DELAY IN SETTLEMENT OF FINAL...
Transcript of DELAY IN SETTLEMENT OF FINAL...
DELAY IN SETTLEMENT OF FINAL ACCOUNT
HAJARATUL AZILA BINTI ROMLI
UNIVERSITI TEKNOLOGI MALAYSIA
iii
DELAY IN SETTLEMENT OF FINAL ACCOUNT
HAJARATUL AZILA BINTI ROMLI
A thesis submitted in fulfilment of the
requirements for the award of the degree of
Master of Science in Construction Contract Management
Faculty of Built Environment
Universiti Teknologi Malaysia
JANUARY 2015
v
Specially dedicated with deepest love to Umi and Abah, Datin Hanisah Binti Hj
Ismail and Dato’ Hj Romli Bin Hj Hassan and my husband Mohammad Harith Bin
Mohd Yunos
Thank you for your support, love and encouragement
vi
ACKNOWLEDGEMENT
In the name of Allah most gracious most merciful.
In preparing this thesis, I was in contact with many people, researchers,
academicians and practitioners. They have contributed towards my understanding
and thoughts. I wish to express my sincere appreciation to my supervisor, Assoc.
Prof. Dr. Sr. Maizon Binti Hashim, for encouragement, guidance, critics and
friendship. Also not forgotten to all the lecturues in programme of Master of
Science (Construction Contract Management) especially Assoc. Prof. Dr. Sr. Rosli
Bin Abdul Rashid, En. Jamaluddin Yaacob and Assoc. Prof. Dr. Nur Emma
Mustaffa for being so helpful and understanding.
I am so very thankful to all my family especially to my beloved husband, for
always being with me to light up my spirit and motivation. Not forgetting my
dearest parents, brothers and sisters, for always supporting me during the process of
completing of my study. My sincere appreciations to all my colleagues and others
who have provided assistance at various occasions. Their views and tips are useful
indeed.
Thank you
vii
ABSTRACT
When the project is certified to be practically completed the contractor will
be entitled to be paid the final payment. There are a lot of criticism regarding the
final account for construction projects that have been settled unreasonably late or far
beyond the period stipulated in the contract. This scenario occurs due to the duration
to settle the final account by government agencies. The government agencies have
failed to prepare the final accounts and final certificates according to the period
stated in the condition of contract and the government agencies also failed to release
the performance guarantee sum or performance bond within stipulated time.
Therefore, the objective of this study is to identify the problem associated with the
settlement of final account in the government projects and to recommend the
solution to the problem related to settlement of final account. The scope of this study
is limited to government project and government agencies . This questionnaires and
interview will be analysed to achieve the aims to identify the problem associated
with the settlement of final account and recommended solution. From the analysis, it
can be summarized that, there are ten (10) serious problems associated with the
settlement of final account. This are listed as variation, price, time, contractor,
contract, management matter (contract administrator), human, contractual, client and
external factor. There are numerous solutions to resolve these problems that have
been identified by the respondents in chapter 5 of the study. Therefore, by
conducting this research, hopefully will help the quantity surveyor and contract
administrator in identifying the problems in settlement final account and make
reasonable actions as soon as possible. This also to enable quantity surveyor to
reduce potential conflict in final account settlement and to ensure that the final
account and final certificate can be completed in timely manner.
viii
ABSTRAK
Apabila projek itu disahkan secara praktikal siap kontraktor berhak untuk
dibayar pembayaran akhir. Terdapat banyak kritikan berkenaan akaun akhir bagi
projek-projek pembinaan yang telah dibayar lewat atau lambat daripada tempoh
yang ditetapkan dalam kontrak. Senario ini terjadi kerana terdapat penangguhan di
dalam penyelesaian perakaun muktamad oleh agensi kerajaan. Kegagalan agensi
kerajaan untuk menyediakan akaun muktamad dan sijil akhir mengikut tempoh
yang dinyatakan dalam syarat-syarat kontrak dan juga kegagalan agensi kerajaan
untuk melepaskan wang jaminan perlaksanaan dalam masa yang ditetapkan. Oleh
itu, objektif kajian ini adalah untuk mengenalpasti masalah yang berkaitan dengan
penyelesaian perakuan muktamad dalam projek-projek kerajaan dan mencadangkan
penyelesaian kepada masalah tersebut. Skop kajian ini adalah terhad untuk projek
kerajaan dan agensi-agensi kerajaan. Soal selidik dan temubual akan dianalisis untuk
mengenalpasti masalah yang berkaitan dengan penyelesaian perakuan muktamad dan
cadangan penyelesaian yang disyorkan. Daripada analisis yang dijalankan, dapat
dirumuskan bahawa, terdapat sepuluh (10) masalah yang serius berkaitan dengan
penyelesaian perakuan muktamad. Diantaranya ialah perubahan, harga, masa,
kontraktor, kontrak, perkara-perkara pengurusan (pentadbir kontrak), manusia,
perkara-perkara kontrak, pelanggan dan faktor luaran. Penyelidikan ini, diharapkan
dapat membantu juruukur bahan dan pentadbir kontrak di dalam mengenalpasti
masalah dalam penyelesaian perakuan muktamad dan mengambil tindakan
sewajarnya secepat mungkin. Penyelidikan ini juga bertujuan untuk membolehkan
juruukur bahan mengurangkan pertelingkahan di dalam penyelesaian perakuan
muktamad dan memastikan perakuan muktamad dapat diselesaikan mengikut
tempoh ditetapkan.
