DOT estándar Especificaciones Libro 2005 - División I - 1101 a través de las Secciones 1911...
-
Upload
usamazarifeh -
Category
Documents
-
view
217 -
download
0
Transcript of DOT estándar Especificaciones Libro 2005 - División I - 1101 a través de las Secciones 1911...
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
1/112
Pgina 1
1101.1
1
Divisin IREQUISITOS GENERALES Y CONVENIOS
1101Abreviaturas
Siempre que estas especificaciones, planos, o Contrato de otrosdocumentos utilizan las siguientes abreviaturas, las siglas tienen lael siguiente significado:1101.1 GLOSARIO DE SIGLASAAN Asociacin Estadounidense de ViverosAAR Asociacin de Ferrocarriles AmericanosAASHTO Asociacin Americana de Carreteras del Estado y
Funcionarios de transporteAITC Instituto Americano de la Construccin MaderaAC Corriente alternaACI American Concrete Institute
AGC Associated General Contractors of America, Inc.AFP Instituto Americano de ArquitectosAISC Instituto Americano de Construccin en AceroAISI American Iron and Steel InstituteAITC Instituto Americano de la Construccin MaderaANSI Instituto Nacional de Estndares AmericanosARA Asociacin Americana de trenREA Ferrocarril de la Asociacin Americana de IngenieraASCE Sociedad Americana de Ingenieros CivilesASLA Sociedad Americana de Arquitectos PaisajistasASME Sociedad Americana de Ingenieros MecnicosASTM Sociedad Americana de Pruebas y MaterialesATR Automtico Grabadora de trficoAWPA Preservadores de madera de la Asociacin AmericanaAWS Sociedad Americana de SoldaduraAWG Calibre del cable de Amrica
AWWA American Water Works AssociationCCTV Circuito cerrado de televisinCMP Comunicaciones por Cable Pleno o corrugado
Pipa metalCMS Regstrate mensaje cambiableCOAX Radio Frecuencia de transmisin por cable (coaxial
Cable)CRSI Para hormign armado Steel InstituteCV Volumen compactadoDBE Desventaja empresa comercial
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 1/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
2/112
Pgina
1101.1
2
EEO Igualdad de Oportunidades en el EmpleoEV Volumen excavado
Vicepresidente EjecutivoVehculo de la emergencia de suscripcin preferenteFAA Administracin Federal de AviacinFHWA Administracin Federal de Carreteras,
USDepartment de TransporteSFS Federal de Especificaciones y Estndares, General
Administracin de Servicios deTLC Administracin Federal de TrnsitoGFI Interruptor de falla a tierraHH HandholeIEEE Instituto de Ingenieros Elctricos y ElectrnicosIES Iluminacin de la Sociedad de IngenierosICEA Asociacin de Ingenieros de CablesIMC Intermedio del conducto de metalISO Organizacin Internacional de NormalizacinIPS Tamao del tubo de hierroCCI Capacidad de Transmisin de InformacinITE Instituto de Ingenieros de TransporteJMF Trabajo Mix frmula utilizada en la bituminoso
Especificaciones.KVA Kilovoltios amperiosLV Sueltas de volumen para las mediciones, o de nivelacin
Curso para bituminosoM Gal 1.000 galonesMN MUTCD Minnesota Manual para el Control del Trfico Uniforme
DispositivosMn / DOT Departamento de Transporte de MinnesotaMN Estatutos Los Estatutos de MinnesotaMPCA Contaminacin de Minnesota Agencia de Control deNEC Cdigo Elctrico NacionalNEMA Asociacin Nacional de Fabricantes ElctricosNMC -El conducto no metlico
N Cuando se haga referencia al cable, es el calibre AWGnmero.NPDES Nacional de Eliminacin de Descargas Contaminantes del sistemaOSHA Seguridad Ocupacional y Administracin de Salud(P) (Definido en 1103)PCI Hormign pretensado InstitutoPIV Pico de tensin InvertirPLS Puro directo de semillasPVC Cloruro de polivinilo
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 2/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
3/112
Pgina
1101.2
3
Control de calidadAseguramiento de la CalidadControl de calidadControl de CalidadRCS Rampa de la seal de control
REA Asociacin Rural de ElectrificacinRF Radio FrecuenciaRHW La humedad y resistente al calor o reticulado
Polmero sintticoRMS Root Mean SquareRSC El conducto de acero rgidoSAE Sociedad de Ingenieros AutomotricesSI Sistema Internacional de Unidades (El Modernizado
Sistema Mtrico)SPDT Simple polo doble tiroSPST Polo simple tiro simpleSSPC Sociedad para la aplicacin de recubrimientos protectoresSV Volumen almacenadoSWPPP Aguas Pluviales Plan de Prevencin de la ContaminacinTH Carretera TroncalTMC Centro de Gestin de TrficoTMS Sistema de Gestin de TrficoTSM Gestin del TrficoUL Underwriters Laboratories, Inc.USD Estados Unidos Departamento de AgriculturaUV Ultra VioletaVCA Voltios de corriente alterna (60 Hz)VDC Voltios de corriente continuaXHHW Resistente a la humedad y el calor de la Cruz Vinculado
Polmero sinttico1101.2 Unidades Mtricas
El Sistema Internacional de Unidades (SI) (el modernizado sistema mtricoSystem) de acuerdo con la norma ASTM E 380 se utilizan en estas especificaciones.ASTM E 380 tambin proporciona factores de conversin y el comentario.Prefijo mtricas y MagnitudM mega (106)
k kilo (103)m mili (10 -3)
micro (10-6)n nano (10-9)
p Pico (10-12)Mtricas SmbolosUn amperio (corriente elctrica)cd candela (intensidad luminosa)
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 3/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
4/112
Pgina
1101.2
4
F faradio (capacidad elctrica)g gramos (masa)H Henry (inductancia)ha hectreas (rea)Hz hertz (frecuencia - ciclos o impulsos por segundo)
J julios (energa)kmh kilmetros por hora (velocidad)kilometros2 kilmetro cuadrado (rea)L litro (volumen)m / s metros por segundo (velocidad)m metro (longitud)m2 metro cuadrado (rea)m3 metros cbicos (volumen)m3/ S metros cbicos) en segundo lugar de tesorera (tipo
N newton (fuerza)N m newton metro (par)Pa pascal (presin, el estrs)s segundo (tiempo)S Siemens (conductividad elctrica)t toneladas mtricas (peso)V voltios (potencial elctrico)W vatios (potencia) ohmios (resistencia elctrica) C grados centgrados (temperatura)
1103Definiciones
A menos que otra intencin claramente parece, las palabras y frases(Incluidas las palabras y frases tcnicas y otros, como han adquiridoun significado especial) se interpretar de acuerdo a las reglas de la gramticay segn el uso general.
Dondequiera que los siguientes trminos o pronombres en lugar de ellos, seutilizados en estas especificaciones, planos, o Contrato de otros documentos, ella intencin y significado se interpretarn de la siguiente manera:
ADENDA
Un complemento de la propuesta como se haba publicado o impreso,adiciones que cubre, correcciones o cambios en las condiciones de licitacin parael trabajo de publicidad, que es emitido por el rgano de Contratacinlos posibles licitantes antes de la fecha fijada para la apertura de las propuestas.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 4/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
5/112
Pgina
1103
5
PUBLICIDAD DE LAS OFERTASEl anuncio pblico, como exige la ley, invitando a las ofertas para la
trabajo a realizar o materiales suministrados.
TOTALLos materiales naturales tales como arena, grava triturada, o taconita
de relaves, y el hormign triturado o salvado mezclas bituminosas, por lo generalcon un tamao de partcula especificado, para su uso en curso de construccin de la base, la pavimentacimezclas y otras aplicaciones especficas.
AUXILIAR LANELa porcin de la calzada contigua a la calzada para el estacionamiento,
velocidad de cambio, o para otros fines complementarios a travs del trficomovimiento.
PREMIOLa aceptacin por parte del rgano de Contratacin de la oferta, sin perjuicio de
la ejecucin y aprobacin del Contrato.
PROGRAMA BIDUn listado de los elementos del contrato en la forma propuesta que muestra las cantidades
y unidades de medida que prev el oferente a la unidad de oferta de insertar
precios.
POSTORUn individuo, empresa o corporacin presentar una propuesta de la
el trabajo anunciado.
PUENTEUna estructura, incluyendo apoyos, erigida sobre una depresin o una
obstruccin, tales como, por supuesto carretera agua, o de tren, y que tiene unpista o pasadizo para el trfico u otras cargas en movimiento. Trficou otras cargas en movimiento se realizan directamente en la parte superior de lasuperestructura (llamado el tablero del puente).
CEPILLOArbustos, rboles y otras plantas que tiene un dimetro de 100 mm
(4 pulgadas) o menos en un punto de 600 mm (12 pulgadas) sobre la superficie del sueloas como rboles cados y ramas. sobre la superficie de terreno, as comorboles cados y ramas.
