General Terms and Conditions of Purchase (hereinafter ...€¦ · est and shall expressly alert BI...
Transcript of General Terms and Conditions of Purchase (hereinafter ...€¦ · est and shall expressly alert BI...
Version 01 – Status: March 13, 2020
General Terms and Conditions of Purchase (hereinafter referred to as "GTC-P")
of
Boehringer Ingelheim Pharma GmbH & Co. KG, Boehringer Ingelheim GmbH
and Affiliates of the Boehringer Ingelheim Group (hereinafter referred to as "BI")
Preamble
These GTC-P consist of General Terms and Conditions (Part I) and Special Terms and Conditions (Part II – IV).
Part I contains the General Terms and Conditions applicable to all (purchase) orders (hereinafter collectively
referred to as "Order" or "Orders"). The General Terms and Conditions (Part I) also provide supplementary rules
on Orders for items of moveable property and production of work [“Werkleistungen”].
The Special Terms and Conditions in Parts II–IV contain supplementary rules on services (Part II), design
agreements [“Gestaltungsverträge”] (Part III) and IT software licences (Part IV).
Should there be any conflicts or inconsistencies between the provisions of the Special Terms and Conditions (Part
II, III or IV) and those of the General Terms and Conditions (Part I), then the provisions in the Special Terms and
Conditions (Part II, III or IV) shall take precedence over those in the General Terms and Conditions (Part I).
Boehringer Ingelheim Page - 2 -
Part I:
General Terms and Conditions
1. Scope, deviating/overriding agreements
1.1 All Orders submitted by the BI entity stated on
the Order shall be based exclusively on the
GTC-P set forth below. These GTC-P shall
constitute an integral element of any Order. BI
does not accept any terms and conditions of
the Contractor that conflict with or deviate
from these GTC-P. BI's GTC-P shall apply
even if BI unconditionally accepts or pays for
goods or services despite having knowledge of
the Contractor’s terms and conditions which
conflict with or deviate from its own GTC-P.
1.2 These GTC-P shall apply exclusively in the
context of commercial transactions with “busi-
ness persons” [“Unternehmer”] as defined in
Sec. 14 German Civil Code [Bürgerliches Ge-
setzbuch], sovereign legal entities [“juris-
tischen Personen des öffentlichen Rechts”] or
special funds organised under public law
[“öffentlich-rechtliches Sondervermögen”].
They shall also apply to all future transactions
with the same Contractor as amended at the
time the contract was concluded/the Order was
placed.
1.3 Individual agreements with the Contractor (in-
cluding individual subsidiary agreements, ad-
denda and amendments) shall always take
precedence over these GTC-P. The same shall
apply for conditions stipulated in Orders from
BI that deviate from these GTC-P.
2. Conclusion of contract, written form re-
quirements
2.1 In its offer and service description, the
Contractor shall adhere precisely to BI's requ-
est and shall expressly alert BI in writing in the
event that there are any deviations from BI's
request.
2.2 Orders and notices of acceptance, amend-
ments, and other agreements existing before or
at the time the contract is concluded must be in
writing to have legal effect (letter, fax, e-mail
– hereinafter referred to as "in writing").
2.3 The Contractor hereby undertakes to examine
the Order without delay for any obvious errors,
ambiguities, gaps, or unsuitability in the spe-
cifications selected by BI for their intended use
and to inform BI without delay of any necessa-
ry changes to or elaborations on its Order.
2.4 Offers shall be provided free of charge to BI
and shall not constitute any obligations on BI’s
part. No compensation shall be payable for the
preparation of cost estimates except by spe-
cific agreement. Sec. 632 (3) German Civil
Code shall apply. Written documents including
offers, offers for contractual addenda, confir-
mations and commercial correspondence must
be addressed to the correct purchasing depart-
ment at BI. Contractors shall fully note all Or-
der-specific details in all written documents
Boehringer Ingelheim Page - 3 -
(letters, invoices, consignment notes,
waybills).
2.5 The Contractor shall fulfil its contractual obli-
gations personally or within its own company.
The Contractor's employees must possess the
qualifications required by the laws of the Fe-
deral Republic of Germany.
3. Subcontractors
3.1 The enlistment of subcontractors by the Con-
tractor to render services or partial services re-
quires the prior written consent of BI. BI has
the right to deny the use of individual employ-
ees and subcontractors for cause.
3.2 The Contractor may only contract services to
competent, capable, and reliable subcontrac-
tors. Such subcontractors must also fulfil their
legal obligations to pay taxes and make social
insurance payments, as well as meet the re-
quirements under trade law. Prior to enlist-
ment, the Contractor shall notify BI in writing
of the type and scope of service being con-
tracted, as well as the name, address, and em-
ployers' liability insurance association (includ-
ing member number) of the intended subcon-
tractor. Furthermore, BI is entitled to require
evidence of the competency, capability, and re-
liability of the intended subcontractor.
3.3 The Contractor shall keep BI informed of en-
listed subcontractors and the contracts con-
cluded with them provided such notification
does not conflict with the Contractor's or sub-
contractor's legitimate interests or is not sub-
ject to non-disclosure.
3.4 Should the Contractor enlist subcontractors for
services the Contractor itself provides, BI shall
be entitled to set a reasonable deadline for re-
medial action and declare that the Order shall
be rescinded if the deadline passes without
success should the enlisted subcontractors not
be competent, capable, or reliable, or the Con-
tractor fails to provide evidence of compliance
with this requirement at BI's request within the
set period of time.
3.5 In respect of tasks assumed by subcontractors,
the Contractor shall impose on any approved
subcontractors all obligations it has assumed
vis-á-vis BI and ensure that those obligations
are fulfilled. The Contractor may not prevent
its subcontractors from entering into contracts
with BI for other goods and/or services. In par-
ticular, exclusivity agreements with third par-
ties that prevent the Contractor or subcontrac-
tor from procuring goods or services which the
Contractor or the subcontractor requires to ful-
fil Orders of this kind are prohibited.
4. Delivery and performance deadlines, peri-
ods, early and partial deliveries/services, de-
layed delivery/service, contractual penalties
4.1 The delivery period stated in the Order shall be
binding.
4.2 Early and partial deliveries/services shall only
be permitted with BI's consent and shall be
identified as such in the shipping documents.
4.3 The Contractor shall without delay notify BI in
writing when circumstances arise or become
apparent which make it clear that the Contrac-
tor will be unable to adhere to the agreed de-
Boehringer Ingelheim Page - 4 -
livery period. Whenever it provides such no-
tice, the Contractor shall indicate the reasons
for the delay and the anticipated duration
thereof.
4.4 Where the delay is due to a lack of documents
or materials to be provided by BI, the Contrac-
tor shall be entitled to rely on this fact only if it
has previously issued a written reminder to BI
and the documents or materials are not provid-
ed to the Contractor within a reasonable time.
4.5 The Contractor shall be liable to BI for any and
all damages for performance delay [“Verzug”]
to the extent provided by law unless it proves
that the actual damages were not caused by its
delay. BI's acceptance of any belated delivery
of goods or services shall not constitute a
waiver of its claims for compensatory damag-
es.
4.6 If, for reasons that are within the Contractor’s
sphere of responsibility, the delivery does not
occur within agreed delivery period, then upon
expiry of such reasonable grace period as BI
shall set and without prejudice to BI’s further
statutory claims, BI shall be entitled at its op-
tion to demand compensatory damages in lieu
of performance of the contract or to procure
contractual cover from a third party. BI's right
of rescission shall remain unaffected thereby.
4.7 Any contractual penalty [“Vertragsstrafe”] for
a delay in delivery of goods or services which
may be agreed upon by the parties shall remain
unaffected by the foregoing pursuant to Sec.
340 (2) German Civil Code. BI may assert
contractual penalties until such a time as the
final payment falls due without the need to ex-
press any reservation pursuant to Sec. 341 (3)
German Civil Code. Contractual penalties shall
be credited against any claims for damages.
5. Withholding and set-off by the Contractor
The Contractor may only assert a right to
withhold the provision of goods and services
based on claims from the same contractual re-
lationship that are beyond dispute, adjudicata-
ble, or legally established. The Contractor may
only resort to set-off if its counterclaim is be-
yond dispute, adjudicatable, or legally estab-
lished.
6. Prices/terms of payment, invoicing, no as-
signment
6.1 The price specified in the Order is binding and
fixed. Unless otherwise stipulated, the price
includes all expenditures in relation to the de-
liveries and services ordered from the Contrac-
tor, including but not limited to the costs for
any testing, acceptance, documentation, and
creation of technical documents, packaging,
transportation, customs clearance fees, and in-
surance.
6.2 Prices must not include VAT. VAT must be
specified separately.
6.3 BI shall make prepayments only if the Con-
tractor produces an unconditional, first-rate
guarantee issued by a German commercial
bank or savings and loan bank in accordance
with banking industry standard and only with
the express prior agreement of both parties.
Any guarantee commission fees shall be borne
by the Contractor.
Boehringer Ingelheim Page - 5 -
6.4 Payments shall be made within net thirty (30)
days of delivery (or, if stipulated, acceptance)
and receipt of a contractually compliant in-
voice. BI may reject any invoices that do not
meet the requirements of subsection 6.5. Re-
garding payment, the stipulated deliv-
ery/performance date shall apply in the event
of early delivery/performance.
