-002 - BOE ARCHITECT KAEYER, GARMENT + DAVIDSON

ARCHITECTS, PC 285 Main Street Mount Kisco, NY 10549

BID ISSUE DATE 2 April 2018 THE UNDERSIGNED CERTIFIES THAT TO THE BEST OF HIS KNOWLEDGE, INFORMATION AND BELIEF, THE PLANS AND SPECIFICATIONS ARE IN ACCORDANCE WITH APPLICABLE REQUIREMENTS OF THE CONNECTICUT STATE UNIFORM FIRE PREVENTION AND BUILDING CODE, THE STATE ENERGY CONSERVATION CONSTRUCTION CODE, AND BUILDING STANDARDS OF THE EDUCATION DEPARTMENT, AND THE PLANS AND SPECIFICATIONS REQUIRE THAT NO ASBESTOS CONTAINING MATERIAL SHALL BE USED. _____________________________ Erik A. Kaeyer, AIA, LEED AP

SPECIFICATIONS AND BID FORMS FOR

WESTON HIGH SCHOOL STADIUM FIELD ARTIFICIAL TURF REPLACEMENT

MANDATORY WALK-THRU ON MONDAY, 4/9/18 @ 10:00 A.M.

AT CENTRAL OFFICE ANNEX CONFERENCE ROOM,24 SCHOOL ROAD, WESTON, CT

BID: #18-002- BOE

Due on or before 10:00 A.M. ON FRIDAY, APRIL 20, 2018 at the:

OFFICE OF THE PURCHASING COORDINATOR

CENTRAL OFFICE

WESTON BOARD OF EDUCATION

24 SCHOOL ROAD

WESTON, CONNECTICUT 06883

203 291-1418/FAX 203 291-1420

Sealed bids will be received by the Purchasing Coordinator for the Board of Education of the Town of Weston, Connecticut, until 10:00 A.M. FRIDAY, APRIL 20, 2018 at which time bids for WESTON HIGH SCHOOL STADIUM FIELD ARTIFICIAL TURF REPLACEMENT are due. Each bid should be clearly marked: BID #18-002-BOE.

All bids must be submitted on the forms provided and shall include all firm names, signatures, addresses, and other information required. Each bid must be signed by an authorized representative of the company, placed in a sealed envelope, and identified as a bid giving the name of the company and the bid number and filed with the school district's business office no later than the date and time specified.

The Weston Board of Education reserves the right to accept or reject any and/or all bids. The Weston Board of Education shall be under no obligation to accept the lowest financial bid if it is deemed in the best interest of the school system.

The Weston Board of Education may make such investigations as it deems necessary to determine the ability of a Bidder to perform the work. The Bidder shall furnish all information and data for this purpose as the Weston Board of Education may request. The Weston Board of Education reserves the right to reject any bid if evidence submitted by the Bidder or investigation of the Bidder fails to satisfy the Board that the Bidder is properly qualified to carry out the obligations of a contract resulting from this bid. Bidder is also requested to provide an audited statement of the financial conditions of the company.

No bidder may withdraw his bid for a period of forty-five days after the opening date.

The bidder is to clearly state in the bid exactly what is intended to be furnished and is to furnish with the bid an illustration or other descriptive material which will clearly indicate what will be furnished. Samples are to be submitted upon request.

Any alleged oral agreement or arrangement made by a bidder or contractor with any agency or any employee of the Weston Board of Education will be disregarded.

RETURN ONE COPY OF BID

DO NOT FAX BID

SPECIFICATIONS AND BID FORMS

BID: #18-002-BOE

FOR: WESTON HIGH SCHOOL STADIUM FIELD ARTIFICIAL TURF REPLACEMENT

The Director of Finance and Operations reserves the right to award by item, or part thereof, groups of items, or parts thereof, or all items of the bid, and to award contracts to one or more bidders submitting identical proposals as to prices; to reject any and all bids in whole or in part; to waive technical defects, irregularities, and omissions if, in his judgment, the best interest of the Board will be served.

The Weston Board of Education reserves the sole and absolute right to reject any proposal offering services which, in its opinion, does not meet the standard of quality established by these specifications.

The Board of Education of the Town of Weston is exempt from the payment of taxes imposed by the Federal Government and/or the State of Connecticut, including the Federal Transportation Tax. Such taxes should not be included in any bid price involving the payment of funds from the district.

The contractor must protect all floors, furniture, cabinets, etc., from injury or other damage. Any damage so caused must be repaired by the contractor at its own expense. At the completion of the work, the contractor must remove from the premises all surplus materials and all debris resulting from the work. Furthermore, the premises must be left in a clean and finished condition acceptable to the owner or its agent.

The quantities listed in these specifications may be increased or decreased by the Weston Board of Education, depending upon its actual requirements.

Bidders shall indicate how many days after receipt of the order the Board can expect delivery of merchandise. At the Board’s request, contractors are required to provide written estimated delivery times once an order has been placed with a contractor. The contractor is responsible for notifying the ordering agency at least forty-eight (48) hours in advance of shipment.

Deliveries shall be made as specified by the ordering agency during normal business hours. All items shall be delivered and set-up at the location specified by the ordering agency in accordance with good commercial practice.

All contractors and vendors will be required to comply with all provisions of the Civil Rights Act of 1964, Executive Order 11246 of September 24, 1965, the Connecticut Fair Employment Practices Act and all of the rules, regulations, and relevant orders of the Secretary of Labor (or other authorized agent or agency), as amended.

In accordance with Public Act No. 366, the Contractor and each subcontractor shall agree and warrant that in the performance of this contract, it will not discriminate or permit discrimination against any person or group of persons on the grounds of race, sex, color, religion or national origin, in any manner prohibited by municipal, state or federal law.

All equipment furnished and work performed must meet Federal OSHA (Occupational Safety and Health Act) and CSA (Construction Safety Act) standards as amended.

The bidder is assumed to have made himself familiar with all Federal and State Laws and all local bylaws, ordinances, and regulations which in any manner affect those engaged or employed on the work, or the materials or equipment used in the work, or in any way affect the conduct of the work, and no pleas of misunderstanding will be considered on account of ignorance thereof.

SPECIFICATIONS AND BID FORMS

BID: #18-002-BOE Page 3


If bidder shall discover any provisions in the Bid Specifications which are in conflict with any such law, bylaw or ordinance or regulation, he shall forthwith report it to the Owner's Representative in writing at once.

Specifications, instructions, and bid forms may be obtained at the Business Office, Weston Board of Education.

Amendments to or withdrawals of bids received later than the time and date set for bid opening will not be considered.

Bids must be submitted on proposal schedule forms attached hereto. Bids received later than the time and date specified will not be considered.



Additional specifications for construction or service contracts:

1. All bidders are to furnish a bid bond in the amount of not less than 5% of the total estimated bid as bid security. The surety on the bid bond must be a corporate surety licensed to sign surety bonds in the State of Connecticut and also listed by the United States Treasury Department in its latest list as a qualified surety acceptable to the United States Government.

2. Upon the execution of the contract, the contractor shall furnish a performance and labor and material bond in an amount at least equal to 100% of the total estimated contract price as security for faithful performance of the contract and for the payment of all persons performing labor or furnishing materials in connection with the contract. The surety on the bond must be a corporate surety and must meet the requirements stated relative to the bid bond except that the amount of the bond may exceed the limit for which the United States Treasury Department has qualified the surety if the excess is reinsured with surety companies that are qualified on the United States Treasury Department list for an amount equal to the amount of the reinsurance. Written evidence of how any excess suretyship has been placed by the surety signing the bond must accompany the bond.

3. All bidders must comply with all applicable federal, state, and local laws, rules and regulations of all authorities having jurisdiction over the work in the locality of the project, including but not limited to state wage rates as applicable.

4. The contractor shall carry Worker's Compensation Insurance in accordance with the laws of the State of Connecticut, and all other applicable laws and regulations, for all of his employees engaged in work under the contract. If any work is sublet, the contractor shall require the subcontractor to provide Worker's Compensation Insurance for all of the latter's employees engaged in such work unless such employees are covered by the protection afforded by the contractor's Worker's Compensation Insurance and the certificate of insurance furnished by the contractor so stipulates.

5. The contractor shall carry comprehensive General Liability and Automobile Liability insurance limits in amounts not less than $l,000,000 per occurrence as a Combined Single Limit for Bodily Injury, Personal Injury and Property Damage. Prior to commencing work, the contractor shall furnish the Board of Education with proof of such coverage and will include the Town of Weston/Weston Board of Education as additional insureds with regard to this work. Additionally, the comprehensive general liability coverage must contain a Per Job Site Aggregate Limit endorsement. If any work is sublet, the contractor shall require the subcontractors to provide comprehensive General Liability and Automobile liability coverage in the same limits as for the contractor, with the same Per Job Site Aggregate Limit endorsement and furnish satisfactory proof to the Board of Education, prior to inception of any work, that these insurance requirements have been met.


FOR: WESTON HIGH STADIUM FIELD ARTIFICIAL TURF REPLACEMENT

6. The contractor shall make all needed repairs in the work covered by the contract, due to defective workmanship or materials, during a period of one year after the date of completion of the work by the contractor. During this period of one year, the contractor agrees that the Board of Education may retain from the monies payable to him the sum of 5% of the total amount of the contract. In lieu of the retained 5%, the contractor may choose to furnish a guarantee bond for the equivalent amount. The Board of Education may expend the same or as much thereof as may be required in making the aforesaid repairs to the satisfaction of the Board of Education, if within 10 days after the mailing or delivery of a notice in writing by the Board of Education to the contractor, he shall fail to make the aforesaid repairs; provided, however, that in case of an emergency where, in the opinion of the Board of Education, delay would cause serious loss or damage, the Board of Education may make repairs without previous notice and at the expense of the contractor. At the end of this one-year period, the balance of the retained 5% shall be paid or the bond returned to the contractor, provided all of the terms of the contract shall have been fulfilled. When required by the Director of Finance and Operations for the Board of Education, the Contractor shall furnish satisfactory evidence that he has satisfied all just claims for labor performed or materials furnished for or in the use of the work herein specified; in the absence of such evidence, the Director of Finance and Operations for the Board of Education shall have the right to retain sufficient funds to pay all just claims.

A 5% SECURITY BOND OR CHECK MUST BE INCLUDED WITH THE BID.

Bid #18-002-BOE Page 6

FOR: WESTON HIGH STADIUM FIELD ARTIFICIAL TURF REPLACEMENT

FOR PDF COPY OF BID SPECIFICATIONS CONTACT

A. GALLI @ 203 291-1407


BID SHEET

DELIVERY BEFORE: _____________________________________________________________

PRICES WILL HOLD UNTIL: _______________________________________________________

BIDDER NAME: ________________________________________________________________

BIDDER ADDRESS: _____________________________________________________________

NAME: SIGNATURE:______________________________

TITLE: DATE:____________________________________

TELEPHONE: __________________________ FAX: ____________________________________

E-MAIL: _________________________________________________________________________

RETURN ONE COPY OF BID

DO NOT FAX BID

BID ENVELOPE MUST BE MARKED WITH BID NUMBER.

9 March 2018 Weston Public SchoolsBID ISSUE Turf Field Replacement

Weston High School

KGD2018-1010 00 21 00 - 1 Invitation/Instructions

SECTION 00 21 00

INVITATION AND INSTRUCTIONS TO BIDDERS

1.01 OWNER, PROJECT, ARCHITECT, BID PROCEDUREA. The Owner, Weston Board of Education, invites sealed bids for the synthetic turf field

replacement at Weston High School, 115 School Road, Weston CT all as described in the accompanying contract documents as prepared by KG+D Architects, PC; 285 Main Street; Mt., Kisco, New York 10549.

B. Bids shall be received in accordance with the Connecticut State Public Bidding Laws, this project will be executed under A SINGLE PRIME CONTRACT.

C. The attention of all bidders is directed to the fact that a single set of documents exist for the construction of the Project as a whole. Work on each sheet, or within any technical specification section may or may not have an effect on the work of any single Contractor. Failure on the part of any Contractor to examine all documents will not be cause for additional cost to the Owner.

1.02 DISCREPANCYA. Should any bidder find any discrepancies in, or omission from, the Bidding Documents, or

should the bidder be in doubt as to the meaning of any portion of said documents, they shall at once notify the Architect and obtain an interpretation or clarification prior to submission of their bid.

B. Any request for interpretation or clarification shall be in writing and directed to Joe Reilly at KG+D Architects, P.C. via email to [email protected].

C. The bidder may, during the bidding period, be advised by addendum of additions, deletions, or alterations in any of the documents forming a part of this Contract. All such additions, deletions or alterations shall be included in the work covered by the bid and shall become a part of this Contract.

Upon such mailing or delivery and making available for inspection, such addendum shall become a part of the Bidding Documents and the Contract Documents and shall be binding on all Bidders whether or not the Bidder receives or acknowledges the actual notice of such addendum.

The requirements contained in all Bidding Documents shall apply to all addenda.

All interested Bidders shall register with the Owner by submitting to Andrew Galli at the District Business Office the bidder’s name, address and valid email address. All communications from the Owner or the Architect during the bid process shall be delivered via email to the email address provided by the bidder per such registration.

CUTOFF DATE FOR RECEIPT OF REQUESTS FOR INFORMATION (RFI’S) SHALL BE 7

WORKING DAYS PRIOR TO DESIGNATED DATE FOR RECEIPT OF BIDS.

D. Only interpretations, corrections or additional Contract provisions made in writing by the Architect as addenda shall be binding. No officer, agent or employee of the Owner or the Architect is authorized to explain or to interpret the Contract Documents by any other method and any such explanation or interpretation, if given, shall not be relied upon by the Bidder.

1.03 REPRESENTATION - Each bidder, by making their bid, represents that -A. They have read and understands the Bidding Documents. The “Bidding Documents” shall


Weston High School


include this Request for Proposal, the Project Manual, Drawings, Specifications, and Addenda (if any)) and their Bid is made in accordance therewith.

B. They have visited the site and have familiarized themselves with the conditions under which the work is to be performed.

C. All materials to be incorporated in the work shall be "asbestos free" in their manufacture.D. Their Bid is based upon the materials, systems and equipment described in the Bidding

Documents WITHOUT EXCEPTION.

1.04 DOCUMENTSA. Bidders may obtain the Bidding Documents at the office of the Admin. Asst. Finance, Ops &

Tech: Andrew Galli at the District Business Office; 24 School Road; Weston, CT 06883 after 4:00 PM on 2 April, 2018. The Bidding Documents and all Addenda shall also be available on the Owner’s website at www.westonps.org

B. Refundable document cost - $50.00 total; cash or check made payable to the Owner. Deposit, for the initial sets, will be refunded to all qualified bidders returning plans and specifications in good condition within ten (10) days after the date set for opening of bids.

C. Additional copies of the documents will be available from the designated printer and at the non-refundable cost of reproduction.

1.05 INFORMATIONAL MEETING - All bidders are advised that a informational meeting will be held as follows:A. Date – Monday, 9 April, 2018 B. Local Prevailing Time – 10:00 AMC. Location – Central Office Annex Conference RoomD. Any and all questions that may arise as a result of this meeting will be recorded and

answered by the Addendum process.

NOTE: ALL BIDDERS WILL BE PRESUMED TO HAVE FULL KNOWLEDGE OF THE SITE, AND

ALL INFORMATION AVAILABLE AT THE PRE-BID WALK THROUGH. NO EXTRA COST OR

TIME EXTENSIONS WILL BE GRANTED BECAUSE OF LACK OF KNOWLEDGE OF ON SITE

CONDITIONS, APPARENT, OR DATA AVAILABLE DURING THE WALK THROUGH.

1.06 BIDDINGA. Sealed bids, will be received at the District Business Office; 24 School Road; Weston, CT

06883; directed to the attention of the Director of Finance and Operations: Richard Rudl, on or before 20 April, 2018 until 10:00 A.M., Local Prevailing Time at which time all bids will be opened publicly and read.

B. All bids shall be submitted in duplicate on the Proposal Forms provided within the specifications and shall be submitted in an opaque sealed envelope with the following contained thereon:1. Project Name.2. Bid Number - #18-002-BOE3. Name of Bidder.4. Mark “SEALED BID”.

C. All spaces on Proposal Form must be completed. All signatures shall be in ink and in longhand.

D. No oral or telephonic proposals or modifications of proposals will be considered.E. Any proposals containing exceptions or modifications may, at the Owner's option, be

disqualified.

1.07 QUALIFICATIONS OF BIDDERA. The Owner may make such investigation as the Owner deems necessary to determine the

responsibility of any Bidder or to determine the ability of any Bidder to perform the Work.


Weston High School


B. Bidders shall furnish to the Owner all information and data required by the Owner, including complete financial data, within the time and in the form and manner required by the Owner.

C. The Owner reserves the right to reject any bid if the evidence required by the Owner is not submitted as required or if the evidence submitted by or the investigation of any Bidder fails to satisfy the Owner that the Bidder is responsible, and is able or qualified to carry out the obligations of the Contract or to complete the Work as contemplated.

1.08 POST BID PROCEDURES

The Owner reserves the right to amend or withdraw this RFP for any reason, to waive

technical defects, irregularities, and non-material deficiencies in Bid submissions, to reject

any and all Bids, in whole or in part, to accept a Bid or a part of the Bid, even though such

Bid is not the low Bid, and to award or not award a contract in connection with this RFP, all

as determined by the Owner in its discretion to be in the best interest of the Owner.

Any or all Bids may be rejected if there is any reason to believe that collusion exists among

two or more Bidders. Individual Bids may be rejected for irregularities of any kind, including

without limitation, alteration of form, additions not called for, conditional Bids, incomplete

Bids, or unexplained erasures. Individual Bids may also be rejected if, in the opinion of the

Owner, such Bid does not meet the standard of quality established by the Biding Documents.

The foregoing provisions are for illustrative purposes and shall in no way limit the right of the

Owner to reject any and all Bids, in whole or in part.

A. It is the intent of the Owner to award the Contract to the Bidder whose bid meets the requirements, terms and conditions contained in the Bidding Documents and is the lowest among those bidders possessing the skill, ability and integrity necessary for faithful performance of the Work based on objective criteria considering past performance and financial responsibility (the "Lowest Responsible Qualified Bidder").

Selection Criteria In determining the Lowest Responsible Qualified Bidder the Owner will consider the following criteria, as applicable:(1) The ability and capacity of the Bidder to perform the work based on an evaluation of the character, integrity, reputation and experience of the Bidder. Consideration shall be given to previous work performed by the Bidder for the Owner or for other agencies, including the quality and degree of satisfaction with the work performed.(2) The financial resources of the Bidder and the Bidder's ability to secure therequired bonds and/or insurance.(3) Compliance by the Bidder with all applicable federal, state and local laws,including any licensing requirements.(4) Delivery or completion time.(5) Cost.(6) Involvement in litigation.

The responsibility of bidders and of their proposed subcontractors will be considered inmaking the award. The Owner through the Architect may, but shall not be required to, make such investigation as the Owner deems necessary to determine the responsibility and qualifications of any bidder or to determine the ability of any bidder to perform the Work.

B. To assist the Owner in determining whether a Bidder is responsible and qualified, each Bidder shall include as part of its bid submission the following information, documents and data in the form and as required below:


Weston High School


1. A signed and notarized bidder qualification statement (see section 00 45 13;2. The names, addresses and phone numbers of the subcontractors and suppliers

that the bidder proposes to use on the project;3. The bidder's proposed site safety plan;4. A bar chart (see paragraph 1.03, Section 01 32 00 of the General Requirements)

showing the bidders' proposed plan and schedule to complete the bidder's work inaccordance with the phasing milestones outlined in Section 01 10 00;

5. The insurance certificates required by the Bid Documents;6. A proposed schedule of values for the Bidder's work;7. A proposed list of submittals and a proposed schedule for making them, all keyed to

the bar chart.8. A detailed “certified” financial statement showing assets, liabilities and net worth of

the Bidder as of the time not less than six (6) months prior to the date of the openingof bids for this work. (NOTE: This requirement may be waived, at the option of the Owner, based upon size and complexity of the subject project).

C. After receipt of the bid submissions, one or more Bidders may be requested by the Owner or the Architect to attend an interview for the purposes of discussing the Bidder's responsiveness, responsibility and qualifications.

D. The Owner reserves the right to disapprove the use by a Bidder of any of its proposed Subcontractors and in such event such Bidder shall submit the name of another Subcontractor in like manner within the time specified by the Architect.

E. Bids may not be withdrawn for 45 days after the opening of bid submissions.

F. Award of a contract in connection with this RFP will be by delivery of written notice signed by a duly authorized representative of the Owner.

G. The successful Bidder will be obligated to sign a Contract in substantially the form included in this RFP as Section 00 70 00, as such form of Contract may be modified by the Owner, within ten (10) days after the Contract in executable form is presented to the successful Bidder.

1.09 APPROVAL OF SUBCONTRACTORSA. When requested by the Owner, Bidders shall, within the time specified by the Owner, submit

to the Owner the names of the Subcontractors which the Bidder proposes to use on the project.

1.10 SECURITY AND BONDS (Coordinate with Section 00 61 00)A. Every bid shall be accompanied by a Bid Bond in the amount of 10 percent of the Contract

Sum drawn by a recognized surety authorized to conduct business in the State of Connecticut and made payable to the Owner. 1. Bid Security shall be submitted in a separate sealed envelope clearly identifying the

company and project as well as the name and address of the Surety Company. 2. Each Bond must be accompanied by a Power of Attorney, giving names of

Attorneys-in-fact, and the extent of their bonding authority. All bonds shall be countersigned by a resident Agent and with a Surety Company or Corporation meeting the following qualifications: a. Surety must be licensed to do business in the State of Connecticut. b. Surety shall be listed on the current U.S. Treasury Department Circular 570

entitled “Companies Holding Certificates of Authority” from the Secretary of


Weston High School


the Treasury under the Act of Congress approved July, 30, 1974 (6 U.S.C., Sec. 6-13), as Acceptable Sureties on Federal Bonds.

c. Surety must meet minimum rating requirements as published in current “Best’s Key Rating Guide” as listed below: 1. For contracts not exceeding $250,000, the following shall apply for

all bonding companies holding a certified guarantee agreement form, the Small Business Administration (a copy of said agreement must accompany the bond.)

Contract Amount Financial Size Category

Policy Holder Rating

$0- (But not including) $100,000

Class VI B

$100,000-(But not including) $250,000

Class X A-

2. On all bonds, the Surety shall be rated as equal to “A-” or better as to “Policy Holder Ratings” and “X” or better as to “Financial Size Category” by “Best’s Key Rating Guide.”

3. Limitations:a. Bonding limits or bonding capacity refers to the limit or

amount of bond acceptable on any one project. b. The bonding limit for each contractor shall not exceed the

amount listed on the above referenced U.S. Treasury Department List for the Surety issuing the bond.

4. All Surety companies are subject to approval and may be rejected by the Owner without cause, in the same manner that bids may be rejected.

5. Compliance: In the event any of the requirements outlined herein are not complied with, the Owner shall have the right to reject the bid or annul the Award of the Contract.

B. Remaining Bid security will be returned to bidders after Owner and successful bidder have executed the Contract and the Owner has received and approved performance and payment bonds.

C. If the required Contract has not been executed within 45 days after the bid opening, bid security of any bidder will be returned upon Bidder’s request, provided Bidder has not been notified of acceptance of it’s bid prior to the date of such request.

D. Separate Performance and Payment Bonds will be required for the work. Each shall be in the amount of 100% of the Contract sum.

E. The Contractors shall include in their proposal amounts of the total premiums for the performance and labor and material payment bonds.

1.11 TAX STATUS (Coordinate with Article 3.6 of Section 00 70 00)A. The Owner is "tax-exempt" in accordance with the applicable laws of the State of

Connecticut and with Chapter 32 of the Internal Revenue Code, as most recently amended, for collection of all sales and excise taxes.

B. Exemption Certificates will be furnished to the Contractor.

1.12 INSURANCEA. Insurance as required by Article 11 of the General Conditions and identified in Section 00 70

02 shall be required of each successful Bidder and shall be of forms and limits required therein.


Weston High School


1.13 AWARD OF CONTRACTA. This notice is an offer to receive proposals for a contract and not an offer of a contract. B. Alternates, if stated in the Proposal Form, shall be chosen at the discretion of the Owner

when awarding the Contract. The lowest bid will then be determined by adding to, or subtracting from, to the bidder's total base bid, all Alternates chosen by the Owner.

C. The Bidder agrees to commence work as provided in Owner’s Notice to Proceed, Letter of Intent, and/or Execution of Contract whichever is earlier.

D. The Owner reserves the right to reject any bid or all bids, to waive any informalities or irregularities or omissions in any bid received or to afford any Bidder an opportunity to remedy any informality or irregularity if it is in the Owner's interest to do so.

1.14 LAWS AND REGULATIONSA. All applicable Federal, State, County, Municipal or other laws, orders, ordinances, rules and

regulations of all authorities having jurisdiction over construction work in the locality of the project shall apply to the Contract and shall be deemed to be included in the Contract as if fully set forth therein at length.

1.15 ARREARSA. No bids will be accepted from, or contracts awarded to any Bidder that is in arrears to the

Town of Weston upon debt, or contract, or who is a defaulter as surety or otherwise upon obligations to the Town of Weston.

1.16 NONDISCRIMINATIONA. Notwithstanding implementation of the Owner's Affirmative Action Plan, if any, all

Contractors and Subcontractors of all tiers and vendors will be required to comply with all provisions of the Civil Rights Act of 1964, Executive Order 11246 of 24 September 1965 and the relevant "Laws", "Acts" rules, regulations and orders of the Labor Department of the State of Connecticut as amended.

1.17 TIME OF COMPLETION AND LIQUIDATED DAMAGESA. Work set forth in the Contract Documents shall be commenced as stated in written Notice to

Proceed, and shall be completed within stipulated period of time set forth in Section 01 10 00.

B. Liquidated Damages may be assessed for each and every calendar day that the work is not complete, after the above stated time for total completion of the work at the rate of set forth in the Contract.

**End of Invitation and Instructions**


Weston High School

KGD2018-1010 00 41 00 - 1 Proposal Form

SECTION 00 41 00

PROPOSAL FORMPROJECT: Weston High School

Synthetic Turf Replacement and Related Work

DATED: __________________________

To: Weston Public SchoolsDistrict Business Office24 School RoadWeston, CT 06883

Attn: Jo-Ann Keating, Ed. D.; Director of Finance and Operations

The Undersigned, in compliance with the Invitation and Instructions to Bidders, agrees that if this bid is accepted as hereinafter provided he/she will provide all labor, materials, supplies, tools, plant and equipment necessary to perform all work required for the construction of the aforementioned project in accordance with documents as prepared by Kaeyer, Garment & Davidson, Architects, PC; 285 E. Main Street; Mount Kisco, NY 10549; Telephone: 1-914-666-5900 for the following LUMP SUM COST and RELATED ALTERNATES:

TURF REPLACEMENT AND RELATED WORK

_______________________________________________________________________________

___________________________________________________Dollars ($_________________)

Name of System Offered _________________________________

________________________________________________________

Turf Alternate #1 - The Contractor shall provide a warranty to the Owner that covers defects in materials and workmanship of the turf for a supplemental period of four (4) years in addition to the base required eight (8) year guarantee from the date of substantial completion. The 3rd party insured warranty will be in place for the first 8 years of the 12 year manufacturer warranty.

_______________________________________________________________________________

_________________________________________________Dollars ($___________________)

Further, the undersigned: provides the unit prices indicated on the attached schedule for designated work. These unit prices

shall be for additions to or deletions from the work to be performed under the basic Contract during the entire life of said Contract but shall be considered as payment forms ONLY and not for the purposes of determining contract award.

agrees to the stated percentages for extra work if ordered on a Time and Material basis in accordance with Article 7 of the Conditions to cover all overhead and profit allowance.

Takes notice of the time constraints set forth in Section 01 10 00 and agrees to the terms of the Contract that will be enforced should the time constraints not be adhered to.


Weston High School


Upon notification of acceptance of this proposal, the undersigned agrees to execute a Contract in the form as stated within these Contract Documents for the amount stated.

Prices quoted shall be guaranteed for forty five (45) days after opening of bids.

If Notice of Award is received within forty five (45) calendar days after the opening of bids, the undersigned agrees to execute said contract and furnish to the Owner within ten (10) days after receipt of said notice of award, the executed Contract, together with the Performance Bond, Labor and Material Payment Bonds and Insurance Certificates required herein.

The Undersigned agrees that the Bid Security payable to Owner accompanying this proposal is left in escrow with the Owner; that its' amount is the measure of liquidated damages which the Owner will sustain by the failure of the Undersigned to execute and deliver the above named Bonds and Contract; and that if the undersigned defaults in furnishing said bonds or in executing and delivering said Contract within ten (10) days of written notification of award of the Contract to him/her, then said Security shall be payable to the Owner for its' own account; but if this proposal is not accepted within said forty five (45) days of the time set for submission of Bids, or if the Undersigned executes and delivers said bonds and Contract, the Bid Security shall be returned to the Undersigned.

The following Addenda have been received. The noted modifications to the Bid Documents have been considered and all costs are included in the Bid Sum.

Addendum Date Acknowledgment

The Undersigned has included with this Bid attachments noted:1. Attachment #1: Schedule of Unit Prices

By submission of this Proposal, the undersigned acknowledges that they have read the milestone and schedule requirements, Section 01 10 00, and agrees to provide sufficient staff and organization as well as to select subcontractors, suppliers and vendors to comply with the requirements for submittals, delivery dates, work periods and completion dates as specified.

The Undersigned hereby certifies that they are able to furnish labor that can work in harmony with all other elements of labor employed or to be employed on the Work.

NON-COLLUSIVE AFFIDAVIT

I state that I am the_______________________ of ____________________________and that I am authorized to make this affidavit on behalf of my firm, and its owners, directors, and officers. I am the person responsible in my firm for the price(s) and the amount of this bid.

I further state that:

1. The price(s) and amount of this bid have been arrived at independently and without consultation communication or agreement with any other contractor, bidder/proposer or potential bidder/proposer.


Weston High School


2. Neither the price(s) nor the amount of this PROPOSAL, and neither the approximate price(s) nor approximate amount of this PROPOSAL, have been disclosed to any other firm or person who is a bidder/proposer or potential bidder/proposer, and they will not be disclosed before PROPOSAL opening.

3. No attempt has been made or will be made to induce any firm or person to refrain from bidding/proposing on this contract, or to submit a bid/proposal higher than this PROPOSAL, or to submit any intentionally high or noncompetitive PROPOSAL or other form of complementary PROPOSAL.

4. I fully understand that more than one offer from an individual, firm partnership; corporation or association under the same or different name will be rejected. Reasonable grounds for believing that a bidder/proposer is interested in more than one PROPOSAL for the work contemplated may cause rejection of all PROPOSAL in which the bidder/proposer is interested. Any or all bidders/proposers will be rejected if there is any reason for believing that collusion exists among the bidders/proposers. Participants in such collusion may not be considered in the future offers for the same work. Each bidder/proposer by submitting a bid/proposal certifies that it is not a part to any collusive action.

5. The PROPOSAL of my firm is made in good faith and not pursuant to any agreement or discussion with, or inducement from, any firm or person to submit a complementary or other noncompetitive bid/proposal.

6. (Firm Name)______________________________________ its affiliates, subsidiaries, officers, directors and employees are not currently under investigation by any governmental agency and have not in the last four years been convicted or found liable for any act prohibited by State or Federal law in any jurisdiction, involving conspiracy or collusion with respect to bidding/proposing on any public contract, except as follows:

I state that, I __________________________, understands and acknowledges that the above representations are material and important, and will be relied on by Weston Public Schools in awarding the bid/proposal for which this is submitted. I understand and my firm understands that any misstatement in this affidavit is and shall be treated as fraudulent concealment from Weston Public Schools of the true facts relating to the submission of bids/proposals for this contract.

7. In submitting this bid/proposal, the undersigned declares that this is made without any connection with any persons making another bid/proposal on the same contract; that the bid/proposal is in all respects fair and without collusion, fraud or mental reservation; and that no official of the Town, or any person in the employ of the Town, is directly or indirectly interested in said bid/proposal or in the supplies or work to which it relates, or in any portion of the profits thereof.

8. The undersigned further understands that the above declarations are material representations to the Weston Board of Education made as a condition to the acceptance of the bid/proposal. If found to be false, the Weston Board of Education retains the right to reject said bid/proposal and rescind any resultant contract and/or purchase order and notify the undersigned accordingly, thereby declaring as void said bid/proposal and contract or purchase order.

9. By signing this proposal the proposer understands and agrees to the attached terms, conditions, and specifications, including Collusion among Proposers. Employment Discrimination by the Contractor Prohibited.


Weston High School


Further, by submission of this Proposal each bidder and each person signing on behalf of any bidder certifies, and in the case of a joint bid

each party thereto certifies as to its own organization, under penalty of perjury, that to the best of its knowledge and belief that each bidder is not on the list created pursuant to paragraph (b) of subdivision 3 of Section 165-a of the state finance law.”

the Undersigned acknowledges that they have visited the site, informed themselves of the existing conditions, and have included in the Proposal a sum to cover the costs of all items in the contracts.

Respectfully submitted,

______________________Contractor

By___________________________________Title__________________________

Business Name:______________________________________________________

Address:____________________________________________________________

Telephone Number:___________________________________________________

Attest:________________________________Title________________________

License Number:_____________________________________________________

SEAL IF CORPORATION


Weston High School


ATTACHMENT #1 - SCHEDULE OF UNIT PRICES

In accordance with the terms and conditions of the Contract and as part of the base proposal, the undersigned agrees to the following unit prices for designated work as described in the respective Specification Sections which shall be considered as payment forms and not for purpose of determining contract award.

Unit Price #1 Edge Restoration - 150 Lineal Feet deemed included in the Base Bid

$_______________/LF

Unit Price #2 Repair of Existing Base/Subbase as may be required to permit new field installation on a CY basis for new stone and compacted; 10 cy are deemed to be in included in the base bid.

$______________/CY

**End of Unit Price Schedule**

Contractor Attestment To Schedule

Contractor ____________________________________________________________________

By ____________________________________________________________________________

Dated _________________________________________________________________________

**End of Proposal Form**


Weston High School

KGD2018-1010 00 45 13 - 1 Qualification Statement

SECTION 00 45 13

BIDDER QUALIFICATION STATEMENT

After receipt of bids and upon notification from the Architect, the bidder shall answer all questions set forth

in the form within the time required in Article 1.07 of the Invitation and Instructions to Bidders. Failure to

answer these questions in full may be cause for rejection of the bidder's proposal. If more space is

required, please attach additional sheets.

1. How many years has your organization been in business under your present business name?

___________________________________

2. How many years experience in construction work of a similar type has your organization had?

_______________________________

3. List below the construction projects your organization has under way as of this date:

Contract Sum Class of

Work/%Complete

Name/Address of Owner Name & Phone # of

Contact at Owner

4. List below a minimum of three (3) projects which your firm, as a firm, has performed in the past five

(5) years which you feel will qualify you for this work.

Contract Sum Class of

Work/%Complete

Name/Address of Owner Name & Phone # of

Contact at Owner

5. Have you ever failed to complete any work awarded to you?

Yes No; If Yes, where and why?

________________________________________________________________________

________________________________________________________________________

________________________________________________________________________

6. Has any officer or partner of your organization ever been an officer or partner of some other

organization that failed to complete a construction contract? Yes No; If Yes, state:


Weston High School


Name of Individual(s) Name of Owner(s) Reason(s)

7. Has any officer or partner of your organization ever failed to complete a construction contract

handled in his own name?

Yes No; If yes, state:

Name of Individual(s) Name of Owner(s) Reason(s)

8. Has your firm or organization ever received a Notice of Default or Notice of Termination or ever

been defaulted or terminated on a Project.

9. Has your firm been involved in litigation during the past 5 years? If so, describe.

The undersigned hereby authorizes and requests any firm, person or corporation to furnish any information

requested by the Owner or Architect in verification of the matters contained in the Bidder Qualification

Statement.

Dated __________________, 20__

________________________________

(Name of Bidder)

By ______________________________

Title ___________________________

AFFIDAVIT

STATE OF )

S.S.

COUNTY OF )


Weston High School


______________________________________ being duly sworn and says that he/she is

_________________________ of __________________________________________________

_______________________________________________________________________________

(Name of Organization)

and that the answers to the foregoing interrogatories and all statements therein contained are true and

correct.

Subscribed and sworn to before me

this ____________ day of _____________ 20__

__________________________

Signature

____________________________________________

Notary Public, County of ________________________

**End of Section**


Weston High School

KGD2018-1010 00 46 43 - 1 Wage Rates

SECTION 00 46 43

WAGE AND HOUR RATES

1.01 GENERAL

A. All contractors will be bound and obligated by the Laws of the State of Connecticut to

insure payment to all workers involved with the construction of the Project.

B. Pursuant to Connecticut General Statutes § 7-112 and § 31-53: The wages paid on an

hourly basis to any person performing the work of any mechanic, laborer or worker on the

work herein contracted to be done and the amount of payment or contribution paid or

payable on behalf of each such person to any employee welfare fund, as defined in

subsection (i) of § 31-53, shall be at a rate equal to the rate customary or prevailing for the

same work in the same trade or occupation in the town in which such public work is being

constructed. Any Contractor who is not obligated by agreement to make payment or

contribution on behalf of such persons to any such employee welfare fund shall pay to

each mechanic, laborer or worker as part of such person’s wages the amount of payment

or contribution for such person’s classification on each pay day.

C. Upon the award of the contract, the Contractor shall certify, under oath, to the Labor

Commissioner the pay scale to be used by the Contractor and any of the contractor’s

subcontractors for work to be performed under such contract.

D. The Contractor shall: (1) keep, maintain and preserve such records relating to the wages

and hours worked by each person performing the work of any mechanic, laborer and

worker and a schedule of the occupation or work classification at which each person

performing the work of any mechanic, laborer or worker on the project is employed during

each work day and week in such manner and form as the Labor Commissioner establishes

to assure proper payments due to such persons or employee welfare funds under this

section or section 31-54, regardless of any contractual relationship alleged to exist

between the Contractor and such person, and (2) submit monthly to the Town of Weston a

certified payroll that shall consist of a complete copy of such records accompanied by a

statement signed by the employer that indicates (A) such records are correct; (B) the rate

of wages paid to each person performing the work of any mechanic, laborer or worker and

the amount of payment or contributions paid or payable on behalf of each such person to

any employee welfare fund, as defined in subsection (h) of section 31-53, are not less than

the prevailing rate of wages and the amount of payment or contributions paid or payable

on behalf of such person to any employee welfare fund, as determined by the Labor

Commissioner pursuant to subsection (d) of section 31-53, and not less than those

required by the contract to be paid; (C) the employer has complied with the provisions of

section 31-53 and section 31-54; (D) each such person is covered by a workers’

compensation insurance policy for the duration of such person’s employment, which shall

be demonstrated by submitting to the Town of Weston the name of the workers’

compensation insurance carrier covering each such person, the effective and expiration

dates of each policy and each policy number; (E) the employer does not receive kickbacks,

as defined in 41 U.S.C. 52, from any employee or employee welfare fund; and (F) pursuant

to the provisions of section 53a-157a, the employer is aware that filing a certified payroll

which the employer knows to be false is a class D felony for which the employer may be

fined up to five thousand dollars, imprisoned up to five years, or both.

E. Every contractor or subcontractor performing work under this contract shall post the

prevailing wages as determined by the Labor Commissioner in prominent and easily

accessible places at the site of work or at such place or places as are used to pay its

employees their wages.

F. Annual adjustments to wage rates by contractors doing state work. Each contractor that is

awarded a contract on or after October 1, 2002, for (1) the construction of a state highway


Weston High School

KGD2018-1010 00 46 43 - 2 Wage Rates

or bridge that falls under the provisions of section 31-54, or (2) the construction,

remodeling, refinishing, refurbishing, rehabilitation, alteration or repair of any public works

project that falls under the provisions of section 31-53 shall contact the Labor

Commissioner on or before July first of each year, for the duration of such contract, to

ascertain the prevailing rate of wages on an hourly basis and the amount of payment or

contributions paid or payable on behalf of each mechanic, laborer or worker employed

upon the work contracted to be done, and shall make any necessary adjustments to such

prevailing rate of wages and such payment or contributions paid or payable on behalf of

each such employee, effective each July first.

1.02 PREVAILING WAGE RATES

A. The current wage and benefit rates are available when following the instructions on the

Connecticut State Labor web site.

Document A101TM

– 2017Standard Form of Agreement Between Owner and Contractor where the basis of payment is a Stipulated Sum

Init.

/

AIA Document A101™ – 2017. Copyright © 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997, 2007 and 2017 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 13:08:32 on 03/22/2018 under Order No.2224619413 which expires on 07/17/2018, and is not for resale.User Notes: (1112092747)

1

ADDITIONS AND DELETIONS: The author of this document has added information needed for its completion. The author may also have revised the text of the original AIA standard form. An Additions and Deletions Report that notes added information as well as revisions to the standard form text is available from the author and should be reviewed. A vertical line in the left margin of this document indicates where the author has added necessary information and where the author has added to or deleted from the original AIA text.

This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification.

The parties should complete A101™–2017, Exhibit A, Insurance and Bonds, contemporaneously with this Agreement. AIA Document A201™–2017, General Conditions of the Contract for Construction, is adopted in this document by reference. Do not use with other general conditions unless this document is modified.

AGREEMENT made as of the day of in the year 2018(In words, indicate day, month and year.)

BETWEEN the Owner:(Name, legal status, address and other information)

Weston Board of Education24 School StreetWeston, CT 06883Telephone Number: (203) 291-1418

and the Contractor:(Name, legal status, address and other information)

for the following Project:(Name, location and detailed description)

Weston High School Football Field Artificial Turf ReplacementWeston High School115 School RoadWeston, CT 06883

The Architect:(Name, legal status, address and other information)

Kaeyer, Garment + Davidson Architects, P.C.285 Main Street; Mount Kisco, NYTelephone Number: 914-666-5900The Owner and Contractor agree as follows.

Init.

/


2

TABLE OF ARTICLES

1 THE CONTRACT DOCUMENTS

2 THE WORK OF THIS CONTRACT

3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION

4 CONTRACT SUM

5 PAYMENTS

6 DISPUTE RESOLUTION

7 TERMINATION OR SUSPENSION

8 MISCELLANEOUS PROVISIONS

9 ENUMERATION OF CONTRACT DOCUMENTS

EXHIBIT A INSURANCE AND BONDS

ARTICLE 1 THE CONTRACT DOCUMENTSThe Contract Documents consist of this Agreement, AIA Document A201-2017, as modified by the Owner (the "General Conditions"), Drawings, Specifications, Addenda issued prior to execution of this Agreement, other documents listed in this Agreement, and Modifications issued after execution of this Agreement, all of which form the Contract, and are as fully a part of the Contract as if attached to this Agreement or repeated herein. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations, or agreements, either written or oral. An enumeration of the Contract Documents, other than a Modification, appears in Article 9.

ARTICLE 2 THE WORK OF THIS CONTRACT AND CONTRACTOR"S PROJECT TEAM§ 2.1 The Contractor shall fully execute the Work described in, reasonably inferable from and as necessary to produce the results intended by, the Contract Documents including, but not limited to, the furnishing of (1) all materials, supplies, equipment, fixtures, tools, implements, and other items and facilities required for, or in connection with, or for inclusion or incorporation into, the Project and (2) all labor, supervision, transportation, utilities, storage and all other services required for or in connection with the Project, except as specifically indicated in the Contract Documents to be the responsibility of others.

§ 2.2 THE CONTRACTOR’S PROJECT TEAM§ 2.2.1 The Contractor accepts the relationship of trust and confidence established by this Agreement and covenants with the Owner to cooperate with the Architect and exercise the Contractor’s reasonable skill and judgment in furthering the interests of the Owner. The Contractor agrees to furnish efficient business administration and supervision and to use Contractor’s best efforts to furnish, at all times, an adequate supply of skilled workers and materials, and to perform the Work in the most expeditious and economical manner consistent with the Owner’s interests.

§ 2.2.2 The Contractor’s project team ("Project Team") will consist of a project executive, project manager, and superintendent. The Project Team shall include the following members:

Project Executive: _______________________________Project Manager: ________________________________Superintendent: _________________________________

The Contractor acknowledges that, in entering into this Agreement, the Owner is relying upon the fact that each of the members of the Project Team will continue to perform his or her services throughout the entirety of the performance of the Work. No change will be made in the membership of the Project Team without the Owner’s prior written approval,

Init.

/


3

which approval shall not be withheld on an arbitrary basis. The Contractor will, upon reasonable notice from the Owner, replace any member of the Project Team that the Owner reasonable deems unsatisfactory.

ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION§ 3.1 The date of commencement of the Work shall be:(Check one of the following boxes.)

[ ] The date of this Agreement.

[ X ] A date set forth in a notice to proceed issued by the Owner.

[ ] Established as follows:(Insert a date or a means to determine the date of commencement of the Work.)

If a date of commencement of the Work is not selected, then the date of commencement shall be the date of this Agreement.

§ 3.2 The Contract Time shall be measured from the date of commencement of the Work.

§ 3.3 Substantial Completion§ 3.3.1 Subject to adjustments of the Contract Time as provided in the Contract Documents, the Contractor shall achieve Substantial Completion of the entire Work in accordance with the Contract Documents and the construction schedule attached hereto as Exhibit B (the "Construction Schedule"):(Check one of the following boxes and complete the necessary information.)

[ ] Not later than ( ) calendar days from the date of commencement of the Work.

[ ] By the following date:

§ 3.3.2 Subject to adjustments of the Contract Time as provided in the Contract Documents, if portions of the Work are to be completed prior to Substantial Completion of the entire Work, the Contractor shall achieve Substantial Completion of such portions by the following dates:

Portion of Work Substantial Completion Date

§ 3.3.3 If the Contractor fails to achieve Substantial Completion as provided in this Section 3.3, liquidated damages, if any, shall be assessed as set forth in Section 4.5. TIME IS OF THE ESSENCE in the completion of the Work.

ARTICLE 4 CONTRACT SUM§ 4.1 The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor’s performance of the Contract. The Contract Sum shall be ($ ), subject to additions and deductions as provided in the Contract Documents.

§ 4.2 Alternates§ 4.2.1 Alternates, if any, included in the Contract Sum:

Item Price

§ 4.2.2 Subject to the conditions noted below, the following alternates may be accepted by the Owner following execution of this Agreement. Upon acceptance, the Owner shall issue a Modification to this Agreement.(Insert below each alternate and the conditions that must be met for the Owner to accept the alternate.)

Init.

/


4

Item Price Conditions for Acceptance

§ 4.3 Allowances, if any, included in the Contract Sum:(Identify each allowance.)

Item Price

§ 4.4 Unit prices applicable to the Work, if any, are set forth below (the "Unit Prices"). Unit Prices shall be valid for the life of the Project and are inclusive of all costs associated with the complete performance, furnishing, and installation of the portion of the Work subject to Unit Prices including, without limitation, labor, materials, equipment, machinery, services, engineering, transportation, taxes and insurance as well as overhead and profit.

(Identify the item and state the unit price and quantity limitations, if any, to which the unit price will be applicable.)

Item Units and Limitations Price per Unit ($0.00)

§ 4.5 Liquidated damages, if any:(Insert terms and conditions for liquidated damages, if any.)

It is acknowledged that the Contractor’s failure to achieve Substantial Completion of the Work within the Contract Time provided by the Contract Documents will cause the Owner to incur substantial economic damages and losses of types and in amounts which are impossible to compute and ascertain with certainty as a basis for recovery by the Owner of actual damages, and that liquidated damages represent a fair, reasonable and appropriate estimate thereof. Accordingly, in lieu of actual damages for such delay, the Contractor agrees that liquidated damages may be assessed and recovered by the Owner as against Contractor and its Surety in the event of delayed completion, without the Owner being required to present any evidence of the amount or character of actual damages sustained by reason thereof. Therefore, Contractor shall be liable to the Owner for payment of liquidated damages in the amount of _________ Dollars ($_______) for each day that Substantial Completion is delayed beyond the date set forth herein for the achievement of Substantial Completion, as adjusted for time extensions as may have been granted pursuant to the terms and conditions of the Contract Documents. Such liquidated damages are intended to represent estimated actual damages and are not intended as a penalty, and Contractor shall pay them to Owner without limiting Owner’s right to terminate this Agreement as provided elsewhere herein.

The collection of liquidated damages by the Owner under this Section 3.3 shall be in addition to, and not in lieu of, the Owner’s right to recover from the Contractor the Owner’s increased costs to complete the Project arising from the Contractor’s delay. Further, such liquidated damages shall in no way limit the Owner’s other rights under this Agreement or the Owner’s entitlement to damages for any other injury, damage or loss, other than for delay, for which Contractor may be responsible.

§ 4.6 Other:(Insert provisions for bonus or other incentives, if any, that might result in a change to the Contract Sum.)

§ 4.6.1 The Contractor represents and warrants that the Drawings and Specifications and other materials and information furnished to the Contractor are sufficiently detailed to enable the Contractor to firmly establish the Contract Sum, subject to clarifications and assumptions (if any) expressly herein set forth. The Contractor shall not be permitted to claim any adjustment in the Contract Sum in connection with the completion of drawings, clarifications, supplemental information and other materials (collectively, "Supplemental Materials") issued by the Architect or otherwise after the date of this Agreement, except for changes in the Work as described in this Section 4.6. Adjustments to the Contract Sum on account of changes in the Work may be determined by any of the methods listed in Section 7.3.3 of the General Conditions.

§ 4.6.2 The Architect shall from time to time issue Supplemental Materials. The Contractor shall review such Supplemental Materials in detail and notify the Owner and the Architect of any error, inconsistency or discrepancy that the Contractor discovers between the Supplemental Materials and the Contract Documents. Upon completion of

Init.

/


5

such review, but in any case within seven (7) days of receipt of the applicable Supplemental Materials, the Contractor shall also notify the Owner in writing of any item in the Supplemental Materials which in the Contractor’s opinion represents a change in the Work (as defined in Section 4.6.3), setting forth, with specificity, the reasons the Contractor contends that information or requirements of the Supplemental Materials represent a change in the Work (such notice shall constitute a "Change Request"). The Change Request shall set forth the change in costs and the impacts on the Construction Schedule, if any, that the Contractor attributes to the work covered by such Change Request and shall include evidence reasonably satisfactory to Owner substantiating any claimed increase in any Cost of the Work, including but not limited to any of the following costs:

.1 Costs of labor, including social security, old age and unemployment insurance, fringe benefits required by agreement or custom, and workers’ compensation insurance;

.2 Costs of materials, supplies and equipment, including cost of transportation, whether incorporated or consumed;

.3 Rental costs of machinery and equipment, exclusive of hand tools, whether rented from the Contractor or others;

.4 Costs of premiums for all bonds and insurance, permit fees, and sales, use or similar taxes related to the Work; and

.5 Additional costs of supervision and field office personnel directly attributable to the change.

§ 4.6.3 A change in the Work is any work described in any Supplemental Materials which is not reasonably inferable from the Drawings and Specifications and is (1) inconsistent with any of the Contractor’s clarifications and assumptions expressly herein set forth, or (2) a change in the quantity, quality, programmatic requirements or other substantial deviation from the Drawings and Specifications. The Contractor represents that it is a contractor experienced in constructing projects similar to the Project and the Contractor acknowledges that, prior to execution of this Agreement, it will advise the Owner, in a timely manner, of all tests and inspections of the Project site which the Contractor believes are necessary to minimize the risk that any site conditions may be discovered which could give rise to an increase in the Contract Sum or an extension of the Contract Time.

§ 4.6.4 If the Contractor timely submits to the Owner a completed Change Request pursuant to Section 4.6.2 above, including all required Supporting Documentation (as defined in Section 9.3 of the General Conditions), then the Owner shall have the following options:

.1 within thirty (30) days of receipt of the Change Request, the Owner shall direct the Architect in writing, with a copy to the Contractor, to modify that aspect of the Supplemental Materials to which the Contractor objects. The Contractor shall cooperate with the Owner and the Architect during the modification effort and shall assist in making recommendations appropriate to correct such portions of the Supplemental Materials. After receipt of the Owner’s written directive to revise the Supplemental Materials, the Architect shall submit to the Contractor the revised Supplemental Materials as approved by the Owner. The Contractor shall promptly re-examine such revised Supplemental Materials as described in Section 4.6.2.1.

.2 if, upon review of the Change Request, the Owner believes that the portion of the work described therein does not constitute a change in the Work as described in Section 4.6.3 above, the Owner shall so advise the Contractor within thirty (30) days of receipt of the Change Request. If such disagreement is not resolved, the Work subject to disagreement shall be identified in a schedule (the "Disputed Work Schedule"). Whenever possible, the Owner and the Contractor shall resolve items set forth in the Disputed Work Schedule, confirming such resolution in Change Orders. Items in the Disputed Work Schedule that are not resolved by the Owner and Contractor shall be subject to the dispute resolution procedures set forth in Article 15 of the General Conditions. During the pendency of such dispute resolution procedures, Contractor shall not perform any Work on the Disputed Work Schedule unless specifically requested to do so by Owner. If so requested, the Contractor shall perform the requested work and keep a specific detailed accounting of the item and materials required to complete such item. Adjustments to the Construction Schedule shall not be permitted on a tentative basis.

.3 if, upon review of the Change Request, the Owner agrees that all or a portion of the work therein constitutes a change in the Work, and the Owner elects not to direct the Architect to modify the Supplemental Materials, the Owner and the Contractor shall execute a Change Order providing for appropriate changes to the Contract Sum and the Construction Schedule.

.4 if, with respect to any item in the Change Request, the Owner does not, within the appropriate time limitations, (a) direct the Architect to modify the Supplemental Materials, (b) advise the Contractor in writing of disapproval of such item in the Change Request, or (c) agree that such item represents a

Init.

/


6

change in the Work, then Owner will be deemed to have disapproved such item in the Change Request pursuant to Section 4.6.4.2 above.

ARTICLE 5 PAYMENTS§ 5.1 Progress Payments§ 5.1.1 Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents.

§ 5.1.2 The period covered by each Application for Payment shall be one calendar month ending on the last day of the month, or as follows:

§ 5.1.3 The Contractor shall submit final versions of Applications for Payment, along with all required Supporting Documentation, on a monthly basis to the Architect (with a copy to the Owner) not later than the 15th day of a month. The Owner shall, subject to the provisions of Section 9.6.8 of the General Conditions, make payment of the amount certified by the Architect to be due to the Contractor not later than 15th day of the following month. If an Application for Payment is received by the Architect after the application date fixed above, payment of the amount certified shall be made by the Owner not later than forty-five ( 45 ) days after the Architect receives the Application for Payment and all required Supporting Documentation.(Federal, state or local laws may require payment within a certain period of time.)

§ 5.1.4 Each Application for Payment shall be based on the most recent schedule of values submitted by the Contractor in accordance with the Contract Documents and approved by the Owner and the Architect pursuant to Section 9.2 of the General Conditions (the "Schedule of Values"). The Schedule of Values shall allocate the entire Contract Sum among the various portions of the Work. The Schedule of Values shall be prepared in such form, and supported by such data to substantiate its accuracy, as the Architect may require. This Schedule of Values shall be used as a basis for reviewing the Contractor’s Applications for Payment.

§ 5.1.5 Applications for Payment shall show the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. Each Application for Payment shall include a statement showing the status of all pending change orders, other pending change directives and approved changes to the Contract. Such statement shall identify the pending change orders and other pending change directives, and shall include the date such change orders and directives were initiated, the costs associated with their performance, and a description of any work completed.

§ 5.1.6 In accordance with the General Conditions, and subject to other provisions of the Contract Documents, the amount of each progress payment shall be computed as follows:

§ 5.1.6.1 The amount of each progress payment shall first include:.1 That portion of the Contract Sum properly allocable to completed Work based on the Schedule of

Values;.2 That portion of the Contract Sum properly allocable to materials and equipment delivered and suitably

stored at the site for subsequent incorporation in the completed construction, or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing; and

.3 That portion of Construction Change Directives that the Architect determines, in the Architect’s professional judgment, to be reasonably justified.

§ 5.1.6.2 The amount of each progress payment shall then be reduced by:.1 The aggregate of any amounts previously paid by the Owner;.2 The amount, if any, for Work that remains uncorrected and for which the Architect has previously

withheld a Certificate for Payment as provided in Article 9 of the General Conditions;.3 Any amount for which the Contractor does not intend to pay a Subcontractor or material supplier,

unless the Work has been performed by others the Contractor intends to pay;

Init.

/


7

.4 For Work performed or defects discovered since the last payment application, any amount for which the Architect may withhold payment, or nullify a Certificate of Payment in whole or in part, as provided in Article 9 of the General Conditions; and

.5 Retainage withheld pursuant to Section 5.1.7.

§ 5.1.7 Retainage§ 5.1.7.1 For each progress payment, the Owner may withhold the following amount, as retainage, from the payment otherwise due:(Insert a percentage or amount to be withheld as retainage from each Application for Payment. The amount of retainage may be limited by governing law.)

Five percent (5%) of each progress payment

§ 5.1.7.1.1 The following items are not subject to retainage:(Insert any items not subject to the withholding of retainage, such as general conditions, insurance, etc.)

N/A

§ 5.1.7.2 Reduction or limitation of retainage, if any, shall be as follows:(If the retainage established in Section 5.1.7.1 is to be modified prior to Substantial Completion of the entire Work, including modifications for Substantial Completion of portions of the Work as provided in Section 3.3.2, insert provisions for such modifications.)

N/A

§ 5.1.7.3 Upon Substantial Completion of the Work, the Contractor may submit an Application for Payment that includes the retainage withheld from prior Applications for Payment. The Owner may, in its sole discretion, release all or a portion of retainage withheld from prior progress payments as provided in Section 9.8.5 of the General Conditions. (Insert any other conditions for release of retainage upon Substantial Completion.)

§ 5.1.8 If final completion of the Work is materially delayed through no fault of the Contractor, the Owner shall pay the Contractor any additional amounts in accordance with Article 9 of the General Conditions.

§ 5.1.9 Except with the Owner’s prior approval, the Contractor shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site.

§ 5.2 Final Payment§ 5.2.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when

.1 the Contractor has fully performed the Work and all of its obligations under the Contract Documents except for the Contractor’s responsibility to correct Work as provided in Article 12 of the General Conditions, and to satisfy other requirements, if any, which extend beyond final payment; and

.2 a final Certificate for Payment has been issued by the Architect.

§ 5.2.2 The Owner’s final payment to the Contractor shall be made no later than 30 days after the issuance of the Architect’s final Certificate for Payment. The Architect’s final Certificate for Payment shall not be issued until such time as all required Supporting Documentation has been submitted to the Architect by the Contractor.

§ 5.3 InterestPayments due and unpaid under the Contract shall bear interest (Paragraphs deleted)only to the extent required by applicable Legal Requirements and, if so required, at the minimum required rate.

Init.

/


8

ARTICLE 6 DISPUTE RESOLUTION§ 6.1 Initial Decision MakerThe Architect will serve as the Initial Decision Maker pursuant to Article 15 of the General Conditions, unless the parties appoint below another individual, not a party to this Agreement, to serve as the Initial Decision Maker.(If the parties mutually agree, insert the name, address and other contact information of the Initial Decision Maker, if other than the Architect.)

§ 6.2 Binding Dispute ResolutionFor any Claim subject to, but not resolved by, mediation pursuant to Article 15 of the General Conditions, the method of binding dispute resolution shall be as follows:(Check the appropriate box.)

[ ] Arbitration pursuant to Section 15.4 of AIA Document A201–2017

[ X ] Litigation in a court of competent jurisdiction

[ ] Other (Specify)

If the Owner and Contractor do not select a method of binding dispute resolution, or do not subsequently agree in writing to a binding dispute resolution method other than litigation, Claims will be resolved by litigation in a court of competent jurisdiction.

ARTICLE 7 TERMINATION OR SUSPENSION§ 7.1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of the General Conditions.

§ 7.1.1 If the Contract is terminated for the Owner’s convenience in accordance with Article 14 of the General Conditions, then the Owner shall pay the Contractor (Paragraphs deleted)as provided in Article 14 of the General Conditions.

§ 7.2 The Work may be suspended by the Owner as provided in Article 14 of the General Conditions.

ARTICLE 8 MISCELLANEOUS PROVISIONS§ 8.1 Where reference is made in this Agreement to a provision of the General Conditions or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents.

§ 8.2 The Owner’s representative:(Name, address, email address, and other information)

Joseph OlenikDirector of School Facilities Weston Public School District24 School Rd.Weston, CT [email protected]

§ 8.3 The Contractor’s representative:(Name, address, email address, and other information)

Init.

/


9

§ 8.4 Neither the Owner’s nor the Contractor’s representative shall be changed without ten days’ prior notice to the other party.

§ 8.5 Insurance and Bonds§ 8.5.1 The Owner and the Contractor shall purchase and maintain insurance as required and set forth in Exhibit A, Insurance and Bonds attached hereto, and elsewhere in the Contract Documents.

§ 8.5.2 The Contractor shall provide bonds as set forth in Exhibit A, Insurance and Bonds attached hereto, and elsewhere in the Contract Documents.

§ 8.6 Notice in electronic format, pursuant to Article 1 of AIA Document A201–2017, may be given (Paragraphs deleted)to Joseph Olenik, Director of School Facilities, [email protected].

§ 8.7 Other provisions:

§ 8.7.1 Execution in Counterparts. This Agreement may be signed in two or more counterparts, each of which shall be treated as an original but which, when taken together, shall constitute one and the same instrument. Signed copies of this Agreement may be faxed and e-mailed with the same force and effect as if the originally executed Agreement had been delivered.

ARTICLE 9 ENUMERATION OF CONTRACT DOCUMENTS§ 9.1 This Agreement is comprised of the following documents:

.1 This Standard Form of Agreement Between Owner and Contractor

.2 Exhibit A, Insurance and Bonds

.3 General Conditions

.4 N/A(Paragraph deleted)

.5 Drawings - See Exhibit C

Number Title Date

.6 Specifications - See Exhibit D

Section Title Date Pages

.7 Addenda, if any:

Number Date Pages

Portions of Addenda relating to bidding or proposal requirements are not part of the Contract Documents unless the bidding or proposal requirements are also enumerated in this Article 9.

.8 Other Exhibits:(Check all boxes that apply and include appropriate information identifying the exhibit where required.)

Init.

/


10

[ ] AIA Document E204™–2017, Sustainable Projects Exhibit, dated as indicated below:(Insert the date of the E204-2017 incorporated into this Agreement.)

[ ] The Sustainability Plan:

Title Date Pages

[ ] Supplementary and other Conditions of the Contract:

Document Title Date Pages

.9 Other documents, if any, listed below:(List here any additional documents that are intended to form part of the Contract Documents. AIA Document A201™–2017 provides that the advertisement or invitation to bid, Instructions to Bidders, sample forms, the Contractor’s bid or proposal, portions of Addenda relating to bidding or proposal requirements, and other information furnished by the Owner in anticipation of receiving bids or proposals, are not part of the Contract Documents unless enumerated in this Agreement. Any such documents should be listed here only if intended to be part of the Contract Documents.)

Exhibit B - Construction Schedule

This Agreement entered into as of the day and year first written above.

WESTON BOARD OF EDUCATION

OWNER (Signature) CONTRACTOR (Signature)

(Printed name and title) (Printed name and title)

Date:_____________________________ Date;___________________________

Document A101TM

– 2017 Exhibit AInsurance and Bonds

Init.

/

AIA Document A101™ – 2017 Exhibit A. Copyright © 2017 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 13:07:21 on 03/22/2018 under Order No. 2224619413 which expires on 07/17/2018, and is not for resale.User Notes: (3B9ADA0E)

1



This document is intended to be used in conjunction with AIA Document A201™–2017, General Conditions of the Contract for Construction. Article 11 of A201™–2017 contains additional insurance provisions.

This Insurance and Bonds Exhibit is part of the Agreement, between the Owner and the Contractor, dated the day of in the year (In words, indicate day, month and year.)

for the following PROJECT:(Name and location or address)


THE OWNER:(Name, legal status and address)


THE CONTRACTOR:(Name, legal status and address)

TABLE OF ARTICLES

A.1 GENERAL

A.2 OWNER’S INSURANCE

A.3 CONTRACTOR’S INSURANCE AND BONDS

A.4 SPECIAL TERMS AND CONDITIONS

ARTICLE A.1 GENERALThe Owner and Contractor shall purchase and maintain insurance, and provide bonds, as set forth in this Exhibit. As used in this Exhibit, the term General Conditions refers to AIA Document A201™–2017, General Conditions of the Contract for Construction.

ARTICLE A.2 OWNER’S INSURANCE§ A.2.1 GeneralPrior to commencement of the Work, the Owner shall secure the insurance, and provide evidence of the coverage, required under this Article A.2 and, upon the Contractor’s request, provide a copy of the property insurance policy or policies required by Section

Init.

/


2

A.2.3. The copy of the policy or policies provided shall contain all applicable conditions, definitions, exclusions, and endorsements.

§ A.2.2 Liability InsuranceThe Owner shall be responsible for purchasing and maintaining the Owner’s usual general liability insurance.

§ A.2.3 Required Property Insurance§ A.2.3.1 Unless this obligation is placed on the Contractor pursuant to Section A.3.3.2.1, the Owner shall purchase and maintain, from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located, property insurance written on a builder's risk “all-risks” completed value or equivalent policy form and sufficient to cover the total value of the entire Project on a replacement cost basis. The Owner’s property insurance coverage shall be no less than the amount of the initial Contract Sum, plus the value of subsequent Modifications and labor performed and materials or equipment supplied by others. The property insurance shall be maintained until Substantial Completion and thereafter as provided in Section A.2.3.1.3, unless otherwise provided in the Contract Documents or otherwise agreed in writing by the parties to this Agreement. This insurance shall include the interests of the Owner, Contractor, Subcontractors, and Sub-subcontractors in the Project as insureds. This insurance shall include the interests of mortgagees as loss payees.

§ A.2.3.1.1 Causes of Loss. The insurance required by this Section A.2.3.1 shall provide coverage for direct physical loss or damage, and shall not exclude the risks of fire, explosion, theft, vandalism, malicious mischief, collapse, earthquake, flood, or windstorm. The insurance shall also provide coverage for ensuing loss or resulting damage from error, omission, or deficiency in construction methods, design, specifications, workmanship, or materials. Sub-limits, if any, are as follows:(Indicate below the cause of loss and any applicable sub-limit.)

Causes of Loss Sub-Limit

§ A.2.3.1.2 Specific Required Coverages. The insurance required by this Section A.2.3.1 shall provide coverage for loss or damage to falsework and other temporary structures, and to building systems from testing and startup. The insurance shall also cover debris removal, including demolition occasioned by enforcement of any applicable legal requirements, and reasonable compensation for the Architect’s and Contractor’s services and expenses required as a result of such insured loss, including claim preparation expenses. Sub-limits, if any, are as follows:(Indicate below type of coverage and any applicable sub-limit for specific required coverages.)

Coverage Sub-Limit

§ A.2.3.1.3 Unless the parties agree otherwise, upon Substantial Completion, the Owner shall continue the insurance required by Section A.2.3.1 or, if necessary, replace the insurance policy required under Section A.2.3.1 with property insurance written for the total value of the Project that shall remain in effect until expiration of the period for correction of the Work set forth in Section 12.2.2 of the General Conditions.

§ A.2.3.1.4 Deductibles and Self-Insured Retentions. If the insurance required by this Section A.2.3 is subject to deductibles or self-insured retentions, the Owner shall be responsible for all loss not covered because of such deductibles or retentions.

§ A.2.3.2 Occupancy or Use Prior to Substantial Completion. The Owner’s occupancy or use of any completed or partially completed portion of the Work prior to Substantial Completion shall not commence until the insurance company or companies providing the insurance under Section A.2.3.1 have consented in writing to the continuance of coverage. The Owner and the Contractor shall take no action with respect to partial occupancy or use that would cause cancellation, lapse, or reduction of insurance, unless they agree otherwise in writing.

§ A.2.3.3 Insurance for Existing StructuresIf the Work involves remodeling an existing structure or constructing an addition to an existing structure, the Owner shall purchase and maintain, until the expiration of the period for correction of Work as set forth in Section 12.2.2 of the General Conditions, “all-risks” property insurance, on a replacement cost basis, protecting the existing structure

Init.

/


3

against direct physical loss or damage from the causes of loss identified in Section A.2.3.1, notwithstanding the undertaking of the Work. The Owner shall be responsible for all co-insurance penalties.