CALENDARIO DE DATodos los das se muestra en el calendario.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 5/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
6/112
Pgina
1103
6
CARBONATORoca sedimentaria compuesta principalmente de minerales de carbonato,
doloma incluyendo (dolomita, CaMg (CO3)2), Piedra caliza (calcita,CaCO3) Y las mezclas de dolomas y calizas.
CERTIFICADO DE CUMPLIMIENTOUna certificacin proporcionada por un fabricante, productor o distribuidor de
un producto que el producto, que han sido facilitados al contratista, cumple conla especificacin correspondiente o contrato de los requisitos. La certificacindeber ser firmada por una persona que est autorizada a obligar a la sociedadsuministro de la materia objeto de la certificacin.
CERTIFICADO DE INFORME DE ENSAYOUn informe de la prueba proporcionada por un fabricante, productor o proveedor de un
producto que indica que los resultados reales de las pruebas o anlisis, que abarca los elementosde los requisitos de la especificacin del producto o mano de obra, yincluida la certificacin validada.
CERTIFICADO TCNICO CCTVUna persona certificada por el contratista y aprobado por el
Ingeniero para realizar todos los trabajos relacionados con un sistema de circuito cerrado de televisin.
CAMBIO DE ORDENUna orden escrita expedida por el Ingeniero al Contratista que cubren
ajustes permitidos, Plan de pequeos cambios o correcciones, y resolucionescon respecto a las omisiones, las discrepancias, y la intencin de los Planes yLas especificaciones, pero sin incluir ningn trabajo adicional u otras alteracionesque deben ser cubiertos por Acuerdo Complementario.
rdenes a aplicar los cambios realizados por mutuo acuerdono surtir efecto hasta que firm por el Contratista y regresal Ingeniero.
CAMBIO DE ESTADOLa clusula de contrato (1402) que proporciona para el ajuste del Contrato
trminos de las condiciones del lugar que difieren de las del contrato, porsuspensin de los trabajos ordenados por el Departamento, y de importantescambios en el carcter de la obra.
CIUDAD, PUEBLO, MUNICIPIO, LA CIUDAD, O DEL CONDADOUna subdivisin de la provincia utiliza para designar o identificar los
ubicacin de la obra propuesta.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 6/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
7/112
Pgina
1103
7
COMISIONADOEl Comisionado del Departamento de Transporte de Minnesota,
o el director ejecutivo del departamento u organismo constituido parala administracin del contrato de trabajo dentro de su jurisdiccin.
CONTRATOEl acuerdo por escrito entre el rgano de Contratacin y el
Contratista que se enuncien las obligaciones, incluyendo, pero no limitado a,la ejecucin de la obra, el suministro de mano de obra y materiales, la
base de pago, y otros requisitos que figuran en el Contratode los documentos.Los documentos del contrato incluyen la publicidad de las ofertas,
Propuesta, la forma del contrato, fianza del contrato, las especificaciones,Especificaciones suplementarias, disposiciones especiales, generales y de detallePlanes, el aviso para proceder, y las rdenes y los acuerdos que se requieren paracompletar la construccin de la obra de una manera aceptable,incluidas las prrrogas autorizadas, todo lo cual constituye un instrumento.
CONTRATO DE BONOSEl formulario aprobado de seguridad ejecutadas por el Contratista y
Garanta o garantas, lo que garantiza la ejecucin completa del contrato ytodos los Acuerdos complementarios relativos al mismo y el pago de todos losdeudas legales relativas a la construccin del Proyecto.
PUNTO DE CONTRATO (pago del artculo)Una unidad se describe especficamente de trabajo para el que se ofrece un precio
en el Contrato.
Contrato a tiempoLa fecha de terminacin, el nmero de das de trabajo, o el nmero de
das naturales permitido para la finalizacin del contrato, incluyendoprrroga de los plazos autorizados.
y la fecha del calendario da Contratos Finalizacin se completar eno antes del da indicado, aun cuando esa fecha sea sbado, domingo,o vacaciones.
ADJUDICADORLa subdivisin poltica, organismo gubernamental, de saln, departamento,
comisin, o un funcionario haciendo la adjudicacin y ejecucin del contrato comoel partido de la primera parte.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 7/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
8/112
Pgina
1103
8
CONTRATISTAEl, empresa individual, o la contratacin de sociedades y empresas
enjuiciamiento de la obra prescrita; el partido de la segunda parte a laContrato, ya sea directamente oa travs de un representante debidamente autorizado.
CONDADOEl condado en el que el trabajo previsto se va a hacer, un
subdivisin del Estado, por conducto de sus funcionarios debidamente electos de la JuntaComisionados del Condado.
ALCANTARILLAUna estructura construida enteramente por debajo de la elevacin de la calzada
superficie y no una parte de la superficie de la calzada, lo que proporciona unaapertura en la calzada para el paso de agua o de trfico.
DEPARTAMENTOEl Departamento de Transporte del Estado de Minnesota, o el
subdivisin poltica, agencia de gobierno, junta, comisin, oficina,departamento, divisin o agencia constituido para la administracin de laContrato de trabajo dentro de su jurisdiccin.
DESVOUn camino o el sistema de carreteras, por lo general existente, designado como
ruta temporal por el rgano de Contratacin para desviar el trficode una seccin de la carretera est mejorando.
CARRETERA DIVIDIDAUna autopista con formas separadas viaj para el trfico en frentedirecciones.
ESTANCADOS SIEMBRASiembra permiti a finales del otoo cuando la temperatura del suelo es demasiado
bajos para producir la germinacin de semillas para que la semilla se mantiene en un latentecondicin hasta la primavera.
ESTANCADOS soddingSodding permiti a finales del otoo cuando la temperatura del suelo es demasiado
bajo de modo que lo normal enraizamiento no tiene lugar hasta la primavera.
SERVIDUMBREUn derecho adquirido por la autoridad pblica para uso o control de la propiedad de un
designado propsito carretera.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 8/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
9/112
Pgina
1103
9
INGENIEROEl representante debidamente autorizado de la ingeniera de las Partes Contratantes
Autoridad, ya sea directamente oa travs de los representantes designados a quehan delegado la responsabilidad de la supervisin de ingeniera de laconstruccin, cada uno dentro del mbito de aplicacin delegado de los derechos yautoridad.
EQUIPOTodas las mquinas, herramientas y aparatos, junto con la necesaria
suministros para la conservacin y mantenimiento, necesarios para la adecuadaconstruccin y aceptable realizacin del contrato en sudestinados mbito de aplicacin.
EROSIN DE CONTROL HORARIOUn compromiso verbal o escrito por el Contratista
construccin de secuencias que ilustran y los mtodos propuestos para el controlla erosin.
TRABAJO EXTRACualquier trabajo que no es requerido por el contrato adjudicado, pero es que
autorizado y realizado por Acuerdo Complementario, ya sea enprecios negociados o en una cuenta de base de la Fuerza a lo dispuesto en otras partesestas especificaciones.
Tramo de la fachada (o calle)Una carretera local o auxiliar de la calle y se encuentra en la ladera de una
carretera para el servicio a la propiedad colindante y las zonas adyacentes y decontrol de acceso.
GRADOS DE SEPARACINUn puente con sus accesos que establece la autopista o
el trnsito de peatones para pasar sin interrupcin por encima o por debajo de un tren,autopista, carretera o calle.
GRAVADe origen natural o mineral producido por partculas de roca glacial
agua y la accin. Rangos de tamao de partculas de 76 mm (3pulgadas) de dimetroal tamao retenido en un 2,0 mm de dimetro (# 10 tamiz).
ANLISIS GARANTIZADOUna garanta de un fabricante, productor o distribuidor de un producto
que el producto cumple con los ingredientes o las especificacionesindicada en la etiqueta del producto.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 9/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
10/112
Pgina 1
1103
10
Carretera, calle o caminoUn trmino general que denota una va pblica a los efectos de vehicular
de viaje, incluyendo toda el rea dentro del derecho de va.
VACACIONESLos das de cada ao a un lado por la autoridad legal para el pblico
conmemoracin de eventos especiales, y en el que ninguna empresa pblicase podr realizar, salvo lo dispuesto especficamente en casos de necesidad.A menos que se indique lo contrario, las vacaciones ser el establecido en la EM 645.44.
INCIDENTALESSiempre que la palabra "incidental" se utiliza en el plan o especiales
disposiciones que se entender sin compensacin directa se har.
Estndar de la IndustriaUna medida aceptable y reconocido de la cuantitativa o
valor cualitativo o de un procedimiento establecido que debe seguirse para una determinadaoperacin dentro de la industria dada. En general, esto ser en la formade un cdigo escrito, norma o especificacin por una asociacin acreditada.
INSPECTORrepresentante autorizado del Ingeniero La asignado para hacer detallada
inspecciones de ejecucin del contrato.
INTERCAMBIOUna separados por la interseccin de grado con una o ms girando carreteras
para viajar entre las piernas de interseccin.
