Cover March 2020 Monthly Progress Report...
Transcript of Cover March 2020 Monthly Progress Report...
HONOLULU RAIL TRANSIT PROJECT
March 2020 MONTHLY PROGRESS REPORT
www.HonoluluTransit.org
Honolulu Rail Transit Project Monthly Progress Report March 2020
2 | P a g e
DISCLAIMER NOTICE This document is disseminated under the sponsorship of the United States Department of Transportation, Federal Transit Administration (FTA), in the interest of information exchange. The United States Government assumes no liability for the contents or use thereof. The United States Government does not endorse products or manufacturers. Any trade or manufacturers' names appear herein solely because they are considered essential to the contents of the report.
NO RELIANCE BY THIRD PARTIES This report and all subsidiary reports are prepared solely for the FTA, and should not be relied upon by any party, except the FTA, its Project Management Oversight Contractors (PMOC), and the Honolulu Authority for Rapid Transportation (HART) Board of Directors, in accordance with the purpose as described in the next section.
REPORT FORMAT AND FOCUS This document is submitted in compliance with the terms of FTA Contract No. DTFT60-09-D-00012, Task Order No. 2. Its purpose is to provide information and data to assist the FTA as it continually monitors HART's technical capability and capacity to execute a project efficiently and effectively, and hence, whether HART continues to be ready to receive federal funds for further project development. This document covers the project and quality management activities on the Honolulu Rail Transit Project managed by HART as the project sponsor and partially financed by the FTA under the Full Funding Grant Agreement (FFGA). Concurrent non-project activities and other items not covered by the FFGA may not be included.
INFORMATION REGARDING FORWARD-LOOKING STATEMENTS This document includes forward-looking information. The words "believe”, "anticipate", "expect", "intend", "aim", "plan", "predict", "continue", "assume", "positioned", "may", "will", "should", "shall", "risk" and any other similar expressions that are predictions of or indicate future events and future trends identifies forward-looking information. Forward-looking information includes all matters that are not historical facts. Readers should not place undue reliance on forward-looking information because it involves known and unknown risks, uncertainties and other factors that are in many cases beyond HART's control. By its nature, forward-looking information involves risks and uncertainties because it relates to events and depends on circumstances that may or may not occur in the future. Forward-looking information is not a guarantee of future performance, and HART's actual results of operations, financial condition, and the development of the industry in which it operates may differ materially from those made in or suggested by forward-looking information contained in this document. The cautionary statements set forth above should be considered in connection with any subsequent forward-looking information that HART, or persons acting on its behalf, may issue. Factors that may cause HART's actual results to differ materially from those expressed or implied by the forward-looking statements in this document include but are not limited to the risks described in HART's annual report. For projects funded through the FTA's New Starts program, the FTA and its PMOC use a risk-based assessment process to review and validate a project sponsor's budget and schedule. Any results of an FTA or PMOC risk-based assessment represent a "snapshot in time" for a particular project under the conditions known at that same point in time. The status of any assessment may be altered at any time by new information, changes in circumstances, or further developments in the project. Furthermore, any forward looking statements contained in this document are made as of the date of this report, and HART does not undertake any obligation to update publicly or to revise any of the included forward-looking statements, whether as a result of new information, future events or otherwise, except as expressly required by law. ON THE COVER: Left: Guideway construction on the eastern section of the alignment. Upper Right: Construction at the Honolulu International Airport Station site. Lower Right: Waipahu Transit Center Station construction.
Honolulu Rail Transit Project Monthly Progress Report March 2020
3 | P a g e
Table of Contents LIST OF ACRONYMS .......................................................................................................................................................................... 4 PROJECT MAP ................................................................................................................................................................................... 9 1 SUMMARY .............................................................................................................................................................................. 10 2 OVERALL PROJECT PROGRESS AND FINANCIALS ................................................................................................................... 12
2.1 Project Progress .................................................................................................................................................... 12 2.2 Project Budget ...................................................................................................................................................... 14 2.3 Project Funding ..................................................................................................................................................... 15
3 SCHEDULE .............................................................................................................................................................................. 17 4 CONTRACT STATUS ................................................................................................................................................................ 20
4.1 System-wide .......................................................................................................................................................... 22 4.2 Section I – West O'ahu/Farrington Highway: East Kapolei to Pearl Highlands ..................................................... 33 4.3 Section II – Kamehameha Highway: Pearl Highlands to Aloha Stadium ............................................................... 45 4.4 Section III – Airport: Aloha Stadium to Middle Street Transit Center Station ...................................................... 54 4.5 Section IV – City Center: Middle Street Transit Center Station to Ala Moana Center .......................................... 57 4.6 Project-Wide ......................................................................................................................................................... 64 4.7 Contract Status by Contract Packaging Plan (CPP) Number ................................................................................. 76
5 OVERALL PROJECT-WIDE ACTIVITIES ..................................................................................................................................... 78 5.1 Overall Key Issues ................................................................................................................................................. 78 5.2 Permits .................................................................................................................................................................. 79 5.3 Hawai'i Department of Transportation (HDOT) Agreements ............................................................................... 79 5.4 Utility Agreements ................................................................................................................................................ 80 5.5 Right-of-Way ......................................................................................................................................................... 82
6 MANAGEMENT AND ADMINISTRATIVE UPDATES ................................................................................................................. 91 6.1 Safety and Security (S&S) ...................................................................................................................................... 91 6.2 Quality Management ............................................................................................................................................ 95 6.3 Buy America Compliance (49 CFR 661 and 49 CFR 663) ....................................................................................... 97 6.4 Disadvantaged Business Enterprise (DBE) ............................................................................................................ 97 6.5 Art-in-Transit (AIT) Program ................................................................................................................................. 97 6.6 Planning and Environment .................................................................................................................................... 99 6.7 Risk Management ............................................................................................................................................... 100 6.8 Construction Claims ............................................................................................................................................ 108 6.9 Community Outreach .......................................................................................................................................... 109 6.10 Staffing ................................................................................................................................................................ 109 6.11 HART Baseline Plans and Procedures Status List ................................................................................................ 111 6.12 Readiness and Activation .................................................................................................................................... 115
APPENDICES ................................................................................................................................................................................. 116 A. Project Costs by SCC – Level 2 ............................................................................................................................ 117 B. Core Accountability Items Including Major Issues .............................................................................................. 119 C. Construction Progress Interim Opening ............................................................................................................. 120 D. Project Organization Chart ................................................................................................................................. 121