§ A.2.4 Optional Extended Property Insurance.The Owner shall purchase and maintain the insurance selected and described below.(Select the types of insurance the Owner is required to purchase and maintain by placing an X in the box(es) next to the description(s) of selected insurance. For each type of insurance selected, indicate applicable limits of coverage or other conditions in the fill point below the selected item.)

[ ] § A.2.4.1 Loss of Use, Business Interruption, and Delay in Completion Insurance, to reimburse the Owner for loss of use of the Owner’s property, or the inability to conduct normal operations due to a covered cause of loss.

[ ] § A.2.4.2 Ordinance or Law Insurance, for the reasonable and necessary costs to satisfy the minimum requirements of the enforcement of any law or ordinance regulating the demolition, construction, repair, replacement or use of the Project.

[ ] § A.2.4.3 Expediting Cost Insurance, for the reasonable and necessary costs for the temporary repair of damage to insured property, and to expedite the permanent repair or replacement of the damaged property.

[ ] § A.2.4.4 Extra Expense Insurance, to provide reimbursement of the reasonable and necessary excess costs incurred during the period of restoration or repair of the damaged property that are over and above the total costs that would normally have been incurred during the same period of time had no loss or damage occurred.

[ ] § A.2.4.5 Civil Authority Insurance, for losses or costs arising from an order of a civil authority prohibiting access to the Project, provided such order is the direct result of physical damage covered under the required property insurance.

[ ] § A.2.4.6 Ingress/Egress Insurance, for loss due to the necessary interruption of the insured’s business due to physical prevention of ingress to, or egress from, the Project as a direct result of physical damage.

[ ] § A.2.4.7 Soft Costs Insurance, to reimburse the Owner for costs due to the delay of completion of the Work, arising out of physical loss or damage covered by the required property insurance: including construction loan fees; leasing and marketing expenses; additional fees, including those of architects, engineers, consultants, attorneys and accountants, needed for the completion of the construction, repairs, or reconstruction; and carrying costs such as property taxes, building permits, additional interest on loans, realty taxes, and insurance premiums over and above normal expenses.

§ A.2.5 Other Optional Insurance.The Owner shall purchase and maintain the insurance selected below.

Init.

/


4

(Select the types of insurance the Owner is required to purchase and maintain by placing an X in the box(es) next to the description(s) of selected insurance.)

[ ] § A.2.5.1 Cyber Security Insurance for loss to the Owner due to data security and privacy breach, including costs of investigating a potential or actual breach of confidential or private information.(Indicate applicable limits of coverage or other conditions in the fill point below.)

[ ] § A.2.5.2 Other Insurance(List below any other insurance coverage to be provided by the Owner and any applicable limits.)

Coverage Limits

ARTICLE A.3 CONTRACTOR’S INSURANCE AND BONDS§ A.3.1 General§ A.3.1.1 Certificates of Insurance. The Contractor shall provide certificates of insurance acceptable to the Owner evidencing compliance with the requirements in this Article A.3 at the following times: (1) prior to commencement of the Work; (2) upon renewal or replacement of each required policy of insurance; and (3) upon the Owner’s written request. An additional certificate evidencing continuation of commercial liability coverage, including coverage for completed operations, shall be submitted with the final Application for Payment and thereafter upon renewal or replacement of such coverage until the expiration of the periods required by Section A.3.2.1 and Section A.3.3.1. The certificates will show the Owner and the Town of Weston as additional insureds on the Contractor’s Commercial General Liability, automobile and excess or umbrella liability policy or policies.

§ A.3.1.2 Deductibles and Self-Insured Retentions. The Contractor shall disclose to the Owner any deductible or self- insured retentions applicable to any insurance required to be provided by the Contractor.

§ A.3.1.3 Additional Insured Obligations. To the fullest extent permitted by law, the Contractor shall cause the commercial general liability coverage, excess or umbrella policies and automobile policies to include (1) the Owner, the Town of Weston, the Architect, and the Architect’s consultants as additional insureds for claims caused in whole or in part by the Contractor’s negligent acts or omissions during the Contractor’s operations; and (2) the Owner and the Town of Weston as additional insureds for claims caused in whole or in part by the Contractor’s negligent acts or omissions for which loss occurs during completed operations. The additional insured coverage shall be primary and non-contributory to any of the Owner’s liability insurance policies and shall apply to both ongoing and completed operations. To the extent commercially available, the additional insured coverage shall be no less than that provided by Insurance Services Office, Inc. (ISO) forms CG 20 10 07 04, CG 20 37 07 04, and, with respect to the Architect and the Architect’s consultants, CG 20 32 07 04.

§ A.3.2 Contractor’s Required Insurance Coverage§ A.3.2.1 The Contractor shall purchase and maintain the following types and limits of insurance from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located. The Contractor shall maintain the required insurance until the expiration of the period for correction of Work as set forth in Section 12.2.2 of the General Conditions, unless a different duration is stated below:(If the Contractor is required to maintain insurance for a duration other than the expiration of the period for correction of Work, state the duration.)

§ A.3.2.2 Commercial General Liability§ A.3.2.2.1 Commercial General Liability insurance for the Project written on an occurrence form with policy limits of not less than One Million and 00/100 Dollars ($ 1,000,000.00 ) each occurrence, Two Million and 00/100 Dollars ($ 2,000,000.00 ) general aggregate, and One Million and 00/100 Dollars ($ 1,000,000.00 ) aggregate for products-completed operations hazard, providing coverage for claims including

.1 damages because of bodily injury, sickness or disease, including occupational sickness or disease, and death of any person;

Init.

/


5

.2 personal injury and advertising injury;

.3 damages because of physical damage to or destruction of tangible property, including the loss of use of such property;

.4 bodily injury or property damage arising out of completed operations; and

.5 the Contractor’s indemnity obligations under Section 3.18 of the General Conditions.

§ A.3.2.2.2 The Contractor’s Commercial General Liability policy under this Section A.3.2.2 shall not contain an exclusion or restriction of coverage for the following:

.1 Claims by one insured against another insured, if the exclusion or restriction is based solely on the fact that the claimant is an insured, and there would otherwise be coverage for the claim.

.2 Claims for property damage to the Contractor’s Work arising out of the products-completed operations hazard where the damaged Work or the Work out of which the damage arises was performed by a Subcontractor.

.3 Claims for bodily injury other than to employees of the insured.

.4 Claims for indemnity under Section 3.18 of the General Conditions arising out of injury to employees of the insured.

.5 Claims or loss excluded under a prior work endorsement or other similar exclusionary language.

.6 Claims or loss due to physical damage under a prior injury endorsement or similar exclusionary language.

.7 Claims related to residential, multi-family, or other habitational projects, if the Work is to be performed on such a project.

.8 Claims related to roofing, if the Work involves roofing.

.9 Claims related to exterior insulation finish systems (EIFS), synthetic stucco or similar exterior coatings or surfaces, if the Work involves such coatings or surfaces.

.10 Claims related to earth subsidence or movement, where the Work involves such hazards.

.11 Claims related to explosion, collapse and underground hazards, where the Work involves such hazards.

§ A.3.2.3 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Contractor, with policy limits of not less than One Million and 00/100 Dollars ($ 1,000,000.00 ) per accident, for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles along with any other statutorily required automobile coverage.

§ A.3.2.4 The Contractor shall also maintain excess or umbrella liability insurance with policy limits of not less than Two Million and 00/100 Dollars ($ 2,000,000.00 ) each occurrence, Two Million and 00/100 Dollars ($ 2,000,000.00 ) general aggregate, which provides the same or greater coverage as the coverages required under Section A.3.2.2 and A.3.2.3, and in no event shall any excess or umbrella liability insurance provide narrower coverage than the primary policy. The excess policy shall not require the exhaustion of the underlying limits only through the actual payment by the underlying insurers.

§ A.3.2.5 Workers’ Compensation at statutory limits.

§ A.3.2.6 Employers’ Liability with policy limits not less than Five Hundred Thousand and 00/100 Dollars ($ 500,000.00 ) each accident, Five Hundred and 00/100 Dollars ($ 500,000.00 ) each employee, and Five Hundred Thousand and 00/100 Dollars ($ 500,000.00 ) policy limit.

§ A.3.2.7 Jones Act, and the Longshore & Harbor Workers’ Compensation Act, as required, if the Work involves hazards arising from work on or near navigable waterways, including vessels and docks

§ A.3.2.8 If the Contractor is required to furnish professional services as part of the Work, the Contractor shall procure Professional Liability insurance covering performance of the professional services, with policy limits of not less than One Million and 00/100 Dollars ($ 1,000,000.00 ) per claim and One Million and 00/100 Dollars ($ 1,000,000.00 ) in the aggregate.

§ A.3.2.9 If the Work involves the removal, disposal, transport, dissemination, use, or release of pollutants or hazardous materials of any kind, the Contractor shall procure Pollution Liability insurance, with policy limits of not

Init.

/


6

less than One Million and 00./100 Dollars ($ 1,000,000.00) per claim and Two Million and 00/100 Dollars ($ 2,000,000.00 ) in the aggregate.

§ A.3.2.10 Coverage under Sections A.3.2.8 and A.3.2.9 may be procured through a Combined Professional Liability and Pollution Liability insurance policy, with combined policy limits of not less than One Million and 00/100 Dollars ($ 1,000,000.00 ) per claim and Two Million and 00/100 Dollars ($ 2,000,00.00 ) in the aggregate.

§ A.3.2.11 Insurance for maritime liability risks associated with the operation of a vessel, if the Work requires such activities, with policy limits of not less than ($ ) per claim and ($ ) in the aggregate. N/A

§ A.3.2.12 Insurance for the use or operation of manned or unmanned aircraft, if the Work requires such activities, with policy limits of not less than ($ ) per claim and ($ ) in the aggregate. N/A

§ A.3.3 Contractor’s Other Insurance Coverage§ A.3.3.1 Insurance selected and described in this Section A.3.3 shall be purchased from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located. The Contractor shall maintain the required insurance until the expiration of the period for correction of Work as set forth in Section 12.2.2 of the General Conditions, unless a different duration is stated below:(If the Contractor is required to maintain any of the types of insurance selected below for a duration other than the expiration of the period for correction of Work, state the duration.)

§ A.3.3.2 The Contractor shall purchase and maintain the following types and limits of insurance in accordance with Section A.3.3.1.(Select the types of insurance the Contractor is required to purchase and maintain by placing an X in the box(es) next to the description(s) of selected insurance. Where policy limits are provided, include the policy limit in the appropriate fill point.)

[X ] § A.3.3.2.1 Property insurance of the same type and scope satisfying the requirements identified in Section A.2.3, which, if selected in this section A.3.3.2.1, relieves the Owner of the responsibility to purchase and maintain such insurance except insurance required by Section A.2.3.1.3 and Section A.2.3.3. The Contractor shall comply with all obligations of the Owner under Section A.2.3 except to the extent provided below. The Contractor shall disclose to the Owner the amount of any deductible, and the Owner shall be responsible for losses within the deductible unless the subject loss was due to the fault of the Contractor or anyone else for whom the Contractor is responsible. Upon request, the Contractor shall provide the Owner with a copy of the property insurance policy or policies required. The Owner shall adjust and settle the loss with the insurer and be the trustee of the proceeds of the property insurance in accordance with Article 11 of the General Conditions unless otherwise set forth below:(Where the Contractor’s obligation to provide property insurance differs from the Owner’s obligations as described under Section A.2.3, indicate such differences in the space below. Additionally, if a party other than the Owner will be responsible for adjusting and settling a loss with the insurer and acting as the trustee of the proceeds of property insurance in accordance with Article 11 of the General Conditions, indicate the responsible party below.)

[ ] § A.3.3.2.2 Railroad Protective Liability Insurance, with policy limits of not less than ($ ) per claim and ($ ) in the aggregate, for Work within fifty (50) feet of railroad property.

[ ] § A.3.3.2.3 Asbestos Abatement Liability Insurance, with policy limits of not less than ($ ) per claim and ($ ) in the aggregate, for liability arising from the encapsulation, removal, handling, storage, transportation, and disposal of asbestos-containing materials.

[ X ] § A.3.3.2.4 Insurance for physical damage to property while it is in storage and in transit to the construction site on an “all-risks” completed value form.

Init.

/


7

[ X ] § A.3.3.2.5 Property insurance on an “all-risks” completed value form, covering property owned by the Contractor and used on the Project, including scaffolding and other equipment.

[ ] § A.3.3.2.6 Other Insurance(List below any other insurance coverage to be provided by the Contractor and any applicable limits.)

Coverage Limits

§ A.3.4 Performance Bond and Payment BondThe Contractor shall provide surety bonds, from a company or companies lawfully authorized to issue surety bonds in the jurisdiction where the Project is located, as follows:(Specify type and penal sum of bonds.)

Type Penal Sum ($0.00) []Payment Bond In an amount no less than the Contract Sum

Performance Bond In an amount no less than the Contract Sum

Payment and Performance Bonds shall be AIA Document A312™, Payment Bond and Performance Bond, or contain provisions identical to AIA Document A312™, current as of the date of this Agreement.

ARTICLE A.4 SPECIAL TERMS AND CONDITIONSSpecial terms and conditions that modify this Insurance and Bonds Exhibit, if any, are as follows:


Weston High School

KGD 2018-1010 00 61 00 – 1 Bond Requirements

SECTION 00 61 00

BOND REQUIREMENTS

SEE SECTION 01 61 01 FOR ACCEPTABLE BONDING COMPANY RATINGS

1.01 Prior to the Owner signing the contract agreement, he will require the Contractor (s) to furnish

separate performance and labor and material payment bonds covering the faithful performance of

the entire construction contract agreement.

The performance bond and the labor and material payment bond shall each be made out in one

hundred percent (100%) of the guaranteed maximum contract amount.

1.02 The "Performance Bond" and "Labor and Material Payment Bond", A.I.A. Document A-312, as

published by The American Institute of Architects shall be used and modified, if necessary, to

comply with applicable statutes.

NOTE: Date of forms to be used shall be complementary to the date of the contract form

and general conditions incorporated within these Bidding and Contract Requirements.

1.03 The bonds shall be signed by an official of the bonding company and shall be accompanied by the

bonding agent's written power of attorney.

1.04 Provide four (4) copies each of the bonds and the power of attorney in order that one (1) copy of

each may be attached to each copy of the contract agreement.

1.05 The Contractor (s) shall include in his proposal amount the total premiums for the performance and

labor and material payment bonds.

**End of Section**

9 March 2018BID ISSUE

Weston Public SchoolsTurf Field Replacement Weston High School

KGD 2018-1010 00 61 01 - 1 Bonding Requirements

Section 00 61 01 - Bonding Requirement

Acceptable Bonding Company Ratings

Contract Amounts ($) A.M. Best Company RatingA + XII B + XI B + X B X B IX B VIII B VII

10 Million and Over ▲7.5 to 10 Million ▲ ▲5.0 to 7.5 Million ▲ ▲ ▲2.5 to 5.0 Million ▲ ▲ ▲ ▲1.0 to 2.5 Million ▲ ▲ ▲ ▲ ▲0.5 to 1.0 Million ▲ ▲ ▲ ▲ ▲ ▲

0.25 to 0.5 Million ▲ ▲ ▲ ▲ ▲ ▲ ▲0.25 and Under ▲ ▲ ▲ ▲ ▲ ▲ ▲

9 March 2018BID ISSUE

Weston Public SchoolsTurf Field Replacement Weston High School

KGD 2018-1010 00 61 01 - 1 Bonding Requirements

B VI

▲

Section 00 61 01 - Bonding Requirement

A.M. Best Company Rating

You created this PDF from an application that is not licensed to print to novaPDF printer (http://www.novapdf.com)

http://www.novapdf.com

9 March 2018 Weston Public Schools

BID ISSUE Turf Field Replacement

Weston High School

KGD2018-1010 00 63 00 - 1 RFI Submittal Form

SECTION 00 63 00

REQUESTS FOR INFORMATION (RFI)

Part 1 - GENERAL

1.01 This document is for issuance at the Post Bid/Pre-Construction Conference and specifies

administrative and procedural requirements for handling requests for information (RFI’s) made

after award of Contract.

1.02 Attention is directed to Sections 01 33 00 and 01 32 00 of Division #1 as same concerns

construction progress schedules, submittal schedules and submittals of shop drawings, samples

and product data in general.

1.03 SUBMITTAL PROCEDURES: RFI’s shall be submitted in the following manner:

A. One (1) completed copy of form following to Architect with copies to Owner (as directed)

and appropriate Consultants with the following minimum information:

1. Work identified by RFI listing affected Drawing(s) and specific detail(s) and

Specification paragraph reference(s).

2. Identify specific field conditions and “as-built” conditions on sketches attached to

RFI submittal.

3. If RFI addresses conflict(s) in, or between, Contract Documents, describe

completely and provide such data necessary to permit thorough and proper

response by affected discipline.

4. Indicate proposed solution along with any impacts on cost and construction time.

5. Listing of Trade/Specialty Contractors affected by RFI and indication that RFI

proposal has been coordinated with said contractors.

INCOMPLETE RFI’s WILL BE RETURNED TO CONTRACTOR WITHOUT ACTION

TAKEN.

1.04 REVIEW PROCEDURES/ACTIONS

A. Architect/Engineer may request additional information or documentation as may be

deemed necessary for fair evaluation of RFI.

B. Architect/Engineer will respond with reasonable promptness as outlined in Section 01 33

00 in writing and may, if deemed appropriate, issue a “Bulletin” as a clarification to the

Contract Documents.

**End of Section**

Document G716TM – 2004Request for Information (“RFI”)

AIA Document G716™ – 2004. Copyright © 2004 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 15:01:42 on 02/09/2012 under Order No.0084045711_1 which expires on 02/28/2013, and is not for resale. User Notes: (1247105096)

1

TO:

FROM:

PROJECT:xyz

ISSUE DATE: RFI No.

REQUESTED REPLY DATE: PROJECT NUMBERS: / COPIES TO:

RFI DESCRIPTION: (Fully describe the question or type of information requested.)

REFERENCES/ATTACHMENTS: (List specific documents researched when seeking the information requested.)SPECIFICATIONS: DRAWINGS: OTHER:

SENDER’S RECOMMENDATION: (If RFI concerns a site or construction condition, the sender may provide a recommended solution, including cost and/or schedule considerations.)

RECEIVER’S REPLY: (Provide answer to RFI, including cost and/or schedule considerations.)

BY DATE COPIES TO

Note: This reply is not an authorization to proceed with work involving additional cost, time or both. If any reply requires a change to the Contract Documents, a Change Order, Construction Change Directive or a Minor Change in the work must be executed in accordance with the Contract Documents.

You created this PDF from an application that is not licensed to print to novaPDF printer (http://www.novapdf.com)

http://www.novapdf.com

Document A201TM

– 2017General Conditions of the Contract for Construction

Init.

/


1



For guidance in modifying this document to include supplementary conditions, see AIA Document A503™, Guide for Supplementary Conditions.

for the following PROJECT:(Name and location or address)


THE OWNER:(Name, legal status and address)


THE ARCHITECT:(Name, legal status and address)

Kaeyer, Garment + Davidson Architects, P.C.285 Main Street; Mount Kisco, NYTelephone Number: 914-666-5900

TABLE OF ARTICLES

1 GENERAL PROVISIONS

2 OWNER

3 CONTRACTOR

4 ARCHITECT

5 SUBCONTRACTORS

6 CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS

7 CHANGES IN THE WORK

8 TIME

9 PAYMENTS AND COMPLETION

10 PROTECTION OF PERSONS AND PROPERTY

11 INSURANCE AND BONDS

12 UNCOVERING AND CORRECTION OF WORK

13 MISCELLANEOUS PROVISIONS

Init.

/


2

14 TERMINATION OR SUSPENSION OF THE CONTRACT

15 CLAIMS AND DISPUTES

Init.

/


3

INDEX(Topics and numbers in bold are Section headings.)

Acceptance of Nonconforming Work9.6.6, 9.9.3, 12.3Acceptance of Work9.6.6, 9.8.2, 9.9.3, 9.10.1, 9.10.3, 12.3Access to Work3.16, 6.2.1, 12.1Accident Prevention10Acts and Omissions3.2, 3.3.2, 3.12.8, 3.18, 4.2.3, 8.3.1, 9.5.1, 10.2.5, 10.2.8, 13.3.2, 14.1, 15.1.2, 15.2Addenda1.1.1Additional Costs, Claims for3.7.4, 3.7.5, 10.3.2, 15.1.5Additional Inspections and Testing9.4.2, 9.8.3, 12.2.1, 13.4Additional Time, Claims for3.2.4, 3.7.4, 3.7.5, 3.10.2, 8.3.2, 15.1.6Administration of the Contract3.1.3, 4.2, 9.4, 9.5Advertisement or Invitation to Bid1.1.1Aesthetic Effect4.2.13Allowances3.8Applications for Payment4.2.5, 7.3.9, 9.2, 9.3, 9.4, 9.5.1, 9.5.4, 9.6.3, 9.7, 9.10Approvals2.1.1, 2.3.1, 2.5, 3.1.3, 3.10.2, 3.12.8, 3.12.9, 3.12.10.1, 4.2.7, 9.3.2, 13.4.1Arbitration8.3.1, 15.3.2, 15.4 ARCHITECT4Architect, Definition of4.1.1Architect, Extent of Authority2.5, 3.12.7, 4.1.2, 4.2, 5.2, 6.3, 7.1.2, 7.3.4, 7.4, 9.2, 9.3.1, 9.4, 9.5, 9.6.3, 9.8, 9.10.1, 9.10.3, 12.1, 12.2.1, 13.4.1, 13.4.2, 14.2.2, 14.2.4, 15.1.4, 15.2.1Architect, Limitations of Authority and Responsibility2.1.1, 3.12.4, 3.12.8, 3.12.10, 4.1.2, 4.2.1, 4.2.2, 4.2.3, 4.2.6, 4.2.7, 4.2.10, 4.2.12, 4.2.13, 5.2.1, 7.4, 9.4.2, 9.5.4, 9.6.4, 15.1.4, 15.2Architect’s Additional Services and Expenses2.5, 12.2.1, 13.4.2, 13.4.3, 14.2.4Architect’s Administration of the Contract3.1.3, 3.7.4, 15.2, 9.4.1, 9.5Architect’s Approvals2.5, 3.1.3, 3.5, 3.10.2, 4.2.7

Architect’s Authority to Reject Work3.5, 4.2.6, 12.1.2, 12.2.1Architect’s Copyright1.1.7, 1.5Architect’s Decisions3.7.4, 4.2.6, 4.2.7, 4.2.11, 4.2.12, 4.2.13, 4.2.14, 6.3, 7.3.4, 7.3.9, 8.1.3, 8.3.1, 9.2, 9.4.1, 9.5, 9.8.4, 9.9.1, 13.4.2, 15.2Architect’s Inspections3.7.4, 4.2.2, 4.2.9, 9.4.2, 9.8.3, 9.9.2, 9.10.1, 13.4Architect’s Instructions3.2.4, 3.3.1, 4.2.6, 4.2.7, 13.4.2Architect’s Interpretations4.2.11, 4.2.12Architect’s Project Representative4.2.10Architect’s Relationship with Contractor1.1.2, 1.5, 2.3.3, 3.1.3, 3.2.2, 3.2.3, 3.2.4, 3.3.1, 3.4.2, 3.5, 3.7.4, 3.7.5, 3.9.2, 3.9.3, 3.10, 3.11, 3.12, 3.16, 3.18, 4.1.2, 4.2, 5.2, 6.2.2, 7, 8.3.1, 9.2, 9.3, 9.4, 9.5, 9.7, 9.8, 9.9, 10.2.6, 10.3, 11.3, 12, 13.3.2, 13.4, 15.2Architect’s Relationship with Subcontractors1.1.2, 4.2.3, 4.2.4, 4.2.6, 9.6.3, 9.6.4, 11.3Architect’s Representations9.4.2, 9.5.1, 9.10.1Architect’s Site Visits3.7.4, 4.2.2, 4.2.9, 9.4.2, 9.5.1, 9.9.2, 9.10.1, 13.4Asbestos10.3.1Attorneys’ Fees3.18.1, 9.6.8, 9.10.2, 10.3.3Award of Separate Contracts6.1.1, 6.1.2Award of Subcontracts and Other Contracts for Portions of the Work5.2Basic Definitions1.1Bidding Requirements1.1.1Binding Dispute Resolution8.3.1, 9.7, 11.5, 13.1, 15.1.2, 15.1.3, 15.2.1, 15.2.5, 15.2.6.1, 15.3.1, 15.3.2, 15.3.3, 15.4.1Bonds, Lien7.3.4.4, 9.6.8, 9.10.2, 9.10.3Bonds, Performance, and Payment7.3.4.4, 9.6.7, 9.10.3, 11.1.2, 11.1.3, 11.5Building Information Models Use and Reliance1.8Building Permit3.7.1Capitalization1.3Certificate of Substantial Completion9.8.3, 9.8.4, 9.8.5

Init.

/


4

Certificates for Payment4.2.1, 4.2.5, 4.2.9, 9.3.3, 9.4, 9.5, 9.6.1, 9.6.6, 9.7, 9.10.1, 9.10.3, 14.1.1.3, 14.2.4, 15.1.4Certificates of Inspection, Testing or Approval13.4.4Certificates of Insurance9.10.2Change Orders1.1.1, 3.4.2, 3.7.4, 3.8.2.3, 3.11, 3.12.8, 4.2.8, 5.2.3, 7.1.2, 7.1.3, 7.2, 7.3.2, 7.3.7, 7.3.9, 7.3.10, 8.3.1, 9.3.1.1, 9.10.3, 10.3.2, 11.2, 11.5, 12.1.2Change Orders, Definition of7.2.1CHANGES IN THE WORK2.2.2, 3.11, 4.2.8, 7, 7.2.1, 7.3.1, 7.4, 8.3.1, 9.3.1.1, 11.5Claims, Definition of15.1.1Claims, Notice of1.6.2, 15.1.3CLAIMS AND DISPUTES3.2.4, 6.1.1, 6.3, 7.3.9, 9.3.3, 9.10.4, 10.3.3, 15, 15.4Claims and Timely Assertion of Claims15.4.1Claims for Additional Cost3.2.4, 3.3.1, 3.7.4, 7.3.9, 9.5.2, 10.2.5, 10.3.2, 15.1.5Claims for Additional Time3.2.4, 3.3.1, 3.7.4, 6.1.1, 8.3.2, 9.5.2, 10.3.2, 15.1.6Concealed or Unknown Conditions, Claims for3.7.4Claims for Damages3.2.4, 3.18, 8.3.3, 9.5.1, 9.6.7, 10.2.5, 10.3.3, 11.3, 11.3.2, 14.2.4, 15.1.7Claims Subject to Arbitration15.4.1Cleaning Up3.15, 6.3Commencement of the Work, Conditions Relating to2.2.1, 3.2.2, 3.4.1, 3.7.1, 3.10.1, 3.12.6, 5.2.1, 5.2.3, 6.2.2, 8.1.2, 8.2.2, 8.3.1, 11.1, 11.2, 15.1.5Commencement of the Work, Definition of8.1.2Communications3.9.1, 4.2.4Completion, Conditions Relating to3.4.1, 3.11, 3.15, 4.2.2, 4.2.9, 8.2, 9.4.2, 9.8, 9.9.1, 9.10, 12.2, 14.1.2, 15.1.2COMPLETION, PAYMENTS AND9Completion, Substantial3.10.1, 4.2.9, 8.1.1, 8.1.3, 8.2.3, 9.4.2, 9.8, 9.9.1, 9.10.3, 12.2, 15.1.2Compliance with Laws2.3.2, 3.2.3, 3.6, 3.7, 3.12.10, 3.13, 9.6.4, 10.2.2, 13.1, 13.3, 13.4.1, 13.4.2, 13.5, 14.1.1, 14.2.1.3, 15.2.8, 15.4.2, 15.4.3

Concealed or Unknown Conditions3.7.4, 4.2.8, 8.3.1, 10.3Conditions of the Contract1.1.1, 6.1.1, 6.1.4Consent, Written3.4.2, 3.14.2, 4.1.2, 9.8.5, 9.9.1, 9.10.2, 9.10.3, 13.2, 15.4.4.2Consolidation or Joinder15.4.4CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS1.1.4, 6Construction Change Directive, Definition of7.3.1Construction Change Directives1.1.1, 3.4.2, 3.11, 3.12.8, 4.2.8, 7.1.1, 7.1.2, 7.1.3, 7.3, 9.3.1.1Construction Schedules, Contractor’s3.10, 3.11, 3.12.1, 3.12.2, 6.1.3, 15.1.6.2Contingent Assignment of Subcontracts5.4, 14.2.2.2Continuing Contract Performance15.1.4Contract, Definition of1.1.2CONTRACT, TERMINATION OR SUSPENSION OF THE5.4.1.1, 5.4.2, 11.5, 14Contract Administration3.1.3, 4, 9.4, 9.5Contract Award and Execution, Conditions Relating to3.7.1, 3.10, 5.2, 6.1Contract Documents, Copies Furnished and Use of1.5.2, 2.3.6, 5.3Contract Documents, Definition of1.1.1Contract Sum2.2.2, 2.2.4, 3.7.4, 3.7.5, 3.8, 3.10.2, 5.2.3, 7.3, 7.4, 9.1, 9.2, 9.4.2, 9.5.1.4, 9.6.7, 9.7, 10.3.2, 11.5, 12.1.2, 12.3, 14.2.4, 14.3.2, 15.1.4.2, 15.1.5, 15.2.5Contract Sum, Definition of9.1Contract Time1.1.4, 2.2.1, 2.2.2, 3.7.4, 3.7.5, 3.10.2, 5.2.3, 6.1.5, 7.2.1.3, 7.3.1, 7.3.5, 7.3.6, 7, 7, 7.3.10, 7.4, 8.1.1, 8.2.1, 8.2.3, 8.3.1, 9.5.1, 9.7, 10.3.2, 12.1.1, 12.1.2, 14.3.2, 15.1.4.2, 15.1.6.1, 15.2.5Contract Time, Definition of8.1.1CONTRACTOR3Contractor, Definition of3.1, 6.1.2Contractor’s Construction and Submittal Schedules3.10, 3.12.1, 3.12.2, 4.2.3, 6.1.3, 15.1.6.2

Init.

/


5

Contractor’s Employees2.2.4, 3.3.2, 3.4.3, 3.8.1, 3.9, 3.18.2, 4.2.3, 4.2.6, 10.2, 10.3, 11.3, 14.1, 14.2.1.1Contractor’s Liability Insurance11.1Contractor’s Relationship with Separate Contractors and Owner’s Forces3.12.5, 3.14.2, 4.2.4, 6, 11.3, 12.2.4Contractor’s Relationship with Subcontractors1.2.2, 2.2.4, 3.3.2, 3.18.1, 3.18.2, 4.2.4, 5, 9.6.2, 9.6.7, 9.10.2, 11.2, 11.3, 11.4Contractor’s Relationship with the Architect1.1.2, 1.5, 2.3.3, 3.1.3, 3.2.2, 3.2.3, 3.2.4, 3.3.1, 3.4.2, 3.5.1, 3.7.4, 3.10, 3.11, 3.12, 3.16, 3.18, 4.2, 5.2, 6.2.2, 7, 8.3.1, 9.2, 9.3, 9.4, 9.5, 9.7, 9.8, 9.9, 10.2.6, 10.3, 11.3, 12, 13.4, 15.1.3, 15.2.1Contractor’s Representations3.2.1, 3.2.2, 3.5, 3.12.6, 6.2.2, 8.2.1, 9.3.3, 9.8.2Contractor’s Responsibility for Those Performing the Work3.3.2, 3.18, 5.3, 6.1.3, 6.2, 9.5.1, 10.2.8Contractor’s Review of Contract Documents3.2Contractor’s Right to Stop the Work2.2.2, 9.7Contractor’s Right to Terminate the Contract14.1Contractor’s Submittals3.10, 3.11, 3.12, 4.2.7, 5.2.1, 5.2.3, 9.2, 9.3, 9.8.2, 9.8.3, 9.9.1, 9.10.2, 9.10.3Contractor’s Superintendent3.9, 10.2.6Contractor’s Supervision and Construction Procedures1.2.2, 3.3, 3.4, 3.12.10, 4.2.2, 4.2.7, 6.1.3, 6.2.4, 7.1.3, 7.3.4, 7.3.6, 8.2, 10, 12, 14, 15.1.4Coordination and Correlation1.2, 3.2.1, 3.3.1, 3.10, 3.12.6, 6.1.3, 6.2.1Copies Furnished of Drawings and Specifications1.5, 2.3.6, 3.11Copyrights1.5, 3.17Correction of Work2.5, 3.7.3, 9.4.2, 9.8.2, 9.8.3, 9.9.1, 12.1.2, 12.2, 12.3, 15.1.3.1, 15.1.3.2, 15.2.1Correlation and Intent of the Contract Documents1.2Cost, Definition of7.3.4Costs2.5, 3.2.4, 3.7.3, 3.8.2, 3.15.2, 5.4.2, 6.1.1, 6.2.3, 7.3.3.3, 7.3.4, 7.3.8, 7.3.9, 9.10.2, 10.3.2, 10.3.6, 11.2, 12.1.2, 12.2.1, 12.2.4, 13.4, 14Cutting and Patching3.14, 6.2.5

Damage to Construction of Owner or Separate Contractors3.14.2, 6.2.4, 10.2.1.2, 10.2.5, 10.4, 12.2.4Damage to the Work3.14.2, 9.9.1, 10.2.1.2, 10.2.5, 10.4, 12.2.4Damages, Claims for3.2.4, 3.18, 6.1.1, 8.3.3, 9.5.1, 9.6.7, 10.3.3, 11.3.2, 11.3, 14.2.4, 15.1.7Damages for Delay6.2.3, 8.3.3, 9.5.1.6, 9.7, 10.3.2, 14.3.2Date of Commencement of the Work, Definition of8.1.2Date of Substantial Completion, Definition of8.1.3Day, Definition of8.1.4Decisions of the Architect3.7.4, 4.2.6, 4.2.7, 4.2.11, 4.2.12, 4.2.13, 6.3, 7.3.4, 7.3.9, 8.1.3, 8.3.1, 9.2, 9.4, 9.5.1, 9.8.4, 9.9.1, 13.4.2, 14.2.2, 14.2.4, 15.1, 15.2Decisions to Withhold Certification9.4.1, 9.5, 9.7, 14.1.1.3Defective or Nonconforming Work, Acceptance, Rejection and Correction of2.5, 3.5, 4.2.6, 6.2.3, 9.5.1, 9.5.3, 9.6.6, 9.8.2, 9.9.3, 9.10.4, 12.2.1Definitions1.1, 2.1.1, 3.1.1, 3.5, 3.12.1, 3.12.2, 3.12.3, 4.1.1, 5.1, 6.1.2, 7.2.1, 7.3.1, 8.1, 9.1, 9.8.1, 15.1.1Delays and Extensions of Time3.2, 3.7.4, 5.2.3, 7.2.1, 7.3.1, 7.4, 8.3, 9.5.1, 9.7, 10.3.2, 10.4, 14.3.2, 15.1.6, 15.2.5Digital Data Use and Transmission1.7Disputes6.3, 7.3.9, 15.1, 15.2Documents and Samples at the Site3.11Drawings, Definition of1.1.5Drawings and Specifications, Use and Ownership of3.11Effective Date of Insurance8.2.2Emergencies10.4, 14.1.1.2, 15.1.5Employees, Contractor’s3.3.2, 3.4.3, 3.8.1, 3.9, 3.18.2, 4.2.3, 4.2.6, 10.2, 10.3.3, 11.3, 14.1, 14.2.1.1Equipment, Labor, or Materials1.1.3, 1.1.6, 3.4, 3.5, 3.8.2, 3.8.3, 3.12, 3.13, 3.15.1, 4.2.6, 4.2.7, 5.2.1, 6.2.1, 7.3.4, 9.3.2, 9.3.3, 9.5.1.3, 9.10.2, 10.2.1, 10.2.4, 14.2.1.1, 14.2.1.2Execution and Progress of the Work1.1.3, 1.2.1, 1.2.2, 2.3.4, 2.3.6, 3.1, 3.3.1, 3.4.1, 3.7.1, 3.10.1, 3.12, 3.14, 4.2, 6.2.2, 7.1.3, 7.3.6, 8.2, 9.5.1, 9.9.1, 10.2, 10.3, 12.1, 12.2, 14.2, 14.3.1, 15.1.4

Init.

/


6

Extensions of Time3.2.4, 3.7.4, 5.2.3, 7.2.1, 7.3, 7.4, 9.5.1, 9.7, 10.3.2, 10.4, 14.3, 15.1.6, 15.2.5Failure of Payment9.5.1.3, 9.7, 9.10.2, 13.5, 14.1.1.3, 14.2.1.2Faulty Work(See Defective or Nonconforming Work)Final Completion and Final Payment4.2.1, 4.2.9, 9.8.2, 9.10, 12.3, 14.2.4, 14.4.3Financial Arrangements, Owner’s2.2.1, 13.2.2, 14.1.1.4GENERAL PROVISIONS1Governing Law13.1Guarantees (See Warranty)Hazardous Materials and Substances10.2.4, 10.3Identification of Subcontractors and Suppliers5.2.1Indemnification3.17, 3.18, 9.6.8, 9.10.2, 10.3.3, 11.3Information and Services Required of the Owner2.1.2, 2.2, 2.3, 3.2.2, 3.12.10.1, 6.1.3, 6.1.4, 6.2.5, 9.6.1, 9.9.2, 9.10.3, 10.3.3, 11.2, 13.4.1, 13.4.2, 14.1.1.4, 14.1.4, 15.1.4Initial Decision15.2Initial Decision Maker, Definition of1.1.8Initial Decision Maker, Decisions14.2.4, 15.1.4.2, 15.2.1, 15.2.2, 15.2.3, 15.2.4, 15.2.5Initial Decision Maker, Extent of Authority14.2.4, 15.1.4.2, 15.2.1, 15.2.2, 15.2.3, 15.2.4, 15.2.5Injury or Damage to Person or Property10.2.8, 10.4Inspections3.1.3, 3.3.3, 3.7.1, 4.2.2, 4.2.6, 4.2.9, 9.4.2, 9.8.3, 9.9.2, 9.10.1, 12.2.1, 13.4Instructions to Bidders1.1.1Instructions to the Contractor3.2.4, 3.3.1, 3.8.1, 5.2.1, 7, 8.2.2, 12, 13.4.2Instruments of Service, Definition of1.1.7Insurance6.1.1, 7.3.4, 8.2.2, 9.3.2, 9.8.4, 9.9.1, 9.10.2, 10.2.5, 11Insurance, Notice of Cancellation or Expiration11.1.4, 11.2.3Insurance, Contractor’s Liability11.1Insurance, Effective Date of8.2.2, 14.4.2Insurance, Owner’s Liability11.2Insurance, Property10.2.5, 11.2, 11.4, 11.5

Insurance, Stored Materials9.3.2INSURANCE AND BONDS11Insurance Companies, Consent to Partial Occupancy9.9.1Insured loss, Adjustment and Settlement of11.5Intent of the Contract Documents1.2.1, 4.2.7, 4.2.12, 4.2.13Interest13.5Interpretation1.1.8, 1.2.3, 1.4, 4.1.1, 5.1, 6.1.2, 15.1.1Interpretations, Written4.2.11, 4.2.12Judgment on Final Award15.4.2Labor and Materials, Equipment1.1.3, 1.1.6, 3.4, 3.5, 3.8.2, 3.8.3, 3.12, 3.13, 3.15.1, 5.2.1, 6.2.1, 7.3.4, 9.3.2, 9.3.3, 9.5.1.3, 9.10.2, 10.2.1, 10.2.4, 14.2.1.1, 14.2.1.2Labor Disputes8.3.1Laws and Regulations1.5, 2.3.2, 3.2.3, 3.2.4, 3.6, 3.7, 3.12.10, 3.13, 9.6.4, 9.9.1, 10.2.2, 13.1, 13.3.1, 13.4.2, 13.5, 14, 15.2.8, 15.4Liens2.1.2, 9.3.1, 9.3.3, 9.6.8, 9.10.2, 9.10.4, 15.2.8Limitations, Statutes of12.2.5, 15.1.2, 15.4.1.1Limitations of Liability3.2.2, 3.5, 3.12.10, 3.12.10.1, 3.17, 3.18.1, 4.2.6, 4.2.7, 6.2.2, 9.4.2, 9.6.4, 9.6.7, 9.6.8, 10.2.5, 10.3.3, 11.3, 12.2.5, 13.3.1Limitations of Time2.1.2, 2.2, 2.5, 3.2.2, 3.10, 3.11, 3.12.5, 3.15.1, 4.2.7, 5.2, 5.3, 5.4.1, 6.2.4, 7.3, 7.4, 8.2, 9.2, 9.3.1, 9.3.3, 9.4.1, 9.5, 9.6, 9.7, 9.8, 9.9, 9.10, 12.2, 13.4, 14, 15, 15.1.2, 15.1.3, 15.1.5Materials, Hazardous10.2.4, 10.3Materials, Labor, Equipment and1.1.3, 1.1.6, 3.4.1, 3.5, 3.8.2, 3.8.3, 3.12, 3.13, 3.15.1, 5.2.1, 6.2.1, 7.3.4, 9.3.2, 9.3.3, 9.5.1.3, 9.10.2, 10.2.1.2, 10.2.4, 14.2.1.1, 14.2.1.2Means, Methods, Techniques, Sequences and Procedures of Construction3.3.1, 3.12.10, 4.2.2, 4.2.7, 9.4.2Mechanic’s Lien2.1.2, 9.3.1, 9.3.3, 9.6.8, 9.10.2, 9.10.4, 15.2.8Mediation8.3.1, 15.1.3.2, 15.2.1, 15.2.5, 15.2.6, 15.3, 15.4.1, 15.4.1.1Minor Changes in the Work1.1.1, 3.4.2, 3.12.8, 4.2.8, 7.1, 7.4

Init.

/


7

MISCELLANEOUS PROVISIONS13Modifications, Definition of1.1.1Modifications to the Contract1.1.1, 1.1.2, 2.5, 3.11, 4.1.2, 4.2.1, 5.2.3, 7, 8.3.1, 9.7, 10.3.2Mutual Responsibility6.2Nonconforming Work, Acceptance of9.6.6, 9.9.3, 12.3Nonconforming Work, Rejection and Correction of2.4, 2.5, 3.5, 4.2.6, 6.2.4, 9.5.1, 9.8.2, 9.9.3, 9.10.4, 12.2Notice1.6, 1.6.1, 1.6.2, 2.1.2, 2.2.2., 2.2.3, 2.2.4, 2.5, 3.2.4, 3.3.1, 3.7.4, 3.7.5, 3.9.2, 3.12.9, 3.12.10, 5.2.1, 7.4, 8.2.2 9.6.8, 9.7, 9.10.1, 10.2.8, 10.3.2, 11.5, 12.2.2.1, 13.4.1, 13.4.2, 14.1, 14.2.2, 14.4.2, 15.1.3, 15.1.5, 15.1.6, 15.4.1Notice of Cancellation or Expiration of Insurance11.1.4, 11.2.3Notice of Claims1.6.2, 2.1.2, 3.7.4, 9.6.8, 10.2.8, 15.1.3, 15.1.5, 15.1.6, 15.2.8, 15.3.2, 15.4.1Notice of Testing and Inspections13.4.1, 13.4.2Observations, Contractor’s3.2, 3.7.4Occupancy2.3.1, 9.6.6, 9.8Orders, Written1.1.1, 2.4, 3.9.2, 7, 8.2.2, 11.5, 12.1, 12.2.2.1, 13.4.2, 14.3.1OWNER2Owner, Definition of2.1.1Owner, Evidence of Financial Arrangements2.2, 13.2.2, 14.1.1.4Owner, Information and Services Required of the2.1.2, 2.2, 2.3, 3.2.2, 3.12.10, 6.1.3, 6.1.4, 6.2.5, 9.3.2, 9.6.1, 9.6.4, 9.9.2, 9.10.3, 10.3.3, 11.2, 13.4.1, 13.4.2, 14.1.1.4, 14.1.4, 15.1.4Owner’s Authority1.5, 2.1.1, 2.3.32.4, 2.5, 3.4.2, 3.8.1, 3.12.10, 3.14.2, 4.1.2, 4.2.4, 4.2.9, 5.2.1, 5.2.4, 5.4.1, 6.1, 6.3, 7.2.1, 7.3.1, 8.2.2, 8.3.1, 9.3.2, 9.5.1, 9.6.4, 9.9.1, 9.10.2, 10.3.2, 11.4, 11.5, 12.2.2, 12.3, 13.2.2, 14.3, 14.4, 15.2.7Owner’s Insurance11.2Owner’s Relationship with Subcontractors1.1.2, 5.2, 5.3, 5.4, 9.6.4, 9.10.2, 14.2.2Owner’s Right to Carry Out the Work2.5, 14.2.2

Owner’s Right to Clean Up6.3Owner’s Right to Perform Construction and to Award Separate Contracts6.1Owner’s Right to Stop the Work2.4Owner’s Right to Suspend the Work14.3Owner’s Right to Terminate the Contract14.2, 14.4Ownership and Use of Drawings, Specifications and Other Instruments of Service1.1.1, 1.1.6, 1.1.7, 1.5, 2.3.6, 3.2.2, 3.11, 3.17, 4.2.12, 5.3Partial Occupancy or Use9.6.6, 9.9Patching, Cutting and3.14, 6.2.5Patents3.17Payment, Applications for4.2.5, 7.3.9, 9.2, 9.3, 9.4, 9.5, 9.6.3, 9.7, 9.8.5, 9.10.1, 14.2.3, 14.2.4, 14.4.3Payment, Certificates for4.2.5, 4.2.9, 9.3.3, 9.4, 9.5, 9.6.1, 9.6.6, 9.7, 9.10.1, 9.10.3, 14.1.1.3, 14.2.4Payment, Failure of9.5.1.3, 9.7, 9.10.2, 13.5, 14.1.1.3, 14.2.1.2Payment, Final4.2.1, 4.2.9, 9.10, 12.3, 14.2.4, 14.4.3Payment Bond, Performance Bond and7.3.4.4, 9.6.7, 9.10.3, 11.1.2Payments, Progress9.3, 9.6, 9.8.5, 9.10.3, 14.2.3, 15.1.4PAYMENTS AND COMPLETION9Payments to Subcontractors5.4.2, 9.5.1.3, 9.6.2, 9.6.3, 9.6.4, 9.6.7, 14.2.1.2PCB10.3.1Performance Bond and Payment Bond7.3.4.4, 9.6.7, 9.10.3, 11.1.2Permits, Fees, Notices and Compliance with Laws2.3.1, 3.7, 3.13, 7.3.4.4, 10.2.2PERSONS AND PROPERTY, PROTECTION OF10Polychlorinated Biphenyl10.3.1Product Data, Definition of3.12.2Product Data and Samples, Shop Drawings3.11, 3.12, 4.2.7Progress and Completion4.2.2, 8.2, 9.8, 9.9.1, 14.1.4, 15.1.4Progress Payments9.3, 9.6, 9.8.5, 9.10.3, 14.2.3, 15.1.4

Init.

/


8

Project, Definition of1.1.4Project Representatives4.2.10Property Insurance10.2.5, 11.2Proposal Requirements1.1.1PROTECTION OF PERSONS AND PROPERTY10Regulations and Laws1.5, 2.3.2, 3.2.3, 3.6, 3.7, 3.12.10, 3.13, 9.6.4, 9.9.1, 10.2.2, 13.1, 13.3, 13.4.1, 13.4.2, 13.5, 14, 15.2.8, 15.4Rejection of Work4.2.6, 12.2.1Releases and Waivers of Liens9.3.1, 9.10.2Representations3.2.1, 3.5, 3.12.6, 8.2.1, 9.3.3, 9.4.2, 9.5.1, 9.10.1Representatives2.1.1, 3.1.1, 3.9, 4.1.1, 4.2.10, 13.2.1Responsibility for Those Performing the Work3.3.2, 3.18, 4.2.2, 4.2.3, 5.3, 6.1.3, 6.2, 6.3, 9.5.1, 10Retainage9.3.1, 9.6.2, 9.8.5, 9.9.1, 9.10.2, 9.10.3Review of Contract Documents and Field Conditions by Contractor3.2, 3.12.7, 6.1.3Review of Contractor’s Submittals by Owner and Architect3.10.1, 3.10.2, 3.11, 3.12, 4.2, 5.2, 6.1.3, 9.2, 9.8.2Review of Shop Drawings, Product Data and Samples by Contractor3.12Rights and Remedies1.1.2, 2.4, 2.5, 3.5, 3.7.4, 3.15.2, 4.2.6, 5.3, 5.4, 6.1, 6.3, 7.3.1, 8.3, 9.5.1, 9.7, 10.2.5, 10.3, 12.2.1, 12.2.2, 12.2.4, 13.3, 14, 15.4Royalties, Patents and Copyrights3.17Rules and Notices for Arbitration15.4.1Safety of Persons and Property10.2, 10.4Safety Precautions and Programs3.3.1, 4.2.2, 4.2.7, 5.3, 10.1, 10.2, 10.4Samples, Definition of3.12.3Samples, Shop Drawings, Product Data and3.11, 3.12, 4.2.7Samples at the Site, Documents and3.11Schedule of Values9.2, 9.3.1Schedules, Construction3.10, 3.12.1, 3.12.2, 6.1.3, 15.1.6.2

Separate Contracts and Contractors1.1.4, 3.12.5, 3.14.2, 4.2.4, 4.2.7, 6, 8.3.1, 12.1.2Separate Contractors, Definition of6.1.1Shop Drawings, Definition of3.12.1Shop Drawings, Product Data and Samples3.11, 3.12, 4.2.7Site, Use of3.13, 6.1.1, 6.2.1Site Inspections3.2.2, 3.3.3, 3.7.1, 3.7.4, 4.2, 9.9.2, 9.4.2, 9.10.1, 13.4Site Visits, Architect’s3.7.4, 4.2.2, 4.2.9, 9.4.2, 9.5.1, 9.9.2, 9.10.1, 13.4Special Inspections and Testing4.2.6, 12.2.1, 13.4Specifications, Definition of1.1.6Specifications1.1.1, 1.1.6, 1.2.2, 1.5, 3.12.10, 3.17, 4.2.14Statute of Limitations15.1.2, 15.4.1.1Stopping the Work2.2.2, 2.4, 9.7, 10.3, 14.1Stored Materials6.2.1, 9.3.2, 10.2.1.2, 10.2.4Subcontractor, Definition of5.1.1SUBCONTRACTORS5Subcontractors, Work by1.2.2, 3.3.2, 3.12.1, 3.18, 4.2.3, 5.2.3, 5.3, 5.4, 9.3.1.2, 9.6.7Subcontractual Relations5.3, 5.4, 9.3.1.2, 9.6, 9.10, 10.2.1, 14.1, 14.2.1Submittals3.10, 3.11, 3.12, 4.2.7, 5.2.1, 5.2.3, 7.3.4, 9.2, 9.3, 9.8, 9.9.1, 9.10.2, 9.10.3Submittal Schedule3.10.2, 3.12.5, 4.2.7Subrogation, Waivers of6.1.1, 11.3Substances, Hazardous10.3Substantial Completion4.2.9, 8.1.1, 8.1.3, 8.2.3, 9.4.2, 9.8, 9.9.1, 9.10.3, 12.2, 15.1.2Substantial Completion, Definition of9.8.1Substitution of Subcontractors5.2.3, 5.2.4Substitution of Architect2.3.3Substitutions of Materials3.4.2, 3.5, 7.3.8Sub-subcontractor, Definition of5.1.2

Init.

/


9

Subsurface Conditions3.7.4Successors and Assigns13.2Superintendent3.9, 10.2.6Supervision and Construction Procedures1.2.2, 3.3, 3.4, 3.12.10, 4.2.2, 4.2.7, 6.1.3, 6.2.4, 7.1.3, 7.3.4, 8.2, 8.3.1, 9.4.2, 10, 12, 14, 15.1.4Suppliers1.5, 3.12.1, 4.2.4, 4.2.6, 5.2.1, 9.3, 9.4.2, 9.5.4, 9.6, 9.10.5, 14.2.1Surety5.4.1.2, 9.6.8, 9.8.5, 9.10.2, 9.10.3, 11.1.2, 14.2.2, 15.2.7Surety, Consent of9.8.5, 9.10.2, 9.10.3Surveys1.1.7, 2.3.4Suspension by the Owner for Convenience14.3Suspension of the Work3.7.5, 5.4.2, 14.3Suspension or Termination of the Contract5.4.1.1, 14Taxes3.6, 3.8.2.1, 7.3.4.4Termination by the Contractor14.1, 15.1.7Termination by the Owner for Cause5.4.1.1, 14.2, 15.1.7Termination by the Owner for Convenience14.4Termination of the Architect2.3.3Termination of the Contractor Employment14.2.2

TERMINATION OR SUSPENSION OF THE CONTRACT14Tests and Inspections3.1.3, 3.3.3, 3.7.1, 4.2.2, 4.2.6, 4.2.9, 9.4.2, 9.8.3, 9.9.2, 9.10.1, 10.3.2, 12.2.1, 13.4TIME8Time, Delays and Extensions of3.2.4, 3.7.4, 5.2.3, 7.2.1, 7.3.1, 7.4, 8.3, 9.5.1, 9.7, 10.3.2, 10.4, 14.3.2, 15.1.6, 15.2.5

Time Limits2.1.2, 2.2, 2.5, 3.2.2, 3.10, 3.11, 3.12.5, 3.15.1, 4.2, 5.2, 5.3, 5.4, 6.2.4, 7.3, 7.4, 8.2, 9.2, 9.3.1, 9.3.3, 9.4.1, 9.5, 9.6, 9.7, 9.8, 9.9, 9.10, 12.2, 13.4, 14, 15.1.2, 15.1.3, 15.4Time Limits on Claims3.7.4, 10.2.8, 15.1.2, 15.1.3Title to Work9.3.2, 9.3.3UNCOVERING AND CORRECTION OF WORK12Uncovering of Work12.1Unforeseen Conditions, Concealed or Unknown3.7.4, 8.3.1, 10.3Unit Prices7.3.3.2, 9.1.2Use of Documents1.1.1, 1.5, 2.3.6, 3.12.6, 5.3Use of Site3.13, 6.1.1, 6.2.1Values, Schedule of9.2, 9.3.1Waiver of Claims by the Architect13.3.2Waiver of Claims by the Contractor9.10.5, 13.3.2, 15.1.7Waiver of Claims by the Owner9.9.3, 9.10.3, 9.10.4, 12.2.2.1, 13.3.2, 14.2.4, 15.1.7Waiver of Consequential Damages14.2.4, 15.1.7Waiver of Liens9.3, 9.10.2, 9.10.4Waivers of Subrogation6.1.1, 11.3Warranty3.5, 4.2.9, 9.3.3, 9.8.4, 9.9.1, 9.10.2, 9.10.4, 12.2.2, 15.1.2Weather Delays8.3, 15.1.6.2Work, Definition of1.1.3Written Consent1.5.2, 3.4.2, 3.7.4, 3.12.8, 3.14.2, 4.1.2, 9.3.2, 9.10.3, 13.2, 13.3.2, 15.4.4.2Written Interpretations4.2.11, 4.2.12Written Orders1.1.1, 2.4, 3.9, 7, 8.2.2, 12.1, 12.2, 13.4.2, 14.3.1

Init.

/


10

ARTICLE 1 GENERAL PROVISIONS§ 1.1 Basic Definitions§ 1.1.1 The Contract DocumentsThe Contract Documents are enumerated in the Agreement between the Owner and Contractor (hereinafter the Agreement) and consist of the Agreement, Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, Addenda issued prior to execution of the Contract, other documents listed in the Agreement, and Modifications issued after execution of the Contract. A Modification is (1) a written amendment to the Contract signed by both parties (including, without limitation the Guaranteed Maximum Price Amendment, if applicable), (2) a Change Order, (3) a Construction Change Directive, or (4) a written order for a minor change in the Work issued by the Architect. Unless specifically enumerated in the Agreement, the Contract Documents do not include the advertisement or invitation to bid, Instructions to Bidders, sample forms, other information furnished by the Owner in anticipation of receiving bids or proposals, the Contractor’s bid or proposal, or portions of Addenda relating to bidding or proposal requirements.

§ 1.1.2 The ContractThe Contract Documents form the Contract for Construction. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations, or agreements, either written or oral. The Contract may be amended or modified only by a Modification. The Contract Documents shall not be construed to create a contractual relationship of any kind (1) between the Contractor and the Architect or the Architect’s consultants, (2) between the Owner and a Subcontractor, supplier, or a Sub-subcontractor, (3) between the Owner and the Architect or the Architect’s consultants, or (4) between any persons or entities other than the Owner and the Contractor.

§ 1.1.3 The WorkThe term "Work" means the construction and services required by, reasonably inferable from, and as necessary to produce the results intended by, the Contract Documents, whether completed or partially completed, and includes all other labor, materials, equipment, and services provided or to be provided by the Contractor to fulfill the Contractor’s obligations. The Work may constitute the whole or a part of the Project.

§ 1.1.4 The ProjectThe Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part and which may include construction by the Owner and by Separate Contractors.

§ 1.1.5 The DrawingsThe Drawings are the graphic and pictorial portions of the Contract Documents showing the design, location and dimensions of the Work, generally including plans, elevations, sections, details, schedules, and diagrams.

§ 1.1.6 The SpecificationsThe Specifications are that portion of the Contract Documents consisting of the written requirements for materials, equipment, systems, standards and workmanship for the Work, and performance of related services.

§ 1.1.7 Instruments of ServiceInstruments of Service are representations, in any medium of expression now known or later developed, of the tangible and intangible creative work performed by the Architect and the Architect’s consultants under their respective professional services agreements. Instruments of Service may include, without limitation, studies, surveys, models, sketches, drawings, specifications, and other similar materials.

§ 1.1.8 Initial Decision MakerThe Initial Decision Maker is the person identified in the Agreement to render initial decisions on Claims in accordance with Section 15.2. The Initial Decision Maker shall not show partiality to the Owner or Contractor and shall not be liable for results of interpretations or decisions rendered in good faith.

§ 1.1.9 CONTRACTORIf the Agreement which is a part of the Contract Documents is AIA Document A133-2009-2009, the term "Contractor", as used in these General Conditions, shall mean and refer to the Construction Manager, as defined in the Agreement.

Init.

/


11

§ 1.2 Correlation and Intent of the Contract Documents§ 1.2.1 The intent of the Contract Documents is to include all items necessary for the proper execution and completion of the Work by the Contractor. The Contract Documents are complementary, and what is required by one shall be as binding as if required by all; performance by the Contractor shall be required only to the extent consistent with the Contract Documents and reasonably inferable from them as being necessary to produce the indicated results. If the Contractor discovers any inconsistency within or among parts of the Contract Documents, or between the Contract Documents and applicable standards, codes or ordinances, the Contractor shall promptly give notice to the Owner and the Architect of such inconsistency and shall, unless otherwise instructed in writing by the Architect or the Owner, provide work or materials of the better quality, greater quantity, or that otherwise comply with applicable standards, codes or ordinances.

§ 1.2.1.1 The invalidity of any provision of the Contract Documents shall not invalidate the Contract or its remaining provisions. If it is determined that any provision of the Contract Documents violates any law, or is otherwise invalid or unenforceable, then that provision shall be revised to the extent necessary to make that provision legal and enforceable. In such case the Contract Documents shall be construed, to the fullest extent permitted by law, to give effect to the parties’ intentions and purposes in executing the Contract.

§ 1.2.2 Organization of the Specifications into divisions, sections and articles, and arrangement of Drawings shall not control the Contractor in dividing the Work among Subcontractors or in establishing the extent of Work to be performed by any trade.

§ 1.2.3 Unless otherwise stated in the Contract Documents, words that have well-known technical or construction industry meanings are used in the Contract Documents in accordance with such recognized meanings.

§ 1.3 CapitalizationTerms capitalized in these General Conditions include those that are (1) specifically defined, (2) the titles of numbered articles, or (3) the titles of other documents published by the American Institute of Architects.

§ 1.4 InterpretationIn the interest of brevity the Contract Documents frequently omit modifying words such as "all" and "any" and articles such as "the" and "an," but the fact that a modifier or an article is absent from one statement and appears in another is not intended to affect the interpretation of either statement.

§ 1.5 Ownership and Use of Drawings, Specifications, and Other Instruments of Service§ 1.5.1 The Contractor, Subcontractors, Sub-subcontractors, and suppliers shall not own or claim a copyright in the Instruments of Service. Submittal or distribution to meet official regulatory requirements or for other purposes in connection with the Project is not to be construed as publication in derogation of the reserved rights of the owner of such Instruments of Service.

§ 1.5.2 The Contractor, Subcontractors, Sub-subcontractors, and suppliers are authorized to use and reproduce the Instruments of Service provided to them, subject to any protocols established pursuant to Sections 1.7 and 1.8, solely and exclusively for execution of the Work. All copies made under this authorization shall bear the copyright notice, if any, shown on the Instruments of Service. The Contractor, Subcontractors, Sub-subcontractors, and suppliers may not use the Instruments of Service on other projects or for additions to the Project outside the scope of the Work without the specific written consent of the Owner, Architect, and the Architect’s consultants.

§ 1.6 Notice§ 1.6.1 Except as otherwise provided in Section 1.6.2, where the Contract Documents require one party to notify or give notice to the other party, such notice shall be provided in writing to the designated representative of the party to whom the notice is addressed and shall be deemed to have been duly served if delivered in person, by mail, by courier, or by electronic transmission if a method for electronic transmission is set forth in the Agreement.

§ 1.6.2 Notice of Claims as provided in Section 15.1.3 shall be provided in writing and shall be deemed to have been duly served only if delivered to the designated representative of the party to whom the notice is addressed by certified or registered mail, or by courier providing proof of delivery.

Init.

/


12

§ 1.7 Digital Data Use and TransmissionThe parties shall agree upon protocols governing the transmission and use of Instruments of Service or any other information or documentation in digital form. The parties may use AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, to establish the protocols for the development, use, transmission, and exchange of digital data.

§ 1.8 Building Information Models Use and RelianceAny use of, or reliance on, all or a portion of a building information model without agreement to protocols governing the use of, and reliance on, the information contained in the model and without having those protocols set forth in AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, and the requisite AIA Document G202™–2013, Project Building Information Modeling Protocol Form, shall be at the using or relying party’s sole risk and without liability to the other party and its contractors or consultants, the authors of, or contributors to, the building information model, and each of their agents and employees.

ARTICLE 2 OWNER§ 2.1 General§ 2.1.1 The Owner is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The Owner’s representative shall be the person designated as such in the Agreement, or a successor to such person designated by the Owner in writing from time to time, which person shall have express authority to bind the Owner with respect to all matters requiring the Owner’s approval or authorization, subject to such limitations as Owner may specify in writing to Contractor from time to time. Any action taken on Owner’s behalf other than by the representative so designated by Owner will not be binding upon the Owner. The Architect does not have such authority. The term "Owner" means the Owner or the Owner’s authorized representative.

§ 2.1.2 Intentionally Omitted.

§ 2.2 Evidence of the Owner’s Financial Arrangements§ 2.2.1 Prior to commencement of the Work, upon written request by the Contractor, the Owner shall furnish to the Contractor reasonable evidence that the Owner has made financial arrangements to fulfill the Owner’s obligations under the Contract. If such evidence is so requested, the Contractor shall have no obligation to commence the Work until the Owner provides such evidence.


§ 2.2.3 After the Owner furnishes evidence of financial arrangements under this Section 2.2, the Owner shall not materially vary such financial arrangements without prior notice to the Contractor.

§ 2.2.4 Where the Owner has designated information furnished under this Section 2.2 as "confidential," the Contractor shall keep the information confidential and shall not disclose it to any other person. However, the Contractor may disclose "confidential" information, after seven (7) days’ notice to the Owner, where disclosure is required by law, including a subpoena or other form of compulsory legal process issued by a court or governmental entity, or by court or arbitrator(s) order. The Contractor may also disclose "confidential" information to its employees, consultants, sureties, Subcontractors and their employees, Sub-subcontractors, and others who need to know the content of such information solely and exclusively for the Project and who agree to maintain the confidentiality of such information.

§ 2.3 Information and Services Required of the Owner§ 2.3.1 Except for permits, related fees and filings that are the responsibility of the Contractor under the Contract Documents, including those required under Section 3.7.1, the Owner shall secure, file and pay for necessary approvals, easements, assessments and charges required for construction, use or occupancy of permanent structures or for permanent changes in existing facilities.

§ 2.3.2 The Owner shall retain an architect (or engineer, as appropriate) lawfully licensed to practice architecture (or engineering, as applicable), or an entity lawfully practicing architecture (or engineering, as applicable), in the jurisdiction where the Project is located. That person or entity is identified as the Architect in the Agreement and is referred to throughout the Contract Documents as if singular in number.

Init.

/


13

§ 2.3.3 If the employment of the Architect (or engineer, as applicable) terminates, the Owner shall employ a successor provided the services of the Architect (or engineer, as applicable) are still needed for the Project at the time of termination. § 2.3.4 The Owner shall furnish surveys describing physical characteristics, legal limitations and utility locations for the site of the Project. The Contractor shall be entitled to rely on the accuracy of such surveys but shall, in all cases, exercise proper precautions relating to the safe performance of the Work. Any other data provided by the Owner to the Contractor concerning the physical characteristics or measurements of the components that comprise the Project site; access to the Project site or staging and storing at the Project site; present obstructions and conditions of structures on or near the Project site; locations and depths of sewers, conduits, pipes, and gas lines on or near the Project site; positions of sidewalks, curbs and pavements on or near the Project site and other data concerning the conditions of the Project site and its surroundings (collectively, "Site Data"), have been obtained from sources the Owner believes to be reliable. Accuracy of the Site Data, however, is not guaranteed and is furnished solely for accommodation of the Contractor. Use of the Site Data is made at the Contractor’s sole risk and Contractor releases and waives as against the Owner any claim for damages arising from any defect in or deficiency of the Contract Documents, including without limitation, the failure of the Site Data to comply with all applicable Legal Requirements (as defined in Section 3.7.2 of these General Conditions), it being understood and agreed that the Contractor’s sole remedy for inaccuracies or other deficiencies in Site Data will be to request an appropriate Change Order pursuant to the Contract Documents.

§ 2.3.5 The Owner shall furnish information or services required of the Owner by the Contract Documents with reasonable promptness. The Owner shall furnish such information and services with reasonable promptness after receiving the Contractor’s written request for such information or services.

§ 2.3.6 Unless otherwise provided in the Contract Documents, the Owner shall furnish to the Contractor one copy of the Contract Documents for purposes of making reproductions pursuant to Section 1.5.2.

§ 2.4 Owner’s Right to Stop the WorkIf the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity, except to the extent required by Section 6.1.3.

§ 2.5 Owner’s Right to Carry Out the WorkIf the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a five-day period after receipt of notice from the Owner to commence and continue correction of such default or neglect, and all deficiencies in the Work arising therefrom, with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such default or neglect and the deficiencies in the Work arising therefrom. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the Owner’s cost of correcting the default or neglect and the deficiencies in the Work arising therefrom, including, without limitation, expenses, attorneys’ fees, and compensation for the Architect’s additional services made necessary by such default, neglect, failure and deficiencies. The Contractor shall also be responsible for all of Owner’s other costs, damages, delays, and associated impacts arising in the event that the Owner exercises its rights under this Section 2.5. The Architect may, pursuant to Section 9.5.1, withhold or nullify a Certificate for Payment in whole or in part, to the extent necessary to pay the Owner the amounts due under this Section 2.5. If current and future payments are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner. If the Contractor disagrees with the actions of the Owner or the Architect, or the amounts claimed as costs to the Owner, the Contractor may file a Claim pursuant to Article 15. The right of the Owner to carry out the Work pursuant to this Section 2.5 shall not give rise to any duties on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity. In performing any work pursuant to this Section 2.5, the Owner shall have the right to take possession of the site and of all materials, equipment, tools, and construction equipment and machinery thereon owned by the Contractor or any Subcontractor.

§ 2.6 ADDITIONAL RIGHTS§ 2.6.1 The rights stated in this Article 2 shall be in addition to, and not in limitation of, any other rights of the Owner provided in the Contract Documents, or as may be available to the Owner at law or in equity.

Init.

/


14

ARTICLE 3 CONTRACTOR§ 3.1 General§ 3.1.1 The Contractor is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The Contractor and subcontractors of all tiers shall be lawfully licensed to the extent and as required in the jurisdiction where the Project is located. The Contractor shall designate in writing a representative who shall have express authority to bind the Contractor with respect to all matters under this Contract. The term "Contractor" means the Contractor or the Contractor’s authorized representative.

