SCL/PS/2017E0065901 13/05/2017 Purchase& Stores · Tender No: SCL/PS/2017E0065901 3 (c) Approximate...
Transcript of SCL/PS/2017E0065901 13/05/2017 Purchase& Stores · Tender No: SCL/PS/2017E0065901 3 (c) Approximate...
Tender No: SCL/PS/2017E0065901 1
Tender Details
Tender No: SCL/PS/2017E0065901
Tender Date: 13/05/2017
Purchase Entity: Purchase& Stores
Tender Notice
Tender No: SCL/PS/2017E0065901 2
Tender Attachments
Technical Write-up/Drawings
Attachment - I:
IDT00121900000000000isro05401.pdf
Attachment - II:
Attachment - III:
Attachment - IV:
Attachment - V:
Instructions to Tenderers (LT)
.:
1. Bids will not be entertained after the due date and time.
2. Sales Tax/ Service Tax and/or other duties/levies where legally leviable and intended to be claimed
should be distinctly shown separately in the tender.
3. (a) Your quotation should be valid for 90 days from the date of opening of the tender.
(b) Prices are required to be quoted according to the units indicated.
4. (a) All available technical literature, catalogues and other data in support of the specifications and
detail of the items should be furnished as attachments.
(b) Samples, if called for, should be submitted free of all charges by the tenderer and the Purchaser shall
not be responsible for any loss or damage thereof due to any reason whatsoever. In the event of non -
acceptance of tender, the tenderer will have to remove the samples at his own expense.
Tender No: SCL/PS/2017E0065901 3
(c) Approximate net and gross weight of the items offered shall be indicated in your offer. If dimensions
details are available the same should be indicated in your offer.
(d) Specifications: Stores offered should strictly conform to our specifications. Deviations, if any, should
be clearly indicated by the tenderer in their quotation. The tenderer should also indicate the Make/Type
number of the stores offered and provide catalogues, technical literature and samples wherever
necessary. Test certificates wherever necessary should be attached. Whenever options are called for in
our specifications, the tenderer should address all such options. Wherever specifically mentioned by us
the tenderer could suggest changes to specifications with appropriate response for the same.
5. The purchaser shall be under no obligation to accept the lowest or any tender and reserves the right
of acceptance of the whole or any part of the tender or portion of quantity offered and the tenderers
shall supply the same at the rates quoted.
6. All amounts shall be indicated both in words as well as in figures. Where there is difference between
amounts quoted in words and figures, amount quoted in words shall prevail.
7. The tenderer will be required to furnish a document containing the name of his bankers as well as the
latest income-tax clearance certificate duly counter signed by the Income-tax Officer of the Circle
concerned under the Seal of his office, if required by the Purchaser.
8. The Purchaser reserves the right to place order on the successful tenderer for additional quantities up
to 25% of the quantity offered by them at the rates quoted.
9. This being a two part tender i.e. Technical and Commercial part separate, the Technical part should
not contain Pricing information of the tendered stores. The tenders containing Price details of the
tendered stores in Technical part will be treated as unsolicited offers and rejected
Standard Terms and Conditions
.:
1. Interested tenderers may, at their option, login to http://eprocure.isro.gov.in and submit offers as per
details in the tender notification.
2. Indian agents while quoting on behalf of their principals are requested to attach necessary
authorization letter from their Principals in their bid.
3. The offer should be valid for a minimum period of 90 days from the date of opening.
4. Bids will not be entertained after the due date and time.
5. Request for the extension of the due date will not be considered.
Tender No: SCL/PS/2017E0065901 4
6. SCL reserves the right to reject the lowest or in part any bid or all bids. The Vendor is at liberty to seek
information related to bidding conditions, process and/or rejection of its bid.
Terms and Conditions - Imported Items
.:
1. The Tenderers should submit the bids through e-procurement portal http://eprocure.isro.gov in and
complete in all respects with technical specifications, including pamphlets and catalogues.
