Oklahoma Air National Guard – Tulsa, OK is seeking the replacement of the Building 316 Chiller and HVAC system at the Tulsa Air National Guard Base. This solicitation B316Chiller is100% set aside for small business IAW DFARS 219.502-2(a)(i). If there is an after hour point of contact, please include in quote. The Disclosure of Magnitude for this project is betw een $500,000 and $1,000,000 IAW FAR 36.204(e).

Funds are not presently available for this contract. Currently, the Government anticipates funds w illbecome available prior to but no later than midnight 30 Sep 2017. This action has been identif ied on the NationalGuard priority list for aw ard if funds become available and the prices received are w ithin an aw ardable range.

Aw ard w ill be made to the responsible bidder w hose bid conforms to the invitation for bids and is most advantageous to the Government considering only price and price related factors.

X

DAVID A. HUGUELEY (918) 833-7118

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

10-Aug-2017

(RFP)

(IFB)

CALL:

B316 HVAC Renovation

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________150 calendar days after receiving

aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________ copies to perform the w ork required are due at the place specified in Item 8 by ___________

local time ______________12 Sep 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

138 CONTRACTING FLIGHT (MSG/MSC)9100 E 46TH ST NORTH: ATTN: SMSGT AMANDA LOTULSA OK 74115-1632

W912L6

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

.)

12B. CALENDAR DAYS

10

09:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

XHZG201501230

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 918-833-7305 TEL: FAX:

W912L6-17-B-0012 99

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer isaccepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGNOFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-

to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and

on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is

contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses,

representations, certif ications, and specif ications or incorporated by ref er-

ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

3

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT 0001 1 Job B316 Renovation

FFP Contractor shall provide all plant, labor, equipment, appliances, materials, expertise and supervision necessary for remodel of the Building 316 HVAC Renovation. Project XHZG201501230 per plans and specifications as proposed to include wage determination. FOB: Destination SIGNAL CODE: A

NET AMT

DELIVERY INFORMATION CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC 0001 160 dys. ADC 1 138 CIVIL ENGINEERING

KURT STEPHENS 9100 E 46TH ST NORTH TULSA OK 74115-1000 918-833-7282 FOB: Destination

F9L3CE

CLAUSES INCORPORATED BY REFERENCE 52.203-2 Certificate Of Independent Price Determination APR 1985 52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions SEP 2007

52.203-18 Prohibition on Contracting With Entities That Require Certain Internal Confidentiality Agreements or Statements--Representation

JAN 2017

52.204-7 System for Award Management OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016

4

52.204-22 Alternative Line Item Proposal JAN 2017 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.219-2 Equal Low Bids OCT 1995 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work MAY 2014

52.222-38 Compliance With Veterans' Employment Reporting Requirements

FEB 2016

52.222-58 Subcontractor Responsibility Matters Regarding Compliance with Labor Laws (Executive Order 13673)

DEC 2016

52.225-10 Notice of Buy American Requirement--Construction Materials

MAY 2014

52.225-12 Notice of Buy American Requirement - Construction Materials Under Trade Agreements

MAY 2014

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls OCT 2016

252.222-7007 Representation Regarding Combating Trafficking in Persons JAN 2015 252.225-7031 Secondary Arab Boycott Of Israel JUN 2005 252.246-7005 Notice of Warranty Tracking of Serialized Items MAR 2016 CLAUSES INCORPORATED BY FULL TEXT 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2017) (a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238220. (2) The small business size standard is $15,000,000. (3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees. (b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies. (2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

5

( ) Paragraph (d) applies. ( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding elinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

6

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

7

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

8

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. ------------------------------------------------------------------------ FAR Clause Title Date Change ------------------------------------------------------------------------ ------ ---------- ------ ------ ------------------------------------------------------------------------

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision) 52.204-17 OWNERSHIP OR CONTROL OF OFFEROR (JUL 2016)

9

(a) Definitions. As used in this provision-- Commercial and Government Entity (CAGE) code means— (1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity; or (2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code. Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner. Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. (b) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (c) and if applicable, paragraph (d) of this provision for each participant in the joint venture. (c) If the Offeror indicates ``has'' in paragraph (b) of this provision, enter the following information: Immediate owner CAGE code: ___ Immediate owner legal name: ___ (Do not use a ``doing business as'' name) Is the immediate owner owned or controlled by another entity?: [ ___ ] Yes or [ ___ ] No. (d) If the Offeror indicates ``yes'' in paragraph (c) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information: Highest-level owner CAGE code: ___ Highest-level owner legal name: ___ (Do not use a ``doing business as'' name) (End of provision) 52.204-20 Predecessor of Offeror (JUL 2016) (a) Definitions. As used in this provision--

10

Commercial and Government Entity (CAGE) code means-- (1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity; or (2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code. Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor. Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances. (b) The Offeror represents that it [____] is or [____] is not a successor to a predecessor that held a Federal contract or grant within the last three years. (c) If the Offeror has indicated “is” in paragraph (b) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order): Predecessor CAGE code: ____ (or mark “Unknown”). Predecessor legal name: ____. (Do not use a “doing business as” name). (End of provision) 52.209-2 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS--REPRESENTATION (NOV 2015) (a) Definitions. Inverted domestic corporation and subsidiary have the meaning given in the clause of this contract entitled Prohibition on Contracting with Inverted Domestic Corporations (52.209-10). (b) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4. (c) Representation. The Offeror represents that-- (1) It [ ___ ] is, [ ___ ] is not an inverted domestic corporation; and (2) It [ ___ ] is, [ ___ ] is not a subsidiary of an inverted domestic corporation. (End of provision)

11

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015) (a)(1) The Offeror certifies, to the best of its knowledge and belief, that- (i) The Offeror and/or any of its Principals- (A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency; (B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and (C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.; and (D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied. (1) Federal taxes are considered delinquent if both of the following criteria apply: (i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted. (ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded. (2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment. (iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

12

(ii) The Offeror has ( ) has not ( ), within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency. (2) Principal, for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions). (b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances. (c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible. (d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings. (e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default. (End of provision) 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013) (a) Definitions. As used in this provision-- Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables. Federal contracts and grants with total value greater than $10,000,000 means-- (1) The total value of all current, active contracts and grants, including all priced options; and (2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules). Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions). (b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

13

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information: (1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions: (i) In a criminal proceeding, a conviction. (ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more. (iii) In an administrative proceeding, a finding of fault and liability that results in-- (A) The payment of a monetary fine or penalty of $5,000 or more; or (B) The payment of a reimbursement, restitution, or damages in excess of $100,000. (iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision. (2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence. (d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7). (End of provision) 52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016) (a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that-- (1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or (2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government. (b) The Offeror represents that--

14

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and (2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months. (End of provision) 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017) ALTERNATE I (OCT 2014) The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal . If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. “Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. “Civil judgment” means-- (1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction. (2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. “DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

15

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are-- (1) Department of Labor Wage and Hour Division (WHD) for-- (i) The Fair Labor Standards Act; (ii) The Migrant and Seasonal Agricultural Worker Protection Act; (iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act; (iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act; (v) The Family and Medical Leave Act; and (vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors); (2) Department of Labor Occupational Safety and Health Administration (OSHA) for-- (i) The Occupational Safety and Health Act of 1970; and (ii) OSHA-approved State Plans; (3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for-- (i) Section 503 of the Rehabilitation Act of 1973; (ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and (iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity); (4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and (5) Equal Employment Opportunity Commission (EEOC) for-- (i) Title VII of the Civil Rights Act of 1964; (ii) The Americans with Disabilities Act of 1990; (iii) The Age Discrimination in Employment Act of 1967; and (iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

16

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters. “Labor laws” means the following labor laws and E.O.s: (1) The Fair Labor Standards Act. (2) The Occupational Safety and Health Act (OSHA) of 1970. (3) The Migrant and Seasonal Agricultural Worker Protection Act. (4) The National Labor Relations Act. (5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act. (6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act. (7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity). (8) Section 503 of the Rehabilitation Act of 1973. (9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974. (10) The Family and Medical Leave Act. (11) Title VII of the Civil Rights Act of 1964. (12) The Americans with Disabilities Act of 1990. (13) The Age Discrimination in Employment Act of 1967. (14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors). (15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html). “Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

17

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

18

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

19

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)

(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAMwebsite.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this

offer by reference (see FAR 4.1201), except for paragraphs ___ . [Offeror to identify the applicable paragraphs

at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small

business concern.

20

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business

concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its

offer that it [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business

concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not, a small

disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business

concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not a women-

owned small business concern.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required

documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the

representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible

under the WOSB Program and other small businesses that are participating in the joint venture: ___ .] Each

WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern, has provided all the required documents to the WOSB

Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the

representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that

are participating in the joint venture: ___ .] Each EDWOSB concern participating in the joint venture shall submit

a separate signed copy of the EDWOSB representation.

21

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this

provision.] The offeror represents that it [ ___ ] is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

___

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the

List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126,

and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small

business concerns participating in the HUBZone joint venture: ___ .] Each HUBZone small business concern

participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(11) (Complete if the offeror has represented itself as disadvantaged in paragraph (c)(4) of this provision.)

[The offeror shall check the category in which its ownership falls]:

___ Black American.

___ Hispanic American.

___ Native American (American Indians, Eskimos, Aleuts, or Native Hawaiians).

___ Asian-Pacific American (persons with origins from Burma, Thailand, Malaysia, Indonesia, Singapore, Brunei, Japan, China, Taiwan, Laos, Cambodia (Kampuchea), Vietnam, Korea, The Philippines, Republic of Palau, Republic of the Marshall Islands, Federated States of Micronesia, the Commonwealth of the Northern Mariana Islands, Guam, Samoa, Macao, Hong Kong, Fiji, Tonga, Kiribati, Tuvalu, or Nauru).

___ Subcontinent Asian (Asian-Indian) American (persons with origins from India, Pakistan, Bangladesh, Sri Lanka, Bhutan, the Maldives Islands, or Nepal).

___ Individual/concern, other than one of the preceding.

(d) Representations required to implement provisions of Executive Order 11246 --

(1) Previous contracts and compliance. The offeror represents that --

22

(i) It [ ___ ] has, [ ___ ] has not, participated in a previous contract or subcontract subject to the Equal

Opportunity clause of this solicitation; and

(ii) It [ ___ ] has, [ ___ ] has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that --

(i) It [ ___ ] has developed and has on file, [ ___ ] has not developed and does not have on file, at each

establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR parts 60-1 and 60-2), or

(ii) It [ ___ ] has not previously had contracts subject to the written affirmative action programs requirement of the

rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American – Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Supplies.”

(2) Foreign End Products:

LINE ITEM NO. COUNTRY OF ORIGIN

___ ___

___ ___

___ ___

[List as necessary]

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

23

(g)

(1) Buy American -- Free Trade Agreements -- Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American -- Free Trade Agreements -- Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,” “Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American--Free Trade Agreements--Israeli Trade Act.”

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

LINE ITEM NO. COUNTRY OF ORIGIN

___ ___

___ ___

___ ___

[List as necessary]

(iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) or this provision) as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act.” The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.”

Other Foreign End Products:

LINE ITEM NO. COUNTRY OF ORIGIN

___ ___

___ ___

___ ___

[List as necessary]

(iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(2) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

24

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Canadian End Products:

Line Item No.:

___

[List as necessary]

(3) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled “Buy American--Free Trade Agreements--Israeli Trade Act'':

Canadian or Israeli End Products:

Line Item No.: Country of Origin:

___ ___

___ ___

___ ___

[List as necessary]

(4) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

Line Item No.: Country of Origin:

___ ___

___ ___

___ ___

[List as necessary]

(5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.)

25

(i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product as defined in the clause of this solicitation entitled “Trade Agreements.”

(ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products.

Other End Products

Line Item No.: Country of Origin:

___ ___

___ ___

___ ___

[List as necessary]

(iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation.

(h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals--

(1) [ ___ ] Are, [ ___ ] are not presently debarred, suspended, proposed for debarment, or declared ineligible for

the award of contracts by any Federal agency;

(2) [ ___ ] Have, [ ___ ] have not, within a three-year period preceding this offer, been convicted of or had a

civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; and

(3) [ ___ ] Are, [ ___ ] are not presently indicted for, or otherwise criminally or civilly charged by a Government

entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and

(4) [ ___ ] Have, [ ___ ] have not, within a three-year period preceding this offer, been notified of any

delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(i) Taxes are considered delinquent if both of the following criteria apply:

(A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

26

(B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(ii) Examples.

(A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appear rights.

(B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals Contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(C) The taxpayer has entered into an installment agreement pursuant to I.R.C. §6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(D) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. §362 (the Bankruptcy Code).

(i) Certification Regarding Knowledge of Child Labor for Listed End Products (Executive Order 13126). [The Contracting Officer must list in paragraph (i)(1) any end products being acquired under this solicitation that are included in the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor, unless excluded at 22.1503(b).]

(1) Listed End Product

Listed End Product: Listed Countries of Origin:

___ ___

___ ___

___ ___

(2) Certification. [If the Contracting Officer has identified end products and countries of origin in paragraph (i)(1) of this provision, then the offeror must certify to either (i)(2)(i) or (i)(2)(ii) by checking the appropriate block.]

[ ___ ] (i) The offeror will not supply any end product listed in paragraph (i)(1) of this provision that was mined,

produced, or manufactured in the corresponding country as listed for that product.

[ ___ ] (ii) The offeror may supply an end product listed in paragraph (i)(1) of this provision that was mined,

produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that is has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture any such end product furnished under this contract. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor.

27

(j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly—

(1) [ ___ ] In the United States (Check this box if the total anticipated price of offered end products manufactured

in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or

(2) [ ___ ] Outside the United States.

(k) Certificates regarding exemptions from the application of the Service Contract Labor Standards. (Certification by the offeror as to its compliance with respect to the contract also constitutes its certification as to compliance by its subcontractor if it subcontracts out the exempt services.) [The contracting officer is to check a box to indicate if paragraph (k)(1) or (k)(2) applies.]

(1) [ ___ ] Maintenance, calibration, or repair of certain equipment as described in FAR 22.1003-4(c)(1). The

offeror [ ___ ] does [ ___ ] does not certify that—

(i) The items of equipment to be serviced under this contract are used regularly for other than Governmental purposes and are sold or traded by the offeror (or subcontractor in the case of an exempt subcontract) in substantial quantities to the general public in the course of normal business operations;

(ii) The services will be furnished at prices which are, or are based on, established catalog or market prices (see FAR 22.1003-4(c)(2)(ii)) for the maintenance, calibration, or repair of such equipment; and

(iii) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract will be the same as that used for these employees and equivalent employees servicing the same equipment of commercial customers.

(2) [ ___ ] Certain services as described in FAR 22.1003-4(d)(1). The offeror [ ___ ] does [ ___ ] does not

certify that—

(i) The services under the contract are offered and sold regularly to non-Governmental customers, and are provided by the offeror (or subcontractor in the case of an exempt subcontract) to the general public in substantial quantities in the course of normal business operations;

(ii) The contract services will be furnished at prices that are, or are based on, established catalog or market prices (see FAR 22.1003-4(d)(2)(iii));

(iii) Each service employee who will perform the services under the contract will spend only a small portion of his or her time (a monthly average of less than 20 percent of the available hours on an annualized basis, or less than 20 percent of available hours during the contract period if the contract period is less than a month) servicing the Government contract; and

(iv) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract is the same as that used for these employees and equivalent employees servicing commercial customers.

(3) If paragraph (k)(1) or (k)(2) of this clause applies—

28

(i) If the offeror does not certify to the conditions in paragraph (k)(1) or (k)(2) and the Contracting Officer did not attach a Service Contract Labor Standards wage determination to the solicitation, the offeror shall notify the Contracting Officer as soon as possible; and

(ii) The Contracting Officer may not make an award to the offeror if the offeror fails to execute the certification in paragraph (k)(1) or (k)(2) of this clause or to contact the Contracting Officer as required in paragraph (k)(3)(i) of this clause.

(l) Taxpayer identification number (TIN) (26 U.S.C. 6109, 31 U.S.C. 7701). (Not applicable if the offeror is required to provide this information to the SAM database to be eligible for award.)

(1) All offerors must submit the information required in paragraphs (l)(3) through (l)(5) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the Internal Revenue Service (IRS).

(2) The TIN may be used by the government to collect and report on any delinquent amounts arising out of the offeror’s relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror’s TIN.

(3) Taxpayer Identification Number (TIN).

[ ___ ] TIN: ___ .

[ ___ ] TIN has been applied for.

[ ___ ] TIN is not required because:

[ ___ ] Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income

effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States;

[ ___ ] Offeror is an agency or instrumentality of a foreign government;

[ ___ ] Offeror is an agency or instrumentality of the Federal Government;

(4) Type of organization.

[ ___ ] Sole proprietorship;

[ ___ ] Partnership;

[ ___ ] Corporate entity (not tax-exempt);

29

[ ___ ] Corporate entity (tax-exempt);

[ ___ ] Government entity (Federal, State, or local);

[ ___ ] Foreign government;

[ ___ ] International organization per 26 CFR 1.6049-4;

[ ___ ] Other ___ .

(5) Common parent.

[ ___ ] Offeror is not owned or controlled by a common parent:

[ ___ ] Name and TIN of common parent:

Name ___

TIN ___

(m) Restricted business operations in Sudan. By submission of its offer, the offeror certifies that the offeror does not conduct any restricted business operations in Sudan.

(n) Prohibition on Contracting with Inverted Domestic Corporations—

(1) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4.

(2) Representation. The Offeror represents that-- (i) It [ ___ ] is, [ ___ ] is not an inverted domestic corporation; and (ii) It [ ___ ] is, [ ___ ] is not a subsidiary of an inverted domestic corporation.