ix
TABLE OF CONTENTS
CHAPTER TITLE TITLE
THESIS DECLARATION i
SUPERVISOR’S DECLARATION ii
TITLE PAGE iii
DECLARATION iv
DEDICATION v
ACKNOWLEDGEMENT vi
ABSTRACT vii
ABSTRAK viii
TABLE OF CONTENTS ix
LIST OF TABLES xv
LIST OF FIGURES xviii
LIST OF ABBREVIATION xix
LIST OF SYMBOLS xx
LIST OF CASES xxi
LIST OF APPENDICES xxii
1 INTRODUCTION
1.1 Introduction 1- 4
1.2 Problem Statement 4-6
1.3 Research Questions 6-7
1.4 Research Objective 7
1.5 Scope of Research 7
1.6 The Significant of Research 7- 8
1.7 Organization of Thesis Chapter 8 - 9
x
1.7.1 Chapter 1 : Introduction 8
1.7.2 Chapter 2 : Final Account in Government Sector 8
1.7.3 Chapter 3 : The Problem in Final Account Settlement 9
1.7.4 Chapter 4 : Research Methodology 9
1.7.5 Chapter 5 : Data Analysis 9
1.7.6 Chapter 6 : Conclusion and Recommendation 9
1.8 Conclusion 10
2 PROCEDURE IN THE SETTLEMENT OF FINAL ACCOUNT
2.1 Introduction 11
2.2 Defination of Final Account 11- 12
2.3 The Purpose of Final Account 13
2.4 Party involved in Preparation
Settlement of Final Account 13-15
2.4.1 Client 13
2.4.2 Superintendent Officer 13- 14
2.4.3 Consultant 13
2.4.4 Contractor 13
2.5 Final Account Requirement 13
2.6 The important of Final Account Settlement 13
2.7 Express Contractual Provisions 13
2.8 General content in Final Account 13
2.9 Process and Procedure 20-21
2.9.1 Procedure in Form of Contract
PWD 203/203A (Rev. 1/2010) 21-25
2.9.2 General Process in Standard Form of Contract 13
2.9.3 The Standard of Procedure for
Final Account settlement 30-32
2.9.4 Process of Final Account
in Standard of Procedure 33-51
2.10 Conclusion 51
xi
3 PROBLEMS IN THE FINAL ACCOUNT SETTLEMENT
3.1 Introduction 52
3.2 Problem related to settlement of the Final Account 52-67
3.3 Problem in Final Account settlement
according to circular 70-71
3.4 Solution to the problem in Final Account settlement 71-78
3.5 Improvement procedure of Final Account
settlement in circular 78-81
3.6 Conclusion 81
4 RESEARCH METHODOLOGY
4.1 Introduction 82
4.2 Research Methodology 82-82
4.2.1 Stage 1 : Initial Study and Finding the research 83-84
4.3 Stage 2 : Literature review, data collected
and research design 85
4.3.1 Literature review 85-87
4.3.2 Research Design 87-93
4.3.3 Instrument of Data Collection 93-96
4.4 Stage 3 : Data Analysis and Interpretation 96
4.4.1 Data Analysis Technique 96
4.4.2 Questionnaires Analysis 97-98
4.4.3 Interview Analysis 98-99
4.5 Stage 4: Writing-up 100
4.5.1 Structuring and writing the thesis 100
4.6 Research Framework 100-100
4.7 Conclusion 102
5 DATA ANALYSIS
5.1 Introduction 103
xii
5.2 Part A : Background of respondent 103
5.2.1 Analysis of respondent background 104
5.2.2 Analysis the number of project involved
by respondent over 5 years 105
5.3 Part B : Perception of the respondent
regarding in Final Account Settlement 103
5.3.1 Analysis of respondent perception
in final account settlement 103
5.3.2 Analysis of the respondents regarding
the important of Final Account Settlement 103
5.4 Part C : The Problems in Final Account Settlement 105
5.4.1 Analysis of the respondents’s involvement in
Final Account Settlement 105
5.4.2 Analysis of the respondents’ satisfaction with
final account procedure implemented
by government 105
5.4.3 Analysis of the frequency of the problems caused
by contractor during the final account settlement 105
5.4.4 Analysis of the respondents’ satisfaction with the
final account procedure implemented
by government 105
5.4.5 Analysis of the duration taken by respondent in
Final Account settlement 112-113
5.4.6 Analysis to determine the respondents’ view
of the delay in final account settlement and
whether it will affect the contractor 105-114
5.4.7 Analysis conducted to determine the most serious
factor contribute to problem
in final account settlement 114-116
5.4.8 Analysis the reason contribute to the problem
in final account settlement 116-117
5.4.8.1 Time 117-120
5.4.8.2 Contract 121-126
xiii
5.4.8.3 Price 127-128
5.4.8.4 Human 129-131
5.4.8.5 Variation 132-135
5.4.8.6 Contractor 136-139
5.4.8.7 Management Matter
(Contract Administrator) 139-144
5.4.8.8 Client 144-148
5.4.8.9 Contractual 148-151
5.4.8.10 External Factor 151-154
5.5 Part D : Improvement in the Final Account Settlement 154
5.5.1 Analysis whether 3 months duration is enough
for final account settlement 154-157
5.5.2 Analysis the reasonable period to
start final account 105
5.5.3 Analysis to determine the respondent opinion
regarding the acceptable of standard of procedure
to describe in a condition of contract
for final account settlement 158-159
5.5.4 Analysis to the view the respondent’s
opinion regarding the early settlement
in final account help in improving
the performance of contractor 159-160
5.5.5 Analysis to identify the suitable recommended
solution related to the problem in
final account settlement 161
5.5.5.1 Time 161-162
5.5.5.2 Contract 163-165
5.5.5.3 Price 166-167
5.5.5.4 Human 168-169
5.5.5.5 Variation 170-171
5.5.5.6 Contractor 172-174
5.5.5.7 Management Matter
(Contract Administrator) 175-179
xiv
5.5.5.8 Client 180-181
5.5.5.9 Contractual 182-184
5.5.5.10 External Factor 185-186
5.6 Interview 105
5.6.1 Analysis the Question 1: In your opinion,
what are the reasons related to the problem
in final account settlement 187-193
5.6.2 Analysis the Question 2: if the problem
in final account settlement happen
what action can be taken? 193-195
5.6.3 Analysis the Question 3: it is the
final account procedure need to
be improved? Why? 196
5.6.4 Analysis the Question 4 : In your opinion
is there any suggestion to minimize
the problem in final account settlement 197-200
5.7 Conclusion 200-209
6 CONCLUSION AND RECOMMENDATION
6.1 Introduction 210
