TENDER DOCUMENT · 2019-06-01 · at STC Building, Rohini. Contractor’s Signature SECTION –...

`1

Civil, Interior-Furnishing & AC Works of PSB BO

at STC Building, Rohini. Contractor’s Signature

PUNJAB & SIND BANK

TENDER DOCUMENT

OF

CIVIL, INTERIOR-FURNISHING, ELECTRICAL &AIR-CONDITIONING

WORKS FOR BO at STC BUILDING, ROHINI, SEC-3, DELHI.

TECHNICAL BID

Architects M/s SPACE ACE

PLANNERS& INTERIOR DESIGNERS V-20A/05 DLF CITY-III, GURUGRAM,

HARYANA - 122002 TEL. PH. No. :- 0124-4106618

Email: [email protected]

`2



SECTION- I: DETAILS OF TENDER

DETAILS OF TENDER

1. Details of work to

be done

Civil, Interior-Furnishing, Electrical & air-conditioning works for

B/O at STC Building Sec -3, Rohini, Delhi

2. Form of tender Limited tender from empanelled Interior Furnishers under ZO

Delhi-II

3. Approximate

estimate cost of

tender

Rs.16.65 lakhs.

4. Earnest Money

Deposit

Rs.33,300/- in the form of Demand draft in favour of Punjab &

Sind Bank payable at Delhi (to be enclosed in a separate cover).

EMD of the successful bidder shall be release on receipt of

Performance Guarantee.

5. Date of issue of

tender

01/06/2019

6. Last date of receipt

of tender

11/06/2019 at 11.00 a.m

Zonal Office - II

Punjab & Sind Bank,

B-38, 3rd

floor,

Naraina Industrial Area, Phase-I,

New Delhi-110028.

7. Date & Place of

Bid opening

11/06/2019 at 12.00 p.m

Zonal Office - II

Punjab & Sind Bank,

B-38, 3rd

floor,

Naraina Industrial Area, Phase-I,

New Delhi-110028.

8. Date of

commencement of

work

Within 3 days from the date of issue of LOI

9. Performance

Guarantee

The successful bidder is required to deposit an amount @5% of

total contract value as performance guarantee. This P.G shall be

released within 15 days from the date of virtual completion of

work.

Signature of contractor

with date and seal

`3



SECTION- II:SUMMARY OF SALIENT FEATURES 1. Type of Contract Item rate contract

2. Validity of offer 45 days from the last date of submission

of bid.

3. Earnest Money Deposit (Refundable)

Rs. 33,300/- by demand draft only drawn

in favor of the Punjab & Sind Bank

Payable at New Delhi in a Separate

Sealed Envelope.

EMD of the successful bidder shall be

release on receipt of the performance

security.

4. Date of commencement of work at site Within 3 days from the date of issue of

letter of Intent.

5. Performance Security

5% of the total contract value to be

submitted within 7 days from the date of

issue of letter of Intent.

Performance security shall be released

after payment of final bill/deduction of

security deposit.

6. Mobilization advance No mobilization advance will be paid.

7. Secured Advance against Material No Secured Advance against Material

shall be paid

8. Period of completion 15 days from the 3

rdday of issue of letter

of Intent.

9. Interim / Final Payments On final completion of work.

10. Retention Money 10% to be retained from each R/A bill.

11. Defect Liability period

12 months from the date of issue of

virtual Completion certificate by the

Architect.

12. Liquidated Damages

2% per week or part there of subject to

the max of 10% of accepted contract

price.

13. Language for communication English

14. Insurance, Custom Duties & taxes, work

contract tax, sales tax, GST

To be provided and paid by contractor

(price quoted to include all taxes)

15. Assignment &Subletting Not allowed

16. Rates of B.O.Q's items

To be quoted all inclusive and including

all taxes, charges, surcharges, cess etc.

i.e., net to the Bank.

17. Period of submitting final bill by

contractor

07 days from the date of virtual

completion

18. Labour Cess

1% of contract value will be deducted by

PSB as labor Cess payable to Delhi

Government.

19. Water and electricity charges

Electricity & water connection will be

provided by the bank at one point.

Contractor shall make his own

arrangements to supply it further.

20. Signing of Agreement Within three days of the issue of letter of

intent/work order.

`4



SECTION – III: NOTICE TO CONTRACTORS

Tender for Civil, Interior-Furnishing, Electrical &Air-conditioning works for B/O at

STC Building, Sec-3, Rohini, Delhi

1) Sealed item rates tenders are invited from Interior Furnishers empanelled under Bank’s

ZO Delhi –ii.

2) Tenders should be addressed to the Zonal Manager, Punjab and Sind Bank, Zonal

office Delhi-II, B-38, 3rd

floor, Naraina Industrial Area, Phase-I, New Delhi-110028.

3) The tenderers are required to submit their offer in sealed packets and super scribed as “

Civil, Interior-Furnishing, Electrical &Air-conditioning works for B/O at STC

Building, Sec-3, Rohini, Delhi”

4) All the pages of the tender document is required to be signed and stamped by the person

or persons submitting the tender in token of his/their having acquainted

himself/themselves with all the conditions/specifications, as laid down. Any tender with

any of the document not so signed may be rejected.

5) Clarification if any, may be obtained from the Bank or the Architect, M/s SPACE ACE,

V 20A/5, D.L.F. CITY III, GURUGRAM, HARYANA -122002 (Tel: 0124-4106618,

Email: [email protected]) on any working day during from 10.00 a.m to 5.00

p.m.

6) The tender must obtain for himself on his own responsibility and at his own expenses all

the information which may be necessary for the purpose of filling this tender and for

entering into contract for the execution of the same and must examine the drawings and

inspect the site of the work acquaint himself with all local conditions and matters

pertaining thereto.

7) Any additions and alternations made filling the tender must be attested be initial of the

tenderer. Over-writing of figures is not permitted. Failure to comply with either of these

conditions will render the tender void. No request, advice or any change in rates or

conditions after submission of the tender will be entertained.

8) The tenderers shall deposit with PSB payable at Delhi Rs33,300/- by Demand Draft only

from any of the scheduled bank in favor of the PSB as the Earnest Money. The EMD of

the unsuccessful tenderers will be returned without any interest within 15 days, after a

decision is taken regarding the award of the Contract. Any tender not accompanied by

the requisite Earnest Money in Demand Draft will not be considered and shall stand

rejected. It may' be noted that conditional Tender may be liable to be rejected. The EMD

of the Tenderer shall be forfeited in the following circumstances:-

(i) the Tenderer withdraws his bid;

(ii) the tenderer either fails to start the work within a period of 3 calendar days or fails

to execute the agreement within 3 days after the receipt of letter of acceptance of

tender or the Letter of intent;

(iii) The Tenderer fails to supply goods / services as per the terms of the Tender and

Purchase / Work Order.

(iv) Any other justified reasons e.g. misleading or wrong information in the Bid,

violation of the terms and conditions of the Tender, involvement in forming ring /

cartel, submission of multiple bids in different names etc.

`5



9) EMD of successful tenderer(s) shall be refunded to the successful Tenderer on receipt of

Performance Security.

10) Within 3 (working) days of the receipt of intimation from the PSB of the acceptance of

his/their tender, the successful tenderers shall be bound to implement the Contract by

signing agreement in accordance with the terms and conditions of the contract attaching

herewith, but the work order or the written acceptance by the PSB of tender will

constitute a binding agreement between the PSB and the Contractors so tendering

whether such formal contract is or not subsequently entered into.

11) All compensations or other monies payable by the Contractor to PSB under the terms of

this contract may be deducted from the retention money or from any sum that may be or

may become due to the Contractor on any account whatsoever and in the event of the

retention money being reduced by reason of- any such deductions the Contractor shall

within 5 days of being asked to do so make good in cash or cheque any sum or sums

which have been deducted from his retention money.

12) In case, where the same item of work is mentioned at more than one place in the

Schedule of quantities the lowest of the rates quoted by the Contractor for the item shall

be taken for the payment of that item.

13) Time is the essence of the Contract. The work should be completed in 15 days to the

Contractor from 3rd

day of issue of letter of Intent to commence the work. Tenders shall

not claim any extension of time. However, the PSB to its sole discretion may

extend the time for completion of work.

14) The contractor fails to complete the work by the schedule date of completion or within

any sanctioned extended time, he will have to pay liquidated damages for the period that

work remains incomplete maximum up to 10% of the agreed sum of contract.

15) The quantities contained in the Schedule are only approximate. The work as actually

carried out and done will be measure up from time to time, for which payment will be

made subject to the terms and conditions of the Contract.

16) The Tenderers are advised to note that NO MOBILISATION ADVANCE shall be

released to the contractor for commencing the work.

17) Tender shall be valid for period of thirty days (30 days) from the last date of submission

of bid to the PSB. However, PSB is not bound to accept the lowest or any tender and

reserves the right to accept or reject any or all tenders either in whole or in part, without

assigning any reason for doing so. The along with their tender.

Zonal Manager

`6



SECTION IV - GENERAL CONDITIONS OF THE CONTRACT

DIRECTIONS REGARDING PROCEDURES

In construing these conditions, specifications and Contract Agreement, the following words

shall have the meaning here in assigned to them except where the subject or context

otherwise requires:

(a) "Bank" Shall mean Zonal office, Punjab & Sind Bank, Delhi-II, B-

38, 3rd floor, Naraina Industrial Area, Phase-I, New Delhi-

110028 and shall include his (their) legal representative/s

assign/s or authorized officer.

(b) "Contractor/Builder” Shall mean the individual or firm or company, whether

incorporated or not, undertaking the work and shall include

legal personal representatives of such individual or the persons

comprising such firm or company or the successors of such

individual or firm or company and the permitted assignee of

such individual or such individual or firm or company.