§ 3.1.2 The Contractor shall perform the Work in accordance with the Contract Documents.§ 3.1.2.1 Unless explicit quality or standards for materials or workmanship are established in the Contract Documents for any portion of the Work, the Contractor shall perform such Work in a good and workman like manner, in a manner of good quality for the intended use, and consistent with the quality of the surrounding Work and of the construction of the Project generally.

§ 3.1.2.2 All manufactured articles, materials and equipment shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the manufacturer’s written or printed directions and instructions unless otherwise specifically indicated in the Contract Documents.

§ 3.1.2.3 CONTRACTOR’S STANDARD OF CARE§ 3.1.2.3.1 The Contractor shall be responsible for the performance of all of the Work (i) in a good and workmanlike manner; (ii) consistent and in accordance with the Contract Documents; (iii) consistent and in accordance with the instructions, guidance and direction of the Owner and Architect; (iv) consistent and in accordance with the prevailing applicable professional or industry standards; (v) consistent and in accordance with sound practices; and (vi) as expeditiously as is consistent with the foregoing (the standards of this Section 3.1.2.3.1 shall be referred to herein as the "Contractor’s Standard of Care").

§ 3.1.2,3.2 The Contractor shall perform the Work as an independent contractor and shall exercise the Contractor’s Standard of Care in performing all aspects of the Work and its obligations under the Contract Documents. All references in the Contract Documents to the knowledge, inference, reliance, awareness, determination, belief, observation, recognition or discovery of the Contractor or reference to any similar term shall include the knowledge, inference, reliance, awareness, determination, belief, observation, recognition the Contractor would have obtained or achieved upon the exercise of the Contractor’s Standard of Care. The Contractor shall be responsible for exercise of the Contractor’s Standard of Care by all others performing any component of the Work.

§ 3.1.3 The Contractor shall not be relieved of its obligations to perform the Work in accordance with the Contract Documents either by activities or duties of the Architect in the Architect’s administration of the Contract, or by tests, inspections or approvals required or performed by persons or entities other than the Contractor.

§ 3.1.4 The Contractor shall comply, and shall cause Subcontractors of every tier to comply, with all accounting procedures and record retention policies reasonably requested by the Owner.

§ 3.1.5 NONRESIDENT CONTRACTORIf the Contractor is a "nonresident contractor" as defined in Section 12-430(7)(A) of the Connecticut General Statutes, as revised, the Contractor shall provide evidence to the Owner prior to commencement of the Work that Contractor has complied fully with the provisions of Section 12-430(7). The Contractor is hereby notified that, if any subcontractor or supplier performing any part of the Work under the Contract Documents is a nonresident unverified contractor, the Contractor will withhold 5% of all payments to such subcontractor or supplier unless and until such subcontractor or supplier provides to the Contractor a Certificate of Compliance issued by the Connecticut Department of Revenue Services as defined in the Connecticut General Statutes §12-430(7). A nonresident unverified contractor is a contractor without an office in the State of Connecticut that is continuously maintained, occupied and used by the contractor’s regular employees regularly in attendance to carry on the contractor’s business in the contractor’s own name and which contractor has not been verified pursuant to the requirements of the Connecticut Department of Revenue Services. The amount withheld pursuant to CGS §12-430(7) shall be in addition to, and not in lieu of, the retainage held by the Contractor under its subcontract with the subcontractor or supplier pursuant to paragraph (d) above.

Init.

/


15

§ 3.1.6 Notwithstanding anything to the contrary in this Agreement, the Contractor shall attend such meetings and site-visits, and make such submissions, as are necessary to comply with applicable Legal; Requirements.

§ 3.1.7 Nondiscrimination

To the extent applicable, the Contractor shall comply with the following:

§ 3.1.7.1 Pursuant to the requirements of CGS §4a-60:(a)(1) The Contractor agrees and warrants that in the performance of the Contract the Contractor will not discriminate or permit discrimination against any person or group of persons on the grounds of race, color, religious creed, age, marital status, national origin, ancestry, sex, gender identity or expression, intellectual disability, mental disability or physical disability, including, but not limited to, blindness, unless it is shown by such Contractor that such disability prevents performance of the work involved, in any manner prohibited by the laws of the United States or of the state of Connecticut; and the Contractor further agrees to take affirmative action to insure that applicants with job-related qualifications are employed and that employees are treated when employed without regard to their race, color, religious creed, age, marital status, national origin, ancestry, sex, gender identity or expression, intellectual disability, mental disability or physical disability, including, but not limited to, blindness, unless it is shown by such contractor that such disability prevents performance of the work involved;

(2) The Contractor agrees, in all solicitations or advertisements for employees placed by or on behalf of the Contractor, to state that it is an "affirmative action-equal opportunity employer" in accordance with regulations adopted by the Commission on Human Rights and Opportunities;

(3) The Contractor agrees to provide each labor union or representative of workers with which such contractor has a collective bargaining agreement or other contract or understanding and each vendor with which such contractor has a contract or understanding, a notice to be provided by the Commission on Human Rights and Opportunities advising the labor union or workers’ representative of the contractor’s commitments under this section, and to post copies of the notice in conspicuous places available to employees and applicants for employment;

(4) The Contractor agrees to comply with each provision of this section and sections 46a-68e and 46a-68f and with each regulation or relevant order issued by said commission pursuant to sections 46a-56, 46a-68e, 46a-68f and 46a-86; and

(5) The Contractor agrees to provide the Commission on Human Rights and Opportunities with such information requested by the commission, and permit access to pertinent books, records and accounts, concerning the employment practices and procedures of the contractor as relate to the provisions of this section and section 46a-56.

(b) If the Contract is a public works contract, municipal public works contract or contract for a quasi-public agency project, the Contractor agrees and warrants that he or she will make good faith efforts to employ minority business enterprises as subcontractors and suppliers of materials on such public works or quasi-public agency project.

(c) The Contractor shall include the provisions of subsections (a) and (b) of this section in every subcontract or purchase order entered into in order to fulfill any obligation of a contract with the state, and in every subcontract entered into in order to fulfill any obligation of a municipal public works contract or contract for a quasi-public agency project, and such provisions shall be binding on a subcontractor, vendor or manufacturer, unless exempted by regulations or orders of the Commission on Human Rights and Opportunities. The Contractor shall take such action with respect to any such subcontract or purchase order as the commission may direct as a means of enforcing such provisions, including sanctions for noncompliance in accordance with section 46a-56; provided, if such Contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the commission regarding a state contract, the Contractor may request the state of Connecticut to enter into any such litigation or negotiation prior thereto to protect the interests of the state and the state may so enter.

§ 3.1.7.2 Pursuant to the requirements of CGS §4a-60a: (a)(1) The Contactor agrees and warrants that in the performance of the Contract the Contractor will not discriminate or permit discrimination against any person or group of persons on the grounds of sexual orientation, in any manner

Init.

/


16

prohibited by the laws of the United States or of the state of Connecticut, and that employees are treated when employed without regard to their sexual orientation;

(2) The Contractor agrees to provide each labor union or representative of workers with which such Contractor has a collective bargaining agreement or other contract or understanding and each vendor with which the Contractor has a contract or understanding, a notice to be provided by the Commission on Human Rights and Opportunities advising the labor union or workers’ representative of the Contractor’s commitments under Connecticut General Statutes §4a-60a, and to post copies of the notice in conspicuous places available to employees and applicants for employment;

(3) The Contractor agrees to comply with each provision of Connecticut General Statutes §4a-60a and with each regulation or relevant order issued by said Commission on Human Rights and Opportunities pursuant to Connecticut General Statutes §46a-56; and

(4) The Contractor agrees to provide the Commission on Human Rights and Opportunities with such information requested by the commission, and permit access to pertinent books, records and accounts, concerning the employment practices and procedures of the Contractor which relate to the provisions of Connecticut General Statutes §4a-60a and Connecticut General Statutes §46a-56.

(b) The Contractor shall include the provisions of subsection (a) of this section in every subcontract or purchase order entered into in order to fulfill any obligation of a contract with the state, and in every subcontract entered into in order to fulfill any obligation of a municipal public works contractor contract for a quasi-public agency project, and such provisions shall be binding on a subcontractor, vendor or manufacturer unless exempted by regulations or orders of the Commission on Human Rights and Opportunities. The Contractor shall take such action with respect to any such subcontract or purchase order as the commission may direct as a means of enforcing such provisions, including sanctions for noncompliance in accordance with section 46a-56; provided, if such contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the commission regarding a state contract, the Contractor may request the state of Connecticut to enter into any such litigation or negotiation prior thereto to protect the interests of the state and the state may so enter.

§ 3.2 Review of Contract Documents and Field Conditions by Contractor§ 3.2.1 Execution of the Contract by the Contractor is a representation that the Contractor has (i) visited the site, become generally familiar with local conditions under which the Work is to be performed, and correlated personal observations with requirements of the Contract Documents, and (ii) evaluated and satisfied itself and will cause its Subcontractors to satisfy themselves as to the conditions and limitations under which the Work is to be performed, including, without limitation (1) the location, condition, layout and physical conditions of the Project site and surrounding areas, (2) generally prevailing climatic conditions, (3) anticipated labor supply and costs, (4) anticipated availability and costs of materials, tools and equipment, and (5) except as provided in Section 10.3, and subject to the provisions of Section 3.7.4, anticipated soil and subsurface conditions of the Project site. The Owner shall not be required to pay any amount, including any increase in the Contract Sum, or make any adjustment in the Contract Time in connection with any failure by the Contractor or any Subcontractor to comply with the requirements of this Section. The provisions of this Section 3.2.1 shall not be construed to limit the investigative and review responsibilities of the Contractor under any other provisions of the Contract Documents.

§ 3.2.2 Because the Contract Documents are complementary, the Contractor shall, before starting each portion of the Work, carefully study and compare the various Contract Documents relative to that portion of the Work, as well as the information furnished by the Owner pursuant to Section 2.3.4, shall take field measurements of any existing conditions related to that portion of the Work, and shall observe any conditions at the site affecting it. These obligations are for the purpose of facilitating coordination and construction by the Contractor and are not for the purpose of discovering errors, omissions, or inconsistencies in the Contract Documents; however, the Contractor shall promptly report to the Architect any errors, inconsistencies or omissions discovered by or made known to the Contractor as a request for information in such form as the Architect may require. It is recognized that the Contractor’s review is made in the Contractor’s capacity as a contractor and not as a licensed design professional, unless otherwise specifically provided in the Contract Documents.

§ 3.2.3 The Contractor is not required to ascertain that the Contract Documents are in accordance with applicable laws, statutes, ordinances, codes, rules and regulations, or lawful orders of public authorities, but the Contractor shall

Init.

/


17

promptly report to the Architect any nonconformity discovered by or made known to the Contractor as a request for information in such form as the Architect may require.

§ 3.2.4 If the Contractor believes that additional cost or time is involved because of clarifications or instructions the Architect issues in response to the Contractor’s notices or requests for information pursuant to Sections 3.2.2 or 3.2.3, the Contractor shall submit Claims as provided in Article 15. If the Contractor fails to perform the obligations of Sections 3.2.2 or 3.2.3, the Contractor shall pay such costs and damages to the Owner as would have been avoided if the Contractor had performed such obligations and the Contractor shall be responsible for associated delays and impacts. If the Contractor performs those obligations, the Contractor shall not be liable to the Owner or Architect for damages resulting from errors, inconsistencies or omissions in the Contract Documents, for differences between field measurements or conditions and the Contract Documents, or for nonconformities of the Contract Documents to applicable laws, statutes, ordinances, codes, rules and regulations, and lawful orders of public authorities.

§ 3.2.5 If the Contractor fails to fulfill its obligations to report to the Architect or Owner under this Article 3, such failure shall preclude the Contractor from any subsequent Claim arising from, or relating to the factors giving rise to the Contractor’s obligation to make such report.

§ 3.2.6 The Owner assumes no contractual liability or responsibility for the physical condition or safety of the Project site or of any improvements thereon. Except as set forth in Section 10.3, the Contractor shall be solely responsible for providing safe conditions for the performance of the Work.

§ 3.2.7 The Contractor shall give the Architect notice of any additional Drawings, Specification or instructions required to define the Work in greater detail, or to permit the proper progress of the Work. Requests for such information shall be made by the Contractor sufficiently in advance of the time such information is needed by the Contractor so as to permit the Architect a reasonable time for responding to such requests without affecting the progress of the Work.

§ 3.2.8 The execution of the Contract or, in the case where the Contract Sum is subject to a Guaranteed Maximum Price, the Guaranteed Maximum Price Amendment, shall constitute:

§ 3.2.8.1 A representation by the Contractor that the Contractor has carefully reviewed the Contract Documents, and that the Contract Documents are sufficiently detailed and complete to permit the Contractor, (i) to complete the Project for an amount not in excess of the Contract Sum (or, as applicable, the Guaranteed Maximum Price, subject to adjustments in the Guaranteed Maximum Price permitted under the Contract Documents); and (ii) complete the Work within the Contract Time and in accordance with the Contract Documents and all applicable Legal Requirements. The Contractor shall not perform any construction activity it knows constitutes a recognized error, inconsistency or omission. If the Contractor performs any construction activity knowing it involves a recognized error, inconsistency or omission in the Contract Documents without reporting the error, inconsistency or omission to the Architect, the Contractor shall assume appropriate responsibility for such performance and shall bear an appropriate amount of the costs of correction.

§ 3.2.8.2 A certification by the Contractor that it has taken all steps necessary to ascertain the nature and location of the Work, and the general and reasonably observable conditions which can or may affect the Work and/or the cost thereof. Failure by the Contractor to fully acquaint itself with conditions which may affect the Work and/or the cost thereof, including, but not limited to, conditions relating to transportation, handling, storage of materials, availability of labor, water, other known projects in the region, applicable provisions of law, and the character and availability of equipment and facilities needed preliminary to and during the prosecution the Work, shall not relieve the Contractor of its responsibilities under the Contract Documents and shall not constitute a basis for extension of the Contract Time or any increase in the Contract Sum (or the Guaranteed Maximum Price, as applicable). Owner assumes no responsibility for any representations concerning conditions made by any of its officers, or employees or representatives, prior to the execution of the Contract (or the Guaranteed Maximum Price Amendment, as applicable), unless such representations are expressly stated in the Contract Documents.

§ 3.3 Supervision and Construction Procedures§ 3.3.1 The Contractor shall supervise and direct the Work, using the Contractor’s best skill and attention. The Contractor shall be solely responsible for, and have control over, construction means, methods, techniques, sequences, and procedures, and for coordinating all portions of the Work under the Contract. If the Contract Documents give

Init.

/


18

specific instructions concerning construction means, methods, techniques, sequences, or procedures, the Contractor shall evaluate the jobsite safety thereof and shall be solely responsible for the jobsite safety of such means, methods, techniques, sequences, or procedures. If the Contractor determines that such means, methods, techniques, sequences or procedures may not be safe, the Contractor shall give timely notice to the Owner and Architect, and shall propose alternative means, methods, techniques, sequences, or procedures. The Architect shall evaluate the proposed alternative solely for conformance with the design intent for the completed construction. Unless the Architect objects to the Contractor’s proposed alternative, the Contractor shall perform the Work using its alternative means, methods, techniques, sequences, or procedures. In no event shall the Contractor employ construction means, methods, techniques, sequences or procedures that violate (1) requirements of any warranties applicable to the Work; or (2) any Legal Requirements.

§ 3.3.2 The Contractor shall be responsible to the Owner for acts and omissions of the Contractor’s employees, Subcontractors and their agents and employees, and other persons or entities performing portions of the Work for, or on behalf of, the Contractor or any of its Subcontractors.

§ 3.3.3 The Contractor shall be responsible for inspection of portions of Work already performed to determine that such portions are in proper condition to receive subsequent Work.

§ 3.3.4 The Contractor shall furnish sufficient forces, plant and equipment as may be necessary to insure the progress of the Work in accordance with the Construction Schedule. If, in the opinion of the Owner, the Contractor has fallen behind the Construction Schedule, the Contractor shall submit its proposal demonstrating the manner in which the desired rate of progress may be achieved and Contractor shall take such steps as may be necessary to meet the Construction Schedule. Unless the Contractor has fallen behind schedule due to delays which entitle Contractor to an adjustment in the Contract Time in accordance with the terms and conditions of the Contract Documents, the taking of such steps shall be at the sole costs and expense of the Contractor. It shall be the responsibility of the Contractor to maintain its schedule so as not to delay the progress of the Work or the scheduled work of separate contractors.

§ 3.3.5 Contractor’s coordination of Work shall include, without limitation, review of all shop drawings (including, without limitation, architectural, civil, structural, mechanical, and electrical shop drawings) submitted by Subcontractors for various trades or subdivisions of work, as indicated by Contractor’s approval in accordance with Section 3.12.

§ 3.3.6 The Contractor shall be solely responsible for properly laying out the Work, and for all lines, elevations and measurements for all of the Work. Contractor shall verify the figures shown on the Drawings before laying out the Work and will be responsible for any errors or inaccuracies resulting from Contractor’s failure to do so. In the event that the Contractor shall, while laying out the Work, become aware of: (1) any conflicts between (a) the Drawings, the Specifications or any Modification to the Drawings or the Specifications and (b) the actual layout of the Work, or (2) any conflicts or inconsistencies in the Drawings, the Specifications or any Modification to the Drawings or the Specifications themselves, Contractor shall promptly notify the Architect. If the Contractor proceeds without the Architect’s clarification and instruction on the matter, the Contractor shall proceed at Contractor’s own risk.

§ 3.4 Labor and Materials§ 3.4.1 Unless otherwise provided in the Contract Documents, the Contractor shall provide and pay for labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation, and other facilities and services necessary for proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work.

§ 3.4.2 Except in the case of minor changes in the Work approved by the Architect in accordance with Section 3.12.8 or ordered by the Architect in accordance with Section 7.4, the Contractor may make substitutions only with the consent of the Owner, after evaluation by the Architect and in accordance with a Change Order or Construction Change Directive.

§ 3.4.3 All labor shall be performed by workmen skilled in their respective trades, and workmanship shall be of good quality so that first class work in accordance with the standards of construction set forth in the Contract Documents and the Contractor’s Standard of Care will be achieved. The Contractor shall enforce strict discipline and good order among the Contractor’s employees and other persons carrying out the Work. The Contractor shall not permit employment of unfit persons or persons not properly skilled in tasks assigned to them.

Init.

/


19

§ 3.4.3.1 To the extent required under Section 31-53 of the Connecticut General Statutes, the wages paid on a hourly basis to any mechanic, laborer or workman employed upon the work herein contracted to be done and the amount of payment or contribution paid or payable on behalf of each such employee to any employee welfare fund, as defined in subsection (i) of Section 31-53 of the General Statutes of Connecticut shall be at a rate equal to the rate customary or prevailing for the same work in the same trade or occupation in the town in which such public works project is being constructed. Any contractor who is not obligated by agreement to make such payment or contribution on behalf of such employees to any such employee welfare fund shall pay to each employee as part of their wages the amount of the payment of contribution for their classification on each pay day.

§ 3.4.3.2 To the extent required pursuant to Connecticut General Statute Section 31-53b, the Contractor shall furnish proof, and shall cause its Subcontractors to furnish proof, with the weekly certified payroll form for the first week each employee begins work on such project that any person performing the work of a mechanic, laborer or worker pursuant to the classifications of labor under section 31-53 on such public works project, pursuant to such contract, has completed a course of at least ten hours in duration in construction safety and health approved by the federal Occupational Safety and Health Administration or, has completed a new miner training program approved by the Federal Mine Safety and Health Administration in accordance with 30 CFR 48 or, in the case of telecommunications employees, has completed at least ten hours of training in accordance with 29 CFR 1910.268.

§ 3.4.3.3 To the extent consistent with any provision regarding residence requirements contained in a collective bargaining agreement to which the Contractor is a party, in the employment of labor to perform the work specified herein, preference shall be given to citizens of the United States, who are, and continuously for at least three months prior to the date hereof have been, residents of the labor market area, as established by the Labor Commissioner, in which such work is to be done, and if no such qualified person is available, then to citizens who have continuously resided in the county in which the work is to be performed for at least three months prior to the date hereof, and then to citizens of the state who have continuously resided in the state at least three months prior to the date hereof.

§ 3.4.4 If the Contractor desires to substitute a product or method in lieu of what has been specified or shown in the Contract Documents, the Contractor may propose to do so in a written request delivered to the Architect and the Owner setting forth the following:

.1 Full explanation of the proposed substitution and submittal of all supporting data including technical information, catalog cuts, warranties, test results, installation instructions, operating procedures, and other like information necessary for a complete evaluation of the substitution and relevant materials prepared as part of pre-construction services.

.2 Reasons why the substitution is advantageous and necessary, including the benefits to the Owner and the Work in the event the substitution is acceptable.

.3 The adjustment, if any, in the Contract Sum, in the event the substitution is acceptable.

.4 The adjustment, if any, in the Contract Time and any milestone dates in the event the substitution is acceptable.

.5 The Contractor shall submit a written request for any substitution, together with complete substantiating data and information, to the Architect and the Owner not later than thirty (30) days prior to the time that such substitute product or method would be incorporated into the Work. No substitution shall be made by the Contractor, or considered or approved by the Architect or the Owner, without the Contractor’s submittal of a written request with respect to such substitution as provided above. The Contractor may make a substitution only: (1) upon the written approval of the Architect and the Owner of such written request therefor after evaluation by them of such request and all accompanying data and information; and (2) in accordance with a Change Order.

.6 Any written request for a substitution by the Contractor shall be a representation by the Contractor to the Owner that: (1) the Contractor has investigated the product or method proposed to be substituted and found it to be equivalent to or better than the product or method specified in the Contract Documents, (2) except to the extent otherwise expressly stated in such request, the Contractor is waiving any Claim for additional costs related to such substitution; (3) the Contractor will provide the same warranty for the substitution that the Contractor would for that specified; (4) the substitution will not entail changes in detail and construction of related Work; and (5) the Contractor shall coordinate the installation of the accepted substitution, making such changes as may be required for the Work to be complete in all respects.

Init.

/


20

§ 3.4.5 Notwithstanding the fact that the Contract Documents may specify a particular brand or make of material or equipment "or equal", if the Contractor elects to utilize "equal" materials or equipment rather than the specified materials or equipment, the "equal" materials or equipment will be subject to the prior written approval of the Owner.

§ 3.5 Warranty§ 3.5.1 The Contractor warrants to the Owner and Architect that materials and equipment furnished under the Contract will be of good quality and new unless the Contract Documents require or permit otherwise. The Contractor further warrants that the Work will conform to the requirements of the Contract Documents and will be free from defects, except for those inherent in the quality of the Work the Contract Documents require or permit. Work, materials, or equipment not conforming to these requirements may be considered defective. The Contractor’s warranty excludes remedy for damage or defect caused by abuse, alterations to the Work not executed by the Contractor, improper or insufficient maintenance, improper operation, or normal wear and tear and normal usage. If required by the Architect, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment.

§ 3.5.2 The Contractor shall procure and assign to the Owner at the time of Substantial Completion of the Work any and all Subcontractor, manufacturer or supplier warranties relating to any materials and labor used in the Work. Such warranties shall supplement the warranties provided by the Contractor in Section 3.5.1. All material, equipment, or other special warranties required by the Contract Documents shall be issued in the name of the Owner, or shall be transferable to the Owner, and shall commence in accordance with Section 9.8.4.

§ 3.5.3 Substitutions not properly approved and authorized and work, materials or equipment which fail to perform under the proper use and normal wear for intended purposes shall be considered defective. If required by the Architect or the Owner, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment to be incorporated in the Work.

§3.5.4 The Contractor hereby represents and warrants (in addition to other representations and warranties contained above and otherwise in the Contract Documents), as an inducement to the Owner to enter into the Contract, which representations and warranties shall survive the final completion of the Work:

.1 that it is financially solvent, able to pay its debts as they mature and possessed of sufficient working capital to complete the Work and perform its obligations under the Contract Documents;

.2 that it, through its Subcontractors or otherwise, is able to furnish the tools, materials, supplies, equipment, machinery, labor and services required to complete the Work and perform its obligations hereunder in a timely manner and has sufficient experience and competence to do so; and

.3 the Contractor is authorized to do business in the State in which the Project is located and is properly licensed by all necessary governmental authorities having jurisdiction over the Contractor and the Project.

§ 3.5.5 The Contractor further agrees that each Subcontract shall contain a warranty of the portion of the Work performed thereunder in the same form as the above stated warranty of Contractor. Included in said warranty shall be the statement that it shall be enforceable directly by the Owner, if the Owner so elects. The warranty of any Subcontractor shall not relieve the Contractor of its warranty as set forth above and the Owner may look to the Contractor, directly, and in the first instance to correct any defects in the Work.

§ 3.5.6 The representations and warranties under this Section 3.5 shall be in addition to, and not a substitute for, any other rights of the Owner under the Contract Documents or existing in law or equity.

§3.5.7 The representations and warranties set forth in this Section 3.5 shall survive final payment and termination of the Contract.

§ 3.6 TaxesUnless the Owner is tax exempt as regards sales and use taxes (in which case the Contract Sum shall not include any such taxes), the Contractor shall pay sales, consumer, use and similar taxes for the Work provided by the Contractor that are legally enacted when bids are received or negotiations concluded, whether or not yet effective or merely scheduled to go into effect.

Init.

/


21

§ 3.7 Permits, Fees, Notices and Compliance with Laws§ 3.7.1 Unless otherwise provided in the Contract Documents, the Contractor shall secure and pay for the building permit as well as for other permits, fees, licenses, certifications and inspections by government agencies necessary for proper execution and completion of the Work that are customarily secured after execution of the Contract and required by applicable Legal Requirements as of the effective date of this Contract. The Contractor shall provide the Owner and Architect with reproductions of all permits, licenses, permissions, certifications and receipts for payments and, upon submission of the final Application for Payment, shall deliver all originals of such documents to the Owner with copies to the Architect.

§ 3.7.2 The Contractor shall comply with, be responsible for performance of the Work in accordance with, and give notices required by all applicable local, state and federal laws, statutes, ordinances, codes, building codes, rules, regulations, permits, and orders enacted, promulgated, issued or ordered by any governmental body or public or quasi-public authority having jurisdiction over the Work, the Contractor and/ or the site of the Project (collectively, the "Legal Requirements"). Legal Requirements shall include, without limitation, those relating to equal opportunity, labor, wages and employment.

§ 3.7.3 If the Contractor performs Work knowing it to be contrary to applicable Legal Requirements, the Contractor shall assume appropriate responsibility for such Work and shall bear the costs attributable to correction.

§ 3.7.4 Concealed or Unknown ConditionsIf the Contractor encounters conditions at the site that are (1) subsurface or otherwise concealed physical conditions that differ materially from those indicated in the Contract Documents or (2) unknown physical conditions of an unusual nature that differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, the Contractor shall promptly provide notice to the Owner and the Architect before conditions are disturbed and in no event later than 14 days after first observance of the conditions. The Architect will promptly investigate such conditions and, if the Architect determines that they differ materially and cause an increase or decrease in the Contractor’s cost of, or time required for, performance of any part of the Work, will recommend that an equitable adjustment be made in the Contract Sum or Contract Time, or both. If the Architect determines that the conditions at the site are not materially different from those indicated in the Contract Documents and that no change in the terms of the Contract is justified, the Architect shall promptly notify the Owner and Contractor, stating the reasons. If either party disputes the Architect’s determination or recommendation, that party may submit a Claim as provided in Article 15.

§ 3.7.5 If, in the course of the Work, the Contractor encounters human remains or recognizes the existence of burial markers, archaeological sites or wetlands or other conditions that would warrant a suspicion that such matters are being encountered during the performance of the Work although they are not indicated in the Contract Documents, the Contractor shall immediately suspend any operations that would affect them and shall notify the Owner and Architect. Upon receipt of such notice, the Owner shall promptly take any action necessary to obtain governmental authorization required to resume the operations. The Contractor shall continue to suspend such operations until otherwise instructed by the Owner but shall continue with all other operations that do not affect those remains or features. Requests for adjustments in the Contract Time arising from the existence of such remains or features may be made as provided in Article 15.

§ 3.8 Allowances§ 3.8.1 The Contractor shall include in the Contract Sum all allowances stated in the Contract Documents. Items covered by allowances shall be supplied for such amounts and by such persons or entities as the Owner may direct, but the Contractor shall not be required to employ persons or entities to whom the Contractor has reasonable objection.

§ 3.8.2 Unless otherwise provided in the Contract Documents,.1 allowances shall cover the cost to the Contractor of materials and equipment delivered at the site and all

required taxes, less applicable trade discounts;.2 Contractor’s costs for unloading and handling at the site, labor, installation costs, overhead, profit, and

other expenses contemplated for stated allowance amounts shall be included in the Contract Sum but not in the allowances; and

.3 whenever costs are more than or less than allowances, the Contract Sum shall be adjusted accordingly by Change Order. The amount of the Change Order shall reflect (1) the difference between actual costs and the allowances under Section 3.8.2.1 and (2) changes in Contractor’s costs under Section 3.8.2.2.

Init.

/


22

§ 3.8.3 Materials and equipment under an allowance shall be selected by the Owner with reasonable promptness.

§ 3.9 Superintendent§ 3.9.1 The Contractor shall employ a competent superintendent and necessary assistants who shall be in attendance at the Project site at all times during performance of the Work. The superintendent shall represent the Contractor, and communications given to the superintendent shall be as binding as if given to the Contractor. Important communications shall be confirmed in writing. Other communications shall be similarly confirmed upon written request in each case.

§ 3.9.2 The Contractor, as soon as practicable after award of the Contract, shall notify the Owner and Architect of the name and qualifications of a proposed superintendent. Within 14 days of receipt of the information, the Architect may notify the Contractor, stating whether the Owner or the Architect (1) has reasonable objection to the proposed superintendent or (2) requires additional time for review. Failure of the Architect to provide notice within the 14-day period shall constitute notice of no reasonable objection.

§ 3.9.3 The Contractor shall not employ a proposed superintendent to whom the Owner or Architect has made reasonable and timely objection. The Contractor shall not change the superintendent without the Owner’s consent, which shall not unreasonably be withheld or delayed. The list of all supervisory personnel, including the project manager and superintendent that the Contractor intends to use on the Project and an organizational chart reflecting the chain of command among such personnel, shall be submitted to the Owner for approval prior to the commencement of the Work. The Contractor shall not engage supervisory personnel other than as approved by Owner in writing and shall not change such personnel or form of organization without the prior written approval of the Owner.

§ 3.10 Contractor’s Construction and Submittal Schedules§ 3.10.1 The Contractor shall, pursuant to Section 2.2.13.1 of the Agreement, prepare and submit for the Owner’s and Architect’s approval, a proposed construction schedule for the Work. The proposed construction schedule (i) shall comply with all of the applicable requirements of, and shall not exceed time limits current under, the Contract Documents, (ii) shall be in such form and detail and include such content as required by the Owner, (iii) shall be related to the entire Project to the extent required by the Contract Documents, (iv) shall provide for expeditious and practicable execution of the Work for completion within the time limits current under the Contract Documents; (v) shall include the date of commencement of the Work, interim schedule milestone dates, and the date required for Substantial Completion; and (vi) shall include an apportionment of the Work by construction activity and the time required for completion of each portion of the Work . If the Owner requires a precedence-style critical path method (CPM) schedule, the proposed construction schedule shall also: (a) provide a graphic representation of all activities and events that will occur during performance of the Work: (b) identify each phase of construction and occupancy (if applicable): and (c) set forth dates that are critical in ensuring the timely and orderly completion of the Work (hereinafter referred to as "Milestone Dates"). If the proposed construction schedule is not accepted by the Owner, the Contractor shall promptly modify the proposed construction schedule in accordance with the recommendations of the Owner and the Architect and resubmit the revised schedules for acceptance. The schedule shall be revised at appropriate intervals as required by the conditions of the Work and Project.

§ 3.10.2 The Contractor, promptly after being awarded the Contract and thereafter as necessary to maintain a current submittal schedule, shall submit a submittal schedule for the Architect’s approval. The Architect’s approval shall not be unreasonably delayed or withheld. The submittal schedule shall (1) be coordinated with the Contractor’s construction schedule, and (2) allow the Architect reasonable time to review submittals. If the Contractor fails to submit a submittal schedule, or fails to provide submittals in accordance with the approved submittal schedule, the Contractor shall not be entitled to any increase in Contract Sum or extension of Contract Time based on the time required for review of submittals.

§ 3.10.3 The Contractor shall perform the Work in general accordance with the most recent construction schedule submitted to and approved by the Owner and Architect (as so approved, the "Construction Schedule").

3.10.4 The Contractor shall monitor the progress of the Work for conformance with the requirements of the Construction Schedule and shall promptly advise the Owner of any delays or potential delays. The Construction Schedule shall be updated to reflect actual conditions ("Progress Reports") (which updated schedule shall be subject to the approval of the Owner and the Architect) at appropriate intervals as determined by the Contractor and as required

Init.

/


23

by the conditions of the Work and the Project (but in no event less frequently than monthly) or as otherwise requested by the Owner. In the event any Progress Report indicates any delays, the Contractor shall propose an affirmative plan to correct the delay, including overtime and/or additional labor, if necessary. In no event shall any Progress Report constitute an adjustment in the Contract Time, any Milestone Date or the Contract Sum (or Guaranteed Maximum Price as applicable) unless any such adjustment is agreed to by the Owner and authorized pursuant to a Change Order.

§3.10.5 In the event the Owner determines that the performance of the Work as of a Milestone Date has not progressed or reached the level of completion required by the Contract Documents, the Owner shall have the right, but not the obligation, to order the Contractor to take corrective measures necessary to expedite the progress of construction, including, without limitation, (1) working additional shifts or overtime, (2) supplying additional manpower, equipment, and facilities, and (3) other similar measures (hereinafter referred to collectively as "Extraordinary Measures"). Such Extraordinary Measures shall continue until the progress of the Work complies with the stage of completion required by the Contract Documents. The Owner’s right to require Extraordinary Measures is solely for the purposes of ensuring the Contractor’s compliance with the accepted construction schedule as adjusted for time extensions granted pursuant to Section 8.3. Except as provided in Section 8.3, the Contractor shall not be entitled to an adjustment in the Contract Sum (or the Guaranteed Maximum Price, as applicable) in connection with Extraordinary Measures required by the Owner pursuant to this Section 3.10.5. The Owner may exercise the rights furnished the Owner under or pursuant to this Section 3.10.5 as frequently as the Owner deems necessary to ensure that that Contractor’s performance of the Work will comply with any Milestone Date or the Substantial Completion Date, as the same may be extended by Change Order.

§3.10.6 The Owner shall have the right to direct a postponement or rescheduling of any date or time for the performance of any part of the Work that may interfere with the Owner’s operations. Any postponement, rescheduling or performance of the Work under this Section 3.10.6 may be grounds for an extension of the Contract Time, if permitted under Section 8.3, and an equitable adjustment in the Contract Sum (or Guaranteed Maximum Price, as applicable) if: (1) the performance of the Work was properly scheduled by the Contractor in compliance with the requirements of the Contract Documents and (2) such rescheduling or postponement is requested by or required for the convenience of the Owner. Without limiting the foregoing, the Contractor will not be entitled to an extension of the Contract Time or an adjustment of the Contract Sum to the extent the interfering Work so interferes as a result of the negligent act or omission of the Contractor or its subcontractors of any tier or the failure of any of the same to perform the Work in a manner consistent with the Contract Documents, including Section 3.10.3 hereof.

§ 3.11 Documents and Samples at the SiteThe Contractor shall make available, at the Project site, the Contract Documents, including a record set of Change Orders, Construction Change Directives, and other Modifications, in good order and marked currently to indicate field changes and selections made during construction, and the approved Shop Drawings, Product Data, Samples, and similar required submittals. The record set of documents shall reflect all deviations from the Drawings and Specifications and shall be updated in detail from time to time to reflect the actual progress of the Work. The Owner and the Architect shall have free and complete access to such documents during the construction of the Work. Upon Substantial Completion of the Work, the Contractor shall furnish to the Owner through the Architect one set of "as built" plans in such form as the Owner shall require. Such plans shall completely record all Work in place and serve as a record of the Work as constructed.

§ 3.12 Shop Drawings, Product Data and Samples§ 3.12.1 Shop Drawings are drawings, diagrams, schedules, and other data specially prepared for the Work by the Contractor or a Subcontractor, Sub-subcontractor, manufacturer, supplier, or distributor to illustrate some portion of the Work.

§ 3.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams, and other information furnished by the Contractor to illustrate materials or equipment for some portion of the Work.

§ 3.12.3 Samples are physical examples that illustrate materials, equipment, or workmanship, and establish standards by which the Work will be judged.

§ 3.12.4 Shop Drawings, Product Data, Samples, and similar submittals are not Contract Documents. Their purpose is to demonstrate how the Contractor proposes to conform to the information given and the design concept expressed in the Contract Documents for those portions of the Work for which the Contract Documents require submittals. Review

Init.

/


24

by the Architect is subject to the limitations of Section 4.2.7. Informational submittals upon which the Architect is not expected to take responsive action may be so identified in the Contract Documents. Submittals that are not required by the Contract Documents may be returned by the Architect without action.

§ 3.12.5 The Contractor shall review for compliance with the Contract Documents, approve, and submit to the Architect, Shop Drawings, Product Data, Samples, and similar submittals required by the Contract Documents, in accordance with the submittal schedule approved by the Architect or, in the absence of an approved submittal schedule, with reasonable promptness and in such sequence as to cause no delay in the Work or in the activities of the Owner or of Separate Contractors.

§ 3.12.6 By submitting Shop Drawings, Product Data, Samples, and similar submittals, the Contractor represents to the Owner and Architect that the Contractor has (1) reviewed and approved them, (2) determined and verified materials, field measurements and field construction criteria related thereto, or will do so, and (3) checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. Submittals shall be marked as reviewed by the Contractor for compliance with the Contract Documents and approved by the Contractor. Those that are not so marked may be returned by the Architect without action. The Contractor shall meet with the Architect in a timely fashion to discuss the schedule of submittals required under Section 3.10.2 and shall thereafter timely prepare and submit for approval by the Architect a schedule of submittals for the Work.

§ 3.12.7 The Contractor shall perform no portion of the Work for which the Contract Documents require submittal and review of Shop Drawings, Product Data, Samples, or similar submittals, until the respective submittal has been approved by the Architect.

§ 3.12.8 The Work shall be in accordance with approved submittals except that the Contractor shall not be relieved of responsibility for deviations from the requirements of the Contract Documents by the Architect’s approval of Shop Drawings, Product Data, Samples, or similar submittals, unless the Contractor has specifically notified the Architect of such deviation at the time of submittal and (1) the Architect has given written approval to the specific deviation as a minor change in the Work, or (2) a Change Order or Construction Change Directive has been issued authorizing the deviation. The Contractor shall not be relieved of responsibility for errors or omissions in Shop Drawings, Product Data, Samples, or similar submittals, by the Architect’s approval thereof.

§ 3.12.9 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data, Samples, or similar submittals, to revisions other than those requested by the Architect on previous submittals. In the absence of such notice, the Architect’s approval of a resubmission shall not apply to such revisions.

§ 3.12.10 The Contractor shall not be required to provide professional services that constitute the practice of architecture or engineering unless such services are specifically required by the Contract Documents for a portion of the Work or unless the Contractor needs to provide such services in order to carry out the Contractor’s responsibilities for construction means, methods, techniques, sequences, and procedures. The Contractor shall not be required to provide professional services in violation of applicable law.

§ 3.12.10.1 If professional design services or certifications by a design professional related to systems, materials, or equipment are specifically required of the Contractor by the Contract Documents, the Owner and the Architect will specify all performance and design criteria that such services must satisfy. The Contractor shall be entitled to rely upon the adequacy and accuracy of the performance and design criteria provided in the Contract Documents. The Contractor shall cause such services or certifications to be provided by an appropriately licensed design professional, who has been approved by the Owner and that carries such professional liability insurance coverage as required by the Owner and whose signature and seal shall appear on all drawings, calculations, specifications, certifications, Shop Drawings, and other submittals prepared by such professional. Shop Drawings, and other submittals related to the Work, designed or certified by such professional, if prepared by others, shall bear such professional’s written approval when submitted to the Architect. The Owner and the Architect shall be entitled to rely upon the adequacy and accuracy of the services, certifications, and approvals performed or provided by such design professionals, provided the Owner and Architect have specified to the Contractor the performance and design criteria that such services must satisfy. Pursuant to this Section 3.12.10, the Architect will review and approve or take other appropriate action on submittals only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents.

Init.

/


25

§ 3.12.10.2 If the Contract Documents require the Contractor’s design professional to certify that the Work has been performed in accordance with the design criteria, the Contractor shall furnish such certifications to the Architect at the time and in the form specified by the Architect.

§ 3.13 Use of Site§ 3.13.1 The Contractor shall confine operations at the site to areas permitted by applicable Legal Requirements and the Contract Documents and shall not unreasonably encumber the site with materials or equipment.

§3.13.2 The Contractor shall locate, protect and save from damage or disruption utilities and utility services lines of all kinds, either above or below grade found in the areas affected by the Work. The Contractor shall be responsible for all damage caused to such utilities by the operation of equipment or machinery, the delivery of materials, or as the direct or indirect result of any of the Work, and shall repair all such damage at its expense and as part of the Work included in the Contract Documents.

§ 3.14 Cutting and Patching§ 3.14.1 The Contractor shall be responsible for cutting, fitting, or patching required to complete the Work or to make its parts fit together properly. All areas requiring cutting, fitting, or patching shall be restored to the condition existing prior to the cutting, fitting, or patching, unless otherwise required by the Contract Documents.

§ 3.14.2 The Contractor shall not damage or endanger a portion of the Work or fully or partially completed construction of the Owner or Separate Contractors by cutting, patching, or otherwise altering such construction, or by excavation. The Contractor shall not cut or otherwise alter construction by the Owner or a Separate Contractor except with written consent of the Owner and of the Separate Contractor. Consent shall not be unreasonably withheld. The Contractor shall not unreasonably withhold, from the Owner or a Separate Contractor, its consent to cutting or otherwise altering the Work.

§ 3.14.3 Unless authorized in writing by the Owner and the Architect, structural elements of the Work shall not be cut, patched, or otherwise altered or repaired. Existing work that is cut, damaged, disturbed or otherwise interfered with by the Contractor, a Subcontractor, or anyone for whom any of them is responsible shall be fully, properly and carefully repaired by the responsible Contractor or Subcontractor. All such repairs shall be completed to the satisfaction of the Architect, and shall match similar existing adjoining work.

§ 3.15 Cleaning Up§ 3.15.1 The Contractor shall keep the premises and surrounding area free from accumulation of waste materials and rubbish caused by operations under the Contract. At completion of the Work, the Contractor shall remove waste materials, rubbish, the Contractor’s tools, construction equipment, machinery, and surplus materials from and about the Project.

§ 3.15.2 If the Contractor fails to clean up as provided in the Contract Documents, the Owner may do so and the Owner shall be entitled to reimbursement from the Contractor.

§ 3.16 Access to WorkThe Contractor shall provide the Owner and Architect with access to the Work in preparation and progress wherever located.

§ 3.17 Royalties, Patents and CopyrightsThe Contractor shall pay all royalties and license fees. The Contractor shall defend suits or claims for infringement of copyrights and patent rights, or failure to pay such royalty and license fees, and shall hold the Owner and Architect harmless from loss on account thereof, but shall not be responsible for defense or loss when a particular design, process, or product of a particular manufacturer or manufacturers is required by the Contract Documents, or where the copyright violations are contained in Drawings, Specifications, or other documents prepared by the Owner or Architect. However, if an infringement of a copyright or patent is discovered by, or made known to, the Contractor, the Contractor shall be responsible for the loss unless the information is promptly furnished to the Architect.

§ 3.18 Indemnification§ 3.18.1 To the fullest extent permitted by law, the Contractor shall indemnify, defend and hold harmless the Owner, the Owner’s designated representative, the Town of Weston, the Architect, the Architect’s consultants, and all of their

Init.

/


26

respective directors, members of governing boards, officials, officers, partners, employees, shareholders, members, managers, beneficiaries, agents and representatives (each an "Indemnitee") from and against claims, damages, losses, and expenses, including but not limited to attorneys’ fees, arising out of or resulting from performance of the Work, but only to the extent caused by the negligent acts or omissions, violations of Legal Requirements, or breach of contract by the Contractor, a Subcontractor, anyone directly or indirectly employed by them, or anyone for whose acts they may be liable. The obligations of the Contractor under the foregoing indemnity shall include, without limitation, to the fullest extent permitted by law, any and all claims (including attorneys’ fees resulting therefrom) directly or indirectly arising or alleged to arise (1) out of the performance of or the failure to perform the Work, or the condition of the Work, the job site, adjoining land or driveways, or streets or alleys used in connection with the performance of the Work, and from any and all claims by workmen, suppliers or Subcontractors who are involved in the performance of the Work, and (2) under any scaffolding, structural work or safe place law or any law with respect to the protection of adjacent landowners. These indemnification obligations are not intended to include liability for damage arising out of bodily injury to person or damage to property to the extent caused by or resulting from the negligence of the indemnitee, such indemnitee’s agents or employees, nor shall such obligations be construed to negate, abridge, or reduce other rights or obligations of indemnity that would otherwise exist as to a party or person described in this Section 3.18.

§ 3.18.2 In claims against any person or entity indemnified under this Section 3.18 by an employee of the Contractor, a Subcontractor, anyone directly or indirectly employed by them, or anyone for whose acts they may be liable, the indemnification obligation under Section 3.18.1 shall not be limited by a limitation on amount or type of damages, compensation, or benefits payable by or for the Contractor or a Subcontractor under workers’ compensation acts, disability benefit acts, or other employee benefit acts.

§ 3.18.3 To the fullest extent permitted by law, the Contractor shall further indemnify, defend and hold harmless each Indemnitee from and against (1) all claims for payment by any Subcontractor or supplier of any tier, (2) any and all actions, lawsuits, claims and proceedings brought against the Indemnitee as a result of liens filed against the Work, the Project site or any improvements thereon (referred to collectively as "Liens") by the Contractor, any Subcontractor, Sub-subcontractor or anyone claiming by, through or under them, and (3) all loss, liability, damage or expense, including reasonable attorney’s fees and litigation expenses, arising out of any Lien, claim or other claim for payment by any Subcontractor or supplier of any tier. The Contractor shall pay any judgment or Lien resulting from any such actions, lawsuits or proceedings. Upon receipt of notice of a Lien claim or other claim for payment, the Owner shall notify the Contractor. If approved by the applicable court, when required, the Contractor may substitute a surety bond for the property against which the Lien or other claim for payment has been asserted. The Contractor’s obligations under this Section 3.18.3 are conditioned upon Owner having fulfilled its payment obligations to the Contractor with respect to the Work that is the subject of the Lien or claim and for which indemnification is sought.

§ 3.18.4 The Contractor shall bear any and all reasonable expenses incurred by any Indemnitee because of any claim or other matter indemnified against under this Section 3.18, including without limitation, attorneys’ and consultants’ fees and expenses, court costs, and costs related to the defense of, or preparing for the defense against, any such claim. If any such claim has not been settled or discharged or bonded at the time of final completion of the Work, and if such claim is not covered in full by a policy of insurance then in effect from a reputable and financially sound insurance company which has not declined or reserved the right to decline coverage of such claim, the Owner may withhold an amount equal to two hundred percent (200%) of the outstanding claim until any such claim is paid or settled or the Contractor provides a bond, acceptable to the Owner, to satisfy such claim.

§3.19 MEETINGS§3.19.1 A qualified representative of the Contractor shall attend periodic progress meetings held at such time and as such place as the Architect or the Owner shall designate.

§3.19.2 The Contractor shall schedule and conduct progress meetings at the Project site on a bi-weekly basis (or interval appropriate for the level of jobsite activity). Attendance is required of each Subcontractor, supplier or other entity whose portion of the Work is currently the subject of concern or discussion or planning of future construction activities. Contractor shall provide the Owner and Architect with forty-eight (48) hours prior notice of each such progress meetings and be permitted to attend and participate in the meetings.

Init.

/


27

ARTICLE 4 ARCHITECT§ 4.1 General§ 4.1.1 The Architect is the person or entity retained by the Owner pursuant to Section 2.3.2 and identified as such in the Agreement.

§ 4.1.2 Duties, responsibilities, and limitations of authority of the Architect as set forth in the Contract Documents shall not be restricted, modified, or extended without written consent of the Owner, Contractor, and Architect. Consent shall not be unreasonably withheld.

§ 4.2 Administration of the Contract§ 4.2.1 The Architect will provide administration of the Contract as described in the Contract Documents and will be an Owner’s representative during construction until the date the Architect issues the final Certificate for Payment. The Architect will have authority to act on behalf of the Owner only to the extent provided in the Contract Documents.

§ 4.2.2 The Architect will visit the site at intervals appropriate to the stage of construction, or as otherwise agreed with the Owner, to become generally familiar with the progress and quality of the portion of the Work completed, and to determine in general if the Work observed is being performed in a manner indicating that such portion of the Work is, and when the Work is fully completed the entirety of the Work will be, in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. The Architect will not have control over, charge of, or responsibility for the construction means, methods, techniques, sequences or procedures, or for the safety precautions and programs in connection with the Work, since these are solely the Contractor’s rights and responsibilities under the Contract Documents.

§ 4.2.3 On the basis of the site visits, the Architect will keep the Owner reasonably informed about the progress and quality of the portion of the Work completed, and promptly report to the Owner (1) known deviations from the Contract Documents, (2) known deviations from the most recent construction schedule submitted by the Contractor, and (3) defects and deficiencies observed in the Work. The Architect will not be responsible for the Contractor’s failure to perform the Work in accordance with the requirements of the Contract Documents. The Architect will not have control over or charge of, and will not be responsible for acts or omissions of, the Contractor, Subcontractors, or their agents or employees, or any other persons or entities performing portions of the Work.

§ 4.2.4 Communications The Owner and Contractor shall include the Architect in all communications that relate to or affect the Architect’s services or professional responsibilities. The Owner shall promptly notify the Architect of the substance of any direct communications between the Owner and the Contractor otherwise relating to the Project. Communications by and with the Architect’s consultants shall be through the Architect. Communications by and with Subcontractors and suppliers shall be through the Contractor. Communications by and with Separate Contractors shall be through the Owner. The Contract Documents may specify other communication protocols.

§ 4.2.5 Based on the Architect’s evaluations of the Contractor’s Applications for Payment, the Architect will review and certify the amounts due the Contractor and will issue Certificates for Payment in such amounts.

§ 4.2.6 The Architect has authority to reject Work that does not conform to the Contract Documents. Whenever the Architect considers it necessary or advisable, the Architect will have authority to require inspection or testing of the Work in accordance with Sections 13.4.2 and 13.4.3, whether or not the Work is fabricated, installed or completed. However, neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect to the Contractor, Subcontractors, suppliers, their agents or employees, or other persons or entities performing portions of the Work.

§ 4.2.7 The Architect will review and approve, or take other appropriate action upon, the Contractor’s submittals such as Shop Drawings, Product Data, and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect’s action will be taken in accordance with the submittal schedule approved by the Architect or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time in the Architect’s professional judgment to permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Contractor as required by the

Init.

/


28

Contract Documents. The Architect’s review of the Contractor’s submittals shall not relieve the Contractor of the obligations under Sections 3.3, 3.5, and 3.12. The Architect’s review shall not constitute approval of safety precautions or of any construction means, methods, techniques, sequences, or procedures. The Architect’s approval of a specific item shall not indicate approval of an assembly of which the item is a component.

§ 4.2.8 The Architect will prepare Change Orders and Construction Change Directives, and may order minor changes in the Work as provided in Section 7.4. The Architect will investigate and make determinations and recommendations regarding concealed and unknown conditions as provided in Section 3.7.4.

§ 4.2.9 The Architect will conduct inspections to determine the date or dates of Substantial Completion and the date of final completion; issue Certificates of Substantial Completion pursuant to Section 9.8; receive and forward to the Owner, for the Owner’s review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor pursuant to Section 9.10; and issue a final Certificate for Payment pursuant to Section 9.10.

§ 4.2.10 If the Owner and Architect agree, the Architect will provide one or more Project representatives to assist in carrying out the Architect’s responsibilities at the site. The Owner shall notify the Contractor of any change in the duties, responsibilities and limitations of authority of the Project representatives.

§ 4.2.11 The Architect will interpret and decide matters concerning performance under, and requirements of, the Contract Documents on written request of either the Owner or Contractor. The Architect’s response to such requests will be made in writing within any time limits agreed upon or otherwise with reasonable promptness.

§ 4.2.12 Interpretations and decisions of the Architect will be consistent with the intent of, and reasonably inferable from, the Contract Documents and will be in writing or in the form of drawings. When making such interpretations and decisions, the Architect will endeavor to secure faithful performance by both Owner and Contractor, will not show partiality to either, and will not be liable for results of interpretations or decisions rendered in good faith.

§ 4.2.13 The Architect’s decisions on matters relating to aesthetic effect will be final if consistent with the intent expressed in the Contract Documents.

§ 4.2.14 The Architect will review and respond to requests for information about the Contract Documents. The Architect’s response to such requests will be made in writing within any time limits agreed upon or otherwise with reasonable promptness. If appropriate, the Architect will prepare and issue supplemental Drawings and Specifications in response to the requests for information.

ARTICLE 5 SUBCONTRACTORS§ 5.1 Definitions§ 5.1.1 A Subcontractor is a person or entity who has a direct contract with the Contractor to perform a portion of the Work at the site. The term "Subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Subcontractor or an authorized representative of the Subcontractor. The term "Subcontractor" does not include a Separate Contractor or the subcontractors of a Separate Contractor.

§ 5.1.2 A Sub-subcontractor is a person or entity who has a direct or indirect contract with a Subcontractor to perform a portion of the Work at the site. The term "Sub-subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Sub-subcontractor or an authorized representative of the Sub-subcontractor.

§ 5.2 Award of Subcontracts and Other Contracts for Portions of the Work§ 5.2.1 Unless otherwise stated in the Contract Documents, the Contractor, as soon as practicable after award of the Contract (or, as applicable, at the time of Contractor’s submission of the Guaranteed Maximum Price proposal), shall notify the Owner and Architect of the persons or entities proposed for each principal portion of the Work, including those who are to furnish materials or equipment fabricated to a special design, plus such other information as required under the Agreement.. The Owner shall have the right to reject a proposed subcontractor or supplier as provided in the Agreement.

§ 5.2.1.1 If requested by the Owner, the Contractor shall provide to the Owner copies of all subcontracts and supply agreements entered into by the Contractor for the Work.

Init.

/


29

§ 5.2.2 The Contractor shall not contract with a proposed person or entity to whom the Owner or Architect has made reasonable and timely objection. The Contractor shall not be required to contract with anyone to whom the Contractor has made reasonable objection.

§ 5.2.3 If the Owner or Architect has reasonable objection to a person or entity proposed by the Contractor, the Contractor shall propose another to whom the Owner or Architect has no reasonable objection.

§ 5.2.4 The Contractor shall not substitute a Subcontractor, person, or entity for one previously selected if the Owner or Architect makes reasonable objection to such substitution. If the Contractor wishes to substitute a different person or entity for a person or entity previously selected and approved as a Subcontractor pursuant to this Section 5.2, the procedure set forth in Section 5.2.1 and the Agreement shall be followed.

§ 5.3 Subcontractual RelationsAny part of the Work performed by a Subcontractor shall be pursuant to a written Subcontract between the Contractor and Subcontractor, which form of Subcontract shall be reasonably satisfactory to the Owner in all respects. Copies of all Subcontractor bids or proposals shall, upon request of Owner, be submitted to the Owner and Architect. All Subcontracts shall provide that each Subcontractor, to the extent of the Work to be performed by the Subcontractor, be bound to the Contractor by the terms of the Contract Documents, and to assume toward the Contractor all the obligations and responsibilities, including the responsibility for safety of the Subcontractor’s Work that the Contractor, by these Contract Documents, assumes toward the Owner and Architect. Each subcontract agreement shall preserve and protect the rights of the Owner and Architect under the Contract Documents with respect to the Work to be performed by the Subcontractor so that subcontracting thereof will not prejudice such rights, and shall allow to the Subcontractor, unless specifically provided otherwise in the subcontract agreement, the benefit of all rights, remedies, and redress against the Contractor that the Contractor, by the Contract Documents, has against the Owner. Where appropriate, the Contractor shall require each Subcontractor to enter into similar agreements with Sub-subcontractors. The Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract agreement, copies of the Contract Documents to which the Subcontractor will be bound, and, upon written request of the Subcontractor, identify to the Subcontractor terms and conditions of the proposed subcontract agreement that may be at variance with the Contract Documents. Subcontractors will similarly make copies of applicable portions of such documents available to their respective proposed Sub-subcontractors.

§ 5.4 Contingent Assignment of Subcontracts§ 5.4.1 Each subcontract and supply agreement for a portion of the Work is assigned by the Contractor to the Owner, provided that

.1 assignment is effective only after termination of the Contract by the Owner pursuant to and in accordance with Section 14 of these General Conditions and only for those subcontract and supply agreements that the Owner accepts by notifying the Subcontractor or supplier and Contractor; and

.2 assignment is subject to the prior rights of the surety, if any, obligated under bond relating to the Contract.

When the Owner accepts the assignment of a subcontract agreement, the Owner assumes the Contractor’s rights and obligations under the subcontract to the extent such rights and obligations arise subsequent to Owner’s acceptance of the assignment. The Contractor agrees to execute any and all other documents required to effect this assignment.

§ 5.4.2 Upon such assignment, if the Work has been suspended for more than 60 days, the Subcontractor’s compensation shall be equitably adjusted for increases in cost resulting from the suspension.

§ 5.4.3 Upon assignment to the Owner under this Section 5.4, the Owner may further assign the subcontract and/or supply agreement to a successor contractor or other entity.

ARTICLE 6 CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS§ 6.1 Owner’s Right to Perform Construction and to Award Separate Contracts§ 6.1.1 The term "Separate Contractor(s)" shall mean other contractors retained by the Owner under separate agreements. The Owner reserves the right to perform construction or operations related to the Project with the Owner’s own forces, and with Separate Contractors retained under Conditions of the Contract substantially similar to those of

Init.

/


30

this Contract, including those provisions of the Conditions of the Contract related to insurance and waiver of subrogation.

§ 6.1.2 When separate contracts are awarded for different portions of the Project or other construction or operations on the site, the term "Contractor" in the Contract Documents in each case shall mean the Contractor who executes each separate Owner-Contractor Agreement.

§ 6.1.3 The Owner shall provide for coordination of the activities of the Owner’s own forces and of each Separate Contractor with the Work of the Contractor, who shall cooperate with them. The Contractor shall participate with any Separate Contractors and the Owner in reviewing their construction schedules. The Contractor shall make any revisions to its construction schedule deemed necessary after a joint review and mutual agreement. The construction schedules shall then constitute the schedules to be used by the Contractor, Separate Contractors, and the Owner until subsequently revised.


§ 6.2 Mutual Responsibility§ 6.2.1 The Contractor shall afford the Owner and Separate Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities, and shall connect and coordinate the Contractor’s construction and operations with theirs as required by the Contract Documents.

§ 6.2.2 If part of the Contractor’s Work depends for proper execution or results upon construction or operations by the Owner or a Separate Contractor, the Contractor shall, prior to proceeding with that portion of the Work, promptly notify the Architect of apparent discrepancies or defects in the construction or operations by the Owner or Separate Contractor that would render it unsuitable for proper execution and results of the Contractor’s Work. Failure of the Contractor to notify the Architect of apparent discrepancies or defects prior to proceeding with the Work shall constitute an acknowledgment that the Owner’s or Separate Contractor’s completed or partially completed construction is fit and proper to receive the Contractor’s Work. The Contractor shall not be responsible for discrepancies or defects in the construction or operations by the Owner or Separate Contractor that are not apparent.

§ 6.2.3 The Contractor shall reimburse the Owner for costs the Owner incurs that are payable to a Separate Contractor because of the Contractor’s delays, disruption of the work of such separate contractor, improperly timed activities or defective construction. The Owner shall have the right to off-set such costs against any amounts owed to the Contractor by the Owner to the extent related to the Project and such off-sets are consistent with unit pricing (if applicable). The Owner shall be responsible to the Contractor for costs the Contractor incurs because of a Separate Contractor’s delays, disruption of the work of such separate contractor, improperly timed activities, damage to the Work or defective construction provided that the Contractor timely notifies the Owner of its Claim based upon the fault of such separate contractor.

§ 6.2.4 The Contractor shall promptly remedy damage that the Contractor wrongfully causes to completed or partially completed construction or to property of the Owner or Separate Contractor as provided in Section 10.2.5.

§ 6.2.5 The Owner and each Separate Contractor shall have the same responsibilities for cutting and patching as are described for the Contractor in Section 3.14.

§6.2.6 Upon the Owner’s request, the Contractor shall defend any proceedings brought against the Owner by any separate contractor on account of any damage alleged to have been caused by the Contractor which arises from the Contractor’s failure to comply with the terms and conditions of this Section 6.2.

§ 6.3 Owner’s Right to Clean UpIf a dispute arises among the Contractor, Separate Contractors, and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish, the Owner may clean up and the Architect will allocate the cost among those responsible, as the Architect deems appropriate in its sole discretion.

Init.

/


31

ARTICLE 7 CHANGES IN THE WORK§ 7.1 General§ 7.1.1 Changes in the Work may be accomplished after execution of the Contract, and without invalidating the Contract, only by Change Order, Construction Change Directive or order for a minor change in the Work, subject to the limitations stated in this Article 7 and elsewhere in the Contract Documents.

§ 7.1.2 A Change Order shall be based upon agreement among the Owner, Contractor, and Architect. A Construction Change Directive requires agreement by the Owner and Architect and may or may not be agreed to by the Contractor. An order for a minor change in the Work may be issued by the Architect alone.

§ 7.1.3 Changes in the Work shall be performed under applicable provisions of the Contract Documents. The Contractor shall proceed promptly with changes in the Work, unless otherwise provided in the Change Order, Construction Change Directive, or order for a minor change in the Work.

§ 7.1.4 Upon the request of the Owner or the Architect (with the Owner’s approval), the Contractor shall submit to the Architect, in such form as the Architect may require, an accurate written estimate of the cost of any proposed extra Work or change in the Work. Such estimates shall be provided without cost to the Owner provided that the number of estimates requested is reasonable in the context of the Project as a whole. The Contractor’s estimate shall indicate the description, quantity and unit cost of each item of material, and the number of hours of work and hourly rate for each class of labor, as well as all other costs chargeable under the terms of this Article. Unit labor costs for the installation of each item of materials shall be provided if required by the Architect. The Contractor shall promptly revise and resubmit such estimate if the Architect determines that it is not in compliance with the requirements of this Section, or that it contains errors of fact or mathematical errors. If required by the Architect, in order to establish the exact cost of new Work added or of previously required Work omitted, the Contractor shall obtain and furnish to the Architect bona fide proposals from recognized suppliers for furnishing any material included in such Work. Such estimates shall be furnished promptly so as to occasion no delay in the Work. The Contractor shall also state in the estimate any change in the Contract Time that would result from the change or extra work.

§ 7.2 Change Orders§ 7.2.1 A Change Order is a written instrument prepared by the Architect and signed by the Owner, Contractor, and Architect stating their agreement upon all of the following:

.1 The change in the Work;

.2 The amount of the adjustment, if any, in the Contract Sum; and

.3 The extent of the adjustment, if any, in the Contract Time.

§ 7.2.2 A Change Order executed by the Owner and the Contractor shall constitute a final settlement of all matters relating to the subject matter of the Change Order including, without limitation, compensation to be paid to the Contractor in connection with any change in the Work required by the Change Order (provided that the Work that is the subject of such change is performed in a manner consistent with the provisions of the Contract Documents and the applicable Change Order), including but not limited to all direct and indirect costs, profit, overhead, extended overhead, loss of productivity and general conditions associated with such change, and any and all adjustments to the Contract Sum and/or the Guaranteed Maximum Price, as applicable, the Construction Schedule, and to the Contract Time. In the event a Change Order affects an increase in the Contract Sum or the Guaranteed Maximum Price, as applicable, Contractor shall include the work covered by such the Change Order in Applications for Payment for such work as if the work were originally part of the Work as set forth in the Contract Documents.

§ 7.2.3 Notwithstanding anything to the contrary set forth in these General Conditions, if the Agreement sets forth the methodology for calculating adjustments in the Contract Sum (and/or Guaranteed Maximum Price, as applicable) associated with a change in the Work, and if, under the terms of the Contract Documents, an adjustment in the Contract Sum (and/or Guaranteed Maximum Price, as applicable) would be required, then the adjustment will be based on such methodology unless otherwise mutually agreed by the parties. This paragraph shall be applicable in the case of a change in the Work effected by a Change Order as well as a Construction Change Directive.

§ 7.2.4 Unless otherwise instructed by the Owner, Change Orders shall be prepared on the form AIA G-701.

Init.

/


32

§ 7.3 Construction Change Directives§ 7.3.1 A Construction Change Directive is a written order prepared by the Architect and signed by the Owner and Architect, directing a change in the Work prior to agreement on adjustment, if any, in the Contract Sum (and/or Guaranteed Maximum Price, as applicable) or Contract Time, or both. The Owner may by Construction Change Directive, without invalidating the Contract, order changes in the Work within the general scope of the Contract consisting of additions, deletions, or other revisions, the Contract Sum (and/or Guaranteed Maximum Price, as applicable) and Contract Time being adjusted accordingly.

§ 7.3.2 A Construction Change Directive shall be used in the absence of total agreement on the terms of a Change Order.

§ 7.3.3 If the Construction Change Directive provides for an adjustment to the Contract Sum (and/or Guaranteed Maximum Price, as applicable), the adjustment shall be based on one of the following methods:

.1 Mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit evaluation;

.2 Unit prices stated in the Contract Documents or subsequently agreed upon;

.3 Cost to be determined in a manner agreed upon by the parties and a mutually acceptable fixed or percentage fee; or

.4 As provided in Section 7.3.4.

§ 7.3.3.5 Notwithstanding anything to the contrary contained in the foregoing provisions of this Section 7.3, In the case of a change in the Work for which the Contractor is entitled to an adjustment in the Contract Sum under the terms and conditions of the Contract Documents, such adjustment shall be limited as follows:

(i) Change Orders, in aggregate, shall not increase the Contract Sum by more than ten percent (10%);(ii) For that portion of the change in the Work that is self-performed by the Contractor, the Contractor’s

overhead and profit on such Work shall not exceed ten percent (10%) of the Contractor’s direct costs incurred in the performance of such Work; and

(iii) For that portion of the change in the Work that is performed by Subcontractors, the Contractor’s markup on such subcontracted Work shall not exceed five percent (5%) of the amount invoiced to the Contractor by the Subcontractors for that Work and a Subcontractor’s overhead and profit on its portion of the change in the Work shall not exceed ten percent (10%) of the Subcontractor’s direct costs incurred in the performance of such Work.

These limitations shall apply to both additions to and deductions from the Contract Sum.

For change order Work that is the subject of Unit Prices under the Contract Documents, there will be no markup permitted on the applicable Unit Prices.

The Contractor shall include the markup limitations set forth in this Section 7.3.3.5 in all Subcontracts and require in all Subcontracts that the Subcontractors include such limitations in all lower tier Subcontracts.

§ 7.3.3.6 All Change Orders and Construction Change Directives shall provide itemized accounting that provides a detailed break-out of all materials and labor rates applicable thereto:

.1 Costs of labor, including social security, old age and unemployment insurance, fringe benefits required by agreement or custom, and workers’ compensation insurance;

.2 Costs of materials, supplies and equipment, including cost of transportation, whether incorporated or consumed;

.3 Fair market rental costs of machinery and equipment, exclusive of hand tools, whether rented from the Contractor or others provided, if rented from the Contractor, such rental and the rental rates have been approved by the Owner;

.4 Costs of premiums for all bonds and insurance, permit fees, and sales, use or similar taxes related to the Work;

.5 Additional costs of supervision and field office personnel directly attributable to the change to the extent permitted under the Contract Documents.

The costs described in Section 7.3.3.6.1 through and including 7.3.3.6.5 shall not include any of the following:

Init.