(o) Prohibition on contracting with entities engaging in certain activities or transactions relating to Iran.

(1) The offeror shall email questions concerning sensitive technology to the Department of State at CISADA106@state.gov.

(2) Representation and Certification. Unless a waiver is granted or an exception applies as provided in paragraph (o)(3) of this provision, by submission of its offer, the offeror—

30

(i) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran;

(ii) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act; and

(iii) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $3,500 with Iran’s Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50(U.S.C. 1701 et seq.) (see OFAC’s Specially Designated Nationals and Blocked Persons List at http://www.treasury.gov/ofac/downloads/t11sdn.pdf).

(3) The representation and certification requirements of paragraph (o)(2) of this provision do not apply if—

(i) This solicitation includes a trade agreements certification (e.g., 52.212-3(g) or a comparable agency provision); and

(ii) The offeror has certified that all the offered products to be supplied are designated country end products.

(p) Ownership or Control of Offeror. (Applies in all solicitations when there is a requirement to be registered in SAM or a requirement to have a unique entity identifier in the solicitation. (1) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (2) and if applicable, paragraph (3) of this provision for each participant in the joint venture. (2) If the Offeror indicates “has” in paragraph (p)(1) of this provision, enter the following information:

Immediate owner CAGE code: ____________________. Immediate owner legal name: _____________________. (Do not use a “doing business as” name) Is the immediate owner owned or controlled by another entity: □ Yes or □ No.

(3) If the Offeror indicates “yes” in paragraph (p)(2) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information:

Highest-level owner CAGE code: __________________. Highest-level owner legal name: ___________________. (Do not use a “doing business as” name)

(q) Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. (1) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, The Government will not enter into a contract with any corporation that— (i) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

31

(ii) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government. (2) The Offeror represents that— (i) It is □ is not □ a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and (ii) It is □ is not □ a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months. (r) Predecessor of Offeror. (Applies in all solicitations that include the provision at 52.204-16, Commercial and Government Entity Code Reporting.) (1) The Offeror represents that it [ ___ ] is or [ ___ ] is not a successor to a predecessor that held a Federal contract or grant within the last three years. (2) If the Offeror has indicated ``is'' in paragraph (r)(1) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order): Predecessor CAGE code: ____ (or mark ``Unknown''). Predecessor legal name: ____. (Do not use a ``doing business as'' name). (s) Representation regarding compliance with labor laws (Executive Order 13673). If the offeror is a joint venture that is not itself a separate legal entity, each concern participating in the joint venture shall separately comply with the requirements of this provision. (1)(i) For solicitations issued on or after October 25, 2016 through April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $50 million. (ii) For solicitations issued after April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $500,000. (2) If the Offeror checked ``does'' in paragraph (s)(1)(i) or (ii) of this provision, the Offeror represents to the best of the Offeror's knowledge and belief [Offeror to check appropriate block]: [ ](i) There has been no administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the offeror (see definitions in paragraph (a) of this section) during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter; or [ ](ii) There has been an administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter. (3)(i) If the box at paragraph (s)(2)(ii) of this provision is checked and theContracting Officer has initiated a responsibility determination and has requested additional information, the Offeror shall provide--

32

(A) The following information for each disclosed labor law decision in the System for Award Management (SAM) at www.sam.gov, unless the information is already current, accurate, and complete in SAM. This information will be publicly available in the Federal Awardee Performance and Integrity Information System (FAPIIS): (1) The labor law violated. (2) The case number, inspection number, charge number, docket number, or other unique identification number. (3) The date rendered. (4) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision; (B) The administrative merits determination, arbitral award or decision, or civil judgment document, to the Contracting Officer, if the Contracting Officer requires it; (C) In SAM, such additional information as the Offeror deems necessary to demonstrate its responsibility, including mitigating factors and remedial measures such as offeror actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws. Offerors may provide explanatory text and upload documents. This information will not be made public unless the contractor determines that it wants the information to be made public; and (D) The information in paragraphs (s)(3)(i)(A) and (s)(3)(i)(C) of this provision to the Contracting Officer, if the Offeror meets an exception to SAM registration (see FAR 4.1102(a)). (ii)(A) The Contracting Officer will consider all information provided under (s)(3)(i) of this provision as part of making a responsibility determination. (B) A representation that any labor law decision(s) were rendered against the Offeror will not necessarily result in withholding of an award under this solicitation. Failure of the Offeror to furnish a representation or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible. (C) The representation in paragraph (s)(2) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous representation, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation in accordance with the procedures set forth in FAR 12.403. (4) The Offeror shall provide immediate written notice to the Contracting Officer if at any time prior to contract award the Offeror learns that its representation at paragraph (s)(2) of this provision is no longer accurate. (5) The representation in paragraph (s)(2) of this provision will be public information in the Federal Awardee Performance and Integrity Information System (FAPIIS). Note to paragraph (s): By a court order issued on October 24, 2016, this paragraph (s) is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (t) Public Disclosure of Greenhouse Gas Emissions and Reduction Goals. Applies in all solicitations that require offerors to register in SAM (52.212-1(k)). (1) This representation shall be completed if the Offeror received $7.5 million or more in contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year.

33

(2) Representation. [Offeror to check applicable block(s) in paragraph (t)(2)(i) and (ii)]. (i) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose greenhouse gas emissions, i.e., makes available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard. (ii) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly accessible Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage. (iii) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program. (3) If the Offeror checked ``does'' in paragraphs (t)(2)(i) or (t)(2)(ii) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported: ___ . (u)(1) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with an entity that requires employees or subcontractors of such entity seeking to report waste, fraud, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information. (2) The prohibition in paragraph (u)(1) of this provision does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information. (3) Representation. By submission of its offer, the Offeror represents that it will not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General). (End of provision)

CLAUSES INCORPORATED BY FULL TEXT 52.216-1 TYPE OF CONTRACT (APR 1984) The Government contemplates award of a firm fixed price contract resulting from this solicitation.

34

(End of provision) CLAUSES INCORPORATED BY FULL TEXT 52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (OCT 2014) - ALTERNATE I (SEPT 2015) (a)(1) The North American Industry Classification System (NAICS) code for this acquisition is ___ (insert NAICS code). (2) The small business size standard is ___ (insert size standard). (3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees. (b) Representations. (1) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a small business concern. (2) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents, for general statistical purposes, that it ( ___ ) is, ( ___ ) is not a small disadvantaged business concern as defined in 13 CFR 124.1002. (3) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a women-owned small business concern. (4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (b)(3) of this provision.] The offeror represents as part of its offer that-- (i) It ( ___ ) is, ( ___ ) is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (b)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ---- ___ ------.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation. (5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB Program in (b)(4) of this provision.] The offeror represents as part of its offer that-- (i) It ( ___ ) is, ( ___ ) is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (b)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that

35

are participating in the joint venture: ----- ___ -----.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation. (6) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a veteran-owned small business concern. (7) (Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (b)(6) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a service-disabled veteran-owned small business concern. (8) [Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.] The offeror represents, as part of its offer, that-- (i) It ( ___ ) is, ( ___ ) is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material change in ownership and control, principal office, or HUBZone employee percentage has occurred since it was certified by the Small Business Administration in accordance with 13 CFR part 126; and (ii) It ( ___ ) is, ( ___ ) is not a joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (b)(8)(i) of this provision is accurate for the HUBZone small business concern or concerns that are participating in the joint venture. (The offeror shall enter the name or names of the HUBZone small business concern or concerns that are participating in the joint venture: ___ .) Each HUBZone small business concern participating in the joint venture shall submit a separate signed copy of the HUBZone representation. (9) (Complete if offeror represented itself as disadvantaged in paragraph (c)(2) of this provision.) The offeror shall check the category in which its ownership falls: ___ Black American. ___ Hispanic American. ___ Native American (American Indians, Eskimos, Aleuts, or Native Hawaiians). ___ Asian-Pacific American (persons with origins from Burma, Thailand, Malaysia, Indonesia, Singapore, Brunei, Japan, China, Taiwan, Laos, Cambodia (Kampuchea), Vietnam, Korea, The Philippines, Republic of Palau, Republic of the Marshall Islands, Federated States of Micronesia, the Commonwealth of the Northern Mariana Islands, Guam, Samoa, Macao, Hong Kong, Fiji, Tonga, Kiribati, Tuvalu, or Nauru). ___ Subcontinent Asian (Asian-Indian) American (persons with origins from India, Pakistan, Bangladesh, Sri Lanka, Bhutan, the Maldives Islands, or Nepal). ___ Individual/concern, other than one of the preceding. (c) Definitions. As used in this provision-- Service-disabled veteran-owned small business concern-- (1) Means a small business concern-- (i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and (ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

36

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16). "Small business concern," means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and the size standard in paragraph (a) of this provision. Veteran-owned small business concern means a small business concern-- (1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and (2) The management and daily business operations of which are controlled by one or more veterans. "Women-owned small business concern," means a small business concern -- (1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; or (2) Whose management and daily business operations are controlled by one or more women. (d) Notice. (1) If this solicitation is for supplies and has been set aside, in whole or in part, for small business concerns, then the clause in this solicitation providing notice of the set-aside contains restrictions on the source of the end items to be furnished. (2) Under 15 U.S.C. 645(d), any person who misrepresents a firm's status as a small, HUBZone small, small disadvantaged, or women-owned small business concern in order to obtain a contract to be awarded under the preference programs established pursuant to section 8(a), 8(d), 9, or 15 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall-- (i) Be punished by imposition of fine, imprisonment, or both; (ii) Be subject to administrative remedies, including suspension and debarment; and (iii) Be ineligible for participation in programs conducted under the authority of the Act. (End of provision) CLAUSES INCORPORATED BY FULL TEXT 52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999) The offeror represents that -- (a) ( ) It has, ( ) has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; (b) ( ) It has, ( ) has not, filed all required compliance reports; and

37

(c) Representations indicating submission of required compliance reports, signed by proposed subcontractors, will be obtained before subcontract awards. (End of provision) CLAUSES INCORPORATED BY FULL TEXT 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999) (a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation. (b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

10.2% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office. (c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed. (d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the -- (1) Name, address, and telephone number of the subcontractor; (2) Employer's identification number of the subcontractor; (3) Estimated dollar amount of the subcontract; (4) Estimated starting and completion dates of the subcontract; and (5) Geographical area in which the subcontract is to be performed.

38

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Tulsa City, Tulsa County, Oklahoma (End of provision) 52.222-57 REPRESENTATION REGARDING COMPLIANCE WITH LABOR LAWS (EXECUTIVE ORDER 13673) (DEC 2016) (a)(1) Definitions. Administrative merits determination, arbitral award or decision, civil judgment, DOL Guidance, enforcement agency, labor compliance agreement, labor laws, and labor law decision as used in this provision have the meaning given in the clause in this solicitation entitled 52.222-59, Compliance with Labor Laws (Executive Order 13673). (2) Joint ventures. If the offeror is a joint venture that is not itself a separate legal entity, each concern participating in the joint venture shall separately comply with the requirements of this provision. (b)(1) For solicitations issued on or after October 25, 2016 through April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $50 million. (2) For solicitations issued after April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $500,000. (c) If the Offeror checked ``does'' in paragraph (b)(1) or (2) of this provision, the Offeror represents to the best of the Offeror's knowledge and belief [Offeror to check appropriate block]: [ ___ ](1) There has been no administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter; or [ ___ ](2) There has been an administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter. (d)(1) If the box at paragraph (c)(2) of this provision is checked and the Contracting Officer has initiated a responsibility determination and has requested additional information, the Offeror shall provide-- (i) For each disclosed labor law decision in the System for Award Management (SAM) at www.sam.gov, the following, unless the information is already current, accurate, and complete in SAM. This information will be publicly available in the Federal Awardee Performance and Integrity Information System (FAPIIS): (A) The labor law violated. (B) The case number, inspection number, charge number, docket number, or other unique identification number. (C) The date rendered. (D) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision; (ii) The administrative merits determination, arbitral award or decision, or civil judgment document to the Contracting Officer, if the Contracting Officer requires it;

39

(iii) In SAM, such additional information as the Offeror deems necessary to demonstrate its responsibility, including mitigating factors and remedial measures such as Offeror actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws. Offerors may provide explanatory text and upload documents. This information will not be made public unless the contractor determines that it wants the information to be made public; and (iv) The information in paragraphs (d)(1)(i) and (d)(1)(iii) of this provision to the Contracting Officer, if the Offeror meets an exception to SAM registration (see 4.1102(a)). (2)(i) The Contracting Officer will consider all information provided under (d)(1) of this provision as part of making a responsibility determination. (ii) A representation that any labor law decisions were rendered against the Offeror will not necessarily result in withholding of an award under this solicitation. Failure of the Offeror to furnish a representation or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible. (iii) The representation in paragraph (c) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous representation, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation in accordance with the procedures set forth in part 49. (e) The Offeror shall provide immediate written notice to the Contracting Officer if at any time prior to contract award the Offeror learns that its representation at paragraph (c) of this provision is no longer accurate. (f) The representation in paragraph (c) of this provision will be public information in the Federal Awardee Performance and Integrity Information System (FAPIIS). Note to 52.222-57: By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined section will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (End of provision) 52.223-22 PUBLIC DISCLOSURE OF GREENHOUSE GAS EMISSIONS AND REDUCTION GOALS--REPRESENTATION (DEC 2016) (a) This representation shall be completed if the Offeror received $7.5 million or more in Federal contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year. (b) Representation. [Offeror is to check applicable blocks in paragraphs (b)(1) and (2).] (1) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose greenhouse gas emissions, i.e., make available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard. (2) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly available Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage.

40

(3) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program. (c) If the Offeror checked ``does'' in paragraphs (b)(1) or (b)(2) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported: ___ . (End of provision) 52.228-1 BID GUARANTEE (SEP 1996) (a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid. (b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.- (c) The amount of the bid guarantee shall be _20_ percent of the bid price or $3,000,000.00_, whichever is less.- (d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.- (e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference. (End of provision) 52.233-2 SERVICE OF PROTEST (SEP 2006) (a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Mr. Dan Tatro at daniel.r.tatro.civ@mail.mil (b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO. (End of provision) 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995) (a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

41

(b) An organized site visit has been scheduled for-- 1:00 PM Central Standard Time on 17 August 2017 (c) Participants will meet at-- Oklahoma Air National Guard Building 222 9100 E. 46th Street North Tulsa, OK 74115 (End of provision) 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): http://farsite.hill.af.mil/ (End of provision) 252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015) Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8: (d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated: (i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education. (ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials. (iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold. (iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country. (v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities--Representations. Applies to solicitations for the acquisition of commercial satellite services. (vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

42

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy. (viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain. (ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold. (2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.] ____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government. ____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate. ____ (iii) 252.225-7020, Trade Agreements Certificate. ____ Use with Alternate I. ____ (iv) 252.225-7031, Secondary Arab Boycott of Israel. ____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate. ____ Use with Alternate I. ____ Use with Alternate II. ____ Use with Alternate III. ____ Use with Alternate IV. ____ Use with Alternate V. (e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database. (End of provision)

43

Section 00 21 13 - Instructions to Bidders STATEMENT OF WORK

STATEMENT OF WORK (316 HVAC Renovation)

XHZG201501230 19 July 2017

The contractor shall provide all labor, material, tools, equipment and transportation necessary to

complete the work identified in the plans and this Statement of Work. Work areas will be cleaned upon completion of work and all debris is to be disposed of off Base. This project is to be in accordance with the Base Specifications. This project is to be in accordance with the Environmental Compliance Guide for Designers and

Contractors dated 26 August 2013. A copy of this document will be provided to bidding contractors during the pre-bid meeting.

The contractor shall apply all safety procedures required by local, state and federal regulations. All work to be performed 7:00 AM to 5:30 PM Monday thru Thursday in accordance with the general

conditions stated in the Base Specifications. If alternate work schedule is desired it must be requested in writing and approved by CE and Security 48 hours prior to the desired schedule. Base Specifications cam be provided upon request.

The contractor will be responsible for moving furniture or moveable partitions. The movement and replacement of furniture and equipment will be coordinated with OKANG and the contractor.

All furniture and equipment not being moved will need to be covered with plastic sheeting or equivalent for protection of debris.

The contractor shall coordinate all work with a representative of the CE office. Prior to any work the contractor shall submit for approval by CE a minimum of four copies (or one

electronic copy) of technical literature for all products to be used. Provide Material Safety Data Sheets for all appropriate products.

Refer to any and all sketches, plans, specifications and this SOW included with this Request for Proposal.

The contractor will recycle all refrigerant and oils from equipment. The contractor will turn over all equipment to be recycled at Base HAZMAT located at building 420. Recycle bins will be provided.

See attached plans and drawings for construction details. Referring to drawings M-701, EXISTING FRONT END INTERFACE. Gateways WILL NOT be made

from existing front end interface to new interface. NOTE: Provide a standalone front end interface for Automated Logic system controls.