(c) "Architect" Shall mean SPACE ACE whose registered office is situated at

V-20 A/05, DLF Phase-III, Gurgaon, Haryana-122002. (and

shall include his authorized representative) or in the event of

his death or termination of his services by the Bank in his sole

and unqualified discretion, such other person/persons as shall

be provided always that no person subsequently appointed to

be Architect under this contract shall be entitled to disregard

or over rule any previous decision or direction given or

expressed by the Architect specified here in unless otherwise

approved by the Bank.

(d) “Contract” Means the documents forming the tender and acceptance

thereof and the formal agreement executed between the

competent authority on behalf of The Zonal Manager,

Punjab & Sind Bank, Zonal office Delhi-II, B-38, 3rd floor,

Naraina Industrial Area, Phase-I, New Delhi-110028and

the Contractor, together with the documents referred to there

in including these conditions, the specifications, designs,

drawings and instructions issued from time to time by the

Engineer-in-Charge and all these documents taken together,

shall be deemed to form one contract and shall be

complementary to one another.

`7



In the contract, the following expressions shall, unless the

context otherwise requires have the meanings, hereby

respectively assigned to them:

(i) The expression works or work shall, unless there be

something either in the subject or context repugnant to

such construction, be construed and taken to mean the

works by or by virtue of the contract contracted to be

executed whether temporary or permanent, and

whether original, altered, substituted or additional.

(ii) The site shall mean the land/or other places on, into or

through which work is to be executed under the

contract or any adjacent land, path or street through

which work is to be executed under the contract or any

adjacent land, path or street which may be allotted or

used for the purpose of carrying out the contract.

(iii) Schedule(s) referred to in these conditions shall mean

the relevant schedule(s).

(iv) Tendered Value means the value of the entire work as

stipulated in the letter of award of work.

1. GENERAL

The work shall be carried out strictly in accordance with the drawings amplified by the

specifications of materials and workmanship given hereunder. The drawings and

specifications shall be taken together and shall complement each other. In case of any

discrepancy, the following order of preference shall be followed:

(a) Particular Specifications.

(b) Drawings.

(c) CPWD Specifications & DSR 2016.

(d) National Building Code and Relevant IS Provisions.

In case there are no specifications for items shown on the drawings or where items are not

exhaustively described, the general specifications of CPWD shall be followed for which

nothing extra shall be paid. However the specification should be got approved from the

Architect before commencement of work.

2. DRAWINGS AND SPECIFICATIONS

(a) After signing the Contract, the contractor will be given free of charge three prints of all

working drawings. The contractor shall make at his own expense any additional copies

he requires. One copy of the drawing furnished to the contractor as aforesaid shall be

kept by the contractor at site and the same shall, at all reasonable times be available for

inspection and use by the Architect and his representatives any by any other person

authorized by him in writing.

`8



(b) Such further drawings and instructions including revisions, as the Architect may

furnish to the Contractor shall form part of this contract.

(c) Only figured dimensions and detailed drawings shall be followed. The Contractor

shall verify all dimensions in the field before any work is started and obtain

instructions of the Architect in case of any discrepancy.

(d) The Architect with approval of the The Zonal Manager, Zonal office Delhi-II, B-38,

3rd floor, Naraina Industrial Area, Phase-I, New Delhi-110028shall have power

and authority to supply to the Contractor from time to time during the progress of the

work, such further drawings and instructions as shall be necessary for the purpose of

proper and adequate execution and maintenance of work and the Contractor shall carry

out and be bound by the same.

3. ARCHITECTS STATUS AND DECISIONS

(a) Status:

The Architects shall have general supervision and direction of the work. He has

authority on behalf of the Bank to stop the work whenever such stoppage may be

necessary to ensure the proper execution of the work. The architect shall be the

interpreter of the conditions of contract and the judge of its performance.

(b) Decisions:

The Architect shall, within a reasonable time, make decisions on all claims of the

contractor and on all other matter relating to the execution & progress of the work or

the interpretation of the contract documents. The decisions, opinion or direction of the

Architects with respect to all or any of the following matters shall be referred to the

The Zonal Manager &PSB and decision so taken shall be final & binding to the

contractor.

1. Variation or modifications of the design.

2. The quality or quantity of works or the additions/alterations or omissions or

substitutions of any work.

3. Any discrepancy in the drawings or between the drawings and or specifications.

4. The removal and / or re-execution of any work by the contractor.

5. The dismissal from the work of any persons employed therein.

6. The opening up for inspection of any work covered up.

7. The amending the making good of any defects under defects liability period.

8. Approval of materials and workmanship.

9. The contractor to provide everything necessary for the proper execution of the

work.

(c) Dismissal:

The contractor shall on the report of the architects immediately dismiss from the works

within 24 hours any person employed by him for the above work, who may, in the opinion

of Architects be incompetent or misconducts himself and such person shall not be re-

employed on the works without the permission of the Architects.

`9



4. EXTENT OF CONTRACT

The contractor shall supply at his own cost all material implements, ladders, cordage, tackle,

scaffolding and temporary works required for the proper execution of the work whether

original, altered or substituted and whether included in the specifications or other documents

forming part of the contractor of the contract or referred to in these conditions or not and

which may be necessary for the purpose of satisfying of conditions he is entitled to be

satisfied which he is entitled to require together with carriage therefore to and from the

work. The contractor shall also supply survey instruments and other materials necessary for

the purpose of setting out works, and counting weighing and assisting to the measurement or

examinations at the any time and from time to time of the work material, failing his so doing

the same may be provided by the engineer-in-charge at the expense of the contractor and the

expenses may be deducted from any money due to the contractor under the contract from his

security deposit or the proceeds of sale thereof. The contractor shall also provide a sufficient

portion of fencing and lights required to protect the public from accident, and shall be bound

to bear the expenses of defense brought by any person for injury sustained owing to neglect

of the above precautions and to pay any damage and costs which may be awarded in any

such suit, action or proceedings to any such person or which may with the consent of the

contractor be paid to compromise any claim by any such person. In no case, the Bank shall

be a party to any such claim/claims and the contractor shall indemnify the Bank against any

claim for any person on this account.

5. ASSIGNMENT OR SUB LETTING OF CONTRACT

The contractor shall not assign the contract or any part thereof or any benefit or interest

therein or there under or any claim arising out of the contract to any other party without the

prior written consent of the Bank.

6. CONTRACTORS OFFICE AND STORES

All offices, sheds and stores required by the contractor shall be enacted at his own cost with

the prior approval of the Bank or its representative and shall be dismantled and removed

upon the completion of the work if so directed within 7 (seven) days of the issue of such

intimation.

7. DIRECTION FOR EXECUTION OF WORK

7.1 Setting outs

The contractor shall be responsible for the true and proper setting out of the works in

relation to the original points, lines and levels of reference given by the architect in writing

and for correctness subject as above mentioned of all the positions, levels dimensions and

alignments of all parts of the work and for the provision of all necessary instruments,

appliances and labor in connection therewith. If at any time during the progress of the work

any error shall appear or arises in any part of the work, the contractor on being required to

do so by The Zonal Manager, (PSB) shall at once inform the architect or their

`10



representatives. The checking of the work by the architect/representative shall not in any

way relieve the contractor from his responsibilities of carrying out the work as per the best

practices of construction.

7.2 Engagement of Labor

The contractor shall be solely responsible for the labor/ personnel employed and that the

personnel provided by the contractor shall and will not make any claim to become

employees of the Bank and that there will be no Employee and Bank relationship between

the personnel engaged by the Contractor and the Bank.

The contractor shall employ labor in sufficient numbers either directly or through

subcontractors, where such sub letting is permitted to maintain the required rate of specified

in the contract and to the satisfaction of the architect. The contractor shall not employ in

connection with the works any person who has not completed his fifteen years of age.

The contractor shall comply with the provisions of the payment of Wages Act, 1936;

Minimum Wages Act, 1948; Act, 1947; Maternity Benefit Act, 1961 and Mines Act, 1938,

Labor Contract (Regulations & Abolishing) Act or Rules, or any modifications thereof and

any other law relating thereto and rules made there under time to time.

The Contractor shall be fully responsible for timely monthly payment of wages and any

other dues to the personnel deployed by the Contractor. Further the Contractor shall solely

be responsible for having made the payments towards ESI and EPF amount (both Banks and

employee’s contribution) in the respective account of the worker for the period for which

bill is raised.

The contractor shall indemnify the Bank against any payment to be made under and for

observance of the Regulation aforesaid without prejudice to his right to claim indemnity

from his sub-contractors.

The contractor shall provide and maintain at his own expenses all rights, guards, fencing and

watching when and where necessary or required by the Resident Engineer for the protection

of the works or for the safety and convenience of those employed on works or the public.

7.3 Sampling

The contractor shall submit the samples of various materials for the approval of the

Architect &Bank. The contractor shall use the material only after the approval of the

Architect/ Bank. The verification of the material shall be done on random base during the

progress of the work in either the following manner:

(a) Random samples would be picked up during execution of work from site & if decided

by the Architect/ Bank, it would be sent to one of the approved laboratories for test &

quality check. The cost of such tests would be borne by the client.

(b) The Architect/Bank may direct the contractor to submit the challan of delivery of the

material brought at site. It would be on Random based. The Architect may also direct the

contractor to submit the copy of the test/verification certificate provided by the

manufacturer of that particular material.

`11



7.4 Inspection of work

All work under or in course of execution or executed in pursuance of the contract shall at all

times be open to inspection and supervision of the Architect or his representative and to the

personnel and the representatives of the Bank and the contractor shall at all times with

reasonable notice or the intention of the Architect or his representatives to visit work shall

have been given to the contractor, either himself be present to receive orders and

instructions, or have responsible agent duly accredited in writing present for that purpose.

Orders to the contractor's agent shall be deemed to have been given to the contractor

himself.