6.2 Research conclusion 210-220
6.3 Constraints during the Research 220
6.4 Future Study 220
6.5 Conclusion 220-222
REFERENCES 223-231
Appendices A - E 232 - 270
xv
LIST OF TABLES
TABLE NO. TITLE PAGE
3.1 Forms of Contract in Malaysia 63
4.1 Schedule for determine the sample size
by Krejcie and Morgan (1970) 91
4.2 Number of target of respondent to distribution questionnaires 92
4.3 Scale Rating for Relative Index Method 97
5.1 The respondents background based on the total
distribution and return of questionnaires 104
5.2 Number of project involved by respondent over 5 years 105
5.3 Perception of respondent in Final Account 106
5.4 The important of Final Account Settlement 107
5.5 The respondents’ involvement of Final Account Settlement 108
5.6 The respondents’ satisfaction level in the procedure of
final account settlement 109
5.7 The frequency of the problem caused by contractor
during the final account settlement 110
5.8 The respondents’ satisfaction with the process
of final account settlement after the Certificate of
Practical Completion 111
5.9 The duration taken by respondent in final account settlement 112
5.10 The respondent’s view the delay in the preparation
final account and whether it will affect the contractor 113
5.11 The factor influencing the problem in Final Account Settlement 115
5.12 The reason related to time factor contributed the problem
in Final account settlement 117-118
xvi
5.13 The reason related to contract factor contributed the problem
in Final account settlement 121-122
5.14 The reason related to price factor contributed the problem
in Final account settlement 127
5.15 The reason related to human factor contributed the problem
in Final account settlement 129
5.16 The reason related to variation factor contribute the problem
in Final account settlement 132-133
5.17 The reason related to contractor factor contributed the problem
in Final account settlement 136
5.18 The reason related to management matter (contract administrator)
factor contributed the problem in
in Final account settlement 139-140
5.19 The reason related to client factor contributed the problem
in Final account settlement 144-145
5.20 The reason related to contractual factor contributed
the problem in final account settlement 148-149
5.21 The reason related to external factor contribute the problem
in Final account settlement 151-152
5.22 The 3 months duration is enough for
in Final account settlement 154
5.23 The reasonable period to start the Final Account Settlement 157
5.24 The respondent’s opinion regarding the acceptance of
Standard of procedure implemented by government to
to describe in a condition of contract 159
5.25 The respondent opinion the early settlement of final account
helps in improving performance of th contractor 160
5.26 The suitable recommended solution in time related
problems in final account settlement 161
5.27 The suitable recommended solution in contract related
problems in final account settlement 163
5.28 The suitable recommended solution in price related
problems in final account settlement 166
5.29 The suitable recommended solution in human related
xvii
problems in final account settlement 168
5.30 The suitable recommended solution in variation related
problems in final account settlement 170
5.31 The suitable recommended solution in contractor related
problems in final account settlement 172
5.32 The suitable recommended solution for management matter
( contract administrator) problems in final account
settlement 175-176
5.33 The suitable recommended solution for client related
problems in final account settlement 180
5.34 The suitable recommended solution for contractual related
problems in final account settlement 182
5.35 The suitable recommended solution for external factor
problems in final account settlement 185
5.36 Summary of the reason related to the problems
in the final account settlement 187
5.37 The action can be taken if the problem in settlement
final account happen 193-194
5.38 The Final Account procedure need to improved 196
5.39 The suggestion to minimize the problem in
final account settlement 197-198
xviii
LIST OF FIGURES
FIGURE NO. TITLE PAGE
2.1 Flow chart of closing Final Account
Based to PWD 203A (Rev 1/2010) 25
2.2 Flowchart on general procedure for preparation of
Final Account (Part I) 26
2.3 Flowchart in general procedure for preparation of
Final Account (Part II) 27
2.4 Flowchart in general procedure for preparation of
Final Account (Part III) 28
2.5 Process of closing Final Account 39
2.6 Period for preparation Final Account 41
2.7 Flowchart in standard procedure for preparation of
Final Account 43
2.8 Flowchart in standard procedure for preparation of
Final Account in mutual termination 48
2.9 Flow chart for preparation final account in
government 50
3.1 Factor influencing final account settlement 68
3.2 Factor Final account closing delay in theorical
framework 69
4.4 Research Methodology Framework 101
xix
LIST OF ABBREVIATION
CMGD Certificate of Making Good Defect
FA Final Account
EPU Economic Planning Unit
VO Variation Orders
KPPK Ketua Penolong Pengarah Kanan
JKR Jabatan Kerja Raya
SAKPKR Surat Arahan Ketua Pengarah Kementerian Kerja Raya
Bil Bilangan
SKALA Sistem Pengurusan Projek
SPK Sistem Pematuhan Kerja
CPC Certificate of Practical Completion
SO Superitendent Officer
CL Clause
SPP Surat Pekeliling Perbendaharaan
PK Perolehan Kerajaan
PMK Pegawai Mentadbir Kontrak (Agensi/ Konsultant)
PP Pengawai Penguasa atau Pengarah Projek bagi Projek Reka
Bina
LAD Liquidated and Ascertained Damages
APK Work Change Directive (Arahan Perubahan Kerja)
PHK Adjustment for omission Contract Sum (Pelarasan Harga
Kurangan)
SOFA Statement of Final Account