INTERSECCINEl rea general donde dos o ms carreteras registrarte o cruz, dentro deque se incluyen las instalaciones de va y carretera para el trficomovimientos en la zona.
CALIZAVer carbonato
LAZOUn camino de ida vuelta que las curvas de alrededor de 270 grados a la
derecho, sobre todo para dar cabida a un movimiento de giro-izquierda, pero quepuede tambin incluir disposiciones para otro movimiento de giro.
Pgina 1
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 10/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
11/112
1103
11
MATERIALESCualquier sustancia especificada para su uso en la construccin del Proyecto
y sus dependencias.
MATERIAL DE LABORATORIOEl Mn / DOT Central Material de laboratorio y, en las pruebas para la
autorizado y la Mn / DOT Distrito Material de laboratorio.
DENSIDAD MXIMALa densidad mxima de un suelo determinado segn lo determinado por el
mtodo previsto en el Mn Clasificacin del DOT y / Manual de Base.
MTRICAEl Sistema Internacional de Unidades (SI) (el modernizado sistema mtrico
System) de acuerdo con la norma ASTM E 380 se utilizan en estas especificaciones.ASTM E 380 tambin proporciona factores de conversin y el comentario.
Toneladas mtricas (t)Una masa de 1000 kilogramos.
MENORES DE TRABAJO EXTRATrabajo extra ordenados por el Ingeniero y necesario para completar la
proyecto tal como estaba previsto y autorizado por escrito, (TrabajoOrden / Menor extra de trabajo), tal como se especifica en el 1403.
M Gal1.000 galones
NOMINALLa intencin, con nombre o valor declarado, en contraposicin a la actual
valor. El valor nominal de algo es el valor que se suponeo vayan a tener, o el valor por el cual se le conoce comnmente. Lavalor real puede diferir de estas declaraciones de un mayor o menorcantidad en funcin de la exactitud y la precisin del proceso utilizado paradeterminar el valor real.
AVISO PARA PROCEDERLa notificacin por escrito al contratista para continuar con los trabajos del contrato
incluyendo, cuando sea aplicable, la fecha de comienzo de los tiempos del contrato.
Pgina 1
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 11/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
12/112
1103
12
Permiso NPDESEl permiso general expedido por la MPCA que autoriz a la
aprobacin de la gestin del agua de lluvia asociadas a la actividad de construccin en el marco delNacional de Eliminacin de Descargas Contaminantes Programa de Sistema.
PTIMO DE HUMEDADEl contenido de humedad de un suelo especialmente a la densidad seca mxima
determinado por el mtodo previsto en el Mn Clasificacin del DOT / y la BaseManual.
(P)Una designacin en el resumen de las cantidades en el plan de lo que significa que
la cantidad Plan ser la cantidad de pago. Medicin oreclculo no se har excepcin de lo dispuesto en 1901.
PAGO DEL ARTCULO (artculo) Contrato
Una unidad se describe especficamente de trabajo para el que se ofrece un precioen el Contrato.
ESTRUCTURA DE PAVIMENTOLa combinacin de sub-base, capa base y capa de rodadura puesto
en una sub-base para soportar la carga de trfico y distribuirlo a la capa de balasto.
MEDIDAS DE CONTROL PERMANENTE DE EROSINLa erosin del suelo medidas de control, como frenar, delantales alcantarilla,
escollera, canaletas, colocacin de csped, alfombras de la erosin, y otros medios de forma permanenteminimizar la erosin en el Proyecto terminado.
PLANEl Plan, perfiles, cortes transversales y complementarios
dibujos que muestran la ubicacin, el carcter, las dimensiones y detalles deel trabajo por hacer.
PLAN DE CANTIDADLa cantidad que figuran en el resumen de las cantidades en el Plan. La
Resumen de las cantidades por lo general se titula Declaracin de estimadoCantidades, la Lista de Cantidades para todo el puente, o en la Lista deLas cantidades.
PERFIL DE GRADOLa traza de un plano vertical que corte la superficie superior de la
o pavimento estructura calzada, por lo general a lo largo de la lnea central longitudinal
Pgina 1
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 12/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
13/112
1103
13
de la calzada. Perfil de grado medio o elevacin o gradiente decomo seguimiento de acuerdo al contexto.
PROYECTOLa seccin especfica de la carretera, la ubicacin o el tipo de
trabajar conjuntamente con todos los accesorios y la construccin a realizaren virtud del Contrato.
PROPUESTALa oferta de un postor en el formulario de la Propuesta fijada para realizar la
trabajo y proporcionar la mano de obra y materiales a los precios cotizados.
FORMULARIOEl formulario aprobado, en la que el rgano de Contratacin exige
las ofertas que se elabore y someta a la obra.
PROPUESTA DE GARANTIALas garantas otorgadas con una oferta para garantizar que el postor
entrar en el contrato si la oferta es aceptada.
PURO EN VIVO DE SEMILLAS (Porcentaje)Un porcentaje determinado por el porcentaje de veces que la germinacin de semillas
el porcentaje de pureza de las semillas.
ASEGURAMIENTO DE LA CALIDAD (GC)Las actividades desarrolladas por el Departamento que tienen que ver con
asegurndose de que la calidad de un producto es lo que debera ser.
CALIDAD COMPACTACINUn mtodo de compactacin tal como se define en 2105.3F2.
CONTROL DE CALIDAD (QC)Las actividades realizadas por el contratista de que tienen que ver con
haciendo que la calidad de un producto lo que debera ser.
CUESTIONARIOLas formas especificadas en los que puede ser un oferente obligado a proporcionar
informacin sobre la capacidad de realizar y financiar las obras.
RAMPAUna va de conexin para viajar entre las piernas o en la interseccin
que conduce a un intercambio.
Pgina 1
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 13/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
14/112
1103
14
DERECHO DE PASOUn trmino general que denota la tierra, propiedad o inters en ello, por lo general
en una franja, adquiridas a favor o dedicados a una carretera.
CAMINOUn trmino general que denota una va pblica a los efectos de vehicular
de viaje, incluyendo toda el rea dentro del derecho de va.
Capa de balastoLa parte nivelada de una carretera dentro y parte superior de esqu,
preparado como base para la estructura del pavimento y los hombros.
CARRETERASLa porcin de una carretera dentro de los lmites de la construccin.
ESCALAUn dispositivo utilizado para medir la masa o la proporcin de un lquido o
slidos. Esta definicin incluye dispositivos de medicin.
HOMBROLa porcin de la calzada contigua a la calzada paraalojamiento de los vehculos detenidos, en caso de emergencia, y por lateralapoyo de los cursos y la superficie de base.
ACERALa parte de la calzada construida principalmente para el uso de
peatones.
TAMIZUna pantalla de alambre tejido que cumplan los requisitos de AASHTO M-92
para el tamao especificado.
DISPOSICIONESLas adiciones y modificaciones a la norma y suplementario
Especificaciones referidas a las condiciones propias de un proyecto individual.
ESPECIFICACIONESUn trmino general que se aplica a todas las direcciones, las disposiciones, y
requisitos relativos a la ejecucin de la obra.
FECHA DE FINALIZACIN ESPECIFICADOLa fecha en que el trabajo especificado es el contrato de su conclusin.
Pgina 1
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 14/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
15/112
1103
15
MODELO DE RBOLo de otra manera significativa rbol histrico se indica en el Contrato o
determinado por el Ingeniero.
ESTADOEl Estado de Minnesota a travs de sus funcionarios electos y sus
representantes autorizados.
CALLEUn trmino general que denota una va pblica a los efectos de vehicular
de viaje, incluyendo toda el rea dentro del derecho de va.
ESTRUCTURASPuentes, alcantarillas, sumideros, tomas de gota, muros de contencin, apuntalamiento,
pozos de visita, endwalls, edificios, alcantarillas, tuberas de servicios, drenajes,fundacin desages, y otras caractersticas-hecho hombre.
SUBCONTRATISTAUna, empresa individual o corporacin a la que el contratista subarrendar
parte del Contrato.
EXPLANADASLa superficie superior de una capa de balasto en los que la estructura del pavimento
y los hombros se construyen. Tambin, un trmino general que denota labase sobre la que una base por supuesto, la capa de rodadura, o de otro tipola construccin se va a colocar, en el que caso de referencia a la sub-baseoperaciones puede implicar la profundidad, as como la superficie superior.
SUBESTRUCTURALa parte de un puente por debajo de los rodamientos de simple y continuo
abarca, skewbacks, o los arcos y las tapas de zapatas para los marcos rgidos,junto con las mamparas, WINGWALLS, y la proteccin de barandas de las alas.
SUPERINTENDENTErepresentante autorizado del Contratista a cargo de responsables
el trabajo.
SUPERESTRUCTURAEl puente entero, excepto la estructura.