7.5 Suspension of Work

The contractor shall on the written order of the Architect/Bank suspend the progress of the

work or any part thereof for such time or time and in such a manner as the Architect/ Bank

may consider necessary and shall during such suspension properly protect and secure the

work as considered necessary in the opinion of the Architect/ Bankor their representative-in-

charge of the work. No compensation shall be payable to the contractor on what so ever

account for the suspension of work.

7.6 Extension of time for completion

Time is the essence of the contract. The owner and the contractor in consultation with the the

Architects shall agree upon the work progress chart. The chart shall be prepared in direct

relation to the time stated in the contract or the works order for completion of the individual

items thereof and/or the contract or works order as a whole. It shall indicate the forecast of

the dates of commencement and completion of the various trade processes or sections of the

work and shall be amended as may be required by agreement between the architects and the

Contractor within the limitations of time imposed in the contract.

If the works be delayed:

i.) By force majeure, or

ii.) By reasons of abnormally and bad weather

iii.) By reason of serious loss or damage by fire or

iv.) By reason of civil accommodation local combination of workmen or

strike or lockout effecting any of the trades employed on the work or

v.) By reason of delay on the part of contractor or trademen engaged by

the owner in executing works not forming part of the contract or

vi.) By reason of proceeding taken threatened by or dispute with adjoining

or neighboring owners or public authorities arising otherwise, than

through the Contractor’s own default, or

vii.) By reason of any other cause which in the absolute discretion of Owner is

beyond contractor’s control then in any such case the owner may make fair and

reasonable extension after obtaining Architect’s advice in the completion dates

of individual items or groups of items of work for which separate periods of

completion are mentioned in the contractor or works order as applicable.

`12



viii.) Upon the happening of any such event causing delay, the contractor shall

immediately give the notice thereof in writing to the architects with a copy to

Bank but shall nevertheless use constantly his best Endeavour to prevent or

make good the delay and shall do all that may reasonably be required to the

satisfaction of the Architect/Bank to proceed with the works Extension of time

shall be granted.

7.7 Defacement

If the contractor or his work people, or servants shall break, deface, injure, or destroy any

part of a building, or interiors, then the contractor has to rectify the same part at his own

expenses to the satisfaction of the Architect.

7.8 Approval of Materials

The contractor would bring samples of necessary materials as per the directions & would get

them approved prior to execution of work from Architect.

8. LIQUIDATED DAMAGES FOR DELAY

The times and date stipulated in the contract for the completion of the work or any part or

stage thereof shall be deemed to be the essence of the contract. The work shall, throughout

the stipulated period of the contract, be carried out with all diligence. If the contractor fails

to complete the work within the time prescribed or within the extended time under the

contract, he shall pay to the Bank on demand amount without prejudice to other rights and

remedies the Bank may have against the contractor, 2% of contract price per week or part

there of as liquidated damages for such fault, if the work remain unfinished after the

stipulated date of completion provided that the total liquidated damages payable shall not

exceed 10% of the accepted contract price. The Bank may, without prejudice to any other

method of recovery, deduct the amount of such damages from any money due or which

become due to the contractor. The recovery or deduction of such damages shall not relieve

the contractor from any obligations and liabilities under the contract.

9. DEFECTS LIABILITY PERIOD

The contractor shall be responsible to make good and remedy at his own expense within

such period as may be stipulated by the Bank any defect which may develop or may be

noticed before the expiry of 12 (twelve) calendar months from the date of completion and

intimation of which has been sent to the contractor within seven days of the expiry of the

said period.

10. SECURITY DEPOSIT

a) The Bank will, at the time of making any payment to the contractor for work

done or supply made under the contract deduct 10% of Gross value of each

bill.

b) All compensations or other sums of money payable by the contractor to the

Bank in terms of this contract may be deducted from, or paid by, the sale of a

`13



sufficient part of his security deposit, or from any sums which may become

due to the contractor by the Bank on any account whatsoever, and in the event

of his security deposit being reduced by reason of any such deduction or sale

as aforesaid, the contractor shall within ten days. Thereafter make good in

demand draft, endorsed in favor of the Bank as aforesaid any sum or sums

which may have been deducted from, or raised by sale of his security deposit

or any part thereof.

c) The above said security deposit shall be liable to forfeiture wholly or in part at

the sole discretion of the Architect if the contractor fails to carry out the work

or perform or observe any of the conditions of the contract.

d) No interest would be payable by the Bank to the contractor on the security held

in deposit.

11. BILL PAYMENT

a) Final bill supported with consolidated measurement of the full work executed

shall be submitted by the contractor within 07 days from the date of issue of

certificate of virtual completion.

b) Architect/Bank or his representative shall verify the requisite measurement for

the purpose of having the same verified for the claim as far as admissible

c) All measurements to be taken in duplicate and all bills shall be submitted in

triplicate along with a contractor’s copy of each.

d) When the final bill has been verified and corrected, the architect will give

seven days notice to the contractor to countersign the bill in token of

acceptance, the contractor shall countersign the bill within the above seven

days or intimate in writing his intention to dispute.

e) If the contractor fails to take appropriate action as above within the period

prescribed, the bill finalized by the architect or his representative shall be final

and binding on the contractor and the contractor shall have no right to dispute

the same.

12. CLAIM FOR INTEREST

No claim for interest will be entertained by the Bank with respect to any moneys

or balances which may be in its hands owing to a dispute between itself and the

contractor or with respect of any delay on the part of the Bank in making interim

or final payments or otherwise.

13. RATES FOR EXTRA ADDITIONAL, ALTERED OR SUBSTITUTED

WORK

The rates for additional, altered or substituted work shall be worked out in

accordance with the following provisions in their respective order.

i) If the rates for similar additional, altered or substituted work and directly

available in the contract for the work, the contractor is bound to carry out the

work at the same rates as are available in the contract for the work.

`14



ii) If the rates for additional, altered or substituted work are not directly

available in the contract for the work the rates will be derived from the rates

for a similar class of work as are specified in the contract for the work.

iii) If the rates for the altered, additional or substituted work cannot be

determined in the manner specified in sub-clause (i) to (ii) above, then the

contractor shall within three days of the date of receipt of order to carry out

the work, inform the Architect of the rate which it is intending to charge for

such works supported by analysis of the rate or rates claimed (CPWD

analysis). Rates finalized and approved by the Architect on the basis of these

details will be final and binding. However, the architect by notice in writing

will be at liberty to cancel his order to execute such work and arrange to carry

it out in such a manner as he may deem advisable, but under no circumstances

shall the contractor suspend the work once ordered in writing o n the plea of

non-settlement of rate.

iv) In case of furniture items, the minor changes I modifications in the design

shall not be considered as deviation, and no price adjustment shall be made

against the rates agreed to as per the Schedule of Quantities of t he contract.

For major change in the design of any item of the furniture, the deviation shall

be priced by the Architects as Extra, as per above however the decision of the

Architects whether the charge / modification in the design of furniture items is

minor or major, shall be final and binding on the contractor.

13.1REIMBURSEMENT OF VARIATION IN PRICE

Prices and rates quoted by the Tenderers shall be considered as firm for the

complete work and entire duration of the contract. No claim for extra payment due

to any rise in rates of raw material and labour or due to whatsoever reasons shall

be considered, not even for extended period of completion.

14. GUARANTEES

14.1 Quality of Work

The contractor shall guarantee that the materials and workmanship are the best of

their respective kinds for the service intended and that all items of work will be

free from all inherent defects in workmanship and materials. He shall also

guarantee that the works will not fail in any respect due to quality of materials,

workmanship and methods of construction.

The specifications assume a proper degree of skill on the part of contractor and

workmen employed. The contractor shall consult the Architect or his

representative, whenever in his judgment variation in the methods of construction

or in the quality of material would be beneficial or necessary to fulfill the

guarantee is called for. Such variations may be made by the contractor only when

authorized by the architect.

`15



14.2 Rejection

If during the “Period of Guarantee”, any work or material shall fail in any respect

to meet the above guarantee, the contractor shall replace such work or material in

a condition which will meet the above guarantee, immediately.

14.3 Cost of Execution of work or repair etc.

All work of repair shall be carried out by the contractor at his own expense if the

necessity thereof shall in the opinion of the Architect be due to the use of

materials or workmanship not in accordance with the contract or on account of

neglect or failure on the part of the contractor to comply with any obligation

expressed or complied on the contractor’s part under the contract.

14.4 Remedy on Contractor’s failure to carry out the work required

If the contractor shall fail to do any such work as aforesaid required by the

architect the Bank shall be entitled to carry out such work from/through other

person, at the contractor’s own cost. The Bank shall be entitled to recover from

the contractor the cost thereof or may deduct the same from any money due or that

may be come due to the contractor.

15. CERTIFICATE OF COMPLETION OF WORKS

On completion of the work, the Contractor shall be furnished with a certificate,

but no such certificate be given nor shall the work be considered to have been

completed until the contractor shall have removed from the area of the premises

(to be distinctly marked by the Architect) in the site plan which, the work shall be

executed) all scaffolding, surplus materials and rubbish and clean the dirt from all

wood work, doors, windows, walls, floors or other parts of any building, in or

upon which the work is to be executed, or of which he may have had in possession

for the purpose of the execution hereof. If the contractor shall fail to comply with

the requirements of the clause as to the removal of scaffolding, surplus materials

and rubbish and cleaning off dirt on or before the date fixed for the completion of

the work, the architect may at the expense of the contractor remove such

scaffolding, surplus materials, and the contractor shall forthwith pay th e amount

of all expense so incurred, and shall have no claim in respect of any such

scaffolding or surplus materials aforesaid, except for any sum actually realized by

the sale thereof.