Table of Figures Figure 1. Overall Project Progress (% Complete) ..................................................................................................................................... 12 Figure 2. Construction Progress (% Complete) ........................................................................................................................................ 12 Figure 3. Design Progress (% Complete) .................................................................................................................................................. 13 Figure 4. Planned vs. Received Project Funding ...................................................................................................................................... 15 Figure 5. New Starts Drawdown by Federal Fiscal Year ........................................................................................................................... 16 Figure 6. HRTP Master Project Schedule Summary (MPSS) ..................................................................................................................... 19 Figure 7. Right-of-Way Status for the Parcels .......................................................................................................................................... 83 Figure 8. Relocation Status for the Occupants ......................................................................................................................................... 83 Figure 9. Temporary Construction Easements and Utility ....................................................................................................................... 84 Figure 10. Inter-Governmental Agreement Status .................................................................................................................................. 84 Figure 11. Cost Probability Curve, March 2020 Risk Data ...................................................................................................................... 106 Figure 12. Schedule Probability Curve, March 2020 Risk Data .............................................................................................................. 107 Figure 13. Staffing Activities .................................................................................................................................................................. 110
Honolulu Rail Transit Project Monthly Progress Report March 2020
4 | P a g e
A&E Architect/Engineer AAN Accepted as Noted
AANR Accepted as noted, resubmit AC Asphalt Concrete
ACB Articulated Concrete Block ACHP Advisory Council on Historic Preservation
ACI Application Centric Infrastructure ACS Access Control System ADA Americans with Disabilities Act AFA Air Force Association AFE Authorized for Expenditure AG Attorney General
AGS Airport Guideway and Stations AIS Archaeological Inventory Survey AIT Art-in-Transit ALS Aloha Stadium Station
AMP Archaeological Monitoring Plan ANR Accepted as Noted–Resubmit APE Area of Potential Effect API Application Program Interface APS Auxiliary Power Supply
APTA American Public Transportation Association ARRA American Recovery and Reinvestment Act
ASG Airport Station Group ASI Architect Supplemental Information
ASTM American Society for Testing and Materials ASU Airport Section Utilities ATB Asphalt Treated Base ATC Automatic Train Control ATO Automatic Train Operation ATP Automatic Train Protection ATS Automatic Train Supervision AVA Anil Verma Associates, Inc. AVS Address Verification Systems
AW0 Assigned Weight, Empty Vehicle (rail car weight with no passengers) AW3 Assigned Weight, Crush Load (empty weight plus crush load of
standees) BA Buy America
BAC Buy America Compliance BACM Buy America Compliance Matrix BAFO Best and Final Offer
BANCT Best Available Noise Control Technology BAP Buy America Plan
BART Bay Area Rapid Transit BCS Balanced Cantilever System
BFMP Bus Fleet Management Plan BFS Budget and Fiscal Services BIC Ball in Court BLS Blue Light Station
BMP Best Management Practice BOC Backup Operations Center BOD Board of Directors BOH Bank of Hawaii BPS Baseline Project Schedule BUE Bottom-Up Estimate
BUEG Back-up Emergency Generator BUILD Better Utilizing Investments to Leverage Development
BWS Board of Water Supply CAD Computer-Aided Design
CAM Construction Access Milestone CAP Corrective Action Plan CAR Corrective Actions CC2 City Center Phase 2 CC3 City Center Phase 3 ccd Consecutive Calendar Days
CCGS City Center Guideway and Stations CCH City and County of Honolulu CCO Contract Change Order
CCTV Closed Circuit Television CCUG City Center Section Utilities and Guideway CCUR City Center Utilities Relocation
CDC Compendium of Design Criteria CDL Commercial Driver License
CDR Conceptual Design Review CDRL Contract Document Requirements List
CEB Civil Engineering Branch CEI Construction Engineering and Inspection CEL Certifiable Elements List
CFM Configuration Management CFMP Configuration Management Plan
CFO Chief Financial Officer CHB Car History Book CIC Communication Interface Cabinet CIL Certifiable Items List CIP Cast-in-place CJA Condon‐Johnson & Associates
CLOMR Conditional Letter of Map Revision CLR Cultural Landscape Report
CLSM Controlled Low-strength Material CM Construction Manager
CMP Construction Management Plan CMS Contract Management System CMU Concrete Masonry Unit
CNMMP Construction Noise Mitigation and Monitoring Plan CO Change Order
COI Conflict of Interest COMMs Communications CONRAC Consolidated Rental Car Facility
COO Chief Operating Officer COR Corporation Counsel
CORP Central Oahu Regional Park CP Contractor Proposed
CPC Cost Proposals by Consultant CPM Critical Path Method CPO Chief Procurement Officer CPP Contract Packaging Plan
CR Consolidated Resolution CRM Customer-Relationship Management
CRMS Customer Relational Management System CROE Construction Right-of-Entry CRRB Car Readiness Review Board
CSC Core Systems Contractor CSCC Construction Specification Conformance Checklist
CSD Department of Customer Services CSDBOM Core System Design-Build-Operate-Maintain
CSL Cross Hole Sonic Logging CSOC Core Systems Oversight Consultant CSSC Core System Support Consultant
CSSM Construction Safety and Security Manager CSSP Construction Safety & Security Plan
CST Customer Service Terminal CTP Central Test Procedure CTS Communications Transmission System CW Contract-Wide
CWA Clean Water Act CWR Continuous Welded Rail
CWRM Commission on Water Resource Management CZM Coastal Zone Management D&C Design & Construction
DAGS Department of Accounting & General Services DAV Disabled American Veterans
DB Design-Build DBB Design-Bid-Build DBE Disadvantaged Business Enterprise
DBEDT Department of Business, Economic Development and Tourism DBF Design-Build-Finance
DBFOM Design-Build-Finance-Operate-Maintain DBOM Design-Build-Operate-Maintain DCAB Disability and Communication Access Board DCCA Department of Commerce and Consumer Affairs DCCC Design Criteria Conformance Checklists DCN Design Change Notice
DD Definitive Design DDC Department of Design and Construction
DDC-MED Department of Design & Construction-Mechanical & Electrical Division
LIST OF ACRONYMS
Honolulu Rail Transit Project Monthly Progress Report March 2020
5 | P a g e
DED Deputy Executive Director DES Department of Environmental Services
DF Direct Fixation DFF Direct Fixation Fastener
DFIM Design Furnish Install Maintain DFM Department of Facility Maintenance
DHHL Department of Hawaiian Homelands DHR Department of Human Resources DIT Department of Information Technology
DKSG Dillingham and Kaka'ako Station Group DLIR Hawai'i Department of Labor and Industrial Relations
DLNR Department of Land and Natural Resources DOE Department of Education DOH Department of Health DOJ Department of Justice DOL Department of Labor DOT Department of Transportation DPM Deputy Project Managers DPP Department of Planning and Permitting DPR Department of Parks and Recreation DPS Department of Public Safety DRH D.R. Horton
DS Downstream DSDC Design Services During Construction
DTS Department of Transportation Services DTU Dillingham Temporary Utilities DUF Division of Urban Forestry DVT Design Verification Test E&E Elevators and Escalators E&O Errors and Omissions
EA Environmental Assessment EAC Estimate at Completion
EB East Bound EC Environmental Compliance
ECP Environmental Compliance Plan ED-CEO Executive Director and Chief Executive Officer
EDD Executive Decision Document E/E Elevator/Escalator EEC Elevators & Escalators Contractor
EHE-EHMP Environmental Hazard Evaluation and Environmental Hazard Management Plan
EIS Environmental Impact Statement EKP East Kapolei
EMC Electromagnetic Compatibility EMF Electromagnetic Forces EMI Electromagnetic Interference
EMP Emergency Management Panel EMR Elevator Machine Room EMT Electrical Metallic Tubing EOM End of Month EOR Engineer of Record EOS Electrically Operated Switch EPA Environmental Protection Agency EPB Emergency Push Button ERD Environmental Review Documents ESA Environmental Site Assessment ETC Estimate to Complete EV Expected Value
FAA Federal Aviation Administration FACI First Article Configuration Inspection
FAI First Article Inspection FAR Floor Area Ratios FAT Factory Acceptance Tests
FC Fare Collection FCC Federal Communications Commission FCN Field Change Notice FCU Fan Coil Units
FD Final Design FDAS Fire Detection Alarm System
FDC Field Design Change FDR Final Design Review FEIS Final Environmental Impact Statement
FEMA Federal Emergency Management Agency FFC Fixed Facility Contractor
FFGA Full Funding Grant Agreement FHB First Hawaiian Bank
FHSG Farrington Highway Station Group FHWA Federal Highway Administration
FISC Fleet and Industrial Supply Center FIT Field Integration Test
FLSWG Fire/Life-Safety Working Group FM Force Main
FMB Fasi Municipal Building FMEA Failure Modes and Effects Analysis
FMECA Failure Modes, Effects, and Criticality Analysis FO Fiber Optic
FOCN Fiber Optic Communication Network FOM Finding of Merit/No Merit
FP Fix Panel FPM Fix Panel Mono FPO Federal Preservation Officer FSC Fare Systems Contract FTA Federal Transit Administration FTE Full-Time Equivalent FUT Functional Unit Testing FWS Fish and Wildlife Service
FY Fiscal Year GAT Great Aleutian Tsunami GBS Gap Breaker Station GDR Geotechnical Data Report GEC General Engineering Consultant GER Geotechnical Engineering Report GET General Excise and Use Tax GGP General Growth Properties GIS Geographic Information System
GOE Grant of Easement GPR Ground Penetrating Radar GRP Glass Reinforced Plastic GSA General Services Administration
GT General Terms GW Guideway HA Hazard Analysis
HABS Historic American Buildings Survey HACBED Hawai‘i Alliance for Community-Based Economic Development
HAER Historic American Engineering Record HALS Historic American Landscape Survey HAR Hawai‘i Administrative Rules
HART Honolulu Authority for Rapid Transportation HCC Honolulu Community College
HCDA Hawai‘i Community Development Authority HCS Historic Context Studies
HCSD Hawai'i Capital Special District HDCC Hawaiian Dredging Construction Company HDD Horizontal Directional Drilling
HDOE Hawai'i Department of Education HDOH Hawai'i Department of Health HDOT Hawai'i Department of Transportation
HDOT-A Hawai'i Department of Transportation Airports Division HDPE High-density polyethylene HECO Hawaiian Electric Company
HEI High Energy Inc. HFD Honolulu Fire Department HHC Howard Hughes Corp HHF Historic Hawai'i Foundation
HHFDC Hawaii Housing Finance & Development Corporation HHM Hardy Heck Moore
HHPRB Hawai'i Historic Places Review Board HIA Honolulu International Airport HIE Hawaii Independent Energy
HILT Hawaiian Islands Land Trust HIOSH Hawaii Occupational Safety and Health Division
HOP Ho'opili HP Historic Preservation
HPC Historic Preservation Committee HPCA Historic Preservation Certification Application
HPCAT Historic Preservation & Cultural Awareness Training HPD Honolulu Police Department HPF Historic Preservation Fund
Honolulu Rail Transit Project Monthly Progress Report March 2020
6 | P a g e
HPL Horizon Partners Ltd. HPU Hawai‘i Pacific University HRH Hitachi Rail Honolulu Joint Venture
HRHP Hawai'i Register of Historic Places HRI Hitachi Rail Italy
HRR Heat Release Rate HRTP Honolulu Rail Transit Project HRU Hitachi Rail USA, Inc.