END OF STATEMENT SUPPLEMENTAL INSTRUCTIONS SUPPLEMENTAL INFORMATION Contract Specialist: MSgt David Hugueley Phone: 918-833-7118 E-mail: david.a.hugueley.mil@mail.mil

44

Contracting Officer SMSgt Amanda Lonsdale Phone: 918-833-7305 E-mail: amanda.j.lonsdale.mil@mail.mil Contracting Officer: Dan Tatro Phone: 405-228-5560 Email: daniel.r.tatro.civ@mail.mil Include the following within the sealed bid package:

1) Completed SF1442 with acknowledgement of all amendments 2) Completed SF24 3) Any additional verification documents

Contractor POC E-mail ____________________________________________ DUNS____________________________________________ TAXPAYER ID #__________________________ This solicitation is a 100% small business set aside under North American Industry Classification System code 238220 with a size standard of $15.0M. Bids can be submitted in any of the following ways: Delivered to Oklahoma Air National Guard Building 222, 9100 E. 46th Street North, Tulsa, OK 74115 prior to 09:00 AM Central Standard Time on 12 September 2017 Delivered by mail prior to 08:00 AM Central Standard Time on 11 September 2017 138 CONTRACTING FLIGHT (MSG/MSC) Attn: MSgt David Hugueley 9100 E 46TH ST NORTH TULSA OK 74115-1632 A site visit is scheduled for August 17, 2017 1:00 PM Local time. Interested attendees are asked to meet at the Oklahoma Air National Guard Building 222, 9100 E. 46th Street North, Tulsa, OK 74115. The POCs for the project are MSgt David Hugueley at (918) 833-7118 and SMSgt Amanda Lonsdale at (918) 833-7305. The entrance to the base is off of 46th Street North. If you do not have a military ID you will need to be escorted onto base. The guards at the front gate will provide you with a visitor badge and you will wait in the parking lot. Prior to the site visit we will go to the parking lot to pick up the contractors that need to be escorted. See Site Visit in Section 00100. For Site Visit information, see Site Visit clause 52.236-27, Alternate 1 in Section 00100. The conference will begin promptly without considerations for late or lost bidders. Remarks, explanations and answers provided by Government representatives before, during and after the site visit shall not change or qualify any of the terms or conditions of the solicitation. The solicitation can only be changed by a formal written amendment issued by the 138th Contracting Office. Any questions concerns, verification, requests for information or clarification of information of the documents included in the solicitation package shall be submitted in writing and submitted to the Government POC’s identified herein no later than Noon, local time on September 4, 2017. Include in the subject line of the email the Government’s solicitation number; failure to do so will lessen the Government’s ability to ensure all questions are considered during the bidding process. Provide your company name, POC and contact information in the body of the email.

45

Section 00 70 00 - Conditions of the Contract INSPECTION AND ACCEPTANCE TERMS Supplies/services will be inspected/accepted at: CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY 0001 N/A N/A N/A Government CLAUSES INCORPORATED BY REFERENCE 52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions OCT 2010

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards OCT 2016

52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications. DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-13 Notice of Set-Aside of Orders NOV 2011 52.219-14 Limitations On Subcontracting JAN 2017 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014

46

52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction APR 2015

52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-59 Compliance with Labor Laws (Executive Order 13673) DEC 2016 52.222-60 Paycheck Transparency (Executive Order 13673) OCT 2016 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-11 Ozone-Depleting Substances and High Global Warming

Potential Hydrofluorocarbons. JUN 2016

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-13 Notice Of Progress Payments APR 1984 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment,

Utilities, and Improvements APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984

47

52.236-13 Accident Prevention NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.237-2 Protection Of Government Buildings, Equipment, And

Vegetation APR 1984

52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.244-6 Subcontracts for Commercial Items JAN 2017 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.246-21 Alt I Warranty of Construction (Mar 1994) - Alternate I APR 1984 52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Termination For Convenience Of The Government (Fixed-

Price) APR 2012

52.249-2 Alt I Termination for Convenience of the Government (Fixed-Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General DEC 2012 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting OCT 2016

252.204-7014 Limitations on the Use or Disclosure of Information by Litigation Support Contractors

MAY 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.223-7001 Hazard Warning Labels DEC 1991 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7001 Buy American And Balance Of Payments Program-- Basic

(Dec 2016) DEC 2016

252.225-7002 Qualifying Country Sources As Subcontractors DEC 2016 252.225-7048 Export-Controlled Items JUN 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports JUN 2012

252.232-7004 DOD Progress Payment Rates OCT 2014 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7001 Contract Drawings, and Specifications AUG 2000 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012

48

252.247-7023 Transportation of Supplies by Sea APR 2014 CLAUSES INCORPORATED BY FULL TEXT 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 150 days after the contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises. (End of clause) 52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL ITEMS) (JAN 2017). (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are ncorporated by reference: (1) The clauses listed below implement provisions of law or Executive order: (i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (ii) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755). (iii) 52.222-21, Prohibition of Segregated Facilities (APR 2015). (iv) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246). (v) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). (vi) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (vii) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note). (2) Listed below are additional clauses that apply: (i) 52.232-1, Payments (APR 1984). (ii) 52.232-8, Discounts for Prompt Payment (FEB 2002). (iii) 52.232-11, Extras (APR 1984). (iv) 52.232-25, Prompt Payment (JAN 2017). (v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013). (vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

49

(vii) 52.233-1, Disputes (MAY 2014). (viii) 52.244-6, Subcontracts for Commercial Items (JAN 2017). (ix) 52.222-55, Minimum Wages Under Executive Order 13658 (MAR 2016) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)). (b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply: (1) The clauses listed below implement provisions of law or Executive order: (i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more). (ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold). (iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (MAY 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands). (iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (applies to contracts of $150,000 or more). (v) 52.222-36, Equal Employment for Workers with Disabilities (JUL 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, ``United States'' includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.) (vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more). (vii) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf). (viii)(A) 52.222-50, Combating Trafficking in Persons (MAR 2015) (22 U.S.C. chapter 78 and E.O 13627) (Applies to all solicitations and contracts). (B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies). (ix) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)). (x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

50

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities). (xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)). (xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners). (xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR[supreg] Program or Federal Energy Management Program (FEMP) will be-- (A) Delivered; (B) Acquired by the Contractor for use in performing services at a Federally-controlled facility; (C) Furnished by the Contractor for use by the Government; or (D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance). (xv) 52.223-20, Aerosols (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices). (xvi) 52.223-21, Foams (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent; or contracts for construction of buildings or facilities. (xvii) 52.225-1, Buy American--Supplies (MAY 2014) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition-- (A) Is set aside for small business concerns; or (B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000). (xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States). (xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (JUL 2013) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) database as its source of EFT information.) (xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.) (xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).) (2) Listed below are additional clauses that may apply:

51

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (June, 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system. (ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (Applies to contracts over $35,000). (iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies). (iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin). (v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination). (c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://farsite.hill.af.mil/ (d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights-- (1) Within a reasonable period of time after the defect was discovered or should have been discovered; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item. (e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided. (g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is

52

determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience. (h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract. (End of clause) 52.216-7 ALLOWABLE COST AND PAYMENT (JUN 2013) -- ALTERNATE I (FEB 1997) (a) Invoicing. (1) The Government will make payments to the Contractor when requested as work progresses, but (except for small business concerns) not more often than once every 2 weeks, in amounts determined to be allowable by the Contracting Officer in accordance with Federal Acquisition Regulation (FAR) Subpart 31.2 in effect on the date of this contract and the terms of this contract. The Contractor may submit to an authorized representative of the Contracting Officer, in such form and reasonable detail as the representative may require, an invoice or voucher supported by a statement of the claimed allowable cost for performing this contract. (2) Contract financing payments are not subject to the interest penalty provisions of the Prompt Payment Act. Interim payments made prior to the final payment under the contract are contract financing payments, except interim payments if this contract contains Alternate I to the clause at 52.232-25. (3) The designated payment office will make interim payments for contract financing on the 30th day after the designated billing office receives a proper payment request. In the event that the Government requires an audit or other review of a specific payment request to ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make payment by the specified due date. (b) Reimbursing costs. (1) For the purpose of reimbursing allowable costs (except as provided in paragraph (b)(2) of this clause, with respect to pension, deferred profit sharing, and employee stock ownership plan contributions), the term "costs" includes only- (i) Those recorded costs that, at the time of the request for reimbursement, the Contractor has paid by cash, check, or other form of actual payment for items or services purchased directly for the contract; (ii) When the Contractor is not delinquent in paying costs of contract performance in the ordinary course of business, costs incurred, but not necessarily paid, for- (A) Supplies and services purchased directly for the contract and associated financing payments to subcontractors, provided payments determined due will be made- (1) In accordance with the terms and conditions of a subcontract or invoice; and (2) Ordinarily within 30 days of the submission of the Contractor's payment request to the Government; (B) Materials issued from the Contractor's inventory and placed in the production process for use on the contract; (C) Direct labor; (D) Direct travel; (E) Other direct in-house costs; and

53

(F) Properly allocable and allowable indirect costs, as shown in the records maintained by the Contractor for purposes of obtaining reimbursement under Government contracts; and (iii) The amount of progress and other payments to the Contractor's subcontractors that either have been paid, or that the Contractor is required to pay pursuant to the clause of this contract entitled "Prompt Payment for Construction Contracts." Payments shall be made by cash, check, or other form of payment to the Contractor's subcontractors under similar cost standards. (2) Accrued costs of Contractor contributions under employee pension plans shall be excluded until actually paid unless- (i) The Contractor's practice is to make contributions to the retirement fund quarterly or more frequently; and (ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid shall be excluded from the Contractor's indirect costs for payment purposes). (3) Notwithstanding the audit and adjustment of invoices or vouchers under paragraph (g) of this clause, allowable indirect costs under this contract shall be obtained by applying indirect cost rates established in accordance with paragraph (d) of this clause. (4) Any statements in specifications or other documents incorporated in this contract by reference designating performance of services or furnishing of materials at the Contractor's expense or at no cost to the Government shall be disregarded for purposes of cost-reimbursement under this clause. (c) Small business concerns. A small business concern may receive more frequent payments than every 2 weeks. (d) Final indirect cost rates. (1) Final annual indirect cost rates and the appropriate bases shall be established in accordance with Subpart 42.7 of the Federal Acquisition Regulation (FAR) in effect for the period covered by the indirect cost rate proposal. (2)(i) The Contractor shall submit an adequate final indirect cost rate proposal to the Contracting Officer (or cognizant Federal agency official) and auditor within the 6-month period following the expiration of each of its fiscal years. Reasonable extensions, for exceptional circumstances only, may be requested in writing by the Contractor and granted in writing by the Contracting Officer. The Contractor shall support its proposal with adequate supporting data. (ii) The proposed rates shall be based on the Contractor's actual cost experience for that period. The appropriate Government representative and the Contractor shall establish the final indirect cost rates as promptly as practical after receipt of the Contractor's proposal. (3) The Contractor and the appropriate Government representative shall execute a written understanding setting forth the final indirect cost rates. The understanding shall specify (i) the agreed-upon final annual indirect cost rates, (ii) the bases to which the rates apply, (iii) the periods for which the rates apply, (iv) any specific indirect cost items treated as direct costs in the settlement, and (v) the affected contract and/or subcontract, identifying any with advance agreements or special terms and the applicable rates. The understanding shall not change any monetary ceiling, contract obligation, or specific cost allowance or disallowance provided for in this contract. The understanding is incorporated into this contract upon execution.

54

(4) Failure by the parties to agree on a final annual indirect cost rate shall be a dispute within the meaning of the Disputes clause. (5) Within 120 days (or longer period if approved in writing by the Contracting Officer) after settlement of the final annual indirect cost rates for all years of a physically complete contract, the Contractor shall submit a completion invoice or voucher to reflect the settled amounts and rates. (6)(i) If the Contractor fails to submit a completion invoice or voucher within the time specified in paragraph (d)(5) of this clause, the Contracting Officer may- (A) Determine the amounts due to the Contractor under the contract; and (B) Record this determination in a unilateral modification to the contract. (ii) This determination constitutes the final decision of the Contracting Officer in accordance with the Disputes clause. (e) Billing rates. Until final annual indirect cost rates are established for any period, the Government shall reimburse the Contractor at billing rates established by the Contracting Officer or by an authorized representative (the cognizant auditor), subject to adjustment when the final rates are established. These billing rates- (1) Shall be the anticipated final rates; and (2) May be prospectively or retroactively revised by mutual agreement, at either party's request, to prevent substantial overpayment or underpayment. (f) Quick-closeout procedures. Quick-closeout procedures are applicable when the conditions in FAR 42.708(a) are satisfied. (g) Audit. At any time or times before final payment, the Contracting Officer may have the Contractor's invoices or vouchers and statements of cost audited. Any payment may be- (1) Reduced by amounts found by the Contracting Officer not to constitute allowable costs; or (2) Adjusted for prior overpayments or underpayments. (h) Final payment. (1) Upon approval of a completion invoice or voucher submitted by the Contractor in accordance with paragraph (d)(5) of this clause, and upon the Contractor's compliance with all terms of this contract, the Government shall promptly pay any balance of allowable costs and that part of the fee (if any) not previously paid. (2) The Contractor shall pay to the Government any refunds, rebates, credits, or other amounts (including interest, if any) accruing to or received by the Contractor or any assignee under this contract, to the extent that those amounts are properly allocable to costs for which the Contractor has been reimbursed by the Government. Reasonable expenses incurred by the Contractor for securing refunds, rebates, credits, or other amounts shall be allowable costs if approved by the Contracting Officer. Before final payment under this contract, the Contractor and each assignee whose assignment is in effect at the time of final payment shall execute and deliver- (i) An assignment to the Government, in form and substance satisfactory to the Contracting Officer, of refunds, rebates, credits, or other amounts (including interest, if any) properly allocable to costs for which the Contractor has been reimbursed by the Government under this contract; and (ii) A release discharging the Government, its officers, agents, and employees from all liabilities, obligations, and claims arising out of or under this contract, except-

55

(A) Specified claims stated in exact amounts, or in estimated amounts when the exact amounts are not known; (B) Claims (including reasonable incidental expenses) based upon liabilities of the Contractor to third parties arising out of the performance of this contract; provided, that the claims are not known to the Contractor on the date of the execution of the release, and that the Contractor gives notice of the claims in writing to the Contracting Officer within 6 years following the release date or notice of final payment date, whichever is earlier; and (C) Claims for reimbursement of costs, including reasonable incidental expenses, incurred by the Contractor under the patent clauses of this contract, excluding, however, any expenses arising from the Contractor's indemnification of the Government against patent liability. (End of clause) 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013) (a) Definitions. As used in this clause-- Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority. Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity. (b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following: (1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract. (2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract. (3) For long-term contracts-- (i) Within 60 to 120 days prior to the end of the fifth year of the contract; and (ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter. (c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

56

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees. (e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update. (f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause. (g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed: The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 238220- assigned to contract number W912L6-17-X-XXXX. (Contractor to sign and date and insert authorized signer's name and title). (End of clause) 52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (JAN 1997) (a) "Hazardous material", as used in this clause, includes any material defined as hazardous under the latest version of Federal Standard No. 313 (including revisions adopted during the term of the contract). (b) The offeror must list any hazardous material, as defined in paragraph (a) of this clause, to be delivered under this contract. The hazardous material shall be properly identified and include any applicable identification number, such as National Stock Number or Special Item Number. This information shall also be included on the Material Safety Data Sheet submitted under this contract. Material Identification No. (If none, insert "None") ___ ___ ___ ___ ___ ___ (c) This list must be updated during performance of the contract whenever the Contractor determines that any other material to be delivered under this contract is hazardous. (d) The apparently successful offeror agrees to submit, for each item as required prior to award, a Material Safety Data Sheet, meeting the requirements of 29 CFR 1910.1200(g) and the latest version of Federal Standard No. 313,

57

for all hazardous material identified in paragraph (b) of this clause. Data shall be submitted in accordance with Federal Standard No. 313, whether or not the apparently successful offeror is the actual manufacturer of these items. Failure to submit the Material Safety Data Sheet prior to award may result in the apparently successful offeror being considered nonresponsible and ineligible for award. (e) If, after award, there is a change in the composition of the item(s) or a revision to Federal Standard No. 313, which renders incomplete or inaccurate the data submitted under paragraph (d) of this clause, the Contractor shall promptly notify the Contracting Officer and resubmit the data. (f) Neither the requirements of this clause nor any act or failure to act by the Government shall relieve the Contractor of any responsibility or liability for the safety of Government, Contractor, or subcontractor personnel or property. (g) Nothing contained in this clause shall relieve the Contractor from complying with applicable Federal, State, and local laws, codes, ordinances, and regulations (including the obtaining of licenses and permits) in connection with hazardous material. (h) The Government's rights in data furnished under this contract with respect to hazardous material are as follows: (1) To use, duplicate and disclose any data to which this clause is applicable. The purposes of this right are to-- (i) Apprise personnel of the hazards to which they may be exposed in using, handling, packaging, transporting, or disposing of hazardous materials; (ii) Obtain medical treatment for those affected by the material; and (iii) Have others use, duplicate, and disclose the data for the Government for these purposes. (2) To use, duplicate, and disclose data furnished under this clause, in accordance with subparagraph (h)(1) of this clause, in precedence over any other clause of this contract providing for rights in data. (3) The Government is not precluded from using similar or identical data acquired from other sources. (End of clause) 52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014) (a) “Irrevocable letter of credit” (ILC), as used in this clause, means a written commitment by a federally insured financial institution to pay all or part of a stated amount of money, until the expiration date of the letter, upon presentation by the Government (the beneficiary) of a written demand therefor. Neither the financial institution nor the offeror/Contractor can revoke or condition the letter of credit. (b) If the offeror intends to use an ILC in lieu of a bid bond, or to secure other types of bonds such as performance and payment bonds, the letter of credit and letter of confirmation formats in paragraphs (e) and (f) of this clause shall be used. (c) The letter of credit shall be irrevocable, shall require presentation of no document other than a written demand and the ILC (including confirming letter, if any), shall be issued/confirmed by an acceptable federally insured financial institution as provided in paragraph (d) of this clause, and-- (1) If used as a bid guarantee, the ILC shall expire no earlier than 60 days after the close of the bid acceptance period; (2) If used as an alternative to corporate or individual sureties as security for a performance or payment bond, the