16. TERMINATION OF THE CONTRACT

If at any time after the commencement of the work the Bank for any reason

whatsoever does not require the whole or part thereof as specified in the tender to

be carried out, the Bank shall have the right to terminate this Agreement and The

PSB shall communicate the termination by giving a notice in writing to the

contractor.

The contractor shall have no claim to any payment or compensation whatsoever on

account of any profit or advantage, which would have derived from the execution

`16



of the work in full, but which he did not derive in consequences the full amount of

the work not having been carried out.

The Contractor shall not have any claim or compensation by reason of any

alterations having been made in the original specification, or the designs and

instruction on which shall involve any containment of the work originally

contemplated. However, in case of part cancellation, the Contractor shall be paid

such amount as is commensurate to the actual work done by him till such

termination notice is received.

17. JURISDICTION

The contractor and its operation shall be governed by the law of India for the time

being in force, irrespective of the place of delivery of materials the place of

execution of work or place of payment under this contract shall be deemed to have

been entered into at New Delhi.

18. BYE LAWS OF LOCAL AUTHORITIES

The contractor shall conform to the provisions of all applicable Government Acts

which relate to works and to the regulations and bye laws of any local authorities.

The Contractor shall give all such notices required by the said Act or Laws, etc.,

and pay all fees payable to such authorities and allow for these contingencies in

his tendered rates including fees for encroachment, stacking charges, costs of

restorations, etc., and all other fees payable to the local authorities. The

Contractor shall keep the Bank indemnified against all penalties and liabilities for

every breach of any such Act, Rules, Regulations or Bye-laws.

Further the Contractor shall specifically ensure compliance of various Labor

Laws/Acts including but not limited to with the following and their re -

enactments/amendments/modifications while dealing with the employment of

labor such as:

a. The Payment of Wages Act, 1936

b. The Minimum Wages Act, 1938

c. The Workmen Compensation Act, 1923

d. The Contract Labor (Regulations & Abolishing) Act.

e. The Bank’s Liabilities Act, 1938

f. Industrial Dispute Act, 1938

g. Maternity Benefit Act, 1961

h. The Employees State Insurance Act, 1948

Safety code, labor welfare Act or rules or any modificat ion thereof any other laws

and regulations framed by the Competent Legislative Authorities from time to

time.

`17



19. LIASONING & CO- ORDINATION WITH LOCAL MUNICIPAL

AUTHORITIES

The contractor has to liason and takes any clearance from local authorities

like Delhi / other authorities for approval to start renovation and during

renovation of work including Defect Liability Period if needed. Only statuary

fees will be reimbursed by PSB.

`18



SECTION V– SPECIAL CONDITIONS OF THE CONTRACT

1. INSURANCE FOR WORKS

The contractor at the time of signing the contract or before commencing the

execution of work, without limiting his obligations and responsibilities shall

insure the works at his own cost and keep them insured until the virtual

completion of the contract against all acts of God including Fire, Theft, Riots,

War, Floods etc. with a Nationalized Insurance company in the joint names of the

Bank and the contractor (the name of the former being placed first in the policy)

for the full amount of the contract. Such policy shall cover the property of the

Bank and fees for assessing the claim and in connection with is services generally

therein and shall not cover any property of the Contractor or of any sub contractor

or employee.

The contractor shall deposit the policy and receipt for the premiums with the Bank

within seven (7) days, from the date of signing of the contract/commencement of

the execution of the work or unless otherwise instructed by the Bank. In default of

the contractor insuring as provided above, the Bank on his behalf may so insure

and may deduct the premiums paid from any moneys due on which may become

due to the contractor. The contractor shall as soon any claim under the policy is

settled on the work reinstated by the Insurance office should e lect to do so,

proceed with all due diligence with, the completion of the works in the same

manner as through the misfortune/accident had not occurred and in all respects

under the same conditions of the contract. The contractor in case of rebuilding or

reimbursement after accident shall be entitled to such extension of time for

completion, as the Bank deems fit.

2. INSURANCE IN RESPECT OF DAMAGE TO PERSONS AND

PROPERTY

a. The contractor shall be responsible for all injury to persons, animals or things

and for all structural and decorative damage to property which may arise from

the operation or neglect of himself or of any approved sub-contractor’s or

employees, whether such injury or damage arise from carelessness, accident or

any other cause whatsoever in any way connected with the carrying out of this

contract. The clause shall be held to include any damage to buildings, whether

immediately adjacent or otherwise, and any damage to roads, streets, foot

paths, bridges and works forming the subject of this cont ract by frost or other

inclemency of the weather. The contractor shall indemnify the Bank and hold

him harmless damage to persons or property as aforesaid and also respect of

any claims made in respect of injury or damage under any Acts of Government

or otherwise and also in respect of any award of compensation of damages

consequent upon such claims.

`19



b. The contractor shall reinstate all damages of every sort mentioned in this

clause, so as to deliver up the whole of the contract works complete and

perfect in every respect and so as to make good or otherwise satisfy all claims

for damage to the property of third parties.

c. The contractor shall indemnify the Bank against all claims which may be made

against the Bank by any member of the public or other third party in respect of

works in consequence thereof and shall at his own expense arrange to effect

and maintain, until the virtual completion of the contract, with any

Nationalized Insurance company in the joint name of the Bank and the

contractor against such risks and deposit such policy or policies with the Bank

from time to time during the currency of this contract. The contractor shall

similarly indemnify the Bank against all claims which may be made upon the

Bank whether under the Workman’s Compensation Act or any other statute in

force during the currency of this contract or at common law in respect of any

employee of the contractor or any sub-contractor and shall at his own expenses

effect and maintain with an approved office a policy of Insurance in the j oint

names of the Bank and the contractor against such risks and deposit such

policy of policies with the Bank and the contractor against such risks and

deposit such policy or policies with the Bank from time to time during the

currency of the contract. The contractor shall be responsible for anything

which may be excluded from the insurance policies above referred to and also

for all other damages to any property arising out of and incidental to the

negligent or defective carrying out of this contract. He shall also indemnify the

Bank in respect of any costs, charges or expenses arising out of any claim or

proceedings and also in respect of any award of or compensation of damages

arising there from.

d. The Bank shall be at liberty and is empowered to deduct the amount of any

damages, compensation costs, charges and expenses arising or occurring from

or in respect of any such claim or damage from any sum or sums due to or

become due to the contractor including the security deposit.

e. If the contractor fails to comply with the terms of these conditions, the Bank

may insure the works and may deduct the amount of the premiums paid from

any moneys that may be or become payable to the contractor or may at the

option, not release running payment to the contractor until the contractor shall

have complied with the terms of this condition.

f. Such insurance whether affected by the Bank or the contractor will not limit or

bar the liability and obligation of the contractor to deliver the works to the

Bank completed in all respects according to the contract. In case of loss or

damage due to any of the aforesaid clause, the moneys payable under any such

insurance shall be received and retained by the Bank until the works are finally

completed and such moneys shall then be credited to the contractor in final

settlement of accounts.

`20



g. The works shall be executed in close co-ordination with the progress of other work. This

being absence of the contract, no claim for idles labor will be entertained.

3. TYPOGRAPHIC OR CLERICAL ERRORS:

The Architect’s/Engineer-in-Charge's clarifications regarding partially omitted particulars or

typographical or clerical errors shall be final and binding on the Contractor.

4. SCOPE OF CONTRACT:

The Contractor shall carry out and complete the said furnishing works comprising of

wooden partition, paneling false ceiling including miscellaneous, electrical works and

modification / addition to existing provision. Provision and Furniture, furnishing etc.

complete in every respect in accordance with Contract and with the directions of and to the

satisfaction of the Architects and the Bank. The Architects may in their absolute discretion

and from time to time, issue further drawings and/or written instructions, details, directions

and explanations which are hereafter collectively referred to as "Architect's Instructions" in

regard to:

a. The variations or modifications of the design quality or quantity of works or the

addition or omission or substitute of any work.

b. Any discrepancy in the drawings or between the Schedule of Quantities and/or

drawings and/or Specifications.

c. The removal and / or re-execution or any works executed by the Contractor.

d. The removal from the site of any material brought there on by the contractor and the

e. Substitution of any other material there from.

f. The dismissal from the works of any person / persons employed thereupon.

g. The opening up for inspection of any work covered up.

h. The amending and making good of any defects under clause "Removal of Improper

Work and Material".

The Contractor shall forthwith comply and fully execute any work comprised in such

Architect's Instructions provided always that verbal instruction. Directions and explanations

given to the Contractor or his representative upon the works by the Architects shall, if

involving a variation, be confirmed in writing by the Contractor within 3 days and if not

dissented from in writing within further 3 days by the Architect. Such shall be deemed to be

the Architect's instructions within the scope of the contract.

If compliance with the Architect's instructions as aforesaid involved work and/or expense

and/or loss beyond that contemplated by the Contract. Then unless the same were issued

owing to some breach of this contract by the Contractors. The Bank shall pay to the

Contractor on the Architect's Certificate, the price of the said work (as an extra to be valued

as herein after provided) and/or expense and/or loss.

5. SCHEDULE OF QUANTITIES:

The Schedule of Quantities unless otherwise stated shall be deemed to have been prepared in

accordance with the method of measurements specified in the particular specifications and

`21



shall be considered to be approximate. The Bank does not undertake to carry out the whole

of work as shown in the drawings and taken in the schedule of quantities and reserves the

right to modify the same or any part thereof. The Contractor shall not be allowed any

compensations or damages for the work so omitted or cancelled by the Bank. Each tender

item should be filled in with the rates and amounts in separate columns and all the sections

should be totalled up in order to show the aggregate value of the entire tender. The rates

should be filled both in figures and words for each item and in case of discrepancy the rates

filled in words shall be considered as correct for the evaluation of tender amount. The

initials of the tenderers shall duly attest all corrections in the tender Schedule. Corrections,

which are not attested, may entail the rejection of tender.