/


33

.1 Salaries and other compensation of the Contractor’s personnel stationed at the Contractor’s principal office or offices other than the site office, except as specifically approved by the Owner;

.2 Expenses of the Contractor’s principal office and offices other than the site office;

.3 Overhead and general expenses, except as may be expressly included in Section 7.3.7;

.4 The Contractor’s capital expenses, including interest on the Contractor’s capital employed for the Work;

.5 Costs due to the negligence or failure of the Contractor, Subcontractors and suppliers or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable to fulfill a specific responsibility of the Contract Documents; or

.6 Any cost not described in Section 7.3.4.1 through and including 7.3.4.5.

§ 7.3.4 If the Contractor does not respond promptly or disagrees with the method for adjustment in the Contract Sum, the Architect shall determine the adjustment on the basis of reasonable expenditures and savings of those performing the Work attributable to the change, including, in case of an increase in the Contract Sum, an amount for overhead and profit as set forth in the Agreement and subject to the limitations set forth in Section 7.3.3.5. In such case, and also under Section 7.3.3.3, the Contractor shall keep and present, in such form as the Architect may prescribe, an itemized accounting together with appropriate supporting data. Unless otherwise provided in the Contract Documents, costs for the purposes of this Section 7.3.4 shall be limited to the following:

.1 Costs of labor, including applicable payroll taxes, fringe benefits required by agreement or custom, workers’ compensation insurance, and other employee costs approved by the Architect;

.2 Costs of materials, supplies, and equipment, including cost of transportation, whether incorporated or consumed;

.3 Rental costs (not to exceed fair market rental costs) of machinery and equipment, exclusive of hand tools, whether rented from the Contractor or others provided, if rented from the Contractor, such rental and the rental rates have been approved by the Owner;

.4 Costs of premiums for all bonds and insurance, permit fees, and sales, use, or similar taxes, directly related to the change; and

.5 Costs of supervision and field office personnel directly attributable to the change to the extent permitted under the Contract Documents.

§ 7.3.5 If the Contractor disagrees with the adjustment in the Contract Time, the Contractor may make a Claim in accordance with applicable provisions of Article 15.

§ 7.3.6 Upon receipt of a Construction Change Directive, the Contractor shall promptly proceed with the change in the Work involved and, prior to proceeding with such Work, advise the Architect of the Contractor’s agreement or disagreement with the method, if any, provided in the Construction Change Directive for determining the proposed adjustment in the Contract Sum or Contract Time.

§ 7.3.7 A Construction Change Directive signed by the Contractor indicates the Contractor’s agreement therewith, including adjustment in Contract Sum (or Guaranteed Maximum Price, as applicable) and Contract Time or the method for determining them. Such agreement shall be effective immediately and shall be recorded as a Change Order.

§ 7.3.8 The amount of credit to be allowed by the Contractor to the Owner for a deletion or change that results in a net decrease in the Contract Sum shall be actual net cost as confirmed by the Architect. When both additions and credits covering related Work or substitutions are involved in a change, the allowance for overhead and profit shall be figured on the basis of net increase, if any, with respect to that change.

§ 7.3.9 Pending final determination of the total cost of a Construction Change Directive to the Owner, the Contractor may request payment for Work completed under the Construction Change Directive in Applications for Payment. The Architect will make an interim determination for purposes of monthly certification for payment for those costs and certify for payment actual costs incurred by the Contractor as a result of such Construction Change Directive; provided, however, to the extent such Construction Change Directive is made necessary by the act or omission of the Contractor or of anyone for whom the Contractor is responsible, the Architect shall certify for payment the amount, if any, that the Architect determines, in the Architect’s professional judgment, to be reasonably justified. The Architect’s interim determination of cost shall adjust the Contract Sum (or the Guaranteed Maximum Price as applicable) on the

Init.

/


34

same basis as a Change Order, subject to the right of either party to disagree and assert a Claim in accordance with Article 15.

§ 7.3.10 When the Owner and Contractor agree with a determination made by the Architect concerning the adjustments in the Contract Sum and Contract Time, or otherwise reach agreement upon the adjustments, such agreement shall be effective immediately and the Architect will prepare a Change Order. Change Orders may be issued for all or any part of a Construction Change Directive.

§ 7.4 Minor Changes in the WorkThe Architect may order minor changes in the Work that are consistent with the intent of the Contract Documents and do not involve an adjustment in the Contract Sum (or the Guaranteed Maximum Price, as applicable) or an extension of the Contract Time. The Architect’s order for minor changes shall be in writing. If the Contractor believes that the proposed minor change in the Work will affect the Contract Sum (or the Guaranteed Maximum Price, as applicable) or Contract Time, the Contractor shall notify the Architect and shall not proceed to implement the change in the Work. If the Contractor performs the Work set forth in the Architect’s order for a minor change without prior notice to the Architect that such change will affect the Contract Sum (or the Guaranteed Maximum Price, as applicable) or Contract Time, the Contractor waives any adjustment to the Contract Sum (and the Guaranteed Maximum Price, as applicable) or extension of the Contract Time.

ARTICLE 8 TIME§ 8.1 Definitions§ 8.1.1 Unless otherwise provided, Contract Time is the period of time, including authorized adjustments, allotted in the Contract Documents for Substantial Completion of the Work.

§ 8.1.2 The date of commencement of the Work is the date established in the Agreement.

§ 8.1.3 The date of Substantial Completion is the date Substantial Completion is achieved in accordance with Section 9.8.1.

§ 8.1.4 The term "day" as used in the Contract Documents shall mean calendar day unless otherwise specifically defined.

§ 8.2 Progress and Completion§ 8.2.1 Time limits stated in the Contract Documents are of the essence of the Contract. By executing the Agreement, the Contractor confirms that the Contract Time is a reasonable period for performing the Work.

§ 8.2.2 The Contractor shall not knowingly, except by agreement or instruction of the Owner in writing, commence the Work prior to the effective date of insurance required to be furnished by the Contractor and Owner.

§ 8.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion of the Work in accordance with the Contract Documents within the Contract Time.

§ 8.3 Delays and Extensions of Time§ 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by (1) an act or neglect of the Owner or Architect, of an employee of either, or of a Separate Contractor; (2) by changes ordered in the Work the Owner, which changes were not necessitated by the fault of the Contractor, a Subcontractor, a material or equipment supplier or anyone for whom any of them is responsible; (3) area-wide labor disputes not directed at the Contractor or any of its Subcontractors or by illegal labor actions or disputes; (4) fire, unusual delay in deliveries, unavoidable casualties, adverse weather conditions documented in accordance with Section 15.1.6.2, or other causes beyond the Contractor’s control; (5) by delay authorized by the Owner pending mediation and binding dispute resolution; or (6) by other causes that the Contractor asserts, and the Architect determines, justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Architect may determine provided that (i) any such delay has the effect of delaying completion of components of the Work on any critical path indicated in the Construction Schedule; (ii) any such delay is not caused by, or could not have been avoided by the exercise of reasonable efforts of the Contractor; (iii) any such delay could not be limited or avoided by the Contractor’s timely notice to the Owner of the delay; and (iv) such delay has an impact of at least one (1) day.

Init.

/


35

§ 8.3.2 Claims relating to time shall be made in accordance with applicable provisions of Article 15.

§ 8.3.3 No Damage for Delay. Notwithstanding anything to the contrary set forth in the Contract Documents, the Owner shall not be liable to the Contractor or any Subcontractor for Claims or damages of any nature caused by or arising out of delays. The sole remedy against the Owner for delays shall be the allowance of additional time for completion of the Work, the amount of which shall be subject to the procedures set forth in the Contract Documents. Except to the extent, if any, expressly prohibited by law, the Contractor expressly agrees not to make and hereby waives any Claim for damages for any delay, including, but not limited to, those resulting from increased labor or material costs; directions given or not given by the Owner or Architect, including scheduling and coordination of the Project Work; the Architect’s preparation of drawings and specifications or review of shop drawings and requests for instruction(s); or, on account of any delay, obstruction or hindrance for any cause whatsoever by the Owner, Architect, or any other contractor on the Project, whether or not foreseeable or anticipated. The Contractor agrees that its sole right and remedy therefore shall be an extension of the Contract Time, if appropriate.

§ 8.3.4 It is expressly understood that notwithstanding anything to the contrary set forth in the Contract Documents, no Subcontractor shall be entitled to make any Claim for additional compensation, costs or damages against the Contractor (nor may the Contractor assert against Owner such Claims as pass-through claims of Subcontractor or otherwise) for delay. Unless agreed by Owner in writing, Contractor shall include in every Subcontract a ’No-Damage-For-Delay’ provision in a form reasonably approved by the Owner.

§ 8.3.5 This Section 8.3 does not preclude recovery of damages for delay by either party under other provisions of the Contract Documents.

ARTICLE 9 PAYMENTS AND COMPLETION§ 9.1 Contract Sum§ 9.1.1 The Contract Sum is defined in the Agreement and, including authorized adjustments, is the total amount payable by the Owner to the Contractor for performance of the Work under the Contract Documents (subject to the Guaranteed Maximum Price, as applicable).

(Paragraph deleted)§ 9.1.2Intentionally Omitted.

§ 9.2 Schedule of ValuesWhere the Contract is based on a stipulated sum or Guaranteed Maximum Price, the Contractor shall submit a schedule of values to the Architect before the first Application for Payment, allocating the entire Contract Sum to the various portions of the Work. The schedule of values shall be prepared in the form, and supported by the data to substantiate its accuracy, required by the Architect. This schedule, upon the approval thereof by the Owner and the Architect, shall be used as a basis for reviewing the Contractor’s Applications for Payment. Any changes to the schedule of values shall be submitted to the Architect and supported by such data to substantiate its accuracy as the Architect may require, and unless objected to by the Architect, shall be used as a basis for reviewing the Contractor’s subsequent Applications for Payment.

§ 9.3 Applications for Payment§ 9.3.1 At least ten days before the date established for submission of an Application for Payment pursuant to the Agreement, the Contractor shall submit to the Architect and the Owner a draft itemized Application for Payment prepared in accordance with the Contract Documents and the schedule of values, if required under Section 9.2, for completed portions of the Work for review and consideration. The Application shall be notarized, if required, and submitted along with all data, information and documentation substantiating the Contractor’s right to payment as required under the Contract Documents and as may otherwise be required by the Owner or Architect (collectively, the "Supporting Documentation"). Subsequent to the Architect’s and the Owner’s review and comment, the Contractor shall make all necessary changes to the Application for Payment and resubmit a final version of the Application for Payment to the Architect and the Owner for payment.

§ 9.3.1.1 "Supporting Documentation" may include, without limitation, payrolls, petty cash accounts, receipted invoices or invoices with check vouchers attached, releases and waivers of liens from Subcontractors and supplier, and

Init.

/


36

other evidence required by the Owner or Architect to demonstrate that cash disbursements already made by the Contractor on account of the Cost of the Work equal or exceed progress payments already received by the Contractor.

§ 9.3.1.2 Applications for Payment shall reflect retainage as provided for in the Contract Documents.

§ 9.3.1.1 As provided in Section 7.3.9, such applications may include requests for payment on account of changes in the Work that have been properly authorized by Construction Change Directives, or by interim determinations of the Architect, but not yet included in Change Orders.

§ 9.3.1.2 Applications for Payment shall not include requests for payment for portions of the Work for which the Contractor does not intend to pay a Subcontractor or supplier, unless such Work has been performed by others whom the Contractor intends to pay.

§ 9.3.2 Unless otherwise provided in the Contract Documents, or prohibited by any person or entity providing funding for the Project, payments shall be made on account of materials and equipment delivered and suitably stored at the site for subsequent incorporation in the Work. If approved in advance by the Owner, and not prohibited by any person or entity providing funding for the Project, payment may similarly be made for materials and equipment suitably stored off the site at a location agreed upon in writing. Payment for materials and equipment stored on or off the site shall be conditioned upon compliance by the Contractor with procedures satisfactory to the Owner to establish the Owner’s title to such materials and equipment or otherwise protect the Owner’s interest, and shall include the costs of applicable insurance (which insurance shall include coverage naming the Owner, the Town of Weston, and the Owner’s lender (and such others as may be identified by the Owner from time to time) as additional insureds, and which shall specify and relate to the address where the stored materials and equipment are located including, if applicable, the Project Site), storage, and transportation to the site, for such materials and equipment stored off the site.

§ 9.3.3 The Contractor warrants that title to all Work covered by an Application for Payment will pass to the Owner no later than the time of payment. The Contractor further warrants that upon submittal of an Application for Payment all Work for which Certificates for Payment have been previously issued and payments received from the Owner shall, to the best of the Contractor’s knowledge, information, and belief, be free and clear of liens, claims, security interests, or encumbrances, in favor of the Contractor, Subcontractors, suppliers, or other persons or entities that provided labor, materials, and equipment relating to the Work.

§9.3.3.1 Commencing with the second Application for Payment, and continuing with each Application for Payment submitted thereafter, the Contractor shall furnish to the Owner a properly executed release and waiver of claims and mechanics liens in form acceptable to the Owner and its lender, as applicable, from the Contractor and each Subcontractor and material supplier whose Work was included on the previous Application for Payment for which payment by Owner was made to the Contractor. In addition to the foregoing, if requested by the Owner, commencing with the first Application for Payment and continuing with each Application for Payment submitted thereafter, the Contractor shall also provide a properly executed conditional release and waiver of mechanics liens in form acceptable to the Owner from the Contractor and each Subcontractor and material or equipment supplier whose Work is included on the Application for Payment subject only to receipt of payment under such Application for Payment,

§ 9.3.4 Unless otherwise required by the Owner, Applications for Payment shall be on AIA documents G702 and G703.

§ 9.4 Certificates for Payment§ 9.4.1 The Architect will, within seven days after receipt of the Contractor’s Application for Payment, either (1) issue to the Owner a Certificate for Payment in the full amount of the Application for Payment, with a copy to the Contractor; or (2) issue to the Owner a Certificate for Payment for such amount as the Architect determines is properly due, and notify the Contractor and Owner of the Architect’s reasons for withholding certification in part as provided in Section 9.5.1; or (3) withhold certification of the entire Application for Payment, and notify the Contractor and Owner of the Architect’s reason for withholding certification in whole as provided in Section 9.5.1.

§ 9.4.2 The issuance of a Certificate for Payment will constitute a representation by the Architect to the Owner, based on the Architect’s evaluation of the Work and the data in the Application for Payment and Supporting Documentation submitted therewith, that, to the best of the Architect’s knowledge, information, and belief, the Work has progressed to the point indicated, the quality of the Work is in accordance with the Contract Documents, and that the Contractor is

Init.

/


37

entitled to payment in the amount certified. The foregoing representations are subject to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, to results of subsequent tests and inspections, to correction of minor deviations from the Contract Documents prior to completion, and to specific qualifications expressed by the Architect. However, the issuance of a Certificate for Payment will not be a representation that the Architect has (1) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work; (2) reviewed construction means, methods, techniques, sequences, or procedures; (3) reviewed copies of requisitions received from Subcontractors and suppliers and other data requested by the Owner to substantiate the Contractor’s right to payment; or (4) made examination to ascertain how or for what purpose the Contractor has used money previously paid on account of the Contract Sum.

§ 9.5 Decisions to Withhold Certification§ 9.5.1 The Architect may withhold a Certificate for Payment in whole or in part, to the extent reasonably necessary to protect the Owner, if in the Architect’s opinion the representations to the Owner required by Section 9.4.2 cannot be made. If the Architect is unable to certify payment in the amount of the Application, the Architect will notify the Contractor and Owner as provided in Section 9.4.1. If the Contractor and Architect cannot agree on a revised amount, the Architect will promptly issue a Certificate for Payment for the amount for which the Architect is able to make such representations to the Owner. The Architect may also withhold a Certificate for Payment or, because of subsequently discovered evidence, may nullify the whole or a part of a Certificate for Payment previously issued, to such extent as may be necessary in the Architect’s opinion to protect the Owner from loss for which the Contractor is responsible, including loss resulting from acts and omissions described in Section 3.3.2, because of

.1 defective Work not remedied;

.2 third party claims filed or reasonable evidence indicating probable filing of such claims, unless security acceptable to the Owner is provided by the Contractor;

.3 failure of the Contractor to make payments properly to Subcontractors or suppliers for labor, materials or equipment;

.4 reasonable evidence that the Work cannot be completed for the unpaid balance of the Contract Sum;

.5 damage to the Owner or a Separate Contractor;

.6 reasonable evidence that the Work will not be completed within the Contract Time, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay;

.7 repeated failure to carry out the Work in accordance with the Contract Documents; or

.8 amounts previously paid to the Contractor in excess of amounts properly due the Contractor;

.9 failure of the Contractor to comply with any of the Contractor’s indemnification obligations under the Contract Documents.

§ 9.5.2 When either party disputes the Architect’s decision regarding a Certificate for Payment under Section 9.5.1, in whole or in part, that party may submit a Claim in accordance with Article 15.

§ 9.5.3 When the reasons for withholding certification are removed, certification will be made for amounts previously withheld.

§ 9.5.4 If the Architect withholds certification for payment under Section 9.5.1.3, the Owner may, at its sole option, issue joint checks to the Contractor and to any Subcontractor or supplier to whom the Contractor failed to make payment for Work properly performed or material or equipment suitably delivered. The Contractor will properly endorse any such joint checks upon Owner’s request and, unless the Owner instructs otherwise, the Contractor shall thereafter promptly deliver the joint check(s) to the appropriate subcontractors and suppliers. If the Owner makes payments by joint check, the Owner shall notify the Architect and the Contractor shall reflect such payment on its next Application for Payment.

§ 9.6 Progress Payments§ 9.6.1 After the Architect has issued a Certificate for Payment, the Owner shall make payment in the manner and within the time provided in the Contract Documents, and shall so notify the Architect.

§ 9.6.2 The Contractor shall pay any amounts due a Subcontractor or supplier, whether for labor performed or materials furnished, not later than seven (7) days after the date the Contractor receives payment from the Owner which encompasses labor performed or materials furnished by such Subcontractor or supplier. Retainage withheld by the Contractor from such payments shall not exceed amounts actually retained from payments to the Contractor on account of the Subcontractor’s or supplier’s portion of the Work. The Contractor shall include in all of its Subcontracts with its Subcontractors and suppliers a requirement that the Subcontractors and suppliers pay any amounts due any

Init.

/


38

sub-subcontractors or suppliers no later than seven (7) days after the Subcontractor or supplier receives a payment from the Contractor which encompasses labor performed or materials furnished by such sub-subcontractor or supplier.

§ 9.6.2.1 Contractor shall use payments made under this Agreement solely for the purpose of performance of the Work pursuant to the Contract Documents. Contractor shall pay for all labor and services performed and materials, equipment and machinery supplied by others in connection with the performance of the Work in accordance with the Contract Documents and as required by applicable Legal Requirements (as defined in Section 3.7.2 of the General Conditions).

§ 9.6.3 The Architect will, on request, furnish to a Subcontractor, if practicable, information regarding percentages of completion or amounts applied for by the Contractor and action taken thereon by the Architect and Owner on account of portions of the Work done by such Subcontractor.

§ 9.6.4 The Owner has the right to request written evidence from the Contractor that the Contractor has properly paid Subcontractors and suppliers amounts paid by the Owner to the Contractor for subcontracted Work. If the Contractor fails to furnish such evidence within seven days, the Owner shall have the right to contact Subcontractors and suppliers to ascertain whether they have been properly paid. Neither the Owner nor Architect shall have an obligation to pay, or to see to the payment of money to, a Subcontractor or supplier, except as may otherwise be required by law.

§ 9.6.5 The Contractor’s payments to suppliers shall be treated in a manner similar to that, and subject to the same requirements as are, provided in Sections 9.6.2, 9.6.3 and 9.6.4.

§ 9.6.6 A Certificate for Payment, a progress payment, or partial or entire use or occupancy of the Project by the Owner shall not constitute acceptance of Work not in accordance with the Contract Documents or applicable Legal Requirements.

§ 9.6.7 Unless the Contractor provides the Owner with a payment bond in the full penal sum of the Contract Sum, payments received by the Contractor for Work properly performed by Subcontractors or provided by suppliers shall be held by the Contractor for those Subcontractors or suppliers who performed Work or furnished materials, or both, under contract with the Contractor for which payment was made by the Owner. Nothing contained herein shall require money to be placed in a separate account and not commingled with money of the Contractor, create any fiduciary liability or tort liability on the part of the Contractor for breach of trust, or entitle any person or entity to an award of punitive damages against the Contractor for breach of the requirements of this provision.

§ 9.6.8 Any provision in the Contract Documents to the contrary notwithstanding, the Owner shall not be obligated to make payment to the Contractor hereunder to the extent that the Contractor has not performed the Work or supplied the materials, for which payment is requested, in accordance with the Contract Documents.

§ 9.7 Failure of PaymentIf the Architect does not issue a Certificate for Payment in accordance with the requirements of the Contract Documents, through no fault of the Contractor, within ten days after receipt of the Contractor’s Application for Payment, or if the Owner does not pay the Contractor within seven days after the date established in the Contract Documents, the amount certified by the Architect or awarded by binding dispute resolution, then the Contractor may, upon ten additional days’ notice to the Owner and Architect, stop the Work until payment of the amount owing has been received. The Contract Time shall be extended appropriately and the Contract Sum shall be increased by the amount of the Contractor’s reasonable costs of shutdown, delay and start-up, plus interest as provided for in the Contract Documents.

§ 9.8 Substantial Completion§ 9.8.1 The Work shall be considered to be "Substantially Complete(d)" or to have reached "Substantial Completion" on the date as determined by the Architect when (1) the entirety of the Work is sufficiently complete in accordance with the Contract Documents so that the Owner can utilize the Work for the use for which it is intended (subject only items on the Punch List, the completion of which can be accomplished within thirty (30) days without interfering with the actual use of the Work by the Owner or those claiming by, through or under the Owner), (2) the Contractor has obtained a temporary or permanent certificate of occupancy for the Work permitting the lawful occupancy of the entire Project and any other permits, approvals, licenses, and other documents from any governmental authority having

Init.

/


39

jurisdiction thereof necessary for the beneficial occupancy thereof, and (3) the Architect has issued a Certificate of Substantial Completion for the entirety of the Work pursuant to Section 9.8.4 of these General Conditions.

Without limitation, if and to the extent applicable given the Work to be performed hereunder, Substantial Completion of the Work shall not be deemed to have occurred until construction and installation of all facilities and systems (including but not limited to instrumentation and controls) shall be complete in all respects as required for the issuance of all required use and occupancy permits and approvals by all applicable governmental authorities, excluding only the final landscaping work (if applicable). Further, if and to the extent applicable, given the Work to be performed hereunder, Substantial Completion requires full commissioning and operation of all automatic systems, including but not limited to testing of individual system components and equipment and full operational startup and certification testing.

§ 9.8.2 When the Contractor considers that the Work, is substantially complete, the Contractor shall prepare and submit to the Architect a comprehensive list of items to be completed or corrected prior to final payment (the "Punchlist"). Failure to include an item on the Punchlist does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents.

§ 9.8.3 Upon receipt of the Contractor’s Punchlist, the Architect will make an inspection to determine whether the Work or designated portion thereof is substantially complete. If the Architect’s inspection discloses any item, whether or not included on the Contractor’s list, which is not sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use, the Contractor shall, before issuance of the Certificate of Substantial Completion, complete or correct such item upon notification by the Architect. In such case, the Contractor shall then submit a request for another inspection by the Architect to determine Substantial Completion.

§ 9.8.4 When the Work is Substantially Complete, the Architect will prepare a Certificate of Substantial Completion that shall establish the date of Substantial Completion; establish responsibilities of the Owner and Contractor for security, maintenance, heat, utilities, damage to the Work and insurance; and fix the time within which the Contractor shall finish all items remaining on the Punch List accompanying the Certificate. Warranties required by the Contract Documents shall commence on the date of Substantial Completion of the Work or designated portion thereof unless otherwise provided in the Certificate of Substantial Completion.

§ 9.8.5 The Certificate of Substantial Completion shall be submitted to the Owner and Contractor for their written acceptance of responsibilities assigned to them in the Certificate. Upon Substantial Completion of the Work and such acceptance, and consent of surety if any, the Owner may, in its sole and absolute discretion, release and make payment of all or a portion of retainage as applicable to the Work that is complete in accordance with the Contract Documents. The Owner shall not be obligated to release any portion of retainage held by the Owner under the Contract Documents until such time as the Work is finally complete pursuant to Section 9,10 of these General Conditions.

§ 9.9 Partial Occupancy or Use§ 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to by the insurer and authorized by public authorities having jurisdiction over the Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete, the Contractor shall prepare and submit the Punchlist to the Architect as provided under Section 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld. The stage of the progress of the Work shall be determined by written agreement between the Owner and Contractor or, if no agreement is reached, by decision of the Architect.

§ 9.9.2 Immediately prior to such partial occupancy or use, the Owner, Contractor, and Architect shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work.

§ 9.9.3 Unless otherwise agreed upon, partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents.

Init.

/


40

§ 9.10 Final Completion and Final Payment§ 9.10.1 Upon receipt of the Contractor’s notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such inspection. When the Architect finds the Work acceptable under the Contract Documents and the Contract fully performed, the Architect will promptly issue a final Certificate for Payment stating that to the best of the Architect’s knowledge, information and belief, and on the basis of the Architect’s on-site visits and inspections, the Work has been completed in accordance with the Contract Documents and that the entire balance found to be due the Contractor and noted in the final Certificate is due and payable. The Architect’s final Certificate for Payment will constitute a further representation that conditions listed in Section 9.10.2 as precedent to the Contractor’s being entitled to final payment have been fulfilled. All warranties and guarantees required under or pursuant to the Contract Documents not previously delivered shall be assembled and delivered by the Contractor to the Owner and Architect as part of the final Application for Payment. The final Certificate for Payment will not be issued by the Architect until all warranties and guarantees and all other close-out deliverables (including those set forth in Section 9.10.2 below) have been received and accepted by the Owner.

§ 9.10.2 The Contractor shall be required to submit the following to the Owner and the Architect, as conditions to the issuance of a final Certificate for Payment and delivery of final payment: (1) an affidavit that payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the Owner or the Owner’s property might be responsible or encumbered (less amounts withheld by Owner) have been paid or otherwise satisfied, (2) a certificate evidencing that insurance required by the Contract Documents to remain in force after final payment is currently in effect which shall include, without limitation product liability and completed operations, for the six year period following final completion, (3) a written statement that the Contractor knows of no reason that the insurance will not be renewable to cover the period required by the Contract Documents, (4) consent of surety, if any, to final payment, (5) all guarantees and warranties to which the Owner is entitled hereunder including documentation of any special warranties, such as manufacturers’ warranties or specific Subcontractor warranties, and (6) satisfactory proof that all claims, including taxes, arising out of the Work (including any claims of Subcontractors or suppliers) have been released or bonded and other data establishing payment or satisfaction of obligations, such as receipts and releases and waivers of liens, claims, security interests, or encumbrances arising out of the Contract including releases and final waivers of liens arising out of the Contract conditioned only upon receipt of final payment, the amount of which is consistent with the final Application for Payment , all to the extent and in such form as may be designated by the Owner, (7) final documents of similar nature to those required by the Contract Documents for any monthly payments hereunder, (8) all final permits, approvals (including, without limitation, the approval of the Owner’s insurance company, if required and requested in a timely fashion) certificates (including, without limitation, certificates in respect of electrical systems and life safety systems) and authorizations for use and occupancy of the Project required by any authority having jurisdiction, including any building permits, temporary and unconditioned permanent and full certificate of occupancy and any other necessary occupancy and use permits,(9) formally prepared "as built" drawings, records and related data including all field notes of all the Work (such drawings shall be in the form of "mylar" reproducible drawings, or as otherwise called for in the Contract Documents),(10) the Operating and Maintenance Manual for the Project as provided below,(11) a final statement of accounting for all allowances in form satisfactory to the Owner and the Owner’s lender, and(13) delivery of all spare parts required to be submitted pursuant to the Contract Documents.

§ 9.10.2.1 The "Operating and Maintenance Manual" for the Project shall contain, as applicable to the Work, (1) full information for each item of mechanical, electrical, or other operating equipment, copies of warranties therefor, schematic diagrams of control systems, circuit directories for each electric and communications panel board, and charts showing the tagging of all valves; and (2) complete keying schedules, paint color schedules, and paint color samples. Each volume of the manual shall be clearly indexed, and shall include a directory of all Subcontractors and maintenance contractors, indicating the area of responsibility of each, and the name and telephone number of the responsible member of each organization. The volumes shall be bound in book form.

§ 9.10.2.2. If a Subcontractor refuses to furnish a release or waiver required by the Owner, the Contractor may furnish a bond satisfactory to the Owner to indemnify the Owner against such lien, claim, security interest, or encumbrance. If no such bond is provided, the Owner may, without limiting its remedies under law, in equity, or under the Contract Documents, withhold the portion of final payment claimed to be due by the relevant Subcontractor or supplier until such lien, claim, security interest, or encumbrance is no longer a viable encumbrance. The Contractor shall refund to the Owner all money that the Owner may be compelled to pay in discharging such lien, claim, security interest, or encumbrance, including all costs and reasonable attorneys’ fees.

Init.

/


41

§ 9.10.2.3 If the final documentation submitted by the Contractor is not deemed complete by the Owner or if the Owner deems the Work incomplete in any respect, the Contractor shall promptly complete any such Work and shall promptly resubmit the final documentation.

§ 9.10.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by issuance of Change Orders affecting final completion, and the Architect so confirms, the Owner shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed, corrected, and accepted. If the remaining balance for Work not fully completed or corrected is less than retainage stipulated in the Contract Documents, and if bonds have been furnished, the written consent of the surety to payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under terms and conditions governing final payment, except that it shall not constitute a waiver of Claims.

§ 9.10.4 The making of final payment shall constitute a waiver of Claims by the Owner except those arising from.1 liens, Claims, security interests, or encumbrances arising out of the Contract and unsettled;.2 failure of the Work to comply with the requirements of the Contract Documents; .3 terms of special warranties required by the Contract Documents; .4 audits performed by the Owner, if permitted by the Contract Documents, after final payment; or.5 corrective work performed subsequent to final payment.

§ 9.10.5 Acceptance of final payment by the Contractor, a Subcontractor, or a supplier, shall constitute a waiver of claims by that payee except those previously made in writing and identified by that payee as unsettled at the time of final Application for Payment.

ARTICLE 10 PROTECTION OF PERSONS AND PROPERTY§ 10.1 Safety Precautions and ProgramsThe Contractor shall be responsible for initiating, maintaining, and supervising all safety precautions and programs required by the applicable Legal Requirements, the Contract Documents or as reasonably requested by the Owner in connection with the performance of the Contract.

§ 10.2 Safety of Persons and Property§ 10.2.1 The Contractor shall take reasonable precautions for safety of, and shall provide reasonable protection to prevent damage, injury, or loss to

.1 employees on the Work and other persons who may be affected thereby;

.2 the Work and materials and equipment to be incorporated therein, whether in storage on or off the site, under care, custody, or control of the Contractor, a Subcontractor, or a Sub-subcontractor; and

.3 other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks, pavements, roadways, structures, and utilities not designated for removal, relocation, or replacement in the course of construction.

§ 10.2.2 The Contractor shall comply with, and give notices required by applicable Legal Requirements bearing on safety of persons or property or their protection from damage, injury, or loss.

§ 10.2.3 The Contractor shall implement, erect, and maintain, as required by existing conditions and performance of the Contract, reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards; promulgating safety regulations; and notifying the owners and users of adjacent sites and utilities of the safeguards. The Contractor shall also be responsible for all measures necessary to protect any property adjacent to the Project and improvements thereon. Any damage to such property or improvements shall be promptly repaired by the Contractor at its cost and expense.

§ 10.2.4 When use or storage of explosives or other hazardous materials or equipment, or unusual methods are necessary for execution of the Work, the Contractor shall exercise utmost care and carry on such activities under supervision of properly qualified personnel.

Init.

/


42

§ 10.2.5 The Contractor shall promptly remedy damage and loss (other than damage or loss insured under property insurance required by the Contract Documents) to property referred to in Sections 10.2.1.2 and 10.2.1.3 caused in whole or in part by the Contractor, a Subcontractor, a Sub-subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose acts they may be liable and for which the Contractor is responsible under Sections 10.2.1.2 and 10.2.1.3. The Contractor may make a Claim for the cost to remedy the damage or loss to the extent such damage or loss is attributable to acts or omissions of the Owner or Architect or anyone directly or indirectly employed by either of them, or by anyone for whose acts either of them may be liable, and not attributable to the fault or negligence of the Contractor, a Subcontractor, a supplier, a Sub-subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable. The foregoing obligations of the Contractor are separate from and in addition to the Contractor’s obligations under Section 3.18.

§ 10.2.6 The Contractor shall designate a responsible member of the Contractor’s organization at the site whose duty shall be the prevention of accidents. This person shall be the Contractor’s superintendent unless otherwise designated by the Contractor in writing to the Owner and Architect.

§ 10.2.7 The Contractor shall not permit any part of the construction or site to be loaded so as to cause damage or create an unsafe condition.

§ 10.2.8 Injury or Damage to Person or PropertyIf either party suffers injury or damage to person or property because of an act or omission of the other party, or of others for whose acts such party is legally responsible, notice of the injury or damage, whether or not insured, shall be given to the other party within a reasonable time not exceeding 21 days after discovery. The notice shall provide sufficient detail to enable the other party to investigate the matter.

§ 10.2.9 In the event the Contractor identifies activities or conditions during performance of the Work or at the Project, which, in the Contractor’s good faith opinion, pose an unreasonable risk of bodily injury or property damage, whether immediate or in the future, the Contractor shall have the right to immediately take steps to protect its personnel and Subcontractors and stop Work and remove its personnel from the affected area.

§ 10.2.10 The Contractor shall at all times provide protection against weather (rain, wind, storms or heat) so as to maintain all Work, materials, apparatus and fixtures free from damage. At the end of the day’s work, all new Work likely to be damaged shall be reasonably protected against such weather.

§ 10.2.11 The Contractor shall provide adequate fire protection for all operations associated with the Work, and such protection must meet all applicable federal (including OSHA), State and municipal regulations.

§ 10.2.12 The Contractor shall remove and replace with new work, at the Contractor’s own expense, any Work damaged by failure to provide protection pursuant to Sections 10.2.10 and 10.2.11.

§ 10.2.13 The Contractor shall be responsible, to the extent not covered by insurance, for damage, loss or liability due to theft or vandalism to the Work and stored materials whether the same occurs while work is in progress or not, and during the day or at night, or on weekdays, weekends or holidays.

§ 10.2.14 The Contractor shall protect and prevent damage to all finished and unfinished phases of the Work during the course of the Project.

§ 10.2.15 SECURING THE SITEThe Contractor is responsible for securing, and preventing access by unauthorized individuals to, the Project site from such date as the Contractor, Subcontractors, suppliers, consultants, or agents commence the Work until the date of Final Completion, unless the Owner and Contractor agree in writing to an earlier date.

§ 10.3 Hazardous Materials and Substances§ 10.3.1 The Contractor is responsible for compliance with any requirements included in the Contract Documents regarding any material, substance, chemical, waste, product, derivative, compound, mixture, solid, liquid, mineral or gas, whether naturally occurring or manmade, that is hazardous, toxic, or words of similar import or regulatory effect, and any petroleum or petroleum-derived products, radon, radioactive materials or wastes, asbestos in any form, lead or lead-containing materials, urea formaldehyde foam insulation, and polychlorinated biphenyls (collectively,

Init.

/


43

"Hazardous Materials"). If the Contractor believes its Work will disturb or otherwise implicate any actual or suspected Hazardous Material or encounters a Hazardous Material not addressed in the Contract Documents, the Contractor shall not disturb any such Hazardous Material, immediately report the condition to the Owner and the Architect in writing and take all necessary precautions to prevent release of and exposure to the Hazardous Materials and foreseeable bodily injury or death to persons resulting from such Hazardous Material. If such reasonable precautions will be inadequate to prevent release of and exposure to Hazardous Materials, or foreseeable bodily injury and death, the Contractor shall, upon recognizing the condition, immediately stop Work in the affected area.

§ 10.3.2 Upon receipt of the Contractor’s notice pursuant to Section 10.3.1, of the existence of actual or suspect Hazardous Materials not addressed in the Contract Documents, the Owner shall obtain the services of a licensed laboratory to verify the presence or absence of the Hazardous Material or substance reported by the Contractor and, in the event such Hazardous Material or substance is found to be present, to cause it to be rendered harmless or otherwise abated. Unless otherwise required by the Contract Documents, the Owner shall furnish in writing to the Contractor and Architect the names and qualifications of persons or entities who are to perform tests verifying the presence or absence of the material or substance or who are to perform the task of removal or safe containment of the material or substance. The Contractor and the Architect will promptly reply to the Owner in writing stating whether or not either has reasonable objection to the persons or entities proposed by the Owner. If either the Contractor or Architect has an objection to a person or entity proposed by the Owner, the Owner shall propose another to whom the Contractor and the Architect have no reasonable objection. When the Hazardous Material has been rendered harmless and/or otherwise abated in accordance with all applicable Legal Requirements, Work in the affected area shall resume upon written agreement of the Owner and Contractor. By Change Order, the Contract Time shall be extended appropriately and the Contract Sum shall be increased by the amount of the Contractor’s reasonable additional costs of shutdown, delay, and start-up.

(Paragraph deleted)§ 10.3.3Intentionally Omitted.

§ 10.3.4 The Owner shall not be responsible under this Section 10.3 for hazardous materials or substances the Contractor any Subcontractor or any materialman or supplier, or any entity for whom any of them is responsible, brings to the site unless such materials or substances are required by the Contract Documents. The Owner shall be responsible for hazardous materials or substances required by the Contract Documents, except to the extent of the Contractor’s fault or negligence in the use and handling of such materials or substances or its failure to comply with the Contract Documents. The Contractor agrees not to use any fill or other materials to be incorporated into the Work which are hazardous, toxic or comprised of any items that are hazardous or toxic except to the extent required by the Contract Documents.

§ 10.3.5 To the fullest extent permitted by law, the Contractor shall indemnify, defend and hold harmless the Owner, the Town of Weston, and their respective agents, officers, officials, governing boards, employees, and the lender for the Project, as applicable, against claims, damages, losses and expenses, including but not limited to attorney’s fees, resulting from (1) an actual or suspect Hazardous Material the Contractor, or any party for whose acts the Contractor is responsible, brings to the site and negligently handles, or (2) where the Contractor fails to perform its obligations under Section 10.3.1, except to the extent that the cost and expense are due to the Owner’s fault or negligence.

§ 10.3.6 If, without negligence or fault on the part of the Contractor, or any party for whose acts the Contractor is responsible, the Contractor is held liable by a government agency for the cost of remediation of a hazardous material or substance solely by reason of properly performing Work as required by the Contract Documents, the Owner shall reimburse the Contractor for all cost and expense thereby incurred.

§ 10.3.7 The Contractor shall perform all required procedures necessary to insure that there will be no actual or threatened release, discharge, spillage, uncontrolled loss, seepage or filtration (each a "Release") of any Hazardous Material on the site caused by Contractor’s operations. The Contractor is responsible for any and all costs and liabilities associated with the investigation and remediation of any such Release, or as required by regulating authorities having jurisdiction under any of the applicable Legal Requirements, and holds the Owner, its employees and agents, and the fee owner of the Project site (if other than the Owner), harmless against any current or future liabilities resulting from such incidents.

Init.

/


44

§ 10.3.8 All material and equipment furnished under the Contract Documents shall be free of asbestos, lead based paint, and PCBs. Unless otherwise specified in the Contract Documents, any material or equipment containing these, and any other Hazardous Materials shall be considered defective and shall be removed by the Contractor at the Contractor’s sole expense.

§ 10.4 EmergenciesIn an emergency affecting safety of persons or property, the Contractor shall act, at the Contractor’s discretion, to prevent threatened damage, injury, or loss. Additional compensation or extension of time claimed by the Contractor on account of an emergency shall be determined as provided in Article 15 and Article 7. The Contractor shall promptly notify insurers as applicable, and the Architect and the Owner of the nature of the emergency. Immediately thereafter, the Contractor shall submit to the Architect and the Owner a written report including description of circumstances of the emergency and details of actions taken.

ARTICLE 11 INSURANCE AND BONDS§ 11.1 Contractor’s Insurance and Bonds§ 11.1.1 The Contractor shall purchase and maintain insurance of the types and limits of liability, containing the endorsements, and subject to the terms and conditions, as described in the Agreement or elsewhere in the Contract Documents. The Contractor shall purchase and maintain the required insurance from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located. The Owner, the Town of Weston, the Owner’s lender for the Project (if applicable), Architect, Architect’s consultants, such other parties as are identified in the Contract Documents and such others as may be required by the Owner, shall be named as additional insureds under the Contractor’s commercial general liability policy, automobile insurance policy and umbrella/excess insurance policy or as otherwise described in the Contract Documents.

§ 11.1.2 The Contractor shall provide surety bonds of the types, for such penal sums, and subject to such terms and conditions as required by the Contract Documents. The Contractor shall purchase and maintain the required bonds from a company or companies lawfully authorized to issue surety bonds in the jurisdiction where the Project is located.

§ 11.1.3 Upon the request of any person or entity appearing to be a potential beneficiary of bonds covering payment of obligations arising under the Contract, the Contractor shall promptly furnish a copy of the bonds or shall authorize a copy to be furnished.

§ 11.1.4 Notice of Cancellation or Expiration of Contractor’s Required Insurance. Within three (3) business days of the date the Contractor becomes aware of an impending or actual cancellation or expiration of any insurance required by the Contract Documents, the Contractor shall provide notice to the Owner of such impending or actual cancellation or expiration. Upon receipt of notice from the Contractor, the Owner shall, unless the lapse in coverage arises from an act or omission of the Owner, have the right to stop the Work until the lapse in coverage has been cured by the procurement of replacement coverage by the Contractor. In the event of such suspension, the Contractor shall be responsible for, and shall not receive an extension of the Contract Time in connection with, the delay in the Work arising from the suspension. The furnishing of notice by the Contractor shall not relieve the Contractor of any contractual obligation to provide any required coverage.

§ 11.2 Owner’s Insurance§ 11.2.1 The Owner shall purchase and maintain insurance of the types and limits of liability, containing the endorsements, and subject to the terms and conditions, as customarily maintained by the Owner .

§ 11.2.2 Failure to Purchase Required Property Insurance. The Contractor shall to maintain Builders Risk insurance for the Project as provided in the Agreement to protect the interests of the Owner, Contractor, Subcontractors, and Sub-Subcontractors in the Work. The cost of such insurance shall be charged to the Owner as part of the Contract Sum. If the Contractor fails to maintain such insurance, and the Owner is damaged by such failure, the Contractor shall reimburse the Owner for all reasonable costs and damages attributable thereto.

§ 11.2.3 Notice of Cancellation or Expiration of Owner’s Required Property Insurance. Within three (3) business days of the date the Contractor becomes aware of an impending or actual cancellation or expiration of the Builder’s Risk insurance required by the Contract Documents, the Contractor shall provide notice to the Owner of such impending or actual cancellation or expiration. If the Owner purchases replacement coverage, the cost of the insurance shall be

Init.

/


45

charged to the Contractor by an appropriate Change Order. The furnishing of notice by the Contractor shall not relieve the Contractor of any contractual obligation to provide required insurance.

§ 11.3 Waivers of Subrogation§ 11.3.1 The Owner and Contractor waive all rights against (1) each other and any of their subcontractors, sub-subcontractors, agents, and employees, each of the other; (2) the Architect and Architect’s consultants; and (3) Separate Contractors, if any, and any of their subcontractors, sub-subcontractors, agents, and employees, for damages caused by fire, or other causes of loss, to the extent those losses are covered by property insurance required by the Agreement or other property insurance applicable to the Project, except such rights as they have to proceeds of such insurance. The Owner or Contractor, as appropriate, shall require similar written waivers in favor of the individuals and entities identified above from the Architect, Architect’s consultants, Separate Contractors, subcontractors, and sub-subcontractors. The policies of insurance purchased and maintained by each person or entity agreeing to waive claims pursuant to this section 11.3.1 shall not prohibit this waiver of subrogation. This waiver of subrogation shall be effective as to a person or entity (1) even though that person or entity would otherwise have a duty of indemnification, contractual or otherwise, (2) even though that person or entity did not pay the insurance premium directly or indirectly, or (3) whether or not the person or entity had an insurable interest in the damaged property.

§ 11.3.2 If during the Project construction period the Owner insures properties, real or personal or both, at or adjacent to the site by property insurance under policies separate from those insuring the Project, or if after final payment property insurance is to be provided on the completed Project through a policy or policies other than those insuring the Project during the construction period, to the extent permissible by such policies, the Owner waives all rights in accordance with the terms of Section 11.3.1 for damages caused by fire or other causes of loss covered by this separate property insurance.

§ 11.4 Loss of Use, Business Interruption, and Delay in Completion InsuranceThe Owner, at the Owner’s option, may purchase and maintain insurance that will protect the Owner against loss of use of the Owner’s property, or the inability to conduct normal operations, due to fire or other causes of loss. The Owner waives all rights of action against the Contractor and Architect for loss of use of the Owner’s property, due to fire or other hazards however caused.

§11.5 Adjustment and Settlement of Insured Loss§ 11.5.1 A loss insured under the property insurance required by the Agreement shall be adjusted by the Owner and made payable to the Owner for the insureds, as their interests may appear, subject to requirements of any applicable mortgagee clause and of Section 11.5.2. The Owner shall pay the Architect and Contractor their just shares of insurance proceeds received by the Owner, and by appropriate agreements the Architect and Contractor shall make payments to their consultants and Subcontractors in similar manner.

§ 11.5.2 Prior to settlement of an insured loss, the Owner shall notify the Contractor of the terms of the proposed settlement as well as the proposed allocation of the insurance proceeds. The Contractor shall have 5 days from receipt of notice to object to the proposed settlement or allocation of the proceeds. If the Contractor does not object, the Owner may settle the loss and the Contractor shall be bound by the settlement and allocation. Upon receipt, the Owner shall deposit the insurance proceeds in a separate account and make the appropriate distributions. Thereafter, if no other agreement is made or the Owner does not terminate the Contract for convenience, the Owner and Contractor shall execute a Change Order for reconstruction of the damaged or destroyed Work in the amount allocated for that purpose. If the Contractor timely objects to either the terms of the proposed settlement or the allocation of the proceeds, the Owner may proceed to settle the insured loss, and any dispute between the Owner and Contractor arising out of the settlement or allocation of the proceeds shall be resolved pursuant to Article 15. Pending resolution of any dispute, the Owner may issue a Construction Change Directive for the reconstruction of the damaged or destroyed Work.

ARTICLE 12 UNCOVERING AND CORRECTION OF WORK§ 12.1 Uncovering of Work§ 12.1.1 If a portion of the Work is covered contrary to the Architect’s request or to requirements specifically expressed in the Contract Documents, it must, if requested in writing by the Architect, be uncovered for the Architect’s examination and be replaced at the Contractor’s expense without change in the Contract Time.

Init.

/


46

§ 12.1.2 If a portion of the Work has been covered that the Architect has not specifically requested to examine prior to its being covered, the Architect may request to see such Work and it shall be uncovered by the Contractor. If such Work is in accordance with the Contract Documents, the Contractor shall be entitled to an equitable adjustment to the Contract Sum and Contract Time as may be appropriate. If such Work is not in accordance with the Contract Documents, the costs of uncovering the Work, and the cost of correction, shall be at the Contractor’s expense.

§ 12.2 Correction of Work§ 12.2.1 Before Substantial CompletionThe Contractor shall promptly correct Work rejected by the Architect or failing to conform to the requirements of the Contract Documents, discovered before Substantial Completion and whether or not fabricated, installed or completed. Costs of correcting such rejected Work, including additional testing and inspections, the cost of uncovering and replacement, and compensation for the Architect’s services and expenses made necessary thereby, shall be at the Contractor’s expense.

§ 12.2.2 After Substantial Completion§ 12.2.2.1 In addition to the Contractor’s obligations under Section 3.5, if, within one year after the date of Substantial Completion of the Work or after the date for commencement of warranties established under Section 9.9.1, or by terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be not in accordance with the requirements of the Contract Documents, the Contractor shall correct it promptly after receipt of notice from the Owner to do so, unless the Owner has previously given the Contractor a written acceptance of such condition. The Owner shall give such notice promptly after discovery of the condition. During the one-year period for correction of Work, if the Owner fails to notify the Contractor by the end of such one-year period and, thereafter give the Contractor an opportunity to make the correction, the Owner waives the rights to require correction by the Contractor. If the Contractor fails to correct nonconforming Work within a reasonable time during that period after receipt of notice from the Owner or Architect, the Owner may correct it in accordance with Section 2.5.

§ 12.2.2.2 The one-year period for correction of Work shall be extended with respect to portions of Work first performed after Substantial Completion by the period of time between Substantial Completion and the actual completion of that portion of the Work.

§ 12.2.2.3 The one-year period for correction of Work shall not be extended by corrective Work performed by the Contractor pursuant to this Section 12.2.

§ 12.2.3 The Contractor shall remove from the site portions of the Work that are not in accordance with the requirements of the Contract Documents and are neither corrected by the Contractor nor accepted by the Owner.

§ 12.2.4 The Contractor shall bear the cost of correcting destroyed or damaged construction of the Owner or Separate Contractors, whether completed or partially completed, caused by the Contractor’s correction or removal of Work that is not in accordance with the requirements of the Contract Documents.

§ 12.2.5 Nothing contained in this Section 12.2 shall be construed to modify the Contractor’s obligations under Section 3.5 or to establish a period of limitation with respect to other obligations the Contractor has under the Contract Documents. Establishment of the one-year period for correction of Work as described in Section 12.2.2 relates only to the specific obligation of the Contractor to correct the Work, and has no relationship to the time within which the obligation to comply with the Contract Documents may be sought to be enforced, nor to the time within which proceedings may be commenced to establish the Contractor’s liability with respect to the Contractor’s obligations other than specifically to correct the Work.

§ 12.2.6 AUDITSUpon request of the Owner, the Contractor will cooperate, and secure the cooperation of all Subcontractors, suppliers and Sub-subcontractors, and assist the Owner during any audit of the Project conducted by the Owner at any time after Substantial Completion at no cost to the Owner. Such cooperation shall include providing the Owner with access to all records related to the Project.

Init.

/


47

§ 12.3 Acceptance of Nonconforming WorkIf the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.

ARTICLE 13 MISCELLANEOUS PROVISIONS§ 13.1 Governing LawThe Contract shall be governed by the law of the place where the Project is located, excluding that jurisdiction’s choice of law rules.

§ 13.2 Successors and Assigns§ 13.2.1 The Owner and Contractor respectively bind themselves, their partners, successors, assigns, and legal representatives to covenants, agreements, and obligations contained in the Contract Documents. Except as provided in Section 13.2.2, neither party to the Contract shall assign the Contract as a whole without written consent of the other. If either party attempts to make an assignment without such consent, that party shall nevertheless remain legally responsible for all obligations under the Contract.

§ 13.2.2 The Owner may, without consent of the Contractor, assign the Contract to a lender providing construction financing for the Project, if the lender assumes the Owner’s rights and obligations under the Contract Documents that arise subsequent to the effective date of such assignment. The Contractor shall execute all consents reasonably required to facilitate the assignment.

§ 13.3 Rights and Remedies§ 13.3.1 Duties and obligations imposed by the Contract Documents and rights and remedies available thereunder shall be in addition to and not a limitation of duties, obligations, rights, and remedies otherwise imposed or available by law or in equity.

§ 13.3.2 No action or failure to act by the Owner, Architect, or Contractor shall constitute a waiver of a right or duty afforded them under the Contract, nor shall such action or failure to act constitute approval of or acquiescence in a breach thereunder, except as may be specifically agreed upon in writing.

§ 13.3.3 No provision contained in the Contract Documents shall create or give to third parties any claim or right against the Owner or the Contractor except as specifically provided herein.

§ 13.4 Tests and Inspections§ 13.4.1 Tests, inspections, and approvals of portions of the Work shall be made as required by the Contract Documents and by applicable Legal Requirements. Unless otherwise provided, the Contractor shall make arrangements for such tests, inspections, and approvals with an independent testing laboratory or entity acceptable to the Owner, or with the appropriate public authority, and shall bear all related costs of tests, inspections, and approvals. The Contractor shall give the Architect timely notice of when and where tests and inspections are to be made so that the Architect may be present for such procedures. The Owner shall bear costs of tests, inspections, or approvals that do not become requirements until after bids are received or negotiations concluded. Unless otherwise provided in the Contract Documents, the Owner shall directly arrange and pay for tests, inspections, or approvals where building codes or applicable laws or regulations so require.

§ 13.4.2 If the Architect, Owner, or public authorities having jurisdiction determine that portions of the Work require additional testing, inspection, or approval not included under Section 13.4.1, the Architect will, upon written authorization from the Owner, instruct the Contractor to make arrangements for such additional testing, inspection, or approval, by an entity acceptable to the Owner, and the Contractor shall give timely notice to the Architect of when and where tests and inspections are to be made so that the Architect may be present for such procedures. Such costs, except as provided in Section 13.4.3, shall be at the Owner’s expense. If the inspections and tests conducted under Section 13.4.1 or this Section 13.4.2 reveal failure in a portion of the Work, the Owner may order the inspection and testing at the Contractor’s expense of any and all portions of the Work that are identical or similar to the failing portion.

Init.

/


48

§ 13.4.3 If procedures for testing, inspection, or approval under Sections 13.4.1 and 13.4.2 reveal failure of the portions of the Work to comply with requirements established by the Contract Documents, all costs made necessary by such failure, including those of repeated procedures and compensation for the Architect’s services and expenses, shall be at the Contractor’s expense.

§ 13.4.4 Required certificates of testing, inspection, or approval shall, unless otherwise required by the Contract Documents, be secured by the Contractor and promptly delivered to the Architect.

§ 13.4.5 If the Architect is to observe tests, inspections, or approvals required by the Contract Documents, the Architect will do so promptly and, where practicable, at the normal place of testing.

§ 13.4.6 Tests or inspections conducted pursuant to the Contract Documents shall be made promptly to avoid unreasonable delay in the Work.

§ 13.5 InterestPayments due and unpaid under the Contract Documents shall bear interest as provided in the Agreement.

§ 13.6 Background Checks § 13.6.1 Contractor shall comply with all applicable Legal Requirements including, without limitation, Connecticut General Statutes Section 222c, as applicable.

§ 13.6.2 The scope of the Work does not, and will not under any circumstances, require any contact with students. The Contractor, its subcontractors, and their respective employees, agents and representatives are hereby prohibited from making any verbal, physical, telephonic or electronic contract of any kind with any student or any other minor person on school property including, without limitation, the Project site, whether inside or outside of any school facility. The Contractor shall immediately remove any individual performing Work on the Project from school property and from the Project if it becomes known to the Contractor that such person may be a danger to the health or safety of the school community or its students, or at the request of the Owner, in its sole discretion. The Contractor shall include, and shall require its subcontractors to include, this section in all subcontracts for the Project.

§ 13.7 Confidential Information Any information obtained by the Contractor from the Owner or Architect may not be used, published, distributed, sold or divulged by the Contractor or its Subcontractor or Sub-subcontractors for such party’s own purposes or for the benefit of any person, firm, corporation or other entity other than the Owner, without the prior written consent of the Owner. Any information obtained by the Contractor of its Subcontractors or Sub-subcontractors that is designated by the Owner as confidential shall not be disclosed to any other parties without the prior written consent of the Owner.

ARTICLE 14 TERMINATION OR SUSPENSION OF THE CONTRACT§ 14.1 Termination by the Contractor§ 14.1.1 The Contractor may terminate the Contract if the Work is stopped for a period of 60 consecutive days through no act or fault of the Contractor, a Subcontractor, a Sub-subcontractor, their agents or employees, or any other persons or entities performing portions of the Work, for any of the following reasons:

.1 Issuance of an order of a court or other public authority having jurisdiction that requires all Work to be stopped;

.2 An act of government, such as a declaration of national emergency, that requires all Work to be stopped; or

.3 Because the Owner has repeatedly defaulted, beyond any applicable notice and cure periods, in its payment obligations to the Contractor under the Contract Documents .

§ 14.1.2 The Contractor may terminate the Contract if, through no act or fault of the Contractor, a Subcontractor, a Sub-subcontractor, supplier or any of their respective agents or employees, or any other persons or entities performing portions of the Work, repeated suspensions, delays, or interruptions of the entire Work by the Owner as described in Section 14.3, constitute in the aggregate more than 100 percent of the total number of days scheduled for completion, or 120 days in any 365-day period, whichever is less.

§ 14.1.3 If one of the reasons described in Section 14.1.1 or 14.1.2 exists, the Contractor may, upon seven days’ notice to the Owner and Architect, terminate the Contract and recover from the Owner payment pursuant to the Contract

Init.

/


49

Documents for Work executed in accordance with the Contract Documents, along with direct costs incurred by the Contractor reason of such termination.

§ 14.1.4 If the Work is stopped for a period of 60 consecutive days through no act or fault of the Contractor, a Subcontractor, a Sub-subcontractor, supplier or their agents or employees or any other persons or entities performing portions of the Work by or on behalf of any of them because the Owner has repeatedly failed to fulfill the Owner’s obligations under the Contract Documents with respect to matters important and critical to the progress of the Work, the Contractor may, upon seven additional days’ notice to the Owner and the Architect, terminate the Contract and recover from the Owner as provided in Section 14.1.3.

§ 14.1.5 The notice of termination delivered pursuant to Section 14.1.3 or 14.1.4 must state with specificity the means by which the Owner may cure its nonperformance, and the Contractor shall not terminate the Contract if, within the applicable ten (10) day period, the Owner substantially takes such curative measures.

§ 14.2 Termination by the Owner for Cause§ 14.2.1 The Owner may, without prejudice and without waiving any other rights or remedies the Owner may have, terminate the Contract if the Contractor

.1 repeatedly refuses or fails to supply enough properly skilled workers or proper materials;

.2 fails to make payment to Subcontractors or suppliers in accordance with the respective agreements between the Contractor and the Subcontractors or suppliers;

.3 repeatedly disregards applicable laws, statutes, ordinances, codes, rules and regulations, or lawful orders of a public authority;

.4 otherwise is guilty of substantial breach of a provision of the Contract Documents;

.5 institutes proceedings or consent to proceedings requesting relief or arrangement under the Federal Bankruptcy Act or similar or applicable federal or state law, or a petition under any federal or state bankruptcy or insolvency law is filed against the Contractor and such petition is not dismissed within sixty (60) days from the date of said filing, or the Contractor admits in writing its inability to pay its debts as they become due, or it makes a general assignment for the benefit of its creditors, or a receiver, liquidator, trustee, or assignee is appointed, or a receiver of all or any substantial portion of the Contractor’s properties is appointed;

.6 abandons the Work;

.7 submits an Application for Payment, sworn statement, waiver of lien, affidavit or document of any nature whatsoever which is intentionally falsified;

.8 fails to make prompt payment to Subcontractors or for materials or labor in accordance with the respective subcontracts or otherwise breaches its obligations under any subcontract with a Subcontractor; or

.9 disregards any provision of any lease with which the Contract Documents require the Contractor to comply, or

.10 if a mechanics or materialman’s lien or notice of lien is filed against any part of the Work or the Project site and the lien and underlying claim are not promptly resolved as under the Contract Documents.

§ 14.2.2 When any of the reasons described in Section 14.2.1 exist, the Owner may, without prejudice to any other rights or remedies of the Owner and after giving the Contractor and the Contractor’s surety, if any, seven days’ notice, terminate employment of the Contractor and may, subject to any prior rights of the surety:

.1 Exclude the Contractor from the site and take possession of all materials, equipment, tools, and construction equipment and machinery thereon owned by the Contractor;

.2 Accept assignment of subcontracts pursuant to Section 5.4; and

.3 Finish the Work by whatever reasonable method the Owner may deem expedient. Upon written request of the Contractor, the Owner shall furnish to the Contractor a detailed accounting of the costs incurred by the Owner in finishing the Work.

§ 14.2.3 When the Owner terminates the Contract for one of the reasons stated in Section 14.2.1, the Contractor shall not be entitled to receive further payment until the Work is finished.

§ 14.2.4 If the unpaid balance of the Contract Sum exceeds costs of finishing the Work, including compensation for the Architect’s services and expenses made necessary thereby, and other damages incurred by the Owner and not expressly waived, such excess shall be paid to the Contractor. If such costs and damages exceed the unpaid balance,

Init.

/


50

the Contractor shall pay the difference to the Owner. The amount to be paid to the Contractor or Owner, as the case may be, shall be certified by the Initial Decision Maker, upon application, and this obligation for payment shall survive termination of the Contract.

§ 14.2.5 Notwithstanding Section 14.2.4, if the Contract Sum is subject to a Guaranteed Maximum Price and the remaining balance of the estimate of the Cost of the Work included as a component of the Guaranteed Maximum Price net of any unused portion of the Construction Manager’s Contingency (the "Remaining Balance") exceeds the aggregate of (i) the Cost of the Work attributable to finishing the Work, (ii) the compensation for the Architect’s services and expenses made necessary thereby, and (iii) other damages incurred by the Owner and not expressly waived (such costs, compensation, expenses and damages, collectively, the "Completion Cost"), such excess shall be retained by the Owner. If the Completion Cost exceeds the Remaining Balance, the Contractor shall pay the difference to the Owner. The amount to be paid to the Contractor or Owner, as the case may be, shall be reviewed by the Architect. This obligation for payment shall survive termination of the Contract. The term "Construction Manager’s

Contingency" is defined in Section 2.2 of the Agreement.§ 14.3 Suspension by the Owner for Convenience§ 14.3.1 The Owner may, without cause and without prejudice and without waiving any other rights or remedies the Owner may have, order the Contractor in writing to suspend, delay or interrupt the Work, in whole or in part for such period of time as the Owner may determine.

§ 14.3.2 The Contract Sum and Contract Time shall be adjusted for increases in the cost and time caused by suspension, delay, or interruption under Section 14.3.1. Adjustment of the Contract Sum shall include profit. No adjustment shall be made to the extent

.1 that performance is, was, or would have been, so suspended, delayed, or interrupted, by another cause for which the Contractor is responsible; or

.2 that an equitable adjustment is made or denied under another provision of the Contract.

§ 14.4 Termination by the Owner for Convenience§ 14.4.1 The Owner may, at any time, terminate the Contract for the Owner’s convenience and without cause.

§ 14.4.2 Upon receipt of notice from the Owner of such termination for the Owner’s convenience, the Contractor shall.1 cease operations as directed by the Owner in the notice;.2 take actions necessary, or that the Owner may direct, for the protection and preservation of the Work;

and.3 except for Work directed to be performed prior to the effective date of termination stated in the notice,

terminate all existing subcontracts and purchase orders and enter into no further subcontracts and purchase orders.

§ 14.4.3 In case of such termination for the Owner’s convenience, the Owner shall pay the Contractor for Work properly executed in accordance with the Contract Documents and direct costs incurred by reason of the termination, including direct costs attributable to termination of Subcontracts.

ARTICLE 15 CLAIMS AND DISPUTES§ 15.1 Claims § 15.1.1 DefinitionA Claim is a demand or assertion by one of the parties seeking, as a matter of right, payment of money, a change in the Contract Time, or other relief with respect to the terms of the Contract. The term "Claim" also includes other disputes and matters in question between the Owner and Contractor arising out of or relating to the Contract. The responsibility to substantiate Claims shall rest with the party making the Claim. This Section 15.1.1 does not require the Owner to file a Claim in order to impose liquidated damages in accordance with the Contract Documents.

§ 15.1.2 Time Limits on ClaimsThe Owner and Contractor shall commence all Claims and causes of action against the other and arising out of or related to the Contract, whether in contract, tort, breach of warranty or otherwise, in accordance with the requirements of the binding dispute resolution method selected in the Agreement and within the period specified by applicable law, but in any case not more than 10 years after the date of Substantial Completion of the Work. The Owner and Contractor waive all Claims and causes of action not commenced in accordance with this Section 15.1.2.

Init.

/


51

§ 15.1.3 Notice of Claims§ 15.1.3.1 Claims by either the Owner or Contractor, where the condition giving rise to the Claim is first discovered prior to expiration of the period for correction of the Work set forth in Section 12.2.2, shall be initiated by notice to the other party and to the Initial Decision Maker with a copy sent to the Architect, if the Architect is not serving as the Initial Decision Maker. Claims by either party under this Section 15.1.3.1 shall be initiated within 21 days after occurrence of the event giving rise to such Claim or within 21 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later.

§ 15.1.3.2 Claims by either the Owner or Contractor, where the condition giving rise to the Claim is first discovered after expiration of the period for correction of the Work set forth in Section 12.2.2, shall be initiated by notice to the other party. In such event, no decision by the Initial Decision Maker is required.

§ 15.1.4 Continuing Contract Performance§ 15.1.4.1 Pending final resolution of a Claim, except as otherwise agreed in writing or as provided in Section 9.7 and Article 14, the Contractor shall proceed diligently with performance of the Work and its obligations under the Contract Documents and the Owner shall continue to make payments in accordance with the Contract Documents.

§ 15.1.4.2 The Contract Sum and Contract Time shall be adjusted in accordance with the Initial Decision Maker’s decision, subject to the right of either party to proceed in accordance with this Article 15. The Architect will issue Certificates for Payment in accordance with the decision of the Initial Decision Maker.

§ 15.1.5 Claims for Additional CostIf the Contractor wishes to make a Claim for an increase in the Contract Sum (or the Guaranteed Maximum Price, as applicable), notice as provided in Section 15.1.3 shall be given before proceeding to execute the portion of the Work that is the subject of the Claim. Prior notice is not required for Claims relating to an emergency endangering life or property arising under Section 10.4.

§ 15.1.6 Claims for Additional Time§ 15.1.6.1 If the Contractor wishes to make a Claim for an increase in the Contract Time, notice as provided in Section 15.1.3 shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.

§ 15.1.6.2 If adverse weather conditions are the basis for a Claim for additional time, such Claim shall be documented by data substantiating that weather conditions were abnormal for the period of time, could not have been reasonably anticipated, and had an adverse effect on the scheduled construction.

(Paragraphs deleted)§ 15.1.7 Intentionally Omitted.

§ 15.1.8 Notwithstanding anything to the contrary herein or in the Contract Documents, none of the Contract Sum, (or, as applicable, the Guaranteed Maximum Price), or the Contract Time shall be adjusted if the increased costs or delay underlying the Contractor’s claim for adjustment stems from the negligent act or omission of the Contractor, its subcontractors of any tier, or of anyone for whose performance the Contractor is responsible to the Owner, or as a result of the error of any of the same or of the failure of any of the same to comply with, and fulfill their responsibilities under, the Contract Documents.

§ 15.2 Initial Decision§ 15.2.1 Claims, excluding those where the condition giving rise to the Claim is first discovered after expiration of the period for correction of the Work set forth in Section 12.2.2 or arising under Sections 10.3, 10.4, and 11.5, shall be referred to the Initial Decision Maker for initial decision. The Architect will serve as the Initial Decision Maker, unless otherwise indicated in the Agreement. Except for those Claims excluded by this Section 15.2.1, an initial decision shall be required as a condition precedent to mediation of any Claim. If an initial decision has not been rendered within 30 days after the Claim has been referred to the Initial Decision Maker, the party asserting the Claim may demand mediation and binding dispute resolution without a decision having been rendered. Unless the Initial Decision Maker and all affected parties agree, the Initial Decision Maker will not decide disputes between the Contractor and persons or entities other than the Owner.

Init.

/


52

§ 15.2.2 The Initial Decision Maker will review Claims and within ten days of the receipt of a Claim take one or more of the following actions: (1) request additional supporting data from the claimant or a response with supporting data from the other party, (2) reject the Claim in whole or in part, (3) approve the Claim, (4) suggest a compromise, or (5) advise the parties that the Initial Decision Maker is unable to resolve the Claim if the Initial Decision Maker lacks sufficient information to evaluate the merits of the Claim or if the Initial Decision Maker concludes that, in the Initial Decision Maker’s sole discretion, it would be inappropriate for the Initial Decision Maker to resolve the Claim.

§ 15.2.3 In evaluating Claims, the Initial Decision Maker may, but shall not be obligated to, consult with or seek information from either party or from persons with special knowledge or expertise who may assist the Initial Decision Maker in rendering a decision. The Initial Decision Maker may request the Owner to authorize retention of such persons at the Owner’s expense.