58

offeror/Contractor may submit an ILC with an initial expiration date estimated to cover the entire period for which financial security is required or may submit an ILC with an initial expiration date that is a minimum period of one year from the date of issuance. The ILC shall provide that, unless the issuer provides the beneficiary written notice of non-renewal at least 60 days in advance of the current expiration date, the ILC is automatically extended without amendment for one year from the expiration date, or any future expiration date, until the period of required coverage is completed and the Contracting Officer provides the financial institution with a written statement waiving the right to payment. The period of required coverage shall be: (i) For contracts subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of-- (A) One year following the expected date of final payment; (B) For performance bonds only, until completion of any warranty period; or (C) For payment bonds only, until resolution of all claims filed against the payment bond during the one-year period following final payment. (ii) For contracts not subject to the Miller Act, the later of-- (A) 90 days following final payment; or (B) For performance bonds only, until completion of any warranty period. (d)(1) Only federally insured financial institutions rated investment grade by a commercial rating service shall issue or confirm the ILC. (2) Unless the financial institution issuing the ILC had letter of credit business of at least $25 million in the past year, ILCs over $5 million must be confirmed by another acceptable financial institution that had letter of credit business of at least $25 million in the past year. (3) The Offeror/Contractor shall provide the Contracting Officer a credit rating that indicates the financial institutions have the required credit rating as of the date of issuance of the ILC. (4) The current rating for a financial institution is available through any of the following rating services registered with the U.S. Securities and Exchange Commission (SEC) as a Nationally Recognized Statistical Rating Organization (NRSRO). NRSRO's can be located at the Web site http://www.sec.gov/answers/nrsro.htm maintained by the SEC. (e) The following format shall be used by the issuing financial institution to create an ILC: ___ [Issuing Financial Institution's Letterhead or Name and Address] Issue Date _ ___ IRREVOCABLE LETTER OF CREDIT NO. ___ Account party's name ___ _ Account party's address ___ _ For Solicitation No. ___ _(for reference only) TO: [ ___ U.S. Government agency] [ ___ U.S. Government agency's address]

59

1. We hereby establish this irrevocable and transferable Letter of Credit in your favor for one or more drawings up to United States $ ___ . This Letter of Credit is payable at [issuing financial institution's and, if any, confirming financial institution's] office at [ ___ issuing financial institution's address and, if any, confirming financial institution's address] and expires with our close of business on ___ , or any automatically extended expiration date. 2. We hereby undertake to honor your or the transferee's sight draft(s) drawn on the issuing or, if any, the confirming financial institution, for all or any part of this credit if presented with this Letter of Credit and confirmation, if any, at the office specified in paragraph 1 of this Letter of Credit on or before the expiration date or any automatically extended expiration date. 3. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this Letter of Credit that it is deemed to be automatically extended without amendment for one year from the expiration date hereof, or any future expiration date, unless at least 60 days prior to any expiration date, we notify you or the transferee by registered mail, or other receipted means of delivery, that we elect not to consider this Letter of Credit renewed for any such additional period. At the time we notify you, we also agree to notify the account party (and confirming financial institution, if any) by the same means of delivery. 4. This Letter of Credit is transferable. Transfers and assignments of proceeds are to be effected without charge to either the beneficiary or the transferee/assignee of proceeds. Such transfer or assignment shall be only at the written direction of the Government (the beneficiary) in a form satisfactory to the issuing financial institution and the confirming financial institution, if any. 5. This Letter of Credit is subject to the Uniform Customs and Practice (UCP) for Documentary Credits, International Chamber of Commerce Publication No. ___ -- (Insert version in effect at the time of ILC issuance, e.g., ``Publication 600, 2006 edition'') and to the extent not inconsistent therewith, to the laws of ___ --[State of confirming financial institution, if any, otherwise State of issuing financial institution]. 6. If this credit expires during an interruption of business of this financial institution as described in Article 17 of the UCP, the financial institution specifically agrees to effect payment if this credit is drawn against within 30 days after the resumption of our business. Sincerely, ___ [ ___ Issuing financial institution] (f) The following format shall be used by the financial institution to confirm an ILC: ___ [Confirming Financial Institution's Letterhead or Name and Address] (Date) ___ Our Letter of Credit Advice Number ___ Beneficiary: ___ [U.S. Government agency] Issuing Financial Institution: ___ Issuing Financial Institution's LC No.: ___ Gentlemen: 1. We hereby confirm the above indicated Letter of Credit, the original of which is attached, issued by ___ [name of issuing financial institution] for drawings of up to United States dollars ___ _/U.S. $ ___ and expiring with our

60

close of business on ___ [the expiration date], or any automatically extended expiration date. 2. Draft(s) drawn under the Letter of Credit and this Confirmation are payable at our office located at ___ _. 3. We hereby undertake to honor sight draft(s) drawn under and presented with the Letter of Credit and this Confirmation at our offices as specified herein. 4. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this confirmation that it be deemed automatically extended without amendment for one year from the expiration date hereof, or any automatically extended expiration date, unless: (a) At least 60 days prior to any such expiration date, we shall notify the Contracting Officer, or the transferee and the issuing financial institution, by registered mail or other receipted means of delivery, that we elect not to consider this confirmation extended for any such additional period; or (b) The issuing financial institution shall have exercised its right to notify you or the transferee, the account party, and ourselves, of its election not to extend the expiration date of the Letter of Credit. 5. This confirmation is subject to the Uniform Customs and Practice (UCP) for Documentary Credits, International Chamber of Commerce Publication No. ___ -- (Insert version in effect at the time of ILC issuance, e.g., ``Publication 600, 2006 edition'') and to the extent not inconsistent therewith, to the laws of ___ --[State of confirming financial institution]. 6. If this confirmation expires during an interruption of business of this financial institution as described in Article 17 of the UCP, we specifically agree to effect payment if this credit is drawn against within 30 days after the resumption of our business. Sincerely, ___ [Confirming financial institution] (g) The following format shall be used by the Contracting Officer for a sight draft to draw on the Letter of Credit: SIGHT DRAFT ___ [City, State] (Date) ___ [Name and address of financial institution] Pay to the order of ___ [Beneficiary Agency] ___ the sum of United States ___ This draft is drawn under Irrevocable Letter of Credit No. ___ ___ [Beneficiary Agency] By: ___ (End of clause)

61

52.232-16 PROGRESS PAYMENTS (APR 2012) The Government will make progress payments to the Contractor when requested as work progresses, but not more frequently than monthly, in amounts of $2,500 or more approved by the Contracting Officer, under the following conditions: (a) Computation of amounts. (1) Unless the Contractor requests a smaller amount, the Government will compute each progress payment as 80 percent of the Contractor's total costs incurred under this contract whether or not actually paid, plus financing payments to subcontractors (see paragraph (j) of this clause), less the sum of all previous progress payments made by the Government under this contract. The Contracting Officer will consider cost of money that would be allowable under FAR 31.205-10 as an incurred cost for progress payment purposes. (2) The amount of financing and other payments for supplies and services purchased directly for the contract are limited to the amounts that have been paid by cash, check, or other forms of payment, or that are determined due and will be paid to subcontractors-- (i) In accordance with the terms and conditions of a subcontract or invoice; and (ii) Ordinarily within 30 days of the submission of the Contractor's payment request to the Government. (3) The Government will exclude accrued costs of Contractor contributions under employee pension plans until actually paid unless-- (i) The Contractor's practice is to make contributions to the retirement fund quarterly or more frequently; and (ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid shall be excluded from the Contractor's total costs for progress payments until paid). (4) The Contractor shall not include the following in total costs for progress payment purposes in paragraph (a)(1) of this clause: (i) Costs that are not reasonable, allocable to this contract, and consistent with sound and generally accepted accounting principles and practices. (ii) Costs incurred by subcontractors or suppliers. (iii) Costs ordinarily capitalized and subject to depreciation or amortization except for the properly depreciated or amortized portion of such costs. (iv) Payments made or amounts payable to subcontractors or suppliers, except for -- (A) Completed work, including partial deliveries, to which the Contractor has acquired title; and (B) Work under cost-reimbursement or time-and-material subcontracts to which the Contractor has acquired title. (5) The amount of unliquidated progress payments may exceed neither (i) the progress payments made against incomplete work (including allowable unliquidated progress payments to subcontractors) nor (ii) the value, for progress payment purposes, of the incomplete work. Incomplete work shall be considered to be the supplies and services required by this contract, for which delivery and invoicing by the Contractor and acceptance by the Government are incomplete. (6) The total amount of progress payments shall not exceed 80 percent of the total contract price. (7) If a progress payment or the unliquidated progress payments exceed the amounts permitted by subparagraphs

62

(a)(4) or (a)(5) of this clause, the Contractor shall repay the amount of such excess to the Government on demand. (8) Notwithstanding any other terms of the contract, the Contractor agrees not to request progress payments in dollar amounts of less than $2,500. The Contracting Officer may make exceptions. (9) The costs applicable to items delivered, invoiced, and accepted shall not include costs in excess of the contract price of the items. (b) Liquidation. Except as provided in the Termination for Convenience of the Government clause, all progress payments shall be liquidated by deducting from any payment under this contract, other than advance or progress payments, the unliquidated progress payments, or 80 percent of the amount invoiced, whichever is less. The Contractor shall repay to the Government any amounts required by a retroactive price reduction, after computing liquidations and payments on past invoices at the reduced prices and adjusting the unliquidated progress payments accordingly. The Government reserves the right to unilaterally change from the ordinary liquidation rate to an alternate rate when deemed appropriate for proper contract financing. (c) Reduction or suspension. The Contracting Officer may reduce or suspend progress payments, increase the rate of liquidation, or take a combination of these actions, after finding on substantial evidence any of the following conditions: (1) The Contractor failed to comply with any material requirement of this contract (which includes paragraphs (f) and (g) of this clause). (2) Performance of this contract is endangered by the Contractor's -- (i) Failure to make progress or (ii) Unsatisfactory financial condition. (3) Inventory allocated to this contract substantially exceeds reasonable requirements. (4) The Contractor is delinquent in payment of the costs of performing this contract in the ordinary course of business. (5) The fair value of the undelivered work is less than the amount of unliquidated progress payments for that work. (6) The Contractor is realizing less profit than that reflected in the establishment of any alternate liquidation rate in paragraph (b) of this clause, and that rate is less than the progress payment rate stated in subparagraph (a)(1) of this clause. (d) Title. (1) Title to the property described in this paragraph (d) shall vest in the Government. Vestiture shall be immediately upon the date of this contract, for property acquired or produced before that date. Otherwise, vestiture shall occur when the property is or should have been allocable or properly chargeable to this contract. (2) "Property," as used in this clause, includes all of the below-described items acquired or produced by the Contractor that are or should be allocable or properly chargeable to this contract under sound and generally accepted accounting principles and practices. (i) Parts, materials, inventories, and work in process; (ii) Special tooling and special test equipment to which the Government is to acquire title; (iii) Nondurable (i.e., noncapital) tools, jigs, dies, fixtures, molds, patterns, taps, gauges, test equipment, and other similar manufacturing aids, title to which would not be obtained as special tooling under paragraph (d) (2)(ii) of this

63

clause; and (iv) Drawings and technical data, to the extent the Contractor or subcontractors are required to deliver them to the Government by other clauses of this contract. (3) Although title to property is in the Government under this clause, other applicable clauses of this contract; e.g., the termination clauses, shall determine the handling and disposition of the property. (4) The Contractor may sell any scrap resulting from production under this contract without requesting the Contracting Officer's approval, but the proceeds shall be credited against the costs of performance. (5) To acquire for its own use or dispose of property to which title is vested in the Government under this clause, the Contractor must obtain the Contracting Officer's advance approval of the action and the terms. The Contractor shall (i) exclude the allocable costs of the property from the costs of contract performance, and (ii) repay to the Government any amount of unliquidated progress payments allocable to the property. Repayment may be by cash or credit memorandum. (6) When the Contractor completes all of the obligations under this contract, including liquidation of all progress payments, title shall vest in the Contractor for all property (or the proceeds thereof) not-- (i) Delivered to, and accepted by, the Government under this contract; or (ii) Incorporated in supplies delivered to, and accepted by, the Government under this contract and to which title is vested in the Government under this clause. (7) The terms of this contract concerning liability for Government-furnished property shall not apply to property to which the Government acquired title solely under this clause. (e) Risk of loss. Before delivery to and acceptance by the Government, the Contractor shall bear the risk of loss for property, the title to which vests in the Government under this clause, except to the extent the Government expressly assumes the risk. The Contractor shall repay the Government an amount equal to the unliquidated progress payments that are based on costs allocable to property that is lost (see 45.101). (f) Control of costs and property. The Contractor shall maintain an accounting system and controls adequate for the proper administration of this clause. (g) Reports, forms, and access to records. (1) The Contractor shall promptly furnish reports, certificates, financial statements, and other pertinent information (including estimates to complete) reasonably requested by the Contracting Officer for the administration of this clause. Also, the Contractor shall give the Government reasonable opportunity to examine and verify the Contractor's books, records, and accounts. (2) The Contractor shall furnish estimates to complete that have been developed or updated within six months of the date of the progress payment request. The estimates to complete shall represent the Contractor's best estimate of total costs to complete all remaining contract work required under the contract. The estimates shall include sufficient detail to permit Government verification. (3) Each Contractor request for progress payment shall: (i) Be submitted on Standard Form 1443, Contractor's Request for Progress Payment, or the electronic equivalent as required by agency regulations, in accordance with the form instructions and the contract terms; and (ii) Include any additional supporting documentation requested by the Contracting Officer. (h) Special terms regarding default. If this contract is terminated under the Default clause, (i) the Contractor shall, on demand, repay to the Government the amount of unliquidated progress payments and (ii) title shall vest in the

64

Contractor, on full liquidation of progress payments, for all property for which the Government elects not to require delivery under the Default clause. The Government shall be liable for no payment except as provided by the Default clause. (i) Reservations of rights. (1) No payment or vesting of title under this clause shall -- (i) Excuse the Contractor from performance of obligations under this contract or (ii) Constitute a waiver of any of the rights or remedies of the parties under the contract. (2) The Government's rights and remedies under this clause (i) Shall not be exclusive but rather shall be in addition to any other rights and remedies provided by law or this contract and (ii) Shall not be affected by delayed, partial, or omitted exercise of any right, remedy, power, or privilege, nor shall such exercise or any single exercise preclude or impair any further exercise under this clause or the exercise of any other right, power, or privilege of the Government. (j) Financing payments to subcontractors. The financing payments to subcontractors mentioned in paragraphs (a)(1) and (a)(2) of this clause shall be all financing payments to subcontractors or divisions, if the following conditions are met: (1) The amounts included are limited to-- (i) The unliquidated remainder of financing payments made; plus (ii) Any unpaid subcontractor requests for financing payments. (2) The subcontract or interdivisional order is expected to involve a minimum of approximately 6 months between the beginning of work and the first delivery; or, if the subcontractor is a small business concern, 4 months. (3) If the financing payments are in the form of progress payments, the terms of the subcontract or interdivisional order concerning progress payments-- (i) Are substantially similar to the terms of this clause for any subcontractor that is a large business concern, or this clause with its Alternate I for any subcontractor that is a small business concern; (ii) Are at least as favorable to the Government as the terms of this clause; (iii) Are not more favorable to the subcontractor or division than the terms of this clause are to the Contractor; (iv) Are in conformance with the requirements of FAR 32.504(e); and (v) Subordinate all subcontractor rights concerning property to which the Government has title under the subcontract to the Government's right to require delivery of the property to the Government if-- (A) The Contractor defaults; or (B) The subcontractor becomes bankrupt or insolvent. (4) If the financing payments are in the form of performance-based payments, the terms of the subcontract or interdivisional order concerning payments--

65

(i) Are substantially similar to the Performance-Based Payments clause at FAR 52.232-32 and meet the criteria for, and definition of, performance-based payments in FAR Part 32; (ii) Are in conformance with the requirements of FAR 32.504(f); and (iii) Subordinate all subcontractor rights concerning property to which the Government has title under the subcontract to the Government's right to require delivery of the property to the Government if-- (A) The Contractor defaults; or (B) The subcontractor becomes bankrupt or insolvent. (5) If the financing payments are in the form of commercial item financing payments, the terms of the subcontract or interdivisional order concerning payments-- (i) Are constructed in accordance with FAR 32.206(c) and included in a subcontract for a commercial item purchase that meets the definition and standards for acquisition of commercial items in FAR Parts 2 and 12; (ii) Are in conformance with the requirements of FAR 32.504(g); and (iii) Subordinate all subcontractor rights concerning property to which the Government has title under the subcontract to the Government's right to require delivery of the property to the Government if-- (A) The Contractor defaults; or (B) The subcontractor becomes bankrupt or insolvent. (6) If financing is in the form of progress payments, the progress payment rate in the subcontract is the customary rate used by the contracting agency, depending on whether the subcontractor is or is not a small business concern. (7) Concerning any proceeds received by the Government for property to which title has vested in the Government under the subcontract terms, the parties agree that the proceeds shall be applied to reducing any unliquidated financing payments by the Government to the Contractor under this contract. (8) If no unliquidated financing payments to the Contractor remain, but there are unliquidated financing payments that the Contractor has made to any subcontractor, the Contractor shall be subrogated to all the rights the Government obtained through the terms required by this clause to be in any subcontract, as if all such rights had been assigned and transferred to the Contractor. (9) To facilitate small business participation in subcontracting under this contract, the Contractor shall provide financing payments to small business concerns, in conformity with the standards for customary contract financing payments stated in Subpart 32.113. The Contractor shall not consider the need for such financing payments as a handicap or adverse factor in the award of subcontracts. (k) Limitations on undefinitized contract actions. Notwithstanding any other progress payment provisions in this contract, progress payments may not exceed 80 percent of costs incurred on work accomplished under undefinitized contract actions. A "contract action" is any action resulting in a contract, as defined in Subpart 2.1, including contract modifications for additional supplies or services, but not including contract modifications that are within the scope and under the terms of the contract, such as contract modifications issued pursuant to the Changes clause, or funding and other administrative changes. This limitation shall apply to the costs incurred, as computed in accordance with paragraph (a) of this clause, and shall remain in effect until the contract action is definitized. Costs incurred which are subject to this limitation shall be segregated on Contractor progress payment requests and invoices from those costs eligible for higher progress payment rates. For purposes of progress payment liquidation, as described in paragraph (b) of this clause, progress payments for undefinitized contract actions shall be liquidated at 80 percent of the amount invoiced for work performed under the undefinitized contract action as long as the contract action remains undefinitized. The amount of unliquidated progress payments for undefinitized contract