HSNWG Hawaiian Station Naming Working Group HSQE Health, Safety, Quality and Environment
HSSQE Health Safety Security Quality and Environment HTI Hawaiian Telcom HTL Hazard Tracking Log HV High Voltage
HVAC Heating, Ventilation and Air Conditioning I&T Inspection & Testing
IAMR Interstate Access Modification Report IBEW International Brotherhood of Electrical Workers
IC Interim Certification ICCS Integrated Communications Control System ICD Interface Control Documents ICE Independent Cost Estimate
ICM Interface Control Manual ICWG Interim Certification Working Group
IDIQ Indefinite Delivery/Indefinite Quantity IDS Intrusion Detection System IFB Issued for Bid IFC Issued for Construction
IJ Isolation Joint IMP Interface Management Plan
INMS Integrated Network Management System I/O Interim Opening
IOMP Intermediate Operations and Maintenance Period IP Implementing Procedures
IRTP Individual Role Training Plans ITP Inspection and Test Plan ITS Intelligent Transportation Systems IVR Interactive Voice Response
JTMC Joint Traffic Management Center JTMS Joint Traffic Management System JU&O Joint Use & Occupancy JUOA Joint Use and Occupancy Agreement
JV Joint Venture KCC Kapi‘olani Community College
KCDD Kaka'ako Community Development District KCH Kanehili Cultural Hui KHG Kamehameha Highway Guideway KHR Kamehameha Highway Resurfacing
KHSG Kamehameha Highway Station Group KIWC Kiewit Infrastructure West Company KKJV Kiewit/Kobayashi Joint Venture
KPI Key Performance Indicator KVM Keyboard Monitor Mouse
L+E Lea +Elliott LCC Leeward Community College LCP Local Control Panel LD Lagoon Drive
LDS Latter Day Saints LEED Leadership in Energy and Environmental Design
LF Linear Feet LOO Letter of Offer
LOTB Log of Test Borings LPR License Plate Reader LRV Light Rail Vehicle
LT Load Test LTC Load Tap Changer LV Low Voltage
LVPS Low Voltage Power Supply MAI Mason Architects MCY Makai Casting Yard MDS Mobile Data System MED Mechanical/Electrical Division MEP Mechanical, Electrical and Plumbing MIM Manufacture-Install-Maintain
MIP Manufacturing and Inspection Plans MITT Multimodal Integration Technical Team
MMIS Maintenance Management Information System MMP Mitigation Monitoring Program MOA Memorandum of Agreement MOS Minimum Operable Segment MOT Maintenance of Traffic MOU Memorandum of Understanding
MOW Maintenance of Way MPD Multiple Property Documentation MPIS Master Project Integrated Schedule MPS Master Project Schedule
MPSS Master Project Schedule Summary MPV Multiple Purpose Vehicle MPY Makai Precast Yard MS4 Municipal Separate Storm Sewer System
MSDS Material Safety Data Sheet MSE Mechanically Stabilized Earth MSF Maintenance and Storage Facility MSP Maintenance Service Plan
MSTC Middle Street Transit Center MSTCS Middle Street Transit Center Station
MTM Modern Track Machineries MV Medium Voltage
NAICS North American Industry Classification System NCE Non-Conformance Evaluation NCR Non-Conformance Report NDC Notice of Design Change
NEPA National Environmental Policy Act NFPA National Fire Protection Association NGO Non-governmental Organization NHL National Historic Landmark NOI Notice of Intent
NPDES National Pollutant Discharge Elimination System NPS National Park Service NR National Register
NRHP National Register of Historic Places NSM Negotiation Strategy Memo NTE Not to Exceed NTP Notice to Proceed NTS Network Time Server
NUC Next Unit of Computing O&M Operations and Maintenance
OCC Operations Control Center OCCC Oahu Community Correctional Center OCCL Office of Conservation and Coastal Lands OCIP Owner-Controlled Insurance Program ODC Other Direct Costs
OEQC Office of Environmental Quality Control OH Overhead
OHA Office of Hawaiian Affairs OIBC O'ahu Island Burial Council
OIC Officer-in-Charge OIL Open Items List OIP Order of Immediate Possession
OMP Operation and Management Plan OMPO Oahu Metropolitan Planning Organization
OP Oversight Procedure OR&L Oahu Railway & Land Co. ORCC Operational Readiness Conformance Checklist
OSB Operations and Servicing Building OSHA Occupational Safety and Health Administration
OSIT On-Site Inspection Test OSM Owner Supplied Materials
OTDR Optical Time Domain Reflectometer OTR One-Time Review OTS Oahu Transit Services
OTW Oceanic Time Warner OTWC Oceanic Time Warner Cable OWG Operation Working Group
P3 Public-Private Partnership PA Programmatic Agreement
PAIS Programmatic Agreement Implementation Schedule PARs Preventative Actions
Honolulu Rail Transit Project Monthly Progress Report March 2020
7 | P a g e
PAT Production Acceptance Test PB Parsons Brinckerhoff, Inc.
PCCP Portland Cement Concrete Pavement PCI Payment Card Industry
PCN Potential Change Notice PCY Precast Yard PD Position Description
PDR Preliminary Design Review PE Preliminary Engineering PF Power Frequency
PFP Project Financial Plan PGC Pacific Guardian Center PHA Preliminary Hazard Analysis
PHGTC Pearl Highlands Parking Garage and Transit Center PHL Pearl Highlands Station
PHNB Pearl Harbor Naval Base PHPR Pearl Highlands Park and Ride
PHPTR Pearl Highlands Parking Structure, Transit Center and Ramp H2R1 PHS Pearl Harbor Station
PI Public Involvement PICM Project Interface Control Manual
PID Parcel Identification Number PIG Permitted Interaction Group PIM Project Interface Manager PIP Public Involvement Plan PIS Passenger Information Systems
PLA Project Labor Agreement PLO Priority-Listed Offerors PLR Pearlridge Station PM Project Managers
PMC Project Management Consultant PMIM Project Management and Interface Management PMOC Project Management Oversight Contractor
PMP Project Management Plan PMSC Program Management Support Consultant
PNR Park-and-Ride POC Project Oversight Committee POP Period of Performance POS Point of Sales PPE Personal Protective Equipment
PRTCC Pre-revenue Testing Conform Checklist PSC Personal Services Contract PSG Platform Screen Gate
PSGS Platform Screen Gate System PSIT Pre-shipment Inspection Test PSS Public Sector Solutions PT Post-tensioned
PTG Parsons Transportation Group PUA Possession and Use Agreements PUC Public Utilities Commission PUP Property Utilization Plan
PV Passenger Vehicle QA Quality Assurance
QAM Quality Assurance Manager QAP Quality Assurance Plan
QC Quality Control QMP Quality Management Plan QMS Quality Management System QTF Quality Task Force QTO Quantity Takeoff R&A Readiness and Activation R&R Revise & Re-submit
RA Risk Assessment RAC Rail Activation Committee
RAMP Real Estate Acquisition Management Plan RAP Rail Activation Plan RAT Routine Acceptance Test
RC Reinforced Concrete RCMP Risk and Contingency Management Plan
RCP Reinforced Concrete Pipe RE Resident Engineer
READ Real Estate Acquisition Database REC Real Estate Consultant RFB Request for Bids
RFC Request for Change RFCC Request for Change from Contractor RFCR Request for Change by HART RFHB Request for High Bids
RFI Request for Information RFID Requests for Interface Data
RFMP Rail Fleet Management Plan RFP Request for Proposals RFQ Request for Qualifications RFV Request for Variance RHB Road and Highway Builders, LLC RLB Rider Levett Bucknall RLS Request for Legal Services
RMS Risk Management System RMTC R.M. Towill Corporation
RNR Revise and Resubmit ROC Rail Operations Center ROD Record of Decision ROE Right of Entry ROH Revised Ordinances of Honolulu
ROM Rough Order of Magnitude ROW Right-of-Way
RP Recovery Plan RR Risk Register
RSD Revenue Service Date RST Retail Sales Device Training RTE Request to Exceed Negotiation Strategy Memo Target
RTM Requirements Traceability Matrix RTSA Regional Transit Stabilization Agreement
S&S Safety and Security S1 Segment 1
SAIS Supplemental Archaeological Inventory Survey SAV Shared Autonomous Vehicle