VOP Variation of Price
WJP Performance Guarantee Sum (Wang Jaminan Perlaksanaan)
SPSS Statistical Packaging for Social Science
xx
LIST OF SYMBOLS
∑ - total sum
n - the number of respondent indices
xxi
LIST OF CASE
NO. CASE PAGE
1 Rees & Kirby Ltd v Swansea City Council (1983) 16
xxii
LIST OF APPENDICES
APPENDIX TITLE PAGE
A Sample of Questionnaire 232-248
B Sample of Interview question 249-250
C Sample of Checklist for Final Account 251-255
D Sample of Final Account Form 256-260
E Summary of the problem and solution 261-270
For settlement of final account
1
CHAPTER 1
INTRODUCTION
1.1 Introduction
The final account refers to the calculation and adjustment of the final
construction cost between the client or employer and the contractor based on a fair
valuation of the work carried out. Thus, a contractor’s actual profits or losses can be
determined when the final account is settled (Chan, 2002). Any delay in final
account settlement can adversely affect the contractors’ cash flow and the ability to
secure its finance (Ashworth & Hogg, 2002).
The finalizing of the account is not a one sided activity involving the contract
administrator but entails the necessary input of the contractor especially in terms of
the provision of the relevant documents, substantiation each in regard to his claims
and also of those pertaining to his sub-contractor. Therefore, there must be a pro-
active approach on both sides and a strict adherence to any programmed or deadlines
set. For that reason, the issue of the final account remaining open for years after ther
Certificate of Making Good Defect (CMGD) has been issued in majority of contract
(Harbans Singh,2010).
Besides that, the final account period of settled is depending on the final
payment certificate described in contractual prescribed timescale. It is classified as
on time and satisfaction, if the final account settlement is completed in the
2
contractual prescribed timescale. It is classified as delay and dissatisfaction, if the
prescribed timescale overrun or if the engineer is not able to issue the final payment
certificate within such timeframe (Walker, 1998).
One of the conditions of the contract that led to problems and disputes in
preparation of the final account settlement is duration for preparation. Although the
contract clearly identify the period for the issuance of the final account of not later
than three (3) months after the issuing of the Certificate of Making Good Defect
(CMGD). The period of three (3) months is a practical and reasonable time for all
parties. However, as with the preparation of other documents in the administration of
a building contract, the process of preparation final account often face problems and
obstacles (Quantity Surveying, 2010). Moreover, the lack of understanding the roles
and responsiblilities in the contract regarding the issuance of a final payment
certificate to the contractor will cause the disputes and problems in the closing of the
final account statement (Zarabizan et al., 2012).
Therefore, settling a final account can be long drawn out process, that brings
together all financial aspects of the contract. The goal for a final account is to agree
to a fair valuation of the works undertaken by the building contractor and to enable
the contract administrator to issue the final certificate, thereby concluding the project
works. Reaching an agreement between parties may involve much negotiation and
the final accounts prepared from these should be able to withstand the most stringent
financial audit as it’s legally binding (Ashworth & Hogg, 2002).
Although the backlogs in the closing of final accounts have existed for
decades, there are many factors significantly affecting the closing of a final account.
For example, the construction projects in Hong Kong have been identified
contractual, contractor and management. Unfortunately, factors delay in closing
final account usually attract less attention and priority by project participant more
difficult and frequently leads to emergence of unnecessary dispute (Kwok Chi Ko,
2009).
3
The rapid increase of the late payment issues nowadays has gone to the point
that it tends to decrease the good image of construction in Malaysia. The Malay
Contractor Association whom once revealed that some contractor are owed RM 100
million to RM 200 million for four to five years, mostly on final payment (Utusan
Malaysia, 2006). According to the then Prime Minister Abdullah Ahmad Badawi
(2006) dated 6 October 2006, complaints relating payment to contractors and
supplier tends to give negative perception that the implementation of the 9th
Malaysia Plan is moving at a slow pace. This shows the seriousness of the
problems because it is related to the image of Malaysia’s construction industry
(Zarabizan et al., 2013).
However, parallel to these increasing developments in the construction
industry, the practices and procedures today are vastly different from the old days.
There are numerous criticisms as to the increasing number of the construction
projects final account of which were settled unreasonably late or far beyond the
period stipulated in the contract (Zarabizan et al., 2013).
In PWD Form 203A (Rev. 1/ 2010), the contract states that the Contractor
shall submit full particulars complete with supporting documents within but not
more than three (3) months after issuing of the Certificate of Practical Completion.
The Superintendent Officer (S.O) shall issue the Final Certificate within three (3)
months after the expiry of the Defect Liability Period for the whole of the Works or
three (3) months after the issuance of the Certificate of Completion of Making Good
Defect (CMGD) in Clause 31.