ACUERDO COMPLEMENTARIOUn acuerdo escrito entre el rgano de Contratacin y el
Contratista, ejecutado en la forma prescrita y aprobada requiere como
Pgina 1
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 15/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
16/112
1103
16
por la ley, de la realizacin del trabajo extra u otras alteraciones olos ajustes previstos en el alcance general del Contrato,
pero que el trabajo extra u orden de cambio constituye una modificacin delContrato como se haba ejecutado y aprobado.
DIBUJOS COMPLEMENTARIOS
Un juego de planos aprobados que consiste en placas estndar o planesmostrando los detalles de diseo y construccin de diversas estructuras yproductos para los que las normas se han desarrollado. Estos estndaresplacas y los planes se regir por la referencia que se sealan ycompletar o modificar los planes generales y especificaciones.
Especificaciones suplementariasLas adiciones y revisiones de las especificaciones estndar que se
aprobados con posterioridad a la emisin del libro impreso de la normaEspecificaciones.
GARANTAEl, asociacin Corporacin, o persona, que no sea el
Contratista, la ejecucin de una fianza prestada por el contratista.
TEMPORAL BY-PASS
Una seccin de la carretera, por lo general dentro del derecho de va existentes,previstas para llevar temporalmente todo el trfico en torno a un lugar de trabajo especfico.
TEMPORAL DE MEDIDAS DE CONTROL EROSIONLa erosin del suelo medidas de control, tales como cheques bala, cortinas de limo,
trampas de sedimentos, y otros medios para proteger temporalmente el proyecto dela erosin antes y durante la instalacin del control de la erosin permanentemedidas. Medidas temporales de control de la erosin tambin puede ser utilizado paracomplementar las medidas de carcter permanente.
Carril de trficoLa porcin de una calzada para la circulacin de una sola lnea de
los vehculos.
CAMINO RECORRIDOLa porcin de la calzada para la circulacin de vehculos, en exclusiva
de los hombros y los carriles auxiliares.TURN LANE
Un carril auxiliar para vehculos de giro a la derecha oa la izquierda.
Pgina 1
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 16/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
17/112
1103
17
TRABAJOEl suministro de mano de obra, materiales, equipos y otros
incidentales necesarios o convenientes para el buen xito de laProyecto y la realizacin de todos los deberes y obligaciones impuestas porContrato a la Contratista. Tambin se utiliza para indicar la construccinrequeridos o completado por el Contratista.
DA DE TRABAJOUn da natural, exclusivo de los sbados, domingos, y el Estadoreconocido das feriados, en el que las condiciones climticas y otros no
bajo el control de la Contratista permitir que las operaciones de construccinpara continuar durante al menos 2 horas, con la fuerza normal de trabajo comprometidoen la ejecucin del control de las operaciones curso.
DIBUJOS DE TRABAJOhojas de estrs, planos de taller, planes de construccin, planes de cimbra,
marco de los planes, los planes de atagua, diagramas de flexin para reforzarde acero, o los planes complementarios o similares otros datos que elContratista est obligado a proporcionar y presentar al Ingeniero.
ORDEN DE TRABAJOUna orden por escrito firmada por el Ingeniero de una situacin contractual
que requieren un rendimiento u otra accin por parte del contratista, sin
negociacin de ningn tipo.ORDEN DE TRABAJO / TRABAJO EXTRA MENOR
Una orden escrita firmada por el Ingeniero que requieren un rendimiento deMenor de trabajo extra.
Pgina 1
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 17/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
18/112
1201
18
Requisitos y Condiciones de pujas
1201Precalificacin de postores
No hay requisitos de precalificacin se imponen antes de presentar unaoferta, sin embargo, cada entidad participante se aconseja que una declaracin por escrito puede sernecesarios antes de la consideracin de las ofertas, que muestra la experiencia,certificaciones y licencias necesarias del oferente y la cantidad dede capital y los equipos disponibles para la ejecucin del trabajo propuesto.
1202Contenido del Formato de Propuesta
El formulario de propuesta se indicar la localizacin y descripcin de loscontempla la construccin, e incluir un calendario de elementosmostrando las cantidades estimadas de los distintos tipos y clases detrabajo para el que los precios de compra estn invitados. La forma propuesta el Estadotiempo en el que el trabajo debe ser completado, la cantidad y naturaleza deGaranta de la Propuesta es necesario, y la fecha, hora y lugar de laapertura de propuestas.
Consolidado en la forma propuesta ser de las disposiciones particulares yotros requisitos complementarios. Todos los trabajos vinculados con la misma o adjuntasa la forma propuesta son partes esenciales de la propuesta y no seindividual o alterada sin autorizacin especfica. Los planes,Especificaciones y otros documentos designados en la propuesta tambin seuna parte de la propuesta.
1203La emisin de formularios de la propuesta
formas Propuesta ser emitido a los posibles oferentes a peticiny el pago de la tasa se indica en el Anuncio de Licitacin.
1204La interpretacin de las cantidades en la Lista de pujas
El Departamento utiliza las cantidades que figuran en la ofertacalendario como base para la comparacin de las ofertas. Las cantidades de la ofertahorario se deben considerar slo aproximadas, y cada uno se puedeaumentar, disminuir, o se omite siempre como en 1402. El pago sesobre la base de las cantidades de trabajo realizado de acuerdo a 1901, o comose indique lo contrario.
Pgina 1
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 18/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
19/112
1205
19
1205El examen de los planes, e specificaciones,Disposiciones Especiales , y el sitio de trabajo
Planes, Especificaciones y Disposiciones Especiales para el trabajo propuestose encuentran archivados en la oficina del rgano de Contratacin en los que pueden serexaminarse sin cargo, o que las copias se pueden comprar en lalas tasas estipuladas.
El ofertante se espera que examinar cuidadosamente el sitio de la propuesta detrabajo, planes, especificaciones, disposiciones especiales, Propuesta, y otrosContrato de documentos antes de presentar una propuesta. La presentacin de unaPropuesta ser evidencia concluyente de que el oferente ha investigadoel sitio y los documentos del Contrato, y est satisfecho con las condicionesque se encuentran en la ejecucin de la obra y el Contratolos requisitos.
El Departamento pondr a disposicin para su examen en su domiciliocualquier informacin en el archivo sobre las exploraciones del subsuelo y la utilidadacuerdos que no estn incluidos en los documentos del Contrato. Lalicitante deber entender que los registros, informes y documentos paraexaminados no son parte del contrato, pero slo se muestran para elconveniencia de los licitantes. El oferente es el nico responsable de todos lossuposiciones, deducciones y conclusiones a las que el oferente puede alcanzar.El licitador deber entender que no garantiza que se haga o implcita en cuanto ala exactitud, suficiencia, o la fiabilidad de la informacin quedisponible.
Cuando las perforaciones de prueba son tomadas en el Proyecto, el Departamento puede ono puede indicar sondeo de informacin sobre los planes. LaDepartamento tiene perforaciones y por los mtodos convencionales de corriente ycon cuidado se considere adecuada para el diseo de los propsitos del Departamento. Lalos registros de las perforaciones pueden haber sido editados o abreviada y no puederevelar toda la informacin que pueda ser til o de inters para laContratista. En consecuencia, el Departamento har el campo de los registros ylaboratorio de registros relativos a las perforaciones a disposicin de los licitadores (oContratista) en el Departamento de la oficina. Debido a que algunos sondeos nose han tomado para recopilar informacin relativa a la construccin de laProyecto, los datos se indica en el campo y se registran en los registros nonecesariamente que el Contratista hubiera un deseo. Por lo tanto, mientras queel Departamento cree que la informacin sobre las condiciones ymateriales reportados en cada hoyo de prueba se precisa en el momento de laaburrida fue tomada, no garantiza que la informacin es necesariamentecompleta. Dado que las condiciones bajo la superficie exterior de cada prueba individualhoyos son desconocidos para el Departamento, y el suelo, roca y aguacondiciones no se puede confiar en ser constante y uniforme, la
Departamento no garantiza que las condiciones adyacente a las perforaciones de prueba
Pgina 2
1205
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 19/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
20/112
20
necesariamente ser el mismo que aparece en los registros. Adems, elDepartamento no ser responsable de todas las interpretaciones hechas por elContratista. La ausencia de anotaciones en los registros en materia de agua seno necesariamente significa que los agujeros estaban secos o que el Contratistano aparece el agua del subsuelo en el transcurso de la construccin.
1206Preparacin de la propuesta
1206.1 PREPARACINEl licitador deber presentar una propuesta sobre el calendario de formularios de oferta
proporcionada por el Departamento.El licitador deber:
(A) Especificar un precio por unidad en las cifras para cada elemento de pago para los que unacantidad se da, (para todos los elementos con una cantidad de "Lump Sum"una cantidad numrica de "1" se supone) no, excepto lonecesaria en el caso de artculos alternativos, y
(B) Mostrar los productos de los precios unitarios respectivos y de las cantidadescifras en la columna destinada a tal fin, y
(C) Indique el total de la propuesta obtenido por adicin de laimportes de los varios elementos.