§ 15.2.4 If the Initial Decision Maker requests a party to provide a response to a Claim or to furnish additional supporting data, such party shall respond, within ten days after receipt of the request, and shall either (1) provide a response on the requested supporting data, (2) advise the Initial Decision Maker when the response or supporting data will be furnished, or (3) advise the Initial Decision Maker that no supporting data will be furnished. Upon receipt of the response or supporting data, if any, the Initial Decision Maker will either reject or approve the Claim in whole or in part.

§ 15.2.5 The Initial Decision Maker will render an initial decision approving or rejecting the Claim, or indicating that the Initial Decision Maker is unable to resolve the Claim. This initial decision shall (1) be in writing; (2) state the reasons therefor; and (3) notify the parties and the Architect, if the Architect is not serving as the Initial Decision Maker, of any change in the Contract Sum (or the Guaranteed Maximum Price, as applicable) or Contract Time or both. The initial decision shall be final and binding on the parties but subject to mediation and, if the parties fail to resolve their dispute through mediation, to binding dispute resolution.

§ 15.2.6 Either party may file for mediation of an initial decision at any time, subject to the terms of Section 15.2.6.1.

§ 15.2.6.1 Either party may, within 30 days from the date of receipt of an initial decision, demand in writing that the other party file for mediation. If such a demand is made and the party receiving the demand fails to file for mediation within 30 days after receipt thereof, then both parties waive their rights to mediate or pursue binding dispute resolution proceedings with respect to the initial decision.

§ 15.2.7 In the event of a Claim against the Contractor, the Owner may, but is not obligated to, notify the surety, if any, of the nature and amount of the Claim. If the Claim relates to a possibility of a Contractor’s default, the Owner may, but is not obligated to, notify the surety and request the surety’s assistance in resolving the controversy.

§ 15.2.8 If a Claim relates to or is the subject of a mechanic’s lien, the party asserting such Claim may proceed in accordance with applicable law to comply with the lien notice or filing deadlines.

§ 15.3 Mediation§ 15.3.1 Claims, disputes, or other matters in controversy arising out of or related to the Contract, except those waived as provided for in Sections 9.10.4, 9.10.5, and 15.1.7, shall be subject to mediation as a condition precedent to binding dispute resolution.

§ 15.3.2 The parties shall endeavor to resolve their Claims by mediation which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Mediation Procedures in effect on the date of the Agreement. A request for mediation shall be made in writing, delivered to the other party to the Contract, and filed with the person or entity administering the mediation. The request may be made concurrently with the filing of binding dispute resolution proceedings but, in such event, mediation shall proceed in advance of binding dispute resolution proceedings, which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed for a longer period by agreement of the parties or court order. If an arbitration is stayed pursuant to this Section 15.3.2, the parties may nonetheless proceed to the selection of the arbitrator(s) and agree upon a schedule for later proceedings.

Init.

/


53

§ 15.3.3 Either party may, within 30 days from the date that mediation has been concluded without resolution of the dispute or 60 days after mediation has been demanded without resolution of the dispute, demand in writing that the other party file for binding dispute resolution. If such a demand is made and the party receiving the demand fails to file for binding dispute resolution within 60 days after receipt thereof, then both parties waive their rights to binding dispute resolution proceedings with respect to the initial decision.

§ 15.3.4 The parties shall share the mediator’s fee and any filing fees equally. The mediation shall be held in the place where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof.

§ 15.4 Arbitration§ 15.4.1 If the parties have selected arbitration as the method for binding dispute resolution in the Agreement, any Claim subject to, but not resolved by, mediation shall be subject to arbitration which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Arbitration Rules in effect on the date of the Agreement. The Arbitration shall be conducted in the place where the Project is located, unless another location is mutually agreed upon. A demand for arbitration shall be made in writing, delivered to the other party to the Contract, and filed with the person or entity administering the arbitration. The party filing a notice of demand for arbitration must assert in the demand all Claims then known to that party on which arbitration is permitted to be demanded.

§ 15.4.1.1 A demand for arbitration shall be made no earlier than concurrently with the filing of a request for mediation, but in no event shall it be made after the date when the institution of legal or equitable proceedings based on the Claim would be barred by the applicable statute of limitations. For statute of limitations purposes, receipt of a written demand for arbitration by the person or entity administering the arbitration shall constitute the institution of legal or equitable proceedings based on the Claim.

§ 15.4.2 The award rendered by the arbitrator or arbitrators shall be final, and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof.

§ 15.4.3 The foregoing agreement to arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by parties to the Agreement, shall be specifically enforceable under applicable law in any court having jurisdiction thereof.

§ 15.4.4 Consolidation or Joinder § 15.4.4.1 Subject to the rules of the American Arbitration Association or other applicable arbitration rules, either party may consolidate an arbitration conducted under this Agreement with any other arbitration to which it is a party provided that (1) the arbitration agreement governing the other arbitration permits consolidation, (2) the arbitrations to be consolidated substantially involve common questions of law or fact, and (3) the arbitrations employ materially similar procedural rules and methods for selecting arbitrator(s).

§ 15.4.4.2 Subject to the rules of the American Arbitration Association or other applicable arbitration rules, either party may include by joinder persons or entities substantially involved in a common question of law or fact whose presence is required if complete relief is to be accorded in arbitration, provided that the party sought to be joined consents in writing to such joinder. Consent to arbitration involving an additional person or entity shall not constitute consent to arbitration of any claim, dispute or other matter in question not described in the written consent.

§ 15.4.4.3 The Owner and Contractor grant to any person or entity made a party to an arbitration conducted under this Section 15.4, whether by joinder or consolidation, the same rights of joinder and consolidation as those of the Owner and Contractor under the Contract.


Weston High School

KGD2018-1010 00 70 01 - 1 Waiver of Lien Form

REQUISITION FOR PARTIAL PAYMENT - WAIVER OF LIENS

PROJECT OWNER

GENERAL CONTRACTOR SUBCONTRACTOR/VENDOR

CONTRACT WORK COMPLETE

PROJECT: CONTRACT - $

TRADE: CHANGE ORDERS - $

CONTRACT - $ TOTAL COMPLETE - $

CHANGE ORDERS - $ RETAINAGE (___%) - $

TOTAL CONTRACT - $ LESS PRE. REQ. - $

THIS REQUISITION - $

Waiver of Lien

The undersigned, upon receipt of the above requisition payment hereby releases and discharges the Owner of and from any liability or obligation in any way related to or arising out of this project up to and including the date of this document.

The undersigned further covenants and agrees that it shall not in any way claim or file a mechanic's or other lien against the premises of the above designated project, or any part thereof, or against any fund applicable thereto for any of the work, labor, materials heretofore furnished by it in connection with the improvement of said premises.

The undersigned further warrants that, in order to induce the Owner to release this partial payment, they have paid all claims for labor, material, insurance, taxes, equipment, etc., employed in the prosecution of the work above, to date of this requisition.

The undersigned hereby releases and agrees to hold the Owner harmless from any and all claims in connection with the furnishing of such labor and materials, etc., for the construction of the aforementioned project.

The undersigned further guarantees that all portions of the work furnished and/or provided by them are in accordance with the contract and that the terms of the contract with respect to these guarantees will hold for the period specified in said contract.

IN WITNESS WHEREOF, we have executed under seal this release on the above date and to be legally bound hereby:

WITNESS: _______________________________ FIRM: _________________________________

BY:_______________________________________


Weston High School

KGD2018-1010 00 70 01 - 2 Waiver of Lien Form

CORPORATE ACKNOWLEDGEMENT

)SS.)

On the ______________ day of ______________, before me came ____________________ to me known and who by me being duly sworn did depose and say that he resides at ___________________ _____________; that he is the officer of the said corporation executing the foregoing instrument, that he knows the seal of said corporation, that the seal affixed to said instrument is such corporate seal, that it was so affixed by order of the Board of Directors of said corporation and that he signed his name thereto by like order.

______________________________ Notary Public

INDIVIDUAL ACKNOWLEDGEMENT

State of)SS.)

County of

On the ___________ day of _________________, before me came _________________ to me known and who by me being duly sworn did depose and say that he resides at ________________________ ______________________________ that he is the individual who executed the foregoing instrument.

______________________________ Notary Public

PARTNERSHIP ACKNOWLEDGEMENT

State of)SS.)

County of

On the _________________ day of ________________, before me came _________________ to me known and who by me being duly sworn did depose and say that he resides at ___________________ ______________________; that he is the partner in the firm of ______________________________ doing business under the name of _______________________________ and that he executed the foregoing instrument on behalf of said partnership.

______________________________ Notary Public


Weston High School

KGD2018-1010 00 70 02 - 1 Insurance Rider

Section 00 50 02

Insurance Rider(Supplement to Article 17 of Section 00 50 00, AIA

A107-07 For Insurance Requirements for this Project)

Name of Insurance Producer:

Name of Insured:

The Contractor shall purchase and maintain during the life of the contract insurances as listed herein. This insurance must be purchased from a Connecticut State licensed, A.M. Best Rated "A" or "A+" carrier. The Owner, the Architect, their Consultants and Subconsultants shall, with the exception of Worker's Compensation and Employer's Liability Insurance, be named as additional named insureds on a primary and non-contributory basis. Contractor must submit additional insured endorsements to the District for approval.

At least ten (10) working days prior to the commencement of the Work, the Contractor and all Subcontractors shall submit to the Owner, through the Architect, a Certificate of Insurance (AIA Form G705) or Accord 25-s showing evidence of insurance coverage as required by these documents. The standard Accord Form of Certificate of Insurance or insurance carrier certificate will be acceptable for employer's liability and statutory Disability. Submit all Workers’ Compensation Certificates on form C-105.2.

All Certificates of Insurance must be signed by a licensed agent or authorized representative of the insurance carrier..

The certificate shall be issued to the Owner with a provision that in the event the policies are either canceled or diminished, at least 30 days prior notice thereof shall be given to the Owner.

The insurance required for this project shall be written for not less than limits of liability specified in this attachment or otherwise within the Contract Documents or required by law, whichever coverage is greater. Coverages, whether written on an occurrence or claims-made basis, shall be maintained without interruption from date of commencement of the Work until date of final payment and termination of any coverage required to be maintained after final payment.

.1 General Liability: (Occurrence Form) ) – Limits Per Project using ISO Form CG 00 01 07 98 or later date

$2,000,000 General Aggregate

$1,000,000 Products/Completed Operations

$1,000,000 Personal and Adv. Injury

$1,000,000 Occurrence

$ 50,000 Fire Damage

$ 5,000 Medical Expense

Coverage to include Broad Form Property Damage, Contractual Liability,

Independent Contractors, and Personal Injury. No exclusion for XCU or hazards

shall be endorsed to the Policy.


Weston High School


Products and Completed Operations Coverage to be kept in force for 12 months

after final payment; a renewal certificate is to be submitted for the project if the

coverage renews in less than 12 months following the completion of the project.

Coordinate requirements for additional insurance covering contractual obligations assumed by Contractor as established in AIA Document A101-2017, Exhibit A by using Endorsement ISO Form B, CG2010 11/85 or CG 20 10 10/01 plus CG 20 37 10/01 or equivalent. This endorsement must also reflect that the coverage provided is Primary and Non-Contributory. Waiver of Subrogation applies to all policies for all additional insureds.

.2 Auto Liability to cover ALL autos; or Owned, Hired, Leased and Non-Owned Autos.

$1,000,000 Combined Single Limit or

$ 500,000 Bodily injury (per person)

$1,000,000 Bodily injury (per accident)

$ 500,000 Property Damage

$ 5,000 Medical Payments

.3 Excess Liability: Insurance is to cover all stated insurance coverages listed within this Attachment

$2,000,000 Each Occurrence

$2,000,000 Aggregate

$ 10,000 Retention (Maximum)

.4 Workers' Compensation

Statutory Part A

Statutory Disability

Employer's Liability Part B

$ 500,000 Each Accident

$1,000,000 Disease Policy Limit

$ 500,000 Disease Each Employee

.5 Hazardous Material Coverage

Hazardous material liability insurance as follows:

$1,000,000 occurrence/$2,000,000 aggregate, including products and completed operations.

Such insurance shall include coverage for the Contractor's operations including, but not limited to, removal, replacement enclosure, encapsulation and/or disposal of asbestos, or any other hazardous material, along with any related pollution events, including coverage for third-party liability claims for bodily injury, property damage and clean-up costs. If a retroactive date is used, it shall pre-date the inception of the Contract.

If motor vehicles are used for transporting hazardous materials, the Contractor shall provide pollution liability broadened coverage (ISO endorsement CA 9948) as well as proof of M CS 90.

Coverage shall fulfill all requirements of the Contract and General Conditions and shall extend for a period of three (3) years following acceptance by the Owner of the Certificate of Completion.

.6 Testing Company Errors and Omission Insurance$1,000,000 Each Occurrence$2,000,000 Aggregatefor the testing and other professional acts of the Contractor performed under the contract with the Owner.


Weston High School


Further, Contractor shall require all Subcontractors to carry similar insurance coverages and limits of liability as set forth above and adjusted to the nature of Subcontractors' operations and submit same to Owner for approval prior to start of any Work.

Further, it is not the intention of these insurance requirements to require each Subcontractor, vendor or material man involved in the work to provide “excess” coverage in the amounts stated herein but the “excess” limit shall be at least 2 times the contract sum entered into between the individual Contractor and the particular Subcontractor, vendor or material man but not less than $1,000,000.00, each occurrence, $3,000,000 aggregate and $10,000 retention (Maximum).

In the event Contractor fails to obtain the required certificates of insurance from the Subcontractor and a claim is made or suffered, the Contractor shall indemnify, defend and hold harmless Owner, Architect, Engineers, Consultants and Subconsultants and their agents or employees from any and all claims for which the required insurance would have provided coverage. This indemnity obligation is in addition to any other indemnity obligation provided in the Contract.

The following shall be included as Additional Insured’s

The Town of Weston and the Weston Board of Education and any officer, member of its staff, employee, or representative of said Town and Board of Eduction.

Kaeyer, Garment and Davidson Architects and ALL consultants listed on the cover of the PROJECT/SPECIFICATIONS MANUAL

Proof of Insurance shall show the following Insured’s and Holder:

(a) Certificate Holder:

(b) Additional Named Insureds, on a primary basis:

The Town of Weston, CT.

Darien Public Schools

Architect

Consultants:


Weston High School

KGD2018-1010 01 10 00- 1 Description of Work

SECTION 01 10 00

DESCRIPTION OF WORK

1.01 GENERAL PROJECT DESCRIPTION

A. The scope of work of this project generally consists of the work involved with the Synthetic

Turf Replacement and related work at the Weston High School including, but not limited to:

Removal and legal disposal of the existing synthetic turf.

Removal, salvage and resetting of any field appliances.

Removal and replacement in-kind of football goalposts

Protection of existing concrete curb and jogging track and restoration of same at

completion of the work.

Cleaning and protection of perimeter trench drain system.

Removal, salvage and restoration of existing fencing to allow for access to the work

area.

Preparation of the staging area as required and restoration to “new” condition at

completion of the Work.

The field will be used for football (white lines), soccer (yellow Lines) and shall utilize

the National Federation of High School Design Standards for Field Hockey (Red lines),

Boys Lacrosse (Black Lines), and Girls Lacrosse (Royal Blue Lines). All lines should

be stitched into the carpet (not painted).

and the like all as depicted on the accompanying Contract Drawings and the Technical

Specifications.

B. Bids shall be received in accordance with the Connecticut State Public Bidding Laws, this

project will be executed under a Single CONTRACT.

C. Alternate proposals are solicited for the items of work as described on the drawings and

within specification Section 32 18 13.

D. Unit prices are solicited for the items of work as described on the proposal form.

E. Existing conditions are shown on the drawings to the best knowledge of the Architect. The

Architect, however, cannot guarantee the correctness of the existing conditions shown and

assumes no responsibility therefore. It shall be the responsibility of the Contractor to visit

the site and verify all existing conditions.

F. ADDITIONAL SECURITY PROVISIONS, COORDINATE WITH ARTICLE 3 OF SECTION

00 70 00 AND SECTION 01 15 01

1. All Contractors' employees shall use a single means of access and egress, except

in the case of emergency, to be designated by the General Contractor.

2. Each Contractor and each Subcontractor shall require his employees, while on the

job site, to wear, in a conspicuous location, an Photo I.D. badge bearing the name

of the individual and the Contractor for whom working. The badges of each

Contractor shall be numbered consecutively. An up-to-date list of all I.D. badges,

indicating the name and number along with a copy of the photograph for each

employee, shall be furnished to the Owner.

G. Regarding special inspections, (IF REQUIRED BY THE SCOPE OF THE PROPOSED

WORK), the registered design professional in responsible charge shall be the Architect.

The Owner shall hire the special inspectors and shall be responsible for the cost of special

inspections but the contractor is responsible for the cost of any re-inspections or retesting.

The Architect shall be responsible for determining the qualifications of the special

inspectors, receiving and retaining all reports and assuring that any discrepancies are

corrected.

Special inspectors must keep records of inspections and furnish inspection reports to the

Architect of record. The reports must indicate that the work inspected was done in


Weston High School


conformance with the approved construction documents. Discrepancies must be brought

to the attention of the contractor and non-corrected discrepancies must be brought to the

attention of the Architect of record. A final report of inspections documenting required

special inspections and correction of any discrepancies noted must be submitted to the

registered design professional in responsible charge at the completion of the project. The

design professional shall forward a copy of the final report to the school district for their

records.

1.02 REQUIREMENTS INCLUDED IN THIS SECTION

A. Asbestos and lead paint awareness requirements.

B. Construction time requirements and phasing if applicable.

C. Proof of orders and delivery dates

D. Intent of Documents

E. Field Measurements

F. Initial Submittal Requirements

G. Quality Requirements

H. Manufacturers Field Services and Reports

I. Coordination.

J. Field Engineering.

K. Job and Progress Meetings – See Section 01 31 19.

L. Design Responsibility

M. Schedules and Milestones

N. Additional Requirements

O. Mold Mitigation Requirements

P. Waste Management

Q. Payrolls and Payroll Records – Coordinate with Section 01 77 00

1.03 ASBESTOS AND LEAD PAINT AWARENESS REQUIREMENTS

A. Contractor agrees not to use or permit the use of any asbestos containing material in or on

any property belonging to the Owner.

B. For purposes of this requirement, asbestos free shall mean free from all forms of asbestos

including - actinolite, amosite, anthrophyhllite, chrysotile, cricidolite and tremolite both in

friable and non-friable states and without regard to the purposes for which such material is

used.

C. Reference Sections 02 41 20 (AS APPLICABLE TO THE PROJECT SCOPE) of these

documents for procedures and protocols to be followed in the event of discovery of

asbestos or lead paint contamination.

1.04 CONSTRUCTION TIME AND PHASING REQUIREMENTS

A. The Contractor is advised the "time is of the essence" of the Contract as defined in Article

8 of the "Conditions". It is understood that the work is to be carried through to completion

with the utmost speed consistent with good workmanship.

B. Further, safe and legal ingress and egress shall be maintained at all times to and through

the occupied portions of the construction site.

C. Attention is directed to Article 3.13 of Section 00 70 00 for use of site, temporary new work

and maintenance of legal egress at all times.

D. Work shall proceed in such a manner as to cause the least amount of disruption to the

ongoing operations as possible. COORDINATE CLOSELY WITH SCHOOL OPERATING

PERSONNEL.

E. All work and storage areas shall be completely enclosed by a fence or barricade at all

times so that no student or the public can approach the area or the equipment. The

Contractor shall maintain fences and barricades at all times and shall -


Weston High School


° Provide signs posted on fence 50 feet on center that read "Work Area - Keep Out".

° Maintain at all times, all exits and walkways from the Building.

Where the barricade is removed for work, the Contractor performing such work shall

provide adequate safety personnel to prevent unauthorized persons from approaching the

work area.

1.05 PROOF OF ORDERS AND DELIVERY DATES - Coordinate w/Section 01 33 00 and 01 32 00.

A. Within 2 weeks after the approval of shop drawings, samples, product data and the like,

the Contractor shall provide copies of purchase orders for all equipment and materials

which are not available in local stock. The Contractor shall submit written statements from

suppliers confirming the orders and stating promised delivery dates.

B. This information shall be incorporated within the progress schedules so required as part of

Section ( 01 33 00 ) (01 32 00 ) and shall be monitored so as to insure compliance with

promised dates.

1.06 INTENT OF DOCUMENTS - See Article 1, Subparagraph 1.2.1 of Section 00 70 00 for resolution

of conflicts between drawings and specifications.

Regardless of hierarchy listed in reference paragraph, in cases of conflict as to the type or

quality of materials to be supplied, the Specifications shall govern.

1.07 FIELD MEASUREMENTS

A. Contractor shall take all necessary field measurements prior to fabrication and installation

of work and shall assume complete responsibility for accuracy of same.

B. This project is an ALTERATION and therefore necessitates additional attention to existing

conditions receiving newly fabricated and installed equipment, i.e. note the requirements

for field dimensioning of shop fabricated items whether or not so required by each technical

section.

1.08 INITIAL SUBMITTAL REQUIREMENTS

A. As outlined in Sections 00 50 00, 00 70 00, 01 33 00, 01 32 00, 01 50 00 and 01 57 19

Contractor shall provide items noted including - bonds, insurance, emergency telephone

numbers, progress scheduling, schedules of submittals, subcontractor listings, and the like

prior to the start of any work.

B. Schedule of Values

1. Submit schedule on AIA Form G703.

2. Submit Schedule of Values in duplicate within 15 days after date of Owner-

Contractor Agreement or as established in Notice to Proceed, whichever is

earliest.

1.08 QUALITY REQUIREMENTS

A. Monitor quality control over suppliers, manufacturers, Products, services, site conditions,

and workmanship, to produce Work of specified quality.

B. Comply with manufacturer’s instructions.

C. Comply with specified standards as minimum quality for the Work except when more

stringent tolerances, codes, or specified requirements indicate higher standards or more

precise workmanship.

D. Monitor fabrication and installation tolerance control of installed Products over suppliers,

manufacturers, Products, site conditions, and workmanship, to produce acceptable Work.

Do not permit tolerances to accumulate.

E. Comply fully with manufacturer’s tolerances.


Weston High School


1.09 MANUFACTURER’S FIELD SERVICES AND REPORTS

A. When specified in individual specification sections, require material or Product suppliers or

manufacturers to furnish qualified staff personnel to observe site conditions and to initiate

instructions when necessary.

B. Report observations and site decisions or instructions that are supplemental or contrary to

manufacturer’s written instructions.

1.10 COORDINATION

A. Coordinate scheduling, submittals, and Work of various sections of specifications to ensure

efficient and orderly sequence of installation of interdependent construction elements.

B. Verify utility requirement characteristics of operating equipment are compatible with

building utilities.

C. Coordinate space requirements and installation of mechanical and electrical work indicated

diagrammatically on Drawings. Follow routing shown for pipes, ducts, and conduit, as

closely as practicable.

D. In finished areas, conceal pipes, ducts, and wiring within construction.

1.11 FIELD ENGINEERING – Coordinate with Section 01 71 23 of Division #1 AND Section 32 18 13.

A. Contractor shall establish elevations, lines, and levels and certify elevations and locations

of the Work conform with Contract Documents.

1.12 DESIGN RESPONSIBILITY – NOT APPLICABLE TO THIS CONTRACT

1.13 SCHEDULES AND MILESTONES

A. General

1. The objective of this project is to complete the overall work in the shortest period of

time and to protect the building and occupants from damages caused by weather

and construction activity during the progress of the work.

2. To meet these objectives, the Contractor shall plan the work, obtain materials, and

execute the construction on the most expeditious manner possible in accordance

with the requirements listed below.

3. If the Contractor fails to expedite and pursue any part of the work, the Owner may

terminate the contract as per Article 14.2 or may carry out the work as per Article

2.4 of the General Conditions.

4. The Contractor shall work in coordination with work of other Contractors and with

school activities with special attention to noise, dust, safety and other contract

requirements for work in and around the occupied buildings.

B. Work Period and Milestones

Construction Start 20 June 2018

Substantial Completion 13 August 2018

Final Completion inc. Warranties 5 September 2018

1.14 ADDITIONAL REQUIREMENTS

A. If it appears that some of the work cannot be completed by the scheduled date, the

Contractor shall increase the work force or increase the hours of work, including evenings

and weekends or necessary, at no additional cost to the Owner.

B. If the work is complete but the area is not cleaned and debris or equipment is not removed,

the Owner shall have the right to prepare the area for occupancy with his own forces and

deduct the costs from the Contract Amount.

C. If the Contractor fails to staff the job adequately to meet the completion date, the Owner

reserves the right to assume possession of the material and complete installation with the

Owner's forces or other Contractors or to require the Contractor to work evenings and


Weston High School


weekends.

D. The school can be made available on weekends and evenings to allow the Contractor

adequate time to complete the work before final completion date. Any custodial cost

resulting in this after hours scheduling will be the Contractor's responsibility.

E. In addition to the above-stated requirements for phasing of the work, the Contractors shall

not do any noisy work in the areas where examinations will be conducted as per the

published school calendar.

F. Work in each work period shall progress at least at a pace in proportion to the Contract

time available.

G. The Contractor is responsible for temporary protection of all work until acceptance.

H. The school will be closed on Saturdays, Sundays, regularly scheduled district holidays, and

at night after cleaning crews have finished. If any Contractor wishes to work at any time

when the school is normally closed, that Contractor shall arrange and pay for custodial

services for the building at the applicable district pay rates.

1.15 MOLD MITIGATION REQUIREMENTS (As applicable to Project Construction)

A. All return air ductwork and all exhaust air ductwork be sealed tight with mastic.

B. Do not allow open plenum returns above dropped ceilings unless the plenum is sealed

tightly with respect to the exterior walls and roof.

C. The buildings HVAC system shall not be operated during construction.

D. All gypsum wallboard be installed with a fire sealant bead of 3/8 in. (9 mm) between the

floor and the bottom edge of the gypsum, coordinate with Sections 07 84 00 and 09 29 00.

E. The moisture content (or water vapor emission rate) of all concrete block walls be

measured and documented by the general contractor, and that no gypsum board be hung

on those walls until the moisture content of the blocks in the wall measures the same as

the identical type of block that has been stored away from any rain exposure, coordinate

with Sections 04 20 00 and 09 29 00.

F. The moisture content of the taped and sanded gypsum board walls be measured and

documented by the general contractor at two locations on each wall: the bottom edge and

halfway between floor and ceiling. Interior finish may not be applied until the moisture

content of the wallboard is below 0.4% on a gypsum moisture meter or below 12% on a

wood meter, coordinate with Division 9 sections as applicable.

G. The moisture content of the concrete floor slab shall be measured as soon as the building

has been closed in and as soon as the slab temperature can be brought within the 65°F to

75°F (18.3°C to 23.9°C) temperature required for the measurement. If the moisture content

is excessive, the air above the concrete shall be held below 30% relative humidity until the

material is dry enough to meet the specification established by the respective flooring

manufacturers, coordinate with Division 9 sections as applicable.

H. Attention is directed to Sections 06 20 00, 09 51 00 and 09 90 00 for temperature and

humidity restrictions prior to start of work and maintenance of work conditions.

1.16 WASTE MANAGEMENT PROCEDURES AND DEFINITIONS

A. Waste Management Coordination: Coordinate recycling of materials with Owner and as

required to conform to the Construction Waste Management Plan defined in Section 01 74

19.

B. Contractor shall conduct Construction Waste Management meetings as outlined in Section

01 31 19 - Project Meetings. At a minimum, waste management goals and issues shall be

discussed at the following meetings:

1. Pre-bid meeting.

2. Pre-construction meeting.

3. Regular job-site meetings.

4. Job safety meetings.


Weston High School


C. Use on-site waste as primers, sealers, underlayments, supports, backing, blocking, furring,

suspension systems, and accessories as required for any purpose in patching work

damaged as a result of construction activities.

D. Waste Management Definitions

1. Clean: Untreated and unpainted; not contaminated with oils, solvents, caulk, or

the like.

2. Construction and Demolition Waste: Solid wastes typically including building

materials, packaging, trash, debris, and rubble resulting from construction,

remodeling, repair and demolition operations.

3. Hazardous: Exhibiting the characteristics of hazardous substances, i.e.,

ignitability, corrosivity, toxicity or reactivity.

4. Nonhazardous: Exhibiting none of the characteristics of hazardous substances,

i.e., ignitability, corrosivity, toxicity, or reactivity.

5. Nontoxic: Neither immediately poisonous to humans nor poisonous after a long

period of exposure.

6. Recyclable: The ability of a product or material to be recovered at the end of its

life cycle and remanufactured into a new product for reuse by others.

7. Recycle: To remove a waste material from the Project site to another site for

remanufacture into a new product for reuse by others.

8. Recycling: The process of sorting, cleansing, treating and reconstituting solid

waste and other discarded materials for the purpose of using the altered form.

Recycling does not include burning, incinerating, or thermally destroying waste.

9. Return: To give back reusable items or unused products to vendors for credit.

10. Reuse: To reuse a construction waste material in some manner on the Project

site.

11. Salvage: To remove a waste material from the Project site to another site for

resale or reuse by others.

12. Sediment: Soil and other debris that has been eroded and transported by storm or

well production run-off water.

13. Source Separation: The act of keeping different types of waste materials separate

beginning from the first time they become waste.

14. Toxic: Poisonous to humans either immediately or after a long period of exposure.

15. Trash: Any product or material unable to be reused, returned, recycled, or

salvaged.

16. Volatile Organic Compounds (VOCs): Chemical compounds common in and

emitted by many building products over time through outgassing including -

solvents in paints and other coatings; wood preservatives; strippers and household

cleaners; adhesives in particleboard, fiberboard, and some plywoods; and foam

insulation.

17. Waste: Extra material or material that has reached the end of its useful life in its

intended use. Waste includes salvageable, returnable, recyclable, and reusable

material.

18. Waste Management Plan: A Project-related plan for the collection, transportation,

and disposal of the waste generated at the construction site. The purpose of the

plan is to ultimately reduce the amount of material being landfilled.

1.17 PAYROLLS AND PAYROLL RECORDS – Coordinate with Section 01 77 00

A. Pursuant to Connecticut General Statutes § 7-112 and § 31-53 and applicable Article in the

General Conditions, every contractor and subcontractor must keep original payrolls or

transcripts subscribed and affirmed as true under penalty of perjury. Payrolls must be

maintained for at least three years from the project's date of completion. At a minimum,


Weston High School


payrolls must show the following information for each person employed on a public work

project:

1. Name

2. Classification(s) in which the worker was employed

3. Hourly wage rate(s) paid

4. Supplements paid or provided

5. Daily and weekly number of hours worked in each classification.

B. Every contractor and subcontractor shall submit, within thirty (30) days after issuance of its

first payroll and every thirty (30) days thereafter, a transcript of the original payrolls,

subscribed and affirmed as true under penalty of perjury.

**End of Section**


Weston High School

KGD2018-1010 01 15 01 - 1 Special Project Requirements

SECTION 01 15 01

SPECIAL PROJECT REQUIREMENTS

1.01 GENERAL

A. Requirements set forth herein are in addition to and shall be considered as complementary

to the Conditions of the Contract and the balance of Division #1 and Technical

Specifications.

B. All Contractors, Subcontractors, Sub-subcontractors, Vendors and the like shall be

required to familiarize themselves with said provisions.

C. All contractors, subcontractors, Sub-subcontractors, vendors and the like shall monitor

their workers and require that they adhere to the following safety provisions during all

construction and maintenance activities for the duration of the project.


A. Safe and Secure Storage of Construction Materials

B. Fencing – Project; Material storage areas; Container/Refuse areas

C. Gates – Manned during working hours; locked and secure off hours.

D. Temporary partitions – separation of construction areas from occupied spaces;

construction, materials, inspection and maintenance.

E. Debris removal.

F. Exiting

G. Fire and hazard prevention

H. No Smoking

I. Fire extinguishers

J. Smoke detectors (temporary)

K. Fire watch and maintenance of existing fire alarm systems

L. Storage of gas and welding equipment

M. Noise abatement procedures

1.03 SAFE AND SECURE STORAGE OF CONSTRUCTION MATERIALS – Coordinate with Sections

01 50 00 and 01 61 00 each as included with these documents.

A. Materials stored on the Site shall be neatly arranged and protected, and shall be stored in

an orderly fashion in locations that shall not interfere with the progress of the Work.

NOTE: If approval is given to store materials in any part of the building area, they shall be

so stored as to cause no overloading of the structure.

1.04 FENCING – PROJECT; MATERIAL STORAGE AREAS; CONTAINER/REFUSE AREAS –

Coordinate with Section 01 50 00

A. Barrier fencing constructed as outlined in Section 01 50 00 shall be provided surrounding

all work areas, material storage locations and around dumpsters and/or chutes when

involved with demolition/removal operations.

B. Fencing shall be maintained in good sound condition throughout the entire course of

construction by the Owner’s Representative and/or Contractor and removed only when

directed by the Architect and/or Owner’s Representative.

1.05 GATES

A. Gates in construction fencing shall be of construction outlined in Section 01 50 00 and

shall be under either the Owner’s Representative or Contractors’ supervision throughout

the work day and shall be secured in a locked condition at the close of any single business

day and on all non work days. Gates shall be manned at all times work is in progress.


Weston High School


1.06 TEMPORARY PARTITIONS – SEPARATION OF CONSTRUCTION AREAS FROM OCCUPIED

SPACES; CONSTRUCTION, MATERIALS, INSPECTION AND MAINTENANCE – Coordinate with

Section 01 50 00 as applicable to project type.

A. Provide temporary partitions from floors to underside of structure above, in sash and any

other openings created by new construction, additions and alterations.

B. Such partitions shall be constructed dust-tight using steel studs and acoustically

and/or thermally insulated, Level 1 taped fire rated gypsum board as specified in

Section 09 29 00.

C. Locate enclosures as directed by the Architect and/or as shown on the drawings.

D. In addition to partitions and closures, provide tight fitting filters over all return air grilles

and/or open ducts in order to properly protect central air handling equipment.

E. Take all necessary precautions to avoid unnecessary dust spreading to adjoining rooms

and spaces.

F. Keep all doors to spaces closed and provide positive seals around cracks, frames, doors

and other openings within work areas.

G. All temporary enclosures/partitions/containment barriers shall be periodically inspected

and maintained in good repair so as to prevent exposure to dust and contaminants outside

the work and/or containment areas.

1.07 DEBRIS REMOVAL – Coordinate with Sections 01 50 00, 01 77 00 and 02 41 19.

A. Large amounts of debris must be removed by use of enclosed chutes or similar systems.

There shall be no movement of debris through corridors of occupied spaces of the

building. No materials shall be dropped or thrown outside the walls of the building.

B. All occupied parts of the building or buildings affected by renovation activity shall be

cleaned at the close of each work day.

C. School buildings occupied during any construction period shall maintain required health,

safety and educational capabilities at all times that classes are in session.

1.08 EXITING

A. At all times, the General Contractor is responsible for maintenance of safety and egress

requirements from work areas. NOTE: All legal forms of egress must be maintained at all

times.

1.09 FIRE AND HAZARD PREVENTION – See Section 01 50 00 for requirements for fire watches,

storage and maintenance of welding gasses and temporary heating and the like.

1.10 NO SMOKING – No smoking is permitted on the grounds or within the construction area of any

project.

1.11 FIRE EXTINGUISHERS – Fire extinguishers shall be provided within the work area and shall be

monitored on a scheduled maintenance basis and so tagged to indicate same.

1.12 FIRE WATCH AND MAINTENANCE OF EXISTING FIRE ALARM SYSTEMS – See Section 01 50

00

A. All Contractors shall comply with the safety provisions of the National Fire Protection

Association's "National Fire Codes" pertaining to the work and, particularly, in connection

with any cutting or welding performed as part of the work.

B. During welding or cutting operations, a contractor's man shall act as a fire watcher. The

fire watcher shall have proper eye protection and suitable fire fighting equipment including

fire extinguisher (bearing current inspection Certificate), protective gloves and any other

equipment deemed necessary.

C. The Electrical Specialty Contractor will provide for and maintain the proper operation of fire

alarm and smoke detection systems in all areas throughout the course of the project. The


Weston High School


Electrical Specialty Contractor will provide all labor and material required to accomplish

this in occupied areas of the school buildings and in areas under construction.

1.13 STORAGE OF GAS AND WELDING EQUIPMENT – See Section 01 50 00 for specific

requirements and controls.

1.14 NOISE ABATEMENT PROCEDURES

A. Develop and maintain a noise abatement program and enforce strict discipline over all

personnel to keep noise to a minimum. Equipment and work shall not produce noise in

excess of 60db in occupied areas or shall be scheduled for off hours or acoustical

abatement procedures shall be taken. Noise level measurements (dba) shall be taken with

a type 2 sound level meter in the occupied space in a location closest to the source of the

noise.

B. Execute construction work by methods and by use of equipment which will reduce excess

noise.

C. Equip air compressors with silencers, and power equipment with mufflers.

D. As established in Section 01 10 00, all contractors shall abide by the “no work” periods

designated by the Owner.

**End of Section**


Weston High School

KGD2018-1010 01 25 00 - 1 Product Options

SECTION 01 25 00

PRODUCT OPTIONS AND SUBSTITUTIONS

1.01 GENERALA. Requirements set forth herein are in addition to and shall be considered as complementary

to the Conditions of the Contract and the balance of Division #1 and Technical Specifications.

B. All Contractors, Subcontractors, Sub-subcontractors, Vendors and the like shall be required to familiarize themselves with said provisions.

1.02 REQUIREMENTS INCLUDED IN THIS SECTIONA. Approved Equal ClauseB. Substitution RequestsC. OptionsD. Contractor's RepresentationE. Reimbursements

1.03 APPROVED EQUAL CLAUSEA. Throughout the Specifications, types of material may be specified by manufacturer's name

and catalog number in order to establish standards of quality and performance and not for the purpose of limiting competition. Inclusion by name, of more than one manufacturer or fabricator, does NOT necessarily imply acceptability of standard products of those named. All manufacturers, named or proposed, shall conform, with modification as necessary, to criteria established by Contract Documents for performance, efficiency, materials and special accessories.

B. Contractor may assume the phrase "or approved equal" except that the burden is upon the Contractor to prove such equality and to satisfy Architect that proposed substitute is equal to, or superior to, the item specified.

1.04 SUBSTITUTION REQUESTSA. If the Contractor elects to prove such equality, he must request the Architect's and the

Owner's approval in writing for substitution of such items for the specified items, stating the differences involved with and submitting supporting data and samples, if required, to permit a fair evaluation of the proposed substitution with respect to - 1. Performance;2. Delivery times and effect on schedules, if any;3. Safety;4. Function;5. Appearance;6. Quality and durability;7. Any required license fees or royalties;8. Warranty terms and conditions;The contractor shall submit a separate request for each product, supported with complete data, with drawings and samples as are appropriate to substantiate the above.

B. The Architect, as set forth in the Post Bid Requirements in Section 00 21 00, will review requests for substitutions with reasonable promptness, and notify the Contractor, in writing, of the decision to accept or reject the requested substitution.

1.05 OPTIONS


Weston High School

KGD2018-1010 01 25 00 - 2 Product Options

A. Where Technical Specifications permit Contractor to select optional materials, items, systems, or equipment, the selection of such options is subject to the following conditions:1. Once an option has been selected and approved, it shall be used for the entire

contract.2. The Contractor shall coordinate his selection with the drawings and specifications

and make all necessary adjustments without additional cost to the Owner.

1.06 CONTRACTOR'S REPRESENTATIONA. A request for a substitution constitutes a representation that the Contractor:

1. Has investigated the proposed product and determined that it is equal to or superior in all respects to that specified;

2. Will provide the same warranties or bonds for the substitution as for the product specified;

3. Will coordinate the installation of an accepted substitution in the work, and make such other changes in the work as may be required for installation to make the work complete in all respects;

4. Will waive all claims for additional costs, under its responsibility, which may subsequently become apparent.

5. Will have coordinated installation with all affected trade contractors,

specialty contractors and the like and will be responsible for any and all

costs which may arise as a result of this substitution.

1.07 REIMBURSEMENTSA. As outlined in Section 01 33 00, when resubmittals of materials, equipment and

accessories to be incorporated in the project are necessary due to failure of Contractors to properly coordinate submittals, the submitting Contractor shall compensate the Design Professionals for required re-reviews of said submittals in accordance with the following fee schedule:

Principal's Time -------------------------- $ 225.00 per hourAssociate's Time -------------------------- $ 155.00 per hourEmployees Time ------- Direct Personnel Expenses X 3.0

Engineer's Time --------------------------- $ 175.00 per hour

The charges incurred will be deducted from the ensuing requisition at the direction of the Owner.

**End of Section**


Weston High School

KGD2018-1010 01 25 01 - 1 Substitution Request

SUBSTITUTION REQUEST FORM

To: Project:

Section Page Paragraph Specified Item

THE UNDERSIGNED REQUESTS CONSIDERATION OF THE FOLLOWING SUBSTITUTION:

Attached data shall include, in a tabular format to provide a line by line comparison - product description, specifications,

drawings, photographs, performance and laboratory tests and the like with applicable portions of said data clearly

identified.

FURTHER, The Proposed Substitution WILL (OR WILL NOT) Affect:Dimensions indicated on the drawings?_____________________________________________________

Wiring, piping, ductwork, or other building services indicated on the drawings?____________________

Other trades and abutting or interconnection work? ___________________________________________

Manufacturer's guarantees and warranties? _________________________________________________

The construction schedule? ______________________________________________________________

Maintenance and service parts locally available? _____________________________________________

(NOTE - If Substitution WILL affect any item above, explain in detail.)

In addition to the above, the undersigned agrees to pay for -1. Any and all changes to the building design, including structural, civil or

electro/mechanical systems engineering (if any), detailing; and

2. Any and all additional construction costs caused by the requested substitution.

The undersigned further states that the function, appearance and quality of the Proposed Substitution are equivalent or superior to the Specified Item.

SUBMITTED: DESIGN PROFESSIONAL'S COMMENTS

By: Accepted Accepted as Noted

Firm: _ Not Accepted Received Too Late

Address:

By:

Date: Date:

Telephone/Fax: Remarks:

Approved For Subcontractor Submittal:

By: Contractor: Date:


Weston High School

KGD2018-1010 01 29 00 - 1 Applications for Payment

SECTION 01 29 00

APPLICATIONS FOR PAYMENT

1.01 GENERAL A. Requirements set forth herein are in addition to and shall be considered as complementary

to the Conditions of the Contract and the balance of Division #1 and Technical Specifications.

B. This Section specifies administrative and procedural requirements governing the Contractor's Applications for Payment, and supplements provisions of Article 9 of AIA A201 and further, pursuant to Connecticut General Statutes § 49-41b The Town of New Canaan shall not withhold more than 5% from any periodic or final payment which is otherwise properly due to the Contractor under the terms of the contract, and the Contractor shall not withhold more than 5% from any periodic or final payment which is otherwise due to any subcontractor.

C. Further, pursuant to Connecticut General Statutes § 49-41a: (1) The Contractor, within thirty days after payment to the Contractor by the Town of

New Canaan, shall pay any amounts due any subcontractor, whether for labor performed or materials furnished, when the labor or materials have been included in a requisition submitted by the Contractor and paid by the Town.

(2) The Contractor shall include in each of its subcontracts a provision requiring each subcontractor to pay any amounts due any of its subcontractors, whether for labor performed or materials furnished, within thirty days after such subcontractor receives a payment from the Contractor which encompasses labor or materials furnished by such subcontractor.

1.02 SCHEDULE OF VALUES – Article 9, AIA A201.A. Coordination: Contractor shall coordinate preparation of its Schedule of Values for the

Work with preparation of the Contractors' Construction Schedule.1. Correlate line items in the Schedule of Values with other required administrative

schedules and forms, including:a. Contractor's Construction Schedule.b. Application for Payment forms, including Continuation Sheets.c. List of subcontractors.d. Schedule of alternates.e. Schedule of allowancesf. List of products.g. List of principal suppliers and fabricators.h. Schedule of submittals.

2. Submit the Schedule of Values to the Architect at the earliest possible date but no later than seven (7) days before the date scheduled for submittal of the initial Applications for Payment.

3. Subschedules: Where Work is separated into phases requiring separately phased payments, provide subschedules showing values correlated with each phase of payment.

B. Format and Content: Use the Project Manual Table of Contents as a guide to establish the format for the Schedule of Values. Provide at least one line item for each Specification Section. For major trades with total line items exceeding $25,000, provide a separate, back-up breakdown of each such trade with line items for identifiable units of work within such trade each of which has a value not exceeding $25,000. Provide a computed unit price for each line total.1. Identification: Include the following Project identification on the Schedule of

Values:


Weston High School


a. Project name and location.b. Name of the Architectc. Project number.d. Contractor's name and address.e. Date of submittal.

2. Arrange the Schedule of Values in tabular form with separate columns to indicate the following for each item listed:a. Related Specification Section or Division.b. Description of Work.c. Name of subcontractor.d. Name of manufacturer or fabricator.e. Name of supplier.f. Change Orders (numbers) that affect value.g. Dollar value.h. Percentage of Contract Sum to nearest one-hundredth percent, adjusted

to total 100 percent.

NOTE: Margins of Cost: Show line items for indirect costs and margins on actual costs only when such items are listed individually in Applications for Payment. Each item in the Schedule of Values and Applications for Payment shall be complete. Include the total cost and proportionate share of general overhead and profit margin for each item.

3. Provide a breakdown of the Contract Sum by Phase Area in sufficient detail to facilitate continued evaluation of Applications for Payment and progress reports. Coordinate with the Project Manual table of contents. Break principal subcontract amounts down into several line items.

4. Round amounts to nearest whole dollar; the total shall equal the Contract Sum.5. Provide a separate line item in the Schedule of Values for each part of the Work

where Application for Payment may include materials or equipment, purchased or fabricated and stored, but not installed. Differentiate between items stored on-site and items stored off-site. Include requirements for insurance and bonded warehousing, if required.

6. Provide separate line items on the Schedule of Values for initial cost of the materials, for each subsequent stage of completion, and for total installed value of that part of the Work.

7. Unit Price Work: Show the line-item value of unit-cost allowances, as a product of the unit multiplied by the measured quantity. Estimate quantities from the best indication in the Contract Documents.

8. Temporary facilities, clean up and other major cost items and correction of existing conditions are not direct cost of actual work-in-place may be shown either as separate line items in the Schedule of Values or distributed as general overhead expense, at the Contractor's option.

9. Schedule Updating: Update and resubmit the Schedule of Values prior to the next Application for Payment when Change Orders result in a change in the Contract Sum.

1.03 APPLICATIONS FOR PAYMENT - See Article 9 of AIA A201.A. Each Application for Payment shall be consistent with previous applications and payments

as certified by the Architect and paid for by the Owner. The initial Application for Payment, the Application for Payment at time of Substantial Completion and the final Application for Payment involve additional requirements.


Weston High School


B. Payment-Application Times: Each progress-payment date is indicated in the Agreement. The period of construction Work covered by each Application for Payment is the period indicated in the Agreement or in absence thereof the previous month.

C. Payment-Application Forms: Use AIA Document G702 and Continuation Sheets G703 as the form of Applications for Payment.

D. Application Preparation: Complete every entry on the form. Include notarization and execution of person authorized to sign legal documents on behalf of the Contractor. The Architect will reject, and return, incomplete applications without action.1. Entries shall match data on the approved Schedule of Values and the Contractor's

Construction Schedule. Update schedules if revisions were made.2. Include amounts of Change Orders and Construction Change Directives issued

prior to the last day of the construction period covered by the application.3. Provide copies of payrolls which are signed and notarized documenting

compliance with prevailing wage laws as applicable to particular project.E. Transmittal: Submit three (3) signed and notarized original copies of each Application for

Payment to the Architect by a method ensuring receipt within 24 hours. One copy shall be complete, including waivers of lien and similar attachments, when required. Transmit each copy with a transmittal form listing attachments and recording appropriate information related to the application, in a manner acceptable to the Architect.

F. Waivers of Mechanics Lien: With each Application for Payment, submit waivers of mechanics liens from subcontractors, sub-subcontractors and suppliers for the construction period covered by the previous application.1. Submit partial waivers on each item for the amount requested, prior to deduction

for retainage, on each item.2. When an application shows completion of an item, submit final or full waivers.3. The Owner reserves the right to designate which entities involved in the Work

must submit waivers. Submit final Applications for Payment with or preceded by final waivers from every entity involved with performance of the Work covered by the application who is lawfully entitled to a lien.

4. Waiver Forms: Submit waivers of lien on forms, and executed in a manner, acceptable to the Owner and/or as included as attachment to Section 00 70 00.

G. Initial Application for Payment: Administrative actions and submittals, that must precede or coincide with submittal of the first Application for Payment, shall include the following prerequisites to processing:1. List of subcontractors, approved.2. List of principal suppliers and fabricators, approved.3. Schedule of Values, approved.4. Contractor's Construction Schedule, approved.5. Schedule of principal products.6. Schedule of unit prices, approved.7. Submittal Schedule, approved.8. List of Contractor's staff assignments.9. List of Contractor's principal consultants.10. Copies of building permits as applicable to project requirements.11. Copies of authorizations and licenses from governing authorities for performance

of the Work.12. Initial progress report.13. Report of pre-construction meeting.14. Certificates of insurance and insurance policies.15. Performance and payment bonds.16. Data needed to acquire the Owner's insurance.17. Initial settlement survey and damage report, if required by particular project.18. Safety plan


Weston High School


H. Monthly Application for Payment Administrative actions and submittals, that must precede or coincide with submittal of the periodic Application for Payment, shall include the following:1. As-built Record documents, required documents and submittal records on site.2. Contractor's construction schedule, updated, with corrective action plan as

applicable.3. Material Status Report.4. Stored Materials forms.5. Submittal Schedule and submittal status reports.6. Monthly Progress report, and Notarized Progress Report Statement from the each

Contractor’s manager/superintendent stating that the work is on schedule, and that Contractor will meet the Substantial Completion date for the Work, and the Substantial Completion dates for every portion established under Construction Phasing Schedule Section.

I. Application for Payment at Substantial Completion: Following issuance of the Certificate of Substantial Completion, submit an Application for Payment.1. This application shall reflect Certificates of Partial Substantial Completion issued

previous to Owner occupancy of designated portions of the Work.2. Administrative actions and submittals that shall precede or coincide with this

application include:a. Occupancy permits and similar approvals.b. Warranties (guarantees) and maintenance agreements.c. Test/adjust/balance records.d. Maintenance instructions.e. Meter readings.f. Startup performance reports.g. Changeover information related to Owner's occupancy, use, operation,

and maintenanceh. Final cleaning.i. Application for reduction of retainage and consent of surety.j. Advice on shifting insurance coverages.k. Final progress photographs.l. List of incomplete Work, recognized as exceptions to Architect's Certificate

of Substantial Completion.J. Final Payment Application: Administrative actions and submittals that must precede or

coincide with submittal of the final Application for Payment include the following:1. Completion of Project closeout requirements.2. Completion of items specified for completion after Substantial Completion.3. Ensure that unsettled claims will be settled.4. Ensure that incomplete Work is not accepted and will be completed without undue

delay.5. Transmittal of required Project construction records to the Owner.6. Certified property survey as and/if required by project documents.7. Proof that taxes, fees, and similar obligations were paid.8. Removal of temporary facilities and services.9. Removal of surplus materials, rubbish, and similar elements.10. Consent of Surety to final payment.

Part 2 - PRODUCTS - NOT USED

Part 3 - EXECUTION - NOT USED

**End of Section**


Weston High School


am an officer with the title of ______________________

in the firm of __________________________and am authorized by that firm to sign and swear, under penalty

of perjury, to the validity and accuracy of the statements below.

(1) I pay or supervise the payment of laborers, workers and mechanics employed by ____________

on the

project. During the payroll period commencing on the day of ____________ 20___ and ending the

day of ___________ 20_______ all laborers, workers and mechanics employed on said project

were paid the wages and supplements recorded as earned on the attached payroll records. No deductions have

been made either directly or indirectly from the wages and supplements other than deductions shown on the

payroll records.

(2) The payroll records submitted for the above project and attached hereto are correct and complete,

and the wage rates for laborers, workers, and mechanics contained therein are not less than the applicable

wage rates stated in the Contract and as designated by the State Labor Department. The number of hours

shown for each employee reflects the actual hours worked by that employee. The classification shown for each

employee is accurate and conforms with the work he or she performed.

(3) Supplements required in the Contract that are in addition to the basic hourly wages have been or

will be paid to the appropriate plans, funds or programs.

(4) Such statement so to be filed shall be verified by the oath of the Contractor that he or she has read

such statement subscribed by him or her and knows the content thereof, and that the same is true of his or her

own knowledge except with respect to wages and supplements owing by subcontractors which may be

certified upon information and belief.

(5) All employees of this firm have submitted completed Form I-9, Employment Eligibility Verification

Form which has been reviewed and signed by authorized representatives of the firm and are kept in the

employees' file. Also, any and all subcontractors have certified to us that all of their employees have submitted

completed Form I-9 Employment Eligibility Verification Form, which have been reviewed and signed by authorized

representatives of the firm and are kept in the employees' file.

By: Firm

Name

Title:

Firm

Date: Address

Prime NOTARY

Subcontractor

PAYROLL CERTIFICATION


Weston High School

KGD2018-1010 01 31 13 - 1 Project Coordination

SECTION 01 31 13

PROJECT COORDINATION

1.01 GENERAL



Specifications.




A. Coordination of Work

B. Trade Contractor Obligations

1.03 COORDINATION OF WORK

A. As required by the General Conditions, and restated herein, each Trade and/or Specialty

Contractor or Subcontractor shall compare the architectural, structural, civil/site,

mechanical and electrical Drawings and Specifications with those for all other trades and

shall report any discrepancies between them to the Architect, thru the General Contractor,

and obtain from him written instructions for changes necessary to the work. All work shall

be installed in cooperation with other trades installing interrelated work. Before installation,

each Trade Contractor shall make proper provisions to avoid interference in a manner

approved by the Architect. All changes required in the work caused by neglect to so

advise the Architect shall be made by the offending Contractor at his own expense.

B. Each Trade Contractor shall be responsible for exact location of anchor bolts, sleeves,

inserts, supports, chases, conduits and openings that may be required for the work.

Attention is directed to Section 01 31 14. Each Trade Contractor shall prepare layout

drawings for incorporation of items to be built-in the work, pass through the work and the

like in sufficient time so as not to cause any undue delay in the execution of the work.

Built-in items shall be furnished under the same Section of the Specifications as the

respective items to be supported, and they shall be installed, except as otherwise

specified, by the trade furnishing and installing the material in which they are to be located.

The trade responsible for the installation of anchor bolts shall also insure that they are

properly installed. Chases, conduits and openings shall be laid out in advance to permit

provision in work. Sleeves and inserts shall not be used in any portion of the building,

where their use would impair strength or construction features of the building. Sleeves,

conduits and inserts shall be set in forms before concrete is poured. Extra work required

where anchor bolts, supports, sleeves, chase openings, conduits or inserts have been

omitted or improperly placed shall be performed at expense of trade which made error or

omission.

C. Slots, chases, openings and recesses through floors, walls, ceilings and roofs as specified

will be provided for the various trades in their respective materials under general

construction work, but the trade requiring them shall see that they are properly located and

shall do any cutting and patching caused by the neglect to do so.

D. Locations of pipes, ducts, electrical raceways, switches, panels, equipment, fixtures, etc.

shall be adjusted to accommodate the work to interferences anticipated and encountered.

Each Trade Contractor shall determine, and submit for approval, the exact route and

location of each pipe, duct and electrical raceway prior to fabrication. Approval by the

Architect is required prior to any such modifications.

E. Contractor shall provide temporary weathertight and protected openings in structure to

facilitate placement of equipment.


Weston High School

KGD2018-1010 01 31 13 - 2 Project Coordination

1.04 TRADE CONTRACTOR OBLIGATIONS

A. The Trade Contractors are required to supply all necessary supervision and coordination

information to any other trades who are supplying work to accommodate the electrical and

mechanical installations.

B. Where a trade is required to install items which it does not purchase, it shall include for

such items:

1. The coordination of their delivery.

2. Their unloading from delivery trucks driven in to any designated point on the

property line at grade level.

3. Their safe handling and field storage up to the time of permanent placement in the

project.

4. The correction of any damage, defacement or corrosion to which they may have

been subjected.

5. Their field assembly and internal connection as may be necessary for their proper

operation.

6. Their mounting in place including the purchases and installation of all dunnage

supporting members and fastenings necessary to adapt them to architectural and

structural conditions unless support members are shown on structural or

architectural drawings.

7. Their connection to building systems including the purchase and installation of all

terminating fittings necessary to adapt and connect them to the building systems.

C. Items which are to be installed but not purchased as part of the work of a particular trade

shall be carefully examined by this trade upon delivery to the project. Claims that any of

these have been received in such condition that their installation will require procedures

beyond the reasonable scope of the work of the installing trade will be considered only if

presented in writing within one week of the date of delivery to the project of the items in

question. The work of the installing trade shall include all procedures, regardless of how

extensive, necessary to put into satisfactory operation, all items for which no claims have

been submitted as outlined above.

**End of Section**


Weston High School

KGD2018-1010 01 31 14 - 1 Coordination Drawingsand Procedures

SECTION 01 31 14

COORDINATION DRAWINGS AND PROCEDURES

1.01 GENERAL



Specifications.



C. Coordination of the work shall be performed as outlined below.


A. Scheduling (Coordinate with Section 01 32 00)

B. Coordination Drawings and Procedures - General Construction Work

C. Coordination Drawings and Procedures - Mechanical/Electrical Work

D. Meetings

E. Penalties

1.03 SCHEDULING

A. Development of coordination drawings shall begin immediately upon award and shall not

be dependent upon structural shop drawings; development shall be based upon structural

information included on the Contract Documents.

B. HVAC trade/sub contractor shall provide initial drawings as indicated in Article 1.05 herein

within three (3) weeks of issuance of Letter or Intent or Contract, whichever is earliest.

Time to complete all drawings may vary based upon size and complexity of project.

C. Each subsequent contractor, as listed in 1.05.E shall complete their work within two (2)

weeks of receipt of the coordination drawings.

D. Progress of coordination drawings must be reported at every project meeting until

accepted.

1.04 COORDINATION DRAWINGS AND PROCEDURES

Attention is directed to this Section for coordination drawing requirements for this project.

These drawings are critical to the proper execution of the Work and failure to honor these

requirements may become the basis for denial of any and all claims for either or both

“time” and “money”.

A. Work shall be coordinated as indicated by the following procedure.

B. The HVAC Contractor shall prepare a complete draft set of drawings on “bond” to act as

background drawings at scale not less than 3/8 inch equals 1 foot, showing structure and

other information as needed for coordination. He shall show all piping and duct work

layouts and routing thereon. Upon acceptance of these “bond” drawings, the HVAC

Contractor shall plot, or have plotted, a final coordination set on Vellum and these will be

the Coordination Drawings.

C. ALL FIREWALLS AND SMOKE PARTITIONS MUST BE HIGHLIGHTED ON THE SHEET

METAL DRAWINGS FOR APPROPRIATE COORDINATION.

D. The main paths of egress and for equipment removal, from main mechanical and electrical

rooms must be clearly shown on the coordination drawings.

E. Each of the below specialty trades shall add its work to these background drawings with

appropriate elevations and grid dimensions using a color coding system to be developed

between trades. Drawings shall indicate horizontal and vertical dimensions, to avoid


Weston High School


interference with structural framing, ceilings, partitions, and other services.

1. Specialty Trades

a. HVAC Piping and Associated Control Systems.

b. Plumbing System.

c. Electrical.

d. General Contractor.

F. Each specialty trade shall sign and date each mylar coordination drawing. Return

drawings to the Sheet Metal Subcontractor, who shall route them sequentially to all

specialty trades.

G. Where conflicts occur with placement of materials of various trades, the General

Contractor will be responsible to coordinate the available space to accommodate all

trades. Any resulting adjustments shall be initialed and dated by the specialty trade. The

Mechanical Contractor shall then final date and sign each drawing.

H. A Subcontractor who fails to promptly review and incorporate his work on the drawings

shall assume full responsibility of any installation conflicts affecting his work and of any

schedule ramifications.

I. The Mechanical Contractor shall make copies of all coordination drawings. Fabrication

shall not start until such transparencies of completed coordination drawings are received

by the Architect/Engineer and have been reviewed.

J. Review of coordination drawings shall not diminish responsibility under this Contract for

final coordination of installation and maintenance clearances of all systems and equipment

with Architectural, Structural, Mechanical, Electrical and other work.

K. After Architect/Engineer Review:

1. After review of coordination drawings, the method used to resolve interferences

not previously identified shall be as in 1.06 "MEETINGS" below.

2. All changes to reviewed coordination drawings shall be approved in writing by the

Architect/Engineer prior to start of work in affected area.

L. Distribution of Coordination Drawings:

1. The Mechanical Contractor shall provide the following distribution of documents:

a. One vellum of each Coordination Drawing to each specialty trade and

affected Contractor for their use.

b. One vellum of each Coordination Drawing to Owner.

c. One vellum of each coordination drawing to General Contractor.

NOTE: Electronic documents (CAD files) can be used for these operations based

upon agreement between all parties and in accordance with terms and conditions

set for obtaining of CAD files as per attachment to Section 01 33 00.

M. Coordination Drawings include but are not necessarily limited to:

1. Structure.

2. Partition/room layout.

3. Ceiling tile and grid.

4. Light fixtures.

5. Sheet metal, coils, boxes, grilles, diffusers, etc.

6. HVAC piping and valves.

7. Smoke and fire dampers.

8. Soil, waste and vent piping.

9. Water piping

10. Roof drain piping.

11. Major electrical conduit runs, panelboards, feeder conduit and racks of branch

conduit.

12. Above ceiling miscellaneous metal.

13. Fire Protection Systems.


Weston High School


14. Heat tracing of piping.

15. Equipment support, anchors, guides and seismic restraints.

N. The color coded transparencies shall be kept at the Owner's Representative's field office

for future reference in the event of conflict between the trades.

O. All coordination drawings shall be delivered to the Architect at the end of the project as part

of the record drawing requirements set forth in Article 3.11 of the General Conditions.

1.05 MEETINGS – Coordinate with Section 01 31 19

A. Coordination meetings to resolve interferences in the work will be held at the project site

under the direction of the Architect and Owner's Representative. Representatives of each

Contractor shall be present at each meeting. Each Contractor shall provide the necessary

manpower and/or overtime to insure that the coordination process described herein does

not delay the Project Schedule.

**End of Section**


Weston High School

KGD2018-1010 01 31 19 - 1 Project Meetings

SECTION 01 31 19

PROJECT MEETINGS

1.01 GENERAL

A. Requirements set forth herein are in addition to and shall be considered as

complementary to the Conditions of the Contract and the balance of Division #1 and

Technical Specifications.



1.02 REQUIREMENTS INCLUDED

A. Initial (Kick-Off or Orientation) Meeting

B. Regular Project Meetings

C. Job Progress Meetings

D. Job Coordination Meetings

E. Mockup Review Meetings

F. Recording

NOTE: As part of all individual meetings outlined above there shall be a Waste

Management program discussion held with all responsible parties in attendance.

1.03 INITIAL (KICK-OFF OR ORIENTATION) MEETING

A. The Owner's Representative or their designee will schedule the initial job meeting, prior

to the start of any work, at the project site and will notify all parties concerned of the time

and place of the meeting.

B. The meeting will be conducted by the Architect and shall address the conduct of the job,

lines of communications, and the like. Discussions on waste management requirements

as outlined in Section 01 74 19 shall be part of the agenda.

C. The Contractor and their principal subcontractors are required to attend.

1.04 REGULAR PROJECT MEETING AGENDA

A. Coordinate the Work of the Project (Reference Section 01 31 14).

B. Establish a sound working relationship among the Contractors, the Architect and the

Owner.

C. Review and update progress, submittal and delivery schedules.

D. Review job progress.

E. Review progress payment requests; change proposals and change orders.

F. Expedite the work to completion within the project schedule.

G. Provide a 2 week look ahead schedule.

1.05 JOB PROGRESS MEETINGS

A. Unless otherwise directed, bi-weekly job meetings will be held by the Architect. Present

at these meetings shall be the CONTRACTOR or a representative authorized to make

commitments for action on behalf of the Contractor and the Owner.

B. CONTRACTOR shall arrange for the participation of its Subcontractors when their

presence is required by the Construction Manager and/or the Architect.

C. The minimum agenda will cover:

1. Review minutes of previous meetings.

2. Note field observations, problems, and decisions.

3. Identify present problems and resolve them.


Weston High School

KGD2018-1010 01 31 19 - 2 Project Meetings

4. Plan work progress during next work period and its effect on the related work of

others.

5. Review shop drawings and submittal schedules.

6. Review change order status.

7. Review status of construction progress schedule.

8. Coordinate occupancy arrangements and access requirements with Owner.

9. Discussions on waste management requirements as outlined in Section 01 74 19

shall be part of the agenda.

1.06 JOB COORDINATION MEETINGS (Reference Section 01 31 14)

A. On a bi-weekly basis, either on the day of the scheduled job progress meeting, or such

other time established, a “working” coordination meeting will be held at the project site.

Present at these meetings shall be the Contractor and each trade contractor’s site

supervisor with men working, or scheduled to work within the ensuing 2 weeks, and

the Owner’s site Representative. Further, prior to the start of any major trade work, a

coordination meeting following the guidelines established herein shall be held subject to

the same parties presence as for general meetings.

B. Meeting shall be used to coordinate work of all contracts for the ensuing 2 weeks. At the

close of the meeting, each supervisor shall, in an agreed format, provide a summarized 2

week work plan to the other contractors.

C. The time and place for the meetings will be as established in the preconstruction

meeting.

D. Minutes will be taken by the party designated and distributed to all parties involved and

the Owner’s Representative. The General Contractor will provide, at the next regular

progress meeting, a verbal report of the date and time of the last coordination meeting

and a listing of those present.

1.07 MOCKUP REVIEW MEETINGS (Coordinate with Section 01 43 39 and Technical Sections)

A. Prior to start of any mockup that may be specified or required herein or within the

technical specifications the following shall be accomplished:

1. Submittal of shop drawings for respective mockup;

2. Submittal of samples for respective mockup;

3. Coordination and review meeting between specialty contractors responsible for

mockup and Architect and Owner’s representative.

1.08 RECORDING: The Owner’s Representative or the Architect, as agreed to by contract, shall write

minutes of all meetings and distribute them to all parties present and to those on the distribution

list given out at the orientation meeting within 48 hours of the meeting.

**End of Section**


Weston High School

KGD2018-1010 01 32 00 - 1 Scheduling/Progress

SECTION 01 32 00

SCHEDULING AND PROGRESS

1.01 GENERAL


to the "Conditions of the Contract" and the balance of Division #1 and Technical

Specifications.



C. The requirements set forth within this section are directed to all Contractors involved in the

work and shall be considered mandated requirements subject to penalties as defined

elsewhere in this Section.


A. Preliminary Requirements

B. Commencement, Prosecution and Completion of the work

C. Submittal Schedule

D. Project Progress Schedule

E. Breach of Contract

F. Time of Completion

1.03 PRELIMINARY REQUIREMENTS

A. Within seven (7) days after bids are opened, and before the Contract is executed, the three

(3) apparent low bidder for each trade/contract must submit to the Architect, in writing, a

list of duration’s and a sequence, in the form of a bar chart, for all activities that are the

responsibility of the bidder. Contractor's proposed work force and other resource loading

for each activity of the bar chart, broken down by trades, must also be provided. Failure to

comply with this requirement may be cause for rejection of the bid.

B. The apparent low bidders, concurrent with the submission of bar chart, shall also submit to

the Architect, in writing, the following information:

1. Shop drawing and material sample schedules keyed to the duration’s submitted in

the bar chart. (See Section 01 33 00)

2. Schedules for the award of subcontractor and equipment contracts keyed to the

duration’s submitted for the bar chart.

3. The name of the person who, as Scheduling Coordinator for the apparent low

bidder, is authorized to act on behalf of the apparent low bidder on all matters of

scheduling included in this Section. Once named, the Scheduling Coordinator

may only be replaced after written notice is given to the Owner's Representative

and Architect. The Contractor agrees, upon the request of either of the two

parties, to replace the Scheduling Coordinator.

C. Failure to comply with this subsection 1.03 of this Section of the General Requirements

may be cause for rejection of the bid and forfeiture of security.

1.04 COMMENCEMENT, PROSECUTION AND COMPLETION OF THE WORK

A. Contractor shall commence work under this contract upon receipt by him of Letter of Intent

to Award, Notice to Proceed, and/or Execution of the Contract, and shall prosecute said

work diligently and complete the work within the stated calendar days for each portion of

the work as set forth in Section 01 10 00.