`22



LIST OF APPROVED MATERIALS:

Material

Approved Make/Brand

CIVIL INTERIOR WORKS

Laminated sheet (1.0 mm thick) Premium

Formica /Greenlam / Merino /

Archidply

Comm. Board /Flush door shutter Duro/ century / Green / Archidply

Commercial Ply wood Duro/ century / Green / Archidply

MR grade ply Conforming to IS 303 Duro/ century / Green / Archidply

Marine grade Ply wood Conforming IS 710 Greenply /Duro /Century / Archidply

BWP grade Block Board /ply Duro / Merino /Century / Archidply

Melamine /PU Finish MRF/Asian Paints /Nerolac

Ceramic Tiles/vitrified homogeneous glazed tiles.

Kajaria/Nitco / HR Johnson / Somany /

Marbonite

Glazing (Clear) St. Gobain / Indo Asahi /Modi float / Glaverbel

HYDRAULIC DOOR CLOSER DORMA/ DOORSET

FLOOR SPRING, FRAMELESS GLASS

FITTINGS, HANDLES

DORMA / TRIUM / KICH

Glue Fevicol

Paints/Distemper/Arcylic/Enamel/Plastic paint Asian / Shalimar / ICI / Nerolac / Berger

Door locks Godrej,goldenlocks,dorset

Door closer Dorma /Dorset

Anti termite/fire retardant paint Viper FirestarFr – 881 paint

GREY CEMENT (OPC) ACC/ L&T

WHITE CEMENT JK/ BIRLA

ELECTRICAL WORKS

Distribution Boards withMiniature Circuit

Breakers, ELCB

Legrand, Schneider, Hagger

CableTray/ Raceway CTM Engineers, KME, MEM

Telephone Cable Delton, KEI, Polycab

Co-axial cable for TV KEI, D Link, Polycab

Telephone Tag Block Krone, TVS R&M

M.S. Conduit BEC, RMCON, AKG

PVC Conduit BEC, AKG, Polycab

Modular Switches & Sockets CrabtreeAthena, MK WraproundPlus,

ScheniderOpale

LV System Wire (Cat 6) Amp, Systemax

Telephone/ DataOutlet Amp, Systemax

Exhaust Fan / Wall Fan

GEC, Crompton, Orient

`23



AC WORKS

Copper Pipe Mandev Tubes/ Merchant/ Met Tube

wall mounted automatic stabilizer bluebird/ logictech/ carrier/ micel

Power Cables Phenolex/Kalinga

Control Cable Phenolex / Kalinga

CONDUIT for Elect. Wires AKG / Marshal / Plaza

Voltmeter / Ammeter A. E. / IMP

Overload Relays LT / LK / Siemens / BCH./GE

Time Delay Device Siemens / LT / LK / Concord

Single phase Preventer LT/LK/Minilec/GE

Paints ICI / Asian / Johnson & Nicholson

M.C.B. MDS/L&T / Indo Kopp/Standard

`24



DRAWINGS

`25



`26



`27



`28



`29



`30



`31



PUNJAB & SIND BANK

TENDER DOCUMENT

OF

CIVIL, INTERIOR-FURNISHING, ELECTRICAL &AIR-CONDITIONING

WORKS FOR BO at STC BUILDING, ROHINI, SEC-3, DELHI.

FINANCIAL BID

Architects M/s SPACE ACE

PLANNERS& INTERIOR DESIGNERS V-20A/05 DLF CITY-III, GURUGRAM,

HARYANA - 122002 TEL. PH. No. :- 0124-4106618

Email: [email protected]

32

S. No. Description Unit Qty. Rate Amount

I

1.0 CIVIL WORKS

1.1 BRICK WORK

A Half brick masonry with common burnt clay F.P.S. (non modular) bricks of

class designation 7.5 in superstructure above plinth level up to floor V

level.

Cement mortar 1:3 (1 cement :3 coarse sand) Sqm 15

1.2 PLASTERPlastering of walls in 12mm th. smooth cement plaster on existing block masonary,

RCC columns, RCC Walls, of any profile, in 1:4 cement mortar, (1unit- cement, 4unit-

fine screened sand), incl. of hacking on column/wall, making surface wet before

applying plaster and proper curing after plaster etc complete. all plaster works will

have provision of chicken mesh with more than 2" overlap between RCC member

and wall so as to avoid cracks due to thermal expansion, chicken mesh to be also

provided on all chased surfaces such as ,conduit chasing , pipe line chasing etc. and

then chased area to be replastered . Cost to be inclusive of all including scafolding at

all heights .

Sqm 25

1.3 P.C.CProviding and laying plain cement concrete 1:2:4 mix (1 cement :2 coarse sand :4

hard stone aggregate 20 mm nominal size) under floors. For raceways, electrical

conduits in floors etc. over existing R.C.C Slab, necessary shuttering, curing,

compacting, etc Complete & all to be included in cost & quoted rate shall for all levels

of floor & height.

Cum 5.00

For raceways, electrical conduits in floors etc.

Total to be carried over the summary

2 FALSE CEILING WORKS

Note: Quoted Rates are for all heights , scaffolding, depths, levels, leads and lifts and

for all design and pattern shown in drawings

Contractor to include the cost of members & all required accessories for

installation compelet finished ceiling in his quoted rate

Actual finished area to be measured and paid for

Vendor Shall submit & get approved all type of board/Tiles /plank sample by

Architect before execution.

FINANCIAL BID FOR INTERIOR-FURNISHING, ELECTRICAL & AIR-CONDITIONING WORKS FOR PUNJAB & SIND BANK

BO at STC BUILDING, ROHINI, SEC-3 NEW DELHI.

BOQ - Civil, Interior-Furnishing, Electrical AC Works of BO at STC Building, Sec-3, Rohini. Contractor's Signature

33 S. No. Description Unit Qty. Rate Amount

2.1 Modular Grid Ceiling

Providing and Fixing of false ceilings at all heights of 600mm x 600mm Grid

ceiling tiles with Microlook Edge laid on prelude XL exposed silouette grid

systems with 15mm wide T- section flanges colour white. The framework

comprise of main runner spaced at 1200mm centers securely fixed to the

structural soffit by approved hangers at 1200mm maximum centers. Hangers

(GI wire of 4.0mm dia) to be fixed by approved roof plug/ fastener, level

adjusters and screws etc. The last hanger at the end of each main runner

should not be greater than 450mm from the adjacent wall. Flush fitting

1200mm long cross tees (with double stitching) to be interlocked between

main runners at 600mm centers to form 1200 x 600 modules. Cut cross tees

longer than 600mm to be supported independently.

600mm x 600mm modules to be formed by fitting 600mm long flush fitting

corss tees centrally between the 1200mm cross tees. Perimeter trim to be

Armstrong wall angle secured to walls at 450mm maximum centrers. The

quoted rate shall be inclusive for making opening for light fixtures, diffusers &

AC fittings. The quoted rate shall be inclusive of suspenders at all heihgt &

extra member required for all openings. (Basic rate of only ceiling tile Rs

800/- per Sqm. including taxes)(Contractor to include the cost of

members & all other accessories mentioned above in his quoted rate)

ARMSTRONG silhouette grid system of size 600x600 Sqm 68

2.2 Gypsum False ceiling

Providing and fixing false ceiling at all height including providing and fixing of frame

work made of special sections, power pressed from M.S. sheets and galvanized with zinc

coating of 120 gms/sqm (both side inclusive) as per IS : 277 and consisting of angle cleats

of size 25 mm wide x 1.6 mm thick with flanges of 27 mm and 37mm, at 1200 mm centre

to centre, one flange fixed to the ceiling with dash fastener 12.5 mm dia x 50mm long

with 6mm dia bolts, other flange of cleat fixed to the angle hangers of 25x10x0.50 mm of

required length with nuts & bolts of required size and other end of angle hanger fixed with

intermediate G.I. channels 45x15x0.9 mm running at the spacing of 1200 mm centre to

centre, to which the ceiling section 0.5 mm thick bottom wedge of 80 mm with tapered

flanges of 26 mm each having lips of 10.5 mm, at 450 mm centre to centre, shall be fixed

in a direction perpendicular to G.I. intermediate channel with connecting clips made out

of 2.64 mm dia x 230 mm long G.I. wire at every junction, including fixing perimeter

channels 0.5 mm thick 27 mm high having flanges of 20 mm and 30 mm long, the

perimeter of ceiling fixed to wall/partition with the help of rawl plugs at 450 mm centre,

with 25mm long dry wall screws @230 mm interval, including fixing of gypsum board to

ceiling section and perimeter channel with the help of dry wall screws of size 3.5 x 25 mm

at 230 mm c/c, including jointing and finishing to a flush finish of tapered and square

edges of the board with recomme-nded jointing compound, jointing tapes, finishing with

jointing compound in 3 layers covering upto 150 mm on both sides of joint and two coats

of primer suitable for board, all as per manufacturer’s specification and also including the

cost of making openings for light fittings, grills, diffusers, cutouts made with frame of

perimeter channels suitably fixed, all complete as per drawings, specification and

direction of the Engineer in Charge including the cost of making trap door made of 12

mm thick prelaminated partical board resting/ fixed including all hardware, hard wood

lipping etc. complete as per drawing : Knuff Size: 600x600

a 12.5 mm thick tapered edge gypsum fire resistant board

conforming to IS: 2095- Part I

sqm. 76.0




3.0 FLOORING / CLADDING WORKS

Note: (Quoted Rates are for all heights, depths, levels, leads and lifts and for all design and

pattern shown in drawings)

Note: Actual finished area to be measured and paid for.

Note :- Vendor Shall submit & get approved all type of stone/Tiles sample by

Architect before execution.