6.5 At the time of invoicing, the Contractor's in-
voice must comply with tax regulations as
amended. The following mandatory details are
required in every invoice:
Name and address of the Contractor
Name and address of the legal entity of the
Boehringer Ingelheim Group designated in
the Order as the "customer"
Date of invoice
Order number
Amount and currency of invoice.
Invoices for main orders and any subsidiary,
follow-up, or change orders must be submitted
by the Contractor separately. BI may reject in-
voices containing incomplete or miss-
ing/unverifiable information/documents. In the
event an invoice is reissued, the due date for
payment shall be determined by the date of re-
ceipt of the second, compliant invoice.
6.6 In the event of a delay in payment, default in-
terest shall be charged at a rate of five (5) per-
cent above the base rate of the central bank of
Germany, the Deutsche Bundesbank (sec. 247
and Sec. 288 (2) German Civil Code), as of the
date the payment default occurred. The date of
the bank transfer order shall be considered the
date of payment.
6.7 The Contractor is not entitled to assign or have
collected by third parties its claims against BI
without BI's prior written consent. This shall
not apply if the Contractor grants its supplier
an extended retention of title in the proper
course of business. Sec. 354 (a) German
Commercial Code [Handelsgesetzbuch] shall
remain unaffected.
7. Taxes
7.1 All payments stated shall be inclusive of any
taxes and each party shall be responsible for
and shall bear its own taxes assessed by a tax
or other authority except as otherwise set forth
in the contract. “Taxes” shall mean all forms of
preliminary or finally imposed taxation, do-
mestic and foreign taxes, fees, levies, duties
and other assessments or charges of whatever
kind (including but not limited to sales, use,
excise, stamp, transfer, property, value added,
goods and services, withholding and franchise
taxes) together with any interest, penalties or
additions payable in connection therewith.
7.2 The price is understood to be exclusive of val-
ue added tax (VAT) or comparable indirect
taxes (e.g. goods and service tax, etc.). VAT
and comparable indirect taxes must be paid
additionally as required by law.
7.3 As far as expenses are reimbursed the VAT on
any reimbursed expenses may only be reim-
bursed by BI provided the Contractor cannot
deduct VAT and such inability is not due to
default (e.g. delay) on the part of the Contrac-
tor.
Boehringer Ingelheim Page - 6 -
7.4 Should applicable laws or regulations require
BI to withhold taxes on licences or other pay-
ments made under this contract, these taxes
shall be deducted by BI from the taxable li-
cences or payments as required by law and
paid by BI to the proper tax authorities on be-
half of the Contractor. Official receipts of
payment of any withholding tax shall be se-
cured and sent to the Contractor as evidence of
such payment only upon the Contractor´s re-
quest. The parties shall use their best endeav-
ours to ensure that the withholding taxes in-
curred in accordance with the terms of the ap-
plicable double tax treaty are reduced as much
as possible.
8. Transfer of risk/ place of performance/
goods labelling/ transport insurance/ pack-
aging/ shipping list/ acceptance
8.1 Unless otherwise stipulated, risk shall transfer
to BI pursuant to the international Incoterms
clause "DAP" (Incoterms 2020) at the time of
delivery to the BI place of receipt stated in the
Order. This shall also be the place of perfor-
mance. If the Order does not contain a delivery
location, the place of performance shall be the
main office of the BI company that placed the
Order. Should acceptance be stipulated, e.g.
for contracts to produce a work, such ac-
ceptance shall be authoritative for the transfer
of risk; in such case, the German law on con-
tracts to produce a work [“Werkvertrags-
recht”] shall apply mutatis mutandis. Default
of acceptance on the part of BI shall constitute
transfer/acceptance.
8.2 For technical equipment, systems, and machin-
ery, risk shall not be transferred until the corre-
sponding formal acceptance inspection [“Ab-
nahme”] and functional testing have been
completed, and BI has confirmed the function-
ality of the delivery at BI's place of perfor-
mance listed in subsection 8.1. Subsection 10.5
shall apply to functional testing.
8.3 For deliveries requiring assembly and/or instal-
lation by the Contractor, risk shall not be trans-
ferred nor delivery completed until assembly
and/or installation is completed and document-
ed in a written protocol. For legally required or
stipulated acceptance, risk shall not be trans-
ferred nor service rendered until the service
has been rendered in accordance with the con-
tract and accepted; failure on the part of BI to
accept when legally required to do so shall
constitute acceptance. Unless otherwise stipu-
lated, BI must provide legally required or stip-
ulated acceptance of the performed service
within fifteen (15) days of completion.
8.4 Goods shall be properly and appropriately
packaged and labelled as instructed by BI.
Should the Contractor be required to retrieve
transport packaging under the German Packag-
ing Ordinance [Verpackungsverordnung] or
foreign provisions, it must retrieve the packag-
ing at the place of performance (subsection
8.1) at its own cost.
8.5 A shipping list containing BI's Order number,
the contents of the delivery itemised by the
Contractor's item number(s) (if specified in the
Order), and the type and quantity of items is
required for every goods delivery.
8.6 The parties hereby agree that the use of wood
products, including but not limited to pallets,
Boehringer Ingelheim Page - 7 -
which have been treated with or come into
contact with substances likely to have an ad-
verse impact on the quality of the goods being
supplied/processed, including but not limited
to halogenated phenolic preservatives, is pro-
hibited across the entire supply chain. The
Contractor shall impose corresponding obliga-
tions in favour of BI upon its suppliers and/or
permitted subcontractors and ensure fulfilment
of such obligations. The imposition of such ob-
ligations shall have no effect on the Contrac-
tor's liability to BI.
8.7 For any transport services purchased from the
Contractor by BI under these GTC-P, BI here-
by expressly waives any and all transport in-
surance offered by the shipper or carrier on
behalf of and at cost to BI. The Contractor's
obligation to insure its commercial liability
under the law and under specific agreements
with BI shall remain unaffected.
Should BI and the Contractor specifically con-
clude a delivery agreement under which BI as-
sumes (even part) of the transport risk in dero-
gation of subsection 8.1, BI hereby also ex-
pressly waives any and all transport insurance.
The provisions of the previous Section shall
then apply mutatis mutandis.
9. Transfer of title, processing of delivered
goods before transfer of title
Should a retention of title be specifically stipu-
lated for the delivered goods, title shall be
transferred to BI no later than upon payment
for said goods. In the course of ordinary busi-
ness, BI is entitled to process, sell, or other-
wise dispose of delivered goods even before
transfer of title.
10. Inspection for defects/ liability for defects/
warranty/ statutes of limitation
10.1 BI shall inspect goods for defects without de-
lay after they are received. Such inspections
shall encompass inspections only in respect to
externally visible damage and defects, and ex-
ternally visible deviations in terms of identity
of the goods and quantity. Such defects shall
be reported immediately. BI reserves the right
to conduct more in-depth goods receiving in-
spections during the normal course of business.
Defects which become apparent in the course
of such inspection and which are not covered
under sentence 2 hereof shall be the subject of
an immediate notice of defect. With respect to
these defects, the Contractor hereby waives the
defence of belated notice of defect. Where BI
ascertains the presence of defects, BI shall be
entitled to return the entire delivery. Notices of
defect found at a later point in time shall be
deemed timely pursuant to Sec. 377 (3) Ger-
man Commercial Code and submitted "without
undue delay" [“unverzüglich”] as defined in
this subsection 10.1 if submitted within five
(5) business days from the date of discovery.
In respect of whether a notice of defect was
reasonably forwarded to the Contractor, the
date on which the notice was dispatched shall
be authoritative.
10.2 Payments made on the stipulated price or ac-
ceptance of goods by BI's representative at the
Contractor's location shall not constitute
recognition of a lack of defects in the goods
and shall not release the Contractor from its li-
ability for defects.
Boehringer Ingelheim Page - 8 -
10.3 The Contractor warrants that all goods sup-
plied by it and all services rendered by it shall
conform, as of the date of the transfer of risk,
to the terms and conditions of this contract, as
well as to generally accepted engineering
standards, relevant provisions of law, and the
regulations and guidance of public authorities,
employers' liability insurance associations, and
trade associations, and that the Contractor is
unaware of any pending amendments thereto.
The Contractor shall notify BI without undue
delay of any pending amendments of which it
is aware. Where departures from these regula-
tions become necessary, the Contractor must
obtain BI's written consent thereto. Any such
consent shall not affect the Contractor’s re-
maining obligations under purchase contracts
or contracts to produce a work [“kauf- oder
werkvertraglichen Verpflichtungen”], includ-
ing any guarantees on the quality of the goods
or the works [“Beschaffenheitsgarantie”].
10.4 The Contractor also remains solely responsible
for the goods and services even in the event
that BI approves any drawings, computations,
or other documents, or participates in technical
or official controls, inspections, or acceptance
procedures. The same shall apply in the event
BI accepts any suggestions or recommenda-
tions by the Contractor.
10.5 Unless otherwise stipulated, functional testing
of the technical equipment, systems, and ma-
chinery listed in subsection 8.2 shall be con-
ducted within fourteen (14) days of receipt of
notice of readiness. Subsection 10.1 sentences
5 through 8 shall apply mutatis mutandis.
10.6 To the extent at least two partial deliveries un-
der the same Order with the same Contractor
have been deficient/defective in whole or in
part, BI shall be entitled, following a reasona-
ble grace period without remedy, to cancel the
contract and demand compensation for the
damage caused by the deficient performance
and/or cancellation.