SC Substantial Completion SCADA Supervisory Control and Data Acquisition
SCAP Stream Channel Alteration Permit SCC Standard Cost Category SCH Satellite City Hall
SHPD State Historic Preservation Division SHPO State Historic Preservation Officer
SIC Sandwich Isle Communications SIRP Safety Incident Review Panel
SIT System Integration Testing SITP System Integration and Test Plan SITR Site Inspection and Test Report
SL Street Light SLAN Secured Local Area Network
SLR Sea Level Rise SM Service Manager
SMA Special Management Area SMS Structural Monitoring Solutions SOG Slab on Grade SOI Secretary of the Interior
SON Summary of Negotiations SOP Standard Operating Procedures
SOW Scope of Work SP Special Provisions
SQP Supplemental Quality Plan SS System Site
SSC Safety Security Certification SSCP Safety and Security Certification Plan
SSCWG Safety and Security Certification Working Group SSI Sensitive Security Information
SSMP Safety and Security Management Plan SSRC Safety and Security Review Committee SSSP Site Safety Security Plan
STATCOM Static Synchronous Compensator STCC Specification Testing Conformance Checklists STG Shimmick/Traylor/Granite, Joint Venture STP System Test Procedure
SUBD Subdivision Branch SUE Subsurface Utility Engineering
SuMo Sustainable Mobility SuMoLab Sustainable Mobility Lab
Honolulu Rail Transit Project Monthly Progress Report March 2020
8 | P a g e
SWPPP Storm Water Pollution Prevention Plan SwRI Southwest Research Institute T&M Time and Material TAC Transit Art Committee TAP Track Allocation Procedure TAT Transient Accommodation Tax
TC Train Control TCA Temporary Configuration Change
TCCR Train Control and Communications Room TCE Temporary Construction Easement TCO Temporary Certificate Occupancy TCP Traffic Control Plan TCS Train Control System
TDFM Travel Demand Forecasting Model TDM Transportation Demand Management
TES Traction Electrification System TIA Time Impact Analysis
TIGER Transportation Investment Generating Economic Recovery TIP Transportation Improvement Program
TMK Tax Map Key TMP Traffic Management Plan
TO Task Order TOC The Outdoor Circle TOD Transit-Oriented Development
TP Technical Provision TP&R Temporary Park & Ride
TPBuGen Traction Power Backup Generator TPO Thermoplastic Polyolefin
TPSS Traction Power Substation TS Traffic Signal
TSA Transportation Security Administration TSI Transportation Safety Institute
TTSP Temporary Traffic Signal Plan TUT Temporary Utility Take TVA Threat and Vulnerability Assessment
TVM Ticket Vending Machine TWF Train Wash Facility UCA Utility Construction Agreement
UFRCRA Utility Facilities Relocation and Cost Reimbursement Agreement UG Underground UH University of Hawai'i
UHPRB UH West O‘ahu Park and Ride & UHWO Campus Road “B” UHWO University of Hawai'i West O'ahu
UL Underwriters Laboratories UPS Uninterruptible Power Supply URA Uniform Relocation Assistance and Real Property Acquisition
Policies Act USACE U.S. Army Corps of Engineers USDOE U.S. Department of Energy USDOL United States Department of Labor USDOT U.S. Department of Transportation
USN United States Navy USPS U.S. Postal Service
UST Underground Storage Tank UTR Under Technical Review VAR Volt-Ampere Reactive VCR Vertical Conduit Raceway
VE Value Engineering VECP Value Engineering Change Proposal
VISTA Volunteers in Service to America VMS Variable Message Sign VRC Vertical Raceway Column
VRCS Voice Radio Communication System VRF Variable Refrigerant Flow VTP Vehicle Test Procedure WA Work Area
WCS Wireless Communication System WHS Waipahu High School
WKM Walters, Kimoda, Motoda, Inc. WL West Loch
WLO West Loch WOEDA West Oahu Economic Development Association
WOFH West O'ahu/Farrington Highway WOSG West O'ahu Station Group
WQC Water Quality Certification WSS West Side Stations
WSSG West Side Stations Groups WTB Wheel Truing Building WTC Waipahu Transit Center WTP Wayside Test Procedure
WWB Wastewater Branch WWPS Wastewater pump station
WYL West Yard Lead YCB Yard Control Bungalow YKE Yogi Kwong Engineers YOE Year of Expenditure
Honolulu Rail Transit Project Monthly Progress Report March 2020
9 | P a g e
Rail Stations Kualaka‘i Station at East Kapolei Keone‘ae Station at UH West O‘ahu Honouliuli Station at Ho‘opili Hō‘ae‘ae Station at West Loch Pouhala Station at Waipahu Transit Center Hālaulani Station at Leeward Community College Waiawa Station at Pearl Highlands Kalauao Station at Pearlridge Hālawa Station at Aloha Stadium Makalapa Station at Pearl Harbor Naval Base Lelepaua Station at Honolulu International Airport Āhua Station at Lagoon Drive Kahauiki Station at Middle Street Transit Center Mokauea Station at Kalihi Niuhelewai Station at Kapalama Kūwili Station at Iwilei Hōlau Station at Chinatown Kuloloia Station at Downtown Ka‘ākaukukui Station at Civic Center Kūkuluae‘o Station at Kaka‘ako Kālia Station at Ala Moana Center
PROJECT MAP
Honolulu Rail Transit Project Monthly Progress Report March 2020
10 | P a g e
1 SUMMARY
REPORTING DATE AND SUBSEQUENT EVENTS This report was published on April 30, 2020, for the PMOC meeting scheduled for May 13, 2020. Data is presented with a reporting cutoff
date of March 31, 2020, unless otherwise noted.
KEY ACTIVITIES IN MARCH Project Overview The Honolulu Authority for Rapid Transportation (HART) has obtained the necessary permits to set up and establish controlled lanes on Dillingham Boulevard, which allows us to accelerate utility relocations work under the City Center Utilities Relocation (CCUR) program. Traffic along Dillingham Boulevard in Section 1A (Middle Street to Mokauea Street) will be restricted to one lane in each direction 24 hours a day, seven days a week, and is expected to remain in place for the next several months. The construction work includes relocation of numerous above-ground and underground utilities to clear a path for the elevated guideway and support columns. The roadway itself will eventually be widened. Controlled access is planned for the rest of Dillingham Boulevard up to Kaaahi Street in two additional phases over the next few months.
The fifth train that will be a part of HART’s interim opening fleet arrived at the Rail Operations Center (ROC) in Waipahu at the end of March. A total of six trains will be a part of HART’s interim opening fleet.
Public-Private Partnership (P3) Due to the COVID-19 situation, the offerors for the City Center Guideway and Stations/Pearl Highlands Design-Build-Finance-Operate-Maintain (DBFOM) P3 have requested additional time to prepare their proposals. The due date for the technical proposals has been extended to July 2020, and the Notice to Proceed date has moved to September 2020.
COST (as of March 31, 2020)
Project Cost Summary ($ in millions)
Description Original FFGA
Budget Recovery Plan
Budget* Current Estimate at Completion (EAC)*
Incurred To Date
Project Capital Costs
Base Cost without Contingency $4,305 $7,312 $7,413 $4,140
Allocated Contingency $542 $765 $664 $0
Unallocated Contingency $102 $222 $88 $0
Total Project Capital Costs $4,949 $8,299 $8,165 $4,140
FFGA Finance Charges $173 $609 $547 $34
Total FFGA Project Costs $5,122 $8,908 $8,712 $4,174
Post-RSD Finance Charges $42 $231 $293 $0
Total Project Costs $5,164 $9,139 $9,005 $4,174
*Total Project Costs excludes Operations and Maintenance.
Original FFGA Budget The Original FFGA Budget reflects the full build-out of the project as executed by the Full Funding Grant Agreement in December 2012.
The contingency is a reserve to cover known and unknown, but anticipated, project execution costs and uncertainty due to risk factors such as unresolved design issues, unknown site conditions, schedule impacts and market fluctuations. The Original FFGA Budget reflects $644 million in total contingency.