Make Vitrified Tiles: Kajaria / Somany / Johnson / Nitco

3.1 Tile Flooring

Providing and laying 10-12mm thick Vitrified tiles of Kajaria / Somany / Johnson /

Nitco make of approved shade of size as per drawing in floors over 20mm (average)

base of cement mortar 1:4 ( 1 cement :4 coarse sand) required thickness to match

finished floor level mentioned and to match the neighboring floor finish and jointed

with epoxy grout of approved shade from Bal Endure or equivalent brand all complete

as directed complete. Rate to include forming pattern in the flooring like border,

skirting, cut tiles, Protecting of the tile till hand over date by POP., etc all complete as

per detailed architectural drawing.

a same as above With Vitrified Tiles of Base rate of Vitrified tiles Rs. 800/- per

Sqm. leaving taxes and freight and loading un loading charges )

sqm. 136.00


4.0 DOOR / WINDOW WORKS

Note: Providing and fixing phenol bonded solid core flush door shutters of approved quality

and make non decorative type core of block board construction with internal frame of

red marandi wood.

Door Frame: Made overall size 60 x 150 mm finished with polish finish as shown in

drawing . Note:- for partition frame size - 50 x 100 or as per partitions width.

Architraves of overall size 40 x 12 mm fixed to wooden frame both side as shown in

drawing.

Including providing & fixing of all hardware & accessaries, hinges, door handle,

door closer, door stopper, lock, tower bolt, door buffer, making of grooves, providing

& applying wood preservative, antitermite proof paint, polish, screws, nails,

wooden studs, wooden beading, all necessary fixing arrangement etc complete as per

design and drawing. all hardware to be dorma/Hettich or equivalant Make

Make for Doors & Fittings

Hardware/Locks: Dorma XLC, Kitch, Geze, Hettich, Dorset, Halflae

Hardware: Dorset, Ingersoll Rand, Hettich, Kitch,

Door Closers : Dorma

Door Locks: DORSET,Golden

Door Seals: Enviroseals

4.1 Laminate Doors : Same as above Description with 30-35 mm thick shutter finish with

1 mm thick laminate (Forica, Merino, Durian, Green Lam) in both side of the shutter

of approved make & shade and edge polishing / enamel painting, including

200x1800mm vision panel made of 6mm thick non toughened clear Glass with

wooden frame duly polished on each shutter complete with all necessary fixing

arrangement complete as per shown in drawing and directed by the Architect.

Flush Doors: Merino, Green ply industries, Century, Sonear, Alpro, Durian

Each door to have 4 Nos of 6" railway barring hinges in SS finish

door shall be with the dorma heavy duty door closer code no ITS96GSR with

necessary tower bolts and pivots

Doors to have cylindrical locks

Door to have 400mm long 30mm dia SS buff finish handles on both sides. etc all

complete as per detailed architectural drawing.

a Item same as above but with overall size of shutter is 750 to 900 x 2100mm with or

without vision panel (as per requirement).

Each 2



4.2 GLASS DOORS

Providing and fixing Single/Double leaf frameless glass door made of 12 mm thick

toughened glass including floor spring, patch fittings, SS top pivot, door handle,

lock of approved make (sample approved by the Architect/ Client) and all necessary

hardwares and fixing arrangement complete as shown in drawing and directed by the

Architect. make of Fitting as approved: Kich/Ozone/Neki/Dorma. & Glass Make :

Modiguard/Asahi float/ Saint-Gobain/Asahi India

sq.m. 8

with cylinderical locks and kitch handles both sides 30mm dia and 600mm long in

buffed SS 304 finish.


5.0 PARTITION/PANELLING WORKS

5.1 Providing and fixing G.I Frame for Partitions consisting of G.I vertical studs of size

50mm & horizontal members @ 600 x 600 or where ever required as per

manufacturer, specs, using Gypsteel sections, hardwood will be inserted as may be

required to fix door frames skirting etc. with all necessary fixing arrangement

complete as per shown in drawing and directed by the Architect. Quote only for

framework. All components to be of India Gypsum or LA gyp (la farge)

The cost to be included of 50 mm thick 24 kg/m3 density glass wool insulation inside

the partition frame work including jointing and finishing. and To facilitate the skriting

bottom channel to be cladded with 6mm marine plywood on both sides resist by 5-

10mm groove on both sides. includning Providing and fixing of prefabricated

alumnium skirting as per product details, 50-75mm high of jeb/bottomline or

equivalant make. all inclusive as per architects instruction.

a FRAME WORK FOR FULL HEIGHT PARITION: Frame work of Partition in

G.I

sqm 60.00

b FRAME WORK FOR WALL PANELLING WORKS: Frame work of Partition

in G.I consisting of G.I vertical studs of size 50mm & horizontal members @ 900 x

900 or where ever required as per manufacturer, specs, using Gypsteel sections,

hardwood will be inserted as may be required to fix door frames skirting etc. with all

necessary fixing arrangement complete as per shown in drawing and directed by the

Architect. Quote only for framework. All components to be of India Gypsum or LA

gyp (la farge)

sqm 72.00

5.2 Providing and applying the claddings on the G.I framework erected for Solid

partitions.

Cladding under this section shall be considered to be applied only to one side.

Cost for fixing plywood/ MDF etc. and fixing/cladding laminate/ veneer to be quoted

as per case. Each side of the partition finishes will be measured as per the case.

Contractor to make provision for all electrical/ networking boxes and to provide

30mm dia cut-outs as required. Electrical/ Network boxes/ other services to be

provided at desired height and location as indicated in the drawing or as instructed at

site.

All junctions between materials, columns, walls, etc to have a 6mm groove with

Aluminium `L'/ 'U' sections as per details. And all grooves joint and design pattern

shall be included in quoted cost.

All exposed edges/ corners/ grooves to have proprietary corner/ edge bead sections/

channels as per Architect's instructions.

All exposed gyp board edges to be fixed with BeadEx self adhesive.

At all locations where services are penetrating the partition above false ceiling to have

additional GI frame work around the duct/ cable tray/ pipe and the gaps between the

frame work and service to be filled with appropriate acoustic sealant or with fire stop

material as directed.

Approved make

Laminates: Formica / Greenlam / Durian / Merino

Veneer: Duro group B

Commercial/Flexible Ply: Century/ Green/ Garnet/ Alpro/Durian/ merino/ Duro



a SKIN TYPE-1 OVER G.I FRAMING: 6 mm PLY/MDF + 6mm PLY/MDF +

1mm Laminate on both sides of Partition. The PLY should be Leed certified Green

Products, FSC certified and CE certification. which insure the quality of the products

to the international standards.

sqm 60.00

b SKIN TYPE-1 OVER G.I FRAMING: 6 mm PLY + 6mm PLY + 1mm

Laminate on single sides of Paneling. The PLY should be Leed certified Green

Products, FSC certified and CE certification. which insure the quality of the products

to the international standards.

sqm 72.00

5.3 Laser Cut Graphic / pattern in 19mm+19mm thk MDF For column clading

P/F laser cut shapes out of 19mm+19mm MDF. This will be installed on panel with

3m tape as located in plan. The quoted cost to include making arrangement for fixing

the designer panel in floor and same to be fixed in ceiling with G.I support above false

ceiling lvl

sqm 3.00

5.4 FULL HEIGHT GLASS PARTITION (12mm Thk Toughfened Glass

Partition)

Providing & fixing 12 mm thk toughfened glass partition finished with machine

polish at all exposed sides as per site requirement fixed with L-connectors complete as

per detail drawing & instructions of Architect including Etching Film ( garware ) as

per design on above item as per instructions of Architect in required pattern.

sqm 23.00


6.0 FINISHING WORKS

Notes: Painting rates to include cost of covering/ protecting all finishing materials including

switches, lighting fixtures, AC equipment etc.

Applying painters putty & scrapping the surface and repeating the process as many

times as is required to achieve a thoroughly smooth surface for partitions paneling and

walls

6.1 POP punning

Providing and applying plaster of paris (super fine quality) punning with minimum

thickness of 6mm and finish the surface smooth in line and also making groove, level

to the entire satisfaction of Architect including scraping and hacking the existing

finished surfaces, scaffolding etc. complete as per drawing.

sqm 70.00

6.2 Acrylic Emulsion paint

Wall painting with acrylic emulsion paint of approved brand and

manufacture to give an even shade :

Two or more coats on new work sqm. 76

6.3 SYNTHETIC ENAMEL PAINT

Painting with synthetic enamel paint of approved brand and manufacture

to give an even shade :Make: Asian (Apcolite)/ICI Dulux (Gloss)/Nerolac (Full Glass

Hard Drying)

Two or more coats on new work Sqm 40.00




7.0 FURNITURE

Important Notes:

all veneer (Duro group B ) are of Base Rate 175 Rs./Sq.ft unless or otherwise

specified.

all furniture in veneer are with melamine polish included in desire color shade as to be

approved by architect's

all necessary hardware such as handle, drawer channels, hinges shall be inclusive in

the quoted cost.

Every invidual table to be considered with drawer' and shelf built in as per design and

quoted cost shall include this also.

all Laminates make Merino/Green Lam/Durian/Formica

7.1 TABLES

A P/F Tables of 2'-6" height made ¾ “ th comm board for tables made out of

19mm comm block board for tables/12 mm thk. flexible ply in designs

wherever required as per design, with modesty panel, file drawers, all visible

areas to be finished with 1mm premium laminate / veneer, top side finished

with 6mm thick solid arcylic top (Corian Top) of make Dupont / Samsung

/ Aspiron / Duralax etc. (basic rate of Rs. 550/- per sq.ft. excluding taxes

and transportation) in approved color as per drg/detail with pencil drawer,

file drawer ,3”,6” drawer etc , 3”x 2” steam beech wood leg rest,

european/german steemed beech ¾”x ½” mouldings on margin and 11/2”x

1½”European/German Steemed Beech moulding on all edges sides and 3/4" X

3/4" Ex Steam beech moulding melamine polish at 2” high skirting level with

all necessary hettich/ haffle channels, Keyboard and channel ,handles

,hardware, all drawers with telescopic channels and all handles to be stainless

steel. as per drgs per design /architect's instructions, (Includes the cost of 3/4"

X 3/4" ex steam beech moulding melamine polish at bottom bands) Godrej

locks & SS handles as per approved sample.