2. The bid should contain the following information:-
a. The FOB value, the C & F Value for import by Sea-Freight/ Air Freight upto and for air parcel post upto
Bangalore should be separately indicated.
b. Agency Commission: The amount of commission included in the price and payable to the Indian
Agents of the Contractor shall be directly to the Indian Agents by the purchaser in equivalent Indian
Rupees on the basis of an invoice from him applying T.T. buying rate of exchange ruling on the date of
placement of the Purchase Order and which shall not be subject to any further exchange variations. This
payment will be released to the Indian Agents within 30 days from the date of acceptance of goods.
c. The earliest delivery period and country of origin of the Stores.
d. Banker's name and address of the contractor.
e. The approximate net and gross weight and dimensions of packages/cases.
f. Recommended spares for satisfactory operation for a minimum period of one year.
g. Details of any technical service, if required for erection, assembly, commissioning and demonstration.
Tender No: SCL/PS/2017E0065901 5
3. The FOB and C & F prices quoted should be inclusive of all taxes, levies, duties arising in the tenderer’s
country.
4. The offer should be valid for a minimum period of 120 days from the due date of opening of the
tender.
5. Samples, if called for should be sent free of all charges.
6. Bids will not be entertained after the due date and time.
7. Offers made by Indian Agents on behalf of their Principals, should be supported by the necessary
authorization letter from their Principals.
8. The details of Import License will be furnished in the Purchase Order.
9. The Authority of person signing the tender, if called for, shall be produced.
10. Instruction/operation manual containing all assembly details including wiring diagrams should be
sent wherever necessary in duplicate. All documents/correspondence should be in English Language
only.
11. The Purchaser reserves the right to accept or reject the lowest or any other offer in whole or in part
without assigning any reason.
12 It is expressly agreed that the acceptance of the stores contracted for is subject to final approval in
writing by the Purchaser.
13 a. Part shipment is not allowed unless specifically agreed to by us.
Tender No: SCL/PS/2017E0065901 6
b. As far as possible, stores should be dispatched by Indian Flagged Vessels/ Air India or through any
Agency nominated by us.
14. Inspection/Test Certificates should be provided for the goods after testing it thoroughly at the
Contractor’s works. If any inspection by Lloyds or any other testing agency is considered necessary, it
shall be arranged by Contractors.
15. Where erection or assembly or commissioning is a part of the contract, it should be done
immediately on notification. The Contractor shall be responsible for any loss / damages sustained due to
delay in fulfilling this responsibility.
16. For items having shelf life / those with maximum shelf should be supplied, if order is placed.
Tender No: SCL/PS/2017E0065901 7
Bid Templates
TCAD_Specification_Silicon
Item Specifications
Sl. No Specifications Compliance (Yes /No) Offered Specifications Remarks
1 Scope: Supply, installation,
acceptance and training of
TCAD software for 2D and
3D process and device
simulation. The package
shall be supplied with
necessary modules to
meet technologies and
devices mentioned in
following sections. The
number of licenses are
mentioned separately
alongwith specifications.
This shall also include
modules to carry out
mixed-mode simulation
and evaluation of
radiation impact.
2 Technology Support: The
package shall comprise
modules to support
process and device
simulation of silicon based
technologies. This includes
a. Conventional and Power
Devices: Planar MOSFET,
Si/SiGe HBTs, Laterally
Diffused MOSFET
Tender No: SCL/PS/2017E0065901 8
(LDMOS), Insulated Gate
Bipolar Transistor (IGBT)
b. Silicon-on-Insulator
(SOI) and Advanced
Devices: Partially Depleted
(PD) MOSFET, Fully
Depleted (FD) MOSFET,
FinFET
c. Optical Detector: Charge
Coupled Device, PIN
Diode, Silicon
Photomultiplier and CMOS
Image Sensor
d. Floating Gate Non
Volatile Memory such as
Flash Memory
3 Material database: The
package shall include
a. Material database
required for process and
device simulation of
technologies mentioned in
Technology Support
section
b. Should be user-editable
Tender No: SCL/PS/2017E0065901 9
c. Provision for addition of
user-defined material
d. Sufficient licenses, if
applicable, so as not to
limit the operation of
other modules
4 Process Simulation: 2D
and 3D process simulation
to support all process and
device options mentioned
in ‘Technology Support’
section of the technical
specification (S.N. 2). The
package shall include:
a. Examples
demonstrating capability
across all technology
platforms.
b. Models and numerical
methods to efficiently and
accurately carry out
simulation of process
steps, including, but not
limited to,
i. Oxidation for oxides as
thin as 1nm, dry, wet, etc.
ii. Implantation with
Monte Carlo and
Tender No: SCL/PS/2017E0065901 10
reference library of SIMS
data
iii. Diffusion/Anneal –
Furnace and Rapid
Thermal Anneal (RTA)
iv. Silicidation – Titanium
and Cobalt
v. Geometric
photolithography, etch,
deposition and Chemical
Mechanical Planarization
(CMP)
vi. Epitaxy
vii. Stress and structural
effects
c. Data export for physical
parameters at user-
defined plane/line.
d. Seamless integration
with other modules, like,
Mask View, Visualization,
DOE, Device, etc.
e. Minimum number of
Tender No: SCL/PS/2017E0065901 11
mesh points supported
shall be one million.