According to circular “Surat Pekeliling Perbendaharaan, SPP Bil.6 Tahun
2011”, the Superintendent Officer shall issue a final account and final certificate
within three (3) months after the expiration of the defect liability period for the entire
work, or three (3) months after the Certificate of Making Good Defect (CMGD)
4
issued, whichever is later, according to the provisions of the contract. However,
according to Surat Arahan KPKR Bil (6) dlm. JKR.KPKR. 020.050/3 Klt.4 dated
20.9.2000, the final account and final certificate should be issue not later than 6
months after the date of Practical Completion has been issued.
According to the Perolehan Kerajaan (PK 4/2013), with regard to the
adjustment of the contract sum and approved claims by the Claims Committee, the
agency shall prepare a statement of final account within the prescribed period.
Under the traditional contract the period for preparation statement of final account is
nine (9) months from Certificate of Practical Completion. Whereas under design and
build contract the period for preparation statement of final account is twelve (12)
months from Certificate of Practical Completion. But, it is different indicated in the
SA KPKR Bil. 14/2012 which is during the preparation of the statement of final
account established for six (6) months after the Certificate of Practical Completion
was issued for both type of contract namely traditional and design and build project.
If the final account does not settle according to the duration stated in
construction contract the contract administrator is legal binding. But if the final
account is not settle according to the Treasury Circlular or any circular provided by
department the contract administrator will be surcharge or disciplinary action will
be taken to him. Normally, late or delay due to many reasons such as management
matter (contract administrator), client, consultant, contractor, price, variation, time,
contract, contractual, external factor and others.
1.2 Problem Statement
The delay in payment of the final account and discharge performance
guarantees are often the issues and dilemmas for the contractors nowadays. In
newspaper Utusan Malaysia newspaper article dated 11 December 2002, it was
reported that many contractors have still not received any payment from the agencies
5
after completing the work. Therefore, the Deputy of Prime Minister Dato’ Seri
Abdullah Ahmad Badawi in his instruction dated on the 3rd of July 2001 has issued
an order to government agencies to expedite the payment to contractors including
the issuance of the final account and the final certificate.
According to Norshimah Meon, the Ketua Penolong Pengarah Kanan
(KPPK) of the Jabatan Kerja Raya (JKR) Selangor (2010) the delays in final account
also occur in government agencies because of unfamiliarity with new procedures and
rules introduced by the government and also due to time constraints. As a result, the
appointed quantity surveyor cannot perform the best services for government (Sr.
Norshimah Bt Meon & Pn. Hanawati Bt. Hashim, 2010).
The conflict between regulations and procedures set forth by the government
or the relevant agencies can also occur in the end condition of contract and document
tender. As stated in the KPKR (Surat Arahan Ketua Pengarah Kementerian Kerja
Raya circular, the SAKPKR Bil. 14/2012), the statement of final account should be
prepared six months after the issuance of the Certificate of Practical Completion
(CPC). However, both Clause 31.4 of PWD 203A (Rev. 1/ 2010) for conventional
contract and Clause 54 of PWD 203 (Rev. 1/ 2010) for design and build, indicate
that the final account must be issued by three months after the Certificate of Making
Good Defect (CMGD). The different period in the settlement of the final account has
created problems to the contract administrator to complete the final account (QS
Corner, 2013).
The various agencies have also came out with standard of procedure and
office procedures on how to settle the final account within the stipulated time. But
no pointed out the issue or problem of late settlement of final account still persist.
Some can be months to 3 years which significantly longer than stipulated in due
contract and as stated by the standard of procedure. For example, in yearly report
2013 by “Cawangan Kontrak dan Ukur Bahan, Jabatan Kerja Raya” has stated
Statement of Final Account was prepared more than 6 months from the date of
Certificate of Practical Completion issued. The date of Certificate of Practical
6
Completion is 20 May 2012 which stated in “Sistem Pengurusan Projek” (SKALA)
while the date of certify the Statement of Final Account is 20 Augurst 2013.
Moreover, in Audit Report 2012 (Siri 1) has stated, the delay in issued final account
has identify in Project Redevelopment of Kuala Terengganu Airport Project Package
11-Terminal Building. It can be seen when the Certificate of Making Good Defect
(CMGD) has been issued at Julai 2010 but the delay is 652 days. Furthermore, in
Audit Report 2012 (Siri 2), has stated 29 project has been delay in issung final
account which is about 4 to 44 months.
Therefore, a lot of conflicting can be made in connection with the duration to
settle the final account. One of them is that the final account settlement has always
been delayed by the government agency. The government agency failed to prepare
the final account and the final certificate at the time specified in the contract, and the
government agency failed to release performance monies within the stipulated time
(Zain, 2003).
Due to the problem related to the issuance of final account settlement, this
study will identify the problems in the final account settlement and recommend the
solutions accordingly.
1.3 Research Questions
The discussion and the statatement of problem highlighted important
questions:
a) What are the problem in finalization final account by the contract
administrator?
b) What are the legal implication of the delays in the final account in
accordance with the contract?
7
c) What are finalization and payment of the remedy available to the
contractor in the event of delay in closing final account?
1.4 Research Objectives
The objectives of this research are:-
1. To identify the problem associated with the settlement of final
account in the government projects; and
2. To recommend the solution to the problems related to the settlement
of a final account
1.5 Scope of Research
This research is limited to government project and government agencies.
1.6 The Significance of Research Study
This research is important in order to get a picture of the existing problems
in the final account settlement and to provide solutions for the quantity surveyor’s
practice in government agencies. It also can alert various parties that the delay in the
preparation of the final account actually has legal implications and may allow the
contractor to claim compensation. It also aimed to enable quantity surveyor to reduce
potential conflict in the final account settlement and to ensure that the final account
settlement can be completed in a timely manner.