B. The time stated for completion for contract work includes final cleanup of area. Upon

completion of total Contract work, ALL AREAS SHALL BE CLEAN.

C. The Contractor is to carry on responsibility for services and maintenance of such items as

temporary roads, walks, ramps, field offices, parking areas, environmental controls and the


Weston High School


like until work under this contract is complete, unless otherwise directed by the Owner.

Coordinate work herein with Section 01 10 00, Description of Work.

1.05 SUBMITTAL SCHEDULE

A. Within two (2) weeks after receipt of Letter of Intent to Award, Notice to Proceed, and/or

Execution of the Contract, the General Contractor shall prepare a detailed listing of all

items to be incorporated within the work, including all items of mechanical and electrical.

This information will be incorporated in the "PPS" as prepared by the "General Contractor"

in accordance with Paragraph 1.06 of this Section.

Listing should generally include the following:

1. Overall project milestones;

2. Proposed products list and status report on material orders.

3. Dates of shop drawing/sample submittals;

4. Guaranteed delivery dates after shop drawing and/or sample approvals;

5. Date of installation start;

6. Date of installation completion.

1.06 PROJECT PROGRESS SCHEDULE

A. Within two (2) weeks after receipt of Letter of Intent to Award, Notice to Proceed, and/or

Execution of the Contract, but prior to the actual start of the field work, the Contractor shall

submit to the Architect for his approval the proposed Project Progress Schedule giving the

information listed below.

The minimum information contained within the required project progress schedule shall

consist of -

1. The estimated dates the various classes of work included in the Schedule of

Values will be started and completed.

2. The estimated percentages of completion to be obtained and the total dollar value

of the various classes of said work projected to the end of each calendar month

until substantial completion. Calculations shall be based upon - work in place;

materials on site and not installed; materials fabricated and stored under suitable

conditions and insured to full value in a manner satisfactory to Architect and

Owner; and such other items as may be agreed to among the Contractor, Architect

and Owner.

3. The estimated delivery and installation dates of the major pieces of equipment to

be furnished and installed by the Contractor.

4. The estimated projected progress of work that will be performed away from the job

site.

5. A delineation of the work that will be performed by the Contractor's own forces and

by his Subcontractors.

6. The estimated calendar dates on which all the work under the contract will be

completed and ready for substantial completion and final inspections.

B. The Project Progress Schedule shall be based on an orderly progression of the Work,

allowing adequate time for each operation, and leading to a reasonable certainty of

Substantial Completion by the date established in Section 01 10 00.

The schedule will be reviewed by the Architect and Owner’s Representative for compliance

with the requirements of this article and will be accepted by them or returned to the

contractor for revision and resubmittal.

Unless specifically required by law, no payment under this Contract shall be due until the


Weston High School


Progress Schedule has been submitted to the Architect and Owner’s Representative and

approved by both parties.

C. As the work progresses, an up-to-date copy of the schedule with the actual percent

completion of the various classes of the work indicated in red shall be submitted by the

contractor to the Architect and/or Owner’s Representative during the first week of each

calendar month. (Distribution to be established as part of “preconstruction meeting”).

The schedule may be adjusted and revised to meet unforeseen job conditions, but such

changes shall, at all times, be approved by the Architect and the Owner’s Representative.

D. A copy of the schedule shall be available at all times at the job site for the inspection and

guidance of other Contractors, Subcontractors and Vendors engaged on any construction

phase of the project.

It shall be the responsibility of Each Contractor to ascertain that all his Subcontractors,

Vendors and Material men periodically consult the Schedule so that their work schedule

shall be maintained in conformance with his own.

It shall also be the responsibility of Each Contractor to periodically consult the Job

Progress Schedules of any other Contractors that may be engaged on any separate

construction of the project, so that undue delay in progress on their part shall not delay the

work of the other Contractors.

E. AN UP TO DATE COPY OF PROJECT PROGRESS SCHEDULE MUST BE ATTACHED

TO MONTHLY REQUISITION IN ORDER FOR PROCESSING TO BEGIN.

INCOMPLETE REQUISITIONS WILL BE REJECTED.

1.07 BREACH OF CONTRACT

A. The Contractor's failure to comply with any requirement called for in subsections 1.04, 1.05

and 1.06 above shall constitute a material breach of the Contract, and the Owner shall

have the right to and may terminate the Contract, provided, however, that the failure of the

Owner to so terminate shall not relieve the Contractor from future compliance.

1.08 TIME OF COMPLETION – Coordinate with Contract and General Conditions and Section 01 10

00.

A. Notwithstanding the implementation of the Construction Schedule, it is the sole

responsibility of the Contractor to complete the Work within a Contract Time which will

assure the substantial completion of the Project by the required date.

**End of Section**


Weston High School

KGD2018-1010 01 33 00 - 1 Submittal Requirements

SECTION 01 33 00

SUBMITTAL REQUIREMENTS

NOTES:

SUBMISSIONS CAN BE MADE ELECTRONICALLY PROVIDED THAT

SAID SUBMISSIONS FOLLOWS THE CRITERIA OUTLINED HEREIN AND

BOTH THE FORMAT FOR THE OVERALL PROCESS IS AGREED TO

BETWEEN ALL PARTIES PRIOR TO INITIAL START OF THE PROJECT.

SUBMITTAL TRANSMISSIONS SHALL BE LIMITED TO THE TECHNICAL

PRODUCT AND DRAWING REQUIREMENTS ONLY. MSDS DATA SHALL

NOT BE TRANSMITTED AS AN INTEGRAL PART OF THE SUBMITTAL

BUT SHALL BE INCLUDED AS A SEPARATE DOCUMENT FOR THE

EXPRESS PURPOSE OF ASSEMBLING THE REQUIRED FIELD MANUAL

AS SPECIFIED HEREIN.

ALL SUBMITTALS SHALL BE MADE THROUGH THE SUBMITTAL

EXCHANGE PROCESS – EMAIL TRANSMITTAL OF SAME WILL NOT BE

ACCEPTED AND WILL BE RETURNED WITHOUT REVIEW.

1.01 GENERAL



Specifications.



C. Where practical, submittals shall be made in groupings where installations are

complimentary, i.e. steel, steel decking, steel stairs, stair railings; roof systems/flashings;

etc. Failure to comply with this requirement will be cause for rejection of any or all

submittals.

Coordinate each submittal with fabrication, purchasing, testing, delivery, other submittals,

and related activities that require sequential activity.

Architect reserves the right to withhold action on a submittal requiring coordination

with other submittals until related submittals are received.

D. The Contractor is encouraged to submit for approval products made from recycled and/or

environmentally responsible material. Every effort will be made by the Design Professional

Team to approve these materials; the substitution request procedure shall still be enforced.


A. Related Work Specified Elsewhere.

B. Approved Equal Clause/Substitutions/Options

C. Certification.

D. Manufacturer's Instructions

E. Submittal Instructions

F. Shop Drawings

G. Samples

H. Material Safety Data Sheet (MSDS) Submittals

I. Proposed Products List and Status Report on Material Orders

J. Scheduling of Submittals

K. Job Progress Schedule - See Section 01 32 00

L. Coordination Drawings


Weston High School


M. Progress Photographs

N. Certificates

O. Construction Waste Management Procedures and Certifications – See Section 01 74 19.

P. V.O.C. Compliance certification – See individual technical sections.

1.03 RELATED WORK SPECIFIED ELSEWHERE

A. 01 29 00 - Applications for Payment and the Schedule of Values .

B. 01 31 13/14 - Project Coordination and Coordination Drawings.

C. 01 32 00 - Scheduling and Progress.

D. 01 43 26 - Testing Laboratory test and inspection reports.

E. 01 77 00 - Project Closeout requirements.

F. 01 77 19 - Project Record Documents.

G. 01 78 23 - Operation and Maintenance.

H. Divisions 2 through 33 Sections for specific requirements for submittals in those Sections.

1.04 APPROVED EQUAL CLAUSE/SUBSTITUTIONS/OPTIONS - Section 01 25 00

1.05 CERTIFICATION

A. Certification of compliance with specification performance standards and manufacturers’

specifications and directions shall be furnished for any portion of this work for which

specific performance requirements and/or manufacturers' specifications are listed. It shall

be the responsibility of the Contractor to secure two (2) copies of each certification when

required and transmit same to the Architect.

B. Sample Certification Form (2 pages) Section 01 33 06 as an exhibit at the close of this

Section. Each item requiring certification shall be so noted and affidavits shall be filed

singly to cover each specified material, installation, application and the like.

CERTIFICATIONS SHALL BE SUBMITTED AS PART OF THE CLOSE OUT DOCUMENT

REQUIREMENTS SET FORTH IN SECTION 01 77 00.

C. Decorations, Furnishings and Interior Finish - The Contractor's attention is directed to the

Connecticut State Fire Code as it relates to regulations controlling decoration, furnishings

and interior finishes as they affect the work of this Contract.

It is deemed the sole responsibility of the vendors furnishing fabrics, floor coverings, ceiling

finishes, wall coverings and finishes and the like as covered by the regulations to submit

applications and obtain approvals for same without additional charges to the Owner.

Failure to obtain, and submit, approvals in accordance with requirements of this section

will result in rejection of any submittal for this phase of the work.

D. Packaged Equipment: Where packaged (factory assembled) mechanical and electrical

equipment is furnished, a certificate shall be included with the submission of shop

drawings or catalog data stating that the equipment complies with OSHA, National Electric

Code, and applicable Underwriters Laboratories Standards in respect to motor protection,

grounding and protection against hazards, and is approved by all Regulatory Agencies.

1.06 MANUFACTURER'S INSTRUCTIONS

A. Where in these specifications an item is called for to be installed in accordance with the

manufacturer's directions, specifications or recommendations, the Contractor shall furnish

the Architect with two (2) printed copies of said directions, specifications or

recommendations, before the item is installed.

1.07 SUBMITTAL INSTRUCTIONS

A. Transmit each submittal, except sample installations and sample panels to the Architect.

Transmit submittals with Submittal Cover Sheet attached as Section 01 33 02. On the


Weston High School


Cover Sheet identify Contractor, indicate date of submittal, and include information

prescribed by form and required in paragraph entitled, "Submittal Requirements" of the

individual technical Section and as follows. Process transmittal forms to record actions

regarding sample installations and panels.

1. Name, address, and telephone number of subcontractor, supplier, manufacturer

and any other subcontractor associated with the submittal.

2. Name of Owner.

3. Name of Project and location.

4. Construction contract number/designation.

5. Product Identification.

6. Manufacturer.

7. Subcontractor/Supplier.

8. Spec Section No.

9. Spec Paragraph/Article.

10. Drawing No(s).

11. Drawing Date(s).

12. Room or Detail No(s).

13. When a resubmission, add alphabetic suffix on submittal description, for example,

submittal 18 would become 18A, to indicate resubmission.

1.08 SHOP DRAWINGS

A. The following serves as a further definition of the requirements for shop drawing submittals

as covered in Article 3.12 of the General Conditions:

1. The Contractor shall submit to the Architect with such promptness as to cause no

delay in the work, layout, detail, schedule, setting, product data and shop drawings

for each part of the work as specified or required.

a. Submission of data for review by the Structural and Mechanical/Electrical

Engineers shall be sent directly to those Engineers with duplicate

transmittals sent to the Architect.

2. BEFORE SUBMITTING ANY DATA FOR APPROVAL, THE CONTRACTOR

SHALL CHECK THE SUBMITTALS OF ALL SUBCONTRACTORS FOR

ACCURACY AND CONTRACT COMPLIANCE. ALL SUBMITTALS SHALL BE

UNDER THE COVER SHEET ATTACHED HERETO. SUBMITTALS NOT

COMPLYING WITH THE ABOVE SHALL BE RETURNED TO THE SUBMITTING

CONTRACTOR WITHOUT EXAMINATION BY THE ARCHITECT. Contractor

shall see that all work contiguous with and having bearing on work indicated on

drawings is accurately and distinctly illustrated and that work shown is in

conformity with contract requirements.

EACH CONTRACTOR SHALL BE RESPONSIBLE FOR COORDINATING THEIR

WORK AND SUBMITTAL WITH OTHER CONTRACTORS PERFORMING WORK

ON THE PROJECT.

SHOULD ANY CONTRACTOR CAUSE THE NEED FOR RE-SUBMISSION OR

RE-REVIEWS OF PREVIOUSLY APPROVED INFORMATION OF ANOTHER

CONTRACTOR, ALL COSTS INVOLVED WITH SAID REVIEW WILL BE

BACKCHARGED AT THE RATES SET FORTH IN SECTION 01 25 00 TO THE

CONTRACTOR CREATING THE NEED FOR ADDITIONAL REVIEWS.

3. Shop drawings shall be numbered consecutively and shall represent:

a. All working and erection dimensions.

b. Arrangement and sectional views.


Weston High School


c. Necessary details, including information for making connections to other

work.

d. Kinds of materials and finishes. Colors, where applicable

4. Shop drawings shall be dated, and shall generally contain:

a. Name and Number of project.

b. Name, address and telephone number of submitting Contractor.

c. Description of required equipment, materials, and classification item

numbers.

d. Locations at which materials or equipment are to be installed in the Work.

e. Identification of drawings, schedules, notes and/or details and

specification sections and related paragraphs/articles to which they apply.

f. Equipment or fixture identification corresponding to that used in Contract

Documents.

g. Accessories and special or non-standard features and materials which are

being furnished.

h. Properly marked with external connection identification as related to the

project where they consist of standard factory assembly or field installation

drawings.

In addition to the general data required above, mechanical and electrical

submissions shall contain:

a. Manufacturer's specifications including materials of construction, metal

gauge, thickness and finish.

b. Certified dimensional drawings including clearances required for

maintenance or access (coordinate with Section 01 31 14.)

c. Performance data, ratings, operating characteristics, and operating limits.

d. Electrical ratings and characteristics.

e. Wiring and control diagrams, where applicable.

f. Certifications requested, including UL label or listing.

g. List of accessories which are required but are NOT being provided by the

product manufacturer or are NOT being furnished under this Section.

Identify the Section(s) under which the accessories are being furnished.

5. Submission of data for approval shall be accompanied by letter of transmittal, in

duplicate, containing the name of the project, Contractor's name, number of

drawings, titles and other pertinent data.

6. Procedure for Submitting Shop Drawings and Product Data:

The contractor shall submit five (5) copies of data, for standard manufactured

items, in the form of manufacturer's catalog sheets, showing illustrated cuts of the

items to be furnished, scale details, sizes, dimensions, performance

characteristics, operating clearances, capacities, wiring diagrams and all other

pertinent information.

Two copies of reviewed submissions will be returned to the contractor.

For all other shop drawings, Contractor shall submit one transparency for each

drawing until final approval is obtained.

Each drawing transparency shall have a clear space approximately 4 inches by 10

inches on the right hand side for stamps showing "Date Received" and disposition

of submittal.


Weston High School


In addition to the transparency, three (3) prints shall be required.

a. After completion of checking, the Architect, and Engineer (as appropriate)

will retain one print for his record and return the transparencies to the

submitting Contractor.

The average "turn around time" of any one in-house submittal by the Architect

shall not exceed 15 business days for review and at least 20 business days when

another consultant is involved.

b. For drawings returned "Resubmit", "Amend & Resubmit", "Disapproved" or

"Rejected-Resubmit", the original drawings shall be corrected, a new

transparency made, and resubmitted until final approval.

NOTE: The Owner reserves the right to backcharge the Contractor for the

additional costs beyond the review of any resubmittal as outlined in

Section 01 25 00.

c. For drawings returned "Approved", "No Exceptions Taken", "Approved as

Noted", and "Make Corrections Noted", the Contractor shall obtain and

provide sufficient prints as required for the field.

NOTE: It is the responsibility of the contractor to confirm all dimensions,

quantities, and the coordination of materials and products supplied by him

with other trades. Approval of shop drawings containing errors does not

relieve the contractor from making corrections at his expense.

7. No work as called for by shop drawings shall be done until Architect's approval.

8. IF SUBMITTALS SHOW VARIATIONS FROM CONTRACT REQUIREMENTS

BECAUSE OF STANDARD SHOP PRACTICES, OR OTHER REASONS,

CONTRACTOR SHALL MAKE SPECIFIC MENTION OF SUCH VARIATION IN

HIS LETTER OF TRANSMITTAL.

9. APPROVAL OF SHOP DRAWINGS IS GENERAL. IT SHALL NOT RELIEVE

CONTRACTOR OF THE RESPONSIBILITY FOR ACCURACY OF SUCH

DRAWINGS, NOR FOR THE FURNISHING OF MATERIALS OR PROVISION OF

WORK REQUIRED BY THE CONTRACT AND NOT SHOWN ON THE SHOP

DRAWINGS.

Unless it is an interpretation of design intent, approval of shop drawings shall not

be construed as approval of departures from Contract.

10. If the Contractor should alter any information on previous submittals, besides the

notations called for by the Architect, he must circle this new information to bring it

to the Architect's attention.

11. Where practical, in submitting data for approval, all associated drawings,

product data and the like, relating to a complete assembly shall be submitted

at one and the same time so that each may be checked in relation to the

entire proposed assembly.

PARTIAL SUBMISSIONS WILL BE RETURNED WITHOUT ACTION TAKEN.

EXTRANEOUS MATERIAL ON PRODUCT DATA SHEETS SHALL BE STRUCK

PRIOR TO SUBMITTAL.


Weston High School


Resubmittals of any data shall be “complete”, i.e. – Lighting Fixture resubmittal

shall include all fixtures whether or not some have been approved so that when

the entire submittal is approved, a full record copy is on file.

12. Contractor shall have copies of all approved shop drawings as listed in Paragraph

1.08.A.6 above on the job at all times and shall make them available to the

Architect or the Owner's representatives.

1.09 SAMPLES

A. The following serves as a further definition of the requirements for sample submittals as

covered in Article 3.12 of the General Conditions:

1. Names of proposed manufacturers, materialsmen and dealers who are to furnish

materials, fixtures, appliances or other fittings shall, where practical, be submitted

to the Architect for early approval to afford proper investigation and check.

2. No manufacturer will be approved for any materials to be furnished under this

contract unless he shall be of good reputation and shall have plant of ample

capacity and shall have successfully produced similar products.

3. All transactions with manufacturers and subcontractors shall be through the Prime

Contractor.

4. Unless otherwise specified, samples shall be in duplicate (2) and of adequate size

to show quality, type, color, range, finish, texture, etc.

INTERRELATED COLOR SELECTIONS WILL NOT BE MADE UNTIL ALL

PERTINENT SAMPLES ARE MADE AVAILABLE TO ARCHITECT.

Deliver one (1) sample to field office and one (1) sample to Architect's office

unless otherwise directed.

5. Each sample shall be labeled, bearing material and quality names, submitting

Contractor's name, and project name, and other pertinent data.

In accordance with OSHA regulation Number 1910.1200, a Material Safety

Data Sheet (MSDS) shall be submitted for each product to be incorporated in

the work.

The sole purpose for requiring submittal of MSDS sheets as outlined herein and

respective technical sections is to advise the General Contractor that health and

safety is of primary importance to the execution of the work and for the future

occupants of the project under construction. It is to be assumed, and will be

enforced, that the submission of MSDS sheets be made as a separate package,

covered by it’s own transmittal and marked “for evidence of legal compliance”.

This submission will be noted and returned with a stamp indicating “SUBMITTED

INFORMATION ONLY, NOT REVIEWED”. Failure to observe these submittal

requirements will be cause for rejection of the entire submittal.

The safe handling of products by the applicator according to MSDS

warnings is a safety issue, like any other, entirely within the purview of the

Respective Prime Contractor.

6. Where Specifications require manufacturer's printed installation directions, such

directions and diagrams shall accompany samples. Coordinate with Paragraph

1.05 herein


Weston High School


7. A duplicate letter of transmittal from the submitting Contractor requesting approval

of the sample shall accompany the samples.

8. Transportation charges to designated locations must be prepaid on all samples.

9. Materials shall not be ordered until approval is received in writing from the

Architect.

10. All materials shall be furnished equal in all respects to the samples which

were approved.

1.10 MATERIAL SAFETY DATA SHEET (MSDS) SUBMITTALS

A. As specified in Paragraph 1.09 of this Section and within the technical sections forming this

Specification, the Contractor is directed to the following requirements concerning "MSDS"

submissions.

1. Submit MSDS's for all products used during construction whether incorporated

within the work or used in the performance of the work.

2. Identify which products may be harmful to construction workers or other building

occupants.

3. Develop means and methods for protection of construction workers and other

building occupants from potentially harmful products. Submit said means and

methods to the Owner for review and approval.

B. Further, the General Contractor with assistance from each individual contractor shall

maintain a "MSDS" file on site, accessible to workers and otherwise in compliance with

jurisdiction's "Right To Know" legislation.

C. Attention is directed Section 01 77 00, Article 1.04.A.12 for final closeout submittal

of MSDS compilation to the Owner.

1.11 PROPOSED PRODUCTS LIST AND STATUS REPORT ON MATERIAL ORDERS - Coordinate

with Section 01 32 00.

A. Within two (2) weeks after date of Notice to Proceed or execution of the Contract

(whichever is the earliest), submit a complete list of products proposed for use, with name

of manufacturer/vendor/fabricator, trade name, and model number of each product.

B. For products specified only by reference standards, give manufacturer, trade name, model

or catalog designation, and reference standards.

C. Report to include list, in chronological order by need date, materials orders necessary for

completion of the contract. The following information will be required for each material

order listed:

1. Material name, supplier, and invoice number.

2. Bar chart line item or CPM activity number affected by the order.

3. Delivery date needed to allow directly and indirectly related work to be

completed within the contract performance period.

4. Current delivery date agreed on by supplier.

5. When item 4 exceeds item 3, the effect that delayed delivery date will have on

contract completion date.

6. When item 4 exceeds item 3, a summary of efforts made by the Contractor to

expedite the delayed delivery date to bring it in line with the needed delivery date,

including efforts made to place the order (or subcontract) with other suppliers.

NOTE: This information shall be updated for each requisition, failure to complete

and certify accuracy will be cause for non-payment of requisition.

1.12 SCHEDULING OF SUBMITTALS

A. Within two (2) weeks after execution of the Contract, the Contractor shall submit a detailed

listing of all items to be incorporated within the work, including all items of mechanical and

electrical.

1. Submittals for Review.


Weston High School


2. Quality Control Submittals.

3. Sustainable Design Submittals.

4. Closeout Submittals.

Listing should state the following:

1. Specification section number.

2. Description of submittal.

3. Type of submittal.

4. Date of shop drawing/sample submittals.

5. Guaranteed delivery date after shop drawing and/or sample approvals.

6. Date of installation start.

7. Date of installation completion.

1.13 JOB PROGRESS SCHEDULE - See Section 01 32 00

1.14 COORDINATION DRAWINGS

A. Each Contractor's attention is directed to Section 01 31 14 for required coordination

drawings and the responsibility therefore.

1.15 PROGRESS PHOTOGRAPHS

A. This Article includes requirements for periodic construction photography by the General

Contractor, utilizing digital camera equipment, to demonstrate construction progress and to

serve as a communicative device when describing a given condition to others at a remote

location, by means of the internet.

B. Photography shall be taken using a digital camera and electronic program which will

download the digital photos in a JPEG format to a computer with resolution adequate to

demonstrate the item under discussion.

C. One set of record prints will be required and filed with the monthly requisition. The JPEG

files shall be transmitted to the appropriate parties who shall then have the option to view

the picture(s) on screen or print them out using their own equipment.

D. It is the intention of this Section to provide a tool to enhance communications and reduce

the amount of time required to address questions arising at the Project site. In this end, the

Contractor shall utilize good judgment in providing photographs that are informative, and

not merely repeating what is shown in the other photographs.

E. Provide factual representation of construction extent and conditions. Provide correct

exposure and focus, high resolution and sharpness, maximum depth of field, and minimum

distortion, utilizing a normal lens.

F. Before starting work, the General Contractor shall take photographs of the Work Areas

from different points of view sufficient in number to show all present conditions.

G. The minimum requirements, per requisition period are three (3) photographs of the Work,

from different points of view designated by the Architect

1.16 CERTIFICATES

A. Submit a Summary of Solid Wastes Generated, manifests, weight tickets, and the

like in accordance with requirements of Section 01 74 19 - Construction Waste

Management.

B. Submit, as required by each technical section a certification for V.O.C. compliance.

Part 2 - PRODUCTS

Not used

Part 3 - EXECUTION


Weston High School


Not used

**End of Section**


Weston High School

KGD2018-1010 01 33 01 - 1 Request for Electronic Files

CONTRACTOR REQUEST FOR ELECTRONIC DRAWING FILES

The Architect, for the convenience of the Client/Owner, has electronic copies or representations

of Drawings, Specifications and Project Manuals. Requests for electronic copies of such

Drawings, Specifications and Project Manuals by the Contractor, for the Contractors use or the

use of Subcontractors, shall be made in writing to the Client/Owner as outlined hereinbelow and

shall outline the benefit derived from such a request. The Contractor shall be prepared to

reimburse the Client/Owner for any costs involved in preparing such electronic documents for the

Contractors use.

Architect’s Project Number:

Project Name:

Architect:

Client/Owner:

Construction Manager (if any):

Contractor/Recipient’s Name:

Attention to:

Contractor/Recipient’s Address:

Date of Request:

Date of Release:

As requested, attached is a list of electronic drawing files in DWG/DWF format (Drawings may be compressed). For the release of these electronic drawing files to the recipient, the following items shall be understood, acknowledged and signed by the authorized personnel of the recipient with the fee included as may be required.A. The electronic drawing files are the property of the Client/Owner and the Contractor is granted a

license to use the electronic files only in connection with the subject project. B. The electronic drawing files do not necessarily represent the Contract Documents associated with

the referenced project. These files are solely for the use of the recipient and are not a representation of the scope of work for the project. Any use by contractors, subcontractors or fabricators shall be on all of the same terms and conditions being applicable to such users who shall acknowledge the same in writing. The Recipient may use the electronic drawing files only. Electronic drawing files or portions thereof, shall not be provided to anyone else without the written approval of the Client/Owner. The use of the electronic drawing files, documents and any reprographics shall not identify any member of the Architect or Architect’s consultants or sub-consultants or the Client/Owner without the written approval from the parties.

C. The entire risks as to the results and performance of the package including the electronic drawing files, are assumed by the Contractor/recipient. The Client/Owner, the Architect and the Architect’s consultants and sub-consultants, including directors, employees, representatives, and licensors of the company, shall not have any liability to the Contractor/recipient or any other person or entity for any direct, indirect, incidental special or consequential damages whatsoever, including, but not limited to, the loss of revenue or profit, lost data, or any other personnel,


Weston High School

KGD2018-1010 01 33 01 - 2 Request for Electronic Files

commercial or economic loss, and claims by third parties. Even if the Client/Owner and Architect and the Architect’s consultants and sub-consultants has been advised of the possibility of such damages; said Client/Owner and Architect and the Architect’s consultants and sub-consultants shall not be held liable as stated above.

D. The Contractor/recipient hereby agrees to indemnify and hold the Client/Owner, the Architect and the Architect’s consultants and sub-consultants harmless from and against any cost, damage, liability, loss or claim arising from violation of this license. The Contractor/recipient and all subcontractors of all tiers also agrees that, in addition to all other remedies hereunder, the Contractor/recipient and such parties grant the Client/Owner the right to seek injunctive or other equitable relief to prevent the violation or require the performance of any of the Contractor’s/recipient’s obligations under this license, and the Contractor/recipient hereby consents to the issuance of such relief by any court of competent jurisdiction without the need to post any bond or security.

E. The electronic files requested are as follows:

Electronic file name Corresponding Drawing

(DWG extension unless noted

otherwise)

(close approximation)

1.

2.

3.

Etc.

Total number of files:

CONTRACTOR’S/RECIPIENT’S AGENT SIGNATURE: ___________________________________

NAME IN BLOCK LETTERS: ______________________________________________________

AUTHORIZED POSITION HELD: ___________________________________________________

DATE OF SIGNATURE: __________________________________________________________

**End of Attachment**

KGD2018-1010 01 33 02 – 1 Submittal Cover Sheet

SUBMITTAL COVER SHEET

Contractor:_________________________________________________________________________

Address:______________________________________________ Telephone: ( )_______________

TYPE OF SUBMITTAL:

Shop DrawingsTechnical DataTest Report

ScheduleCertificateWarranty

Physical SampleColor Sample_____________

Submission #: 1st , 2nd, 3rd, 4th (circle one)

Contractor Remarks: Contractor Submittal Review Stamp

THE ATTACHED MATERIAL HAS BEEN REVIEWED BY THE UNDERSIGNED AND IS BELIEVED TO COMPLY WITH ALL REQUIREMENTS OF THE CONTRACT DOCUMENTS. THE UNDERSIGNED UNDERSTANDS VERIFICATION OF FIELD DIMENSIONS, AND COORDINATION WITH OTHER TRADES, REMAINS THE RESPONSIBILITY OF THE CONTRACTOR.

DATE: _______________ BY (SIGN): ____________________

Consultant use below this line: Architect Submittal Review Stamp

NO EXCEPTIONS MAKE CORRECTIONS NOTEDREJECTED REVISE AND RESUBMITEXAMINED SUBMIT SPECIFIED ITEM

CHECKING IS ONLY FOR GENERAL CONFORMANCE WITH THE DESIGN CONCEPT OF THE PROJECT AND GENERAL COMPLIANCE WITH THE INFORMATION GIVEN IN THE CONTRACT DOCUMENTS. ANY ACTION SHOWN IS SUBJECT TO THE REQUIREMENTS OF THE PLANS & SPECIFICATIONS. CONTRACTOR IS RESPONSIBLE FOR DIMENSIONS WHICH SHALL BE CONFIRMED & CORRELATED AT THE JOB SITE; FABRICATION PROCESSES AND TECHNIQUES OF CONSTRUCTION; COORDINATION OF HIS WORK WITH THAT OF ALL OTHER TRADES & THE SATISFACTORY PERFORMANCE OF HIS WORK

KAEYER, GARMENT & DAVIDSON ARCHITECTS, P.C.

DATE_______________ BY____________________________________

Owner:

Name of Project:

Description:

Product Identification: _______________________________________________________

_______________________________________________________

Manufacturer: _______________________________________________________

Subcontractor/Supplier:______________________________________________________

DOCUMENT REFERENCES: (Must be fully filled out)

Spec Section No.:______________________ Drawing No(s):_______________________

Paragraph: ___________________________ Rm. Or Det. No(s):____________________


Weston High School

KGD2014-1019 01 33 06 - 1 Certification

CERTIFICATION OF SPECIFICATION COMPLIANCE

I/WE, the MANUFACTURER/SUPPLIER and INSTALLER of ______________________________

_______________________________________________________________________________

as specified in Section Number __________ of the Contract Documents prepared by Kaeyer, Garment and

Davidson (KG&D) Architects, PC; 285 Main Street; Mt., Kisco, New York 10549 for the

Synthetic Turf Field Replacement and Related Work

At

Weston High School

115 School Road

Weston, CT

do (does) herein certify that -

1. All materials furnished for said project do fully comply with all specification requirements as stated

within the Contract Documents;

2. That no asbestos containing materials of any nature are used in the work;

3. That execution of the Work covered by this certification has been performed in accordance with the

drawings prepared by the design professional team.

CONTRACTOR: ___________________________________________________________________

CERTIFICATION BY: _____________________________ TITLE: ________________________

ADDRESS: ______________________________________________________________________

CERTIFICATION DATED: __________________________________________________________

Distribution:

Original and One Copy to: KGD Architects, PC;

285 Main Street;

Mt., Kisco, New York 10549

Att: Eric Wilson

Att: ____________________________

One Copy to:


Weston High School

KGD2014-1019 01 33 06 - 2 Certification

CERTIFICATION OF SPECIFICATION COMPLIANCE

CORPORATE ACKNOWLEDGEMENT

)SS.

)

On the _________________ day of ________________, before me came _________________ to me

known and who by me being duly sworn did depose and say that he resides at

______________________________ that he is the officer of the said corporation executing the foregoing

instrument, that he knows the seal of said corporation, that the seal affixed to said instrument is such

corporate seal, that it was so affixed by order of the Board of Directors of said corporation and that he

signed his name thereto by like order.

______________________________

Notary Public

INDIVIDUAL ACKNOWLEDGEMENT

State of

)SS.

)

County of

On the _________________ day of _________________, before me came _________________ to me


______________________________ that he is the individual who executed the foregoing instrument.

______________________________

Notary Public

PARTNERSHIP ACKNOWLEDGEMENT

State of

)SS.

)

County of

On the _________________ day of ________________, before me came _________________ to me


______________________________ that he is the partner in the firm of

______________________________ doing business under the name of

_______________________________ and that he executed the foregoing instrument on behalf of said

partnership.

______________________________

Notary Public


Weston High School

KGD2018-1010 01 35 29 - 1 Health & Safety Plan

SECTION 01 35 29

HEALTH AND SAFETY PLAN

1.01 GENERAL



Specifications.



C. Definitions as apply to "Contractors" involved with the work of this Project shall be as set

forth in Section 01 10 00, Article 1.01.


A. Provide all labor, equipment and materials and perform all operations in connection with

monitoring air quality, decontaminating equipment and providing worker health and safety

protection for all Contractor and Subcontractor personnel.

B. Develop a site specific Health and Safety Plan (HASP) specifically addressing the potential

hazards that may be encountered. This plan shall meet all Occupational Safety and Health

Administration (OSHA) requirements.

C. Review the requirements and data presented and supplement the program with any

additional measures deemed necessary to fully comply with regulatory requirements and

adequately protect personnel on the site.

1.03 REFERENCES

A. OSHA Regulation 29 CFR 1910.120

B. OSHA Regulation 29 CFR 1926.62

1.04 DEFINITIONS

A. Site Safety Official (SSO): The individual who is responsible to the Contractor and has the

authority and knowledge necessary to implement the site safety and health plan and verify

compliance with applicable safety and health requirements.

B. SSO shall possess full and complete authority to order stoppage of any work which he

deems unsafe.

1.05 SUBMITTALS

A. Provide within seven (7) days after execution of the Agreement.

1. Site-specific HASP including the Emergency Response Plan to the Owner,

Owner’s Representative and Architect for review, including provisions for

decontamination and a contingency plan for unforeseen emergencies. The review

is only to determine if the HASP meets basic regulatory requirements and the

minimum requirements of this Section. The review will not determine the

adequacy of the HASP to address all potential hazards, as that remains the sole

responsibility of the Contractor.

2. Current certification of employee's health and safety training and certification of

employee's baseline medical exam status.

3. Certification of additional required health and safety training for Supervisors.

4. Qualifications and experience of the SSO for approval.

B. Submit minutes of weekly safety meetings at periodic progress meetings.

C. Refer to related submittal requirements in Section (s) 02 82 00 - Asbestos Abatement for

project.

1.06 CONTRACTOR’S RESPONSIBILITIES


Weston High School


A. Contractor is solely responsible for the health and safety of workers employed by the

Contractor, any Subcontractor and anyone directly or indirectly employed by any of them.

B. Develop and follow a site specific Health & Safety Plan (HASP) in accordance with the

requirements of paragraph 1.07.

C. Provide a full-time SSO regardless of whether or not the Work is at a defined Uncontrolled

Hazardous Waste Site.

D. Pre-arrange emergency medical care services at a nearby hospital, including

establishment of emergency routes of travel.

E. Meetings:

1. Conduct daily job briefings with all site personnel to discuss relevant health and

safety issues including but not limited to hazards, monitoring, procedures and

controls. Document attendance and topics covered.

2. At a minimum, conduct weekly safety meetings with all site personnel,

documenting attendance and topics covered.

F. Train all workers assigned to areas where contaminated media are likely to be

encountered in accordance with 29 CFR 1910.120.

G. Include those workers involved with the abatement of Asbestos containing materials in a

medical surveillance program and respiratory protection program that meet the

requirements of 29 CFR 1910.120 and 29 CFR 1910.134, respectively.

H. In areas where contaminated media are likely to be encountered, monitor air quality in and

around work area using appropriate air monitoring equipment/analysis, as indicated in Part

2. Record all readings and maintain record on site. Stop work and/or upgrade respiratory

protection or personal protective equipment levels if action levels established in the HASP

are exceeded. Ensure that degree and type of respiratory protection provided is consistent

with the monitored concentrations and individual chemical parameters. Lawfully dispose of

all contaminated clothing and equipment that cannot be decontaminated.

1.07 HEALTH & SAFETY PLAN (HASP) REQUIREMENTS

A. The following items shall be addressed in the HASP:

1. safety and health hazard assessment;

2. procedures for emergency medical treatment and first aid;

3. map indicating route to hospital for emergency medical care;

4. Lead Exposure Control Plan (29 CFR 1926.62);

5. equipment decontamination procedures;

6. air monitoring procedures and action levels;

7. personal protective equipment and decontamination;

8. physical hazard evaluation and abatement including:

a. equipment operation;

b. confined space entry;

c. slips and falls;

d. building collapse;

e. falling debris;

f. encountering unmarked utilities;

g. cold and heat stress;

h. hot work (cutting and welding);

i. excavation entry;

9. training requirements;

10. recordkeeping requirements;

11. emergency response plan that includes:

a. names of three (3) Emergency Response Contractors, experienced in the

removal and disposal of oils and hazardous chemicals, that the Contractor

intends to use in the event of an emergency;

b. evacuation routes and procedures;


Weston High School


c. emergency alerting and response procedures.

1.08 CONTINGENCY MEASURES & NOTIFICATIONS

A. The potential for encountering hazardous buried objects or materials that could pose a

threat to human health or the environment exists at the Project Site. In the event that

potentially hazardous materials are encountered during the work under this contract, the

responsibilities of the Contractor and the Owner’s Representative are described herein.

B. The procedures and protocols to be used by the SSO in defining materials that are

potentially hazardous include screening with a photoionization detector, odor, visual

appearance of a material, and obvious oil or chemical contaminated materials.

C. Upon encountering suspected hazardous buried objects or materials as described above,

cover the excavation immediately if no imminent danger, as defined by the SSO, is

present. If there is an imminent danger, as defined by the SSO, evacuate the area

immediately. The SSO shall then notify the Owner’s Representative of the situation.

D. Establish, properly barricade, and mark the area as an exclusion zone under the direction

of the SSO. The SSO shall establish the exclusion zone boundaries based upon air quality

monitoring using a photoionization detector and other equipment as appropriate. The

exclusion zone shall be established at a minimum 50-foot radius around the location where

the potentially hazardous material is encountered. Work within the exclusion zone shall be

discontinued until the hazardous condition has been remediated and testing indicates that

a hazard does not exist. Other activities of the site, outside the limits of the exclusion zone

shall continue. Ambient air quality monitoring shall be performed by the SSO to

demonstrate that ambient air quality in other portions of the site is not adversely impacted

by the exclusion zone condition.

E. Notify Owner’s Representative regarding the presence of potentially hazardous materials.

Owner’s Representative may direct the Contractor to notify regulators and to obtain

necessary regulatory approvals for remediation.

F. Mobilize the appropriate equipment and personnel to sample and test the hazardous

material within the exclusion zone to determine the remedial action required, subject to the

Owner’s Representative’s direction. Contractor may be directed to remove and legally

dispose of the material. Compensation for the removal and disposal of hazardous material

will be as a Change in Work and Change in Contract Price in accordance with the

Subcontract Agreement, if not covered under a specific bid item.

Part 2 - PRODUCTS

2.01 AIR MONITORING EQUIPMENT

A. Provide and maintain portable photoionization detector or organic vapor analyzer capable

of detecting organic vapors or total hydrocarbons. Equipment shall be sensitive to the 0.5

PPM level.

B. Provide and maintain an oxygen analyzer to measure oxygen concentration in any trench

or confined space prior to entry, as determined by the SSO.

C. Provide and maintain an explosimeter whenever the potential for accumulation of explosive

gases exists, as determined by the SSO.

D. Provide and maintain air monitoring equipment as required for the collection/monitoring of

airborne asbestos fibers. All air samples related to abatement work shall be analyzed by a

laboratory accredited by the American Industrial Hygiene Association.

E. All air monitoring equipment shall remain the property of the Contractor.


**End of Section**


Weston High School

KGD2018-1010 01 41 00 - 1 Permits & Compliance

SECTION 01 41 00

PERMITS AND COMPLIANCE

1.01 GENERAL



Specifications.




A. Permits and Licenses

B. Compliance

C. Additional Compliance

1.03 PERMITS AND LICENSES

A. The Contractor shall obtain, maintain and pay for all permits and licenses necessary for

the execution of the work and for the use of such work when completed.

1.04 COMPLIANCE

A. The Contractor shall give all notices, pay all fees and comply with all laws, rules and

regulations applicable to the work.

1.05 ADDITIONAL COMPLIANCE

A. The Contractor, Subcontractors, and the employees of the Contractor and Subcontractors,

shall comply with all regulations governing conduct, access to the premises, operation of

equipment and systems, and conduct while in or near the premises and shall perform the

work in such a manner as not to unreasonably interrupt or interfere with the conduct of

business of the Facility.

B. Further, attention is directed to requirements of Section 01 15 00.

**End of Section**


Weston High School

KGD2018-1010 01 42 19 - 1 Codes and Standards

SECTION 01 42 19

CODES AND STANDARDS

Part 1 - GENERAL

1.01 REFERENCE STANDARDS

The abbreviations, which may be used in the construction specifications, refer to the organizations and specifications of the organizations listed below.

AABC Associated Air Balance CouncilADC Air Diffusion CouncilALSC American Lumber Standards CommitteeAMCA Air Movement and Control AssociationASC Adhesive and Sealant CouncilASLA American Society of Landscape ArchitectsAWI Architectural Woodwork InstituteCBM Certified Ballast ManufacturersGANA Glass Association of North America ICBO International Council of Building OfficialsIES Illuminating Engineering Society of North AmericaIGCC Insulating Glass Certification CouncilLSGA Laminators Safety Glass AssociationNELMA Northeastern Lumber Manufacturers' AssociationNHLA National Hardwood Lumber AssociationNPCA National Paint and Coatings AssociationSFPA Southern Forest Products AssociationSIGMA Sealed Insulating Glass Manufacturers AssociationTIMA Thermal Insulation Manufacturers Association

Further attention is directed to industry guide complied by Sweet's division of McGraw-Hill denoted as "SOURCES OF INFORMATION" as well as in the web site www.4specs.com wherein a comprehensive list of international organizations representing building product manufacturers, associations, institutes, governmental agencies and testing bureaus is put forth.

1.02 APPLICABLE CODES: The following is a listing of applicable codes within the jurisdiction of the Work as embodied within the 2005 Connecticut State Building Code with the 2009 Amendments.

Code Type Code Model Amendment

Building/Dwelling Code 2003 IBC; 2003 IRC (State Building Code, 2005 CT supplement with 2009 Amendments)

Structural Code 2003 IBC; 2003 IRC (State Building Code, 2005 CT supplement with 2009 Amendments)

Plumbing Code IPC 2003 (State Building Code, 2005 CT supplement with 2009 Amendments)

Mechanical Code IMC 2003 (State Building Code, 2005 CT supplement with 2009 Amendments)

Electrical Code 2005/09 NEC (NFPA-70)

Fire/Life Safety Code 2005 State Fire Safety Code (2003 IFC);

NFPA 101-2003 for existing buildings. Portions of the IFC used in the state fire code.


Weston High School

KGD2018-1010 01 42 19 - 2 Codes and Standards

Accessibility Code ICC/ANSI A117.1 2003

Energy Code 2009 International Energy Conservation Code (re-adopted with changes)



**End of Section**


Weston High School

KGD2018-1010 01 43 26 - 1 Testing Services

SECTION 01 43 26

TESTING LABORATORY SERVICES

1.01 GENERAL



Specifications.





D. Pursuant to the provisions of Section 01 33 00, Submittal Requirements, it is further

required that unless otherwise specified, tests called for in the Specifications applicable to

the work and/or required to implement the work shall be paid for by the Owner.

E. Where tests are required by the Architect to substantiate conformance to the specifications

the Owner will pay all costs of such tests and engineering services unless said tests

indicate that the workmanship or materials used by the Contractor are not in conformance

with the Drawings, Specifications, Approved Shop Drawings or the approved materials. In

such event, the Contractor shall pay for the tests, remove all work and material so failing to

conform, REPLACE with work and materials which are in full conformity.

F. Requirements related to testing services and specified elsewhere in these documents

include:

1. Inspections and testing as required by laws, ordinances, rules, regulations or

orders of public authorities having jurisdiction over the work.

2. Certification of compliance as required by individual specification sections.

3. Testing, adjusting and balancing of mechanical equipment and systems.

4. Project record documents, including operation and maintenance manuals, record

drawings and the like.

5. Tests and standards governing work and/or materials as may be specified

throughout these specifications and/or as shown on the drawings.

G. The Owner will employ, and pay for, the services of an Independent Testing Laboratory to

perform all specified services other than mechanical equipment and system balancing.

H. Inspection, sampling and testing is required for the following,

Masonry and mortar.

Roofing and flashing systems

however this listing is to be considered as partial only with the burden placed on the

Contractor to advise, and the Laboratory to provide, all such inspections, sampling and

testing as may be specified and/or required by these Contract Documents and the

applicable laws and ordinances of the jurisdiction.

I. Employment of the Testing Laboratory shall not relieve the Contractor of his obligation to

perform Work in accordance with the Contract.


A. Laboratory Qualifications

B. Laboratory Duties

C. Contractor's Responsibilities

D. Tests Required

1.03 LABORATORY QUALIFICATIONS

A. Laboratory shall meet -

1. The "Recommended Requirements for Independent Laboratory Qualifications",

latest edition as published by the American Council of Independent Laboratories.


Weston High School


2. Basic requirements of ASTM E 329, latest edition, governing "Standards of

Recommended Practice for Inspection and Testing Agencies for Concrete and

Steel as Used in Construction".

B. Laboratory shall submit copy of inspection of facilities as made by Materials Reference

Laboratory of the National Bureau of Standards during most recent tour of inspection; with

memorandum of remedies of any deficiencies reported by inspection.

C. Testing equipment shall be calibrated at maximum 12 month intervals by devices of

accuracy traceable to either - National Bureau of Standards or accepted values of natural

physical constants; submit copy of certificate of calibration as executed by an accredited

calibration agency.

1.04 LABORATORY DUTIES

A. Cooperate with Architect and Contractor; provide qualified personnel promptly on notice.

B. Perform specified inspections, sampling and testing of materials and methods of

construction in conformance with specified standards, recognized authorities and the like

so as to ascertain compliance with the requirements of the Contract Documents.

C. Promptly notify Architect and Contractor of irregularities or deficiencies of Work which are

observed during performance of services.

D. Promptly submit sufficient copies (minimum 5) of reports and tests to Architect for

distribution. Reports shall contain -

1. Issue date

2. Project title and number

3. Testing laboratory name and address

4. Name and signature of inspector

5. Date of inspection or sampling

6. Temperature and weather observations

7. Test date

8. Identification of product and specification section

9. Location in project

10. Type of inspection or test

11. Observations regarding Contract Document compliance.

E. Perform additional services as required by the Owner and/or Architect.

F. The laboratory is not authorized to - release, revoke, alter or enlarge on, requirements of

the Contract Documents; approve or accept any portion of Work; perform any duties of the

Contractor.

1.05 CONTRACTOR'S RESPONSIBILITIES

A. The Contractor shall to the best of his ability -

1. Cooperate with laboratory personnel, provide access to the Work and to

Manufacturer's operations as may be necessary.

2. Provide to the laboratory preliminary representative samples of materials to be

tested in required quantities.

3. Furnish copies of mill test reports.

4. Provide casual labor and facilities as required to provide access to Work to be

tested; to obtain and handle samples at the Site; to facilitate inspections and tests;

for laboratory's exclusive use for storage and curing of test samples.

5. Notify laboratory sufficiently in advance of operations to allow for his assignment of

personnel and scheduling of tests.

6. Arrange with laboratory and PAY FOR, additional sampling and testing required for

the Contractor's convenience.

7. Employ, AND PAY FOR, services of a separate, equally qualified Independent

Testing Laboratory to perform additional inspections, sampling and testing

required when initial tests indicate Work does not comply with Contract


Weston High School


Documents. Coordinate with Paragraph 1.05.A.4 above.

1.06 TESTS REQUIRED

A. General Construction Tests: More detailed testing requirements are given in individual

Specification Sections. The Owner shall retain the right to make any additional tests the

Architect deem necessary or appropriate. The Contractor is responsible for providing his

own tests to determine that materials meet specified requirements. The scope of tests

required and paid for by the Owner (unless otherwise noted below) shall include as a

minimum the following:

1. Masonry Mortar: Three cubes tested for compressive strength at 10 days; ASTM

C 91 tests.

2. Paints and Finishes: Chemical analysis, coating thickness.

B. Plumbing: Conform to requirements specified in individual Division 22 Specification

Sections. The tests shall be performed and paid for by the subcontractor and witnessed

by the Contractor and Owner's on-site representative.

C. HVAC Testing: All HVAC work shall be tested by an independent testing and balancing

agency. Conform to requirements specified in individual Division 23 Specification

Sections. All costs of these tests will be paid by the subcontractor. Adjustments shall be

made by the subcontractor as directed by the Owner.

D. Electrical Power System Testing: Conform to requirements specified in individual Division

26 Specification Sections. The tests shall be performed and paid for by the subcontractor

and witnessed by the Contractor and Owner's on-site representative.

E. Electrical Lighting System Testing: Conform to requirements specified in individual

Division 26 Specification Sections. At least the following tests shall be performed and paid

for by the subcontractor.

1. Operation of every component of entire system.

F. Fire Alarm System Testing: At least the following tests will be performed. Conform to

requirements specified in individual Division 28 Specification Sections. The test shall be

performed and paid for by the subcontractor and witnessed by the Contractor and Owner's

on-site representative:

1. All smoke and heat detectors.

2. Proper operation as required by authorities having jurisdiction.

G. Contractor's Responsibilities: The Contractor shall notify the Owner, Architect, and Testing

Laboratory personnel at least 48 hours prior to performance of work requiring testing. The

Contractor shall fully cooperate with testing agencies and permit free access to all areas at

all times. The Contractor shall permit taking samples at any time during construction,

either before or after installation. Prior to notice to proceed with construction, the

Contractor shall submit a Testing Log of planned tests and scheduled test dates. Tests

shall be numbered based on type of work, type of test, and sequence. The Testing Log

shall be maintained by the Contractor and updated weekly.

1. Coordination: The Contractor shall coordinate all testing, including all testing and

inspections to be paid for by the Owner. The Contractor will arrange testing and

sampling performed by the Owner's testing agency and will have prepared test

record forms. Upon receipt of test results, the Owner will distribute 2 copies to the

Contractor and 2 copies to the Architect with test results.

H. Follow-up and Corrective Action: The Contractor and the Owner will note the test record

on the Testing Log to acknowledge test procedures and results. If the follow-up or

corrective action is needed, the Contractor shall submit to the Owner 2 written copies of

proposed follow-up or corrective plans and obtain the Owner's written approval before

proceeding.

1. Cost of Testing: If tests indicate that materials or work do not comply with

requirements, the contractor shall pay for all retesting, and shall remove and

replace non-complying work at no additional cost to the Owner.


Weston High School


I. Local Owner Inspections: The Contractor is also responsible for coordinating and

cooperating with local requirements for inspections.

**End of Section**


Weston High School

KGD2018-1010 01 43 39 - 1 Mockup Requirements

SECTION 01 43 39

MOCKUP REQUIREMENTS

1.01 GENERAL



Specifications.




A. General Purpose of Mockups

B. Exterior Mockup

C. Miscellaneous Mockups

1.03 GENERAL PURPOSE OF MOCKUPS

A. Contractors are advised that various sections of the Specifications require construction of

mockups. Where mockups are required the Contractor erecting the mockup shall notify

the Architect one week prior to its completion.

B. The purpose of each mockup will be to establish minimum standards of materials and

workmanship and to assure that completed installations based on the mockups will be fully

functional and will serve the purpose for which they have been designed.

C. Approved mockups may be left in place and incorporated into the permanent installation.

D. The Contractor shall not proceed with the purchase or fabrication of any "mockup" items

until the procedure of mockup erection, inspection and approval is completed and

documented.

E. Contractor shall coordinate work at each mockup with other trades construction that

mockup.

1.04 EXTERIOR MOCKUP

A. An exterior mockup consisting of the following items shall be constructed as noted on the

drawings.

B. This mockup shall include:

1. Brick (each of colors)

2. Aluminum Panning and Windows

3. Cast Stone

C. Divisions affected by the exterior mockup generally include: 4, 5, 7, 8 and 9

1.05 MISCELLANEOUS MOCKUPS

A. Additional field mockups for work are required as noted within the technical specifications

and generally include work identified within said sections. Failure to list any required

mockup will not relieve the Contractor from executing said mockup.

**End of Section**


Weston High School

KGD2018-1010 01 50 00 - 1 Temporary Facilities

SECTION 01 50 00

TEMPORARY FACILITIES

1.01 GENERAL



Specifications. Further, attention of all contractors is directed to requirements set forth in

Section 01 15 01 as they affect school building safety during the execution of the work of

this project.




A. Project Sign

B. Field Office - Not mandated, but if opted for, contractor is fully responsible for all utilities

and the costs thereof. First Aid station shall be maintained as part of GC contractual

responsibility.

C. Temporary and Permanent Services, General

D. Temporary Light and Power

E. Temporary Heating/Cooling Facilities

F. Temporary Toilet Facilities

G. Temporary Water

H. Storage Facilities

I. Scaffolding and Staging

J. Rubbish Containers

K. Construction Fencing

L. Janitorial Service/Daily Cleanup

M. Burning

N. Dust and Mud Control

O. Temporary Roadways

P. Maintenance of Permanent Roadways

Q. Traffic Control

R. Fire Prevention Control

S. Temporary Fire Protection

T. Discontinuance, Changes and Removal

1.03 PROJECT SIGN

A. The Contractor shall provide and maintain at the site of the work, the exact location thereof

to be designated by the Architect, a construction sign containing the title of the Project; the

name of the Owner; the names of the Architectural/Engineering team; and such other

information as may be indicated and/or required by the Architect.

B. Said project sign shall be constructed of APA A/C "MDO" plywood, edged and banded in a

minimum size of 4 foot by 8 foot and shall be set on supporting system designed to

withstand a minimum 50 mph wind velocity or greater as determined by codes. Graphics

shall be applied by a sign painter using a maximum of 4 colors plus black and white.

C. Upon completion of the project, or as may be directed by the Architect, said sign, framing,

supports and foundations shall be removed from the project site.

1.04 FIELD OFFICE - Contractors Option

A. Maintain on site all articles necessary for First Aid treatment; further, the Contractor shall

establish standing arrangements for the immediate removal and hospital treatment of any

employees and other persons on the job site who may be injured or who may become ill


Weston High School


during the course of the work.

1.05 TEMPORARY AND PERMANENT SERVICES, GENERAL

A. The Contractor shall provide and maintain, either directly or through its' subcontractors, all

temporary services and utilities, including all labor, materials, equipment and the like

necessary to adequately furnish, deliver and maintain said services at all times when

required during the term of the Contract.

B. Temporary work shall generally include, but not be limited to - temporary light and power;

temporary heat; temporary toilets; temporary water; hoisting systems; rubbish chutes;

temporary stairs, rails and shaft protection; storage; temporary fences; roof protection;

temporary enclosures; pay telephones; and the like required to conduct the work in a

proper manner.

C. The Contractor's use of any permanent system or service of the building or portions

thereof shall be subject to the Owner's approval. The Contractor shall be responsible for

any and all damage to permanent services used, and shall make good any and all damage

to the satisfaction of the Owner, prior to final completion and acceptance.

1.06 TEMPORARY LIGHT AND POWER

NOTE: For the work within the existing building, the energy will be supplied, and paid for, by the

Owner for all work within the present building. Abuse of service will be cause for termination of

service. No reimbursement will be made by Owner in the event of disconnect.

A. In general locations for temporary power shall be from the nearest adequate duplex or

simplex outlet to the work of this Contract. In the event that this is inadequate, Contractor

shall provide adequate and safe connections to locations agreed to between the Owner

and Contractor.

NOTE: Temporary light and power connections to other field offices than the Contractor's

field offices, etc., shall be paid for by the individual contractor if they so desire this service;

further, all use charges for remote offices will be paid for by those respective contractors

requiring said service.

1.07 TEMPORARY HEATING/COOLING FACILITIES

A. The Contractor shall provide and pay for all temporary heating/cooling/dehumidification,

coverings and enclosures necessary to properly protect all work and materials against

damage by dampness and cold, to dry out the work and to facilitate the completion thereof.

The fuel, equipment, materials, operating personnel and methods used therefore shall be

at all times satisfactory to the Architect and adequate for the purpose intended.

The Contractor shall maintain the critical installation temperatures provided in the technical

provisions of the specifications herein for all work in those areas where same is being

performed.

The maintenance of proper heating, ventilation and adequate drying out of the work is the

responsibility of the Contractor and any work damaged by dampness, insufficient or

abnormal heating shall be replaced to the satisfaction of the Architect by and at the sole

expense of the Contractor.

IT IS RECOMMENDED THAT A SYSTEM SIMILAR AND EQUAL TO POLYGON GROUP

(Formerly MUNTERS MOISTURE CONTROL SERVICES) TEMPORARY


Weston High School


DEHUMIDIFICATION EQUIPMENT BE EMPLOYED IN THE WORK OF THIS PROJECT

AND SHALL CONFORM TO THE FOLLOWING:

Desiccant dehumidifiers, as manufactured by Polygon, will be a solid desiccant design

having a single rotary desiccant wheel capable of fully automatic continuous operation.

Dehumidification will utilize all outside air. No air from inside the building shall be

recirculated through the dehumidifiers.

Supply ductwork shall be canvas spiral duct. If supply ductwork is placed outside

building, it shall be securely attached or anchored to withstand damage from winds.

Interior distribution ductwork shall consist of polyethylene tubing (Layflat) of the

appropriate diameter to inflate fully without flutter. The conditioned air shall be

distributed through 2-3 inch holes cut in the Layflat ducting. Distribute air evenly

throughout the area being served. Suspend temporary system from the existing

ceiling structure as recommended by the system manufacturer. Coordinate with

Architect for mounting locations within the building.

B. After the Project is enclosed, the Contractor shall provide all necessary temporary

environmental conditions for efficient and effective work by himself and all trades engaged

in the work.

Unless otherwise specified, the minimum temperature shall be 50 degrees F at all places

where work is actually being performed within the enclosed Project.

Attention is directed to specific temperature requirements for masonry, concrete,

roofing, metal, painting, carpentry, millwork, drywall, flooring and such other

temperature sensitive operations connected with the execution of the Work.

C. Before and during the placing of wood finish and the application of other interior finishing,

varnishing, painting, etc. and until final acceptance by the Owner of all work covered by the

Contract, the Contractor shall, unless otherwise specified in the Contract Documents,

maintain a temperature of between 65 and 85 degrees F. Coordinate with Division 9 of the


D. The permanent mechanical system may not be used without express written consent from

the Owner, through the Owners Representative.

Use of the permanent system, if granted, shall not shorten, or negate, any equipment, or

system guarantees required under this Contract.

A program of use, maintenance and restoration will be submitted with request for use of

systems for temporary services.

1.08 TEMPORARY TOILET FACILITIES

A. The Contractor shall provide suitable toilet facilities at approved locations complying with

all state and local requirements in every respect as follows:

1. Toilets shall be portable chemical type with screened enclosures each having a

urinal and closet and mounted on skids. One (1) unit shall be provided for every

25 employees.

2. Each unit shall be serviced by the renter at least twice a week, including removal

of water matter, sterilizing, recharging tank, refilling tissue holders and thorough

cleaning and scrubbing of entire interior.

3. Each unit shall be delivered to site, located as directed, relocated if desired, and

removed from site by rental company when required.

1.09 TEMPORARY WATER


Weston High School


A. The Owner, for the work within the existing building, will provide water service to the

Contractor without charge, but reserves the right to terminate, without incurring additional

cost, said service in the event of abuse of such service.

B. The Contractor shall make all necessary connections and extend piping to areas required

at no additional cost to the Owner.

C. The Contractor shall have all equipment for the temporary water removed at the

completion of the Project or when directed by the Architect or Owner.

1.10 STORAGE FACILITIES

A. The Contractor and each subcontractor shall provide temporary storage shanties, tool

houses and other facilities as required for his own use. Temporary structures shall be

located where directed or approved by the Owner, and shall be removed upon completion

of the work or when directed. Temporary structures shall be maintained in a neat

appearance.

B. Materials delivered to the site shall be safely stored and adequately protected against loss

or damage. Particular care shall be taken to protect and cover materials that are liable to

be damaged by the elements.

1.11 SCAFFOLDING AND STAGING

A. All scaffold, staging and appurtenances thereto shall comply in total to the requirements of

Safety and Health Regulations for Construction Chapter XVII of OSHA, Part 1926 and all

related amendments.

1.12 RUBBISH CONTAINER

A. Provide suitable rubbish container device (s), properly maintained and serviced, replaced

as required and protected from access by the public by fencing as may be specified herein

or approved by the Architect.

1.13 CONSTRUCTION FENCING

A. Construction fencing shall be provided enclosing all work and storage areas or where

indicated on the drawings. Unless otherwise shown or directed, all fencing shall be 8 feet

high, accurately aligned and plumb, adequately braced, and complete with gates, locks,

and hardware as required. UNDER NO CONDITIONS SHALL FENCING BE ATTACHED

OR ANCHORED TO EXISTING CONSTRUCTION OR TREES. Fencing traversing paved

areas shall be free standing sandbagged barrier type in a continuous manner, firmly

aligned and securely mounted. Fencing shall essentially consist of heavy timber wood sill

with chainlink fencing consisting of 2 inch posts with top and bottom rails of 1 inch pipe and

No. 9 wire fabric. All fencing shall be galvanized.

B. Site access gates shall be provided as required of same material as site fence complete

with all operating hardware and security devices.

C. Contractor shall submit drawings showing type, materials and construction of fencing to

Architect for approval before proceeding with installation.

D. All wood or metal products, unless galvanized, shall receive 2 coats of latex exterior paint

of color and manufacturer as approved by the Architect.

E. Should fencing be required to be relocated during the course of the project, same shall be

done at the total expense of the Contractor. At the completion of the project, the

Contractor shall remove and dispose of the construction fencing.

F. The construction fence shall be MAINTAINED IN GOOD ORDER by the Contractor

throughout the life of the project.

1.14 JANITORIAL SERVICE/DAILY CLEANUP

A. The Contractor shall furnish daily janitorial services for the project and perform any

required maintenance of facilities as deemed necessary by the Architect during the entire


Weston High School


life of the contract. Toilet facilities shall be kept clean and sanitary at all times. Services

shall be accomplished to the satisfaction of the Architect. The Contractor shall provide

daily trash collection and cleanup of the project area and shall dispose of all discarded

debris, and the like in a manner approved by the Architect.

1.15 BURNING

A. Burning will not be permitted.

1.16 DUST AND MUD CONTROL

A. The Contractor shall at all times provide adequate dust control measures. He shall

accomplish this, without interference with the public, and vehicular transportation.

1.17 TEMPORARY ROADWAYS - The Contractor shall:

A. Provide all temporary roadways required by the Contract. Where such roadways are not

designated in the Contract, the location of such roadways shall be approved by the Owner

through the Architect.

B. Maintain all temporary roadways used for the work, including but not limited to the removal

of snow.

C. Allow all persons engaged in the work free access to and use of all such roadways.

1.18 MAINTENANCE OF PERMANENT ROADWAYS

A. The Contractor, for the life of the project, shall immediately remove dirt and debris which

may collect on permanent roadways due to the work. This includes permanent roads and

sidewalks adjacent to the project site.

1.19 TRAFFIC CONTROL

A. Routes to and from the location of the work shall be as indicated in the Contract or as

directed by the Owner through the Architect. Temporary roadways shall be closed only

with prior approval of the Owner.

B. Parking areas for the use of those engaged in the work shall be as indicated on the

Contract Drawings or as directed by the Owner.

C. The Contractor shall maintain parking areas for the use of those engaged in the work,

including but not limited to snow removal.

1.20 FIRE PREVENTION CONTROL

A. The Contractor shall provide private unlisted telephone service reserved for fire calls at a

location or locations approved by the Owner. Such service shall be in addition to any other

telephone service. Clear instructions for sending alarms shall be conspicuously posted.

The Contractor shall pay all costs thereof until completion and acceptance of the work or

as otherwise directed by the Owner.

B. All Contractors shall comply with the safety provisions of the National Fire Protection

Association's "National Fire Codes" pertaining to the work and, particularly , in connection

with any cutting or welding performed as part of the work.

1.21 TEMPORARY FIRE PROTECTION

A. Each Contractor shall take all possible precautions for the prevention of fires. Where

flame cutting torches, blow torches, or welding tools are required to be used within the

building, their use shall be as approved by the Architect at the site. When welding tools or

torches of any type are in use, have available in the immediate vicinity of the work a fire

extinguisher of the dry chemical 20 lbs. type. The fire extinguisher (s) shall be provided

and maintained by the Contractor doing such work.

B. Fuel for cutting and heating torches shall be gas only and shall be contained in

Underwriter's laboratory approved containers. Storage of gas shall be in locations as


Weston High School


approved by the Owner and subject to Fire Department regulations and requirements.

C. No volatile liquids shall be used for cleaning agents or as fuels for motorized equipment or

tools within a building except with the express approval of the Owner and/or Architect and

in accordance with local codes. On-site bulk storage of volatile liquids shall be outside the

buildings at locations directed by the Owner, who shall determine the extent of volatile

liquid allowed within the building at any given time.

D. The Contractor shall comply with the following requirements relating to compressed gas:

1. Where compressed gas of any type is used for any purpose at the site, it shall be

contained in cylinders complying with ICC regulations. Gases of different types

shall not be stored together except when in use and when such proximity is

required.

2. All gas cylinders shall be stored in sheds constructed of noncombustible materials.

Sheds shall be well ventilated and without electric lights or fixtures and shall be

located as far from other buildings as is practicable. All gas cylinders not in actual

use, or in proposed immediate use, shall be removed from the building under

construction or reconstruction. Empty gas cylinders shall be removed prior to

bringing in a replacement cylinder. Cylinders shall at all times be supported and

braced in an upright position. When not in use, the protective cap shall be

screwed over the valve.

3. All persons required to handle gas cylinders or to act as temporary firemen (Fire

Watchers) shall be able to read, write and understand the English language; they

shall also be required by the Contractor to read Part 3 of Pamphlet P-1 "Safe

Handling of Compressed Gases" published by the Compressed Gas Association,

500 Fifth Avenue, New York, NY 10036.

4. Where LP-Gas is required for Temporary Heat (including Construction Heat), the

number of the cylinders within the structure or building shall be limited to the least

amount required; in general, one (1) cylinder per heater. Cylinders and heaters

shall be connected with two (2) braid neoprene hoses fitted at each end with

threaded unions and capable of withstanding a pressure of 250 P.S.I. The length

of those shall not exceed 30 feet and shall be protected from mechanical injury,

kinking and abrasion. Heaters shall not be less than 6 feet from any cylinder and

not less 10 feet from any tarpaulins or type closure. All debris and rubbish shall be

removed to prevent fire hazards.

5. Where local ordinances are in effect regarding gas cylinders, (their use,

appurtenances and handling), such ordinances shall supplement the requirements

of this paragraph. All personnel engaged in firewatch shall be certified by the

Local Fire Department having jurisdiction.

6. LP-Gas Heating will not be permitted in enclosed areas below grade.

7. Any cylinder not having the proper ICC markings or reinspection marking, or any

cylinder with a leak shall be isolated immediately away from any building and the

supplier shall be immediately notified; such other precautions as may be required

to prevent damage or injury shall also be taken by the Contractor.

E. The Contractor shall comply with the following requirements relating to welding and cutting:

1. All cutting and/or welding (electric or gas) must be done only by skilled, certified

and licensed personnel.

2. During welding or cutting operations, a contractor's man shall act as a fire watcher.

The fire watcher shall have proper eye protection and suitable firefighting

equipment including fire extinguisher (bearing current inspection Certificate),

protective gloves and any other equipment deemed necessary.

3. Welding or cutting shall not be done near flammable liquid, vapors or tanks

containing such material.

4. Where cutting or welding is done above or adjacent to (within two feet)

combustible material or persons, a shield of incombustible material shall be


Weston High School


installed to protect against fire or injury to sparks or hot metal.