Vendor should provide
maximum number of
mesh points supported.
f. The number of licenses
shall ensure three parallel
executions with all
features mentioned
above, two for 2D and one
for 3D variant. Illustration:
if 2D variant is pre-
requisite for 3D then SCL
requirement translates to
three licenses for 2D and
one for 3D, else, two
licenses of 2D and one
license of 3D shall meet
the requirement.
5 Device Simulation: 2D and
3D device simulation to
support all process and
device options mentioned
in ‘Technology Support’
section of the technical
specification (S.N. 2). The
package shall include:
a. Examples
demonstrating capability
across all technology
platforms.
b. Models and numerical
Tender No: SCL/PS/2017E0065901 12
methods to efficiently and
accurately carry out
simulation of device,
including, but not limited
to,
i. Transport models: drift-
diffusion, hydrodynamic,
energy balance
ii. Quantum effects:
Schrodinger-Poisson,
Density Gradient
iii. Self-heating and heat-
sinks
iv. Mobility models
v. Recombination models
vi. BTBT, FN and Direct
tunnelling
vii. Floating device
terminals with charge
boundary condition
viii. Impact ionization and
Hot Carrier Injection
Tender No: SCL/PS/2017E0065901 13
ix. Contact definition
(Ohmic and Schottky) with
provision to define work-
function
c. Seamless integration
with other modules, like,
Mask View, Visualization,
DOE, Process, etc.
d. Data export for physical
and electrical parameters.
e. Standard and user-
defined functions/routines
to extract physical and
electrical parameter.
f. DC, AC and transient
simulation
g. Minimum number of
mesh points supported
shall be one million.
Vendor should provide
maximum number of
mesh points supported.
h. The number of licenses
shall ensure five parallel
executions with all
features mentioned
Tender No: SCL/PS/2017E0065901 14
above, four for 2D and one
for 3D variant. For
illustration, please refer
S.N.4f.
6 Mixed-Mode and
Radiation Impact
Simulation:
a. 2D and 3D mixed-mode
simulation for circuits
comprising of compact
model devices in
combination with physical
device. The module shall
support the simulation of
circuit that include upto
four physical devices. The
vendor should provide
maximum number of
devices supported.
b. 3D Simulation for
radiation effects, namely,
SEE (SEU, SET & SEL), TID
and Dose Rate
c. Minimum number of
mesh points supported
shall be one million.
Vendor should provide
maximum number of
mesh points supported.
d. The vendor shall include
Tender No: SCL/PS/2017E0065901 15
one dedicated license, i.e.,
in addition to S.N.5, for
above-mentioned (6a to
6c) requirement.
7 Interface: In addition to
batch mode execution, the
program shall have
following features as
minimum:
a. Interactive graphical
user interface to generate
and modify input deck
b. Report runtime output
and control
c. Ability to integrate
modules as per user
requirement
d. Number of licenses shall
enable five parallel
execution of process or
device simulation through
the Interface.
8 Design-of-Experiment:
Emulation of process splits
to achieve target process
or/and device parameters.
User shall have flexibility
Tender No: SCL/PS/2017E0065901 16
of varying parameters –
process, material, model,
etc. The number of
license(s) shall enable
execution of one Design-
of-Experiment.
9 Mask view: The package
shall be able to import,
view and edit layout in
GDSII format for creation
of 2D and 3D device
structure using both
process simulation and
physical information. The
number of license(s) shall
enable demand of single
instance of the module.
10 Device Creation and
Mesh/Remesh:
a. Creation and
modification of 2D and 3D
device structure for device
simulation with interface
to 2D/3D process
simulation tool.
b. Generation or/and
optimization of mesh as
per or combination of
location, device
layer/region, physical and
device attribute, like
interface, doping density,
doping type, etc.