8
In addition, this research also aims to answer questions that arise in the final
account settlement. Furthermore, this research can helps contract administrator and
quantity surveyors to make reasonable actions related to final account settlement.
While to the contractors and other party involved, it is to assist them fully
understand problems in final account settlement. Findings of this research will also,
provide readers and other interested parties with a better appreciation and
understanding of the problem in final account settlement in government agencies.
1.7 Organization of Thesis Chapter
The report is organized into six (6) chapters:
1.7.1 Chapter 1: Introduction
This chapter, will discuss the background of the problem, problem statement,
objectives of the research, scope of study, significance of the study and the
organization of the thesis chapter.
1.7.2 Chapter 2 : Final Account in Government Sector
This chapter discusses the definition of a final account, parties that are
involved in final account, contractual provisions, and procedures in the issuance of
the final account by construction contract and the standard procedures in government
agencies.
9
1.7.3 Chapter 3 : The problem in Final Account Settlement
This chapter will discuss, the hypothesis of the problem or causes of the
delay in final account settlement and the solution to the problem in final account
settlement.
1.7.4 Chapter 4 : Research Methodology
This chapter is to explain research methodology that has been endorsed in
this study which consist of explanations on the method used and reasons behind the
selection.
1.7.5 Chapter 5 : Data Analysis
In this chapter, all the survey questionnaires will be divided into four sections
and analysis. In Part A the analysis aims to identify the respondent background. In
Part B the analysis aims to identify the perception in final account settlement. Hence,
in Part C and Part D analysis will focus on the problems in final account settlement
and the recommended solution for them.
1.7.6 Chapter 6 : Conclusion and Recommendation
This chapter presents the recommendations, conclusions and suggestions
for research that are needed in this area of study. It also addresses some
implications of the research recommendation to the construction industry.
10
1.8 Summary and Conclusion
In conclusion, the numerous critisim as to the increasing number of the
construction projects final account of which were settled unreasonably late or far
beyond the period stipulated in the contract. Therefore, this study is to identify the
problem accsociated with the settlement of final account in the government project
and to recommend the solution to the problem related to issuance of final account.
The research has been conducted by analysing the questionnaire and interview which
is distributed to quantity surveyor serve in government agency. From the analysis,
the problem in settlement of final account has been identify and categorized under
several problem discovered during the survey. From that, a critical analysis is done
on the result of survey for the problem and recommended solution for the issues in
contention as the findings of the study.
223
LIST OF REFERENCES
Ada Kontraktor Bergolak Bergadai Tunggu Bayaran. (2006, October 6). Utusan
Malaysia
Alias, M.Z (2003). Isu Kelewatan Penyediaan Bayaran Akhir Kepada Kontraktor
Dalam Industry Binaan di Negeri Perlis. Universiti Sains Malaysia: Master
Thesis
Ashworth.A, Hogg K & Catherine Higgs (2013). Willis’ Practice and Procedure for
the Quantity Surveyor (Third edition). UK: Blackwell Science Ltd.
Anwarul Yaqin (2007). Legal Research and Writing. Malaysia: Malayan Law
Journal Sdn Bhd (Lexis Nexis)
Arain and Low S.P (2006). The Potential Effects of Variation Orders on Institutional
Building Projects. The Emerald Research: 496-510
Ashworth A. and Hogg K. (2002). Willis’s Practice and Procedure for the Quantity
Surveyor (Elevent Ed.). UK: Blackwell Science Ltd
Assaf S.A and Al-Hejji S.(2006). Causes of Delay in Large Construction Projects.
International Journal of Project Management, 349-357
Assaf,,S.A , Al-Khalil,M and Al-Hazmi, M (1995). Causes of Delays in Large
Building Construction Project. Journal of Construction Engineering and
Management, 45-50
224
Baccarini D.(1999). The Logical Framework Method for Defining Project Success.
Project Management Journal, 25-32
Baloi D. and Price A. (2003). Modelling Global Risk Factors Affecting
Construction Cost Performance. International Journal of Project
Management, 261-269
Bromilow F.J, Hinds M.F and Moody N.F (1998). The Time and Cost Performane of
Building Contract. The Building Economics, 1976-1986
Burn, R.(1995). Introduction to Research Methods. Melbourne: Logman
Cartlidge D.P (1973). Cost Planning and Building Economic. London: Hutchinson
Educational Ltd
Chan D.W.M and Kemaraswamy M.M (1995). The Study of the Factors Affecting
Construction Duration in Hong Kong. Construction Management and
Economics, 319-330
Chan A.S (2002). Framework of Success Criteria for Design/Build Projects. Journal
of Management Engineering, 120-128
Chan D.W.M and Kumaraswamy, M.M (1996). An Evaluation of Construction Time
Performance in the Building Industry. Building and Environment, 569-578
Cheung S.O and Suen H.(2002). A Multi-attribute Utility Model for Dispute
Resolution Strategy Selection. Construction Management and Economics,
557-568
Cheung, S.O (1999). Critical Factors Effecting the Use of Alternative Dispute
Resolution Process in Construction. International Journal of Project
Management, 189-194
Chow Kok Fong (2006). Construction Contracts Dictionary. Singapore: Thomas,
225
Sweet & Maxwell Asia
Chun Pong Sing, P.E.D Love, Jim Smith and Chi Ming Tam (2013). Factors
Influencing Final Account Settlement in Construction Projects. The
Construction, Building and Real Estate Research Conference of the Royal
Institution of Chartered Surveyors. 10th-12th September 2013. New Delhi
India: University of ULSTER, ISBN: 978-1-78321-030-5.