66

actions shall not exceed 80 percent of the maximum liability of the Government under the undefinitized contract action or such lower limit specified elsewhere in the contract. Separate limits may be specified for separate actions. (l) Due date. The designated payment office will make progress payments on the 30th day after the designated billing office receives a proper progress payment request. In the event that the Government requires an audit or other review of a specific progress payment request to ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make payment by the specified due date. Progress payments are considered contract financing and are not subject to the interest penalty provisions of the Prompt Payment Act. (m) Progress payments under indefinite--delivery contracts. The Contractor shall account for and submit progress payment requests under individual orders as if the order constituted a separate contract, unless otherwise specified in this contract. (End of clause) 52.243-2 CHANGES--COST-REIMBURSEMENT (AUG 1987) - ALTERNATE III (APR 1984) (a) The Contracting Officer may at any time, by written order, and without notice to the sureties, if any, make changes within the general scope of this contract in the plans and specifications or instructions incorporated in the contract. (b) If any such change causes an increase or decrease in the estimated cost of, or the time required for, performance of any part of the work under this contract, whether or not changed by the order, or otherwise affects any other terms and conditions of this contract, the Contracting Officer shall make an equitable adjustment in the (1) estimated cost, delivery or completion schedule, or both; (2) amount of any fixed fee; and (3) other affected terms and shall modify the contract accordingly. (c) The Contractor must assert its right to an adjustment under this clause within 30 days from the date of receipt of the written order. However, if the Contracting Officer decides that the facts justify it, the Contracting Officer may receive and act upon a proposal submitted before final payment of the contract. (d) Failure to agree to any adjustment shall be a dispute under the Disputes clause. However, nothing in this clause shall excuse the Contractor from proceeding with the contract as changed. (e) Notwithstanding the terms and conditions of paragraphs (a) and (b) above, the estimated cost of this contract and, if this contract is incrementally funded, the funds allotted for the performance of this contract, shall not be increased or considered to be increased except by specific written modification of the contract indicating the new contract estimated cost and, if this contract is incrementally funded, the new amount allotted to the contract. Until this modification is made, the Contractor shall not be obligated to continue performance or incur costs beyond the point established in the Limitation of Cost or Limitation of Funds clause of this contract. (End of clause) 52.248-1 VALUE ENGINEERING (OCT 2010) (a) General. The Contractor is encouraged to develop, prepare, and submit value engineering change proposals (VECP's) voluntarily. The Contractor shall share in any net acquisition savings realized from accepted VECP's, in accordance with the incentive sharing rates in paragraph (f) below.

67

(b) Definitions. "Acquisition savings,'' as used in this clause, means savings resulting from the application of a VECP to contracts awarded by the same contracting office or its successor for essentially the same unit. Acquisition savings include-- (1) Instant contract savings, which are the net cost reductions on this, the instant contract, and which are equal to the instant unit cost reduction multiplied by the number of instant contract units affected by the VECP, less the Contractor's allowable development and implementation costs; (2) Concurrent contract savings, which are net reductions in the prices of other contracts that are definitized and ongoing at the time the VECP is accepted; and (3) Future contract savings, which are the product of the future unit cost reduction multiplied by the number of future contract units in the sharing base. On an instant contract, future contract savings include savings on increases in quantities after VECP acceptance that are due to contract modifications, exercise of options, additional orders, and funding of subsequent year requirements on a multiyear contract. "Collateral costs," as used in this clause, means agency cost of operation, maintenance, logistic support, or Government-furnished property. "Collateral savings," as used in this clause, means those measurable net reductions resulting from a VECP in the agency's overall projected collateral costs, exclusive of acquisition savings, whether or not the acquisition cost changes. "Contracting office" includes any contracting office that the acquisition is transferred to, such as another branch of the agency or another agency's office that is performing a joint acquisition action. "Contractor's development and implementation costs," as used in this clause, means those costs the Contractor incurs on a VECP specifically in developing, testing, preparing, and submitting the VECP, as well as those costs the Contractor incurs to make the contractual changes required by Government acceptance of a VECP. "Future unit cost reduction," as used in this clause, means the instant unit cost reduction adjusted as the Contracting Officer considers necessary for projected learning or changes in quantity during the sharing period. It is calculated at the time the VECP is accepted and applies either (1) throughout the sharing period, unless the Contracting Officer decides that recalculation is necessary because conditions are significantly different from those previously anticipated or (2) to the calculation of a lump-sum payment, which cannot later be revised. "Government costs," as used in this clause, means those agency costs that result directly from developing and implementing the VECP, such as any net increases in the cost of testing, operations, maintenance, and logistics support. The term does not include the normal administrative costs of processing the VECP or any increase in this contract's cost or price resulting from negative instant contract savings. "Instant contract," as used in this clause, means this contract, under which the VECP is submitted. It does not include increases in quantities after acceptance of the VECP that are due to contract modifications, exercise of options, or additional orders. If this is a multiyear contract, the term does not include quantities funded after VECP acceptance. If this contract is a fixed-price contract with prospective price redetermination, the term refers to the period for which firm prices have been established. "Instant unit cost reduction" means the amount of the decrease in unit cost of performance (without deducting any Contractor's development or implementation costs) resulting from using the VECP on this, the instant contract. If this is a service contract, the instant unit cost reduction is normally equal to the number of hours per line-item task saved by using the VECP on this contract, multiplied by the appropriate contract labor rate. "Negative instant contract savings" means the increase in the cost or price of this contract when the acceptance of a VECP results in an excess of the Contractor's allowable development and implementation costs over the product of the instant unit cost reduction multiplied by the number of instant contract units affected.

68

"Net acquisition savings" means total acquisition savings, including instant, concurrent, and future contract savings, less Government costs. "Sharing base," as used in this clause, means the number of affected end items on contracts of the contracting office accepting the VECP. Sharing period, as used in this clause, means the period beginning with acceptance of the first unit incorporating the VECP and ending at a calendar date or event determined by the contracting officer for each VECP. "Unit," as used in this clause, means the item or task to which the Contracting Officer and the Contractor agree the VECP applies. "Value engineering change proposal (VECP)" means a proposal that-- (1) Requires a change to this, the instant contract, to implement; and (2) Results in reducing the overall projected cost to the agency without impairing essential functions or characteristics; provided, that it does not involve a change-- (i) In deliverable end item quantities only; (ii) In research and development (R&D) end items or R&D test quantities that is due solely to results of previous testing under this contract; or (iii) To the contract type only. (c) VECP preparation. As a minimum, the Contractor shall include in each VECP the information described in subparagraphs (1) through (8) below. If the proposed change is affected by contractually required configuration management or similar procedures, the instructions in those procedures relating to format, identification, and priority assignment shall govern VECP preparation. The VECP shall include the following: (1) A description of the difference between the existing contract requirement and the proposed requirement, the comparative advantages and disadvantages of each, a justification when an item's function or characteristics are being altered, the effect of the change on the end item's performance, and any pertinent objective test data. (2) A list and analysis of the contract requirements that must be changed if the VECP is accepted, including any suggested specification revisions. (3) Identification of the unit to which the VECP applies. (4) A separate, detailed cost estimate for (i) the affected portions of the existing contract requirement and (ii) the VECP. The cost reduction associated with the VECP shall take into account the Contractor's allowable development and implementation costs, including any amount attributable to subcontracts under the Subcontracts paragraph of this clause, below. (5) A description and estimate of costs the Government may incur in implementing the VECP, such as test and evaluation and operating and support costs. (6) A prediction of any effects the proposed change would have on collateral costs to the agency. (7) A statement of the time by which a contract modification accepting the VECP must be issued in order to achieve the maximum cost reduction, noting any effect on the contract completion time or delivery schedule. (8) Identification of any previous submissions of the VECP, including the dates submitted, the agencies and contract numbers involved, and previous Government actions, if known.

69

(d) Submission. The Contractor shall submit VECP's to the Contracting Officer, unless this contract states otherwise. If this contract is administered by other than the contracting office, the Contractor shall submit a copy of the VECP simultaneously to the Contracting Officer and to the Administrative Contracting Officer. (e) Government action. (1) The Contracting Officer will notify the Contractor of the status of the VECP within 45 calendar days after the contracting office receives it. If additional time is required, the Contracting Officer will notify the Contractor within the 45-day period and provide the reason for the delay and the expected date of the decision. The Government will process VECP's expeditiously; however, it shall not be liable for any delay in acting upon a VECP. (2) If the VECP is not accepted, the Contracting Officer will notify the Contractor in writing, explaining the reasons for rejection. The Contractor may withdraw any VECP, in whole or in part, at any time before it is accepted by the Government. The Contracting Officer may require that the Contractor provide written notification before undertaking significant expenditures for VECP effort. (3) Any VECP may be accepted, in whole or in part, by the Contracting Officer's award of a modification to this contract citing this clause and made either before or within a reasonable time after contract performance is completed. Until such a contract modification applies a VECP to this contract, the Contractor shall perform in accordance with the existing contract. The decision to accept or reject all or part of any VECP is a unilateral decision made solely at the discretion of the Contracting Officer. (f) Sharing rates. If a VECP is accepted, the Contractor shall share in net acquisition savings according to the percentages shown in the table below. The percentage paid the Contractor depends upon (1) this contract's type (fixed-price, incentive, or cost-reimbursement), (2) the sharing arrangement specified in paragraph (a) above (incentive, program requirement, or a combination as delineated in the Schedule), and (3) the source of the savings (the instant contract, or concurrent and future contracts), as follows:

CONTRACTOR'S SHARE OF NET ACQUISITION SAVINGS (Figures in percent)

Contract Type Incentive (Voluntary) Program Requirement

(Mandatory) Instant Contract

Rate Concurrent and Future Contract

Rate

Instant Contract Rate

Concurrent and Future Contract

Rate Fixed-price

(includes fixed-price-award-fee; excludes other

fixed-price incentive contracts)

(1) 50 (1) 50 (1) 25 25

Incentive (fixed-price or cost) (other than award fee)

(2) (1) 50 (2) 25

Cost-reimbursement (includes cost-plus-award-fee; excludes other

cost-type incentive Contracts)

(3) 25 (3) 25 15 15

(1) The Contracting Officer may increase the Contractor's sharing rate to as high as 75 percent for each VECP.

70

(2) Same sharing arrangement as the contract's profit or fee adjustment formula. (3) The Contracting Officer may increase the Contractor's sharing rate to as high as 50 percent for each VECP.

(g) Calculating net acquisition savings. (1) Acquisition savings are realized when (i) the cost or price is reduced on the instant contract, (ii) reductions are negotiated in concurrent contracts, (iii) future contracts are awarded, or (iv) agreement is reached on a lump-sum payment for future contract savings (see subparagraph (i)(4) below). Net acquisition savings are first realized, and the Contractor shall be paid a share, when Government costs and any negative instant contract savings have been fully offset against acquisition savings. (2) Except in incentive contracts, Government costs and any price or cost increases resulting from negative instant contract savings shall be offset against acquisition savings each time such savings are realized until they are fully offset. Then, the Contractor's share is calculated by multiplying net acquisition savings by the appropriate Contractor's percentage sharing rate (see paragraph (f) above). Additional Contractor shares of net acquisition savings shall be paid to the Contractor at the time realized. (3) If this is an incentive contract, recovery of Government costs on the instant contract shall be deferred and offset against concurrent and future contract savings. The Contractor shall share through the contract incentive structure in savings on the instant contract items affected. Any negative instant contract savings shall be added to the target cost or to the target price and ceiling price, and the amount shall be offset against concurrent and future contract savings. (4) If the Government does not receive and accept all items on which it paid the Contractor's share, the Contractor shall reimburse the Government for the proportionate share of these payments. (h) Contract adjustment. The modification accepting the VECP (or a subsequent modification issued as soon as possible after any negotiations are completed) shall-- (1) Reduce the contract price or estimated cost by the amount of instant contract savings, unless this is an incentive contract; (2) When the amount of instant contract savings is negative, increase the contract price, target price and ceiling price, target cost, or estimated cost by that amount; (3) Specify the Contractor's dollar share per unit on future contracts, or provide the lump-sum payment; (4) Specify the amount of any Government costs or negative instant contract savings to be offset in determining net acquisition savings realized from concurrent or future contract savings; and (5) Provide the Contractor's share of any net acquisition savings under the instant contract in accordance with the following: (i) Fixed-price contracts--add to contract price. (ii) Cost-reimbursement contracts--add to contract fee. (i) Concurrent and future contract savings. (1) Payments of the Contractor's share of concurrent and future contract savings shall be made by a modification to the instant contract in accordance with subparagraph (h)(5) above. For incentive contracts, shares shall be added as a separate firm-fixed-price line item on the instant contract. The Contractor shall maintain records adequate to identify the first delivered unit for 3 years after final payment under this contract. (2) The Contracting Officer shall calculate the Contractor's share of concurrent contract savings by (i) subtracting from the reduction in price negotiated on the concurrent contract any Government costs or negative instant contract savings not yet offset and (ii) multiplying the result by the Contractor's sharing rate.

71

(3) The Contracting Officer shall calculate the Contractor's share of future contract savings by (i) multiplying the future unit cost reduction by the number of future contract units scheduled for delivery during the sharing period, (ii) subtracting any Government costs or negative instant contract savings not yet offset, and (iii) multiplying the result by the Contractor's sharing rate. (4) When the Government wishes and the Contractor agrees, the Contractor's share of future contract savings may be paid in a single lump sum rather than in a series of payments over time as future contracts are awarded. Under this alternate procedure, the future contract savings may be calculated when the VECP is accepted, on the basis of the Contracting Officer's forecast of the number of units that will be delivered during the sharing period. The Contractor's share shall be included in a modification to this contract (see subparagraph (h)(3) above) and shall not be subject to subsequent adjustment. (5) Alternate no-cost settlement method. When, in accordance with subsection 48.104-4 of the Federal Acquisition Regulation, the Government and the Contractor mutually agree to use the no-cost settlement method, the following applies: (i) The Contractor will keep all the savings on the instant contract and on its concurrent contracts only. (ii) The Government will keep all the savings resulting from concurrent contracts placed on other sources, savings from all future contracts, and all collateral savings. (j) Collateral savings. If a VECP is accepted, the Contracting Officer will increase the instant contract amount, as specified in paragraph (h)(5) of this clause, by a rate from 20 to 100 percent, as determined by the Contracting Officer, of any projected collateral savings determined to be realized in a typical year of use after subtracting any Government costs not previously offset. However, the Contractor's share of collateral savings will not exceed the contract's firm-fixed-price, target price, target cost, or estimated cost, at the time the VECP is accepted, or $100,000, whichever is greater. The Contracting Officer will be the sole determiner of the amount of collateral savings. (k) Relationship to other incentives. Only those benefits of an accepted VECP not rewardable under performance, design-to-cost (production unit cost, operating and support costs, reliability and maintainability), or similar incentives shall be rewarded under this clause. However, the targets of such incentives affected by the VECP shall not be adjusted because of VECP acceptance. If this contract specifies targets but provides no incentive to surpass them, the value engineering sharing shall apply only to the amount of achievement better than target. (l) Subcontracts. The Contractor shall include an appropriate value engineering clause in any subcontract of $150,000 or more and may include one in subcontracts of lesser value. In calculating any adjustment in this contract's price for instant contract savings (or negative instant contract savings), the Contractor's allowable development and implementation costs shall include any subcontractor's allowable development and implementation costs, and any value engineering incentive payments to a subcontractor, clearly resulting from a VECP accepted by the Government under this contract. The Contractor may choose any arrangement for subcontractor value engineering incentive payments; provided, that the payments shall not reduce the Government's share of concurrent or future contract savings or collateral savings. (m) Data. The Contractor may restrict the Government's right to use any part of a VECP or the supporting data by marking the following legend on the affected parts: "These data, furnished under the Value Engineering clause of contract . . . . . . . . . . , shall not be disclosed outside the Government or duplicated, used, or disclosed, in whole or in part, for any purpose other than to evaluate a value engineering change proposal submitted under the clause. This restriction does not limit the Government's right to use information contained in these data if it has been obtained or is otherwise available from the Contractor or from another source without limitations." If a VECP is accepted, the Contractor hereby grants the Government unlimited rights in the VECP and supporting data, except that, with respect to data qualifying and submitted as limited rights technical data, the Government shall

72

have the rights specified in the contract modification implementing the VECP and shall appropriately mark the data. (The terms "unlimited rights" and "limited rights" are defined in Part 27 of the Federal Acquisition Regulation.) (End of clause) 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://farsite.hill.af.mil/ (End of clause) 252.211-7003 ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2016) (a) Definitions. As used in this clause- Automatic identification device means a device, such as a reader or interrogator, used to retrieve data encoded on machine-readable media. Concatenated unique item identifier means-- (1) For items that are serialized within the enterprise identifier, the linking together of the unique identifier data elements in order of the issuing agency code, enterprise identifier, and unique serial number within the enterprise identifier; or (2) For items that are serialized within the original part, lot, or batch number, the linking together of the unique identifier data elements in order of the issuing agency code; enterprise identifier; original part, lot, or batch number; and serial number within the original part, lot, or batch number. Data Matrix means a two-dimensional matrix symbology, which is made up of square or, in some cases, round modules arranged within a perimeter finder pattern and uses the Error Checking and Correction 200 (ECC200) specification found within International Standards Organization (ISO)/International Electrotechnical Commission (IEC) 16022. Data qualifier means a specified character (or string of characters) that immediately precedes a data field that defines the general category or intended use of the data that follows. DoD recognized unique identification equivalent means a unique identification method that is in commercial use and has been recognized by DoD. All DoD recognized unique identification equivalents are listed at http://www.acq.osd.mil/dpap/pdi/uid/iuid_equivalents.html. DoD item unique identification means a system of marking items delivered to DoD with unique item identifiers that have machine-readable data elements to distinguish an item from all other like and unlike items. For items that are serialized within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier and a unique serial number. For items that are serialized within the part, lot, or batch number within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier; the original part, lot, or batch number; and the serial number.