Tender No: SCL/PS/2017E0065901 17
c. Minimum number of
mesh points supported for
2D and 3D shall be 200k
and one million
respectively. Vendor
should provide maximum
number of mesh points
supported.
d. The number of
license(s) shall ensure
three parallel executions,
two for 2D and one for 3D
variant. For illustration,
please refer S.N.4f.
11 Visualization: Versatile
visualization tool to
support
a. Viewing of
i. Device structure in 1D,
2D and 3D.
ii. Electrical characteristics
iii. Regions, layers, mesh,
doping profile, field
distributions, etc.
b. Macro (set of
Tender No: SCL/PS/2017E0065901 18
commands) recording and
saving feature to recreate
same state of plots
c. Importing dataset from
third party and create
plots for overlay with
simulation results
d. Data probing at point,
cutline and cut-planes
e. Mathematical
operations to extract
device parameters
f. Exporting data for
analysis in commercially
available software
g. The number of licenses
shall meet upto ten
parallel requests of the
visualization tool. If the
visualization tool supports
all of 1D, 2D and 3D, then
SCL requirement
translates to ten licenses
of the visualization tool;
else ten licenses for 3D
visualization tool shall be
provided in addition to
standard ten licenses for
2D.
Tender No: SCL/PS/2017E0065901 19
12 Multi-Thread Processing:
To ensure the efficiency,
the TCAD package shall be
provided with necessary
licenses to utilize
minimum of twelve
core/threads.
13 Technical Evaluation:
a. The evaluation shall be
based on the test cases
provided by the vendor for
all the modules/sub-
modules required by (as
mentioned in the RFP) and
in consultation with SCL.
b. Vendor to provide demo
version with all proposed
licenses for minimum of
four weeks for evaluation.
Application support should
be available during this
period.
14 License: Number and
validity of license shall
meet following
a. All licenses shall be
perpetual floating licenses
to be installed on Blade
server (RHEL6)
Tender No: SCL/PS/2017E0065901 20
b. Two years of
maintenance support that
includes delivery of all
updates
c. Except for license for
the Interface (S.N.7) and
Design-of-Experiment
(S.N.8), all other licenses
offered to meet the
requirements outlined in
remaining sections shall be
mutually independent. For
example, process and
device shall run
independently without
blocking any license for
other.
d. Number of licenses shall
be commensurate with
requirements specified in
relevant sections and 14c.
15 Re-hosting: During two
year maintenance period,
the vendor may be
required to re-host the
software. Although this is
deemed to be free-of-cost;
however, if price
implication is envisaged,
the vendor shall
separately quote for
carrying out the activity.
The quoted price shall be
Tender No: SCL/PS/2017E0065901 21
valid for entire
maintenance period. This
price shall not be
considered for
comparison.
16 Training: Vendor to
provide application
training at SCL in two
phases. First phase shall
coincide with installation
and shall be of minimum
two days subsequent to
the installation of the
software at SCL. Second
phase of four days
duration shall be after
three months from
installation. The training
content shall be mutually
agreed and provided in
advance so as to schedule
on mutually convenient
dates.
17 Documentation: Complete
set of manuals
corresponding to all
quoted modules shall be
provided. The manuals
shall be in portable
document format (pdf).
One set of hard copy of
the user manuals may be
provided.
18 Hardware: The
compatibility of the
software, to the Operating
Systems and the Hardware
Configurations existing at
SCL has to be ensured by
Tender No: SCL/PS/2017E0065901 22
the vendor prior to the
submission of the quote.
Hence the vendor is
requested to visit the SCL
facility on the day of pre-
bid meeting.
19 Problem Solving: Problems
should be addressed
within a reasonable time
preferably through email.
If mutually decided, a visit
should be arranged.
20 Two-Part Bidding: Vendor
shall submit only non-
priced commercial offer
with Part-1 (Technical) of
the bid. Priced offer shall
be in Part-2 (Commercial)
only. Vendor to note that
inclusion of priced offer in
Part-1 (technical) shall
lead to rejection of the
bid.
21 Configuration: Vendor to
attach complete
configuration of the
software including number
of licenses for each
module alongwith
technical offer.
Vendor Specificied Terms
Description Vendor Terms
1. Place of Delivery and Taxes & Duties:
1.1 For imported stores, prices shall be quoted on FCA nearest
Tender No: SCL/PS/2017E0065901 23
International airport basis.