Todas las figuras sern en tinta, mecanografiadas o impresas equipo. En el casode una discrepancia entre el precio de la oferta y la extensin de la unidad, la unidad
precio gobernar.Cuando un elemento de la propuesta contiene una opcin que se har por el
oferente, el oferente deber indicar la eleccin de acuerdo con laEspecificaciones para ese tema, y despus de eso, otra opcin ms se
permitidos.Los licitadores propuesta deber ser firmada con tinta por el individuo, por
uno o ms miembros o funcionarios de cada empresa que representa un conjuntode riesgo, o por uno o ms funcionarios de una corporacin. Si la propuesta eshecha por un individuo, el nombre y direccin de la oficina de correos se muestra;
por una asociacin, el nombre y direccin postal de cada socio deberse muestra, como una empresa conjunta, el nombre y direccin postal de cadamiembro o funcionario de las empresas representadas por la empresa en participacin sese muestra, por la corporacin, el Estado en el que ha sido constituido, y eldireccin profesional de sus funcionarios corporativos se muestran.1.206,2 ALTERACIONES
La atencin del licitador est dirigido a MN Estatuto 16C.32subd. 1c, que establece, entre otras cosas, por que la oferta ser rechazadasi contiene todas las modificaciones o supresiones que no se corrigen ensiguiente:(A) La alteracin o supresin deber ser tachado y la correccin
impresa en tinta, escrita a mquina u ordenador impresa junto a ella,
Pgina 2
1207
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 20/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
21/112
21
y(B) La correccin debe ser rubricado en tinta por la persona que firma lala oferta propuesta.Cualquier alteracin o supresin realizada por el oferente en la propuesta de
acuerdo con una instruccin especfica contenida en un "Addendum" seNo se considera una "alteracin o supresin" en el sentido dedel Estatuto.1.206,3 SUSTITUCIONES ADMISIBLE
Si la propuesta permite, en lugar de utilizar el Departamento de la oferta de lacalendario, el oferente puede utilizar uno de los siguientes mtodos:(A) El licitador podr presentar un equipo sustituto impresa cronograma de su propuesta
CON LA PROPUESTA. El horario oferta sustituto ser en unformato conforme a las directrices contenidas en la propuesta.
(B) Un disquete de 3 pulgadas que contiene el calendario de la oferta puede serpresentado con la propuesta. El disquete debe estar etiquetadocon el nombre de la empresa y el nmero de proyecto. Una copia impresa delel archivo de programacin de la oferta tambin debe ser presentado con la propuesta. Enel caso de una discrepancia, la copia impresa prevalecer. El EBS archivosy el programa de AASHTO "Acelerar la oferta" tiene que ser utilizado para crearel disco.
(C) El licitador podr recurrir a "dos vas electrnicas" hacer una oferta. Lalicitacin electrnica deber ser presentado de conformidad con larequisitos de la AASHTO "Acelerar Oferta" de software y la oferta "Express "del sitio Web (www.bidx.com). Una copia impresa de la propuestaand/or the "Schedule of Prices" is NOT required when submitting a
bid utilizing "Two Way Electronic" bidding. If a hard copy of theProposal is submitted with a "Two Way Electronic Bid", the HardCopy Will Govern.When the bid is submitted using "Two Way Electronic Bidding",
the bidder must sign his bid in conformance with MN Statue 161.32,subd. 1b. The bid must also comply with the requirements of the"Expedite Bid" software and the "Bid Express" Web site(www.bidx.com).
1207Irregular Proposals
Proposals will be considered irregular and may be rejected for anyof the following reasons:(1) If the Proposal is on a form other than that allowed in 1206, or if
the form is altered or any part is detached.(2) If there are unauthorized additions, conditional or alternate bids, or
irregularities of any kind that may tend to make the Proposalincomplete, indefinite, or ambiguous as to its meaning.
Pgina 2
1207
(3) If the bidder adds any unauthorized provisions reserving the rightto accept or reject an award, or to enter into a Contract pursuant to
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 21/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
22/112
22
an award.(4) If the Proposal does not contain a unit price for each pay itemlisted except in the case of authorized alternate pay items.
(5) If any unit prices are obviously unbalanced, either in excess of orbelow the reasonable cost analysis values.
1208Proposal Guaranty
Each Proposal shall be accompanied by a separate guaranty of thecharacter and in an amount not less than that indicated in the Proposalformulario. The guaranty shall be either a certified check or an acceptable
bond made payable to the Contracting Authority. Bonds shall be issuedby corporations authorized to contract as a surety in the State of
Minnesota. Bonds shall be conditioned on execution of the Contract,Contract Bond, and prescribed Noncollusion Affidavit, with the penalsum being expressed either as a lump sum or as a percentage of the totalamount of the bid.
1209Delivery of Proposals
Each proposal, together with the proposal guaranty, shall bedelivered in a sealed envelope marked clearly with the name of the
bidder, type of work, and Project number. A special envelope may befurnished for this purpose by the Contracting Authority. When sent bymail, the envelope shall be addressed to the Contracting Authority at theaddress and in care of the official in whose office the bids are to berecibido. All proposals shall be filed prior to the time and at the placespecified in the Advertisement for Bids. Proposals received after thetime set for opening of bids will be returned to the bidder unopened.
If the Contracting Authority allows for "Two Way Electronic" bidsubmittals, each bid submitted in this manner shall:(A) Include a Proposal Guaranty.(B) Be submitted in accordance with requirements of the
AASHTO "Expedite Bid" software, and the "Bid Express"Web site (www.bidx.com).
(C) Be filed prior to the time specified in the Advertisement forBids.
Pgina 2
1211
1210Withdrawal or Revision of Proposals
Any bidder may withdraw or revise its Proposal after it has been
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 22/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
23/112
23
deposited with the Contracting Authority, provided the request forwithdrawal or revision is received in writing before the time set foropening proposals.
The Department reserves the right to revise the Plans,Specifications, Special Provisions, and Proposal form for any Project atany time prior to the date set for opening the Proposals. Revisions will
be made by Addendum, duly numbered and dated, subject to thesiguientes disposiciones:(1) Each Addendum will be delivered by courier service to each
prospective bidder who has received a Proposal form prior to thedate of Addendum. The Addendum will be included with allProposal forms issued to bidders after the date of the Addendum.
(2) If revisions made by an Addendum require considerable change or
reconsideration on the part of the bidder, the date set for openingthe Proposals may be postponed, in which case the Addendum willinclude an announcement of the new date set for openingProposals.
(3) Each bidder shall acknowledge receipt of each Addendum, eitherin the space provided on the Proposal form or by submitting aletter prior to the time set for opening Proposals.
1211Combination or Conditional Proposals
No combination or conditional Proposals will be allowed otherthan those specifically set up in the Special Provisions, with theexception that any bidder may limit the amount of work accepted at onetiempo. When bids are submitted on more work than is desired, the biddermay complete and include the following statement with each of theProposals:
"This bidder will not accept awards totaling more than $______,and hereby authorizes the Contracting Agency to determine which bidswill be disqualified."
The Department reserves the right to make awards on combinationor conditional Proposals to its best advantage. In each stipulationallowed, the bidder shall provide all information called for and includethe "Project Number" identification. In the case of multiple projects,the lowest Project Number shown on the Proposal shall be used for thisidentification.
Pgina 2
1212
1212Public Opening of Proposals
Proposals will be opened and read publicly at the time and placeindicated in the Advertisement for Bids. Bidders, their authorizedagents, and other interested parties are invited to be present.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 23/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
24/112
24
1213Disqualification of Bidders
Either of the following reasons may be considered sufficient causefor disqualification of a bidder and the rejection of its Proposals:(1) More than one Proposal for the same work from an individual,
firm, or corporation under the same or different name. Suplentebid schedules shall be governed by 1206.
(2) Evidence of collusion among bidders. Participants in collusionwill receive no recognition as bidders on future work until theyhave been reinstated as responsible bidders.
Pgina 2
1302
Requisitos de pujas y Convenios
1301Consideration of Proposals
After the Proposals are opened and read, they will be compared onthe basis of the correct summation of the products of the scheduled
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 24/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
25/112
25
quantities and unit bid prices. If the successful bidder has submittedprices on more than one alternate, the Department reserves the right todetermine which alternate will be accepted. In case of a discrepancy
between a unit bid price and the extension, the unit bid price shallgovern.
Proposals that are not accompanied by a satisfactory Proposalguaranty will not be considered. Any bidder may be required to furnishevidence of competency in performing the proposed work, as providedfor in 1201.
The right is reserved to reject any or all Proposals, to waive defectsand technicalities, or to advertise for new Proposals, if in the judgmentof the Contracting Authority its best interest will be promoted thereby.
1302Award of ContractThe award of Contract, if it be awarded, will be made within 30
Calendar Days after the opening of Proposals to the lowest responsiblebidder who complies with all prescribed requirements. El xitobidder will be notified by letter, mailed to the address shown on theProposal, that the bid has been accepted subject to execution andapproval of the Contract as required by law.