10.7 Unless otherwise expressly stipulated, the stat-
ute of limitations shall apply to warranty
claims from the time of the transfer of risk.
The Contractor shall remedy defects in
goods/services for which BI has given notice
within the statute of limitations by, at BI's dis-
cretion, repairing or replacing the defective
parts, or in case of contracts to produce a work
by refurnishing deficient works at no charge,
including all incidentals. The Contractor's
rights under Sections 275, 439 (3), and 636 (3)
German Civil Code shall remain unaffected.
10.8 The Contractor shall remedy defects, replace
defective goods, or refurnish works without
undue delay. The statutory circumstances of
inhibition and interruption shall apply. For re-
furnishing and replacement, the statute of limi-
tations for warranty claims shall recommence
upon completion of supplementary perfor-
mance [“Nacherfüllungspflicht”] provided
such supplementary performance entails ex-
press or implied recognition of a duty to reme-
dy defects [“Mängelbeseitigungspflicht”]. For
repairing within supplementary performance,
the statute of limitations for warranty claims
shall restart upon completion of supplementary
performance, provided such defect has already
been repaired or in case of deficiencies of re-
pairing and such supplementary performance
Boehringer Ingelheim Page - 9 -
entails express or implied recognition of a duty
to remedy defects.
10.9 To the extent the Contractor has guaranteed the
quality or durability of goods, claims pertain-
ing thereto may be asserted independently of
statutory warranty claims. In such an event, the
Contractor shall be liable without fault and re-
gardless of whether the defect existed at the
time of transfer of risk.
10.10 The Contractor's statutory warranty shall also
cover the goods or works of any subcontractors
involved.
10.11 The defective goods or works shall remain in
the possession of BI after BI has given notice
of the defect until such time as an appropriate
replacement is delivered to BI and BI may, if
necessary, make use of them. By such use BI is
not constituting a waiver of warranty rights.
10.12 All further and other claims on the part of BI,
in particular BI's right of rescission [“Rück-
trittsrecht”], right to reduce the purchase price
[“Minderungsrecht”], and its claims for com-
pensation of damages, including damages in
lieu of specific performance, shall remain un-
affected by the foregoing.
10.13 To the extent that the Contractor fails to meet
its obligation of supplementary performance
within such reasonable time as BI shall set, BI
shall be entitled to take the necessary action it-
self at the Contractor's cost and risk, or engage
a third party to take the necessary action (sub-
stitute performance [“Ersatzvornahme”]).
Should a demand for supplementary perfor-
mance from the Contractor with deadline not
be possible due to special urgency, Contractor
unavailability, or impending, unreasonably
high damages, BI shall be entitled without
prejudice to statutory claims to render or have
rendered substitute performance, and demand
compensation from the Contractor for the nec-
essary costs. BI shall notify the Contractor of
such action where possible. The principle of
proportionality pursuant to Sections 439 (3)
and 636 (3) German Civil Code shall be ob-
served with regard to any substitute perfor-
mance.
11. Observance of legal regulations and guid-
ance, compliance, safety regulations, notifi-
cation requirements
11.1 The Contractor shall observe all applicable na-
tional, European, and international regulations
on delivery and other services, specifically in
regard to environmental protection including
energy, health and safety at work, anti-
corruption, anti-terrorism, human rights, prod-
uct safety, and data protection, as amended,
and at its own cost.
11.2 In particular, the Contractor shall, at its own
costs, comply and ensure that its subcontrac-
tors and suppliers comply with the applicable
legal requirements for the use of dangerous
goods, including without limitation those set
forth by the then current EU Directive
2011/65/EU ("RoHS") and its national imple-
mentations, and of the Regulation (EC) No
1907/2006 of the European Parliament and of
the Council of 18 December 2006 concerning
the Registration, Evaluation, Authorization and
Restriction of Chemicals as it may be amended
over time (hereinafter “REACH”). Contractor
Boehringer Ingelheim Page - 10 -
guarantees that Product delivered is and con-
tinues to be marketable under REACH.
This obligation includes without limitation
(pre-)registration and approval of any chemical
substances and intermediates which constitute
a product, are contained in such product, or are
required for the manufacture of product, in
particular without limitation when substances
of very high concern as stipulated by the
REACH Regulation and its annexes are in-
volved.
Contractor shall specify a dedicated contact for
all REACH related matters and shall provide to
BI relevant information and documentation
(such as safety data sheets, copy of registration
confirmation issued by the European Chemi-
cals Agency, etc.) upon BI's request.
Upon conclusion of this contract/Order and
whenever an opportunity thereafter, Contractor
shall contact BI for both parties to align which
and how planned applications should be regis-
tered jointly/in tandem.
11.3 The Contractor shall provide BI all infor-
mation on compliance with ICH Q3D (Guide-
line for Elemental Impurities) and chapters 232
and 233 of the United States Pharmacopeia
(Elemental Impurities – Limits) with regard to
any delivered substances intended for use in
BI's chemical pharmaceutical production.
11.4 BI is committed to the fundamental principles
of corporate responsibility and integrity, hu-
man rights, working standards and anti-
corruption laws as set forth in the "Supplier
Code of Conduct" available online at
https://www.boehringer-ingelheim.de/ueber-
uns/geschaeftspartner/dokumente. The Con-
tractor hereby acknowledges these fundamen-
tal principles.
11.5 The performance of the foregoing obligations
in this subsection 11 shall be the Contractor's
primary obligation. Failure by the Contractor
to meet its obligations pursuant to this subsec-
tion 11 and to remedy such a breach within a
reasonable period as set by BI shall entitle BI
to cancel the contract/Order. Further claims for
damages on the part of BI shall remain unaf-
fected.
12. German Minimum Wage Act
[Mindestlohngesetz], German Posted
Workers Act [Arbeitnehmerentsendegesetz]
12.1 The Contractor hereby warrants fulfilment of
all relevant duties pursuant to the German
Minimum Wage Act in the provision of ser-
vices, specifically that the Contractor pays its
employees working in the Federal Republic of
Germany no less than the minimum wage (pur-
suant to Sec. 1 German Minimum Wage Act)
no later than the respective due date. This and
all subsequent regulations for subcontractors
shall apply mutatis mutandis for any chain of
subcontractors.
12.2 The Contractor shall notify BI without undue
delay of any claim asserted under the German
Minimum Wage Act by any employee – re-
gardless whether of the Contractor or a sub-
contractor – engaged for the performance of
the contract or of any proceedings initiated
against the Contractor or a subcontractor for a
Boehringer Ingelheim Page - 11 -
violation or violations pursuant to Sec. 21
German Minimum Wage Act.
12.3 Should BI be held liable pursuant to Sec. 13
German Minimum Wage Act or should pro-
ceedings for a fine pursuant to Sec. 21 (2)
German Minimum Wage Act be initiated, the
Contractor shall indemnify BI against any and
all related costs (including reasonable legal de-
fence costs and any imposed monetary fines).
12.4 Insofar as the German Posted Workers Act is
relevant, subsections 12.1 to 12.3 shall apply
mutatis mutandis.
13. Product liability, right of recourse, recalls
13.1 To the extent that third-party claims are assert-
ed against BI pursuant to the German Product
Liability Act [Produkthaftungsgesetz], the
German Medicinal Products Act [Arzneimit-
telgesetz], the German Environmental Liability
Act [Umwelthaftungsgesetz], German tort law
[Deliktsrecht], or comparable domestic or for-
eign law, the Contractor shall indemnify BI
against all third-party claims in which the Con-
tractor is itself responsible for the damage, the
cause of which was within the Contractor's
control, and the Contractor is itself liable to the
third party. Such indemnification shall include
all expenses necessarily incurred by BI in rela-
tion to such a third-party claim, specifically for
legal defence.
13.2 The Contractor shall indemnify BI against all
third-party claims asserted against BI for the
Contractor's infringement of obligations pursu-
ant to subsection 11.2 (REACH). Such indem-
nification shall include all expenses necessarily
incurred by BI from or in relation to such
third-party claims, specifically for legal de-
fence and all costs associated with procuring
necessary replacement.
13.3 Furthermore, the Contractor shall indemnify
BI against all third-party claims of violation of
patents, copyrights, design rights, trademarks,
name rights, and other industrial property
rights or applications for the same (hereinafter
referred to as "Property Rights") arising from
the contractual use of the delivery or work, un-
less the Contractor informed BI in writing up-
on conclusion of the contract of the possibility
that use of the delivery or work could consti-
tute a violation of Property Rights, or the Con-
tractor is not responsible for the violation on
other grounds.
Such indemnification shall include all expens-
es necessarily incurred by BI in relation to
such a third-party claim, specifically for legal
defence.
Furthermore, BI shall be entitled at its discre-
tion either to procure a licence of use of the
supplied goods from the holder of the right at
the Contractor’s cost and expense, or to cancel
the contract.
Should the Contractor be liable pursuant to this
subsection 13.3, it shall be responsible for all
consequential damages incurred by BI, specifi-
cally as a result of supply bottlenecks and pro-
duction stoppages.
Boehringer Ingelheim Page - 12 -
13.4 Other rights arising from Property Rights vio-
lations on the part of the Contractor shall re-
main unaffected.