Conlin J.,Langford,D and Kennedy,P(1996). The Relationship between Construction
Procurement Strategies and Construction Contract Disputes. Northmeets
South’ Procurement Systems Symposium. Durban,South Africa, 66-82.
Cook, C.F. Health,R, Thompson,L and Thompson,B (2001). Score Realiabiliy in
Web or Internet Based Surveys:Unnumbered Graphic Rating Scales versus
Likert Type Scales. Educational and Phychological Measurement, 697-706.
D.White and J.Fortune (2002). Current Practice in Project Management-An
Empirical Study. International Journal of Project Management Volume 20,
1-11
David Dooley (2001). Social Research Methods (4th edition). New Jersey:Prentice
Hall Inc.
Dawes,J (2008). Do Data Characteristic Change According to the Number of Scale
Points used?. International Journal of Market Research, 61-77
Dennes F.Tuner (1983). Quantity Surveying Practice and Administration Third
Edition. London and New York: George Godwin
Department of Statistic, Malaysia (2014). www.statistics.gov.my Retrieved
September 12 ,2014, from Department of Statistic,Malaysia,Official Portal:
http://www.statistics.gov.my/portal/index.php?option
Department of Statistic, Malaysia (2014). www.statistics.gov.gov.my Retrieved
226
September 13, 2014, from Department of Statistic Malaysia, Official Portal:
http://www.statistic.gov.my/portal/images/stories/files/LatestReleases/gdp/20
14/GDP_PRESS_RELEASE_Q1_2014.pdf
Dillman D.S (2009). Internet,Mail and Mixed Mode Survey: The Tailored Design
Method. Honoken, N.J: John Wiley & Sons Inc
Dr D.G Naoum (2013). Dissertation Research & Writing for Construction Student
(third edition). USA and Canada: Routledge
Gelder. C (2010). www.bplaw.com Retrieved July 14, 2014, from Berwin Leighton
Paisner: http://www.bplaw.com
Geoff P. and Judy P. (2004). Key Concepts in Social Research. London:Sage
Publications
Harbans Singh KS (2003). Engineering and Constructions Management: Post
Commencement Practice. Malaysia:Lexis Nexis
J.W.Ramus A.R.I.C.S (1993). Praktik Kontrak Untuk Juruukur Bahan. Kuala
Lumpur: Dewan Bahasa dan Pustaka, Kementerian Pendidikan Malaysia
Kwok Chi Ko (2009). Study Important Factors Affecting Final Account Settlement
Satisfaction of Hong Kong Civil Engineering Projects:Contractor’s
perspective. Hong Kong: City University Hong Kong
K.M.Yee and H. Abdul Rahman (2010). Risk of Late Payment in Malaysia
Construction Industry. Malaysia: Faculty of Building Environmental,
University of Malaya
Kahir A..H(2003). Perlaksanaan Tanggungjawab Klien Dalam Penyediaan
Perakuan Muktamad: Kajian Kes Projek-projek Perbadanan Pembangunan
Pulau Pinang, Malaysia. Master Thesis Universiti Sains Malaysia, Pulau
Pinang.
227
Kaka A and Price A.D.F (1991). Relationship between Value and Duration of
Construction Projects. Construction Management and Economics, 383-400
Keith F.P (1998). Introduction to Social Research: Quantitative and Qualitative
Approaches. London:Sage Publications
Ken Margolies (2007). www.digitalcommons.ilr.cornell.edu Retrieve November
9,2014 from Dgital Commons @ ILR:
http://digitalcommons.illr.cornell.edu/cgi/viewcontents.cgi?article
Ketua Pengarah Kerja Raya (1992). Panduan Pentadbiran Kontrak Kerja Raya Edisi
Kedua. Kuala Lumpur: Ibu Pejabat JKR Malaysia
Ketua Pengarah Kerja Raya (2010). Buku Panduan Pentadbiran Kontrak Kerja Raya
Edisi Ketiga. Kuala Lumpur:Ibu Pejabat JKR Malaysia
Kevin B. (2008). Defective Construction Work and the Project Team. United
Kingdom:Wiley-Blackwell
Khang D.B and Moe T.L (2008). Success Criteria and Factors for International
Development Projects: A Life cycled Based framework. International
Journal of Project Management,72-84
Lim Chong Fong(2013). The Malaysia PWD Construction Contract:First
Supplement to the second edition. Malaysia: Sweet & Maxwell Asia
Lo T.Y, Fung I.W.H and Tung F.C.F (2006). Construction Delays in Hong Kong
Civil Engineering Projects. Journal of Construction Engineering and
Management and Economics, 636-647
M.Sambasivan and Y.W.Soon (2007). Causes and Effects of Delay in Malaysia
Construction Industry. International Journal of Project Management, 517-
526
228
Majid M. and R.McCaffer (1998). Factors of Non-execusable Delays that Influence
Contractor’s Performance. Journal of Management in Engineering, 42-49
Malayan Banking Berhad (2011). Maybank Annual Report 2011. Kuala Lumpur:
Maybank
Market Watch 2012 Construction Industry (2011). www.malaysia.ahk.de Retrieved
from the German Chamber Network: http://www.malaysia.ahk.de
Martin E.(1993). Importance of Teaching Construction Specification. Professional
Issuee in Engineering Education and Practice,147-152
Merriem S.(1998). Quantities Research and Case Study Application in Education
(secons edition). San Francisco: Jossey-Bass
Miles M.A(1994). Quantities Data Analysis:An Expanded Sourcebook (Second
Edition). Thousand Oaks: Califf Sage
Murdoch J and Hughes W. (1992). Construction Contracts: Law and Management.