73

Enterprise means the entity (e.g., a manufacturer or vendor) responsible for assigning unique item identifiers to items. Enterprise identifier means a code that is uniquely assigned to an enterprise by an issuing agency. Government's unit acquisition cost means-- (1) For fixed-price type line, subline, or exhibit line items, the unit price identified in the contract at the time of delivery; (2) For cost-type or undefinitized line, subline, or exhibit line items, the Contractor's estimated fully burdened unit cost to the Government at the time of delivery; and (3) For items produced under a time-and-materials contract, the Contractor's estimated fully burdened unit cost to the Government at the time of delivery. Issuing agency means an organization responsible for assigning a globally unique identifier to an enterprise, as indicated in the Register of Issuing Agency Codes for ISO/IEC 15459, located at http://www.aimglobal.org/?Reg_Authority15459. Issuing agency code means a code that designates the registration (or controlling) authority for the enterprise identifier. Item means a single hardware article or a single unit formed by a grouping of subassemblies, components, or constituent parts. Lot or batch number means an identifying number assigned by the enterprise to a designated group of items, usually referred to as either a lot or a batch, all of which were manufactured under identical conditions. Machine-readable means an automatic identification technology media, such as bar codes, contact memory buttons, radio frequency identification, or optical memory cards. Original part number means a combination of numbers or letters assigned by the enterprise at item creation to a class of items with the same form, fit, function, and interface. Parent item means the item assembly, intermediate component, or subassembly that has an embedded item with a unique item identifier or DoD recognized unique identification equivalent. Serial number within the enterprise identifier means a combination of numbers, letters, or symbols assigned by the enterprise to an item that provides for the differentiation of that item from any other like and unlike item and is never used again within the enterprise. Serial number within the part, lot, or batch number means a combination of numbers or letters assigned by the enterprise to an item that provides for the differentiation of that item from any other like item within a part, lot, or batch number assignment. Serialization within the enterprise identifier means each item produced is assigned a serial number that is unique among all the tangible items produced by the enterprise and is never used again. The enterprise is responsible for ensuring unique serialization within the enterprise identifier. Serialization within the part, lot, or batch number means each item of a particular part, lot, or batch number is assigned a unique serial number within that part, lot, or batch number assignment. The enterprise is responsible for ensuring unique serialization within the part, lot, or batch number within the enterprise identifier.

74

Type designation means a combination of letters and numerals assigned by the Government to a major end item, assembly or subassembly, as appropriate, to provide a convenient means of differentiating between items having the same basic name and to indicate modifications and changes thereto. Unique item identifier means a set of data elements marked on items that is globally unique and unambiguous. The term includes a concatenated unique item identifier or a DoD recognized unique identification equivalent. Unique item identifier type means a designator to indicate which method of uniquely identifying a part has been used. The current list of accepted unique item identifier types is maintained at http://www.acq.osd.mil/dpap/pdi/uid/uii_types.html. (b) The Contractor shall deliver all items under a contract line, subline, or exhibit line item. (c) Unique item identifier. (1) The Contractor shall provide a unique item identifier for the following: (i) Delivered items for which the Government's unit acquisition cost is $5,000 or more, except for the following line items: ------------------------------------------------------------------------ Contract line, subline, or exhibit line item No. Item description ------------------------------------------------------------------------ ................................... ------------------------------------------------------------------------ (ii) Items for which the Government's unit acquisition cost is less than $5,000 that are identified in the Schedule or the following table: ------------------------------------------------------------------------ Contract line, subline, or exhibit line item No. Item description ------------------------------------------------------------------------ ................................... ------------------------------------------------------------------------ (If items are identified in the Schedule, insert ``See Schedule'' in this table.) (iii) Subassemblies, components, and parts embedded within delivered items, items with warranty requirements, DoD serially managed reparables and DoD serially managed nonreparables as specified in Attachment Number ----. (iv) Any item of special tooling or special test equipment as defined in FAR 2.101 that have been designated for preservation and storage for a Major Defense Acquisition Program as specified in Attachment Number ----. (v) Any item not included in paragraphs (c)(1)(i), (ii), (iii), or (iv) of this clause for which the contractor creates and marks a unique item identifier for traceability. (2) The unique item identifier assignment and its component data element combination shall not be duplicated on any other item marked or registered in the DoD Item Unique Identification Registry by the contractor. (3) The unique item identifier component data elements shall be marked on an item using two dimensional data matrix symbology that complies with ISO/IEC International Standard 16022, Information technology--International symbology specification--Data matrix; ECC200 data matrix specification. (4) Data syntax and semantics of unique item identifiers. The Contractor shall ensure that--

75

(i) The data elements (except issuing agency code) of the unique item identifier are encoded within the data matrix symbol that is marked on the item using one of the following three types of data qualifiers, as determined by the Contractor: (A) Application Identifiers (AIs) (Format Indicator 05 of ISO/IEC International Standard 15434), in accordance with ISO/IEC International Standard 15418, Information Technology--EAN/UCC Application Identifiers and Fact Data Identifiers and Maintenance and ANSI MH 10.8.2 Data Identifier and Application Identifier Standard. (B) Data Identifiers (DIs) (Format Indicator 06 of ISO/IEC International Standard 15434), in accordance with ISO/IEC International Standard 15418, Information Technology--EAN/UCC Application Identifiers and Fact Data Identifiers and Maintenance and ANSI MH 10.8.2 Data Identifier and Application Identifier Standard. (C) Text Element Identifiers (TEIs) (Format Indicator 12 of ISO/IEC International Standard 15434), in accordance with the Air Transport Association Common Support Data Dictionary; and (ii) The encoded data elements of the unique item identifier conform to the transfer structure, syntax, and coding of messages and data formats specified for Format Indicators 05, 06, and 12 in ISO/IEC International Standard 15434, Information Technology-Transfer Syntax for High Capacity Automatic Data Capture Media. (5) Unique item identifier. (i) The Contractor shall-- (A) Determine whether to-- (1) Serialize within the enterprise identifier; (2) Serialize within the part, lot, or batch number; or (3) Use a DoD recognized unique identification equivalent (e.g. Vehicle Identification Number); and (B) Place the data elements of the unique item identifier (enterprise identifier; serial number; DoD recognized unique identification equivalent; and for serialization within the part, lot, or batch number only: Original part, lot, or batch number) on items requiring marking by paragraph (c)(1) of this clause, based on the criteria provided in MIL-STD-130, Identification Marking of U.S. Military Property, latest version; (C) Label shipments, storage containers and packages that contain uniquely identified items in accordance with the requirements of MIL-STD-129, Military Marking for Shipment and Storage, latest version; and (D) Verify that the marks on items and labels on shipments, storage containers, and packages are machine readable and conform to the applicable standards. The contractor shall use an automatic identification technology device for this verification that has been programmed to the requirements of Appendix A, MIL-STD-130, latest version. (ii) The issuing agency code-- (A) Shall not be placed on the item; and (B) Shall be derived from the data qualifier for the enterprise identifier. (d) For each item that requires item unique identification under paragraph (c)(1)(i), (ii), or (iv) of this clause or when item unique identification is provided under paragraph (c)(1)(v), in addition to the information provided as part of the Material Inspection and Receiving Report specified elsewhere in this contract, the Contractor shall report at the time of delivery, as part of the Material Inspection and Receiving Report, the following information:

76

(1) Unique item identifier. (2) Unique item identifier type. (3) Issuing agency code (if concatenated unique item identifier is used). (4) Enterprise identifier (if concatenated unique item identifier is used). (5) Original part number (if there is serialization within the original part number). (6) Lot or batch number (if there is serialization within the lot or batch number). (7) Current part number (optional and only if not the same as the original part number). (8) Current part number effective date (optional and only if current part number is used). (9) Serial number (if concatenated unique item identifier is used). (10) Government's unit acquisition cost. (11) Unit of measure. (12) Type designation of the item as specified in the contract schedule, if any. (13) Whether the item is an item of Special Tooling or Special Test Equipment. (14) Whether the item is covered by a warranty. (e) For embedded subassemblies, components, and parts that require DoD unique item identification under paragraph (c)(1)(iii) of this clause, the Contractor shall report as part of, or associated with, the Material Inspection and Receiving Report specified elsewhere in this contract, the following information: (1) Unique item identifier of the parent item under paragraph (c)(1) of this clause that contains the embedded subassembly, component, or part. (2) Unique item identifier of the embedded subassembly, component, or part. (3) Unique item identifier type.** (4) Issuing agency code (if concatenated unique item identifier is used).** (5) Enterprise identifier (if concatenated unique item identifier is used).** (6) Original part number (if there is serialization within the original part number).** (7) Lot or batch number (if there is serialization within the lot or batch number).** (8) Current part number (optional and only if not the same as the original part number).** (9) Current part number effective date (optional and only if current part number is used).** (10) Serial number (if concatenated unique item identifier is used).** (11) Description.

77

** Once per item. (f) The Contractor shall submit the information required by paragraphs (d) and (e) of this clause as follows: (1) End items shall be reported using the receiving report capability in Wide Area WorkFlow (WAWF) in accordance with the clause at 252.232-7003. If WAWF is not required by this contract, and the contractor is not using WAWF, follow the procedures at http://dodprocurementtoolbox.com/site/uidregistry/. (2) Embedded items shall be reported by one of the following methods-- (i) Use of the embedded items capability in WAWF; (ii) Direct data submission to the IUID Registry following the procedures and formats at http://dodprocurementtoolbox.com/site/uidregistry/; or (iii) Via WAWF as a deliverable attachment for exhibit line item number (fill in) ----, Unique Item Identifier Report for Embedded Items, Contract Data Requirements List, DD Form 1423. (g) Subcontracts. If the Contractor acquires by subcontract any items for which item unique identification is required in accordance with paragraph (c)(1) of this clause, the Contractor shall include this clause, including this paragraph (g), in the applicable subcontract(s), including subcontracts for commercial items. (End of clause) 252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013) (a) Definitions. As used in this clause-- Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization. Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF). Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system. (b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports. (c) WAWF access. To access WAWF, the Contractor shall-- (1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and (2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site. (d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

78

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol. (f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order: (1) Document type. The Contractor shall use the following document type(s). Receiving Report and Invoice (Combo) (2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer. Not Applicable (3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system. Routing Data Table* -------------------------------------------------------------------------------------------- Field Name in WAWF Data to be entered in WAWF -------------------------------------------------------------------------------------------- Pay Official DoDAAC F87700 Issue By DoDAAC W912L6 Admin DoDAAC W912L6 Inspect By DoDAAC FA6563 Ship To Code F9L3CE Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) F9L3CE Service Acceptor (DoDAAC) FA6563 Accept at Other DoDAAC N/A LPO DoDAAC See Block 14 of SF 1442 DCAA Auditor DoDAAC N/A Other DoDAAC(s) N/A -------------------------------------------------------------------------------------------- (4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request. (5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system. Daniel.r.tatro.civ@mail.mil Amanda.j.lonsdale.mil@mail.mil David.a.hugueley.mil@mail.mil (g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact. SMSgt Amanda Lonsdale

79

918-833-7305 Amanda.j.lonsdale.mil@mail.mil (2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988. (End of clause)

80

Section 01 00 00 - General Requirements LOCAL ENVIRONMENTAL REGULATION

SECTION– EMS ENVIRONMENTAL PROTECTION

PART 1 – GENERAL 1. SCOPE OF WORK

1.1. The work covered by this section concerns the furnishing all labor, materials, and equipment required for the prevention of environmental degradation during, and as a result of, construction operations under this contract.

1.2. For the purpose of this specification, environmental pollution is defined as “the presence of chemical, physical, or biological elements or agents, not naturally occurring at the site, which adversely affect human health or welfare; unfavorable alter ecological balances important to human life; affect other species of importance to man; or degrade the utility of the environment for aesthetic and recreational purposes.”

1.3. The control of environmental pollution by this Project Contractor requires consideration of air, water, and land and involves noise control, solid waste management and management of radiant energy and radioactive materials, as well as other pollutants.

1.4. This section also requires the protection of cultural and historic resources. 1.5. The provisions listed herein are incorporated by reference to all construction projects

and are in addition to the general environmental, safety, and occupational health clauses of the Federal Acquisition Regulations (FAR). References to “EM” identify the Wing’s Environmental Manager.

1.6. Contact the Contracting Officer’s Representative, concerning the content of these requirements.

2. Base Environmental Commitment Statement Visa Vie Contractor Responsibilities

2.1. Environmental Policy Statement and Environmental Management System (EMS) 2.1.1. The Wing commander’s environmental policy applies to everyone working at the

138th Fighter Wing including designers and contractors. 2.1.2. The Wing’s Environmental Management System is a continuous process designed

to identify, prioritize, manage, and check progress towards meeting the Wing’s organizational and environmental goals, minimizing environmental risk, and identifying areas for continual improvement.

2.1.3. The environmental policy statement and EMS will be briefed at all pre-construction meetings.

2.1.4. A copy of the 138th FW’s Environmental Policy Statement will be provided by contracting officer.

3. Contractor’s General Environmental Compliance Obligation

3.1. Contractor and any subcontractor, agent or representative shall comply with all applicable Federal, State, and local laws and regulations providing for environmental protection and pollution control and abatement including but not limited to the following:

3.1.1. Clean Air Act (CAA); 3.1.2. Clean Water Act (CWA); 3.1.3. Resource Conservation and Recovery Act (RCRA);

81

3.1.4. Comprehensive Environmental Response, Compensation and Liability Act (CERCLA);

3.1.5. Toxic Substances Control Act (TSCA); 3.1.6. Federal Insecticide Fungicide and Rodenticide Act (FIFRA); 3.1.7. Coastal Zone Management Act (CZMA); 3.1.8. Endangered Species Act (ESA); 3.1.9. National Historic Preservation Act (NHPA); 3.1.10. Safe Drinking Water Act (SDWA); 3.1.11. National Pollutant Discharge Elimination System (NPDES) 3.1.12. Emergency Planning and Community Right-to-Know Act (EPCRA); 3.1.13. Oil Pollution Act (OPA) and; 3.1.14. Pollution Prevention Act (PPA).

3.2. Contractor is responsible for determining where such laws and regulations apply, although Contractor may request assistance from the CRO in delineating applicable environmental laws and regulations. Contractor has an independent responsibility to make its own determination and to do so in a timely fashion.

3.3. Hazardous Material Spills: Spills shall be immediately contained, if possible, and reported to the COR. The COR will advise Base Civil Engineer (BCE) and Environmental Manager (CEV) for Tulsa IAP (hereafter referred to as the “Base” or Tulsa IAP) and the Contracting Officer. Spills shall be conducted according to the Base Spill Response RED PLAN (Provided at the Pre-Construction Conference).

3.4. Contractor shall not discharge anything into the Base’s sanitary sewer or storm water systems without coordination and approval from COR who will coordinate with the Base Civil Engineer and Base Environmental Manager.

3.5. The Base Civil Engineer and Base Environmental Manager may conduct inspections without notice at on-base work sites to ensure environmental compliance. Any items of non-compliance will be reported to the Contracting Officer for action.

4. CONTACTS WITH ENVIRONMENTAL REGULATORY OFFICIALS

4.1. Contractor shall, through the Contracting Officer, immediately advise the installation environmental management function of the content of all contact with federal, state or local environmental regulators, before during and after the performance of this contract concerning the performance of this contract.

5. CONTRACTOR’S LIABILITY FOR ENVIRONMENTAL DAMAGES

5.1. Contractor agrees to hold harmless and indemnify the Air Force for any and all damages of any kind resulting from environmental violations by Contractor, Contractor’s employees, or agents or subcontractors.

5.1.1. Damages include, but are not limited to, personal injury, property damage (including diminution of value), or death, environmental restoration and response costs, natural resource damages, expert witness and attorney’s fees.

5.1.2. Reimbursement of any and all expenses incurred to obtain permits as a result of Contractor’s failure to identify or obtain permits shall be borne by the Contractor.

82

5.2. FINES OR PENALTIES FOR ENVIRONMENTAL NON-COMPLIANCE 5.2.1. Contractor shall be responsible for paying any fines or penalties assessed against

the Air Force for environmental violations resulting from acts or omissions of Contractor or its employees, subcontractors, or agents.

5.2.1.1. This obligation is in addition to any fines or penalties that may be assessed against Contractor for the same conduct.