As a condition precedent to approval of a Contract, a foreign ornonresident corporation to whom a Contract is awarded shall furnish
proof that it has met all legal requirements for transacting business inthe State of Minnesota.
As a condition precedent to approval of a Contract, a swornstatement shall be filed with the Department stating that the persons,firm, association, or corporation to whom the Contract is awarded hasnot, either directly or indirectly, entered into any agreement,
participated in any collusion, or otherwise taken any action in restraintof free competitive bidding in connection with the Contract. This swornstatement shall be in the form of an affidavit executed by, or on behalfof, and sworn to by the successful bidder before a person who isauthorized by the laws of this State to administer oaths. The forms forthis affidavit will be furnished to the successful bidder and they shall be
properly executed and returned within the period prescribed.
Pgina 2
1303
1303Cancellation of Award
The Department reserves the right to cancel the award of anyContract at any time before the execution of said Contract by all partieswithout any liability against the Contracting Authority.
1304
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 25/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
26/112
26
Return of Proposal GuarantyAll Proposal guaranties, except those of the two lowest bidders, willbe returned or released immediately following the opening andchecking of Proposals. The Proposal guaranties of the two lowest
bidders will be retained until the Contract has been executed andapproved as required by law, at which time they will be released, exceptin the case of forfeiture as provided for in 1307. Upon release, certifiedchecks will be returned to the bidder, but surety bonds will bedestroyed, unless their return is specifically requested.
1305Requirement of Contract Bond
The successful bidder shall furnish a payment bond equal to the
Contract amount as required by MN Statute 574.26. The surety andform of the bond shall be acceptable to the Contracting Authority. LaContracting Authority shall require that the surety possess bondingcapacity as follows: The minimum bonding capacity on contract equalto or less than $5,000,000.00 (five million dollars) shall be the total ofthe two bonds. The minimum bonding capacity on contracts in excessof $5,000,000.00 (five million dollars) shall be the contract amount.
1306Execution and Approval of Contract
The Contract shall be signed by the successful bidder and returned,together with the Contract bond, within 10 days after the forms have
been mailed to the bidder. If the successful bidder fails to return theexecuted Contract documents within 10 days, and the Contract Timeunder 1806 is specified as a number of working day, the Departmentreserves the right to reduce the Contract Time to reflect the delaycaused by the Contractor. If the Contract Time is specified as acompletion date, the Contractor's delay in returning the executedContract documents is an avoidable delay under 1806.1A and shall notentitle the Contractor to an Extension of the Contract Time. Sireturn of the executed forms within the specified time is impossible dueto the absence of one or more of the required signers, an extension of
Pgina 2
1307
time may be granted by the Department provided satisfactory evidenceis furnished that the forms will be executed.
All members of a partnership, and the President or Vice Presidentand the Secretary or Treasurer of each corporation shall sign theContract and bond. In the case of joint ventures, signature requirementsshall apply to each firm represented.
Notice of approval or disapproval of the Contract and bond will begiven the successful bidder within 10 days after the forms have been
properly executed and returned to the Contracting Authority. No award
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 26/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
27/112
27
shall be considered binding nor shall any Contract become effectiveuntil the Contract form has been fully executed and approved asrequerido por la ley.
1307Failure to Execute Contract
Failure on the part of the successful bidder, within the time allowed,to execute the Contract, furnish an acceptable bond, or comply with anyother requirements imposed precedent to approval of the Contract, shall
be considered just cause for cancellation of the award and forfeiture ofthe Proposal guaranty, not as a penalty, but in liquidation of damagessustained. Award may then be made to the next lowest responsible
bidder, or the work may be readvertised or otherwise performed as the
Department may decide.
Pgina 2
1401
Alcance del Trabajo
1401Intent of Contract
The intent of the Contract is to provide for construction of theProject and compensation for the work, according to the Contractde los documentos. The titles and headings of the various sections andsubsections of the Contract are intended for convenience of reference.
The Contractor shall construct and complete the Project in everydetail as described in the Plans, Specifications, Special Provisions, andsupplemental drawings. It is also intended and will be expected that the
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 27/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
28/112
28
work be prosecuted diligently and pressed vigorously to completion.The Contractor shall consider the public interests, as well as theobligations and rights of all other parties concerned. El Contratistaassumes full responsibility for performance of the work and agrees tofurnish all labor, materials, equipment, tools, supplies, transportation,and other incidentals necessary or convenient for successful completiondel Proyecto.
The Contract may not fully describe every detail or make specificallowances for all probable exceptions and contingencies. El Ingenierohas authority to administer the Contract, rule on apparent discrepancies,fulfill intentions, and allow for construction needs in the performanceand completion of the work. When the Contract is silent or omits adetailed description, only the best general practice is to prevail andmaterials and workmanship shall be of first quality. Failure to itemizeevery allowable exception or condition does not mean that thegoverning provisions will be enforced equally under all conditions or onall parts of the work. The Engineer will decide all discretionary mattersa medida que surjan.
In constructing temporary facilities that do not become a part of thepermanent improvement, the Engineer may waive requirements that theEngineer considers unnecessary in fulfilling the intended service orfunction of the facility. The Engineer may allow alternative designsfrom those specified for temporary construction provided that costs tothe Department do not exceed those that would be incurred with thespecified design.
If operational controls or restrictions are found to be unnecessary orto result in unjustified expense, the Engineer may alter or waive those
provisions when it is in the best interests of the Department to permitearlier completion of the work, take advantage of improved designs andmaterials, make use of improved techniques or the most efficient
practices, or otherwise facilitate progress or completion of the work.
Pgina 2
1402.1
Changes that alter acceptance or payment provisions of the Contractcan only be made effective by mutual agreement.
By proceeding without authority or in violation of any restrictionimposed by the Contract, the Contractor assumes the risks of
performing unauthorized work, and thereby relieves the Department ofany associated risk or loss. The Contractor may be held liable for thereimbursement of any additional costs incurred by the Department in
providing for the inspection or acceptance of work performed inviolation of the terms of the Contract.
1402Alteration of the Work and Changed Condition
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 28/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
29/112
29
An Alteration of the Work and a Changed Condition are addressedby separate procedures.1402.1 ALTERATION OF THE WORK
The Department may alter the details of construction as necessaryfor proper completion of the Project and as desired for reasons of publicde inters. Alterations may be made at any time during the progress of thework, but will not involve added work beyond the limitations imposed
by law, nor beyond the termini of the proposed construction except asmay be necessary to satisfactorily complete the Project.Un Altered Work
The work as altered may:(1) Require performance of increased or decreased quantities,(2) Include alterations in the grade or alignment of the road or
estructuras,(3) Require performance of additional work not required by the originalContract, or
(4) Eliminate unnecessary Contract items, subject to 1905.The Engineer will inform the Contractor in writing of all alterations
having any material effect on the terms of the Contract. El Contratistashall perform the altered work the same as if it had been a part of theoriginal Contract, and its performance shall not in any way invalidatethe Contract nor release the Surety.B Compensacin
The Contractor will receive payment for altered work in accordancewith the payment provisions of the Specifications and as provided for in1403, 1903, 1904, 1905, and 1907. No allowance, except asspecifically provided by the payment provisions of the Contract, will bemade for any increased expenses, loss of expected reimbursement, orloss of anticipated profits suffered or claimed by the Contractor,
whether resulting directly from alterations in the work or indirectlyde
Pgina 3
1402.1unbalanced allocation of overhead expenses among the Contract itemsor from any other cause.
The Contractor shall not make a claim for any increased expenses,loss of expected reimbursement, or loss of anticipated profit because ofalterations in the work or by reason of any variation between thequantities in the bid schedule and the actual quantities ordered and
performed.If the altered work is of sufficient magnitude to require additional
time in which to complete the Project, a time extension may be grantedin accordance with 1806.1402.2 CHANGED CONDITION
Either party to the Contract may claim a Changed Condition of theContrato. Changed Conditions are limited to differing site conditions,suspensions of work, and significant changes in the character of work.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 29/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
30/112
30
A Supplemental Agreement must be executed before performance of thework for which a Changed Condition is claimed.Un Differing Site Conditions
During the progress of the work, if subsurface or latent physicalconditions are encountered at the site differing materially from thoseindicated in the Contract or if unknown physical conditions of anunusual nature, differing materially from those ordinarily encounteredand generally recognized as inherent in the work provided for in theContract, are encountered at the site, the party discovering suchconditions shall promptly notify the other party in writing of thespecific differing conditions before they are disturbed and before theaffected work is performed.
Upon written notification, the Engineer will investigate thecondiciones. If the Engineer determines that the conditions materiallydiffer and cause an increase or decrease in the cost or time required forthe performance of any work under the Contract, an adjustment,excluding loss of anticipated profits, will be made and the Contractmodified in writing accordingly. The Engineer will notify theContractor of the determination whether or not an adjustment of theContract is warranted.