13.5 In the event of a necessary and/or officially or-
dered recall or other action required to avoid
risks to persons or third-party property, the
Contractor shall be liable for any and all ex-
penses, costs, and damages incurred by BI due
to the recall or other action, and shall indemni-
fy BI against corresponding third-party claims
insofar as the recall or other action is due to
the fact that the delivered goods and/or pack-
aging or work is in breach of contract, specifi-
cally that the stipulated specifications were not
observed or contractual assurances were not
met, or there exist product defects, unless the
Contractor is not responsible for the aforemen-
tioned. Further claims by BI shall remain unaf-
fected.
BI shall, to the extent feasible and reasonable,
inform the Contractor as to the substance and
scope of any recalls to be carried out and af-
ford it an opportunity to comment.
13.6 Further obligations notwithstanding, the Con-
tractor shall notify BI without undue delay if it
becomes aware of any specific circumstances
pertaining to the delivered goods or rendered
services that would make it necessary for BI or
the Contractor to conduct a recall or other ac-
tion pursuant to the aforementioned provision
in subsection 13.5 and/or create a relevant risk
of product liability cases. Any legal reporting
requirements to which the parties are subject
shall remain unaffected.
14. Statute of limitations on right of recourse
To the extent BI's customers assert claims
against BI and such claims are for defects in
the goods supplied by the Contractor, BI's
claims for recourse shall be valid for a period
of five (5) years from the date of delivery by
the Contractor to BI.
15. Employers' liability and product liability in-
surance
The Contractor shall take out a policy of com-
prehensive general liability and product liabil-
ity insurance, at its own cost and expense, and
for the duration of its contract with BI, and the
cover must be customary in the market and ap-
propriate to the risk, but shall be no less than a
lump sum of five (5) million euros for personal
injury and damage to property per insured
event, including cover for indirect damages,
covering such losses as are caused by the Con-
tractor, or its employees or representatives as a
result of services rendered, works supplied or
goods delivered. BI shall be entitled to demand
that the Contractor furnish an appropriate con-
firmation of insurance cover from the Contrac-
tor's insurance provider. The Contractor shall
furnish such evidence of insurance cover with-
out undue delay upon BI's request. Any further
claims to which BI is entitled shall remain un-
affected.
16. Good manufacturing practice, requirements
for quality, packaging, and transport of ac-
tive ingredients and excipients
16.1 Should the products ordered by BI be used to
manufacture medicinal products and/or medi-
Boehringer Ingelheim Page - 13 -
cal devices and/or cosmetics and/or food, the
World Health Organisation's "Requirements on
the Quality, Packaging and Transport of Active
Ingredients and Excipients for the Pharmaceu-
tical Industry" as amended, as well as the ap-
plicable GxP guidelines in the product's coun-
try of manufacture/origin shall be observed.
16.2 Each delivery should, wherever possible, orig-
inate from a single batch, i.e. constitute a ho-
mogeneous unit. The batch number shall be
marked on each packaging unit as well as on
the consignment note. Should the delivery con-
sist of two or more batches of the same prod-
uct, all batch numbers shall be marked on the
packing units and the shipping list.
16.3 In all cases of continuous manufacturing pro-
cesses in which it is not possible to record
products by batch, the Contractor shall ensure
that quality conforms to specifications. Each
unit of packaging shall be labelled in a perma-
nent and clear fashion, containing the product
name, net weight, tare, batch number, and any
possible risks and storage information.
16.4 The Contractor shall be liable for losses and
costs resulting from any failure to comply with
these rules, including on the part of its subcon-
tractors.
16.5 Goods shall be inspected for compliance with
the rules under subsections 16.1 to 16.4 imme-
diately upon receipt. Goods shall only be in-
spected for externally visible damage and de-
fects in regard to the rules under subsections
16.1 to 16.4. Such defects shall be reported
immediately. BI is entitled to refuse ac-
ceptance of and reject the delivery in the event
the rules under subsections 16.1 to 16.4 are not
observed. BI reserves the right to conduct
more in-depth goods receiving inspections for
compliance with the rules under subsections
16.1 to 16.4 during the normal course of busi-
ness. Defects which become apparent in the
course of such inspection shall be reported
immediately. With respect to these defects, the
Contractor hereby waives the defence of belat-
ed notice of defect. Where BI ascertains the
presence of defects, BI shall be entitled to re-
turn the entire delivery. The rules in subsection
10.1 otherwise apply mutatis mutandis.
17. Anti-corruption
17.1 The Contractor represents and warrants that it,
its owners, directors, officers, employees, sub-
contractors and agents will act in full compli-
ance with any applicable anti-corruption laws
and regulations, including the FCPA, UK
Bribery Act, German Criminal Code, etc. and
industry and professional codes of practice.
Without limiting the generality of the forego-
ing, the Contractor represents and warrants in
particular that the Contractor, its owners, di-
rectors, officers, employees, subcontractors
and agents will not directly or indirectly in
connection with the business of BI or with this
contract:
(i) offer, promise, pay or arrange for pay-
ment or giving of a bribe or any benefit,
advantage or anything of value to any
Public Official, individual, entity or any
other third party in exchange for an im-
proper advantage in any form either di-
rectly or indirectly in order to fulfil, ob-
tain or retain (a) regulatory requirements,
Boehringer Ingelheim Page - 14 -
(b) any kind of business including any
commercial transaction to which BI is a
party, or which is otherwise in connec-
tion with this contract or (c) any other
improper advantage;
(ii) transfer anything of value to a Public Of-
ficial without the prior approval of the BI
contact person, regardless of whether or
not such transfer might constitute a bribe;
(iii) transfer anything of value to subcontrac-
tors, agents or any third party for the
purpose of offering, promising, paying,
receiving, soliciting, or arranging for the
payment of, or reimbursing anyone for
payment of, a bribe or a transaction of
anything of value to a Public Official;
(iv) or request, accept a promise of or receive
any payment, benefit or advantage from
any individual or entity for oneself or for
a third party in return for giving another
person or entity unfair preferences in the
procurement of goods or commercial or
other services in connection with this
contract.
17.2 For the purpose of this contract, “Public Offi-
cial” means any officer or employee of a local
or foreign government or any department,
agency, political party, institution, or instru-
mentality thereof (including officers and em-
ployees of government controlled entities), or
of a public international organisation as well as
any person acting in an official capacity for or
on behalf of any such government, department,
agency, institution or instrumentality, or for or
on behalf of any such public international or-
ganisation as well healthcare professionals,
working in healthcare institutions, in which the
central, regional or local government owns an
interest or has control or which are paid partly
or as a whole by the government.
17.3 The Contractor shall report any suspicion of
past, current or potential violations of this Sec.
17 to the BI contact person. If the Contractor is
in doubt whether a certain act violates its obli-
gations under this Sec. 17, the Contractor shall
contact the BI contact person and shall delay
the decision before taking the action.
17.4 The Contractor shall ensure that its directors,
officers, employees, subcontractors and agents
receive appropriate anti-corruption training.
17.5 The Contractor agrees that BI shall have the
right, at its cost, at any time upon reasonable
prior notice, to audit Contractor’s records to
ensure its compliance with the provisions of
this contract and applicable laws and regula-
tions by ensuring high level of confidentiality.
In addition, upon BI‘s request from time to
time, the Contractor agrees to certify compli-
ance with the foregoing in a form suitable for
BI.
17.6 Any violation of this Sec. 17 constitutes a ma-
terial breach of this contract. In addition to any
other sanction provided by law and/or this con-
tract, BI may terminate this contract for cause
and with immediate effect, if the Contractor
violates its obligations under this Sec. 17.
17.7 The Contractor is aware of and acknowledges
that BI will exclude any potential contractual
partners who engage in bribery, collusive prac-
Boehringer Ingelheim Page - 15 -
tices or any other form of corruption or fraud
from bids for tenders and future contracting.
17.8 The Contractor shall indemnify and hold BI
harmless for any loss or damage resulting of a
breach by the Contractor, its directors, officers,
employees, subcontractors and agents of this
Sec. 17 or of any applicable laws and regula-
tions.
18. Export control clause
18.1 The Contractor understands and agrees that the
items including goods, software, technology
(specific technical information necessary for
the development, production, or use of a prod-
uct) and technical services provided to BI un-
der this contract may be subject to internation-
al, U.S. and any other applicable export control
laws and regulations (hereinafter “Laws”) re-
stricting exports, re-exports, transfers or dis-
closures, regardless of the mode of provision
(hereinafter “Transactions”). The Contractor
shall comply with all such Laws. The Contrac-
tor shall determine whether an item is con-
trolled under the Laws and identify the specific
export control status of the item. If the item is
subject to any restrictions or license require-
ments under the Laws, the Contractor shall no-
tify BI about these restrictions prior to provid-
ing the item to BI, including information on
where the controlled item is listed (e.g. U.S.
Commerce Control List). The Contractor shall
cooperate with BI by providing upon request
information and other assistance necessary for
the classification (e.g. on the US Export Con-
trol List), export documentation, license de-
termination, export licensing, etc. of items
provided to BI under this contract.
18.2 The Contractor confirms that it is neither a
sanctioned party (i.e. sanctioned by any sanc-
tioned party list) nor controlled by a sanctioned
party to 50% or more. The Contractor shall no-
tify BI without undue delay in case of any
changes in this status.
18.3 The Contractor shall cooperate fully with BI in
any official or unofficial audit or inspection re-
lated to this contract in connection with the
Laws.