5.2.1.2. Contractor may either reimburse these fines or penalties through the Contracting Officer, or with the consent of the Base Civil Engineer, conveyed through the Contracting Officer, Contractor may pay such fines or penalties directly to the regulatory agency or agencies concerned.

5.3. WASTE DISPOSAL FOR CONTRACTS TO BE PERFORMED ON GOVERNMENT FACILITIES

5.3.1. Hazardous Waste Generation, Handling and Disposal: Work under this contract is to be performed on a government facility. According to rules and procedures of the United States Environmental Protection Agency (EPA), a federal facility is required to have a generator identification number under the Resource Conservation and Recovery Act (RCRA) and to be responsible for hazardous wastes (as defined under RCRA) produced, managed, stored, disposed on or transported from the facility.

5.3.1.1. Contractor will, to the greatest extent practicable, use materials, processes and techniques that will avoid the creation of hazardous waste.

5.3.1.2. The Department of Defense (DOD) Solid Waste Measure of Merit (MoM) requires the Air Force to report all solid waste that is disposed in landfills, and, also diverted from landfills through reuse or recycling. Of the inevitable waste that is generated, as many of the waste materials as is economically feasible shall be reused, salvaged or recycled and reported to the base environmental manager as required. Waste disposal in landfills shall be minimized, these waste will be recorded and submitted as required to the base environmental manager.

5.3.1.3. With regard to this directive, the Contractor shall develop a written Waste Management Plan for this Project prior to the generation of hazardous materials and hazardous waste resulting from demolition and new construction. This plan, including disposal policies, shall be reviewed and approved by both the Contracting Officer and the Base Civil Engineer before such activities begin.

5.3.1.4. Contractor shall follow this plan once it has been approved by the Contracting Officer. Contractor shall coordinate all planned activities regarding hazardous materials and hazardous waste with the Base Civil Engineer office through the Contracting Officer.

5.3.1.5. Under no circumstances will the Contractor bring hazardous waste onto the facility.

5.4. Waste Management Plan:

5.4.1. Draft of Plan: Within FIFTEEN (15) CALANDAR DAYS after receipt of the Notice to Proceed, or prior to a waste removal, whichever occurs first, the Contractor shall submit to the Contracting Officer a draft of the Waste Management

83

Plan for review by the Base Environmental Manager. This draft plan shall contain the following:

5.4.1.1. Analysis of the jobsite waste that is anticipated to be generated, including types of materials and their quantities; A manifest will be generated for each load off base, an electronic copy shall be provided to the CRO and approved and signed by the base CEV for approval prior to its departure from the base. This will carry forward until the end of the job.

5.4.1.2. The name of the landfill(s) where trash will be disposed of, the applicable landfill tipping fee(s), and the projected cost of disposing of all Project waste in the landfill(s).

5.4.1.3. Alternates to Landfilling: Contractor to provide a list of each material proposed to be salvaged, reused or recycled during the course of the Project, the probable local market for each material, and the projected net cost savings or additional costs resulting from separating and recycling, versus landing, of each material.

5.4.1.3.1. “Net” means that the materials listed below have been subtracted from the cost of separating and recycling, including revenues from the sale of recycle or salvaged materials and landfill tipping fees saved due to diversion of materials from the landfill.

5.4.1.4. Materials Effected: The list of materials is to include, at a minimum, the following items:

Aluminum; Asphalt; Beverage containers; Brass; Bricks; Bronze; Cardboard; Clean dimensional lumber; Concrete; Concrete masonry units (CMU);

Copper; Galvanized sheet metal; Land clearing debris; Lead; Metals from banding, stud trim, ductwork, piping, reinforcing rods, roofing, other trim, steel, iron; Stainless steel; and Zinc;

5.4.1.5. Final Waste Management Plan: Once the Contracting Officer has determined which of the recycling options listed in the draft Waste Management Plan are acceptable, the Contractor shall submit, within TEN (10) CALANDAR DAYS, a Final Waste Management Plan. The Waste Management Plan shall be implemented in the following fashion:

5.4.1.5.1. Manager: Contractor shall designate an on-site party or parties to be responsible for instructing workers, and overseeing and documenting results of the Waste Management Plan.

5.4.1.5.2. Distribution: Contractor shall distribute copies of the Waste Management Plan to the Job Site foreman, each Subcontractor, the Contracting Officer and the Contracting Officer’s Representative

5.4.1.5.3. Instruction: Contractor shall provide on-site training on appropriate separation, handling and recycling procedures, as well as instruction on salvage, reuse and return of materials to be used by all parties at appropriate stages of the Project.

5.4.1.5.4. Separation Facilities: Contractor shall lay out and label a specific area of the job-site to facilitate separation of materials for potential recycling, salvage, reuse or return.

84

Recycling and waste bin areas are to be kept clean and clearly marked as to contents in order to avoid contamination of materials.

5.4.1.5.5. Hazardous Materials: Such materials shall be separated, stored and legally disposed of according to local regulations.

5.4.1.5.6. Documentation of Compliance: Contractor shall submit with each Application for Progress Payment a Summary of Waste Generated by the Project. Failure to submit this information shall render the Application for Payment incomplete and shall delay Progress Payments. The Summary shall be submitted on a form ascertainable to the contracting Officer, and shall contain the following information:

5.4.1.5.6.1. The amount in tons or cubic yards of material land filled from the Project, the identity of the landfill(s), the total amount of tipping fees paid at the landfill(s), and total disposal costs; include manifests, weight tickets, receipts and invoices.

5.4.1.5.6.2. For each material recycled, reused or salvaged from the Project, the amount in tons or cubic yards, the date removed for the Job Site, the receiving party, the transportation costs, the amount of any money paid or received for the recycled or salvaged materials, and the net cost or savings of salvage or recycling each material. Attach manifests, weight tickets, receipts and invoices. Failure to submit this information

5.4.1.5.7. Contractor shall follow this Plan without deviation once Contracting Officer has approved it. Such wastes will not be created until the Waste Management Plan has been approved by the Contracting Officer.

PART 2 – PERMITS FOR CONSTRUCTION WORK ON A GOVERNMENT INSTALLATION 6. GENERAL: CONSTRUCTION, EXCAVATION, MODIFICATION, RENOVATION,

DEMOLITION, INSTALLATION, OR OTHER ALTERATION OF BUILDING STRUCTURES, EQUIPMENT, INSTALLATIONS, REAL PROPERTY, OR SYSTEMS ON A GOVERNMENT INSTALLATION 6.1. General: Activities such as excavation, demolition, building modification or renovation, equipment

installation or other alteration of building structures, equipment, real estate or systems require permits to allow that work to occur. Required environmental permits include (but are not limited to):

6.1.1. Air Program 6.1.1.1. Permit-by-rule notification for emergency generators over 50 BHP 6.1.1.2. Permit-by-rule notification for boilers/furnaces over 10 MMBTU per hour 6.1.1.3. Permit-to-install/permit-to-operate for spray paint booths fugitive emissions sources, etc.

6.1.2. Sanitary Sewage 6.1.2.1. PTI/PTO for new sanitary sewage service connections, lift stations; a PTI/PTO is

typically not required for interior renovation where a new service connection is not installed 6.1.3. Storm Water

6.1.3.1. Notice of Intent (NOI) for construction storm water discharge 6.1.4. Wetlands

6.1.4.1. Wetlands 401/404 permits 6.1.4.1.1. Contractor shall, after consultation as with the Base Civil Engineer, identify all

Federal, State or Local permit requirements under all applicable environmental laws and regulations. Contractor shall then prepare and submit in draft all applicable permit applications and all supporting data to the Contracting Officer, who will submit these documents to the Base Civil Engineer. No project site work shall start until all required environmental permits have been submitted to, and approved by, the appropriate regulatory agency. All permits will be managed as part of the construction contract. Applications for permits that must be submitted by Contractor will be returned to Contractor after review.

85

7. COMPLIANCE WITH EXISTING INSTALLATION-HELD PERMITS

7.1. Contractor shall provide the Contracting Officer with notice of any activities it plans to undertake which may require the Base Civil Engineer to perform any action regarding these permits such as requesting a permit modification or reporting of required information.

7.2. Contractor will provide such notice as far in advance of planned activity as is practicable.

8. Demolition Work 8.1. Contractor will divert recyclable construction debris to the maximum extent possible. 8.2. Contractor will coordinate with EM prior to any hazardous waste (HW) or universal waste (UW)

disposal actions; EM will be present anytime HW or UW is removed from the installation and will sign the manifest documents as the “generator”. Contractor will provide copies of all disposal documents and manifests.

8.3. Contractor will pay for containerization (drums, boxes, tubes, etc.) and disposal of all HW or UW items generated as part of the project, to include demolition.

8.4. Contractor will treat and dispose of all lighting lamps removed from facilities for disposal as universal waste. Lamps include fluorescent tubes, mercury, high pressure sodium, etc. Lamps will be collected in appropriately labeled cardboard tubes or boxes. Lamps will not be disposed of in Contractor dumpsters.

8.5. Contractor will verify that small capacitors (lighting ballasts weighing less than 3 lbs) are PCB-free prior to disposal. Small capacitors that do not have a “PCB-Free” statement will be treated as “PCB-contaminated waste” and collected and disposed of accordingly. Non-PCB small capacitors will be disposed of at the Contractor’s discretion.

8.6. Contractor will treat and dispose of mercury switches, thermostats, etc. as universal waste; mercury-containing items will be collected in appropriately labeled boxes, drums, or other approved DoT containers. Mercury-containing items will not be disposed of in Contractor dumpsters.

8.7. When feasible, Contractor will work with EM to recycle recoverable materials (scrap metal). Any materials not recycled by EM will be the responsibility of the contractor to recycle or otherwise dispose of.

8.8. Contractor shall track off-site diversion and disposal of demolition debris. At the end of the project, EM will be provided with the following:

8.8.1. Tons of demolition debris diverted (materials recycled or otherwise re-used) 8.8.2. Tons of demolition debris disposed of by landfill or other means

9. PART 2 - MATERIALS

9.1. RECYCLED MATERIALS: Materials used in this contract shall be, to the greatest extent practicable and consistent with financial prudence, made of recycled materials or with materials that are recyclable.

9.2. ASBESTOS: No asbestos containing materials for any project shall be brought onto the Base. Should this be discovered, the Contractor shall be solely responsible for all and any cost associated with the removal and subsequent corrective measures taken to correct the mishap.

9.2.1.1. Removal of asbestos material will be included in the project as required. 9.2.2. The 138th Base Asbestos Management Plan has identified known ACM on the installation.

During the Investigative survey there were 14 buildings suspected to contain ACM. Thru testing this was narrowed to 4 facilities. Known ACM on the installation includes:

9.2.2.1. Facility 311-Thermal wrap on Domestic Cold Water Lines 9.2.2.2. Facility 401-Thermal wrap on Domestic Cold Water Lines 9.2.2.3. Facility 402- Thermal wrap on Domestic Cold Water Lines in walls North end of facility. 9.2.2.4. Facility 501- Thermal wrap on Hot Water Return Fittings and Transite wall board.

9.2.3. As the survey was of a Non-Destructive nature, such things as walls were not penetrated to determine whether or not there are hidden ACM. In addition, due to the type of destructive sampling required to sample roofing materials, there was not testing completed on the roofing

86

systems. Therefore if the above areas are involved in major renovations or demolitions additional sampling for the presence of ACM may be required.

9.2.4. The following structures were constructed before 1980 and have the potential of containing lead in any painted surface including structural metals, wood and wood trim, and wallboard: Building 301, 302, 304, 313, 314, 320, 401, 402, 403, 406, 407, 410, & 501

9.2.5. Additional information is available in the “Asbestos Management Plan” for Tulsa IAP published by the Air National Guard, Civil Engineering Services Center, Minot, North Dakota. Copies of this report can be obtained through the Civil Engineering Operations function.

9.2.5.1. This report is part of the Bidding Documents if required. 9.2.5.2. Asbestos abatement work shall also comply with the Oklahoma Asbestos Control Act

(Title 40 § 450-456 Abatement of Friable Asbestos Materials Rules 380:50-1-1 through 380:50-29-1).

9.2.5.3. Oklahoma Department of Labor, Asbestos Division – (888) 269-5353, (405) 521-6467 9.3. POLYCHLORINATED BIPHENYL’S (PCBS) PCBs will not be used or included in the new

construction portion of this project. 9.4. LEAD-BASED PAINT:

9.4.1. No lead based paint containing materials for any project shall be brought onto the Base. Should this be discovered, the Contractor shall be solely responsible for all and any cost associated with the removal and subsequent corrective measures taken to correct the mishap. The following structures were constructed before 1980 and have the potential of containing lead in any painted surface including structural metals, wood and wood trim, and wallboard: Bldg 301, 302, 304, 313, 314, 320, 401, 402, 403, 406, 407, 410, & 501

9.4.2. If the presence of lead-based paint is encountered during the building demolition or renovation portion of this project, communicate with the Contracting Officer’s Representative and Base Environmental Officer. A subsequent change order upon confirmation will be submitted to the Contracting Officer. Related lead-based paint management procedures will be performed in accordance with applicable regulations, including, but not limited to, those established by the following agencies and governmental acts:

9.4.2.1. Oklahoma Department of Environmental Quality, Air Quality Division, Lead-Based Paint/Work Practice Standards, (405) 702-4100.

9.4.2.2. Section V, Chapter 3 of the Technical Manual of the Occupational Safety and Health Administration (OSHA), dealing with controlling lead exposures in the construction Industry, in regards to engineering and work practice controls.

9.4.2.2.1. National Environmental Policy Act (NEPA). 9.5. OZONE-DEPLETING SUBSTANCES:

9.5.1. “Class I substance,” as used in this clause means any substance designated as class I by the Environmental Protection Agency (EPA) (40 CFR Part 82), including but not limited to chlorofluorocarbons, halos; carbon tetrachloride and methyl chloroform.

9.5.2. “Class II substance,” as used in this clauses means any substance designated as class II by EPA (40 CFR Part 82), including but not limited to hydro-chlorofluorocarbons.

9.5.3. As required by 42 USC 7671j(b), (g) and (d) and 40 CFR Part 82, Subpart E. Contractor shall label products which contain Class I or Class II ozone-depleting substances or are manufactured with a process that uses Class I or Class II ozone-depleting substances, or containers of Class I or Class II ozone-depleting substances as follows:

9.5.3.1. “WARNING: Contains (or manufactured with, if applicable). ________ * ________ (a) substance(s) which harm(s) public health and the environment by destroying ozone in the upper atmosphere.” *Contractor shall insert the name of the substance(s).

9.5.3.2. “Contractor shall ensure no Class I or Class II ozone-depleting substances are used on Tulsa IAP without prior approval of the Base Civil Engineer.

87

9.5.3.3. “”Contractor shall comply with the applicable requirement of Sections 608 and 609 of the Clean Air Act (42 IS 7671g, National Recycling and Emission Reduction Program and 7671h. Servicing of Motor Vehicle Air Conditioners) as each or both apply to the contract.””

9.6. PESTICIDES 9.6.1. Except as may be specified elsewhere in this contract, Contractor will not apply any pesticides

such as herbicides (weed-killers), insecticides, or rodenticides, without the specific written prior approval of the Base Civil Engineer. When approved, all applications shall conform and reports shall be submitted to the base pest control manager upon his direction.

10. HAZARDOUS MATERIALS MANAGEMENT 10.1. All hazardous materials used on-site by the Contractor are subject to government review

and tracking. For each hazardous material to be used on site, the Contractor will provide the following as part of the normal project material submittal and approval process:

10.1.1. A current Safety data Sheet (SDS) for each item proposed for use. 10.1.2. A completed “Hazmat Authorization for Contractors” form. This form requires the following

information for each hazmat item: 10.1.2.1. Material to be used 10.1.2.2. Manufacturer and stock/part number 10.1.2.3. Material unit if issue (5 gallon bucket, 55-gallon drum, etc) 10.1.2.4. Quantity of material to be used 10.1.2.5. Frequency of use (i.e. one-time for one day, or daily for the duration of the project) 10.1.2.6. Location of use 10.1.2.7. Brief description of use (process use) 10.1.2.8. Storage location 10.1.2.9. Intended disposal

10.1.3. Environmental, Safety, and Occupational Health (ESOH) Offices will review for general conformity with AF/ANG goals only. Material reviews are intended to identify hazardous materials for regulatory reporting under the Emergency Planning and Community Right-to-Know Act (EPCRA) and to ensure the health and safety of government employees. Reviews are not evaluation or approval of the contractor’s environmental, health, and safety program nor an indication that the material meets the intent of the project plans and specifications. ESOH offices will request product substitutions through the Contracting Officer, as needed.

10.1.4. Contractor will not deliver, store, or use any hazardous material on the installation until it has been reviewed by the ESOH offices.

10.1.5. At project close-out, Contractor shall provide a final list of all hazardous materials used on site using the “Contractor Hazmat Use Summary” form.

11. PART 3 – EXECUTION

11.1. PROTECTION OF WATER RESOURCES 11.1.1. General: Contractor shall not pollute storm drainage ways, streams, lakes or reservoirs with

fuels, oils, bitumen, calcium chloride, acids, construction wastes or other harmful materials. It is the responsibility of Contractor to investigate and comply with all applicable federal, state and municipal regulations.

11.1.1.1. Contractor shall take particular care to prevent chemical, fuels, oils, greases, bituminous materials, waste washings, herbicides, cement and surface drainage from entering public waters.

11.1.1.2. Waste and Curing Water: Water used in aggregate processing, concrete curing, foundation and concrete lift clean-up and other waste water shall not be allowed to enter the storm drainage system. These materials shall be placed in a secure wash out area suitable for removal at the end of the job.