I Table of size 7'0" x 3'-0" x 2-'6" high with side credenza / table of size 3'6" to 3'10" x

1'-6" x 2-'4" to 2'-6". (For BM cabin).

Nos. 1

II Table of size 5'-0" x 2'-3" x 2-'6" high with side credenza / table of size 3'6 to 3'10" x

1'-6" x 2-'4" to 2'-6". (For Workstations)

Nos. 6

III Cash counter tables Size: 5'9" x 2'6" to 2'3" x 2'6" with corian only on top face of

counter

Nos. 1

7.3 STORAGE FULL / LOW HEIGHT / CREDENZA

7.3.1

P/F low height 1’-6” to 2'0" deep(area calculated as length x breadth ) storage in

cabins as / dwg.made up of 19mm commercial block board shutters,sides & shelves

with melamine polished european/german steemed beech ¾”x ½” mouldings on

margin and 11/2”x 1” European/German Steemed Beech moulding on all edges sides

and 3/4" X 3/4"Ex Steam beech moulding melamine polish at 2” high skirting level .

6mm plywood back,with 1mm thick laminate on all visible surfaces leaving storage

table top. The low heighted storage top side finished with 6mm thick solid

arcylic top (Corian Top) (basic rate of Rs. 550/- per sq.ft. including taxes and

transportation) in approved color as per drg/detail with enamel/plastic base on inner

surfaces, mounted on powdercoated hinges, including efficent gadgets locks. C 4”

stainles steel handles, and magnetic ball catchers with necessary hettich/haffle

hardware, SS tower bolts (300x10 mm), hinges, godrej locks and SS handles as per

architects instructions including shelves as per design .

Sq.mt 10

7.3.2

P/F full height 1’-6” to 2'0" deep(area calculated as length x breadth ) storage in

cabins/working hall area as / dwg.made up of 19mm commercial block board

shutters, sides & shelves with melamine polished european/german steemed beech

¾”x ½” mouldings on margin and 11/2”x 1” European/German Steemed Beech

moulding on all edges sides and 3/4" X 3/4"Ex Steam beech moulding melamine

polish at 2” high skirting level . 6mm plywood back, with 1mm thick premium

laminate on all visible surfaces in approved color as per drg/detail with enamel/

plastic base on inner surfaces, mounted on powdercoated hinges, including efficent

gadgets locks. C 4” stainles steel handles , and magnetic ball catchers with necessary

hettich/haffle hardware,hinges, godrej locks, SS tower bolts (300x10 MM) and SS

handles as per architects instructions including shelves as per design .

Sq.mt 23




8.0 MISCELLANEOUS

8.1 Fabric Board

Providing and fixing Fabric Board. Rates of the Fabric board to be inclusive of

accessory kit like pen stand, duster, magnets etc.

Sqm 20

Base Rate of Fabric : 350 Rs. Rmt (Leaving all taxes and Transportation charges)

8.2 BLINDS

8.2.1 Roller Blinds- Normal

Providing & fixing roller blinds comprising of polymer coated fibre fabric with

minimum openness factor of 3% as per AS standards. The fabric shall be fire retardant

and have high heat reflection ratios. The roller mechanism shall be a moulded unit

made from engineering grade plastic polymer with steel spring support. The fabric

shall be finished on the sides with edge tape duly welded for waviness control. The

fabric shall be attached to the roller tube with high quality self adhesive tape. Average

width of blinds shall be 2000mm and fall of 3000mm with manual operation.

Headrail: shall be .812" high x 2" deep extruded aluminum headrail with a wall

thickness of 0.045” and painted to coordinate with fabric color.

Cord lock: shall be a snap-in design of injection-molded thermoplastic incorporating

a metal, free-floating, serrated cord-locking roller.

Lift cord: shall be 1.2mm polyester and concealed for a clean appearance. A snap

tassel and joiner ball connect to a single Danskord for raising and lowering the shade.

Cord, tassel and joiner ball are color coordinated with fabric.

Installation: Bracket shall be low profile, hidden snap-in design made of 0.025” zinc-

plated spring steel.

Bottomrail: shall be 0.375" high x 2" deep extruded aluminum with a wall thickness

of 0.045” and painted to coordinate with fabric color.

Fabrication Shades shall be fabricated according to specifications and accurate to

tolerance established by SWF engineering standards

a Basic Cost: Rs 1500 per sm + taxes

make: Vista / Hounter Douglas / Livin Sqm 9.00

8.3 MS GRILL IN BRANCH FRONT SIDE

8.3.1 Structural steel work in single section, fixed with or without connecting plate,

including cutting, hoisting, fixing in position and applying a priming coat of approved

steel primer all complete.

Kg 500.00


S.No. ITEM DISCRIPTION AMOUNT

1.0 CIVIL WORKS

2 FALSE CEILING WORKS

3.0 FLOORING / CLADDING WORKS

4.0 DOOR / WINDOW WORKS

5.0 PARTITION / PANNELING WALL FINISHING WORKS

6.0 FINISHING WORKS

7.0 FURNITURE

8.0 MISCELLANEOUS

TOTAL AMOUNT FOR INTERIOR_FURNISHING WORKS

SUMMARY OF CIVIL, INTERIOR_FURNISHING WORKS



II

Note: Providing and fixing and commissining the below mentioned Light fixture with Open

construction low loss electronic / copper Ballasts, starter, HPF condenser, Low glare

and with High lumens output lamps. The installation shall be complete with all

hardwares like anchor fasteners, set of chain / drop rods with ball & sockets, check

nuts, flexible pipes with glands etc. complete.

The rate shall also include cutting open false ceiling and channels to the required sizes

and finishing with pop works.

1.0 Providing and fixing and commissining Philips /Insta power LED Linear/strip

lighting system of approved design, mounted on ceiling, columns as per required

designs.

mtr. 10

14.4W Linear led light strip

2.0 Supply & Installation including making hole for exhaust fan in the opening, including

making the hole to suit the size of the above fan, making good damages connection,

I/c fixing louvers / shutters complete with frame, mounting rings frame with four

fixing holes, testing and commissioning etc. as required.(Crompton Greaves / Orient

Heavy duty )

Nos. 1

450 sweep and RPM 1400

3.0 Fixing in gypsum/armstrong ceiling, connecting testing and commissioning of

dismantalled downlighters (provided by bank dismantalled at time of work

excution and stored in place provided by bank) including the cost of necessary

inter-connections required all complete.

Lumpsum 1

4.0 Supplying, installing, testing and commissioning of wall bracket fan of 400

mm, complete with moulded propeller type blades, and accessories suitable

for operation on 230 / 240 Volts,

50 Hz, single phase, A.C. supply. (Make: GEC/Crompton/Orient)

Nos. 10

5.0 Providing & fixing BELL POINTS on wall /Partition with 2x1.0 sqmm copper

conductor in PVC medium gauge conduit(IS:9537) with call bell switch(Push

Type) including call bell Multi Tune Bell etc. complete in BM Cabin.

Nos. 1

6.0 a) Providingand fixing in gypsum/armstrong ceiling, connecting testing and

commissioning of following luminaires including the cost of necessary inter-

connections required 2'X 2' Luminare all complete.in 42 W(a) Wipro Pure

LED/Phillips/GE Mapple.)

Nos. 18

ELECTRICAL & LIGHT FIXTURES



6.00 WIRING

6.1 Supply all materials, receiving, storing, handling, fixing, laying, wiring and

testing for light, fan, exhaust fan, 5 Amp. switch and socket, etc starting from

point control box to the outlet using ISI marked (IS:694) single core 1.5 sqmm

flexible, flame retardant low smoke (FRLS), stranded copper conductors

PVC insulated 1100 Volt grade wiring in concealed / exposed system using 25

mm ISI marked (IS:IS:9537-III & 3419) 2 mm thick, heavy duty PVC

conduit including all conduit accessories, such as bends, tees, draw boxes,

minimum 1.2 mm thick G.I. or MS point control boxes with zinc plating and

yellow passivation, together with wiring accessories such as white modular

plate type switches and sockets, cover plate, grid plate etc. including circuit

wiring from DB to switch board and switch board to switch board by 2x1.5

sq.mm. flexible flame retardant copper wire with 1.5 sqmm Cu earth

continuity wire.

The conduit being laid in recess (concealed) either in ceiling slab / wall,

chasing on surface or under false ceiling including required clamping

arrangement and required length of PVC flexible conduit or in wooden

partitions etc. complete as required at site. (The minimum size of conduit will

be 25 mm dia irrespective of number of wires drawn into it)

a One light point with 5 Amp. switch. 20 NOS

bEach additional light point controlled by same 5 amp switch 35 NOS

cExhaust fan point with 5 Amp. Switch 1 NOS

dOne 5 pin 5 amp shuttered socket outlet with 5 amp switch 10 NOS

eSet of three 5 pin 5 amp shuttered socket outlet with 1 no. 5 amp switch. 12 NOS

f Blank plate for modular plate type switch boards wherever required. 5 NOS

6.2 Supply all materials, receiving, storing, handling, fixing, laying, wiring and

testing for power outlets using ISI marked (IS:694) single core, flexible,

flame retardant low smoke (FRLS), stranded copper conductors PVC

insulated 1100 Volt grade wiring in concealed/ exposed system using 20

mm/25 mm ISI marked heavy duty PVC conduit (IS:IS:9537-III & 3419)

including all conduit accessories, such as bends, tees, draw boxes, minimum

1.2 mm thick G.I. or MS point control boxes with zinc plating and yellow

passivation, together with wiring accessories such as white modular plate

type switches and sockets, cover plate, grid plate etc. including submain

wiring from DB to outlet with Cu earth continuity wire, conduit being laid in

recess (concealed) either in ceiling slab / wall, chasing on surface or under

false ceiling including required clamping arrangement and required length of

PVC flexible conduit or in wooden partitions etc. complete as required at site.

aOne 6 pin 15 amp shuttered socket outlet with 15 amp switch by 2x4 + 2.5 sq

mm copper wires. (Primary Power)

10 NOS

b

32 amp TPN industrial metal clad outlet in MS box with 32 amp C series FP

MCB and metal plug top instead of modular switch & sockets by 4x6 + 4 sq

mm copper wires.