London: E&FN Spoon
Nor Ainah Abdullah (2001). Pengenalan Kepada Kontrak Binaan. Malaysia:
UPENA (Unit Penerbitan Akademik) Universiti Teknologi Mara Shah Alam
Odeh A.M and Batteineh H.T (2002). Causes of Construction Delay:Traditional
Contracts. International Journal Project Management, 67-73
Odeyinka H.A. (2005). An Evaluation of Contractors’ Satisfaction with Payment
Terms Influencing Construction Cash Flow. Journal of Financial
Management of Property and Construction, 171-180
Ogunla S.O, Promkuntong K. & Jearkjirm V.(1996). Construction Delays in a Fast-
229
growing Economy: Comparing Thailand with other Countries. International
Journal of Project Management, 37-45
Peter M.N (2003). Doing Survey Research: Guide to Quantitative Methods. Boston:
Pearson Education Inc
QS Corner (2013). www.qs.interactive.com Retrieved from QS Corner:
http://www.qs-interactive.com/isu-projek-mansuh-perkiraan-perakuan-
muktamad.html
Reeves K.(2003). Pay up. JUBM Construction News and View 1/2003, 4-6
Roger G.(2008). Construction Delays:Extension of Time and Prolongation Claims.
New York:Routledge
S.Tumi, A.Omran and A.Pakir (2009). Causes of Delay in Construction Industry in
Libya. Romania , 265-272
Seamus Cooley (2010). www.goarticle.com Retrieved from Go.Article.com:
http://www.goarticle.com
Sr. Norshimah M & Hanawati H. (2010). Pengukuran Kuantiti Sementara &
Penutupan Akaun. Kursus Pentadbiran Kontrak Siri Ke-2. 30 June 2010,
Malaysia: Jabatan Kerja Raya (JKR).
Strischeck D (1995). Cash Flow Projections for Contractors. Journal of Commercial
Lending, 17-37
The Hong Kong Institute of Surveyor (2012). Practice Notes For Quantity Surveyor.
Hong Kong: Association at Consultant Quantity Surveyor
Thomas J.S (2001). Methods of Social Research. Orlando FI:Prentice Hall
Thomas H.R, Smith G.R and Ponderlick R.M (1992). Resolving disputes based on
230
misrepresentations. Journal of Construction Engineering and Manageement,
427-87
Thormas H.R, Smith G.R and Mellott R.E(1994). International of Construction
Contract. Journal of Construction Engineering and Management, 321-336
Uher T.E (1991). Risk in subcontracting: Subcontract conditions. Construction
Management and Economics, 495-508
Uma Sekaran (1992). Research Methods in Business: A Skill Building Approach
(second edition). New York:John Wiley & Sons Inc
Unit Perancang Ekonomi (EPU) (2013). www.epu.gov.my Retrieved from Unit
Perancang Ekonomi, Jabatan Perdana Menteri Malaysia:
http://www.epu.gov.my
Vee C and Skitmore (2003). Professional Ethic in the Construction Industry.
Engineering Construction and Architectural Management, 1170127
Vincent P.S, Douglas S. and Redmond J (1999). Civil Engineering Claims Third
Edition. Oxford:Blackwell Science
W.L. Neuman (2003). Social Research Methods: Qualitative and Quantitative
Approaches (5th edition). Boston: Pearson Education Inc
Walker A.L (1998). Evaluation of Project Outcomes. Construction Management and
Economics, 209-219
Wiguna I.P.S and Scott S. (2005). Analyzing the Risks Affecting Construction Delay
and Cost Overruns in Indonesia Building Projects. Innovation in
Architecture, Engineering and Construction. Rotterdam, 841-849
Yiu C.Y, Ho H.K, Lo S.M and Hu B.Q (2005). Performance Evaluation for Cost
231
Estimators by Reliability Interval Method. Journal of Construction
Engineering and Manageement, 108-116
Zainul A., N and Pasquire C.L (2005). Delivery Sustainability through Value
Management: the Concept and Performance Overview. Engineering
Construction and Architectural Management, 168-180
Zarabizan Z., Syuhaida I and Aminah M.Y (2013). An Overview of Comparison
between Construction Contract in Malaysia: The Roles and Responsilibilities
of Contract Administrator in Achieving Final Account Closing Success.
International Conference on Education and Education Technologies, 34-41
Zarabizan Z., Syuhaida I and Aminah M.Y (2013). Toward Sustainabality in
Construction Industry: The Important of Final Account Satisfaction. Wulfenie
Journal, 118-125
Zarabizan Z., Syuhaida I and Aminah M.Y (2013). Fundamental Variables of Final
Account Closing Success in Construction Project in Malaysia. International
Journal of Social, Human Science and Engineering, 121-126
Zarabizan Z., Syuhaida I and Aminah M.Y (2012). Cause and Impact of Dispute and
Delay the Closing of Final Account in Malaysia Construction Indusrty.
Journal of Southeast Asian Research, 1-12
Zarabizan Z., Syuhaida I and Aminah M.Y (2013). Effectiveness of Payment
Management System and its Effects to the Closing of Final Account in
Construction Project Malaysia. Journal of Physical: Conference Series.Vol
423, 012034
Zarabizan Z., Syuhaida I and Aminah M.Y (2013). Causes of Final Account Closing
Delay: A Theoretical Framework. International Journal of Social, Human,
Science and Engineering, 186-192