18.4 The following shall apply in the event BI pro-
vides the Contractor with items pursuant to this
contract:
a) The Contractor shall not, without first ob-
taining permission to do so from the ap-
propriate authorities, perform any further
Transactions of items provided by BI un-
der this contract should (i) the item be
controlled under the Laws; (ii) the Trans-
action be to any country, person or other
party that is ineligible to receive such
item, i.e. sanctioned by any sanctioned
party list (hereinafter: “Sanctioned Party”)
or embargo under the Laws; or (iii) the
Transaction be to a person or other party
if the Contractor knows or has reason to
assume that such person or party intends
to provide the item to any such country,
person or party, or intends to use or allow
others to use the item for activities related
to military or otherwise restricted use.
b) BI will only perform any Transaction of
items if the Transaction is not restricted
by the Laws. BI is not obliged to perform
any Transaction of items if the required
Boehringer Ingelheim Page - 16 -
licenses or other documents have not been
received.
c) The Contractor shall indemnify and hold
BI harmless against any third party claims
arising from or in connection with any of
the provisions of this Section including
any violations by the Contractor`s em-
ployees, consultants, agents, or customers.
19. Changes to products or processes
The Contractor shall inform BI without undue
delay, in writing, and in advance of any in-
tended changes to products and/or manufactur-
ing processes or analysis methods. Changes to
products refers e.g. to changes in product qual-
ity, quality and source of raw materials, syn-
thesis route, including chemicals used, size and
type of production lines, production sites, sig-
nificant increases in batch size (more than thir-
ty (30) percent), and outsourcing of production
stages and/or analysis work.
20. Confidentiality of and title to information
20.1 The Contractor shall hold in strict confidence
all visual, verbal, written, and/or electronic in-
formation, data, material, or know-how, as
well as samples and specimens pertaining
thereto (hereinafter collectively referred to as
"Confidential Information") either designated
confidential or for which it should be assumed
that they should be handled as confidential,
and which is disclosed during ordering or ob-
tained during execution of the Order for the
duration as well as after the conclusion of the
Order, and accordingly to refrain from disclos-
ing Confidential Information to third parties
without the prior written consent of BI except
to execute the Order, from making any com-
mercial use of Confidential Information what-
soever, and from engaging in any other activity
in relation to disclosed and obtained Confiden-
tial Information.
20.2 The parties shall protect Confidential Infor-
mation (specifically of a proprietary, scientific,
or technical nature) against unauthorised ac-
cess by third parties. To the extent Confiden-
tial Information is communicated via the Inter-
net, the use of encryption technology shall be
required (for direct communication between
the parties, BI shall provide suitable technolo-
gy free of charge at http://guides.boehringer-
ingelheim.com).
20.3 The Contractor shall not decompile, reassem-
ble, reverse engineer or otherwise analyse any
part of the Confidential Information of BI
without BI´s explicit written consent.
20.4 Requirements on the confidentiality and non-
use of Confidential Information shall not apply
to the extent such Confidential Information (a)
was known to the Contractor prior to disclo-
sure by BI, (b) was or will be generally known
through lawful publication or other lawful
means without the Contractor's involvement,
(c) was otherwise (i.e. without directly or indi-
rectly originating from BI) demonstrably dis-
closed to the Contractor without violation of a
duty of confidentiality, or (d) must be dis-
closed by law. Information that can only be ob-
tained by compiling isolated, publicly availa-
ble pieces of information shall not be consid-
ered generally known.
Boehringer Ingelheim Page - 17 -
20.5 To the extent employees of the Contractor or
third party (including subcontractors) require
access to Confidential Information in order to
perform the contract, the Contractor shall con-
tractually impose upon them the same obliga-
tions specified in subsection 20. The Contrac-
tor shall verify such to BI in writing upon re-
quest.
20.6 The Contractor shall, at BI's discretion, return
to BI or destroy or erase all Confidential In-
formation received and/or obtained upon com-
pletion of the Order and without retaining any
copies or data. To the extent required by law,
the Contractor shall retain a copy for documen-
tation purposes.
20.7 All Confidential Information BI has provided
to the Contractor for purposes of its perfor-
mance of the contract and the documents the
Contractor has prepared to BI’s specific direc-
tions shall remain the property of BI, and the
Contractor may not use them, reproduce them,
or provide them to third parties for any other
purpose. BI hereby expressly reserves its intel-
lectual property rights to all Confidential In-
formation provided to the Contractor. To the
extent that BI incurs losses as a result of a
breach of any of these obligations, the Con-
tractor shall be liable to BI.
20.8 The provisions of this subsection 20 shall ex-
tend for ten (10) years beyond the mutual
completion of the Order, subject to any legal
confidentiality requirements beyond this peri-
od.
21. Data protection
The Contractor shall comply with applicable
data protection laws. To the extent that the
Contractor collects, processes or uses personal
data on behalf of BI when rendering the work
(“Processing”) according to Article 28 of the
EU General Data Protection Regulation
2016/679, the Contractor shall, upon BI’s re-
quest, enter into any additional contractual ar-
rangement which is, in BI’s reasonable opin-
ion, required by applicable law, especially in
case of transfers of personal data to recipients
outside the European Union. Such contractual
arrangements may include (i) BI’s standard
contract for Processing, and/or (ii) the Europe-
an Union’s Standard Contractual Clauses for
the transfer of personal data to processors
and/or (iii) any other agreement that competent
data protection authorities have declared to be
compulsory or acceptable to comply with data
protection law obligations.
22. Rights to results and publication
22.1 All data, materials, documents, experience
(know-how), and all other results (hereinafter
referred to as "Results") obtained in the course
of providing the deliverable are the exclusive
property of BI. The Contractor hereby assigns
to BI any and all rights to the Results, includ-
ing but not limited to all copyrights, personali-
ty rights, and trademarks, as well as any and all
associated rights, including all conceivable le-
gal rights to designs (technical designs, drafts,
concepts). BI shall be exclusively entitled to
exploit the Results in any place at any time
without restriction.
Boehringer Ingelheim Page - 18 -
22.2 BI shall also acquire exclusive title to all cor-
poreal items of property and data storage me-
dia created by the Contractor or at the Contrac-
tor's direction in connection with the delivera-
bles and performance provided to BI.
22.3 The Contractor shall notify BI without undue
delay of any protectable inventions resulting
from the work performed by the Contractor. At
BI's request, the Contractor shall assert an un-
restricted claim to the inventions vis-à-vis the
inventors and shall thereupon unconditionally
transfer these rights to such inventions to BI
without further compensation.
22.4 BI shall have the sole right to apply for proper-
ty rights globally, with reference to the inven-
tor(s), in its own name and at its own cost, and
likewise to use the invention exclusively and
without restriction. To the extent necessary,
the Contractor shall support the granting and
maintaining of these property rights by provid-
ing such declarations as BI may request from
time to time. The Contractor guarantees that
the inventor(s) shall be made available to BI at
no charge in a timely manner and to a reasona-
ble extent to assist with the patent applica-
tion(s), and submit any declarations necessary
for the granting and maintaining of the pa-
tent(s).
22.5 The Contractor guarantees that appropriate
agreements have been or shall be concluded
before the start of performance with all third
parties involved in the deliverables and per-
formance, including but not limited to its em-
ployees and/or subcontractors that permit the
Contractor to possess the rights specified in
this subsection 22 to the extent described here-
in.
22.6 All rights of publication shall lie exclusively
with BI. Any publication that is planned by the
Contractor, its employees, or third parties en-
gaged by the Contractor must be forwarded in
manuscript or photocopy to BI in advance for
its written consent. BI shall render a decision
in this respect within six (6) weeks.
22.7 The Contractor shall provide the deliverables
(services and items) of the contract or Order
free of any and all third-party rights. Insofar
the Contractor hereby warrants that it is the
exclusive copyright holder of the deliverables
(services and items) of the contract or Order,
and has made no dispositions in conflict with
the transfer of these rights to BI. Where this is
not certain with respect to specific (partial)
works resulting from the provided deliverables
and performance, the Contractor shall inform
BI in writing and furnish BI with all known
facts.
22.8 The Contractor further warrants that it shall
grant all copyright and related rights holders
involved in providing the deliverables (ser-
vices and items) of the contract or Order an
appropriate stake in the resulting earnings as
required by law, including but not limited to
the German Copyright Act [Gesetz über Ur-
heberrecht und verwandte Schutzrechte].
22.9 The Contractor shall fully indemnify BI
against third party claims asserted against BI
pursuant to Sec. 32 (a) German Copyright Act.
Boehringer Ingelheim Page - 19 -
22.10 Furthermore, the Contractor shall fully indem-
nify BI against all third party claims asserted
on the basis of any infringement of industrial
property rights or copyright as a result of the
Contractor's contractual provision of the deliv-
erables and performance.
23. Title to provisions
23.1 Unless otherwise stipulated, all patterns, mod-
els, tools, films, materials, raw materials, etc.
which BI has produced/procured for the Con-
tractor to execute the Order or provided for the
Contractor to perform the contract, including
associated documentation (hereinafter collec-
tively referred to as "Provisions"), shall be-
come the property of BI, even where they re-
main in the possession of the Contractor (con-
structive possession of chattels by agreement
[“Besitzmittlungsverhältnis”], Sec. 930 Ger-
man Civil Code).
23.2 The Provisions may only be used to perform
the contract for BI, and may only be repro-
duced as required by operations and in compli-
ance with copyright provisions, and only inso-
far as absolutely necessary to perform the con-
tract.