88

11.1.1.2.1. In the event of a spill the Base Fire Department and Environmental Office shall be notified immediately. Subsequent communication shall be accomplished to the Contracting Officer’s Representative who will notify the Contracting Officer of the mishap.

11.1.2. Contractor will provide secondary containment of any temporary drums or tanks used during the construction process (ex. Lubricating oil, gasoline and diesel skid tanks, etc.)

11.1.3. If the contractor has contractor-owned containers totaling 1320 gallons or more (calculated as either the capacity of a single large tank or multiple smaller tanks), the contractor shall be required to develop a site-specific Spill Prevention, Control & Countermeasures (SPCC) plans in accordance with the provisions of 40 CFR 112.

11.1.4. Contractor will provide materials, supplies, and equipment to respond to spills and leaks caused by contractor personnel. The contractor will promptly and properly remediate accidental spills and leaks.

11.1.5. Contractor will replace in-kind any Government-owned spill response materials and supplies used to mitigate a contractor spill.

11.2. SECONDARY CONTAINMENT STRUCTURES AND STORAGE TANK PROJECTS 11.2.1. Provide technical amendment to the base SPCC plan certified by a Oklahoma Licensed

Professional Engineer for tank installation, maintenance or repair that meets the definition of “technical change” in accordance with 40 CFR Part 112 within 30 days of completion of project.

11.2.2. If a double-walled, above-ground storage tank is specified for secondary containment, Contractor will insure that all drains and plugs are clearly labeled (i.e. drains for the primary vessel, interstitial space, etc.). The drain for the interstitial space will be provided with a manual, lockable globe valve so this space can be periodically checked for fluids. The tank will be clearly labeled with the contents, capacity, appropriate safety and fire labels, and emergency contact numbers.

11.2.3. Prepare and obtain state or local agencies a notice of intent, when required, to install a tank before starting construction. A copy of all regulatory documentation will be provided to the contracting officer to forward to the environmental manager.

11.2.4. Obtain proper notification and certification forms including necessary construction and operating permits from the appropriate regulatory agency.

11.2.5. Use qualified personnel licensed by state agencies to perform repairs on all USTs if required by state regulations and authorized inspectors to certify repairs were performed on ASTs.

11.2.6. Ensure certified strapping charts are provided for all procured tanks IAW UFC 460-01, Chapter 8.

11.2.7. Repair petroleum storage and dispensing systems including appurtenances IAW all federal, state, local requirements and per UFC 3-460-03, Operations and Maintenance: Maintenance of Petroleum Systems.

11.2.8. Ensure cathodic protection for tank systems are installed in accordance with AFI 32-1054, Corrosion Control.

11.2.9. Ensure new diking and containment construction is in accordance with UFC 3-460-01 and Oklahoma performance standards.

11.2.10. Provide certification from tank installer that tank was installed according to applicable codes and standards.

11.2.11. Only an authorized inspector shall provide formal internal and external inspections of all field erected ASTs IAW API 653.

11.2.12. Meet applicable federal, state and local regulatory requirements for temporary deactivation and permanent closure.

12. POLLUTION PREVENTION 12.1. General: Contractor should use prior planning to find those materials that will minimize the

creation of waste in general and hazardous waste in particular.

89

13. UNEXPECTED SIDE CONDITIONS

13.1. Contaminated Soil or Groundwater: Unless otherwise specified elsewhere in the Contract Documents, the job-site has been inspected and is, consistent with best professional judgment, free of environmental contamination or pollution.

13.1.1. However, unexpected conditions can always arise. Contractor or subcontractor personnel may encounter soil or groundwater that is suspected to be contaminated, either because of odors, colors, free liquids or other suspicious conditions.

13.1.1.1. Should this occur, Contractor will immediately notify the Base Civil Engineer and the Base Environmental Manager and take necessary initial measures to protect workers, the site and other personnel.

13.2. Unexploded Munitions/Ordnance (UXO): No munitions or munitions-related materials are known or expected to be present on site. However, should suspected munitions-type material be encountered, Contractor should immediately Stop Work, Turn Off and Leave Equipment where it Rests, and Remove all personnel from the area and notify Explosive Ordinance Disposal (EOD) and receive advice before disturbing the questionable material.

14. SITE DISTURBANCE DURING CONSTRUCTION ACTIVITIES 14.1. Contractor shall use industry-recognized best management practices to avoid creation of fugitive

dust emissions, and to avoid and control storm water runoff from the construction site and any temporary roads that may be used for access to it.

14.1.1. Water sprinkling may be used to control dust. 14.1.2. Contractor shall perform all work under this contract in such a manner that no pollutants of any

kind are released into ditches, storm drains, streams, lakes or other surface waters of the site.

15. PROTECTION OF LAND RESOURCES 15.1. General: It is intended that the land resources within the project boundaries and outside the limits

of permanent work performed under this Contract be preserved in their present condition, or be restored to a condition after completion of construction that will appear to the natural and not detract from the appearance of the project. Contractor shall limit his construction activities to those areas defined by the Drawings or Specifications.

15.2. Prevention of Landscape Defacement: Except in area marked on the plans to be cleared, Contractor shall not deface, remove, cut, injure or destroy trees or shrubs without special authority.

15.2.1. Trees designated to be saved shall be protected from either excavation or filling within the root zone.

15.2.2. No ropes, cables or guys shall be fastened or attached to any existing trees for anchorage unless specifically authorized by the Contracting Officer.

15.2.3. Contractor shall, in any event, be responsible for any damage resulting from such use.

15.3. Restoration of Landscape Damage: Any trees or other landscape features scarred or damaged by Contractor s equipment or operations shall be restored as nearly as possible to the original condition at Contractor’s expense.

15.3.1. The Contracting Officer will decide what method of restoration shall be used, and whether damaged trees shall be treated and heeled or removed and disposed of.

15.3.2. All scars made on trees not designated on the plans to be removed by equipment construction operations or by the removal of limbs larger than 1-inch in diameter shall be coated immediately with an approved tree wound dressing.

15.3.3. Experienced landscape personnel shall perform all trimming or pruning in an approved manner. Tree trimming with axes shall not be permitted.

90

15.3.4. Trees that are to remaining either within or outside established clearing limits that are subsequently damaged by Contractor, and that are beyond saving in the opinion of the Contracting Officer shall be immediately removed and replaced with a nursery-grown tree of the same species.

16. STORMWATER PERMITS FOR CONSTRUCTION

16.1. General: Permits required for the discharge of stormwater associated with construction activities. 16.2. STORMWATER DISCHARGES FROM SMALL CONSTRUCTION ACTIVITIES

16.2.1. All projects disturbing one (1) or more acre of land will require a site-specific Storm Water Pollution Prevention Plan (SWP3). Generic plans or “corporate” plans are not acceptable. For projects disturbing an area smaller than (1) acre, a SWP3 will not be required unless the smaller project is part of an overall construction program disturbing over one acre. The requirement for a SWP3 for these projects (< 1acre) will be addressed on a case-by-case basis.

16.2.1.1. If Contracted the Designer will develop a site-specific SWP3 in accordance with the requirements of Part III of Oklahoma EPA Permit Number OK0040819 Authorization for Storm Water Discharges Associated with Construction Activity under the National Pollutant Discharge Elimination System. Further guidance on developing the SWP3 can be found in the Oklahoma Department of Environmental Quality webpage. The SWP3 submitted will be evaluated using the OAC 252:606, Oklahoma Pollutant Discharge Elimination Standards. If the design is contracted the Designer will identify specific sections of the SWP3 that must be completed by the Contractor (i.e. project phasing and dates, specific controls to be used, etc.). If the design is in house the Contractor shall be responsible for the SWP3 in its entirety.

16.2.1.2. The SWP3 will be reviewed and signed by the Project Engineer, Contractor and EM prior to the start of any site work.

16.2.1.3. If Contracted the Designer and Contractor shall jointly develop the regulatory Notice of Intent (NOI) for construction greater than one (1) acre in size in accordance with the requirements of section 2. of this guide. If Design is not contracted the Construction Contractor is responsible for the plan in its entirety.

16.3. All storm water general permits may be obtained by submitting a one page application, Notice of Intent (NOI), and terminated by submitting a Notice of Termination (NOT) to the ODEQ. I copy of the documents once approved will be forwarded to the Contracting Officer. Information more specific to each General Permit can be found on their respective web pages. Storm Water General Permit for Construction Activities

16.4. http://www.deq.state.ok.us/WQDnew/stormwater/index.html 16.4.1.1. Notice of Intent 16.4.1.2. Notice of Change, which is used if the operator becomes aware of failing to submit

any relevant information or submitting incorrect information. 16.4.1.3. Notice of Termination

17. PROJECT CLOSE-OUT

17.1. Unless otherwise specified, the Contractor shall remove all excess and waste materials from the project site.

17.2. EM personnel will accompany Project Engineer and Contracting Officer during close-out inspections to ensure compliance.

91

HAZMAT AUTHORIZATION FOR CONTRACTORS

NO HAZARDOUS MATERIAL WILL BE DELIVERED, STORED, OR USED ON-SITE

UNTIL IT HAS BEEN AUTHORIZED BY ENVIRONMENTAL, SAFETY, AND

OCCUPATIONAL HEALTH

Project:

Contractor:

Contractor will provide ALL of the information required below for each hazardous material (hazmat)item used on the job site; this form will be submitted to the Contracting Officer

Attach a current Material Safety Data Sheet (MSDS) for each item A copy of this form will be return to the contractor after all reviews have been completed At project close-out, provide the ACTUAL quantity of the item used during the project on the Hazmat

Use Summary Form This authorization is used strictly to gather information on hazardous materials usage to address regulatoryreporting requirements, as well as ensure the health and safety of government employees. This authorizationis NOT:

An indication that the material meets the intent of the project plans and specifications An evaluation or approval of the contractor’s environmental, safety, or health programs

Product Name:

Product Part/Stock Number:

Material Unit of Issue (55-gallon drum, 5-gallon pail, 16 oz. box, 10 lb. bag, etc.):

Storage Location:

Frequency of Use (one-time, one week, throughoutproject):

Location of Use (if other than on the immediate project site):

Proposed Quantity of Material to be Used On-Site (gallons, pounds, etc.): Brief Description of Use (what is the hazmat being used for):

Intended Disposal (how will excess material, empty containers, and clean up materials be disposed of):

FOR ESOH OFFICE USE (use reverse if needed) This item is exempt from Hazmart tracking; no further evaluation required; contractor does not

need to track use Authorized Bioenvironmental Engineering - Comments

Authorized with comment

Change requested Signature

92

Authorized Environmental Management - Comments

Subject to EPCRA 312

Subject to EPCRA 313 Authorized with

comment Change requested

Signature

Authorized Safety/Fire Protection - Comments

Authorized with comment

Change requested Signature

ADDITIONAL COMMENTS

W912L6-17-B-0012

Page 93 of 99

CONTRACTOR HAZMAT USE SUMMARY

Contractor will provide ALL of the information required below for each hazardous material (hazmat) item used on the job site; this form will be submitted to the Contracting Officer

Provide enough information that quantities can be converted to total pounds.

Product Name:

Product Part/Stock Number:

Material Unit of Issue (55-gallon drum, 5-gallon pail, 16 oz box, 10 lbs bag, etc.):

ACTUAL total quantity of product used throughout the project

END OF SECTION DBA WAGE ACT REQUIREMENT General Decision Number: OK170053 07/21/2017 OK53 Superseded General Decision Number: OK20160053 State: Oklahoma Construction Type: Building Building Construction -does not include residential construction consisting of single family homes and apartments up to and including 4 stories. (Including building projects on industrial sites and treatment plants)

W912L6-17-B-0012

Page 94 of 99

County: Tulsa County in Oklahoma. Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.20 for calendar year 2017 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.20 (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2017. The EO minimum wage rate will be adjusted annually. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts. Modification Number Publication Date 0 01/06/2017 1 02/03/2017 2 06/02/2017 3 07/21/2017 BROK0005-004 06/01/2016 Rates Fringes BRICKLAYER.......................$ 23.34 9.01 ---------------------------------------------------------------- ELEC0584-006 05/29/2017 Rates Fringes ELECTRICIAN (Excludes Low Voltage Wiring and Installation of Alarms and Sound and Communication Systems).........................$ 29.73 7%+9.50 ---------------------------------------------------------------- ELEV0083-003 01/01/2017 Rates Fringes ELEVATOR MECHANIC................$ 38.25 31.585+a+b PAID HOLIDAYS: a. New Year's Day, Memorial Day, Independence Day, Labor Day, Veteran's Day, Thanksgiving Day, the Friday after Thanksgiving, and Christmas Day. b. Employer contributes 8% of regular hourly rate to vacation pay credit for employee who has worked in business more than 5 years; 6% for less than 5 years' service. ---------------------------------------------------------------- ENGI0627-020 06/01/2016 Rates Fringes POWER EQUIPMENT OPERATOR:

W912L6-17-B-0012

Page 95 of 99

Group 1.....................$ 28.05 12.58 Group 2.....................$ 26.35 12.58 Group 3.....................$ 25.80 12.58 Group 4.....................$ 25.05 12.58 Group 8.....................$ 22.10 12.58 Group10.....................$ 21.10 12.58 POWER EQUIPMENT OPERATOR GROUP 1: All Crane Type Equipment 200 ton and larger and including 400 ton capacity cranes. All Tower Cranes. GROUP 2: All Crane Type Equipment 100 ton capacity and larger cranes, and less than 200 ton capacity. GROUP 3: All Crane Type Equipment 50 ton capacity and larger cranes, and less than 100 ton capacity. Crane Equipment (as rated by mfg.) 3 cu. yd. and over Guy derrick Whirley Power Driven Hole Digger (with 30' and longer mast). GROUP 4: CRANES with Boom Incl. Jib less than 100 ft and less than 3 cu. Yd.; Overhead Monorail Crane GROUP 8: FORK-LIFT GROUP 10:OILER; SEMI-TRAILER TRUCK DRIVER ---------------------------------------------------------------- IRON0584-025 06/01/2015 Rates Fringes IRONWORKER (Ornamental, Reinforcing and Structural)......$ 24.00 13.53 ---------------------------------------------------------------- PLUM0430-010 07/01/2016 Rates Fringes PLUMBER (Excludes HVAC Pipe and Unit Installation)...........$ 30.75 13.13 ---------------------------------------------------------------- PLUM0430-019 07/01/2016 Rates Fringes HVAC MECHANIC (Installation of HVAC Unit Only, Excludes Installation of HVAC Pipe and Duct)............................$ 30.75 13.13 ---------------------------------------------------------------- PLUM0430-020 07/01/2016 Rates Fringes PIPEFITTER (Including HVAC Pipe Installation, excluding HVAC Unit Installation)..........$ 30.75 13.13 ---------------------------------------------------------------- * ROOF0143-001 06/01/2017 Rates Fringes ROOFER...........................$ 21.05 7.62

W912L6-17-B-0012

Page 96 of 99

---------------------------------------------------------------- SHEE0270-006 06/01/2012 Rates Fringes SHEET METAL WORKER (HVAC Duct Installation Only)...............$ 30.56 11.52 ---------------------------------------------------------------- SUOK2012-033 07/30/2012 Rates Fringes CARPENTER (Drywall Hanging Only)............................$ 15.08 1.21 CARPENTER, Excludes Drywall Hanging, and Form Work...........$ 14.96 1.55 CAULKER..........................$ 20.00 1.61 CEMENT MASON/CONCRETE FINISHER...$ 13.72 1.27 DRYWALL FINISHER/TAPER...........$ 13.00 0.00 ELECTRICIAN (Alarm Installation)....................$ 19.48 3.34 ELECTRICIAN (Low Voltage Wiring)..........................$ 20.65 3.06 ELECTRICIAN (Sound and Communications Systems Installation)....................$ 21.11 2.47 FORM WORKER......................$ 12.69 0.38 LABORER: Common or General......$ 12.44 2.71 LABORER: Mason Tender - Brick...$ 12.43 0.00 LABORER: Mason Tender - Cement/Concrete..................$ 13.00 1.91 LABORER: Pipelayer..............$ 12.39 0.00 OPERATOR: Asphalt Paver.........$ 16.25 0.00 OPERATOR: Backhoe/Excavator/Trackhoe.......$ 16.96 4.22 OPERATOR: Bulldozer.............$ 21.07 2.48 OPERATOR: Grader/Blade..........$ 14.28 1.70 OPERATOR: Loader (Front End)....$ 16.18 0.00 PAINTER: Brush, Roller and Spray, Excludes Drywall Finishing/Taping.................$ 12.22 0.00 SHEET METAL WORKER, Excludes HVAC Duct Installation...........$ 22.11 4.93

W912L6-17-B-0012

Page 97 of 99

SPRINKLER FITTER (Fire Sprinklers)......................$ 21.86 1.19 TRUCK DRIVER: Dump and Flatbed Truck....................$ 11.00 0.00 ---------------------------------------------------------------- WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental. ================================================================ Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts. Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)). ---------------------------------------------------------------- The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate). Union Rate Identifiers A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the

W912L6-17-B-0012

Page 98 of 99

most current negotiated rate, which in this example is July 1, 2014. Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate. Survey Rate Identifiers Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier. Survey wage rates are not updated and remain in effect until a new survey is conducted. Union Average Rate Identifiers Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier. A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based. ---------------------------------------------------------------- WAGE DETERMINATION APPEALS PROCESS 1.) Has there been an initial decision in the matter? This can be: * an existing published wage determination * a survey underlying a wage determination * a Wage and Hour Division letter setting forth a position on a wage determination matter * a conformance (additional classification and rate) ruling On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted

W912L6-17-B-0012

Page 99 of 99

because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed. With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to: Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to: Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue. 3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to: Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 4.) All decisions by the Administrative Review Board are final. ================================================================ END OF GENERAL DECISION