5. Tanks supplying gases for welding or cutting are to be placed in an upright position

securely fastened, and as close as practical to the operation. Tanks, actives or

spares, shall be protected from excess heat and shall not be placed in stairways,

hallways or exits. When not in use, protective valve cap shall be screwed on the

cylinder.

6. Adequate fire extinguishing equipment shall be maintained at all welding or cutting

operations.

7. The Contractor shall secure all required inspections.

8. All equipment, hoses, gauges, pressure reducing valves, torches, etc., shall be

maintained in good working order and all defective equipment shall immediately be

removed from the job.

9. No person shall be permitted to do any welding or cutting until his name, address

and current license number have been submitted in writing to the Owner.

F. Contractors for work outside the building shall commence operations promptly on award of

Contract, and shall be responsible for same being kept clear of materials and debris in

connection with their own work and that of other Contractors. If a Contractor for outside

work allows other contractors to deposit material and debris over its lines, the Contractor

shall be responsible for all delay and extra cost occasioned thereby.

1.22 DISCONTINUANCE, CHANGES AND REMOVAL

A. All Contractors shall:

1. Discontinue all temporary services required by the Contract when so directed by

the Owner or the Architect. The discontinuance of any such temporary service

prior to the completion of the work shall not render the Owner liable for any

additional cost entailed thereby and each Contractor shall thereafter furnish, at no

additional cost to the Owner, any and all temporary service required by such

Contractor's work.

2. Remove and relocate such temporary facilities as directed by the Owner or the

Architect without additional cost to the Owner, and shall restore the site and the

work to a condition satisfactory to the Owner.

**End of Section**


Weston High School

KGD2018-1010 01 57 13 - 1 Temporary Erosion andSedimentation Controls

SECTION 01 57 13

TEMPORARY EROSION AND SEDIMENT CONTROL

Part 1 - GENERAL

1.01 GENERAL






1.02 REQUIRMENTS INCLUDED

A. Responsibility

B. Description

C. Submittals

D. Definitions

E. Reference Standards

F. Federal Permit Notifications

G. Authority

H. Coordination and Scheduling

I. Sustainability

1.03 RESPONSIBILITY

A. Assume responsibility for the temporary control of soil erosion and water pollution

resulting from performance of the work of this contract.

B. Measures to avoid and minimize waterborne soil erosion during construction and to

minimize off-site discharge or tracking of sediment during construction.

C. The Contractor shall be responsible to perform all tasks and to erect, manage, maintain,

move, extend, and remove at the proper time all physical erosion and sediment control

measures from beginning of construction activities through final completion. Unless

otherwise noted in the contract documents, such activities are considered as part of the

base bid.

D. In the event of conflict between these specifications and the regulation of other Federal,

State, or local jurisdictions, the more restrictive regulations shall apply.

E. The Contractor shall engage services of a Certified Professional in Erosion and Sediment

Control (EPESC) or a licensed professional engineer to conduct regular inspections at

least once every seven calendar days and within 24 hours after each storm producing 0.5

inches of rainfall or greater.

1.04 DESCRIPTION

A. The Work shall consist of temporary control measures as required to provide temporary

control of soil erosion or water pollution and work in conjunction with technical

specifications.

B. Temporary measures shall include silt fences, inlet protections, berms, sedimentation

basins, silt screens, mulches, grasses, or other erosion control devices or methods as

required.

1.05 SUBMITTALS

A. Outline description of erosion and sediment containment program complete with

implementation drawings if requested; coordinate with requirements set forth in Section

01 57 19.


Weston High School


B. Material samples and product data as applicable to the particular products.

C. Material safety data sheets on all products, as necessary.

1.06 DEFINITIONS

A. Erosion: The action of loosening and waterborne transport of soil particles from bare soil

surfaces on construction sites as a result of rainfall or runoff. Erosion can occur as

splash erosion, sheet erosion, rills, gullies, or channel erosion.

B. Sediment: The accumulation of eroded soil particles in streams, ponds, ditches, and

other areas downstream from the construction site.

C. Stabilization: Disturbed earthen surfaces are considered stable when 75% of the

intended vegetation has been established, in the opinion of the Engineer.

1.07 REFERENCE STANDARDS

A. "Developing Your Stormwater Pollution Prevention Plan - A Guide for Construction Sites",

by U.S. EPA.

B. "Field Manual on Sediment and Erosion Control Best Management Practices for

Contractors and Inspectors", by Jerald S. Fifield, Ph.D., CPESC.

C. National Menu of Stormwater Best Management Practices on USEPA

website,http://cfpub.epa.gov/npdes/stormwater/menuofbmps/index.cfm.

D. Item #4 entitled "Construction - BMPS for MS4's and construction site operators to

address stormwater runoff from active construction sites."

1.08 FEDERAL PERMIT NOTIFICATION

A. For all construction sites involving disturbance of one acre or more, the Contractor must

complete and file a "Notice of Intent for Stormwater Discharges Associated with

Construction Activity Under a NPDES Permit" form (NOI) with the U.S. Environmental

Protection Agency (EPA).

B. As a condition of the federal permit, the Contractor must prepare, maintain, and

continually update a Storm Water Pollution Prevention Plan (SWPPP) throughout the

construction process. The Plan and associated documentation must be on-site during all

periods of construction.

1. A meeting with the Contractor, Owner, and Engineer shall be held prior to start of

work to review the requirements for construction phase stormwater management.

This may be concurrent with the overall preconstruction conference.

a. If the Contractor employs a consultant to prepare the SWPPP, the

consultant shall also be in attendance.

2. The SWPPP must be specific to the particular project, and not a "generic"

concept. It must be consistent with the Contractor's proposed schedule for the

project.

3. The SWPPP must show the location of current temporary erosion and sediment

control measures, including but not limited to: site perimeter protection, surface

and slope protection, channel protection, inlet and outlet protection, construction

traffic exit protection, stockpile protection, etc. It must also show flow arrows,

discharge points, and construction phasing. It is expected that as construction

proceeds, the SWPPP will be updated continually to depict the current locations

of all erosion and sediment control measures.

C. As a further condition of the federal permit, the Contractor must regularly inspect all

erosion and sediment control measures and the site in general, and keep a record of

inspections on-site. The inspections must be performed by the Contractor's

superintendent or responsible designee. It must note conditions and maintenance

measures performed. Dated photographs are encouraged as part of the log.

1. Inspections must be performed weekly and within 24 hours after each rainfall

event exceeding one-half inch.


Weston High School


2. Contractor shall employ a rain gauge on-site and record daily results for the

duration of construction.

3. Contractors are encouraged to use the form "Stormwater Control Site Inspection

Report", referenced in Appendix B of the EPA manual in Paragraph 1.03.A,

above.

4. The Contractor shall be prepared to show the current SWPPP, the inspection

record, and a copy of the NOI form to authorized EPA inspection personnel if the

site is visited by them, and to escort the inspector around the construction site.

Such inspections may occur unannounced at any time.

D. At completion of construction and/or when all earth surfaces are stabilized from erosion,

the Contractor shall complete a "Notice of Termination" (NOT) form with EPA.

E. The Contractor must maintain a file of all SWPPP activities and records for three (3)

years after filing the NOT, or as required by EPA, whichever is longer.

1.09 AUTHORITY

A. The Owner's Representative and/or Architect has the authority to limit the surface area of

erodible earth exposed by earthwork operations and to direct the Contractor to provide

immediate temporary or permanent erosion or pollution control measures to minimize

damage to property and contamination of watercourses and water impoundments.

1.10 COORDINATION AND SCHEDULING

A. Schedule the work so as to minimize the time that raw earth areas will be exposed to

erosive conditions.

B. Coordinate the use of temporary controls with the permanent erosion control features or

finish materials shown.

C. Incorporate permanent control features into the work at the earliest practical time.

1.11 SUSTAINABILITY

A. In the selection of the products and materials of this section as well as for the entire

project, preference will be given to those with the following characteristics:

1. Water based.

2. Water-soluble.

3. Can be cleaned up with water.

4. Non-flammable.

5. Biodegradable.

6. Low or preferably no Volatile Organic Compound (VOC) content.

7. Manufactured without compounds that contribute to ozone depletion in the upper

atmosphere.

8. Manufactured without compounds that contribute to smog in the lower

atmosphere.

9. Do not contain methylene-chloride.

10. Do not contain chlorinated hydrocarbons.

11. Contains the least possible of post-consumer or post-industrial waste.

Part 2 - MATERIALS

2.01 SILT FENCE

A. Filter fabric for silt fence shall consist of pervious sheets of woven polypropylene, nylon,

or polyester with or without wire mesh reinforcing. Material shall meet the following

requirements:

PHYSICAL REQUIREMENTS FOR FABRIC SILT FENCE

Property Test Method Requirement


Weston High School


Grab Tensile Strength ASTM D-4632 100 lbs. min.

Grab Tensile Elongation ASTM D-4632 25% max.

Puncture Strength ASTM D-4833 60 lbs. min.

Mullen Burst Strength ASTM D-3786 210 psi min.

Trapezoid Tear Strength ASTM D-4533 60 lbs. min.

NOTE: The filter fabric shall contain a stabilizer and/or inhibitors to make the filaments

resistant to deterioration resulting from exposure to sunlight or heat to provide a minimum

of twelve (12) months of expected usable construction life at a temperature range of 0

deg. to 120 deg. F. The filter fabric shall be a minimum of 36 inches wide, cut from a

continuous roll to finish fence length to avoid the use of seams. Splice filter fabric

together only when absolutely necessary and only at a support post, with a minimum 6-

inch overlap and securely sealed. The filter fabric shall be free of defects or flaws which

significantly affect its physical and/or filtering properties.

B. Posts shall be of wood or steel of length in conformance to state regulations. Wood

posts shall be sound quality hardwood, nominal 1 x 1 inch. Steel posts shall be round or

U, T, or C-shaped with a minimum weight of one pound per foot, and have projections for

fastening the wire to the fence. Max post spacing shall be in conformance with state

regulations.

C. Prefabricated silt fencing, including pre-attached posts, etc. shall be permissible and shall

be one of the following or approved equal:

1. Marafi Inc/Carlisle – “Envirofence System"

2. Akzo Nobel – “Enkamat System"

3. Webtec, Inc. – “EconoFence"

2.02 MULCH

A. Temporary mulch may be straw, hay, wood fiber or wood cellulose, wood chips or bark

chips reasonably clean and free of noxious weeds and materials toxic to plant growth.

2.03 STONE FOR CHECK DAMS AND CONSTRUCTION EXITS

A. Stone for check dams in channels and ditches and for construction exits shall be well

graded angular 2-in. to 3-in. crushed stone.

2.04 EROSION CONTROL BLANKET FOR SLOPE PROTECTION

A. Type A erosion control blanket shall be a 100% straw matrix stitch-bonded with

degradable thread to a single standard photodegradable polypropylene netting. North

American Green S75, or equal.

B. Type B erosion control blanket shall be a 100% straw matrix stitch-bonded with

degradable thread between two standard photodegradable polypropylene nettings. North

American Green S150, or equal.

C. Type C erosion control blanket shall be a matrix of 70% straw and 30% coconut fibers

stitch-bonded between a UV-stabilized polypropylene top netting and standard

polypropylene bottom netting. North American Green SC150, or equal.

D. Type D erosion control blanket shall be a 100% coconut fiber matrix stitched between two

UV stabilized polypropylene nettings. North American Green C125, or equal.

E. Equal products to those named above shall be manufactured by:

1. Erosion Control Systems (1020).

2. Synthetic Industries ("Polyjute").

3. Webtec, Inc. (TerraJute).

4. American Excelsior (Curlex).

2.05 CATCH BASIN SEDIMENT TRAPS (FILTER BAGS) FOR INLET PROTECTION


Weston High School


A. Sediment traps shall be manufactured to fit into the opening of a catch basin or drop inlet

and hang down below the grate. Traps shall be manufactured from geotextile and

stitched webbing. They shall be designed to trap grit, debris, and soil particles, yet pass

water freely.

B. Sediment traps shall be equipped with lifting straps and loops for 1" rebar to set in place.

They shall not rely on the grate to stay in place.

C. Physical requirements shall be as follows:

Property Requirement

Grab Tensile Strength, ASTM D-4632 300 lb. min.

Grab Tensile Elongation, ASTM D-4632 20% max.

Puncture, ASTM D-4833 120 lb. min.

Mullen Burst, ASTM D-3786 800 psi min.

Apparent Size Opening, ASTM D-4751 #40

Flow Rate, ASTM D-4491 40 gpm/sf

D. Sediment traps shall be designed to be cleaned and re-issued multiple times.

E. Catch basin sediment traps shall be "Silt Sack", or equal.

F. Placing a flat piece of geotextile under the grate is not acceptable.

2.06 FILTER LOGS (WATTLES)

A. Filter logs (also known as wattles) shall be used to slow runoff, promote vegetation,

retard erosion, and hold sediments. Filter logs may be used for check dams in swales,

on fresh embankment, as an alternate to catch basin sediment traps, or other similar

functions.

B. Filter logs shall be flexible and roughly cylindrical in shape, 9" nominal diameter, and 25'

nominal length.

C. Filter logs shall be made from decorticated flax fiber in either photodegradable

polypropylene netting or high strength biodegradable netting.

D. Filter logs shall be staked in place with 1" x 1" x 24" wood stakes.

2.07 HAY BALES

A. Hay bales shall consist of hay from acceptable grasses and legumes, free from weeds,

reeds, twigs, chaff, debris, other objectionable material or excessive amounts of seeds

and grain. Hay shall be free from rot or mold and the moisture content shall not exceed

fifteen (15) percent by weight at the time of weighing.

B. The hay shall be securely baled with wire of adequate size to allow for possible rusting

while in use and to permit re-handling when the bale is in a saturated condition.

C. Individual bales shall be of a longitudinal shape not exceeding one hundred (100) pounds

when weighed.

2.08 GRASSES: Grasses: Seed mixture as specified in Section 32 92 00 or other species suitable for

temporary cover which will not compete with the grasses sown later for permanent cover.

Part 3 - EXECUTION

3.01 WORK AREAS

A. The Architect may limit the area of clearing and grubbing and earthwork operations in

progress commensurate with the Contractor's demonstrated capability in protecting

erodible earth surfaces with temporary or permanent erosion control measures.

3.02 SEDIMENTATION AND EROSION CONTROL

A. The Contractor shall plan and execute all operations, particularly those associated with

excavation and backfilling, in such a manner as to minimize the amount of excavated and


Weston High School


exposed fill or other foreign material that is washed or otherwise carried into wetlands

and waterways.

B. The Contractor shall furnish and place silt fence, mulch, check dams, matting, sediment

traps, wattles, hay bales, and other materials necessary for sedimentation and erosion

control in accordance with the accepted SWPPP.

C. Install erosion control measures as shown on the details and sections in the plans, and

follow manufacturer's recommendations.

D. In the event the measures used by the Contractor prove to be inadequate as determined

by the Engineer or regulatory agents, the Contractor shall adjust his operations to the

extent necessary.

E. The Contractor shall keep streams, brooks and other water crossings clear of mud, silt,

debris and other objectionable materials resulting from construction operations.

F. The Contractor shall minimize the amount of bare earth exposed at any one time during

construction, and minimize the duration of exposure. In general, permanent vegetation

shall be established as soon as possible, including temporary vegetation as needed.

Excavated material to be stockpiled for reuse shall be stored away from brooks, streams

and wetland areas and protected.

G. On sloping terrain, if necessary in addition to erosion control matting, install wattles or

hay bales to retard erosion paths until vegetation has become established. Do not

backdrag or smear sloping surfaces. Roughen soil on slopes by mechanical means.

Track marks from tracked vehicles must be perpendicular to the slope, to avoid formation

of rills.

H. Sediment laden water that is being pumped from the trenches or excavations shall not be

pumped directly into water courses. Employ temporary sediment traps as per the

accepted SWPPP.

I. Divert flow from upland areas away from fresh slopes until stabilized.

J. Follow specifications for turf establishment through the stabilization period. Remove any

erosion control measures as they become unnecessary, or interfere with turf

maintenance and mowing.

3.03 PERIMETER PROTECTION

A. The Contractor shall install barriers to prevent sediment transport beyond the perimeter

of each successive work area involving disturbed soil or stockpiling of erodible materials.

B. Generally, barriers shall be silt fences, but many also include hay bales, filter logs, and

other measures.

C. Install and embed silt fence as per details on the drawings.

D. Replace deteriorated or damaged silt fencing, and remove sediment when it reaches the

one-third point.

3.04 SURFACE AND SLOPE PROTECTION

A. Finished grade for all portions of the project will be protected from erosion immediately

upon loaming and seeding.

B. All surfaces flatter than 4:1 shall be protected with a generous layer of mulch. Material

shall be held in place via repeated passes with a tracked vehicle and/or a suitable non-

toxic tackifier. Machine or hand placement is acceptable.

C. Install erosion control blanket on slopes in accordance with the following table:

Slope Range Blanket Type

3.9:1 to 3.0:1 A

2.9:1 to 2.0:1 B

1.9:1 to 1.5:1 C

1.4:1 to 1:1 D


Weston High School


3.05 CHANNEL PROTECTION

A. For constructed vegetated channels and ditches, protect from erosion with stone check

dams until growth of vegetation.

B. Height of dam should be less than the level at which ponded water will overtop the

channel.

C. Place stone check dams at spaces such that the top of the downstream dam is level with

the toe of the upstream dam.

D. Supplement check dams with Type C or D erosion control matting if necessary to stop

erosion.

E. Remove check dams upon stable growth of vegetation.

3.06 OUTLET PROTECTION

A. Prior to allowing flow through storm drains, install permanent stone outlet aprons at all

point discharges as shown on the plans.

B. Protect outlets of minor pipes which do not have permanent outlet aprons with hay bales,

wattles, and/or stone until soil stabilization.

3.07 INLET PROTECTION

A. Install means to intercept any muddy runoff from fouling existing and constructed storm

drain inlets which are downstream from construction activities (e.g., catch basins, culvert

inlets, etc.). Use any or all of the following methods, sufficient to prevent escape of

sediment.

1. Fabric and Stone Filter Method: This method employs a wire mesh placed over

an inlet grate to support a layer of crushed stone wrapped in geotextile. See

detail on plans.

2. Filter Log Method: Place one or more rings of filter logs around the perimeter of

grate or culvert inlet. Secure with stakes or pins. See detail on plans.

3. Filter Bag Method: Install removable, cleanable filter bag under grate of catch

basin. Use this method particularly for existing catch basins in pavement. See

detail on plans. Geotextile fabric stuffed under the grate is not acceptable.

3.08 CONSTRUCTION EXITS (Coordinate with Section 31 00 00)

A. Construct means to retard off-site tracking of mud or dirt at all points where vehicles

leave the site onto paved drives, streets, and highways.

B. Basic method shall employ geotextile fabric for stabilization under a layer of crushed

stone, with a mountable berm near the exit end. See detail on plans.

C. Contractor shall lengthen the installation beyond the minimum if necessary to prevent off-

site tracking.

D. Replenish stone as required for the duration of the project.

3.09 STOCKPILE PROTECTION

A. Stockpiles of excavated material, borrow material, or any other material subject to

waterborne erosion shall be protected from eroding and provided with means to block

discharge of sediment.

B. Small stockpiles of loam, etc. shall be covered with tarps.

C. In general, stockpiles should be broad and gradually sloped, to retard tendency to erode.

D. Establish temporary vegetation on all stockpiles which will not be re-used within three (3)

weeks.

E. Provide silt fencing or other perimeter protection to prevent migration of sediment.

3.10 MAINTENANCE

A. Inspect all erosion control devices daily. Immediately repair, adjust, and replace devices

if damaged, displaced, or rendered ineffective in any way. When the area is subjected to


Weston High School


a rainfall of 1 inch or more within 24 hours, all erosion control facilities shall be inspected

and repairs shall be made within 48 hours after the storm. Disposal of materials removed

from the control facilities shall be the responsibility of the Contractor as part of site

restoration and cleanup.

3.11 REMOVAL AND DISPOSAL

A. At least 70 percent of the disturbed area of the site must be established with erosion

resistant cover before interim stabilization measures and temporary erosion and

sedimentation control measures may be removed.

B. Do not remove erosion control devices and materials without prior approval of the

Architect.

C. Prior to removal of devices, remove all retained silt or other materials and dispose of as

specified in Section 31 00 00.

3.12 WASTE MANAGEMENT – Coordinate with Section 01 74 19

A. Separate and recycle materials and material packaging in accordance with Waste

Management Plan and to the maximum extent economically feasible and place in

designated areas for recycling.

B. Set aside and protect materials suitable for reuse and/or remanufacturing.

C. Separate and fold up metal banding; flatten and place along with other metal scrap for

recycling in designated area.

**End of Section**


Weston High School

KGD2018-1010 01 57 19 - 1 Environment Protection

SECTION 01 57 19

ENVIRONMENTAL PROTECTION DURING CONSTRUCTION

1.01 GENERAL


to the Conditions to the Contract and the balance of Division #1 and Technical

Specifications.






A. Scope

B. Applicable Regulations

C. Notification

D. Protection of Land Resources

E. Protection of Water Resources

F. Burning

G. Dust and Mud Control

H. Maintenance of Pollution Control Facilities During Construction

1.03 SCOPE

A. The work covered by this section consists of furnishing all labor, material and equipment

and performing all work required for the prevention of environmental pollution during and

as the result of construction operations under this contract except for those measures set

forth in other Technical Provisions of these specifications.

For the purpose of this specification environmental pollution is defined by regulatory

authorities as the presence of chemical, physical or biological elements or agents which

adversely affect human health or welfare; unfavorably alter ecological balances of

importance to human life; affect other species of importance to man; or degrade the utility

of the environment for aesthetic and recreational purposes.

The control of environmental pollution requires consideration of air, water and land, and

involves noise, solid waste-management and management of radiant energy and

radioactive materials, as well as other pollutants.

B. Compliance with the provisions of this section by all Subcontractors shall be the


1.04 APPLICABLE REGULATIONS

A. In order to provide for abatement and control of any environmental pollution arising from

the construction activities of the Contractor and his subcontractors in the performance of

this contract, they shall comply with all applicable Federal, State and local laws, and

regulations concerning environmental pollution control and abatement as well as the

specific requirements stated elsewhere in the contract specifications.

1.05 NOTIFICATION

A. The Architect will notify the Contractor in writing of any non-compliance with the foregoing

provisions. The Contractor shall, after receipt of such notice, immediately take corrective

action. Such notice, when delivered to the Contractor or his authorized representative at


Weston High School


the site of the work, shall be deemed sufficient for the purpose. If the Contractor fails or

refuses to comply promptly, the Architect may issue an order stopping all or part of the

work until satisfactory corrective action has been taken. No part of the time lost on

account of any such stop orders shall be made the subject of a claim for extension of time

or for extra costs or damages by the Contractor unless it was later determined that the

Contractor was in compliance.

1.06 PROTECTION OF LAND RESOURCES

A. It is intended that the land resources within the project boundaries and outside the limits of

permanent work performed under this contract be preserved in their present condition or

be restored to a condition after completion of construction that will appear to be natural and

not detract from the appearance of the project. Insofar as possible, the Contractor shall

confine his construction activities to areas defined by the plans or specifications.

B. The following additional requirements are intended to supplement and clarify the

requirements contained in the General Conditions.

The location on the project site of the Contractor's storage and other construction

buildings, required temporarily in the performance of the work, shall be upon assigned

portions of the job site and shall require written approval of the Architect.

The preservation of the landscape shall be an imperative consideration in the selection of

all sites and in the overall construction of buildings.

Plans showing storage and office facilities shall be submitted for approval of the Architect.

C. If the Contractor proposes or is required to construct temporary roads or embankments

and excavations for plant and/or work areas, he shall submit the following for approval at

least 21 days prior to scheduled start of such temporary work.

1. A layout of all temporary access roads, excavations and embankments to be

constructed with the work area.

2. Plans and cross sections of proposed embankments and their foundations,

including a description of proposed materials.

1.07 PROTECTION OF WATER RESOURCES

A. The Contractor shall not pollute streams, lakes, reservoirs or public waters with fuels, oils,

bitumens, calcium chloride, acids or harmful materials. It is the responsibility of the

Contractor to investigate and comply with all applicable Federal, State, County and

Municipal laws concerning pollution of surrounding public waters. All work under this

contract shall be performed in such a manner that objectionable conditions will not be

created in public waters through or adjacent to the project areas.

B. Prior to any major construction the Contractor shall submit a plan for approval by the

Architect showing his scheme for controlling erosion and disposing of waste.

C. Surface drainage from cuts and fills within the construction limits, whether or not

completed, and from borrow and waste disposal areas, shall, if turbidity producing

materials are present, be held in suitable sedimentation ponds or shall be graded to control

erosion within acceptable limits. Temporary erosion and sediment control measures such

as berms, dikes, drains, or sedimentation basins, if required to meet the above standards,

shall be provided until permanent drainage and erosion control facilities are completed and

operative. Fills and waste areas shall be constructed by selecting placement to eliminate

silts or clays on the surface that will erode and contaminate adjacent public waters.

D. At all times of the year, special measures shall be taken to prevent chemicals, fuels, oils,

grease, bituminous materials, waste washings, herbicides and insecticides, and cement

and surface drainage from entering public waters.


Weston High School


E. Disposal of any materials, wastes, effluents, trash, garbage, oil, grease, chemicals, etc., in

areas adjacent to public waters shall be subject to the approval of the Architect. If any

waste material is dumped in unauthorized areas the Contractor shall remove the material

and restore the area to the condition of the adjacent undisturbed area. If necessary,

contaminated ground shall be excavated, disposed of as directed by the Architect, refilled

with clean material and compacted all at the expense of the Contractor.

1.08 BURNING

A. Burning will not be permitted.

1.09 DUST AND MUD CONTROL

A. The Contractor shall at all times provide adequate dust control measures. He shall

accomplish this, without interference to the public and vehicular transportation by wetting

down the site daily with water trucks.

B. To control dust, it is required that all vehicles transporting dust producing materials to and

from the job shall be covered with tarpaulins securely tied down, be sprinkled when

necessary or be satisfactorily treated by other approved methods.

C. Trucks leaving excavations shall be water washed prior to entry on access roads or public

streets to remove mud and other deleterious substances from wheels and undercarriages.

D. All public and private ways adjacent to the site shall be broomed and flushed whenever

necessary in the opinion of the Architect. Drainage systems shall be cleaned and flushed

whenever mud or debris hinders the flow of storm water to or in the sewers.

E. The Contractor shall immediately remove refuse, rubbish, debris and soil accumulations on

roads, streets and on sidewalks, caused by wind, rain and snow erosions or by his own

operations to prevent traffic hazards or interference with road drainage.

1.10 MAINTENANCE OF POLLUTION CONTROL FACILITIES DURING CONSTRUCTION

A. During the life of this contract the Contractor shall maintain all facilities constructed for

pollution control under this contract as long as the operations creating the particular

pollutant are being carried out or until the material concerned has become stabilized to the

extent that pollution is no longer being created. During the construction period the

Contractor shall conduct frequent training courses for his maintenance personnel. The

curriculum shall include methods of detection of pollution, familiarity with pollution

standards, and installation and care of vegetation covers, plants and other facilities to

prevent and correct environmental pollution.

**End of Section**


Weston High School

KGD2018-1010 01 61 00 - 1 Material and Equipment

SECTION 01 61 00

MATERIAL AND EQUIPMENT

1.01 GENERAL



Specifications.




A. General Standards

B. Products

C. Sustainability

D. Transportation and Handling

E. Storage and Protection

1.03 GENERAL STANDARDS APPLICABLE TO ALL SPECIFICATION SECTIONS

A. These provisions, standards, and tolerances shall apply to all work under this Contract.

Where stricter standards and tolerances are specified elsewhere in these Specifications or

in references specified in these Specifications, they shall take precedence over these

standards and tolerances.

B. Build and install parts of the Work level, plumb, square, and in correct position unless

specifically shown or specified otherwise.

1. No part shall be out of plumb, level, square, or correct position so much as to

impair the proper functioning of the part or the Work as judged by the Architect.

2. No part shall be out of plumb, level, square, or correct position so much as to

impair the aesthetic effect of the part or the Work as judged by the Architect.

C. Make joints tight and neat. Provide uniform joints in exposed work. Arrange joints to

achieve the best visual effect. Refer choices of questionable visual effect to the Architect.

D. Under potentially damp conditions, provide galvanic insulation between different metals

which are not adjacent on the galvanic scale.

E. Manufacturers, subcontractors, and workmen shall be experienced and skillful in

performing the work assigned to them; coordinate with Article 5 of Section 00 70 00.

F. All paint used on all products shall conform to ANSI Z66.1, Specifications for Paints and

Coatings Accessible to Children to Minimize Dry Film Toxicity.

G. The Drawings do not attempt to show every item of existing work to be demolished and

every item of repair required to existing surfaces. Perform work required to remove

existing materials which are not to be saved and to restore existing surfaces to condition

equivalent to new as judged by Architect. If possible, repairs shall be indistinguishable

from adjacent sound surfaces. Where it is impossible to achieve repairs which are

indistinguishable from adjacent sound surfaces to remain, notify Architect, and proceed

according to his instructions.

1.04 PRODUCTS

A. Products include material, equipment and systems.

B. Comply with Specifications and referenced standards as minimum requirements.

C. Components required to be supplied in quantity within a Specification Section shall be the

same, and shall be interchangeable.

D. In the case of an inconsistency between Drawings and the Specifications, or within either

document which is not clarified by addendum, the product of greater quality or greater

quantity of work shall be provided in accordance with the Designer's interpretation.


Weston High School


E. Provide environmentally preferable products to the greatest extent possible. To the greatest extent possible, provide products and materials that have a lesser or reduced effect on the environment considering raw materials acquisition, production, manufacturing, packaging, distribution, reuse, operation, maintenance, and/or disposal of the product.

1.05 SUSTAINABILITY



1. Water based.

2. Water-soluble.


4. Non-flammable.

5. Biodegradable.



atmosphere.


atmosphere.




1.06 TRANSPORTATION AND HANDLING

A. Arrange deliveries of materials in accordance with construction schedules in order to avoid

delay in, conflict with, or the impeding of the progress of the Work and conditions at the

site. Deliveries shall be made during regular work hours, unless approved otherwise by

the Owner.

B. Deliver materials in undamaged condition, in manufacturer's original containers or

packaging, with identifying labels intact and legible.

1.07 STORAGE AND PROTECTION

A. Store materials in accordance with manufacturer's instructions, with seals and labels

accessible for inspection. Contractor shall be responsible for work and equipment until

fully inspected, tested and accepted. Carefully store materials and equipment which are

not immediately installed after delivery to site. Close open ends of work with temporary

covers or plug during construction to prevent entry of obstructing material or damaging

water. Materials stored on the Site shall be neatly arranged and protected, and shall be

stored in an orderly fashion in locations that shall not interfere with the progress of the

Work or with the operations of the Owner.

B. Interior Storage: Maintain temperature and humidity within the ranges required by

manufacturer's instructions.

C. Exterior Storage:

1. Store products subject to damage by the elements in weathertight enclosures.

2. Store fabricated products above the ground, on blocking or skids; prevent soiling

or staining. Cover products subject to damage or deterioration with impervious

sheet coverings; provide adequate ventilation to avoid condensation.

3. Store loose granular materials in a well drained area on solid surfaces to prevent

mixing with foreign matter. Locate away from drainage or areas subject to flooding

or storm washes.

D. If it becomes necessary to remove and restack materials to avoid impeding the progress of

any part of the Work or interfering with the work to be done by any other contractor

employed on the Work, or interfering with the Owner's activities, the Contractor shall


Weston High School


remove and restack such materials at no additional cost to the Owner.

E. Protection After Installation

1. Provide adequate coverings to protect installed materials from damage resulting

from natural elements, traffic, and subsequent construction.

2. Remove when no longer needed.

**End of Section**


Weston High School

KGD2018-1010 01 71 23 - 1 Field Engineering

SECTION 01 71 23

FIELD ENGINEERING

Part 1 - GENERAL

1.01 SUMMARY

A. This Section specified field engineering services required for the Project, including but not

limited to:

1. Survey work.

2. Civil, structural, or other professional engineering services specified, or required to

execute Contractor's construction methods.

B. Owner's representative will identify existing control points and property line corner stakes

indicated on the Drawings, as required.


A. Related Requirements

B. Qualifications of Surveyor or Engineer

C. Survey Reference Points

D. Project Survey Requirements

E. Records

F. Submittals

1.03 RELATED REQUIREMENTS

A. Examine Contract Documents for requirements that affect work on this Section. Other

Specification Sections that directly relate to work of this Section include, but are not limited

to:

1. General Conditions, and Modifications to General Conditions.

2. 01 10 00 - Description of Work

3. 01 77 00 - Project Closeout

1.04 QUALIFICATIONS OF SURVEYOR OR ENGINEER

A. Qualified engineer or registered land surveyor, acceptable to Architect and Owner.

B. Registered professional engineer of the discipline required for the specific service on the

Project, licensed in the state in which the Project is located.

1.05 SURVEY REFERENCE POINTS

A. Existing basic horizontal and vertical control points for the Project are those designated on

Drawings.

B. Locate and protect control points prior to starting sitework, and preserve all permanent

reference points during construction.

1. Make no changes or relocations without prior written notice to Architect.

2. Report to Architect when any reference point is lost or destroyed, or requires

relocation because of necessary changes in grades or locations.

3. Require surveyor to replace Project control points which may be destroyed.

a. Establish replacements based on original survey control.

1.06 PROJECT SURVEY REQUIREMENTS

A. Establish a minimum of two permanent bench marks on-site, referenced to data

established by survey control points.

1. Record locations, with horizontal and vertical data, on Project Record Documents.

B. Establish lines and levels, locate and lay out by instrumentation and similar appropriate

means:


Weston High School

KGD2018-1010 01 71 23 - 2 Field Engineering

1. Site improvements.

a. Stakes for grading, fill, and topsoil placement.

b. Utility slopes and invert elevations.

2. Batter boards for structures.

3. Building foundation, column locations, and floor levels.

4. Controlling lines and levels required for mechanical and electrical trades.

C. From tine to time, verify layouts by same methods.

1.07 RECORDS

A. Maintain a complete, accurate log of all control and survey work as it progresses.

B. On completion of foundation walls and major site improvements, prepare a certified survey

showing all dimensions, locations, angles, and elevations of construction in accordance

with the requirements of modifications to General Conditions.

1.08 SUBMITTALS

A. Submit name and address of surveyor and professional engineer to Architect.

B. On request of Architect, submit documentation to verify accuracy of field engineering work.

C. Submit certificate signed by registered engineer or surveyor certifying that elevation and

locations of improvements are in conformance, or non-conformance, with Contract

Documents.

**End of Section**

9 March 2018 WestonBID ISSUE

Weston High School

KGD2018-1010 01 74 19 - 1 Construction Waste Management

SECTION 01 74 19

CONSTRUCTION WASTE MANAGEMENT

Part 1 - GENERAL

1.01 GENERAL



Specifications.



C. Any and all “Waste Handlers and Haulers” shall be licensed by the Authority having

jurisdiction over “Solid Waste Management” and a copy of said license shall be submitted

in accordance with Article 1.05 herein.

1.02 DESCRIPTION OF WORK

A. This Section specifies requirements for a complete program for implementation of waste

management controls and systems for the duration of the Work.

B. Coordinate this work with that of Section 02 82 00 as related to the ASBESTOS

removal and disposal.

1.03 INTENT

A. The Owner has established that this Project shall generate the least amount of waste

practical and that processes that ensure the generation of as little waste as possible due to

error, poor planning, breakage, mishandling, contamination, or other factors shall be

employed.

B. Of the waste that is generated, as many of the waste materials as economically feasible

shall be reused, salvaged, or recycled. Waste disposal in landfills shall be minimized to

the greatest extent practical. With regard to these goals the Contractor shall develop, for

Owner's Representative’s and Architect’s review, a Waste Management Plan for this

Project. The Contractor shall be responsible for ensuring that debris will be disposed of at

appropriately designated licensed solid waste disposal facilities, as defined by governing

laws of the jurisdiction of the Work.

1.04 WASTE MANAGEMENT PLAN

A. Waste Management Plan: The Contractor shall provide a plan containing the following:

1. Analysis of the proposed jobsite waste to be generated, including types and rough

quantities.

2. Landfill Options: The name of the landfills where trash and building debris will be

disposed of, the applicable landfill tipping fees, and the projected cost of disposing

of all Project waste in the landfills.

3. Landfill Certification: Contractor’s statement of verification that landfills proposed

for use are licensed for types of waste to be deposited and have sufficient capacity

to receive waste from this project.

4. Alternatives to Landfilling: A list of each material proposed to be salvaged or

recycled during the course of the Project. Include the following and any additional

items proposed:

a. Cardboard.

b. Clean dimensional wood.

c. Beverage containers.

d. Land clearing debris.

e. Concrete.


Weston High School


f. Bricks and masonry.

g. Asphalt.

h. Gypsum boards.

i. Acoustical ceiling material (grid separate).

j. Metals from framing, banding, stud trim, ductwork, piping, rebar, roofing,

other trim, steel, iron, galvanized sheet steel, stainless steel, aluminum,

copper, zinc, lead, brass, and bronze.

k. Glass, colored glass allowed.

l. Plastic.

1. Type 1: Polyethylene Terephthalate (PET, PETE).

2. Type 2: High Density Polyethylene (HDPE).

3. Type 3: Vinyl (Polyvinyl Chloride or PVC).

4. Type 4: Low Density Polyethylene (LDPE).

5. Type 5: Polypropylene (PP).

6. Type 6: Polystyrene (PS).

7. Type 7: Other. Use of this code indicates that the package in

question is made with a resin other than the six listed above, or is

made of more than one resin listed above, and used in a multi-

layer combination.

m. Paint and paint cans.

n. Carpet.

o. Insulation.

p. Light Fixtures and other electrical apparatus.

q. Others as appropriate.

5. Meetings: A description of the regular meetings to be held to address waste

management.

6. Materials Handling Procedures: A description of the means by which any waste

materials identified above will be protected from contamination, and a description

of the means to be employed in recycling the above materials consistent with

requirements for acceptance by designated facilities.

7. Transportation: A description of the means of transportation of the recyclable

materials (whether materials will be site-separated and self-hauled to designated

centers, or whether mixed materials will be collected by a waste hauler and

removed from the site) and destination of materials.

1.05 SUBMITTALS

A. Construction Waste Management Plan: Submit 3 copies of plan within 21 days of date

established for the Notice to Proceed.

B. Calculations and supporting documentation to demonstrate end-of-project recycling rates

meeting the requirements for Construction Waste Management Plan of Item above.

C. For materials separated for recycling off-site, establish a method for tracking the weight of

the recycled material. The method shall be included in the CWM Plan for the Architect's

review and approval.

D. Waste Reduction Progress Reports: Concurrent with the Applications for Payment, submit

three copies of report. Include monthly tabulations for demolition and construction waste

sent off-site for disposal or recycling.

E. Waste haulers solid waste management license.


Part 3 - EXECUTION

3.01 RECYCLING


Weston High School


A. Metal, including but not limited to aluminum stairs, structural beams and sections, and

reinforcing steel shall be recycled.

B. Wood that is not painted and does not contain preservatives (i.e. creosote, arsenic, and

chromium-containing preservatives) shall be segregated and recycled.

3.02 WASTE MANAGEMENT PLAN IMPLEMENTATION – All sorting will be done “off site” by a

recognized construction and demolition processing facility who will be responsible for provision of

all documentation as to where loads were processed and the recycling rate achieved.

**End of Section **


Weston High School

KGD2018-1010 01 77 00 - 1 Project Close Out

SECTION 01 77 00

PROJECT CLOSE OUT

1.01 GENERAL







A. Final Cleanup

B. Required Close Out Documentation

C. Orientation Instruction

D. Project Close Out Inspections

1.03 FINAL CLEANUP

A. The Contractor shall leave the work ready for use and occupancy without the need of

further cleaning of any kind.

B. The Contractor shall remove all tools, appliances, project signs, material and equipment

from the phased areas as soon as possible upon completion of the work.

C. The work is to be turned over to the Owner in new condition, in proper repair and in

perfect adjustment.

1.04 REQUIRED CLOSE OUT DOCUMENTATION

A. Prior to final payment the Owner shall receive, in addition to those documents required

by the General Conditions, the following:

1. Project record documents as per Section 01 77 19.

2. Coordination drawings as per Section 01 31 14.

3. The General Contractors guarantees.

4. Specific guarantees of material, equipment and systems installed in the work.

5. A copy of all test data taken in connection with the work.

6. Three (3) copies of all operation and maintenance manuals which shall include:

a. Parts List, including illustrations, assembly drawings and diagrams

required for maintenance, predicted life of parts subject to wear, and

recommendations for stocking spare parts.

b. Copies of accepted shop drawings, charts and diagrams.

c. Names, addresses and telephone numbers of manufacturer’s

representative and service company.

d. Letters from each manufacturer certifying that his equipment was

properly installed and is operating in accordance with manufacturer’s

intent.

e. All keys, tools, screens, spare construction material and equipment

required to be furnished to the Owner as part of the work.

f. MSDS sheets tabulated and indexed as per specification sections.

g. Copies of all test reports, including balancing, and with corrections

confirmed, must be provided with the contractor’s request for a

substantial completion inspection.

h. An “Underwriter’s Certificate” shall be provided in the O&M manuals to

be provided to the Owner.

7. Copies of all Certification of Specification Compliance as per Section 01 33 00.


Weston High School

KGD2018-1010 01 77 00 - 2 Project Close Out

8. Final survey if required by Municipality AND/OR Owner.

9. Record of Material Safety Data Sheets (MSDS).

10. Certified Payroll Records.

1.05 ORIENTATION INSTRUCTION

A. Prior to final payment appropriate maintenance personnel of the Owner shall be oriented

and instructed by the Contractor in the operation of all systems and equipment as

required by the Contract.

1.06 PROJECT CLOSE OUT INSPECTIONS

A. When the Work has reached such a point of completion that the building or buildings,

equipment, apparatus or phase of construction or any part thereof required by the Owner

for occupancy or use can be so occupied and used for the purpose intended, the

Contractor, prior to notification to the Architect, shall make a preliminary inspection of the

Work to insure that all the requirements of the Contract have been met and the Work is

substantially complete and is acceptable. Upon such notification, the Architect shall

make a detailed inspection of the Work to insure that all the requirements of the Contract

have been met and that the Work is complete and is acceptable.

B. A copy of the report of the inspection shall be furnished to the Contractor as the

inspection progresses so that the Contractor may proceed without delay with any part of

the Work found to be incomplete or defective.

C. When the items appearing on the report of inspection have been completed or corrected,

the Contractor shall so advise the Architect. After receipt of this notification, the Architect

shall inform the Contractor of the date and time of final inspection. A copy of the report of

the final inspection containing all remaining contract exceptions, omissions and

incompletions shall be furnished to the Contractor.

D. After the receipt of notification of completion and all remaining contract exceptions,

omissions and incompletions from the Contractor, the Architect will reinspect the Work to

verify completion of the exception items appearing on the report of final inspection.

E. Upon completion of reinspection, the Architect will prepare a certificate of final

acceptance or will furnish to the Contractor a copy of the report of the Architect's

reinspection detailing Work that is incomplete or obligations that have not been fulfilled

but are required for final acceptance.

The Contractor shall pay the Architect for services performed in inspection beyond the

original inspection and two reinspections of the same area, through a "credit" change

order to the Owner in accordance with Schedule outlined in Section 01 25 00.

**End of Section**


Weston High School

KGD2018-1010 01 77 19 - 1 Project Record Documents

SECTION 01 77 19

PROJECT RECORD DOCUMENTS

1.01 GENERAL



Specifications.




A. Project Record Drawings

B. Record Drawing Certification

1.03 PROJECT RECORD DRAWINGS

A. The purpose of the project drawings is to record the actual location of the work in place

including but not limited to underground lines, concealed piping within buildings, concealed

valves and control equipment, and to record changes in the work.

In addition to the above, these drawings shall be "color-coded", by each trade, on a

daily basis to indicate progress of the work. Color legend will be assigned by the

Architect.

B. In addition to the sets of contract drawings that are required by the Contractor on the site

to perform the work, the Contractor shall maintain, at the site, one (1) copy of all drawings,

specifications and addenda that are part of the Contract as awarded.

Each of these documents should be clearly marked "Project Record Copy", maintained in a

clean and neat condition available at all times for inspection by the Owner or the Architect,

and shall not be used for any other purpose during the progress of the work.

The Owner's Representative, or other designee, will be the custodian of the project

record documents until the end of the Project.

C. Project Record Requirements

1. The Contractor shall mark-up the "Project Record Copy" to show:

a. Approved changes in the work.

b. Location of underground work and concealed work.

c. Details not shown in the original Contract Documents.

d. Any relocation of work including piping, conduits, ducts and the like.

e. All changes in dimensions.

f. All access doors and "tack" locations access points in accessible ceilings.

g. Location of all plumbing, heating, ventilating, air conditioning or electrical

assemblies, whether existing to remain or newly installed.

h. Revisions to any electrical circuitry.

2. Such information shall include, but shall not be limited to:

a. Any change in floor elevations.

b. Any structural changes.

c. Any substitutions.

d. Elevations and locations of all underground utilities, services, or structures

referenced to permanent above ground structures or monuments.

e. Designation of all utilities as to the size and use of such utilities.


Weston High School


f. The location of all utilities, services and appurtenances concealed in

building structures that have been installed differently from that required

by the Contract.

g. Any approved change order.

and other such data as required by the Architect and/or Owner so as to establish a

complete record of "As-Constructed" conditions.

D. The Contractor, as part of the contract requirements and at no additional cost to the

Owner, shall keep the project record documents up-to-date from day to day as the work

progresses. Appropriate documents are to be updated promptly and accurately; no work is

to be permanently concealed until all required information has been recorded.

E. The project record drawings are to be submitted by the Contractor to the Owner or the

Architect when all the work is completed and is approved by the Owner and the Architect

before the Contractor may request final payment.

If the project record drawings as submitted are found to be unacceptable due to

incompleteness or inaccurate information, the drawings shall be returned to the offending

Contractor for corrective action and resubmitted for approval prior to the release of final

payment.

FINAL PAYMENT IS CONTINGENT UPON PREPARATION OF FINAL PROJECT

RECORD DRAWINGS ON A SET OF "PRINTS" and CAD DISKETTES IN "DXF" or

“DWG” FORMAT AS APPROVED BY THE OWNER (A SET OF BASE DISKETTES WILL

BE FURNISHED BY THE ARCHITECT) AND SUBMITTAL OF SAME TO THE OWNER,

THROUGH THE ARCHITECT.

F. In addition to the drawings required as mentioned above, the Contractor shall submit a list

of all approved Shop Drawings of the Work as installed.

From this list the Architect will select the drawings desired for permanent records. The

Contractor shall furnish these in a bound set to the Owner as part of the closeout

requirements.

1.04 RECORD DRAWING CERTIFICATION

A. The record drawings required under the terms and conditions of this Section shall be

reviewed and processed by the CM/Contractor as part of their overall contractual

responsibility.

B. This certification may be issued for individual trades or as a collective document to cover

the entire record drawing requirements of the project.

The format of this certification shall be as follows:

These record drawings prepared by:

_________________________________________________________________________

for ___________________________________________________________________ have been

reviewed by the undersigned and:

Appear to be an accurate representation of the work incorporated within the project

and are accepted as submitted in accordance with the technical documents.

This record document review made by this office is for determination of compliance to the


Weston High School


requirements of the contract documents.

Firm Name: ______________________________________________________________

Review Date: __________________ By:______________________________________

**End of Section**


Weston High School

KGD2018-1010 01 78 23 - 1 Operation and MaintenanceRequirements

SECTION 01 78 23

OPERATION AND MAINTENANCE REQUIREMENTS

1.01 GENERAL



Specifications.




A. Start Up and Demonstration

B. Parts List

C. Operation and Maintenance Data

D. Content Of Manual For Mechanical Equipment And Systems

E. Content Of Manual For Electric And Pneumatic Systems As Appropriate

F. Manuals For Products, Materials, And Finishes.

1.03 START UP AND DEMONSTRATION

A. The work required herein consists of starting up and demonstrating all systems and

equipment to operating personnel and includes training of said operating personnel.

B. The respective Trade or Subcontractor shall make arrangements, via the Owner's

Representative (with notification to the Architect), as to whom the instructions are to be

given in the operation of the basic and auxiliary systems and the period of time in which

they are to be given.

C. As specified in individual sections, furnish the services of instructors to train designated

personnel in adjustment, operation, maintenance, and safety requirements of equipment

and systems. If procedures are not specified for specific items of equipment, follow that

recommended by the item Manufacturer.

D. Instructors shall be thoroughly familiar with the equipment and systems and shall be

trained in operating theory as well as practical operation and maintenance work.

Instruction shall be given after the equipment or system has been accepted and turned

over to the Owner. The duration of instruction shall be as specified in individual sections

but shall be not less than two (2) days on each portion of operating mechanical/electrical

systems. When more than four (4) days of instruction are specified, approximately one-

half of the time shall be used for classroom instructions. All other time shall be used for

instruction with the equipment or system. Use Operating and Maintenance Data as a

training guide. If requested by the Owner, videotape all demonstrations and training

sessions on VHS two hour format and provide cassettes to the Owner.

E. The Architect, and Owner's Representative, shall be completely satisfied that the

representative of the Owner has been thoroughly and completely instructed in the proper

operation of all systems and equipment before final payment is made. If the Architect, or

the Owner's Representative, determines that complete and thorough instructions have not

been given by the contractor to the Owners' Representative, then the offending Contractor

shall be directed by the Architect to provide whatever instructions are necessary until the

intent of this paragraph of the Specification has been complied with as determined by the

Architect and Owner's Representative.

1.04 PARTS LIST

A. As required the respective Trade or Subcontractor shall furnish three (3) typed sets of

instructions for the ordering and stocking of spare parts for all equipment installed. The

lists shall include parts numbered and suggested supplier. Each set shall also include an


Weston High School


itemized list of component parts that should be kept on hand and where such parts can be

purchased.

1.05 OPERATION AND MAINTENANCE DATA

A. The Contractor shall submit to the Architect for approval three (3) typed sets, bound neatly

in hard backed loose leaf binders, of all instructions for the installation, operation, care and

maintenance of all equipment, fixtures and systems.

1. Provide typed or printed label identifying binder as operating and maintenance

data. List title of project, contract number, and location of equipment.

2. Furnish manufacturer's printed data or sheets neatly typewritten on 8-1/2 inch by

11 inch, 20 pound minimum white paper. Provide indexed tabs.

3. Drawings: Bind in with text. Provide reinforcement rings. Fold larger drawings to

the size of the text pages.

Information shall indicate possible problems with equipment and suggested corrective

action.

1.06 CONTENT OF MANUAL FOR MECHANICAL EQUIPMENT AND SYSTEMS

A. Description of Unit and Component Parts:

1. Function, normal operating characteristics, and limiting conditions.

2. Performance curves, engineering data and tests.

3. Complete nomenclature and commercial number of replaceable parts.

4. Certification (specific) such as ASME for boiler.

5. Complete nameplate data for each major piece of equipment (i.e., boilers, chillers,

cooling towers, pumps, fans, heat exchangers, and similar items).

B. Operating Procedures:

1. Start-up, break-in, routine and normal operating instructions.

2. Regulation, control stopping, shutdown and emergency instructions.

3. Summer and winter operating instructions.

4. Special operating instructions

C. Maintenance Procedures:

1. Routine operations.

2. Guide to "trouble-shooting."

3. Disassembly, repair and reassembly.

4. Alignment, adjusting and checking.

D. Servicing and Lubrication Schedule:

1. List of lubricants required.

E. Manufacturer's printed operating and maintenance instructions for the exact item of

equipment supplied.

F. Description of sequence of operation by control manufacturer.

G. Original manufacturer's parts list, illustrations, assembly drawings and diagrams required

for maintenance.

1. Predicted life of parts subject to wear.

2. Items recommended to be stocked as spare parts.

H. Control diagrams by controls vendor and as-installed control drawing by Contractor.

I. Each Contractor’s Coordination Drawings: As-installed color coded piping diagrams.

J. Charts of valve tag numbers, with the location and function of each valve.

K. List of original manufacturer’s spare parts, manufacturer’s current prices, and

recommended quantities to be maintained in storage.

L. Other data as required under pertinent sections of specifications.

1.07 CONTENT OF MANUAL FOR ELECTRIC AND PNEUMATIC SYSTEMS AS APPROPRIATE

A. Description of System and Component Parts:


Weston High School


1. Catalog data containing information required for service, future additions or

substitutions.

2. Function, normal operating characteristics, and limiting conditions.

3. Performance curves, engineering data and tests.

4. Complete nomenclature and commercial number of replaceable parts.

B. Circuit Directories of Panelboards:

1. Electrical service.

2. Controls.

3. Communications.

C. As-installed Color Coded Wiring Diagrams, i.e., ladder diagrams, point-to-point diagrams,

loop diagrams, and similar items.

D. Operating Procedures:

1. Routine and normal operating instructions.

2. Sequences required.

3. Special operating instructions.

E. Maintenance Procedures:

1. Routine operations.

2. Guide to “trouble-shooting.”

3. Disassembly, repair and reassembly.

4. Adjustment and checking.

F. Manufacturer’s printed operating and maintenance instructions.

G. List of original manufacturer’s spare parts, manufacturer’s current prices, and

recommended quantities to be maintained in storage.

H. Other data as required under pertinent sections of specifications.

1.08 MANUALS FOR PRODUCTS, MATERIALS, AND FINISHES:

A. Submit three (3) copies of complete manual.

B. Content: Provide complete information for architectural products, applied materials, and

finishes.

1. Manufacturer's data, including catalog number, size, composition, color and

texture designations, and information for reordering.

2. Instructions for care and maintenance, including manufacturer's recommendations

for cleaning agents and methods; cautions against detrimental cleaning agents

and methods; and recommended schedule for cleaning and maintenance.

**End of Section**


Weston High School

KGD2018-1010 06 10 00 - 1 Carpentry - Rough

SECTION 06 10 00

ROUGH CARPENTRY

1.01 Applicable provisions of the Conditions of the Contract and Division #1, General Requirements,

govern work in this Section.


A. The work of this Section consists of the provision of all plant, materials, labor and

equipment and the like necessary and/or required for the complete execution of all rough

carpentry work for this project as required by the schedules, keynotes and drawings,

including, but not limited to the following:

1. For field replacement work, provide “bridge” for straddling of jogging track to

provide access to “field” for the turf replacement.

1.03 RELATED WORK SPECIFIED ELSEWHERE - Entire Project Specification.

1.04 QUALITY ASSURANCE

A. All materials used for work of this Section shall conform with Voluntary Product Standards

and trade Association Units as follows:

1. Northeastern Lumber Manufacturer's Association Inc. (NELMA); Southern Pine

Inspection Bureau (SPIB); Western Wood Products Association (WWPA).

2. American Plywood Association (APA); Douglas Fir Plywood Association (DFPA).

3. Architectural Wood Work Institute (AWI)

4. American Society for Testing and Materials (ASTM).

5. American Wood Preservers' Association and Institute (AWPA) (AWPI)

6. Applicable Federal Specifications for fasteners, bolts, nails, screws, etc.

7. Structural standards as set forth by American Forest and Paper Association

(AFPA)

8. Connecticut State Building Code.

9. Underwriters' Laboratories, Inc. (UL) - Building Materials Directory, Sections

BPVV, BUGV and as applicable to materials specified within this Section.

Reference Standards Specific to Fire Retardant Treatments in addition and/or supplement

to those voluntary standards set forth above.

1. ASTM D 3201 - Test Method for Hygroscopic Properties of Fire Retardant Wood.

2. ASTM E 84 - Standard Test Method for Surface Burning Characteristics of Building

Materials - Extended 30 minute test.

3. Military Specifications MIL-L-19140E - Lumber and Plywood, Fire Retardant

Treated.

C. Identify each piece of dimensional lumber and plywood with Underwriters Laboratories,

Inc. mark certifying surface burning characteristics, interior Type A in accordance with

AWPA C-20 (Lumber) AWPA C-27 (Plywood), kiln-dried after treatment (KDAT).

Identification mark shall also indicate monitoring by Timber Products Inspection, Inc., in

accordance with nominated manufacturers standard governing such work.

1.05 SUBMITTALS – Coordinate with Section 01 33 00

Submittals shall be made in groupings where installations are complementary.

Failure to comply with this requirement will be cause for rejection of any or all submittals.

As set forth in Sections 01 33 00 and 01 32 00, prepare and submit a fully

developed submittal schedule; note review times set forth in Section 01 33 00 are

deemed “average”, for large submissions allow longer review times.


Weston High School


The Contractor is encouraged to submit for approval products made from recycled

and/or environmentally responsible material. Every effort will be made by the Design

Professional Team to approve these materials; the substitution request procedure

shall still be enforced.

A. Certification of specification compliance for materials incorporated in the work including the

National Evaluation Report discussing high temperature strength testing, flame spread,

corrosion, and hygroscopic properties for fire retardant treatments.

B. Material Safety Data Sheet (MSDS) must be submitted for each product.

1.06 PRODUCT DELIVERY, STORAGE AND HANDLING (Coordinate with Section 01 61 00)

A. Deliver all materials to the job site clearly labeled as to product, manufacturer, color and/or

other pertinent characteristics.

B. Pile lumber to insure proper ventilation and drainage.

C. Store materials a minimum of 6 inches above ground on framework or blocking and cover

with protective waterproof covering providing for adequate air circulation or ventilation.

D. Protect fire retardant materials against high humidity and moisture during storage and

erection. Keep materials dry during delivery and storage.

Part 2 - PRODUCTS

2.01 GENERAL

A. Grade Marking: Grade Mark, trademark and mill identification of the trade association

having jurisdiction shall appear on each piece of standard yard dimension lumber (not

boards) except that the shipment may instead be accompanied by a Certificate of

Inspection identifying Compliance with these Specifications. This certificate shall be

issued by an agency authorized to grade by the manufacturer's association recognized as

responsible for grading rules for species involved.

B. Moisture Content: Lumber 2 inches and less in thickness, and boards, shall not exceed

19%.

C. SIZING: Surface lumber 4 sides as per Simplified Practice Recommendations PS16, latest

edition.

D. Lumber for concealed work shall be fire and/or preservative treated and of suitable

construction grade species.

2.02 PLYWOOD

A. General Purpose, Exposed - one side and painted - APA MDO EXT.

B. Waterproof use - MARINE A-A EXT-APA, PSl-74.000, 5/8 inch minimum thickness.

2.03 GLUES AND ADHESIVES - All adhesives used in the work of this project shall be VOC

compliant in accordance with requirements of the applicable codes.

2.04 CARPENTER IRON AND ROUGH HARDWARE

A. All anchorage items shall be sized to meet requirements and conditions at the site. All

anchorage items shall be non-corrosive steel. Provide backup plates and other devices as

part of the work of this Section.

Part 3 - EXECUTION

3.01 INSPECTION AND ACCEPTANCE

A. Examine all surfaces and contiguous elements to receive work of this section and correct,

as part of the Work of this Contract, any defects affecting installation. Commencement of


Weston High School


work will be construed as complete acceptability of surfaces and contiguous elements.

3.02 WORKMANSHIP AND CONSTRUCTION, GENERAL

A. All work hereunder shall be executed by mechanics skilled in the trade.


A. Separate wood waste in accordance with the Waste Management Plan.

B. Separate the following categories for salvage or reuse on site:

1. Sheet materials larger than 2 sq. ft.

2. Solid wood:

a. Trim longer than 16 inches

b. Multiple offcuts of any size larger than 12 inches

C. Recycle the following categories:

1. Clean, unpainted engineered wood products

2. Clean, unpainted dimensional lumber

D. Separate the following categories for disposal and place in designated areas for hazardous

materials:

1. Treated, stained, painted, or contaminated wood

**End of Section**


Weston High School

KGD 2018-1010 31 00 00 - 1 Site Preparation, et.al.

SECTION 31 00 00

SITE PREPARATION, EXCAVATION, GRADING AND AMENITIES

Part 1 - GENERAL




A. The work of this Section consists of the provision of all plant, materials, labor and equipment

and the like necessary and/or required for the complete execution of all grading and shaping

for this project in connection with the replacement of the synthetic turf. Coordinate with

Section 32 90 02 for restoration of existing seeded areas.

Coordinate with 06 10 00 for materials in connection with “bridge” over jogging track as

required and as may be so noted on the drawings.



A. Reference Standard: All work herein shall be governed by the requirements set forth in the

"State of Connecticut Department of Transportation, Standard Specifications for Roads,

Bridges and Incidental Construction", Form 816, 2004 Edition plus latest amendments. All

payments shall be on a "Lump Sum" basis unless otherwise directed on the drawings or

within these project specific specifications.







The Contractor is encouraged to submit for approval products made from recycled and/or

environmentally responsible material. Every effort will be made by the Design



A. Samples: For the following:

1. 30-lb. samples, sealed in airtight containers, of each proposed soil material from on-

site or borrow sources.

B. Material Test Reports: From a qualified testing agency indicating and interpreting test

results for compliance of the following with requirements indicated:

1. Classification according to ASTM D 2487 of each on-site or borrow soil material

proposed for fill and backfill.

2. Laboratory compaction curve according to ASTM D 1557 for each on-site or borrow

soil material proposed for fill and backfill.

1.06 JOB CONDITIONS

A. All protection work and general operations shall be governed by the requirements of OSHA,


Weston High School


as most recently amended; as well as by Local and State environmental requirements.

B. Existing grades and other existing conditions are shown on the drawings to the best

knowledge of the Architect. It is the responsibility of the Contractor to visit the site and to

verify all existing conditions.

C. The Contractor shall take proper precautions not to damage any existing site conditions

specifically excluded or excepted from the Contract and will be held solely responsible for

any damage occurring during the course of the work under construction. The Contractor

shall, at his own expense, make any and all repairs as required to restore to the original

condition any area or item so damaged or disturbed due to work required by this Contract.

D. During the construction period, the Contractor shall take special measures including, but not

limited to, wetting down, applying approved dust palliatives, etc., to control dust on site, in

order to prevent annoyance and/or damage to adjacent property, whether public or private.

COORDINATE WITH ENTIRE SECTION 01 57 19 WITH SPECIFIC ATTENTION

DIRECTED TO REQUIREMENTS SET FORTH THEREIN CONCERNING MAINTENANCE

OF PUBLIC WAYS.

E. The Contractor shall take all necessary measures to keep streets, over which equipment

and service for project travel, clean and free from dirt, dust, mud and debris resulting from

construction operations. The actions taken shall meet the requirements of all parties having

jurisdiction. Coordinate with the applicable requirements of Division #1.

1.07 SOIL TESTING AND INSPECTION SERVICES

A. All operations under this Section of the Specifications shall be subject to the continuous

observation of the Architect (or his designee), and of a soils testing laboratory, engaged by

the Owner.

The Architect (or his designee) will determine conformance of materials and workmanship,

particularly compaction, to the requirements of this Specification. The laboratory shall make

such tests of materials and compaction as the Architect (or his designee) directs. Testing

will be performed so as to least encumber the performance of the work.

B. When work of this Section or portions of work are completed, notify the testing laboratory to

perform density testing. Do not proceed with additional portions of the work until results

have been verified.

C. If, during progress of the work, tests indicate that compacted materials do not meet specified

requirements, remove defective work, replace and retest at no additional cost to the Owner,

as directed by the Architect.

Part 2 - PRODUCTS

2.01 GENERAL - All materials shall be governed by the applicable portions of the REFERENCE

STANDARDS set forth in Part 1 above.

2.02 SELECT STRUCTURAL FILL (Granular Fill)

A. Well graded natural sand and gravel free from organic material, loam, trash, snow, ice,

frozen soil and other objectionable material and shall be well graded and conforming to the

following gradation:

U.S. SIEVE NO. TOTAL % PASSING BY WEIGHT

Max. Min.

4" --- 100

1" 100 60

4 85 25

20 55 10

40 35 5


Weston High School


200 5 ---

(Reference Test Method ASTM D 422)

2.03 CRUSHED STONE

A. All material to be placed where Specifications or Drawings call for crushed stone shall be

clean washed gravel or crushed stone conforming to ASTM Designation C 33 Size 57, 1

inch to No. 4, graded as follows:

U.S. SIEVE NO. TOTAL % PASSING BY WEIGHT

Max. Min.

1" --- 100

3/4" 100 90

3/8 55 20

4 10 0

8 5 0

2.04 EROSION CONTROL – See Section 01 57 13 and Paragraph 3.05

Part 3 - EXECUTION

3.01 DEFINITIONS

A. "Finished grades," "finished grade lines," "level" or "levels," "elevation" or "elevations" mean

finished elevations as indicated on the drawings.

B. The term "Site" generally refers to that area within the Contract Limit Lines or as may

otherwise be defined on the drawings.

C. "Disposal" shall mean safe and legal disposal off the project site, or off the Owner's property.

No material shall be burned on the project site, or on the Owner's property.

D. "Rough grading" shall mean excavating or filling to elevations indicated, with the additional

required depths described herein.

The permissible tolerance of rough grading within an area 100 feet square, shall not exceed

plus or minus 0.2 feet. The cost of required fill or additional topsoil or materials resulting

from rough grades lower than as designed, shall be borne by the Contractor.

3.02 ANTI-TRACKING PADS

A. Construct site access (at each entrance) as an “anti-tracking pad” a minimum of 15 feet in

width by at least 50 feet in length. Construction to be of a layer of filter fabric over existing or

revised grade followed by a 6 inch minimum layer of 2 inch crushed stone choked with fines

(dry bound macadam) and rolled. Area shall be maintained throughout the entire period;

“pad” to be removed and curb/walk/green strip to be restored under ensuing contract.

3.03 EXCAVATION AND GRADING - General

A. Excavation and grading work shall include the shaping of the entire site as shown to

accommodate the construction contemplated under this Contract and to comply with

compaction requirements and grade to cross sections, lines, and elevations indicated.

B. Cut out soft spots, fill low spots, and trim high spots to comply with required surface

tolerances.

C. Site Grading: Slope grades to direct water away from buildings and to prevent ponding.

Finish subgrades to required elevations within the following tolerances:

D. If directed, remove unstable soil and replace with sand or gravel thoroughly compacted, in

accordance with applicable Article of the Contract and General Conditions.

3.04 EROSION AND SEDIMENTATION CONTROL – Coordinate with Section 01 57 13; Most Restrictive


Weston High School


Provisions Apply

A. Contractor shall be responsible for all control measures necessary to prevent damage

resulting from erosion and sedimentation to on-site and off-site areas.

3.05 SUBBASE AND BASE COURSES

A. Under pavements and walks, place subbase course material on prepared subgrades. Place

base course material over subbases to pavements.

B. Compact subbase and base courses at optimum moisture content to required grades, lines,

cross sections and thickness to not less than 95 percent of ASTM D 1557 relative density.

C. Shape subbase and base to required crown elevations and cross-slope grades.

D. When thickness of compacted subbase or base course is 6 inches or less, place materials in

a single layer.

E. When thickness of compacted subbase or base course exceeds 6 inches, place materials in

equal layers, with no layer more than 6 inches thick or less than 3 inches thick when

compacted.

3.06 PROTECTION

A. Protecting Graded Areas: Protect newly graded areas from traffic, freezing, and erosion.

Keep free of trash and debris.

B. Repair and reestablish grades to specified tolerances where completed or partially

completed surfaces become eroded, rutted, settled, or where they lose compaction due to

subsequent construction operations or weather conditions.

C. Scarify or remove and replace soil material to depth as directed by Architect; reshape and

recompact.

D. Where settling occurs before Project correction period elapses, remove finished surfacing,

backfill with additional soil material, compact, and reconstruct surfacing.

E. Restore appearance, quality, and condition of finished surfacing to match adjacent work,

and eliminate evidence of restoration to the greatest extent possible.

3.07 DISPOSAL OF SURPLUS AND WASTE MATERIALS – Coordinate with Section 01 74 19

A. Remove surplus satisfactory soil to designated storage areas on Owner's property or legally

dispose of same off the project site. If material is to remain on site, stockpile or spread as

directed by Architect.

B. Remove any and all waste material, unsatisfactory soil, trash, and debris, and legally

dispose of it off Owner's property.

3.08 CLEANUP

A. All areas within the project site shall be raked clean of all trash, wood forms and other debris

upon completion of the work specified herein, spoil piles leveled and excess materials

disposed of as directed by the Architect.

B. Any soil or similar material which has been brought onto paved areas by hauling operations

or otherwise shall be removed promptly, keeping these areas clean at all times.