23.3 The Contractor shall label the Provisions
"Property of Boehringer Ingelheim", store
them with due care at its own cost separately
from the Contractor's property for the duration
of the contract, handle them with care, main-
tain them at its own cost, and insure them
against loss. Provisions may not be removed,
sold, assigned by way of collateral, pledged,
etc. from the location specified in the Order,
without the prior consent of BI. The Contractor
shall bear the risk of loss and damage regard-
ing the Provisions, however not of normal
wear.
23.4 The Provisions, including any duplicates, shall
be returned to BI without undue delay follow-
ing performance of the contract.
24. Delivery of documents
The Contractor shall deliver to BI all docu-
ments required by BI to use, set up, assemble,
process, store, operate, maintain, inspect, ser-
vice, and repair the delivered item promptly,
without solicitation, and at no cost. The stand-
ards and guidelines specified by BI shall apply
as amended.
25. Property of Contractor
BI shall not be liable for the accidental loss,
damage or other deterioration of property
brought by the Contractor or its employees on-
to BI’s premises for purposes of assembly,
servicing, inspection, maintenance, etc.
26. No exploitation of business relationship for
advertising purposes
The Contractor is not permitted to refer to the
business relationship it has with BI in any in-
formational or advertising material, or to use
the name, corporate logo or trademarks of BI
and/or BI Affiliates and/or partner companies
of BI for advertising purposes without BI's
prior written consent.
Boehringer Ingelheim Page - 20 -
27. Health and safety rules and regulations
27.1 The Contractor shall strictly adhere to envi-
ronmental health and safety rules and regula-
tions pursuant to the code of conduct for BI's
partner companies and their employees. This
code of conduct shall be applicable to all con-
tractors, constituting an integral part of the
contract, and Contractors shall likewise impose
a binding obligation on their BI-approved sub-
contractors. The Contractor shall verify such to
BI in writing upon request.
The text of the code of conduct for BI partner
companies and their employees as amended
can be found online at
https://partners.boehringer-
ingelheim.com/index.php?lang=en
All environmental (including energy), health
and safety orientation and training sessions
will be provided at the time the contract is
awarded at no cost to the Contractor.
27.2 In the event that the Contractor violates the
code of conduct or established protections de-
spite warning and a reasonable period for re-
mediation, BI shall be entitled to terminate the
contractual relationship without notice and
demand compensation for the resulting damag-
es. In addition, the Contractor may be (tempo-
rarily) excluded from further business relation-
ships with BI.
27.3 The health and safety training under the code
of conduct referenced in subsection 27.1 shall
be deemed a condition precedent to any grant
of access to BI's plant. BI shall furnish binding
training documentation in respect thereof. That
training documentation as amended can be
found online at
https://partners.boehringer-
ingelheim.com/index.php?lang=en
The Contractor shall register its employees
with the BI liaison by using the registration
form which may be downloaded off the Inter-
net, wherever possible five (5) days prior to the
commencement of work. Submission of a reg-
istration form shall be deemed to constitute
confirmation by the Contractor that it has in-
structed its employees on BI's code of conduct
for BI partner companies. The Contractor shall
likewise satisfy this pre-registration obligation
with respect to the employees of its approved
(sub)contractors. At such time as the job
comes to an end and/or access authorisation
expires, the Contractor shall ensure that the
plant access IDs are returned to BI.
28. Further provisions
28.1 The Contractor is not entitled to assign rights
or delegate duties under the Order to third par-
ties in whole or in part without BI's prior writ-
ten consent.
28.2 The parties hereby agree that BI may assign all
rights or delegate all duties pursuant to this
contract to any BI Affiliate, and that any of
BI's rights or obligations pursuant to this con-
tract may be exercised by one of its Affiliates.
28.3 “Affiliate” means any entity which directly or
indirectly Controls, is Controlled by, or is un-
der common Control with a Party. “Control”
means direct or indirect ownership or control
of more than 50% (fifty percent) of the voting
Boehringer Ingelheim Page - 21 -
interests of the Party or the power to direct or
cause the direction of the management and pol-
icies of such Party whether by contract,
through majority ownership of voting capital
stock or otherwise. “Controlled” shall be inter-
preted accordingly.
28.4 In the event that portions of the Order, includ-
ing but not limited to portions of the contractu-
al object, are performed by the Contractor in
close collaboration with a BI Affiliate, BI shall
inform the Contractor. In such cases, the Con-
tractor shall issue its invoice directly to that
Affiliate. The invoice shall refer to each im-
putable deliverable pursuant to the contractual
object using the information provided by BI.
However, BI shall remain liable for the proper
payment of the invoice pursuant to the Order
by the respective Affiliate. All payments made
by the appropriate Affiliate shall satisfy BI's
obligations under that Order.
28.5 Neither party may be held liable for defaults or
delays in performing their contractual obliga-
tions where such are attributable to force
majeure such as war, fire, flood, civil unrest,
strikes, government actions or controls, and for
other reasons beyond the control of the party in
question (hereinafter referred to as "Force
Majeure Situations"). The party affected by
force majeure shall make every effort to coun-
teract the incident and shall coordinate with the
other party as to emergency measures. Where
the Force Majeure Situation persists for more
than one (1) month, the party unaffected by
force majeure shall be entitled to exceptional
termination at any time.
28.6 The partial or complete failure to assert, or a
delay in asserting any right by any party shall
not be deemed a waiver or abandonment of
such a right. Waivers of a right by a party may
be made only in writing signed by that party.
29. Governing law
The contract is subject solely to German law.
The UN Convention on the International Sale
of Goods (CISG) and conflict of laws shall not
apply.
30. Jurisdiction and venue
Exclusive jurisdiction and venue for all dis-
putes shall be the competent court in Mainz,
Germany. This shall also apply to any litiga-
tion on bills of exchange and cheques.
31. Severability clause
Should any individual provisions of these
GTC-P be deemed invalid in whole or in part,
the validity of the remaining provisions shall
remain unaffected.
32. Precedence of German version of GTC-P
The native language for BI is German. This
English version of the GTC-P is a translation
based on the German version of BI’s General
Terms and Conditions of Purchase [“Allge-
meine Einkaufsbedingungen” – “AEB”]. In
case of any inconsistencies between the con-
tent of this English translation and the content
of the German AEB, the content of the Ger-
man AEB shall prevail.
Boehringer Ingelheim Page - 22 -
Part II:
Special Terms and Conditions for Services
33. Object of the Order
33.1 The Special Terms and Conditions for Services
set forth below shall apply to services of all
kinds, such as any and all consulting, market-
ing, market research, testing, maintenance, or
cleaning services, but shall also refer to per-
formance-based services, such as laboratory
services, sample logistics, or method develop-
ment (hereinafter collectively referred to as
"Service" or “Project”) which do not constitute
construction, engineering, or planning services,
to which BI's Terms and Conditions of Con-
tract for Construction Services [“Vertragsbed-
ingungen für Bauleistungen”] shall apply ex-
clusively.
The object of the Order shall be the Contrac-
tor’s performance of the Service or Project de-
scribed in the specification of services or pro-
ject description contained in the Order (as well
as in BI’s invitation to tender and the Contrac-
tor's offer).
33.2 Changes to the Service as described in the
specification of services shall require BI's prior
written consent. Regarding changes that could
have an impact on the costs, quality, or sched-
ule of the Service/Project, the parties shall
agree on a change to the Order. Otherwise, the
Contractor shall not be entitled to demand any
compensation for such changes. The Contrac-
tor shall notify BI in writing and without un-
due delay of any changes as soon as they be-
come apparent.
34. Principles of the contract
34.1 BI shall appoint a coordinator to handle all
substantive questions in connection with this
Order.
34.2 The Contractor shall appoint a coordinator for
coordinating the Service/Project (hereinafter
referred to as "Coordinator") who shall be au-
thorised to accept instructions and individual
orders from BI. The Coordinator shall also re-
main available to BI as its contact on all tech-
nical and commercial queries. The Contractor
shall notify BI in writing of the identity of the
Coordinator. The Contractor shall ensure that
the Coordinator's duties generally are not as-
signed to any other person. Should such an as-
signment or delegation take place for legiti-
mate reasons and/or is requested by BI, the
Contractor shall without undue delay inform
BI of the identity and qualifications of the new
Coordinator. BI shall then have the right, with-
in a reasonable period, to refuse or consent to
the reassignment.
34.3 The parties shall appoint one deputy each for
these Coordinators.
35. Obligations of the Contractor
35.1 The Contractor shall take all steps necessary to
perform the Service/Project pursuant to the
specification of services, and shall inform BI
regularly of the progress of the work.
Boehringer Ingelheim Page - 23 -
35.2 The Contractor shall promptly submit the full
and detailed Results as agreed in the specifica-
tions of services for BI's review and approval.
At BI's request, the Contractor shall make all
reasonable changes to the Results to be deliv-
ered within one (1) week of receiving BI's
written request.
35.3 The Contractor shall ensure that:
(i) the Service described in the specifications
of services is performed within the stipu-
lated times and in accordance with rele-
vant legal provisions and recommenda-
tions, as well as pursuant to the agree-
ments made in the Order;
(ii) trained and appropriately qualified em-
ployees are scheduled in order to perform
the Service within the planned time frame;
(iii) all data, reports, and other information
provided to BI reflect the latest scientific
knowledge, and have been compiled in
such format as has been agreed with BI;
(iv) to the extent applicable, it complies with
all relevant codes of conduct, including
MRS, ABPI, and ESOMAR (International
European Society for Opinion and Market
Research) in the most current version, as
well as any applicable local codes of con-
duct;
(v) to the extent applicable, it has complied
with the relevant legal provisions and
regulations on collaboration between the
pharmaceutical industry and healthcare
professionals, such as the IFPMA Code of
Marketing Practices, the EFPIA Code of
practice on the promotion of medicines,
and the FSA Code of Conduct on the Col-
laboration with Healthcare Professionals
of the association on collaborating with
Healthcare Professionals ["Freiwillige
Selbstkontrolle für die Arzneimittelindus-
trie e. V.”] (FSA Code on Healthcare Pro-
fessionals) [http://www.fs-
arzneimittelindustrie.de/kodex- fach-
kreise.html].