Recovery Plan Budget Total The approved Recovery Plan Project capital cost estimate is $8,299 million (excluding finance costs). The total project cost is $9,139 million, which includes post-Revenue Service Date (RSD) financing costs of $231 million and $8,908 million in FFGA project costs (which includes $765 million in allocated contingency, $222 million in unallocated contingency, and $609 million in financing costs). While this cost is $134 million greater than HART’s cost estimate of $8,165 million, HART has revised the Project cost estimate and identified the additional funding to meet the higher estimate.
Honolulu Rail Transit Project Monthly Progress Report March 2020
11 | P a g e
The Recovery Plan Budget reflects $987 million of total contingency or 13% of the base cost estimate which reflects available funding capacity. Based on FTA requirements on contingency for the current phase of the project, the 13% is sufficient reserve to cover against the risk of cost increases during development of the project.
Current Estimate at Completion (EAC) The current project capital Estimate at Completion (EAC) is $8,712 million, including $752 million in total contingency ($664 million in allocated contingency and $88 million in unallocated contingency) and $547 million in financing costs. The total project costs including post-Revenue Service Date (RSD) financing costs of $293 million is $9,005 million.
The total project contingency is based on a December 2025 RSD.
Incurred to Date The Incurred-to-date costs are cumulative through March 2020, and exclude third-party reimbursement costs. The $4,174 million to date represents 56% of the base Current EAC. The Incurred-to-date costs increased by $77 million for the period.
SCHEDULE The progress reported in the table below provides percent complete based on construction and design contracts. The early and late plans are based on baseline schedules for active contracts and forecasts of future contracts.
Project Progress* Through March 27, 2020
Actual Early Plan Late Plan
Overall Project Progress 56.6% 67.3% 60.6%
Construction Progress 52.1% 63.4% 57.5%
Design Progress 80.3% 80.4% 77.3%
*Reported percentages complete are based on the Estimate at Completion for the
Minimum Operable Segment (MOS) and December 2025 Revenue Service Date (RSD).
PROGRESS REPORT SUMMARY OF CHANGES The following is a brief summary of major changes that have occurred from the previous month’s report. For more information and detail, please refer to the respective pages in the report.
Contract Status West O‘ahu/Farrington Highway Guideway (WOFH)
o Contract closeout reconciliation resulted in a lower incurred-to-date amount. Please see page 33.
Kamehameha Highway Guideway (KHG) o Contract closeout reconciliation resulted in a lower incurred-to-date amount. Please see page 45.
Kamehameha Highway Station Group (KHSG) o The projected completion of work date has changed from May 2020 to July 2020. Please see page 47. o The schedule status has changed from “1 month behind” to “3 months behind.” Please see page 47.
Kamehameha Highway Resurfacing (KHR) o The projected completion of work date has changed from March 2020 to April 2020. Please see page 50. o The schedule status has changed from “6 months behind” to “7 months behind.” Please see page 50.
Airport Section Guideway and Stations (AGS) o The current contract value amount has increased due to a change order. Please see page 54.
City Center Utilities Relocation (CCUR) Indefinite Delivery/Indefinite Quantity (IDIQ) o The Physical % Complete has changed from “TBD” to 7.5%. The % complete is for work in place and does not
include eliminated scope. HART is currently reviewing the EAC submitted by CEI in March for all the work required prior to the P3 contractor commencing their work; budget and percent complete are subject to change. Please see page 59.
For all professional services contracts, the Incurred-to-Date amounts, as well as the percentages and monthly actuals in the performance curves have been updated. They are now based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS.
Honolulu Rail Transit Project Monthly Progress Report March 2020
12 | P a g e
2 OVERALL PROJECT PROGRESS AND FINANCIALS
2.1 Project Progress (data as of March 27, 2020) Reported percentages complete are based on the Estimate at Completion for the MOS and December 2025 RSD. HART will revise its progress curves further when the in-process change orders are executed. This revision is expected to lower the plan values. Note:
Actual = Actual cost of work performed, based on reported work-in-place.
Early Plan = Earliest dates activities can begin and finish, based on logic and durations used in the schedule.
Late Plan = Latest dates activities can begin and finish and not have an impact on completion date, based on logic and durations used in the schedule.
Figure 1. Overall Project Progress (% Complete)
At present "overall" project progress is based on the weighted value progress of the individual construction and design contracts (Design-Build [DB], Design-Bid-Build [DBB], Design-Build-Operate-Maintain [DBOM], Elevator/Escalator Manufacture-Install-Test-Maintain [MIM], Final Design [FD] and DB-DBOM design levels of effort), not including City or non-design consultant labor.
Figure 2. Construction Progress (% Complete)
Overall construction progress is based on the weighted average progress of the individual DBB and E/E MIM construction contracts and the DB-DBOM construction levels of effort, not including consultant Construction Engineering and Inspection (CEI) services.
Honolulu Rail Transit Project Monthly Progress Report March 2020
13 | P a g e
Figure 3. Design Progress (% Complete)
Overall design progress is based on the weighted average progress of the individual FD contracts and the design levels of effort of the DB and DBOM construction contracts, not including City or non-design consultant labor.
Honolulu Rail Transit Project Monthly Progress Report March 2020
14 | P a g e
2.2 Project Budget (data as of March 31, 2020)
Project Cost Summary ($ in millions)
Description Original FFGA
Budget Recovery Plan
Budget* Current Estimate at Completion (EAC)*
Project Capital Costs
Base Cost without Contingency $4,305 $7,312 $7,413
Allocated Contingency $542 $765 $664
Unallocated Contingency $102 $222 $88
Total Project Capital Costs $4,949 $8,299 $8,165
FFGA Finance Charges $173 $609 $547
Total FFGA Project Costs $5,122 $8,908 $8,712
Post-RSD Finance Charges $42 $231 $293
Total Project Costs $5,164 $9,139 $9,005
*Total Project Costs excludes Operations and Maintenance.
The Original FFGA Budget reflects the full build-out of the project as executed by the Full Funding Grant Agreement in December 2012. The approved Recovery Plan Project capital cost estimate is $8,299 million (excluding finance costs). While this cost is $134 million greater than HART’s cost estimate of $8,165 million, HART has revised the Project cost estimate and identified the additional funding to meet the higher estimate. Total project contingency decreased to $752 million ($664 million in allocated contingency and $88 million in unallocated contingency) since last updated.
Contingency Drawdown Curve
Date Sep-2020 Dec-2020 Sep-2022 Mar-2023 Dec-2024 Dec-2025
Milestone P3 NTP Interim
Opening
DBB511 Construction
Complete
DB450 Construction
Complete
P3 Construction
Complete RSD
FTA Minimum Level ($M)
638
592
405
370
215
134
HART Minimum Level ($M)
504
458
271
236
131
85
Honolulu Rail Transit Project Monthly Progress Report March 2020
15 | P a g e
2.3 Project Funding
Figure 4. Planned vs. Received Project Funding
Planned vs. Received Project Funding
Funding Source
Pre-FFGA Project1
Project Funding Total
Project
2007 - 2009 Actuals
Received
Planned2 2009 -
Present Actuals
Received
2007 - Present Actuals
Received
Actuals Received in Mar 2020 ($YOE M)
Beginning Project Cash Balance3 - 298 298 - -
Interest Income on Cash Balance5 7 1 9 16 0
FTA Section 5309 New Starts Revenue4 - 1,550 806 806 -
ARRA Funds - 4 4 4 -
EPA Brownfields Grant (FY2018-FY2021)6 - 1 0 0 -
Net General Excise Tax (GET) Surcharge revenues FY2010-FY2031 378 5,990 2,292 2,670
-
Transient Accommodation Tax (TAT) revenue FY2018-FY2031 - 1,182 98 98
-
City Subsidy - HART Administration FY2018-FY2031 - 214 69 69
25
Total 385 9,240 3,576 3,663 25
1 GET and Interest Income received during Pre-Preliminary Engineering (pre-PE) phase prior to entry into PE. 2 Updated to Chapter 6 - Project Finance, Figure 6-2 of HART's Approved Recovery Plan (for beginning cash balance, GET, TAT, grant revenue, city subsidy and interest income).
3 Beginning Project Cash Balance at Entry into Preliminary Engineering (PE) on October 16, 2009 (the FFGA Project start date) = Pre-PE GET, investment and miscellaneous income minus pre-PE expenditures. The $298 million is included in the Pre-FFGA actual amounts received between 2007-2009 of $378 million.
4 New Starts Funds Obligated Through Federal Fiscal Year 2014 Totals $806.3 million. 5 Interest Income received in March 2020 - $179,025.61
6 EPA $900,000 Brownfields Grant must be used by 12/31/2020 - to plan and subsidize the environmental cleanup activities.