No Contract adjustment that results in a benefit to the Contractorwill be allowed unless the Contractor has provided the required written
previo aviso.B Suspensions Of Work Ordered By The Engineer
If the performance of all or any portion of the work is suspended ordelayed by the Engineer in writing for an unreasonable period of timenot originally anticipated, customary, or inherent to the constructionindustry) and the Contractor believes that additional compensation, orContract time, or both are due as a result of such suspension or delay,
Pgina 3
1402.2
the Contractor shall submit to the Engineer in writing a request foradjustment within 7 calendar days of receipt of notice to resume work.The request shall set forth the reasons and support for such adjustment.
Upon receipt, the Engineer will evaluate the Contractor's request. Sithe Engineer agrees that the cost, or time required for the performanceof the Contract, or both have increased as a result of such suspensionand the suspension was caused by conditions beyond the control of andnot the fault of the Contractor, its suppliers, or subcontractors approvedunder 1801, and not caused by weather, the Engineer will make anadjustment (excluding profit) and modify the Contract in writingen consecuencia.The Engineer will notify the Contractor of thedetermination whether or not an adjustment of the Contract iswarranted.
No Contract adjustment will be allowed unless the Contractor hassubmitted the request for adjustment within the time prescribed.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 30/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
31/112
31
No Contract adjustment will be allowed under this clause to theextent that performance would have been suspended or delayed by anyother cause, or for which an adjustment is provided for or excludedunder any other term or condition of this Contract.C Significant Changes In The Character Of Work
The Engineer reserves the right to make, in writing, at any timeduring the progress of the work, such changes in quantities and suchalterations in the work as are necessary to satisfactorily complete theDel proyecto. Such changes in quantities and alterations shall not invalidatethe Contract nor release the Surety, and the Contractor agrees to
perform the work as altered.If the alterations or changes in quantities significantly change the
character of the work under Contract, whether those alterations or
changes are in themselves significant changes to the character of thework or, by affecting other work, cause such other work to becomesignificantly different in character, an adjustment, excluding loss ofanticipated profits, will be made to the Contract. The basis for anadjustment shall be agreed upon in writing before the performance ofel trabajo. If a basis cannot be agreed upon, then an adjustment will bemade either for or against the Contractor in such amount as theEngineer may determine to be fair and equitable.
If the alterations or changes in quantities do not significantly changethe character of the work under the Contract, the altered work will be
paid for as provided elsewhere in the Contract.
Pgina 3
1402.2
The term "significant change" shall be construed to apply only to
the following circumstances:(1) When the character of the work as altered differs materially in kindor nature from that involved or included in the original proposedconstruction, or
(2) When a major Contract item of work is increased in excess of 125percent or decreased below 75 percent of the original Contractcantidad. Any allowance for an increase in quantity shall applyonly to that portion in excess of 125 percent of original Contractitem quantity, and in case of a decrease below 75 percent, to theactual amount of work performed.
1403Extra Work
The Contractor shall perform unforeseen work not included underor covered by the Contract items whenever it is deemed necessary tofully complete the Project as contemplated. Any such work ordered by
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 31/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
32/112
32
the Engineer, in the absence of other payment provisions or pricesstipulated in the Contract, will be classified and paid for as Extra Workin accordance with 1904, provided a Supplemental Agreement isexecuted and approved, specifying the location and nature of the workto be performed and establishing the basis of payment. Sin embargo, elEngineer may order Minor Extra Work without the execution andapproval of a Supplemental Agreement, provided the Engineer's order isin writing (Work Order/Minor Extra Work) and specifies the locationand nature of the work.
Minor Extra Work shall not exceed $50,000 per individualoccurrence, Minor Extra Work exceeding $25,000 per individualoccurrence requires the approval of the Construction Assistant DistrictEngineer.
Extra Work shall be performed in accordance with theseSpecifications as they apply to the particular class of work involved,unless otherwise stipulated in the agreement authorizing the ExtraTrabajo. The Supplemental Agreement, authorizing Extra Work, shall not
become effective until it has been fully executed and approved asrequerido por la ley.
Any Extra Work or Minor Extra Work performed without writtenauthorization will be subject to 1512.
Page 3
1404.4
1404Maintenance of Traffic
1404.1 GENERALUnless otherwise provided, a road undergoing improvements shallbe kept open to all traffic by and at the expense of the Contractor.Where so provided in the Contract or when ordered by the Engineer,traffic shall be directed over an approved detour route.
The Contractor shall keep the portions of the Project being used bypublic traffic, whether it be through or local traffic, in such conditionthat the traffic will be adequately accommodated at all times. LaContractor shall provide and maintain temporary approaches, crossings,and intersections with trails, roads, streets, businesses, parking lots,residences, garages, farms, and other abutting property in acceptablecondition, but will not be required to remove snow.1404.2 PLANNED DETOURS
When the Plans, Special Provisions, or orders from the Engineerprovide for closure of the Project or specified portions thereof tothrough traffic, the Department will maintain those detour roads
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 32/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
33/112
33
established by the Commissioner to provide such closures, without anyexpense to the Contractor.1404.3 CONTRACTOR'S REQUEST FOR DETOUR
The Contractor may request that through traffic be detoured. Larequest shall contain all information needed for justification and shallspecify the routes to be established. If arrangements can be made thatare satisfactory to the agencies having jurisdiction over the roads to beused, the Contracting Authority may then at its sole discretion establishan approved detour subject to the following conditions:(a) The Department, at the Contractor's expense, will design, provide,
install, maintain, and remove all the necessary traffic controldevices on the detour roads.
(b) The Contractor shall reimburse the Contracting Authority for all
expenses incurred in maintaining and restoring the detour roads,except for snow removal.(c) The Contractor shall fulfill the obligations for maintenance of local
traffic by furnishing, placing, and maintaining all traffic controldevices and other traffic protection measures required on the roadsundergoing improvement.
1404.4 TEMPORARY BY-PASSESConstruction, maintenance, and removal of all temporary by-pass
facilities provided for in the Plans or Special Provisions or whenordered by the Engineer will be paid for at Contract prices or as ExtraTrabajo. All other temporary by-pass facilities requested by the
Pgina 3
1404.4
Contractor and approved by the Engineer shall be constructed,maintained, and removed at the Contractor's expense.1404.5 SPECIAL MAINTENANCE DIRECTED BY THEINGENIERO
If the Engineer directs the Contractor to perform specialmaintenance work for the benefit of the public or to provide dust controlsolely for the benefit of the public, then the Contractor will be paid forthat work at Contract prices or as Extra Work, except on Contractorrequested detours and Contractor-selected haul roads. El Ingenieroshall be the sole judge of work to be classified as special maintenance.1404.6 CONTRACTOR'S USE OF CROSSOVERS
Subject to all pertinent traffic laws and regulations, the Contractormay use freeway or expressway maintenance crossovers in and near theconstruction area for changing the direction of travel of the equipmentduring construction of the Project. However, such use of the crossoversmay be prohibited at any time by the Engineer.1404.7 WINTER SUSPENSION
On those sections of the Project where through traffic has beenexcluded, the Contractor shall, at no expense to the Department, make
passable and shall open the road to all traffic during periods of
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 33/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
34/112
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
35/112
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
36/112
36
consideration any cost reduction proposals involving changes in thedrawings, designs, specifications, or other requirements of the Contract.These provisions do not apply unless the proposal submitted is
specifically identified by the Contractor as being presented forconsideration as a Value Engineering Proposal.
The cost reduction proposals contemplated are those that wouldproduce a net savings to the Contract by providing less costly items ormethods than those specified in the Contract without impairing essentialfunctions and characteristics such as service life, reliability, economy ofoperation, ease of maintenance, and necessary standardized features.
Value Engineering submittals shall be in sufficient detail to enablethe Department to effectively evaluate the proposed modifications andthe resulting cost reduction. The following minimum information must
accompany each proposal.1) A statement that the proposal is submitted as a Value EngineeringPropuesta.2) A description of the proposal.3) An itemization of the requirements of the Contract that must bechanged, and a recommendation of how to make each change.4) An estimate of the reduction in performance costs that will resultfrom adoption of the proposal.
Pgina 3
1408
5) A prediction of any effects the proposed changes would have onother costs to the Department.6) A Statement of the time by which an agreement for adoption of the
proposal must be executed to obtain the maximum cost reduction duringthe remainder of the Contract, and the reasoning for this time schedule.7) The dates of any previous submissions of the proposal, includingContract numbers and the actions of the Department.8) A statement as to the effect the proposal would have on the time for
completion of the Contract.The Department will not be liable for any delay in acting upon anyproposal submitted. The Contractor may withdraw, in whole or in part,any value engineering proposal not accepted by the Department withinthe period specified in the proposal. The decision of the Department asto the acceptance or rejection of value engineering proposals shall befinal and not subject 1517.