36. Engagement of healthcare professionals and
healthcare organisations
36.1 The cooperation, including contractual rela-
tionships, between the pharmaceutical industry
and healthcare professionals and healthcare or-
ganisations (the “Covered Recipients”) is sub-
ject to certain laws. These laws are relevant al-
so in case that the Contractor engages a Cov-
ered Recipient when rendering the Services.
Consequently, the Contractor shall include in
its agreements with Covered Recipients any
mandatory provision in accordance with appli-
cable laws. BI shall provide advice to the Con-
tractor with respect to the required approval
process and mandatory provisions.
36.2 Any transfer of value to a Covered Recipient
may be subject to reporting/disclosure re-
quirements under the laws of certain countries
such as the United States and European coun-
tries. As details to be reported/disclosed may
vary depending on the country of origin of the
Covered Recipient BI shall inform the Con-
tractor about relevant details in each case (the
“Mandatory Details”).
Boehringer Ingelheim Page - 24 -
36.3 The Contractor shall support BI in meeting its
reporting/disclosure obligations. Before enter-
ing into the agreement with the Covered Re-
cipient the Contractor shall provide BI with the
required details for the approval process for a
fair-market-value-check (if required). BI shall
inform the Contractor about the Mandatory
Details for reporting and shall provide a tem-
plate for the spend reporting (“Spend Capture
Portal Template”). The Contractor shall send
the completed Spend Capture Portal Template
to BI as soon as possible after a payment or
other transfer of value to a Covered Recipient,
however, no later than by 31 December of the
respective year.
36.4 Prior to any transfer of data to BI during the
approval process or the conclusion of the con-
tract between the Contractor and the Covered
Recipient, whichever occurs first, the Contrac-
tor shall inform the Covered Recipient about
BI’s reporting/disclosure obligations and ob-
tain Covered Recipient’s consent for using
Mandatory Details for the general preparation
of the report. If required by applicable data
protection laws, BI shall directly obtain the
Covered Recipient´s consent for the disclosure
of its personal data in the report.
37. Obligations of the Contractor regarding
pharmacovigilance
37.1 As used herein an “Adverse Event” or “AE”
means any undesirable medical occurrence in a
patient (human or animal) or participant in a
clinical study to whom a BI pharmaceutical
product for humans or animals has been ad-
ministered which is not necessarily related to
the respective treatment.
37.2 In order to enable BI to comply with its
world-wide regulatory reporting responsibility,
the Contractor shall forward to BI all infor-
mation received on an AE within one (1) busi-
ness day after the Contractor became aware of:
a) any AE,
b) any report where the embryo or foetus
may have been exposed to the medicinal
product via mother or semen with and
without event and any AEs in conjunction
with breastfeeding;
c) any report of lack of effect, medication er-
ror with/without AE, overdose
with/without AE, abuse with/without AE,
misuse with/without AE, drug-drug or
drug-food interaction, transmission of an
infectious agent via a BI product, off label
use (use outside the approved indication
or contrary to a contraindication)
with/without AE;
d) any report of product complaints or falsi-
fied product associated with an AE;
e) any information where at least adverse
event information after intake of a BI ac-
tive substance/product by patient(s) is
available, and all other information (e.g.
about counterfeits) regarding a BI product
that might lead to a risk for a patient.
37.3 The Contractor shall forward all information in
English translation on AEs on the aforemen-
tioned items a) through e) as it has been re-
ceived, without screening, selection or further
processing, either by fax or secure e-mail to
the following BI PV global indicating the date
of receipt:
Fax: +49 6132-72 90454
Boehringer Ingelheim Page - 25 -
E-mail:
PV_global_casemanagement@boehringer-
ingelheim.com
37.4 Upon BI’s request, the Contractor shall pro-
vide BI with further information on the respec-
tive AE report.
37.5 Depending on the scope of Services under this
contract, BI may request the Contractor to
comply with additional PV requirements, in-
cluding but not limited to PV training for the
Contractor’s personnel engaged in the provi-
sion of the Services. The Contractor agrees to
comply with all PV provisions required by ap-
plicable law or BI policies (e.g. SOPs) which
shall be specified in writing for each Order, as
required.
37.6 The Contractor shall apply with all archiving
and record-keeping requirements according to
respective industry standards and applicable
law. With regard to records retention the Con-
tractor shall apply its internal processes and
systems on records retention.
38. Compensation
38.1 As consideration for the contractual perfor-
mance of the Service/Project, the Contractor
shall receive the maximum amount stated in
the Order under "Total net value" plus the stat-
utory VAT where applicable.
38.2 The amount specified in the Order shall be
due each month and shall be charged on an
hourly or daily rate basis. The Contractor shall
append a detailed itemisation to each invoice,
indicating the following information: i) name
of Contractor(s) or staff, ii) qualification level,
iii) date service was provided, iv) brief de-
scription of work and v) number of days of
Service.
OR
The amount specified in the Order is calculated
and stipulated based on the assumptions in the
specification of services. This amount shall
cover all costs and expenses (both internal and
transit costs) arising in connection with the
Contractor's performance of the Ser-
vice/Project excluding travel costs. Transit
costs shall be set at the actual costs, i.e. less
profit, overhead, administrative fees, or sur-
charge. BI shall be entitled to audit compliance
with this clause. Upon request, the Contractor
shall furnish BI with all necessary documents
for such an audit without undue delay.
The applicable mode of compensation shall be
agreed in the respective Order.
38.3 Transit costs and travel costs shall then only be
reimbursable by BI when they (i) were agreed
to by BI in writing and (ii) the Contractor
submits the original receipts. The travel ex-
pense guidelines as amended shall be provided
by BI and shall apply mutatis mutandis.
39. Term and termination
39.1 The contractual relationship shall commence
upon ordering by BI and shall end upon full
performance of the Service/completion of the
Project, however no later than upon conclusion
of a stipulated performance period.
Boehringer Ingelheim Page - 26 -
39.2 The right of both parties to terminate the con-
tract without notice for cause [“Kündigung aus
wichtigem Grund”] shall remain unaffected.
Specifically, a gross breach of contractual ob-
ligations by the other party shall constitute
cause.
39.3 Furthermore, any merger of the other party
with a third party to the extent that it entails a
major change in ownership and control shall
constitute cause. Each party shall inform the
other party without undue delay and in writing
of any such change or of any such merger.
However, this provision shall not apply should
(i) a change of ownership amongst the current
owners/shareholders take place, or (ii) the
change of ownership be effected by way of a
corporate restructuring scheme within the BI
Group.
39.4 BI shall furthermore be entitled to terminate its
Order at any time and with immediate effect.
In such case, however, BI shall be obliged to
compensate the Contractor for all Services it
has hitherto rendered pursuant to the specifica-
tion of services. Costs the Contractor incurs for
obligations the Contractor has already entered
into at the time it received notice of termina-
tion shall likewise be refunded, provided those
obligations comply with the specification of
services and the Contractor is unable to termi-
nate them. The legal consequences under this
subsection 39.4 shall not apply should BI have
terminated its Order pursuant to subsection
39.2 of these Special Terms and Conditions.
39.5 Notice of termination must be given in writing.
39.6 Subsection 22 shall apply to Results made up
to the point at which the contract was termi-
nated.
39.7 In the event of premature termination of the
parties' collaboration, the Contractor shall
without undue delay furnish BI with all Results
it has produced up to the date of termination.
Boehringer Ingelheim Page - 27 -
Part III:
Special Terms and Conditions for Design Contracts
40. Bases of agreement
The Contractor shall comply with the relevant
legal provisions on unfair competition, the
German Medical Products Advertising Act
[Heilmittelwerbegesetz], the FSA Code of
Conduct on the Collaboration with Healthcare
Professionals, and Boehringer Ingelheim’s
Guidelines on Corporate Design
https://mybi17.eu.boehringer.com/sites/mybi/c
ompany/Pages/corporate_design.aspx
in performing the contract.
To the extent meetings are held during the per-
formance of the contract, the Contractor shall
record minutes of the meetings, which it shall
send to BI within one (1) week. Minutes shall
be binding insofar as BI does not object to
them within fourteen (14) days of receipt.
The Contractor shall be entitled to employ
third parties to perform the contract following
consultation with BI. In such case, the condi-
tion precedent thereto shall be that the Con-
tractor does not select such third party until it
has procured other offers and consulted BI.
Unless otherwise specifically agreed, the Con-
tractor shall engage such third party in its
name and for its own account. The Contractor
shall be responsible for subsequently review-
ing all third party invoices, and the Contractor
shall claim all discounts, commissions, rebates
etc. and to pass them on to BI in full. The Con-
tractor shall furnish evidence of costs to be
charged on to BI by submitting copies to BI.