EPA Brownfields Grant revenue received to date - $55,260.87
Honolulu Rail Transit Project Monthly Progress Report March 2020
16 | P a g e
Figure 5. New Starts Drawdown by Federal Fiscal Year
New Starts Grant Information by Federal Fiscal Year (Amounts in Italics are Pending)
Federal Fiscal Year (FFY) Allocation
FTA Obligated Amounts
Actual Drawdown Amounts to Date
Available Balance FFGA Base Case Cash Flow
2008 $15,190,000 $15,190,000 $0
2009 $19,800,000 $19,800,000 $0
2010 $30,000,000 $30,000,000 $0
2011 $55,000,000 $55,000,000 $0 $20,607,242
2012 $200,000,000 $200,000,000 $0 $99,382,758
2013 $236,277,358 $236,277,358 $0 $258,280,277
2014 $250,000,000 $249,991,376 $8,624 $441,719,724
2015* $250,000,000 $0 $0 $0
2016* $250,000,000 $0 $0 $0
2017* $243,732,642 $0 $0 $0
2018 $0 $0 $0 $0
2019 $0 $0 $0 $0
2020 $0 $0 $100,000,000 $100,000,000
2021 $0 $0 $150,000,000 $150,000,000
2022 $0 $0 $150,000,000 $150,000,000
2023 $0 $0 $150,000,000 $150,000,000
2024 $0 $0 $100,000,000 $100,000,000
2025 $0 $0 $50,000,000 $50,000,000
2026 $0 $0 $43,732,642 $30,010,000
Total $1,550,000,000 $806,258,734 $743,741,266 $1,550,000,000 *These years' awards have not been available for drawdown. The availability of dollars are expected to follow the approved HART Recovery Plan and are reflected in the Available Balance column.
Honolulu Rail Transit Project Monthly Progress Report March 2020
17 | P a g e
3 SCHEDULE (data as of March 27, 2020)
Critical Path Analysis Interim Revenue Service Date is planned for no later than December 2020. The Projected Revenue Service date, currently
forecasted for Oct. 20, 2020, defines operational readiness of the system. The Department of Transportation Services (DTS) makes the final determination of passenger service.
o There are four concurrent critical paths for Operational Readiness of the passenger rail system from East Kapolei Station to Aloha Stadium Station: Operational Readiness at the Maintenance and Storage Facility (MSF), communication systems installation at University of Hawai‘i (UH) West O‘ahu Station, the Supervisory Control and Data Acquisition (SCADA) installation at Pearlridge Station, and canopy, canopy cables and SCADA installation at Aloha Stadium Station. These four concurrent paths are then followed by the Core Systems testing activities into final certification.
o For the near critical path, activities include communication systems and canopy cable installations at East Kapolei Station.
Revenue Service Date (RSD) is planned for no later than December 2025 (Projected Revenue Service date defines operational readiness of the system. DTS makes the final determination of passenger service).
o The critical path begins with Right of Way acquisition of a property required for utility work (AT&T, Hawaiian Electric Company [HECO] 46kV, Hawaiian Telcom, Oceanic Time Warner Cable) in City Center Utilities Relocation (CCUR) Area 1C. After the utility relocation is complete, drilled shafts, columns and segments for Area 1C continue into platform and structure construction for Kapalama Station, followed by Core System installation and testing.
o The near critical path shifted to procurement of the Public-Private Partnership (P3)/City Center Guideway and Stations (CCGS) contract followed by drilled shafts, columns and segments in Area 3, and Chinatown Station construction. The P3 procurement schedule has been extended three months due to the bidder’s request around the international pandemic.
Three-Month Look Ahead Station construction for the west station groups continues to include the following:
o Canopies: The Aloha Stadium canopy arms are scheduled to be completed in May 2020. The tension fabric is forecasted to be in late June 2020 and conduit installations are targeted for completion in July 2020. These activities are on the critical path for Kamehameha Highway Station Group substantial completion.
o University of Hawai‘i West O‘ahu (UHWO) Temporary Park and Ride (“Road B”): A walkthrough is being scheduled with the Core Systems Contractor (CSC), Landscape Engineer, and Engineer of Record (EOR) for final acceptance.
o Elevators and Escalators: Complete installation of Pearlridge Station Elevators #1 and 2. Complete installation of Aloha Stadium Station Escalators #1 and 2. Continue installation of Aloha Stadium Elevators #1 and 2 and Pearl Highlands Elevators #1 and 2. Continue to perform commissioning activities in preparation for State elevator inspections. Continue construction interface for Airport Guideway and Stations (AGS).
CSC o Comms Cable Pull at Waipahu, Leeward Community College (LCC), UH West O‘ahu, East Kapolei, Pearl Highlands,
Pearlridge and Aloha Stadium Stations; ongoing through May 2020. As each station completes Comms Cable Pull, connections will be made, and the Comms equipment will
be installed and tested; April 2020 through May 2020. o Re-submission of required Comms Design submittals and Comms test procedures for MSF official testing. o Continue MSF Comm System punchlist by late April 2020. o Continue Passenger Vehicle (PV) #1 Braking Dynamic Test and PV#3 System Static Test. o Delivery of PV #13 in April 2020 and PV #14 in June 2020. o Continue Wayside Test Procedure (WTP) testing at Waipahu, LCC and Pearl Highlands Stations. o Complete PV #4 Dynamic Routine Acceptance Test (RAT) Testing. o Complete Platform Screen Gate (PSG) On-Site Inspection Test (OSIT) at West Loch Station.
AGS o Reach A: Complete utility relocations. Continue center median installation on Kamehameha Highway from Pier 423 to
426. Complete concrete pad system for System Site #25 and set Traction Power Substation (TPSS) building. Continue installation of the sidewalk, curb and gutter at Halawa Drive and Kamehameha Highway.
o Reach B: Complete wet utility relocations. Continue column and pier cap work. Continue span erection. o Reach C: Complete underground utility relocations for street lights, water and drainage to clear Shafts 551L to 557.
Continue span erection.
Honolulu Rail Transit Project Monthly Progress Report March 2020
18 | P a g e
o Reach D: Complete HECO Zone 8 work. Continue infrastructure for Hawaiian Telcom (HTI) and Oceanic Time Warner Cable (OTWC) communication utilities relocations on Ualena Street with the implementation of nightly Maintenance of Traffic (MOT). Infrastructure work for service reconnections on private property is ongoing.
o Reach E: Continue column rebar erection and framework. Assembly of Gantry 3 continues at Ke’ehi Lagoon Park; anticipated segment operation for 603 to begin May 4, 2020.
o Pearl Harbor Station (Makalapa): Receive station structural steel and start erection. Continue wet utility trenching along Kamehameha Highway. Platform girder reinforcing steel installation to begin in April 2020.
o Honolulu International Airport Station (Lelepaua): Pour Hammerhead 542 and remove all Hammerhead formwork and falsework. Install HECO new service infrastructure for Honolulu International Airport (HIA) Station and System Site (SS) #27. Complete formwork and installation of reinforcement for elevator pit wall 1-3 and for grade beams at elevators 4-5.
o Lagoon Drive Station (Āhua): Complete underground site utilities. Complete station structural steel erection. Complete TCCR building construction.
o Middle Street Transit Center Station (Kahauiki): Complete station shaft work. Complete pedestrian bridge drill shaft. Form and pour elevator pit walls. Construct platform support piers C1 and C2 in Kalihi Stream.
CCUR o Finalize design and receive permits for wet utility task orders 09 and 16. o Finalize design and receive permits for dry utility task orders 17, 24, 27, 28 and 32. o Finalize the Kapalama Bridge design and begin bridge fabrication. o Complete critical Area 1B drainage box culvert modifications. o Commence Area 1B and 1C Controlled Access. o Complete wet utility locations in Area 2. o Start Area 2 Dry Infrastructure (12 kV).
CCGS o Technical and price submittal.
Key Schedule Issues AGS’ Shimmick/Traylor/Granite, Joint Venture (STG) current January schedule update puts Substantial Completion at March
14, 2023. This update was rejected and an acceptable mitigation schedule is being analyzed.
The contractor provided an updated, detailed station construction schedule for Pearl Harbor, Airport, Lagoon Drive and Middle Street Stations for HART’s review on Jan. 29, 2020. HART reviewed the detailed station activities and provided comments in early February 2020. On March 10, 2020, the contractor provided another over the shoulder update of the schedule with Jan. 30, 2020 data date. HART and Construction Engineering and Inspection (CEI) reviewed this schedule and made further comments.
The AGS contractor submitted a Time Impact Analysis (TIA) schedule in October, requesting a schedule extension and time-related overhead costs. CEI and HART are reviewing the TIA schedule.