1 NOS

c

20 amp SPN industrial metal clad outlet in MS box with 20 amp C series DP

MCB and metal plug top instead of modular switch & sockets by 2x4 + 2.5 sq

mm copper wires.

1 NOS



7.0 DISTRIBUTION BOARDS AND CIRCUIT BREAKERS

7.1 Supplying, receiving, storing, handling, erecting, testing and commissioning of

Single Pole and Neutral MCB distribution board, IP 43 protection, sheet

steel, double door, powder coated, 240 volts, in recess/surface, complete with

100 amp tinned copper bus bar, neutral bar, earth bar, top and bottom

removable gland plates with knockouts, interconnections, earthing etc. as

required. DB's shall be original factory fabricated of approved make.

Make : Legrand-Lexic / L&T / Hager / ABB / Schneider-Acti 9 / Havells

a 16 WAYS SPN 1 NOS

b 12 WAYS SPN 2 NOS

7.2 Supplying, fixing, connecting, testing and commissioning of following rating,

ISI marked (IS 8828) 240 / 415 volts, 10 KA, Miniature Circuit Breaker

(MCB) of single / double / three / four poles in the existing MCB DB or in

existing MS enclosure complete in all respects.

Make : Legrand-Lexic / L&T / Hager / ABB / Schneider-Acti 9/ Havells

a 6 to 32 Amp. SP MCB 30 NOS

b 6 to 32 Amp. DP MCB 10 NOS

c 40 Amp. DP MCB 2 NOS

d 50/63 Amp. DP MCB 2 NOS

e 32 Amp. FP MCB 1 NOS

f 40 Amp. FP MCB 2 NOS

g 50/63 Amp. FP MCB 1 NOS

8.0 TELEPHONE, DATA & TV

8.1 Supply and fixing of ISI marked (IS:9537-part 3 & 3419) 2 mm thick heavy

duty PVC conduit in concealed / exposed system in wall, ceiling or on floor

including cutting of brick work, laying of conduit and fixing it with M.S.

hooks and then plastering with cement, sand motar finished to the level,

providing necessary sockets, bends, tees, junction boxes of required sizes etc

as directed at site by the engineer-in-charge with supply of all material labour

and T & P required for proper completion of work. conduit being laid either in

concealed system in ceiling slab or wall or on surface or under the frame of

false ceiling including flexible conduits or through wooden partition including

clamping arrangements as required.

25 mm dia. conduit 150 M

8.2 Providing & Fixing of modular plate type telephone outlet on 1.0 mm tk G. I.

Switch control boxes, with cover plate, grid plate, screws, etc with

connections as required.

a Single RJ 45 Tel. Jack 8 set

b Twin RJ 45 Tel. Jack 3 set



8.3 Providing, fixing, connecting & testing of Krone box (Telephone Tag Block)

in a thermoplastic, IP 65 (weather proof) enclosure, internally embedded

gasket, anti corrosive, insulated and shock proof with provision for cable

through IP 65 glands complete in all respects. (Make : Hensel)a Supply and fixing of cat6 patch cord for voices uses 10 nos.

b Supply and fixing of 100 MDF Box with krone module 1 nos.

8.4 Providing, drawing, connecting and testing of telephone wire of cat6 cable in

MS/PVC conduit from telephone outlet box to the junction box/tag block as

required.

50 M

8.5 Providing, drawing, connecting and testing of telephone wire 0.5 sqmm

tinned annealed high conductivity copper conductor with high density

Polyethylene insulation, paired, polyster taped and FR PVC sheathed in

existing MS/PVC conduit from telephone outlet box to the junction box/tag

block as required.

2 pair 0.51 sq. mm. 250 M

8.6 Providing & Fixing of modular plate type white RJ 45 CAT 6 Data outlet /

information outlets ETL verified to meet or exceed TIA / EIA category 6

requirements, universal wiring label permitting to either T568A or T568B, UL listed,

for computer networking complete in all respect with cover plate, grid plate, screws,

MS box, etc with connections as required.

1 nos. RJ 45 Data Outlet 15 nos.

8.7 Providing, drawing, connecting and testing of enhanced category 4 pair LAN

(local area network) cable, UL and CUL listed, in existing MS/PVC conduit

or floor raceways including connections etc as required complete in all

respects. (Make : AMP / Systemax)

CAT-6 network cable 450 M

8.8 Providing & Fixing of modular plate type white coaxial television outlet

complete in all respect with cover plate, grid plate, screws, 1.0 mm tk G. I.

Switch control boxes, etc with connections as required.

1 nos.

8.9 Providing, drawing, connecting and testing of Television cable, Electrolytic

grade solid annealed high conductivity copper conductor, gas injected physical

polyethylene foam insulated, wrapped with aluminium tape and aluminium

alloy wire braided, jelly flooded and PVC jacketing in black colour

(Compatible to DTH TV signal), in existing MS/PVC conduit from television

outlet box to the junction box / splitter / subscriber or dwelling unit / Dish

antenna as required. (Make : Finolex / RR / Polycab / Skytone)

RG - 6 50 M

9.0 RACEWAY: including cutting of the floor and fixing as and wherever

required.

9.1 Supply, fixing, laying, hanging and embedding in wall of Aluminium raceway

top cover openable with counter sunk screws, painted stove enamelled

approved colour the cover should be tight on channel with counter sunk

screws to avoid entry of vermins. It should be tightened in such a way to avoid

ingress of mosquito, moisture and dust. The Aluminium raceway / wire ways

shall be complete with all accessories required such as bends, tees, reducers,

offsets, cover, junction boxes etc. as reqd.

a Supply, laying, testing and commissioning of 100 MM wide x 50mm

raceway with all requirements.

35 RM

b Supply, laying, testing and commissioning of 150 MM wide x 50mm

raceway with all requirements.

25 RM



10.0 SUBMAINS/MV CABLES

10.1 Providing and laying of PVC insulated copper conductor/Cable 1100 volt

grade stranded flexible FRLS Wire in required size of pvc heavy duty conduit.

a 2 x 10 + 1 x 4 sq.mm PVC insulated stranded flexible copper wires in pvc

conduit

15 rmt.

b 2 x 16 + 1 x 6 sq.mm PVC insulated stranded flexible copper wires in pvc

conduit

10 rmt.

c 4 x 10 + 2 x 4 sq.mm PVC insulated stranded flexible copper wires in pvc

conduit

25 rmt.

d 4 x 16 + 2 x 6 sq.mm PVC insulated stranded flexible copper wires in pvc

conduit

20 rmt.

III

1 Providing and fixing of interconnected refrigerant piping circuit of required

sizes with imported copper tubes duly insulated with close cell elastrometric

foam, complete with supports and properly clamped along with Interconnected

electrical wiring between room and condensing units including power cables

from power supply switch/socket to condensing unit, conduit fittings etc. as

required complete as per design and specifications of the manufacturer and

approval/instruction of the consultant. items include chissiling of walls and

finishig the same upto complete satisfaction of the architect.

100 rmt.

2 Providing and fixing of PVC Drain piping-20 kg density with fittings and

valves, insulated with close cell Elastrometric foam complete as per design

and specifications of the manufacturer and approval/instruction of the

consultant. (For 4 No. AC's unit) items include chissiling of walls and

finishig the same upto complete satisfaction of the architect.

(a) 25MM

105 rmt.

3 Commissioning and installation of Air cooled HI-WALL MOUNTED SPLIT

AC's (supplied by the bank) complete with outdoor unit, cordless remote

control, safety feature as per the design and specifications and

approval/instruction of the consultant.

Nominal CAPACITY– 1.0 TR. 3 no.



4 Providing ,Fixing & Installation of MS Cages for split ac condesing unit to be

hanged outside, or kept on terrace with MS base frame, the cages may be

grouted in the ceiling or wall as the case may be.The cages to have shuttered

opening which are lockable all the cage to be painted in 2 coats of synthetic

enamel after preparing base with primer coating.

8 no.

5 Providing and fixing triple step 5 to 4 k.v.a automatic voltage stabilizer wall

mounted of bluebird/ logictech/ micel make.

8 no.

6 Providing fixing 3c x4sqmm circular wire connection complete,connection 250 rmt.

Total Amount for HVAC Works to be carried over the summary

DISCOUNT (IF ANY)

FINAL AMOUNT (INCLUDING GST)

TOTAL AMOUNT (Interior furnishing+Electrical works+AC Work)

HVAC WORKS (Make : Mitsubishi / Diakin / Voltas / O General / Carrier) of Minimum 5 star rating by BEE (HWS)

Total Amount for Electrical Works to be carried over the summary


TENDER DOCUMENT · 2019-06-01 · at STC Building, Rohini. Contractor’s Signature SECTION –...

Documents

Transcript of TENDER DOCUMENT · 2019-06-01 · at STC Building, Rohini. Contractor’s Signature SECTION –...