1.2 For indigenous stores, prices shall be quoted on F.O.R destination
basis i.e. SCL, S.A.S. Nagar, Mohali, Punjab exclusive of excise duty and
taxes as may be applicable.
The rates at which the said Government levies, taxes and duties are
applicable, shall be indicated separately.
The prices of the indigenous items shall also be exclusive of transit
insurance which shall be arranged by the Purchaser and shall be to
Purchaser account.
1.3 For indigenous stores, no concessional Central Sales Tax form will
be issued. Please indicate the rate of Central Sales Tax (without Form
C) / VAT / Service Tax as applicable.
1.4 Notes:
a) Purchaser is entitled to Excise Duty exemption as per CE Notification
no. 10/97 Central Excise dated March 01, 1997 amended vide
Notification No. 16/2007 Central Excise dated March 01, 2007 and
would accordingly issue Excise Duty Exemption Certificate in favour of
the contractor quoting in Indian Rupees. The bidder should take the
same into account while quoting the prices in Indian Rupees.
b) For imported materials, the Purchaser is entitled to issue Customs
duty exemption certificate (CDEC) to the contractor under customs
notification no.51/96 dated 23.07.1996 and subsequent amendments
to enable the contractor to avail off the benefit of concessional rate of
customs duty under this notification. CVD under this notification is nil.
In addition to the above CDEC, any documentary support requested by
the contractor from the purchaser for customs clearance of goods
against the above CDEC shall be provided by the purchaser.
2. SECURITY DEPOSIT:
2.1 On acceptance of the tender, the Contractor shall submit security
deposit for ten percent (10 percent) of the value of the Contract within
15 days from the date of purchase order.
If the Contractor fails to provide the security within the period
specified, such failure shall constitute a breach of the Contract, and the
Tender No: SCL/PS/2017E0065901 24
Purchaser shall be entitled to make other arrangements for the re-
purchase of the stores contracted at the cost and risk of the
Contractor.
2.2 Security Deposit shall be submitted through Demand Draft /
Bankers Cheque/ fixed deposit receipt or Bank Guarantee from any of
the Scheduled Banks executed on non-judicial stamp paper of
appropriate value, and shall be valid for a period of sixty (60) days
beyond the date for completion of the Purchase Order/Contract.
2.3 In case the contractor fails to furnish the security deposit within
the specified date or extended due date, the Purchase Order/Contract
shall be cancelled, and the EMD, if any, made earlier shall be forfeited,
and, in addition, appropriate penal action may also be considered.
2.4 After the Purchase Order/Contract is successfully executed in all
respects, the Bank Guarantee towards Security Deposit may be
discharged and retained amount and / or EMD refunded to vendors.
2.5 In the event of non-execution of the Purchase order/Contract or
breach of any terms and conditions of the Purchase Order, the Security
Deposit shall be forfeited.
3. Delivery Period:
Vendor shall indicate their minimum delivery period.
4. UPDATES AND MAINTENANCE:
4.1 The vendor must provide free technical support including software
updates, maintenance releases and bug fixing for a period of one year
from the date of acceptance at SCL.
4.2 As an option the vendor must also quote separately for Annual
Support Contract (ASC) including technical support, maintenance
releases and bug fixing for the period of one, two and three years
starting from the end of one year from the date of acceptance at SCL.
This shall be uploaded as a separate pdf file under tab Supporting
documents from vendors (Commercial).
However please note ASC price shall not be considered for commercial
Tender No: SCL/PS/2017E0065901 25
evaluation of bids.
4.3 PERFORMANCE BANK GUARANTEE: To fulfil conditions of one year
maintenance period, the Contractor shall furnish a Bank Guarantee (as
per format given by purchaser) from any scheduled bank/ bank
approved by the Purchaser for an amount equivalent to 10 percent of
the value of the Contract and shall be valid for a period of 60 days
beyond the expiry date of maintenance period. On the performance
and completion of the Contract in all respects, the Bank Guarantee will
be returned to the Contractor without any interest.
5. TERMS OF PAYMENT IN CASE OF OVERSEAS SUPPLIER[S]:
5.1 Being a Department of the Government of India, the normal terms
of payment are by Sight Draft.
5.2 While the purchasers bank charges shall be borne by the
purchaser, the contractor shall bear the bank charges payable to his
banker.