Schedule Contingency Drawdown Curve
The critical path begins with Right of Way acquisition of a property required for utility work (AT&T, HECO 46kV, Hawaiian Telcom, Oceanic Time Warner Cable) in CCUR Area 1C. After the utility relocation is complete, drilled shafts, columns and segments for Area 1C continue into platform and structure construction for Kapalama Station, followed by Core Systems installation and component testing and Full System Integration Testing, Trial Run and Pre-Revenue Service Demonstration achieving full Revenue Service Date. The assumed CCGS schedule has not been revised. Secondary mitigation is being explored and will be implemented.
Honolulu Rail Transit Project Monthly Progress Report March 2020
19 | P a g e
Figure 6. HRTP Master Project Schedule Summary (MPSS) The Master Program Summary Schedule reflects currently approved schedule end dates for contracts that have been awarded, and planned dates for future contracts.
Honolulu Rail Transit Project Monthly Progress Report March 2020
20 | P a g e
4 CONTRACT STATUS
Contracts in Procurement
Overview Awarded Contracts:
o The HDOT Design Review Support (WOFH) Contract was awarded on March 6, 2020 to AECOM Technical Services, Inc.
Active Procurements: o City Center Guideway and Stations / Pearl Highlands Design-Build Finance Operate and Maintain Request
for Proposals (RFP) qualifications proposals in response to RFP Part 1 were received on April 12, 2019. HART released RFP Part 2 to the priority list of offerors on May 3, 2019. Due to recent COVID-19 events, the offerors requested additional time to prepare their proposals; the due date for the technical proposals has been extended to July 2020. As such, the Notice to Proceed (NTP) date has moved to September 2020.
o Art-in-Transit: HART continues its negotiations with the highest-ranked artists for each of the stations. To date, twelve (12) contracts have been awarded.
o HDOT/DTS Traffic Management Coordination Request for Qualifications was issued on Jan. 17, 2020. Statements of Qualification submissions were received on Feb. 19, 2020 and are currently being evaluated.
o Outside Claims Counsel Request for Sealed Proposals was issued on Jan. 14, 2020 as a multi-award solicitation to avoid potential conflicts of interest. Due to limited participation, the solicitation was cancelled. HART will conduct market outreach and will re-solicit the project.
o Passenger WiFi System Request for Sealed Bids was issued on Jan. 17, 2020. Addendum No. 2 issued on Feb. 11, 2020 extended the solicitation timetable. Sealed bids were due on March 3, 2020 and are currently under review.
o Archaeological & Cultural Monitoring “II” Request for Sealed Proposals was issued on March 9, 2020. Sealed proposals are planned to be received on April 9, 2020 and will then be evaluated.
Active Procurements
Contract Code
Contract Name Advertise
Date
Bids or Proposals
Due Issue NTP
Projected Contract
Substantial Completion
Date
AP-00 Art-in-Transit May 09 '13
12 contracts awarded;
active procurement for remaining
stations
Staggered Staggered
DB-550 City Center Guideway and Stations / Pearl Highlands Design-Build Finance Operate And Maintain (DBFOM)
Sep 28 ‘18 Apr 12 ‘19 (RFP Pt. 1)
Sep ‘20 TBD
MM-915 HDOT/DTS Traffic Management Coordination
Jan 17 ‘20 Feb 19 ‘20 May ‘20 TBD
MM-980 Outside Claims Counsel Jan 14 ‘20 Feb 14 ‘20 Cancelled Cancelled
DBOM-920 Passenger WiFi System Jan 17 ‘20 Mar 3 ‘20 Apr ‘20 TBD
MM-960 Archaeological & Cultural Monitoring “II”
Mar 9 ‘20 Apr 9 ‘20 TBD TBD
Honolulu Rail Transit Project Monthly Progress Report March 2020
21 | P a g e
New awards/ contracts/NTP issued
Contract Code
Contract Name Advertise
Date Due Date Contractor
Award
Issue NTP Term/Substantial
Completion Award Amount Contract
Date
MM-920 HDOT Design Review Support (WOFH)
Oct 11 ‘19 Nov 1 ’19 AECOM
Technical Services, Inc.
Mar 6 ‘20
Mar 27 ‘20
Mar 27 ‘21 $300,000
Upcoming Procurement Under Evaluation
Contract Code Contract Name Issue Date
Procurement Duration
Proposal Due Date Award
DBB-511 City Center Utility Relocation II May ‘20 2 Months Jul ‘20 Jul ‘20
TBD Real Estate Consultant (REC) III Apr ‘20 1 Month May ‘20 Jun ‘20
TBD Guideway Bridge Inspection Apr ‘20 1 Month May ‘20 Jun ‘20
TBD Fare Collection System Redundant Fiber Connection Service
Apr ‘20 1 Month May ‘20 Jun ‘20
MM-980 Outside Claims Counsel Apr ‘20 1 Month May ‘20 Jun ‘20
HRT-201 Research and Marketing Services for Public Involvement Program
Apr ‘20 1 Month May ‘20 Jun ‘20
TBD Independent Financial Auditor III Apr ‘20 1 Month May ‘20 Jun ‘20
Honolulu Rail Transit Project Monthly Progress Report March 2020
22 | P a g e
4.1 System-wide
A. Core Systems Contract (CSC) CPP No.: DBOM-920 DBOM Contractor: Hitachi Rail Honolulu Joint Venture (HRH) Contract Start Date: January 2012 Contract Substantial Completion: January 1, 2025 Projected Completion of Work: July 2025
Project Description: A design, build, operate and maintain contract to provide rail passenger vehicles, automated train control system, traction electrification system (TES), communication systems, passenger platform screen gates (PSGs), and operation and maintenance of the Core Systems.
Design & Construction Vehicles Schedule Status
Physical % Complete 67.4% 73.6% On time for 2025
opening Early Plan* 85.1% 96.1%
Late Plan* 66.2% 58.8% *Data as of March 27, 2020. The progress chart reflects early program expectations. Progress is being tracked against interim Construction Access Milestone dates, which show the project is "On-Time".
________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$419,568
DBE % Attained: 0.054%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $209,736,373
None N/A ---
Cumulative Current Report $209,736,373
Original Contract: $573,782,793 Incurred-to-Date: $418,468,833
Current Contract Value¹: $783,519,166 Incurred in March: $5,077,283
Outstanding Issues: 3 Contractor CP Amount: $1,009,097
1Current Contract Value = Original contract value (excluding original O&M budget) + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
23 | P a g e
KEY INDICATORS FOR 2020 INTERIM OPENING 1:
Feb 2020 Mar 2020 Apr 2020
• Completion of Mobile Data System (MDS) network in Functional Section (Ho‘opili [HOP] to Leeward Community College [LCC]): 10% Complete
• Completion of MDS network to East Kapolei (EKP): Installation in progress
• Start of Train Testing to Aloha Stadium Station (ALS) (Central Test Procedure [CTP]/Vehicle Test Procedure [VTP]/System Test Procedure [STP])
• Start of System Integration Testing in the Functional Section
• Completion of MDS network to ALS station
• Energization of 3rd Rail to Pearlridge Station (PLR) (LCC Gap Breaker Station [GBS] + Pearl Highlands Station [PHL] Traction Power Substation [TPSS]): Completed
• Completion of Secured Local Area Network (SLAN) network to LCC GBS: Completed
• Completion of SLAN network to PHL TPSS: Completed
• Completion of LCC Supervisory Control and Data Acquisition (SCADA) TPSS: Completed
• Completion of PHL SCADA TPSS: Completed
• Completion of PHL Uninterruptible Power Supply (UPS): 10% Complete
• Energization of 3rd Rail to ALS (PLR TPSS + ALS TPSS): 70% Complete
• Completion of SLAN network to PLR TPSS: Awaiting replacement CIC cabinet
• Completion of SLAN network to ALS TPSS
• Completion of PLR SCADA TPSS
• Completion of ALS SCADA TPSS
• Completion of University of Hawai‘i West O‘ahu (UHWO) UPS: Completed
• Completion of PLR UPS: Testing to be done remotely, with on-site support starting 4/7.