41. Ownership rights and intellectual property
41.1 Following payment of the stipulated compen-
sation, any and all ownership rights and rights
to intellectual property (including patents,
trademarks, patterns, copyrights and related
rights, whether protected or not) for all works
prepared or created by the Contractor or by
any employee, representative, or agent of the
Contractor in the course of performing work
pursuant to the Order shall be transferred to BI
at the time of their creation. This shall not ap-
ply to "Background Rights”, i.e. intellectual
property rights or copyrights to intellectual
property of any and all kinds that already were
in existence at the time of ordering. For pur-
poses of clarification, the parties hereby agree
that "representatives" as defined in this clause
shall, without limitation, refer to freelance
workers and any other natural or legal person
performing work pursuant to the Order.
41.2 Regarding services which must be procured
but are not covered by the Order (including
buy-outs, i.e. third party rights of use, defined
by time, location, and substantive scope) and
which are necessary or desirable for the or-
dered work (e.g. buyouts from subcontractors,
models, photographers, composers, speakers,
artists, publishers, and record companies), the
Contractor shall:
a) at the time of proposing certain work and
in no event later than at the time of sub-
Boehringer Ingelheim Page - 28 -
mitting a project proposal, inform BI of
buy-outs which may be necessary or de-
sirable and which BI should consider;
b) make written enquiries with BI as to
whether there are any internal BI policies
governing the review and, where applica-
ble, timely procurement of such buy-outs;
c) in preparing any project proposal and
when performing the work ordered, strict-
ly comply with these policies;
d) ensure that BI has such buy-outs as are
deemed necessary pursuant to the Con-
tractor's obligations under this subsection
41.2 in a timely manner and in sufficient
quantities, unrestricted in time, location,
and substance; and
e) inform BI in a timely manner prior to the
expiry of any such rights of use so that BI
is able to negotiate further buy-outs if and
as soon as BI should require this.
41.3 With the exception of Background Rights, the
Contractor shall have no claim to any rights on
trademarks, trade names, copyrights, or regis-
tered design rights related to the works sup-
plied.
41.4 Any and all documents the Contractor, its rep-
resentatives, employees, or agents prepare pur-
suant to BI's Order shall be labelled
"Boehringer Ingelheim" along with the year
of their creation.
41.5 The Contractor hereby warrants that all works
created by it or for it shall constitute its own
works, and shall be free of third party rights or
encumbrances, whether in time, location, or
substance, unless the Contractor informs BI
otherwise in writing. The Contractor hereby
warrants that it shall not use or reproduce any
work protected by copyright or other intellec-
tual property right (either in whole or in part)
without having first requested permission to do
so from BI and the owner of such rights. The
Contractor hereby further warrants that its
works, when used, reproduced, modified, pub-
lished, licensed, or otherwise utilised by BI,
shall not infringe on any intellectual property
rights (including trademark and copyright) and
shall not constitute unfair competition.
41.6 With the exception of Background Rights and
upon payment of the stipulated fees, the Con-
tractor hereby transfers to BI in full, exclusive-
ly and without any further compensation, all
rights of ownership and intellectual property
rights (including patents, trademarks, patterns,
copyrights and related rights, whether protect-
ed or not) to works prepared or created by the
Contractor or any employee, representative, or
agent of the Contractor in the course of per-
forming the works ordered, worldwide and un-
limited in time, territory and content. The fore-
going transfer is global and unrestricted in
time, location, or substance. The Contractor
shall ensure that each of its employees, repre-
sentatives and agents fully and irrevocably
waive their rights to such property or intellec-
tual property in favour of BI. BI shall be au-
thorised, without restriction, to license, trans-
fer, or exploit the intellectual property, includ-
ing the right to reproduce it, adapt it, and pub-
lish it, whether in print, by audiovisual means,
electronic means, on the Internet or in other
media.
Boehringer Ingelheim Page - 29 -
41.7 In cases in which the Contractor uses in con-
nection with its performance of the contract a
work in which it already held the intellectual
property rights prior to commencing its work
for BI, the Contractor hereby grants and shall
ensure that BI and all BI Affiliates are granted
a licence which is unlimited in time, non-
exclusive, free of charge, sub-licensable, and
transferable, for their unrestricted use, repro-
duction, publication, licensing, and other use.
For purposes of clarification, the parties hereby
agree that the Contractor shall remain the own-
er of such intellectual property rights.
42. Fees
The agreed fee shall be payable as soon as the
contractually defined services have been ren-
dered, delivered to BI and have been formally
accepted as being proper in form and sub-
stance. The fee shall constitute full and final
compensation for all works and services of the
Contractor for ideas, design, texts, repeat runs,
etc., including worldwide rights of use thereto.
Any changes to the works and services and/or
fees/costs shall require BI's prior written con-
sent.
43. Domain names and SSL certificates
Domain names and SSL certificates relating to
BI, its business, or its products shall be regis-
tered/applied for by BI only, not by the Con-
tractor. Any need for domain names/SSL cer-
tificates (registration, purchase, or transfer)
shall be addressed by the Contractor to do-
clusively.
Boehringer Ingelheim Page - 30 -
Part IV:
Special Terms and Conditions for IT Software Licences
44. Scope of use of software
44.1 The Contractor hereby grants BI and BI's di-
rect or indirect Affiliates (hereinafter referred
to as the "Boehringer Ingelheim Group") a
non-exclusive, perpetual, global right to use
the software designated in the Order and the
accompanying documentation (pursuant to
ISO/IEC 26514) (hereinafter collectively re-
ferred to as "Software").
44.2 This right of use shall also apply to all compa-
nies, persons, and locations of the Boehringer
Ingelheim Group. Subject to limitations, BI
shall therefore be entitled to make the Software
available to the appropriate users either by
storing it on hard drives of individual computer
systems or by providing access via a network.
44.3 BI shall have the right to make the number of
copies necessary to reliably operate the Soft-
ware for its internal use, including but not lim-
ited to development, testing and quality assur-
ance systems (hereinafter collectively referred
to as "Non-Production Systems"), as well as
for its production systems, including back-up
copies of the Software and related documenta-
tion.
44.4 The Software may be transferred in any form
whatsoever from one computer system to an-
other computer system.
45. Scope of licence
The licence granted hereunder shall permit BI
to use the Software with any model of hard-
ware, system configuration, or platform for
which the Contractor has provided the Soft-
ware. Should BI expand, upgrade, or replace
its hardware models, system configuration, or
working platforms, it shall not be required to
obtain the Contractor's consent. Should use of
the Software be controlled by a software key
which is to be procured from the Contractor,
the Contractor shall furnish the necessary
software keys for further Non-Production Sys-
tems upon BI's request. Insofar as the Contrac-
tor intends to provide Open Source Software as
part of its contractual services, the Contractor
shall, as an essential contractual obligation, in-
form BI in writing without undue delay what
Open Source Software components should be
used and what licensing terms apply. The Con-
tractor shall ensure that the use of Open Source
Software does not restrict BI's contractual or
intended use of the contractual services. Liabil-
ity and warranty for Open Source Software are
based on the provisions of these GTC-P.
46. Transfer of right of use to third parties
BI may permanently transfer to third parties its
rights to use the Software, provided that the
third party acquiring the right of use agrees to
be bound by the further application of these li-
censing terms. In the event of such transfer, BI
shall furnish the third party with all copies of
Boehringer Ingelheim Page - 31 -
the Software and shall destroy copies it has not
delivered to the third party. BI's right to use the
Software shall be forfeited upon transfer.
47. Warranty and software maintenance
47.1 The Software shall be considered free of de-
fects provided it performs the stipulated ser-
vice when used in accordance with the con-
tract. To such extent, the Contractor hereby
warrants that the Software is free of defects.
47.2 Should defects be discovered within the statute
of limitations, the Contractor shall remedy
them by creating and installing a new version
of the Software that is free of defects within a
period set by BI. Further claims by BI shall
remain unaffected.
47.3 The installation of a new version of the Soft-
ware shall require BI's prior written consent.
Upon installing the new version of its Soft-
ware, the Contractor shall familiarise BI's em-
ployees with the new Software version by
providing appropriate training.
47.4 The Contractor shall furnish an alternative so-
lution on short notice in the event it is unable
to remedy a defect in the Software in short or-
der. In such an event, the Contractor shall
adapt the program documentation accordingly.
47.5 The Contractor hereby warrants to BI that, as
of the time of delivery, the data storage media
on which the Software was recorded and any
hardware which may have been supplied with
the Software are free of defects.
47.6 The Contractor hereby warrants that the Soft-
ware it has supplied is free of malware such as
viruses, Trojans, worms, etc., however appro-
priate testing of the Software through the use
of a state-of-the-art virus scanning program
shall be deemed sufficient.
47.7 The Contractor shall not be liable for claims
based on the use of the Software together with
programs or data which were not supplied by
or stipulated with the Contractor should the
damage from the use of the Software have
been avoidable had these programs or data not
been used.
47.8 The Contractor shall offer Software mainte-
nance services under standard market condi-
tions (including but not limited to hotline sup-
port and corrective maintenance once the war-
ranty has expired) for a period of at least five
(5) years from delivery.
48. Infringement of third-party rights
The Contractor hereby warrants that use of its
Software does not infringe any third party
rights. In the event that a third party asserts
claims against BI based on an infringement of
rights, the Contractor shall indemnify BI
against such claims. The Contractor shall also
exchange the part deemed an infringement of
property rights or procure full rights of use for
BI without undue delay, however within no
more than twenty (20) calendar days.
***