6. The Sight Draft will be operative on presentation of the under
mentioned documents:
a) Original Bill of Lading / Airway Bill
b) Commercially certified invoices describing the stores delivered,
quantity, unit rate and their total value, in triplicate. The invoice
should indicate the discounts, if any, and Agency Commission
separately.
c) Packing List showing individual dimensions and weight of packages.
d) Country of Origin Certificate in duplicate, wherever applicable.
e) Test Certificate, wherever applicable.
f) Declaration by the Seller that the contents in each case are not less
than those entered in the invoices and the quality of the Stores are
guaranteed as per the specifications asked for by the Purchaser.
g) Warrantee and guarantee Certificate/s as applicable.
Tender No: SCL/PS/2017E0065901 26
7. TERMS OF PAYMENT IN CASE OF INDIGENOUS SUPPLIER[S]:
7.1 Payment will be made for the accepted stores within 30 days from
the date of receipt of the materials at SCL.
7.2 While the purchaser bank charges shall be borne by the purchaser,
the contractor shall bear the bank charges payable to his banker.
8. ADDRESS OF INDIAN AGENT:, if any
9. VALIDITY:
The tender must be valid for a minimum period of 90 days from the
due date of opening of tender.
10. MODE OF DESPATCH:
In case of foreign order, generally stores should be despatched
through Indian Flagged Vessel / Air India or through any other Agency
nominated by the purchaser whose contact details shall be indicated in
the purchase order.
A copy of the invoice and packing list should invariably be kept inside
each of the packages.
11. INSURANCE OF THE STORES:
Insurance wherever necessary, will be arranged by the Purchaser. The
necessity or otherwise of insurance will be as indicated in the Purchase
Order/Contract.
12. TECHNICAL DOCUMENTATION:
The vendor shall provide Soft and Hard copy of all manuals related to
Tender No: SCL/PS/2017E0065901 27
the software. List of all manuals shall be provided along with the
quote.
All documentation shall be in English language only.
13. CONTRACTORS DEFAULT LIABILITY:
The purchaser may upon written notice of default to the Contractor
terminate the Contract in whole or in part in circumstances detailed
hereunder:
a) If in the judgement of the Purchaser the Contractor fails to make
delivery of Stores within the time specified in the Contract/ agreement
or within the period for which extension has been granted by the
Purchaser to the Contractor.
b) If in the judgment of the Purchaser the Contractor fails to comply
with any of the other provisions of this Contract.
14. In the event the Purchaser terminates the Contract in whole or in
part as provided in Clause 13 the Purchaser reserves the right to
Purchase, upon such terms and in such a manner as he may deem
appropriate, stores similar to that terminated and the Contractor shall
be liable to the Purchaser for any additional costs for such similar
stores and/or for liquidated damages for delay as defined in Clause 18
until such reasonable time as may be required for the final supply of
stores.
14.1 If this Contract is terminated as provided in Clause 13 the
Purchaser in addition to any other rights provided in this Article, may
require the Contractor to transfer title and deliver to the Purchaser
under any of the following clauses in the manner and as directed by
the Purchaser:
a) Any completed stores.
b) Such partially completed stores, drawing, information and Contract
rights (hereinafter called manufacturing material) as the Contractor
has specifically produced or acquired for the performance of the
Contract as terminated. The Purchaser shall pay to the Contractor the
Contract price for completed stores delivered to and accepted, by the
Tender No: SCL/PS/2017E0065901 28
purchaser and for manufacturing material delivered and accepted.
14.2 In the event the Purchaser does not terminate the Contract as
provided in Clause 13, the Contractor shall continue the performance
of the Contract in which case he shall be liable to the purchaser for
liquidated damages for delay as set out in Clause 18 until the stores
are accepted.
15. REPLACEMENT:
If the stores or any portion thereof is damaged or lost during transit,
the Purchaser shall give notice to the Contractor setting forth
particulars of such stores damaged or lost during transit. The
replacement of such stores shall be effected by the Contractor within a
reasonable time to avoid unnecessary delay in the intended usage of
the Stores. In case the purchaser agrees, the price towards
replacement items shall be paid by the purchaser on the basis of
original price quoted in the tender or as reasonably worked out from
the tender.