The Contractor will be notified in writing of the Department'sdecision to accept or reject each value engineering proposal submittedunder these provisions-unless and until a proposal is effected by suchContract modification, the contractor shall remain obligated to performin accordance with the existing Contract. If the proposal is accepted, aSupplemental Agreement shall be executed setting forth the terms,conditions and costs of the proposal. Any work performed inaccordance with the value engineering proposal prior to execution of theSupplemental Agreement will be considered unauthorized work in
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 36/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
37/112
37
accordance with 1512.The Supplemental Agreement effecting the necessary contractmodifications shall establish the net saving agreed upon. La redsavings will be calculated as follows:
A= Contractor's cost for performing the workB= Original cost of performing the work.BA= Net Savings
The Contractor shall receive 50 percent of the net savings as a lumpsum payment for its shares of the Value Engineering Incentive, and thisamount will not be subject to revision as a result of final quantitiesaceptado. The Department reserves the right to include in the agreementany conditions it deems appropriate for consideration, approval, andimplementation of the cost reduction proposal.
The Contractor is solely responsible for its costs incurred in thedesign and development of the proposal.Costs incurred by the Department for reviewing, approving and
implementing the proposal will not be considered for net savingsclculos.
Pgina 3
1408
Upon acceptance of a cost reduction proposal, any restrictionsimposed by the Contractor on its use or disclosure of the informationsubmitted shall be void, and the Department shall thereafter have theright to use, duplicate, and disclose in whole or in part any datanecessary to use the proposal.
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 37/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
38/112
38
Pgina 3
1501.3
Control de Trabajo
1501Authority of the Engineer
1501.1 DECIDING QUESTIONSThe Engineer will decide all questions regarding:
(a) Quality and acceptability of materials furnished and workperformed.
(b) Manner of performance and rate of progress of the work.(c) Interpretation of the Plans, Specifications, and Special Provisions.(d) Measurement, control of quantities, and the amount of any
deductions or adjustments to be made in payment.(e) Acceptable fulfillment of all Contract provisions on the part of theContractor.
1501.2 SUSPENDING WORKThe Engineer may suspend the work, either wholly or in part, due to
failure of the Contractor to:(a) Correct conditions unsafe for the workmen or the general public,(b) Carry out provisions of the Contract, or(c) Carry out orders(d) Comply with the requirements of all permits for the project.
The Engineer may also suspend work for such periods as deemsnecessary due to unsuitable weather, for conditions consideredunsuitable for prosecution of the work, or for any other conditions orreasons deemed to be in the public interest.1501.3 BASIS OF DECISION
In all matters requiring a ruling by the Engineer, the Engineer's
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 38/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
39/112
39
decision will be based on engineering judgment, taking intoconsideracin:(a) Facts and inferences.(b) Inherent variations of materials and processes.(c) Risks associated with drawing inferences from test results on small
samples that may not be truly characteristic of the material orworkmanship represented.
(d) Past experiences relating to the question at issue.(e) Regulations, instructions, and guide lines established by the
Department for administration of the Contract work.(f) Other factors bearing on the issue.Where practicable, additional tests may be made to provide astatistically sound basis for judgment. Satisfactory evidence of properand adequate process control may be accepted in lieu of test results if itis impractical to measure the end result characteristics as specified.
Pgina 4
1502
1502Plans and Working Drawings
The Contracting Authority will furnish Plans for the Project,showing details and directions to provide a comprehensive descriptionof the construction contemplated, but will not provide all necessarydetail drawings for structures. The Plans prepared specifically for theProject under Contract will include a summary of all Contract items andwill show general features, typical cross sections, alignment and grades,structure locations and dimensions, layout diagrams, and special details.Supplemental drawings in the form of standard plates or standard planswill be furnished separately from the general Plans. Earthwork crosssections and contours may or may not be furnished with the Plans.
Prior to performance of the work, the Contractor shall prepare andsubmit, to the Engineer, schedules, documents, and working drawingsnecessary to complete the work. The Contractor shall allow sufficienttime for the Engineer to review and comment on the submittal and forthe Contractor to respond to the comments, prior to performance of thetrabajo que implica. The Engineer may require additional informationincluding permits, detail drawings, and calculations as needed tocomplete the Engineer's review. The Contractor shall furnish as manycopies of the submittals as the Engineer requires for review andsubsequent inspection of the work. The Contractor shall not change thesubmittals without the Engineer's written consent. Sobre la terminacin dethe work, reproducible copies suitable for microfilming shall befurnished to the Engineer if requested. The price bid for the Contractitems includes the cost of preparing and furnishing the submittals.
The Engineer's review of the submittals does not relieve theContractor of responsibility for:
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 39/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
40/112
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
41/112
41
binding as though occurring in all. They are intended to becomplementary and to describe and provide for a complete work.
In case of discrepancy, calculated dimensions will govern overscaled dimensions; Special Provisions will govern over Standard andsupplemental Specifications and Plans; Plans will govern over Standardand supplemental Specifications; supplemental Specifications willgovern over Standard Specifications.
The Engineer will decide all issues concerning errors and omissionsthat are not otherwise resolved by logical conclusion or Contractmodificacin. Both parties to the Contract shall inform each other as toany discrepancies they uncover, and neither the Contractor nor theEngineer shall take advantage of any error or omission.
Pgina 4
1504
In the interest of avoiding repetitious wording in the Specifications,certain words and phrases have been omitted where reference is clearlyrelated by expressions of authority or intention. Where certain wordsand terms appear, they are to be construed with reference to thedefinitions, abbreviations, heading, titles, item names, and other
pertinent provisions of the Contract documents, as may be implied.
1505Cooperation by Contractors
The Contractor shall cooperate with the Engineer, utility owners,and other contractors, in the mutual interest of all parties doing work onthe Project and as may be in the public interest to have the work ofcertain contracts and agencies performed concurrently rather thanconsecutivamente.
The Contractor shall coordinate work with that of utility owners so
that removal and rearrangement operations may progress in areasonable manner, duplication of work may be reduced to a minimum,and services rendered by those parties will not be unnecessarilyinterrupted.
When separate Contracts are let within the limits of any one Project,each Contractor shall conduct work so as not to interfere with or hinderthe progress or completion of the work being performed by othercontratistas. Contractors working on the same Project shall cooperatewith each other as directed. Each Contractor shall assume all liability,financial or otherwise, in connection with the Contract and shall savethe Department harmless from all damages and claims arising from anydelay, inconvenience, or loss experienced because of the presence andoperations of other contractors working within the limits of the sameDel proyecto.
Should a dispute arise between contractors or other agencies doingwork on the Project as to their mutual rights or obligations, the Engineer
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 41/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
42/112
42
will act as referee when requested to do so or upon the Engineer's ownmotion. The Engineer's decision as to the rights and obligations of theinterested parties shall be final.
1506Supervision by Contractor
The Contractor shall have a complete set of Plans andSpecifications available on the Project at all times while the work is in
progress, shall assume full responsibility for supervision of the workirrespective of the quantity of work subcontracted, and shall give thework the attention necessary to facilitate satisfactory progress and toensure completion in accordance with the terms of the Contract.
Pgina 4
1507
1506.1 COMPETENT SUPERINTENDENT
During the life of the Contract, the Contractor shall provide andhave at all times a competent Superintendent in charge of the overallProject who will be personally available at the site of the work within24 hours notice. This Superintendent may be either the Contractorhimself or a responsible employee who has been authorized to act in theContractor's behalf. This individual shall be fully authorized to:(a) Conduct all business with the subcontractors.(b) Negotiate and execute all Supplemental Agreements.(c) Execute the orders and directions of the Engineer without delay.(d) Promptly supply the materials, equipment, tools, labor, and
incidentals necessary for prosecution of the work.1506.2 COMPETENT INDIVIDUAL
At all times while work is actually being performed, the Contractorshall have at the site of the work a competent individual who is:(a) Authorized and fully capable of managing, directing, and
coordinating the work in progress.
(b) Thoroughly experienced in the type of work being performed.(c) Capable of reading and thoroughly understanding the Plans and
Especificaciones.(d) Authorized to receive instructions from the Engineer.
If this individual is an employee of someone other than theContractor, the Contractor shall provide the individual with writtenauthorization to act in the supervisory capacity stated above. Esteindividual and the Superintendent having overall responsibility for theProject may be one and the same person if constantly available in
person on the Project and fully qualified in all other respects.
1507Utility Property and Service
The Contract indicates the approximate location of known utilitieson the Project. The Contractor shall relocate and adjust the utilities asstated in the Contract. The Engineer, however, will make the final
01/06/2011 Mn / DOT estndar Especificaciones Li
googleusercontent.com/translate_c? 42/1
-
8/6/2019 DOT estndar Especificaciones Libro 2005 - Divisin I - 1101 a travs de las Secciones 1911 (DOT)}
43/112
43
decision on the location of all relocated and adjusted utilities.During the design process, the Department has notified public and
private utilities that their properties (such as pole lines, conduits, gaspipes, water pipes, sewers, and tile lines) must be removed or relocatedto complete the Project. However, the Depar