**End of Section**


Weston High School

KGD2018-1010 32 10 00 - 1 Pavements

SECTION 32 10 00

PAVEMENTS AND SURFACING

Part 1 - GENERAL

1.01 Applicable provisions of the General Conditions of the Contract and Division #1, General

Requirements, govern work in this Section.



equipment and the like necessary and/or required for the complete execution of all

required patching of existing pavements that maybe damaged as a result of this work.

Document existing conditions of existing prior to start of work by photographs.



A. Manufacturer Qualifications: A paving-mix manufacturer registered with and approved by

authorities having jurisdiction or the DOT of state in which Project is located.

B. Testing Agency Qualifications: Qualified according to ASTM D 3666 for asphalt

pavement testing indicated.

C. All protection work and general operations shall be governed by the requirements of

OSHA, as most recently amended.

D. The Contractor shall take proper precautions not to damage any existing site conditions




condition any area or item so damaged.

E. Comply with all requirements established in Section 01 57 19 of these Specifications.

F. REFERENCE STANDARD: All work herein shall be governed by the requirements set

forth in the "State of Connecticut Department of Transportation, Standard Specifications

for Roads, Bridges and Incidental Construction", Form 816, 2004 Edition plus latest

amendments.. All payments shall be on a "Lump Sum" basis unless otherwise directed

on the drawings or within these project specific specifications.

G. Preinstallation Conference: Conduct conference at Project site.

1. Review methods and procedures related to hot-mix asphalt paving including, but

not limited to, the following:

a. Review proposed sources of paving materials, including capabilities and

location of plant that will manufacture hot-mix asphalt.

b. Review requirements for protecting paving work, including restriction of

traffic during installation period and for remainder of construction period.


Submittals shall be made in groupings where installations are complementary. Failure to

comply with this requirement will be cause for rejection of any or all submittals.

As set forth in Sections 01 33 00 and 01 32 00, prepare and submit a fully developed

submittal schedule; note review times set forth in Section 01 33 00 are deemed

“average”, for large submissions allow longer review times.


Weston High School

KGD2018-1010 32 10 00 - 2 Pavements



Professional Team to approve these materials; the substitution request procedure shall

still be enforced.

A. Certification of Specification Compliance

B. Plant mix design for pavement systems, curbs and the like.

1. Before asphaltic concrete paving is constructed, submit actual design mix to the

Architect for review and approval. Design mix submittal shall follow a format as

indicated in Asphalt Institute Manual MS-2, Marshall Stability Method; and shall

include type/name of mix, gradation analysis, grade of asphalt cement used,

Marshall Stability in pounds (lb.) flow, effective asphalt content in percent (%),

and direct references to state highway department specifications sections for

each material. Design shall be for mixture listed in governing DOT Construction

and Material Specifications, latest edition. Mix designs over 3 years old will not

be accepted by Owner.

C. Sieve tests of base courses for pavement systems.

D. Samples of all other materials to be used in the work.

E. Material Safety Data Sheet (MSDS) must be submitted for each product.

1.06 PREPARATION

A. Subgrades shall be true to line and grade after compaction with a maximum tolerance of

1/4 inch either way. Compaction shall be to a minimum of 95% maximum density at

optimum moisture.

B. Density test shall be ASTM D 1557-70, Method D. Testing shall be by a laboratory

designated by the Architect and paid for by the Contractor.

C. Remove soft and yielding materials which will not compact readily when rolled or tamped.

Replace with pavement base course or other approved fill material. Ram or roll until firm

and level with adjacent grade.

D. Check for correct elevations and position of all inlet grates, manhole covers, valve boxes

and other site structures located within work areas and make any necessary adjustments

to same.

E. Subgrade shall be smooth, hard and dry prior to placement of paving system. Should

subgrade become rutted or displaced due to any cause, the Contractor shall regrade and

compact as per base specifications without additional payment.

1.07 PROJECT CONDITIONS

A. Environmental Limitations: Do not apply asphalt materials if subgrade is wet or

excessively damp, if rain is imminent or expected before time required for adequate cure,

or if the following conditions are not met:

1. Prime Coat: Minimum surface temperature of 60 deg F (15.6 deg C).

2. Tack Coat: Minimum surface temperature of 60 deg F (15.6 deg C).

3. Slurry Coat: Comply with weather limitations in ASTM D 3910.

4. Asphalt Base Course: Minimum surface temperature of 40 deg F (4.4 deg C)

and rising at time of placement.

5. Asphalt Surface Course: Minimum surface temperature of 60 deg F (15.6 deg C)

at time of placement.

1.08 SUSTAINABILITY




Weston High School

KGD2018-1010 32 10 00 - 3 Pavements

1. Water based.

2. Water-soluble.


4. Non-flammable.

5. Biodegradable.



atmosphere.


atmosphere.




Part 2 - PRODUCTS

2.01 GENERAL

A. All materials shall be governed by the applicable portions of the REFERENCE

STANDARDS set forth in Part 1 above or as maybe modified herein.

2.02 ASPHALTIC PAVING SYSTEMS

A. Bituminous concrete pavement shall conform to referenced standard Specifications,

Section 4.06 and appropriate materials sections.

B. Sub Base Course shall comply with Section 2.12.

C. The materials and composition for the respective courses shall meet the requirements

specified in reference standard Section M.02 and M.04.

2.03 CONCRETE

A. Concrete walks shall conform to the referenced standard Specifications, Sections 9.21

and 9.22, except as otherwise noted.

B. Supports: Provide supports for reinforcement including bolsters, chairs, spacers and

other required devices for spacing, supporting or fastening wire fabric in place.

2.04 PAVEMENT MARKING PAINT

A. Materials shall conform to referenced standard Specification, Section 12.09, Painted

Pavement Markings fast drying type, white, and appropriate materials Section M.07.20

2.04 EQUIPMENT

A. All equipment necessary for the paving be on the project prior to beginning paving

operations.

B. Maintain equipment in satisfactory operating condition and correct breakdowns in

manner that will not delay or be detrimental to the schedule of paving operations.

Part 3 - EXECUTION


A. Examine all surfaces and contiguous elements to receive work of this section and

correct, as part of the Work of this Contract, any defects affecting installation.

Commencement of work will be construed as complete acceptability of surfaces and

contiguous elements.

B. Proof-roll subgrade below pavements with heavy pneumatic-tired equipment to identify

soft pockets and areas of excess yielding. Do not proof-roll wet or saturated subgrades.


Weston High School

KGD2018-1010 32 10 00 - 4 Pavements

1. Proof-roll activities shall be observed by the Geotechnical Engineer.

2. Completely proof-roll subgrade in one direction, repeating proof-rolling in

direction perpendicular to first direction. Limit vehicle speed to 3 mph.

3. Proof roll with a loaded 10-wheel, tandem-axle dump truck weighing not less

than 15 tons.

4. Excavate soft spots, unsatisfactory soils, and areas of excessive pumping or

rutting, as determined by Architect, and replace with compacted backfill or fill as

directed.

C. Proceed with paving only after unsatisfactory conditions have been corrected and the

Geotechnical Engineer accepts the soil conditions.

3.02 ASPHALTIC CONCRETE PAVEMENTS

A. Asphalt pavements shall consist of course construction shown and/or suitable for

intended application.

B. The construction details shall comply with the requirements specified in the referenced

Standard.

C. Bituminous paving mixtures shall be placed on surfaces having a temperature of 45

degrees F or greater unless otherwise authorized by the Architect. These items are

subject to seasonal limitations, and shall be placed only during the period of April 1 to

November 15. The Contractor shall schedule the paving operations such that all paving

necessary to provide safe and adequate maintenance and protection of traffic or for

protection of previously laid courses is completed within the weather and seasonal

limitations.

D. Whenever possible, spread pavement by finishing machine; however, inaccessible or

irregular areas may be placed by hand methods. Spread hot mixture uniformly to

required depth with hot shovels and rakes. After spreading, carefully smooth hot mixture

to remove segregated course aggregate and rake marks. Rakes and lutes used for hand

spreading shall be type designed for use on asphalt mixtures. Do not dump loads faster

that they can be properly spread. Workers shall not stand on loose mixture while

spreading.

E. Paving Machine Placement: Apply successive lifts of asphaltic concrete in transverse

directions with surface course placed parallel to flow of traffic. Place asphaltic paving in

typical strips not less than 10 feet wide. Two (2) or more equal lifts required if same

materials are used, each lift being no thicker than 3 inches, no less than 1 inch. Under

no circumstances will only one lift of asphalt concrete paving be allowed.

F. The finished pavement at joints shall comply with the surface smoothness requirements

and exhibit the same uniformity of texture and compaction as other sections of the

course. Rollers shall not pass over the unprotected edges of a freshly laid mixture

unless permitted by the Architect.

G. In the formation of all joints, the exposed edge of the existing layer that will become part

of the joint shall be the full thickness of the layer and straight. If the existing edge is

unacceptable, the edge shall be corrected by using a power driven saw or other

approved tools to cut a neat line.

H. A light coat of bituminous material shall be applied to existing pavement edges and/or

surfaces in order to provide bond with the newly laid pavement. Care shall be taken to

avoid spraying exposed concrete surfaces with the tack coat by appropriate protection

methods.

I. The surface shall be tested by the Contractor in the presence of the Architect with a 16

foot straightedge or string line placed parallel to the centerline of pavement and with a 10

foot straightedge or string line placed transversely to the centerline of pavement on any

portion of the pavement surface. Variations exceeding 1/4 inch shall be satisfactorily

corrected or the pavement relaid at no additional cost to the Owner.


Weston High School

KGD2018-1010 32 10 00 - 5 Pavements

J. The thickness indicated for each of the various courses of bituminous pavement is the

nominal thickness. The pavement shall be so constructed that the final compacted

thickness is as near to the nominal thickness as is practical, but in no case 1/8 inch less

than the required thickness.

K. Protection: After final rolling, do not permit vehicular traffic on pavement until it has

cooled and hardened. Erect barricades to protect paving from traffic until mixture has

cooled enough not to become marked. Any masked or marred finish surfaces shall be

repaired or smoothed.

3.03 FINISHING OF ASPHALTIC CONCRETE PAVING SYSTEMS

A. Finishing of bituminous concrete surface: For the purpose of testing the finished surfaces

of the base courses and/or binder course and the top course of compacted mixtures, a

10 foot straightedge shall be used. The straightedge shall be carefully applied

immediately after first compaction by rolling, and from then on, as may be necessary until

and after the final compaction of the material in place. The straightedge shall be held in

successive positions parallel to the direction of paving and in contact with the surface;

and the entire area checked from one side to the other of the pavement. Any irregularity

in the finished surface which varies more than 1/4 inch from a true surface shall be

corrected. Any irregularity in the binder or base course which varies 3/8 inch or more

from a true surface shall be corrected Irregularities which may develop before the

completion of rolling and while the material is still workable may be remedied by

loosening the surface mixture and removing or adding material as necessary. Any

unsatisfactory irregularities, defects, or any standing water remaining after final

compaction shall be corrected by removing and replacing with new material, as specified,

to form a true and even surface. All minor surface projections, joints and minor honey-

combed surfaces shall be ironed out smoothly to grade, as directed in the field by the

Architect. Adequate and approved straightedges shall be furnished and used by this

Contractor. The Contractor shall provide or designate a competent employee whose

duty shall be to carefully use the straightedge to check the compacted surfaces.

3.04 PATCHING OF EXISTING ASPHALTIC PAVEMENTS

A. Asphalt Pavement: Saw cut perimeter of patch and excavate existing pavement section

to sound base. Excavate rectangular or trapezoidal patches, extending 12 inches into

perimeter of adjacent sound pavement, unless otherwise indicated. Cut excavation faces

vertically. Remove excavated material. Recompact existing unbound-aggregate base

course to form new subgrade.

B. Tack Coat: Before placing patch material, apply tack coat uniformly to vertical asphalt

surfaces abutting the patch.

1. Allow tack coat to cure undisturbed before applying hot-mix asphalt paving.

2. Avoid smearing or staining adjoining surfaces, appurtenances, and surroundings.

Remove spillages and clean affected surfaces.

C. Placing Patch Material: Partially fill excavated pavements with hot-mix asphalt base mix

and, while still hot, compact. Cover asphalt base course with compacted, hot-mix

surface layer finished flush with adjacent surfaces.

3.05 CLEANUP

A. All debris resulting from operations shall be removed daily and site shall be left clean at

the completion of the Project.

3.06 FIELD QUALITY CONTROL


Weston High School

KGD2018-1010 32 10 00 - 6 Pavements

A. Testing Agency: Owner will engage a qualified testing agency to perform tests and

inspections. Testing requirements for concrete pavements and other elements shall be

as specified in Section 03 30 00.

B. Thickness: In-place compacted thickness of hot-mix asphalt courses will be determined

according to ASTM D 3549.

C. Surface Smoothness: Finished surface of each hot-mix asphalt course will be tested for

compliance with smoothness tolerances.

D. In-Place Density: Testing agency will take samples of uncompacted paving mixtures and

compacted pavement according to ASTM D 979 or AASHTO T 168.

1. Reference maximum theoretical density will be determined by averaging results

from four samples of hot-mix asphalt-paving mixture delivered daily to site,

prepared according to ASTM D 2041, and compacted according to job-mix

specifications.

2. In-place density of compacted pavement will be determined by testing core

samples according to ASTM D 1188 or ASTM D 2726.

a. One core sample will be taken for every 1000 sq. yd. or less of installed

pavement, with no fewer than three cores taken.

b. Field density of in-place compacted pavement may also be determined

by nuclear method according to ASTM D 2950 and correlated with

ASTM D 1188 or ASTM D 2726.

E. Replace and compact hot-mix asphalt where core tests were taken.

F. Remove and replace or install additional hot-mix asphalt where test results or

measurements indicate that it does not comply with specified requirements.








D. Handle asphalt-paving waste according to approved waste management plan.

**End of Section**


Weston High School

KGD2018-1010 32 18 13 - 1 Synthetic Turf Replacement

SECTION 32 18 13

FILLED SYNTHETIC TURF

Part 1 - GENERAL

1.01 Applicable provisions of the Conditions of the Contract and Division #1, General Requirements, govern work in this Section.

1.02 DESCRIPTION OF WORKA. The work of this Section consists of the provision of all plant, materials, labor and

equipment and the like necessary and/or required for the complete removal and replacement of the synthetic turf and miscellaneous repairs to the base and infill materials as indicated on the plans and as specified herein for the field as indicated. The existing nailer shall be exposed and portions of nailer that are un-useable, shall be removed and repaired or replaced at Contractors option. This applies to the concrete curb as well.

NOTES:

Field grading at base and each layer will be done with laser guided equipment (graders

and bull dozers), confirmed with spot elevations at 9 to 10 points on the field at each

level.

Alternatively, should laser equipment not be used for any reason, each level will be

checked by a licensed survey crew, on a 20’ x 20’ grid (approx. 220 points) at

contractor’s sole expense.

The final survey evidencing the surveying points shall be submitted as part of the

record documents as required in Section 01 77 19.

1.03 RELATED WORK SPECIFIED ELSEWHERE - Entire Project Specification

1.04 QUALITY ASSURANCEA. All work herein shall be governed by the requirements set forth in the "State of

Connecticut Department of Transportation, Standard Specifications for Roads, Bridges and Incidental Construction", Form 816, 2004 Edition plus latest amendments. All payments shall be on a "Lump Sum" basis unless otherwise directed on the drawings or within these project specific specifications

B. The synthetic turf system supplier must demonstrate successful experience:1. in the manufacture and installation of at least five (5) installations per year for the

last 5 years of the specific types of infill synthetic turf systems as specified hereinafter;

2. at least five (5) installations installed over a prefabricated rubber shock pad requested as an alternate proposal as applicable.

C. The synthetic turf manufacturer and the field builder each must certify the designated installation supervisory personnel and his crewmembers on the project. A letter on turf manufacturer’s letterhead must be submitted affirming the system installer as competent in the installation of the specified system, including seams and proper installation of their product. The crew must also have installed at least 10 fields over a porous rubber shock pad over the last 3 years.

D. Manufacturer Certificates:


Weston High School


1. Certified list of five (5) existing installations with sand and rubber infill installed over a pre-manufactured rubber shock pad similar to what is specified for this project that have been in use for at least three full athletic seasons, including Owner representative and telephone number, attesting compliance with quality assurance information. All must be located in the continental United States.

2. Must have at least ten (10) synthetic turf 100% slit film and/or mono/parallel long slit hybrid systems installed over a shock pad in NYS.

3. The synthetic turf vendor and fiber manufacturer must certify in writing that

no lead or lead chromate was used in the manufacturing of the synthetic

turf system furnished for this project.

4. The synthetic turf vendor must certify that the infill material is NEW and not

reclaimed and shall provide proof of purchase along with the bill of lading

and delivery receipts to the project site.

5. This information must be submitted for review by architect/owner’s

representative before the synthetic turf contractor/manufacturer/installer

will be accepted.

E. Installation of synthetic turf system shall be done only after any and all preparatory work has been completed and approved by the synthetic turf manufacturer. Damage caused during construction shall be repaired or replaced before acceptance, at no additional cost to the owner.

F. Coordinate the installation of the synthetic turf and surrounding surfaces for optimum interface at all edges.

G. The Contractor shall engage in independent testing agency to test and prepare a report on the installed synthetic turf as described herein. The Owner reserves the right to engage an independent Testing Agency for testing as necessary.

H. Pre-Installation Conference: Conduct conference at project site at time to be determined by Architect. Review methods and procedures related to installation including, but not limited to, the following:1. Inspect and discuss existing conditions and preparatory work performed under

other contracts.2. In addition to the Contractor and the installer, arrange for the attendance of

installers affected by the Work, The Owner’s representative, and the Architect.


Submittals shall be made in groupings where installations are complementary. Failure to comply with this requirement will be cause for rejection of any or all submittals.

As set forth in Sections 01 33 00 and 01 32 00, prepare and submit a fully developed submittal schedule; note review times set forth in Section 01 33 00 are deemed “average”, for large submissions allow longer review times.

The Contractor is encouraged to submit for approval products made from recycled and/or environmentally responsible material. Every effort will be made by the Design Professional Team to approve these materials; the substitution request procedure shall still be enforced.

A. Product Data1. Synthetic Turf2. Infill Material3. Plastic Lumber

B. Data


Weston High School


1. All other Synthetic Turf System components;2. Printed installation instructions;3. Installer experience (list of completed projects);4. All quality assurance requirements;5. Maintenance Manuals – Provide 3 copies. Manual shall include all necessary

instructions for the proper care and maintenance of the playing surface;6. Special grooming equipment (Alternate Proposal)

C. Shop Drawings and Product Data1. Provide shop drawing of all field layouts showing striping plan; layouts for,

Soccer, Boy’s and Girl’ Lacrosse and Field Hockey showing any field lines, markings and boundaries, alternating green colors and field logos per project drawings as well as details including infill mix and shock pad.

2. Nailer.3. Installation details.4. Edge details including other inserts.

D. Samples1. Synthetic turf, approximate size 12” x 12”.2. Colors of line markings.3. Infill material.

E. Test Reports on the System Components1. Pile Height, Face Weight and Total Fabric Weight – ASTM D418.2. Primary and Secondary Backing Weights and Material: ASTM D418.3. Tuft Bind – ASTM D1335.4. Grab Tear Strength – ASTM D1682.5. Dynamic Cushion Test – ASTM F355, Procedure A (System).6. Shock Absorbing Properties – ASTM F1936.7. G-Max Test Results – ASTM F355.8. Glue Test Reports.

F. Certifications1. Certificate of sub base acceptance by synthetic turf manufacturer.2. Warranty of Synthetic Turf System and installation of the system.

G. Provide substantiation that proposed system does not violate any other manufacturer's patents, patents allowed or patents pending.

H. Provide a sample copy of insured, non-prorated warranty and insurance policy information.

I. List of existing installations: Submit list including respective Owner’s representative and telephone number.

J. Total dollar value, number and size of installations completed in each of the last three (3) years including location and contact information.

K. Submit Bills of Lading/Material Delivery Receipts for synthetic turf infill materials. Bills of lading shall bear the name of the project/delivery address, quantity of materials delivered, source/location of origin of infill materials and/or manufacturer, and date of delivery.

L. Prior to Final Acceptance, the Contractor shall submit to the Owner 3 copies of Maintenance Manuals, which will include all necessary instructions for the proper care and preventative maintenance of the synthetic turf system, including painting and striping (Coordinate with Section 01 77 00).

1.06 SPECIAL GUARANTEE/WARRANTY TERMSA. Sample Warranty: A sample warranty including 3rd party insurance information must be

submitted for review before any proposed turf vendor can be considered for approval.


Weston High School


B. Warranties: The Contractor shall provide a warranty to the Owner that covers defects in materials and workmanship of the turf for a period of eight (8) or twelve (12) years (based upon bid selection) from the date of substantial completion. The 3rd party insured warranty will be in place for the first 8 years of the 12 year manufacturer warranty. The turf manufacturer must verify that their representative has inspected the installation and that the work conforms to the manufacturer's requirements. The manufacturer's warranty shall include general wear and damage caused from UV degradation. The warranty shall specifically exclude vandalism, and acts of God beyond the control of the Owner or the manufacturer. The warranty shall be fully third party insured; pre-paid for the first 8 full years of the 12 year manufacturer’s warranty. The Contractor shall provide a warranty to the Owner that covers defects in the installation workmanship, and further warrant that the installation was done in accordance with both the manufacturer's recommendations and any written directives of the manufacturer's representative. Prior to final payment for the synthetic turf, the Contractor shall submit to owner an insurance policy, guaranteeing the warranty to the Owner. The insurance must reflect the following values: 1) Must have minimum per claim coverage amount of $1,000,000 per field. 2) Minimum of 15-million dollar annual aggregate) must cover full 100% replacement value of total square footage of turf installed 4) Pre-paid 8 year third party policy must be issued by a carrier with an A.M. Best rated “A” or better rating. Proposed synthetic turf contractor must submit a certified letter directly from the 3rd party insurance carrier stating that the 3rd party warranty in place is not in any way supported by a letter of credit. Any policy supported in any way by a letter of credit will not be accepted. A complete copy of the actual 3rd party policy in place, not just the certificate, must be submitted along with the certified letter for review by the owner designated representatives. The total aggregate amount divided by the average number of fields completed the last three years by the proposed turf vendor must equal at least $300,000.00. (See 1.05.J for requirement.)

C. The warranty submitted shall include the following characteristics:1. The Contractor shall submit a manufacturer’s warranty listing, at minimum, an

eight (8) year (and in the case of the alternate field bids, a supplemental warranty of four (4) years) guarantee against UV fading, degradation, or defects, such as excessive wear of fibrillation, seam rupture dislodgment, or inadequate drainage.

2. The warranty shall also guarantee a G-Max rating below 110 at installation for a padded field and below 135 for a non-padded field. The G-Max shall not exceed 155 during the life of the warranty for a padded field and 185 for a non-padded field. Warranty shall clearly state that if test results show that G-Max rating has not been met, the field builder will repair or replace product within the warranty period as necessary to meet those requirements at no cost to the Owner.

3. Turf striping and marking shall be warranted for a minimum period of eight (8) or twelve (12) years dependent upon selection.

4. Include that the Synthetic Turf specified infill system and materials installed shall meet or exceed the product specification.

5. Include that a warranty from a single source covering defects in the installation, workmanship and all self manufactured system products or procured materials. Further warrant that the installation was done in accordance with both manufacturer’s recommendations and any written directives of the manufacturer’s on-site designated field supervisory personnel.

1.07 MAINTENANCEA. The Field Builder shall be responsible for maintaining of the synthetic turf for one (1) year

from the time of acceptance of the synthetic turf field. Maintenance shall include grooming and sweeping of the turf with manufacturer’s approved equipment.


Weston High School


Maintenance shall commence after the acceptance of the synthetic turf. It shall be performed as needed to maintain the field in accordance with the manufacturer’s guaranty. Maintenance visits shall be coordinated with the Director of Facilities or such other person designated by the Owner.

B. Contractor shall train the Owner's facility maintenance staff in the use of the turf manufacturer's recommended maintenance equipment.

C. Manufacturer must provide maintenance guidelines and a maintenance video to the facility maintenance staff.

1.08 SUSTAINABILITYA. In the selection of the products and materials of this section as well as for the entire

project, preference will be given to those with the following characteristics:1. Water based.2. Water-soluble.3. Can be cleaned up with water.4. Non-flammable.5. Biodegradable.6. Low or preferably no Volatile Organic Compound (VOC) content.7. Manufactured without compounds that contribute to ozone depletion in the upper

atmosphere.8. Manufactured without compounds that contribute to smog in the lower

atmosphere.9. Do not contain methylene-chloride.10. Do not contain chlorinated hydrocarbons.11. Contains the least possible of post-consumer or post-industrial waste.

Part 2 – PRODUCTS

For purposes of establishing a standard of quality and not for the purposes of limiting competition the basis of this specification and proposal requirements is on the following systems.

It should be so noted that the requirements for any substitution requests shall be made prior to the “Pre-Award” conference with performance and experience data listed on a “line by line” basis and shall be submitted a minimum of 14 calendar days prior to the date set for that conference.

Further, Synthetic turf vendor must have at least 10 existing synthetic turf fields meeting or exceeding the above specifications installed in Connecticut. One of these fields must have been in play for at least 3 full years. A certified reference list for these fields must the submitted for review and approval as part of the turf submittal process. Turf vendors not meeting this requirement will not be approved.

These are performance specifications and the turf shall meet the requirements of these specifications. All components and their installation method shall be designed and manufactured for use on outdoor athletic fields. The materials as hereinafter specified, should be able to withstand full climatic exposure in the Northeast USA, be resistant to insect infestation, rot, fungus and mildew; to ultra-violet light and heat degradation, and shall have the basic characteristic of flow through-drainage allowing free movement of surface run-off through turf and directly into the prepared granular base and into the field drainage system.

Base Bid For Turf Systems

2.01 BASE BID SYNTHETIC TURF – Sprinturf – UltraBlade DFE Extreme 50


Weston High School


A. UltraBlade DFE Extrem 50 Synthetic Grass System Properties:

Pile Weight: 50 oz/sy

Face Yarn Type: Fibrillated Paralel Long Slit/ Monofilament

Yarn Size: 10,000 / 10,800 denier

Yarn Thickness: 100 microns

Pile Height (Finished): 2.25”

Color: As selected by the Owner in one of the following colors - Field Green, Field Green/Lime Green, Field Green/Olive Green

Construction: Broadloom tufted

Stitch Rate: 9/3"

Tufting Gauge: 3/8"

Primary Backing: Woven/Non-woven/Woven

Secondary Backing: 22 oz/sy urethane

Total Product Weight: 81 oz/sy (+/- 2 oz)

Finished Roll Width: 15’

Finished Roll Length: Up to 220’

Turf Permeability: > 60" +/- per hour

Infill Composition: Ambiently ground new SBR crumb rubber mixture and rounded or sub-angular, uniformly sized silica sand

NOTES: The rolls shall be of sufficient length to go from sideline to sideline. Head seams, other than at sidelines, will not be acceptable. Cord for sewing seams of turf shall be as recommended by the synthetic turf

manufacturer. Perimeter edge details required for the system shall be as detailed and

recommended by the manufacturer, and as approved by the manufacturer. The lead content of the fibers must be less than 100 ppm.

B. Adhesives for bonding tufted synthetic turf shall be two-component fast-set urethane adhesive obtained from a single manufacturer and be equivalent to Ultrabond Turf PU 2K as manufactured by Mapei Corporation, Deerfield Beach, FL (800) 992-6273, or one-part moisture-cured polyurethane obtained from a single manufacturer and be equivalent to 34-G as manufactured by Synthetic Surfaces, Inc., Scotch Plains, NJ (908) 233-6803, or approved equal as designated by the Field Builder.

C. Seaming Tape: Tape for securing seams in the tufted synthetic turf and inlaid lines shall be high quality tape made with a minimum roll width of 12 inches. If seams are to be sewn, they must be sewn with high quality cord/thread as recommended by Field Builder.

D. Resilient Layered Infill: A resilient infill system, consisting of a specially formulated mixture of a minimum 2.5 lbs. per square foot of rubber and minimum 2.5 lbs. per square foot of sand engineered to provide the look, feel, footing and shock absorption of a natural grass field in ideal conditions. 1. Ambiently ground SBR Crumb Rubber. Granules shall contain minimal dust or

contaminants and shall be derived from the ambient processing form of recycled


Weston High School


tires. Color shall be substantially black and shall meet the 10 – 20 or 8 – 16 mesh size designation.a. The clean, uniformly sized particles shall be consistent in shape and

particle size distribution. b. The particles shall resist abrasion in high traffic and excessive wear

applications and provide stability to artificial sports turf applications. c. The particles shall be processed and sized under rigid specifications and

Manufacturers' statistical and quality control assurance program. d. Particles shall be structurally pure and consistently uniform in size

distribution for predictable performance. 2. Sand Particulate. The sand provided as a component of the infill mixture shall be

rounded or sub-angular so as to minimize abrasion to the athlete and synthetic grass fibers.

2.03 PLASTIC LUMBER TIE-DOWN CURBA. Recycled plastic lumber shall be fabricated from one hundred percent (100%) High

Density Polyethylene (HDPE) and low density Polyethylene (LDPE) recycled polyethylene, including UV-inhibiting pigment.

B. Composition and mechanical properties shall be as follows:

Minimum High Density Polyethylene: 70%

Tensile Strength (ASTM D638): 3000 psi

Compressive Strength (ASTM D6108): 3000 psi

Flexural Modulus of Elasticity (ASTM 6109) 200,000 psi

C. The Bulk Density and Specific Gravity of the recycled plastic lumber shall conform to the acceptable standards determined by the standard test method in ASTM D611. Recycled plastic lumber shall not absorb moisture, corrode, rot, warp, splinter, or crack and the surface shall not be slippery when wet. The recycled plastic lumber shall not contain any material that will be irritating when in contact with the skin. Cross sections shall not show wide deep gaps or holes and the surface shall remain unpainted. The color shall be Slate Gray, unless otherwise indicated on the plans.

2.07 PERMANENT INLAYED MARKINGS: Permanent inlayed markings shall be constructed for the followings sports in this priority and color (Coordinate with Section 01 10 00 for color, 01 10 00 shall govern:A. Football – WhiteB. Boys and Girls Soccer - YellowC. Boys Lacrosse – BlackD. Girls Lacrosse – Royal BlueE. Field Hockey – RedF. Blue tic marks for water valve locationsG. Black tic marks for drainage manhole locations.

*Exact colors chosen for each sport subject to change

2.08 MAINTENANCEA. REPAIR materials: At no extra cost to the Contract Sum, the contractor shall provide to

the Owner the following materials for maintenance and minor repairs:1. Artificial turf fabric (green) – 1 piece measuring 15’ wide x 20’ long. 2. Artificial turf fabric (school color) – 1 piece measuring 15’ wide x 20’ long.3. Artificial turf fabric (white) – 4” wide x 100’ long.4. Artificial turf fabric (black) – 4” wide x 100’ long.


Weston High School


5. Artificial turf fabric (yellow) – 4” wide x 100’ long.6. Artificial turf fabric (royal blue) – 4” wide x 100’ long.7. Artificial turf fabric (red) – 4” wide x 100’ long.8. Infill materials – 500 lbs.9. Seaming tape and glue – sufficient for 200 linear feet of seams.

Part 3 – EXECUTION

3.01 INSPECTION AND ACCEPTANCEA. Examine all surfaces and contiguous elements to receive work of this section and correct,

as part of the Work of this Contract, any defects affecting installation. Commencement of work will be construed as complete acceptability of surfaces and contiguous elements.

3.02 GENERALA. The installation shall be performed in full compliance with approved shop drawings.B. Only manufacturer-approved technicians skilled in the installation of specified infill athletic

caliber synthetic turf systems working under the direct supervision of the manufacturer’s authorized supervisors, shall undertake the placement of the system.

C. The surface to receive the synthetic turf shall be inspected and certified in writing by the manufacturer/installer as ready for the installation of the synthetic turf system and must be perfectly clean as installation commences and shall be maintained in that condition throughout the process.

D. Installation supervisors shall have a minimum of five (5) years experience in the supervision of the installation of the respective specified synthetic turf infill system.

E. All components of the specified synthetic turf infill system shall be installed in strict accordance with the synthetic turf system manufacturer’s technical specifications and instructions.

F. Any variations and/or modifications from synthetic turf infill system specifications and installation procedures outlined under these sections shall be approved in writing by the Engineer and manufacturer’s on-site authorized supervisory personnel prior to proceeding with the system installation.

3.03 INSTALLATIONA. Plastic Edging

1. Recycled Plastic Lumber Edging shall be installed around the perimeter of the field and secured to the concrete curb with expansion bolts 3’-0” o.c.

B. Synthetic Turf1. The full width rolls of turf shall be laid out across the field and the edges attached

to the perimeter edge restraint as per manufacturer’s directions, at a maximum one foot (1’) intervals. The seams shall be double sewn as per manufacturer’s system application and recommendations and have seams, other than at sidelines, shall not be acceptable. Glued seams are not acceptable. This is a 99% sewn installation. Minimum gluing will only be permitted to repair problem areas, and corner completions. All seams shall be transverse to the field direction, i.e. run perpendicularly across the field. Seams shall be flat, tight, and permanent with no separation or fraying. Permanent playing marking lines shall be laid out and inlaid into the turf as shown on the drawings.

A. Infill1. The completed specified synthetic infill turf field shall be brushed with a

motorized nylon rotary broom and the infill material immediately installed with a minimum four foot (4’) width drop spreader.


Weston High School


2. Crumb rubber and sand shall be applied in a uniform rate of multiple applications until the specified infill depth is achieved.

3. Infill material shall be brushed between infill applications with a motorized rotary broom and pull-type groomer brush simultaneously.

4. A minimum infill rate of 2.5 lbs. of rubber and 2.5 lbs. of sand per square foot is required.

B. Synthetic turf shall be attached to the perimeter edge detail in accordance with the Manufacturer’s standard procedures.

3.04 CLEAN UP AND PROTECTIONA. Contractor shall provide the labor, supplies and equipment necessary for final cleaning of

surfaces and installed items.B. All usable remnants of new material shall become the property of the Owner.C. The Contractor shall keep the area clean throughout the project and clear of debris.D. Surfaces, recesses, enclosures, etc. shall be cleaned as necessary to leave the work

area in a clean, immaculate condition ready for immediate occupancy and use by the Owner.

3.05 CERTIFICATION BY THE BIDDERA. The bidder, by submitting a bid, certifies that there are no pending, threatened, or present

legal actions against the bidder of any associate or subcontracting entity relating to the infringement of patent rights concerning the design of any system of the type to be supplied under this bid.

3.06 CLEANUPA. Contractor shall provide the labor, supplies and equipment as necessary for final cleaning

of surfaces and installed items.B. All usable remnants of new material shall be come the property of the Owner.C. The Contractor shall keep the area clean throughout the project D. Surfaces, recesses, enclosures, etc., shall be cleaned as necessary to leave the work

area in a clean, immaculate condition ready for immediate occupancy and use by the Owner.

3.07 WASTE MANAGEMENT – Coordinate with Section 01 74 19A. Separate and recycle materials and material packaging in accordance with Waste

Management Plan and to the maximum extent economically feasible and place in designated areas for recycling.

B. Set aside and protect materials suitable for reuse and/or remanufacturing.C. Separate and fold up metal banding; flatten and place along with other metal scrap for


**End of Section**


Weston High School

KGD2018-1010 32 30 00 - 1 Site Improvements

SECTION 32 30 00

SITE IMPROVEMENTS

Part 1 - GENERAL





equipment and the like necessary and/or required for the complete execution of all site

improvement work for this project as required by the schedules, keynotes and drawings,


1. Remove, protect, reinstall clad chain link fence and gates as maybe required to

facilitate turf replacement and jogging track repairs if damaged during the work of

this contract.



A. The Contractor is cautioned that various items of other trades will be installed in

conjunction with the work of this Section. Correlation of contract requirements is the


B. Regulatory Agencies and Requirements

1. All materials and methods of installation shall conform to federal, state, and city

codes and regulations having jurisdiction. Where Contract requirements are in

excess of applicable standards the Contract provision shall govern.

2. All work herein shall be governed by the requirements set forth in the "State of

Connecticut Department of Transportation, Standard Specifications for Roads,

Bridges and Incidental Construction", Form 816, 2004 Edition plus latest

amendments. All payments shall be on a "Lump Sum" basis unless otherwise

directed on the drawings or within these project specific specifications.

3. ASTM: American Society for Testing and Materials.

4. AWS: American Welding Society, Code for Welding in Building Construction.

5. AISI: American Iron and Steel Institute, Specifications for the Design of Light

Gauge Cold Form Structural members.

C. All protection work and general operations shall be governed by the requirements of

OSHA, as most recently amended.

D. The Contractor shall take proper precautions not to damage any existing site conditions




condition any area or item so damaged.

E. The Contractor shall take all necessary measures to keep streets, over which equipment

and service for project travel, clean and free from dirt, dust, mud and debris resulting

from construction operations. The actions taken shall meet the requirements of all

parties having jurisdiction.



Weston High School


Submittals shall be made in groupings where installations are complementary. Failure to

comply with this requirement will be cause for rejection of any or all submittals.

As set forth in Sections 01 33 00 and 01 32 00, prepare and submit a fully developed

submittal schedule; note review times set forth in Section 01 33 00 are deemed

“average”, for large submissions allow longer review times.



Professional Team to approve these materials; the substitution request procedure shall

still be enforced.

A. Samples of materials to be incorporated in the work.

B. Certification of Specification Compliance.

C. Material Safety Data Sheet (MSDS) must be submitted for each product.

Part 2 - PRODUCTS



2.02 CONCRETE MATERIALS

A. Concrete - 4000 psi, 6% air entrainment; forms, reinforcing, finish, mesh and the like

shall be as specified in Section 03 30 00.

Part 3 - EXECUTION


A. Examine all surfaces and contiguous elements to receive work of this section and

correct, as part of the Work of this Contract, any defects affecting installation.

Commencement of work will be construed as complete acceptability of surfaces and

contiguous elements.

3.02 INSTALLATION

A. Installation and execution of all work required herein shall be straight and true to line and

in proper, safe and secure manner.

B. Construct concrete footings as shown on drawings. Set sleeves plumb, level and true.

3.03 FENCE INSTALLATION

A. Set posts in concrete curbs and/or exposed footings and/or walks as shown on the

Drawings.

B. Footings shall be constructed of concrete. The top and sides of exposed footings shall

be neatly formed to a true square and shall be neatly troweled to a smooth finish with a

pitch as shown on Drawings. The entire footing including formed portion shall be poured

monolithically. All holes shall be neatly formed and shall have a maximum diameter of

one inch larger than post.

C. Set posts truly vertical, and grout flush with the tops of curbs, walks, and footings with

quick set anchoring compound or an approved quick setting grouting compound.

D. Tie fence with ties inside property lines at spacings recommended by the manufacturer

for the type of installation required.

E. The Contractor shall maintain the installation during the life of the Contract and shall

repair and replace all parts that are disturbed, damaged or destroyed at no additional

cost.


Weston High School


3.04 CLEANING

A. All debris resulting from operations shall be removed daily and site shall be left clean at

the completion of the Project.








**End of Section**


Weston High School

KGD2018-1010 32 90 02 - 1 Restoration of Turf Areas

SECTION 32 90 02

RESTORATION OF TURF AREAS

Part 1 - GENERAL





equipment and the like necessary and/or required for the complete execution of all turf

rehabilitation work for this project as required by the schedules, keynotes and drawings,


1. The contractor shall supply all materials, equipment, labor, incidentals and

maintenance required in order to provide an acceptable stand of turf by topsoiling

and seeding of all disturbed areas including stripping topsoil, grading, placing

topsoil, fertilizing and seeding, in accordance with the drawings and as specified.

2. The Contractor shall be liable for any damage to property caused by the aeration,

topdressing and seeding/sodding operations, and all areas of construction

disturbed shall be returned to their original condition to the satisfaction of the

Architect.



A. Requirements given herein may be affected by other related requirements of the project

specifications. Correlation of the contract requirements is the responsibility of the

Contractor.

B. Materials and labor required for execution of work herein shall generally be governed by

the standards as specified in Part 2.

C. Work required herein shall be performed by a firm specializing in said work and shall be

under the full time supervision of a graduate of an accredited turf management program.

Name and records of certification shall be submitted for approval, if requested by the

Architect.

D. Reference Standards

1. All work herein shall be governed by the requirements set forth in the "State of

Connecticut Department of Transportation, Standard Specifications for Roads,

Bridges and Incidental Construction", Form 816, 2004 Edition plus latest

amendments. All payments shall be on a "Lump Sum" basis unless otherwise

directed on the drawings or within these project specific specifications.







The Contractor is encouraged to submit for approval products made from recycled

and/or environmentally responsible material. Every effort will be made by the Design



Weston High School



NOTE: The work shall include the cost of all inspection and laboratory charges. No materials shall

be delivered until the approval of samples by the Architect, however such approval shall not

constitute final acceptance. The Architect reserves the right to reject, on or after delivery, any

material which does not, in his opinion, meet this specification.

A. The Contractor shall furnish a certified report from an approved seed testing laboratory not

engaged in selling seed, showing a test for purity, viability and weed seed content of

representative samples of the Grass Seed which is proposed for use. The certification

report may be waived where the quantity of seed is less than 75 pounds.

B. Samples of each material proposed for use in the project along with laboratory analysis of

each as may be applicable.

C. Contractor shall provide soil test analysis, or certification, from approved soil testing facility

of any topsoil proposed for use in the Work. Submit results for Architect's approval.

D. Material Safety Data Sheet (MSDS) must be submitted for each product.

1.06 CLEANUP

A. Any soil or similar material which has been brought onto paved areas by hauling

operations or otherwise shall be removed promptly, keeping these areas clean at all times.

B. Upon completion of work under this Section, all excess stones, debris and soil resulting

from work under this Section which have not previously been cleaned up shall be cleaned

up and removed from the project site.

1.07 TURF MAINTENANCE

A. General: Maintain and establish turf by watering, fertilizing, weeding, mowing, trimming,

replanting, and performing other operations as required to establish healthy, viable turf.

Roll, regrade, and replant bare or eroded areas and remulch to produce a uniformly

smooth turf. Provide materials and installation the same as those used in the original

installation.

1. Fill in as necessary soil subsidence that may occur because of settling or other

processes. Replace materials and turf damaged or lost in areas of subsidence.

2. In areas where mulch has been disturbed by wind or maintenance operations, add

new mulch.

3. Apply treatments as required to keep turf and soil free of pests and pathogens or

disease. Use integrated pest management practices whenever possible to

minimize the use of pesticides and reduce hazards.

B. Watering: Install and maintain temporary piping, hoses, and turf-watering equipment to

convey water from sources and to keep turf uniformly moist to a depth of 4 inches.

Schedule watering to prevent wilting, puddling, erosion, and displacement of seed or

mulch. Lay out temporary watering system to avoid walking over muddy or newly planted

areas. Water turf with fine spray at a minimum rate of 1 inch per week unless rainfall

precipitation is adequate.

C. Mow turf as soon as top growth is tall enough to cut. Repeat mowing to maintain specified

height without cutting more than one-third of grass height. Remove no more than one-third

of grass-leaf growth in initial or subsequent mowings. Do not delay mowing until grass

blades bend over and become matted. Do not mow when grass is wet. Schedule initial

and subsequent mowings to maintain the following grass height:

1. Mow turf-type tall fescue to a height of 1-1/2 to 2 inches.

2. Mow Low-Grow grass to a height of 4 inches.

1.08 PRODUCT DELIVERY, STORAGE AND HANDLING (Coordinate with Section 01 61 00)

A. Deliver all grass seed in standard size bags of the vendor, showing weight, analysis and


Weston High School


name of vendor.

B. Store material as directed by the Architect, in such manner that the effectiveness will not

be impaired.

1.09 CERTIFICATE OF ACCEPTANCE

A. After completion and final inspection of all the work and after any defects discovered in the

work have been corrected, the Owner and Architect will issue a Certificate of Final

Acceptance in accordance with the Conditions.

B. Depending upon the progress of the work, the Architect may, at his option, issue partial

certificates of acceptance for areas of work as determined by him. The contractor's duty of

maintenance for such areas shall cease upon receipt of such certification except such

duties shall continue with regard to all other areas or portions of work until such

certification covering those portions is received.

1.10 SUSTAINABILITY



1. Water based.

2. Water-soluble.


4. Non-flammable.

5. Biodegradable.



atmosphere.


atmosphere.




Part 2 - PRODUCTS



2.02 MATERIALS

A. Topsoil

1. Stockpiled topsoil from site preparation, earthwork and trenching operations shall

be used.

2. Topsoil shall not be used in a muddy or frozen condition.

B. Fertilizer: Commercial fertilizer (14-28-15) shall have the following composition by weight:

Nitrogen 14%; Phosphorous 28%; Potash 14%; as manufactured by Jonathan Green “New

Seeding Lawn Fertilizer”.

C. Seed: The seed used shall be fresh, recleaned seed of the latest crop containing a blend

of those listed below and shall be harvested from one field to ensure a uniform color and

texture. Percentages of each grass type are to be within the given range for that type.

20% Devine Perennial Ryegrass

20% America Kentucky Bluegrass

20% Apollo Kentucky Bluegrass

20% Limousine Kentucky Bluegrass

20% Midnight Kentucky Bluegrass


Weston High School


D. Mulch: Mulch shall be approved salt hay or weed free straw and stabilized with a binder.

2.03 Balance of materials shall be as specified elsewhere in this Section.

Part 3 - EXECUTION


A. Examine all surfaces and contiguous elements to receive work of this section and correct,

as part of the Work of this Contract, any defects affecting installation. Commencement of

work will be construed as complete acceptability of surfaces and contiguous elements.

3.02 RESTRICTIONS

A. Proceed with and complete all work herein as rapidly as approved portions of site become

available.

B. Work within seasonal limitation for each kind of work required.

C. Sow grass seed as follows -

1. Fall Planting - August and September

2. Spring Planting - March, April and May or at such other time as are approved by

the Architect.

D. All seeding is to be done to moderately dry to moist (not wet) soil and at time when the

wind does not exceed a velocity of 5 miles per hour.

E. No finish grading shall be performed if topsoil has excess moisture.

F. Add superphosphate to topsoil prior to cultivation.

G. Add fertilizer to finish grade prior to placement of sod.

3.03 STRIPPING SOIL

A. All topsoil shall be stripped as described and stockpiled for reuse. The quantity of topsoil

to be removed shall be approved by the Architect. If sufficient topsoil is not retained on-

site, the contractor will be required to provide the difference from off-site sources at no

expense to the owner. Quality of topsoil from off-site sources shall be subject to

Architect’s approval.

3.04 GRADING AND SUBGRADE PREPARATION

A. Perform grading operations to bring subgrade to levels required and to contour indicated

on the drawings.

B. Completed subgrade shall be approved by Architect before topsoil and seeding.

C. The approved subgrade shall be scarified to a depth of 2 inches to permit mixing with

rootzone material.

3.05 SEEDBED PREPARATION

A. Seasonal and weather limitations - All operations including seedbed preparation shall be

performed only when the soil is in proper condition to permit satisfactory work.

Continuation of work at other than specified times or conditions shall proceed only with

consent of the Architect.

B. Leveling - Any undulations or irregularities in the surface resulting from fertilization, tillage

or any other causes shall be leveled prior to seeding. Flooded, washed out, or otherwise

damaged areas shall be reconstructed and all grades reestablished in conformance with

the drawings and specifications.

C. Cleanup - Prior to seeding, the surface shall be cleared of all trash, debris and stone larger

than 1-1/2 diameter and of all roots, brush, wire, grade stakes and other objects that could

be a hindrance to maintenance operations and use.

D. Fertilizing - After final seedbed preparation, apply fertilizer at the manufacturer’s

recommended rate indicated on the bag. Fertilizer shall be distributed evenly over all areas


Weston High School


to be seeded by machine, or as otherwise approved by the Architect, and shall be worked

lightly into the top 1 inch of the rootzone mixture.

3.06 SEEDING

A. The contractor shall furnish and place all materials required for seeding in all topsoiled

areas.

B. All areas to be seeded shall be thoroughly disked or otherwise loosened to a depth of 4

inches and shall be raked to true lines free from all unsightly variations, bumps, ridges, or

depressions. All sticks, stones, roots or other objectionable material which might interfere

with the formation of a finely pulverized seed bed shall be removed from the soil. Ground

limestone and commercial fertilizer shall be applied as specified above.

C. The soil shall then be raked to a smooth, even draining surface and compacted with an

approved roller as directed by the Architect. Any depressions which occur shall be

regraded and rerolled until a satisfactory grade is obtained.

D. The rate of seeding shall be 10 lbs. per 1000 sq. ft. of area. Grass seed shall be sown by

approved machine in such manner that a uniform stand will result. After seeding, the

surface shall be evenly raked with a fine toothed rake and rolled with an approved roller as

directed by the Architect.

E. Grass seed shall be sown preferably in the fall between August 25 and October 1, in the

spring between March 15 and May 1, or at such other times as are approved by the

Architect. All seeding is to be done in dry or moderately dry soil and at times when the

wind does not exceed a velocity of 5 miles per hour.

3.07 MULCHING

A. All seeded areas shall be mulched not later than three (3) days following seeding. Ground

surfaces shall be completely covered at a rate of at least two (2) tons per acre.

B. Mulch shall be anchored using jute or other approved netting properly fastened in place.

C. Subsequent watering - Seed shall be watered as required to maintain adequate moisture

in the soil. In the absence of rainfall, seed shall be watered at frequencies dictated by

need.

3.08 HYDROSEEDING

A. The contractor shall have the option of hydroseeding the lawn areas at no increased cost

to the owner and subject to the written approval of the Architect. If the contractor selects

this option, he shall submit to the Architect for approval a complete specification of the

hydroseeding operation he intends to follow. Hydroseeding with a cellulose fiber mulch is

acceptable.

3.09 ACCEPTANCE

A. Inspection of the work of seeding to determine provisional acceptance will be made by the

Architect upon written notice requesting such inspection submitted by the contractor at

least seven (7) days prior to the anticipated date of inspection. Request may be made

subsequent to the second mowing of the turf.

B. After inspection the contractor will be notified in writing by the Architect of provisional

acceptance of all work, or if there are any deficiencies of the requirements for completion

of the work.

C. All seeded areas shall be guaranteed for one (l) growing season commencing with the

date of provisional acceptance.

D. Upon provisional acceptance, the owner will assume general responsibility for

maintenance of the lawn areas. The contractor shall, however, make periodic visits to the

site during the guarantee period to advise the owner of proper maintenance procedures.

E. Failure of the contractor to notify the Architect, in writing, of inadequate maintenance by

the owner of the lawn areas installed under this contract shall constitute acceptance of the


Weston High School


owner’s maintenance operations by the contractor. The contractor shall not therefore use

the owner’s alleged lack of proper maintenance as a basis for voiding his responsibilities

under the guarantee herein specified.

F. At the expiration of the guarantee period, upon written request of the contractor, inspection

for final acceptance will be made by the Architect. All remedial work to seeding work by

the contractor shall be completed prior to the request for final acceptance.








**End of Section**

DESIGN TEAM

KG&D Project No.

2018-1010

ARCHITECT

KG&D Architects

Kaeyer, Garment & Davidson Architects PC

285 Main Street, Mount Kisco, NY 10549

phone: 914.666.5900 fax: 914.666.0051

ISSUED FOR BID - MARCH 09, 2018

WESTON HIGH SCHOOL

Competition Field Turf Replacement Project

115 School Road

Weston, CT 06829

G001 TITLE SHEET

ARCHITECTURAL

A1.1 SITE PLAN

A1.2 FIELD LAYOUT PLAN

G001

WESTON HIGH SCHOOL

COMPETITION FIELD TURF

REPLACEMENT PROJECT

REF. - REFRIGERATOR

R, RAD. - RADIUS

P.T. - PRESSURE TREATED

PLAM. - PLASTIC LAMINATE

O.H. - OVERHEAD

O.C. - ON CENTER

M.R. - MOISTURE RESISTANT

M.O. - MASONRY OPENING

M.H. - MAN HOLE

KITCH. - KITCHEN

JAN, JANIT. - JANITOR

INSUL. - INSULATION

H.W. - HOT WATER

MISC. - MISCELLANEOUS

OPP. - OPPOSITE

PLWD - PLYWOOD

N.I.C. - NOT IN CONTRACT

REINF. - REINFORCED

C - CARPET EX., EXIST. - EXISTING

CMU - CONCRETE MASONRY UNIT

CJ - CONSTRUCTION JOINT

DIJ - DOWELED ISOLATION JOINT

C.B. - CONCRETE BLOCK

CONC. - CONCRETE

COL. - COLUMN

CLG. - CEILING

CORR. - CORRIDOR

CONT. - CONTINUOUS

CONC. - CONCRETE

CL., CLOS. - CLOSET

C.L. - CENTER LINE

C.T. - CERAMIC TILE

DIA. - DIAMETER

& AIR CONDITIONING

H.C. - HANDICAPPED

G.C. - GENERAL COORDINATES

GWB - GYPSUM WALL BOARD

F.F. - FINISHED FLOOR

HVAC - HEATING VENTILATION

HM - HOLLOW METAL

HGT. - HEIGHT

GYP. - GYPSUM

G.V. - GATE VALVE

GL - GLASS

GA. - GAUGE

FL. - FLOOR

F.D. - FLOOR DRAIN

PL - PLATE

P - PAINTED

MTL. - METAL

LIST OF ABBREVIATIONS

AHU - AIR HANDLING UNIT

A.F.F. - ABOVE FINISHED FLOOR

ADMIN. - ADMINISTRATION

ACT - ACOUSTIC CEILING TILE

BR. - BROOMED

BLDG. - BUILDING

B.O. - BOTTOM OF

A.B. - ANCHOR BOLT

ALUM. - ALUMINUM

EWC - ELECTRIC WATER COOLER

EJ - EXPANSION JOINT

EQ. - EQUAL

E.W. - EACH WAY

ELEC. - ELECTRICAL

EL. - ELEVATION

DISP. - DISPENSER

DN - DOWN

ELEV. - ELEVATOR L - LONG

MAX. - MAXIMUM

MIN. - MINIMUM

LKR - LOCKER

S.S - STAINLESS STEEL

WC. - WATER CLOSET

UNO - UNLESS NOTED OTHERWISE

VCT - VINYL COMPOSITION TILE

VCB - VINYL COVE BASE

T.O. - TOP OF

T&B - TOP AND BOTTOM

STOR. - STORAGE

VEST. - VESTIBULE

TYP. - TYPICAL

WD. - WOOD

Y - YES

W - WIDE

W/ - WITH

THK. - THICK

STL. - STEEL

S.F., SQ. FT. - SQUARE FEET

SJ - SAWED JOINT

SIM. - SIMILAR

S.I. - SQUARE INCHES

S.C. - SPECIAL COATING

REQ'D. - REQUIRED

R.O. - ROUGH OPENING

S - STAINED

RM. - ROOM

LIST OF DRAWINGS

EXISTING TURF FIELD AERIAL

1

LOCATION MAP

2

AutoCAD SHX Text

Sheet No.

AutoCAD SHX Text

NTS

AutoCAD SHX Text

NTS

N

EXISTING ACCESS ROAD

STAGING AREA

EXISTING TRACK TO REMAIN

(TYP)

PROTECT EXISTING TRACK AT

CONSTRUCTION ACCESS POINT

REMOVE & REPLACE

PORTION OF FENCE FOR

CONSTRUCTION ACCESS

AREA OF WORK:

REMOVE EXISTING TURF FIELD

IN ITS ENTIRETY, INCLUDING

PARTICULATE INFILL,

REPLACE WITH TURF FIELD

REMOVE EXISTING GOAL

POSTS AND REPLACE

WITH NEW, EXISTING

FOUNDATIONS SHALL

REMAIN

MULTI-SPORT FIELD

LINES, SEE A1.2 FOR

LAYOUT AND COLOR

WESTON HIGH SCHOOL

115 School RoadWeston, Connecticut

k darchitects.com

kaeyer, arment & davidson architects, pc285 main street mount kisco, new york 10549p: 914.666.5900 f: 914.666.0051

Competition Field TurfReplacement Project

ISSUED FOR BID

SITE PLAN

A1.1

SITE PLAN

1

Notes

Contractor shall erect a 'bridge' to span the all weather

running track for access to synthetic field.

Bridge shall include provisions to spread the weight of

any vehicles from damaging the all weather surface or

underlying pavement.

Bridge shall be completely removed and track cleaned up

after turf has been replaced. Provide a 20' wide layer of

filter fabric across the track, a 16' wide tarp, 8' long

1

2

"

plywood, ramping up to 12" thick item 4 at 12' wide

crossing the track covered by steel plates.

24-hours prior to any construction (including mobilization)

the contractor, in the presence of the owner, shall

survey the entire existing running track and field events

(long jump, high jump, pole vault) for any damage. Any

discovered damaged prior to the construction shall be

documented by the contractor and agreed upon by the

owner.

Prior to any construction (including mobilization) the

contractor shall coordinate a staging area with the owner.

Silt fence shall be installed around the staging area.

AutoCAD SHX Text

1 inch = ft.

AutoCAD SHX Text

( IN FEET )

AutoCAD SHX Text

GRAPHIC SCALE

AutoCAD SHX Text

0

AutoCAD SHX Text

30

AutoCAD SHX Text

30

AutoCAD SHX Text

60

AutoCAD SHX Text

30

AutoCAD SHX Text

120

AutoCAD SHX Text

15

AutoCAD SHX Text

Job No.

AutoCAD SHX Text

2018-1090

AutoCAD SHX Text

Date

AutoCAD SHX Text

Scale

AutoCAD SHX Text

Drawn/Checked

AutoCAD SHX Text

Sheet No.

AutoCAD SHX Text

Sheet Title

AutoCAD SHX Text

No.

AutoCAD SHX Text

Date

AutoCAD SHX Text

Issue

AutoCAD SHX Text

03-08-18

AutoCAD SHX Text

WRITTEN DIMENSIONS ON THIS DRAWING SHALL HAVE PRECEDENCE OVER SCALED DIMENSIONS. CONTRACTOR SHALL VERIFY AND BE RESPONSIBLE FOR ALL DIMENSIONS AND CONDITIONS ON THE JOB AND THIS OFFICE MUST BE NOTIFIED OF ANY VARIATIONS FROM DIMENSIONS AND CONDITIONS SHOWN BY THESE DRAWINGS. SHOP DETAILS MUST BE SUBMITTED TO THIS OFFICE FOR APPROVAL BEFORE PROCEEDING WITH FABRICATION.

AutoCAD SHX Text

NOTE: ALL IDEAS, DESIGNS, ARRANGEMENTS AND PLANS INDICATED OR REPRESENTED BY THIS DRAWING ARE OWNED BY AND ARE THE PROPERTY OF KAEYER, GARMENT, & DAVIDSON ARCHITECTS, PC (KG&D), AND WERE CREATED, EVOLVED AND DEVELOPED FOR USE ON, AND IN CONNECTION WITH, THE SPECIFIED PROJECT. NONE OF SUCH IDEAS, DESIGNS, ARRANGE- MENTS OR PLANS SHALL BE USED BY OR DISCLOSED TO ANY PURPOSE WHATSOEVER WITHOUT THE WRITTEN PERMISSION OF (KG&D).

AutoCAD SHX Text

All rights reserved.

AutoCAD SHX Text

LEGAL NOTICE: ALTERATIONS BY ANY PERSON, IN ANY WAY, OF ANY ITEM CONTAINED ON THIS DOCUMENT, UNLESS ACTING UNDER THE DIRECTION OF THE LICENCED ARCHITECT WHOSE PROFESSIONAL SEAL IS AFFIXED HERETO, IS A VIOLATION OF TITLE VII, SECT. 69.5 (b) OF NEW YORK STATE LAW.

AutoCAD SHX Text

C Copyright 2018 Kaeyer, Garment, & Davidson Architects.

AutoCAD SHX Text

1 03-09-18 ISSUED FOR BID

AutoCAD SHX Text

Issue

AutoCAD SHX Text

Date

AutoCAD SHX Text

AS NOTED

AutoCAD SHX Text

TS/JR

AutoCAD SHX Text

SCALE: 1' = 30'

10 20 30 40 50 40 30 20 10

10 20 30 40 50 40 30 20 10

BOYS MULTI LACROSSE FIELD

6

GIRLS FIELD HOCKEY FIELD

3

FOOTBALL FIELD

2

GIRLS MULTI LACROSSE FIELD LAYOUT

5

GIRLS AND BOYS SOCCER FIELD LAYOUT

4

SCHOOL LOGO

1

··

·

A C A B A B A B A B A B A B A B A B A B A B C A

A

A

D

D

WESTON HIGH SCHOOL

115 School RoadWeston, Connecticut

k darchitects.com

kaeyer, arment & davidson architects, pc285 main street mount kisco, new york 10549p: 914.666.5900 f: 914.666.0051

Competition Field TurfReplacement Project

ISSUED FOR BID

FIELD LAYOUT

PLANS

A1.2

AutoCAD SHX Text

END LINE

AutoCAD SHX Text

GOAL/DEFENSE AREA LINE

AutoCAD SHX Text

CENTER LINE

AutoCAD SHX Text

END LINE

AutoCAD SHX Text

GOAL/DEFENSE AREA LINE

AutoCAD SHX Text

SIDELINE

AutoCAD SHX Text

WING AREA

AutoCAD SHX Text

END LINE

AutoCAD SHX Text

SIDELINE

AutoCAD SHX Text

GOAL LINE

AutoCAD SHX Text

RESTRAINING LINE

AutoCAD SHX Text

SIDELINE

AutoCAD SHX Text

END LINE

AutoCAD SHX Text

RESTRAINING LINE

AutoCAD SHX Text

GOAL LINE

AutoCAD SHX Text

GOAL LINE

AutoCAD SHX Text

CENTER FACEOFF X

AutoCAD SHX Text

GOAL LINE

AutoCAD SHX Text

GOAL CREASE

AutoCAD SHX Text

SIDELINE

AutoCAD SHX Text

GOAL CREASE

AutoCAD SHX Text

4'X4" INLAID GOAL/DEFENSE AREA EXTENSION LINE-TYP.

AutoCAD SHX Text

4'X4" INLAID CENTER EXTENSION LINE-TYP.

AutoCAD SHX Text

4'X4"INLAID GOAL/DEFENSE AREA EXTENSION LINE-TYP.

AutoCAD SHX Text

4" WHITE FOOTBALL END LINE

AutoCAD SHX Text

4" WHITE TUFTED FOOTBALL 30 YARD LINE

AutoCAD SHX Text

4" WHITE FOOTBALL END LINE

AutoCAD SHX Text

17'-2"X4" INLAID END LINE EXTENSION LINE-TYP.

AutoCAD SHX Text

11'-6"X4" INLAID RESTRAINING LINE EXTENSION LINE-TYP.

AutoCAD SHX Text

17'-2"X4" INLAID END LINE EXTENSION LINE-TYP.

AutoCAD SHX Text

11'-6"X4" INLAID RESTRAINING LINE EXTENSION LINE-TYP.

AutoCAD SHX Text

4" WHITE TUFTED FOOTBALL 30 YARD LINE

AutoCAD SHX Text

SCORING AREA

AutoCAD SHX Text

GOAL AREA

AutoCAD SHX Text

CENTER LINE

AutoCAD SHX Text

SOCCER CENTER CIRCLE

AutoCAD SHX Text

PENALTY STROKE LINE

AutoCAD SHX Text

BROKEN LINE CIRCLE

AutoCAD SHX Text

CENTER MARK

AutoCAD SHX Text

END LINE

AutoCAD SHX Text

CENTER LINE

AutoCAD SHX Text

END LINE

AutoCAD SHX Text

ALLEY LINE MASK MARK

AutoCAD SHX Text

STRIKING CIRCLE

AutoCAD SHX Text

25 YARD LINE

AutoCAD SHX Text

25 YARD LINE

AutoCAD SHX Text

PENALTY STROKE LINE

AutoCAD SHX Text

STRIKING CIRCLE

AutoCAD SHX Text

BROKEN LINE CIRCLE

AutoCAD SHX Text

NOTE: SOCCER FIELD TO BE 210' X 345'

AutoCAD SHX Text

* FIELD HOCKEY LINE COLOR - RED

AutoCAD SHX Text

* BOYS LACROSSE LINE COLOR - BLACK

AutoCAD SHX Text

* GIRLS LACROSSE LINE COLOR - ROYAL BLUE

AutoCAD SHX Text

* SOCCER LINE COLOR - GOLD

AutoCAD SHX Text

SIDELINE

AutoCAD SHX Text

SIDELINE

AutoCAD SHX Text

SCHOOL NAVY BLUE

AutoCAD SHX Text

WHITE

AutoCAD SHX Text

SCALE: 1' = 30'

AutoCAD SHX Text

SCALE: 1' = 30'

AutoCAD SHX Text

SCALE: 1' = 30'

AutoCAD SHX Text

SCALE: 1' = 30'

AutoCAD SHX Text

SCALE: 1' = 30'

AutoCAD SHX Text

SCALE: NTS

AutoCAD SHX Text

SCHOOL GOLD

AutoCAD SHX Text

LOGO TO BE CUT & SEAMED INTO GREEN FIELD PANELS JPEG OF LOGO WILL BE PROVIDED

AutoCAD SHX Text

FOOTBALL FIELD LINE COLOR - WHITE ALTERNATE TWO SHADES OF GREEN BETWEEN 5 YARD LINES END ZONES COLOR - SCHOOL NAVY BLUE TO MATCH MASCOT LOGO COLOR A: GREEN 1 GREEN 1 COLOR B: GREEN 2 GREEN 2 COLOR C: NAVY NAVY COLOR D: WHITEWHITE

AutoCAD SHX Text

FIELD PERIMETER

AutoCAD SHX Text

Job No.

AutoCAD SHX Text

2018-1090

AutoCAD SHX Text

Date

AutoCAD SHX Text

Scale

AutoCAD SHX Text

Drawn/Checked

AutoCAD SHX Text

Sheet No.

AutoCAD SHX Text

Sheet Title

AutoCAD SHX Text

No.

AutoCAD SHX Text

Date

AutoCAD SHX Text

Issue

AutoCAD SHX Text

03-08-18

AutoCAD SHX Text

WRITTEN DIMENSIONS ON THIS DRAWING SHALL HAVE PRECEDENCE OVER SCALED DIMENSIONS. CONTRACTOR SHALL VERIFY AND BE RESPONSIBLE FOR ALL DIMENSIONS AND CONDITIONS ON THE JOB AND THIS OFFICE MUST BE NOTIFIED OF ANY VARIATIONS FROM DIMENSIONS AND CONDITIONS SHOWN BY THESE DRAWINGS. SHOP DETAILS MUST BE SUBMITTED TO THIS OFFICE FOR APPROVAL BEFORE PROCEEDING WITH FABRICATION.

AutoCAD SHX Text

NOTE: ALL IDEAS, DESIGNS, ARRANGEMENTS AND PLANS INDICATED OR REPRESENTED BY THIS DRAWING ARE OWNED BY AND ARE THE PROPERTY OF KAEYER, GARMENT, & DAVIDSON ARCHITECTS, PC (KG&D), AND WERE CREATED, EVOLVED AND DEVELOPED FOR USE ON, AND IN CONNECTION WITH, THE SPECIFIED PROJECT. NONE OF SUCH IDEAS, DESIGNS, ARRANGE- MENTS OR PLANS SHALL BE USED BY OR DISCLOSED TO ANY PURPOSE WHATSOEVER WITHOUT THE WRITTEN PERMISSION OF (KG&D).

AutoCAD SHX Text

All rights reserved.

AutoCAD SHX Text

LEGAL NOTICE: ALTERATIONS BY ANY PERSON, IN ANY WAY, OF ANY ITEM CONTAINED ON THIS DOCUMENT, UNLESS ACTING UNDER THE DIRECTION OF THE LICENCED ARCHITECT WHOSE PROFESSIONAL SEAL IS AFFIXED HERETO, IS A VIOLATION OF TITLE VII, SECT. 69.5 (b) OF NEW YORK STATE LAW.

AutoCAD SHX Text

C Copyright 2018 Kaeyer, Garment, & Davidson Architects.

AutoCAD SHX Text

1 03-09-18 ISSUED FOR BID

AutoCAD SHX Text

Issue

AutoCAD SHX Text

Date

AutoCAD SHX Text

AS NOTED

AutoCAD SHX Text

TS / JR