16. REJECTION :
In the event that any of the stores supplied by the Contractor is found
defective in material or workmanship or otherwise not in conformity
with the requirements of the Contract specifications, the purchaser
shall either reject the stores or request the Contractor, in writing, to
rectify the same. The Contractor, on receipt of such notification, shall
either rectify or replace the defective stores free of cost to the
purchaser. If the Contractor fails to do so, the purchaser may at his
option either
a) replace or rectify such defective stores and recover the extra cost so
involved from the Contractor, or
b) terminate the Contract for default as provided under clause 14
above, or
c) acquire the defective stores at a reduced price considered equitable
under the circumstances. The provision of this article shall not
prejudice the Purchaser's rights under clause 18.
Tender No: SCL/PS/2017E0065901 29
17. EXTENSION OF TIME:
If the completion of supply of stores is delayed due to reason of force
majeure such as acts of god, acts of public enemy, acts of Government,
fires, floods, epidemics, quarantine restriction, strikes, freight
embargoes, etc., the Contractor shall give notice within 15 days to the
purchaser in writing of his claim for an extension of time. The
purchaser on receipt of such notice after verification, if necessary, may
agree to extend the Contract delivery date as may be reasonable but
without prejudice to other terms and conditions of the Contract.
18. DELAY IN COMPLETION/LIQUIDATED DAMAGES:
If the Contractor fails to deliver the stores within the time specified in
the Contract or any extension thereof, the purchaser shall recover
from the Contractor as liquidated damages a sum of one-half of one
percent (0.5 percent) of the Contract price of the undelivered stores
for each calendar week of delay. The total liquidated damages shall not
exceed ten percent (10 percent) of the Contract price of the unit or
units so delayed. Stores will be deemed to have been delivered only
when all their component parts are also delivered. If certain
components are not delivered in time, the stores will be considered as
delayed until such time as the missing parts are delivered. Delivery of
stores shall be complete on Installation, commissioning, Testing and
Acceptance as applicable.
19. PACKING:
The Contractor shall pack and crate all stores for air/road shipment as
applicable in a manner suitable for export to a tropical humid climate,
in accordance with internationally accepted export practices and in
such a manner so as to protect it from damage and deterioration in
transit by road, rail, air or sea. The Contractors shall be responsible for
all damages due to improper packing.
20. ARBITRATION:
Tender No: SCL/PS/2017E0065901 30
If at any time any question, dispute or difference whatsoever shall
arise between the purchaser and the Contractor upon or in connection
with this Contract, either party may forthwith give to the other notice
in writing of the existence of such question, dispute or difference and
the same shall be referred to the adjudication of two arbitrators, one
to be nominated by purchaser, other by a Contractor and in the event
of any difference of opinion, the arbitrators will refer the matter to the
umpire. The arbitration shall be conducted in accordance with the
rules and procedure for arbitration of the International Chamber of
Commerce at Paris. The expenses of the arbitrators and umpire shall
be paid as may be determined by them. However, the venue of such
arbitration should be in India.
In case of dispute arises with domestic/Indian suppliers, the applicable
Arbitration procedure shall be as per Indian Arbitration & Conciliation
Act, 1996.
21. INDEMNITY:
The Contractor shall warrant and be deemed to have warranted that
all Stores supplied against this Contract are free and clean of
infringement of any patent, copyright or trade mark and shall at all
times indemnify the purchaser against all claims which may be made in
respect of stores for infringement of any right protected by Patent,
Registration of design or Trade Mark and shall take all risk of accident
or damage which may cause a failure of the supply from whatever
cause arising and the entire responsibility for the sufficiency of all the
means used by him for the fulfilment of the Contract.
22. COUNTER TERMS AND CONDITIONS OF SUPPLIERS:
Where counter terms and conditions/printed or cyclostyled conditions
have been offered by the supplier, the same shall not be deemed to
have been accepted by the purchaser unless specific written
acceptance thereof is obtained.
23. APPLICABLE LAW:
The Contract shall be interpreted, construed and governed by the laws
Tender No: SCL/PS/2017E0065901 31
of India.
24. The vendor shall supply latest version of the ordered Software.
25. Any Other Term:
Supporting Documents from Vendor
Attachment - I:
Attachment - II:
Price Bid Form
Item Description Slab Range Qty UOM Currency Unit Price Total Price
TCAD Software for
Silicon-based
Process and
Device Simulation
SCL Material
Code: 250513068
- 1 No. - - -
Break-up of other taxes and other costs should be specified in respective narration columns.
Sum of these Break-up values should be specified in respective value columns.
Supporting Documents from Vendor (Commercial)
Document attachment with price bid