• Completion of ALS UPS: Completed
• Completion of PHL Automatic Train Control (ATC) Wayside Test Procedure (WTP): Completed
• Completion of West Yard Lead (WYL) Platform Screen Gate System (PSGS): 70% Complete
• Completion of LCC PSGS: 40% Complete
• Completion of PLR ATC WTP: Completed
• Completion of ALS ATC WTP: 40% Complete
• Completion of EKP PSGS: Installation in progress
• Completion of UHWO PSGS: Installation in progress
• Completion of PHL PSGS • Completion of PLR PSGS
Honolulu Rail Transit Project Monthly Progress Report March 2020
24 | P a g e
Feb 2020 Mar 2020 Apr 2020
• Train #12 Completion of onboard ATC: Completed
• Train #12 Completion of onboard COM: 60% Complete
• Train # 10 Interim Certified for Dynamic Testing & Dynamic Test Completed: Completed
• Arrival of Train #9: Completed
• Train #10 Completion of onboard ATC and onboard COM: 80% Complete
• Train # 11 Interim Certified for Dynamic Testing & Dynamic Test Completed: Completed
• Arrival of Train #8: Completed
• Train #11 Completion of onboard ATC and onboard COM
• Train # 9 Interim Certified for Dynamic Testing & Dynamic Test Completed
• Arrival of Train #13
• Completion of EKP Fire Detection Alarm System (FDAS): Completed
• Completion of WLO FDAS: Installation in progress
• Completion of WYL FDAS • Completion of LCC FDAS
• Completion of Communications (COMM) Closed Circuit Television (CCTV) at HOP: 30% Complete
• Completion of COMM Passenger Information Systems (PIS) at HOP: 30% Complete
• Completion of COMM Access Control System (ACS)-Intrusion Detection System (IDS) at HOP: 15% Complete
• Completion of COMM at MSF: 60% Complete
• Completion of COMM CCTV/PIS/ACS-IDS at WLO/WYL: Installation in progress
• Completion of UHWO UPS: Completed
• Completion of COMM CCTV/PIS/ACS-IDS at LCC: Installation in progress
• Completion of COMM CCTV/PIS/ACS-IDS at EKP
• Completion of Station SCADA HOP: Awaiting cables
• Completion of Station SCADA WLO/WYL: Awaiting cables
• Completion of Station SCADA LCC/EKP: Awaiting cables
________________________________________________________________________________________________________________________________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: Design: Review of design submittals is ongoing. Focus is to close
out communications, passenger vehicles and Requirements Traceability Matrix (RTM) issues.
Continued coordination between HRH and the AGS contractor for integration of Core Systems requirements.
Manufacturing: Hitachi Rail USA, Inc. (HRU) is continuing with the
production of Trains #7 and #13 through #15 in Pittsburg, CA.
Train #8 was delivered to the MSF on March 27. This is the fifth train of the interim opening fleet.
Look Ahead: Design: Close out of open comments to finalize Final
Design of all subsystems. Continue coordination between HRH and
FHSG/KHSG/AGS. Complete Communications Final Design.
Manufacturing: Passenger Vehicle truck fabrication – continue
truck frame and bolster delivery from Italy.
Honolulu Rail Transit Project Monthly Progress Report March 2020
25 | P a g e
Activities this Month (continued): Testing of ventilation hole retrofit continues on Train #3.
Installation, Testing and Commissioning: HRH completed PHL TPSS testing with SCADA in the
Operations Control Center (OCC). Open items include Blue Light Station (BLS) and Transfer Trip.
HRH conducted loop resistance testing of PLR and ALS TPSS. Issues were found.
HRH energized incoming Medium Voltage (MV) breakers in PLR and ALS with HECO incoming power.
HRH started the UPS commissioning in PHL station. HRH continues with electrical installation of PSGS in EKP
and UHWO station. HRH started PSGS functional testing at Waipahu stations. HRH completed the preparation of PSGS mechanical
testing at LCC Station. HRH continues with the remediation of corrosion issues
with the PSGS components. HRH started ATC WTP testing in ALS station. HRH completed inter-station ATC WTP testing between
EKP and HOP. HRH continues with onboard ATC testing with Train #2 in
the functional section. HRH continues with routine acceptance test for onboard
ATC equipment in Train #10. HRH achieved interim certification and completed train
dynamic testing for Train #11. Train #11 is ready for onboard ATC testing.
HRH continues with static acceptance test on Train #9. HRH completed onboard COMM testing in Train #12.
Further testing to be arranged after design changes are implemented, including additional cameras and Wireless Communication System (WCS) antenna mounting.
HRH continues with the communication system installation in HOP, West Loch, Waipahu and LCC stations.
HRH started MDS pole installation on the guideway. HRH connected EKP and HOP FDAS systems to OCC. HRH restarted FDAS cable installation at WLO station.
Look Ahead (continued): Complete car shell fabrication activities in Italy.
Three car shells will be fabricated in Reggio Calabria to replace the car shell used for roof and floor fire re-test and to replace Train #1 and Train #2 car shells with the extrusion defect.
Installation, Testing and Commissioning: Energization of third rail toward ALS station and
start of train testing toward ALS station. Complete SCADA testing with peripheral devices in
the MSF, after installation is completed. Integration test between TPSS/GBS and OCC to
complete (PLR and ALS). MSF SLAN/Communications Transmission System
(CTS), CCTV, ICS/IDS, Voice Radio Communication System (VRCS), TEL Acceptance Test to continue.
MSF PIS acceptance test to start. Complete PSGS Commissioning test at WTC, LCC,
EKP and UHWO. Complete Vehicle Test Procedure, Central Test
Procedure, and System Test Procedure in Functional Section.
Continue System Integration Testing with train(s) in the Yard.
Complete remediation of corrosion issues with the PSGS components.
Continue ATC Wayside testing in PLR and ALS Train Control and Communications Room (TCCR).
Start communication system testing in HOP Station.
Start station SCADA testing in HOP. Complete Train #10 onboard ATC and onboard
COM testing. Complete Train #11 onboard ATC and onboard
COM testing. Achieve Train #9 (April 2020) Interim Certificate for
dynamic testing. Delivery of the last train (Train #13) for Interim
Opening (I/O) #1. Start SCADA installation in the stations.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
Macton Aug 2018 Lift Repair MSF A
Changing of Vehicle "Square Key" Locks (square to triangle key)
VMS Signs - AGS End of Platform
A A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal
Honolulu Rail Transit Project Monthly Progress Report March 2020
26 | P a g e
KEY MILESTONES: Interim Opening Fleet (6 trains) to be on-site by April 2020. Energization of Segment 1 in April 2020.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
QUALITY MANAGEMENT: Hitachi has indicated that the two remaining car shells that require replacement of the bolster assemblies due to
the aluminum extrusion defects, will be scrapped instead of repaired. Hitachi is in the process of ordering additional material for the fabrication of three (3) new car shells; one to replace the car shell used to expedite the floor and roof fire re-test and two to replace the car shells with extrusion defects.
End Car 1 of Train #12 was damaged (about 2.0 ft. long x ¾ in. wide x ¼ in. deep gouge on the left side, which did not penetrate the aluminum extrusion skin, and about ½ in. diameter penetration in the first set of the Door Panel on the right side of End Car 1) during transit from Pittsburg, CA to Honolulu, HI. Repair procedure is being developed.
CSC NCR Log (Issued by HRH)
Total Closed Open
HRH & Subs 58 55 3
Hitachi Rail 2,064 1,713 351
TOTAL 2,122 1,768 354
________________________________________________________________________________________________________________________________________________________________________________________________________________________
TRAIN SCHEDULE:
Honolulu Rail Transit Project Monthly Progress Report March 2020
27 | P a g e
B. Elevators and Escalators Manufacture-Install-Maintain (MIM) CPP No.: MI-930 Contractor: Schindler Elevator Corporation Contract Start Date: August 2013 Contract Substantial Completion: May 2021 Projected Completion of Work: February 2024 (see the Schedule section below) Project Description: A contract to design, fabricate, install, test, commission, and maintain all elevators and escalators at all 21 stations.
Progress Schedule Status
Physical % Complete 46.4%
Just in Time** Early Plan* 56.6%
Late Plan* TBD *Data as of March 27, 2020. **The E&E schedule is dependent on other contractors' schedules. Actual release for manufacturing will be coordinated for a 'just in time' delivery.
_______________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation: $0
DBE % Attained: 0%
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $4,879,726
None N/A ---
Cumulative Current Report $4,879,726
_______________________________________________________________________________________________________
SCHEDULE: The Elevators and Escalators (E&E) contract substantial completion date is May 2021, based on the AGS contract
substantial completion date. The final completion date for the E&E contract will be based on the CCGS contract’s scheduled installation dates after award of the CCGS contract.
Original Contract: $50,982,714 Incurred-to-Date: $27,599,393
Current Contract Value¹: $55,862,440 Incurred in March: $644,634
Outstanding Issues: 0 Contractor CP Amount: $0 1Current Contract Value = Original contract value with Design Allowance + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
28 | P a g e
WORK PROGRESS:
Activities this Month: Elevator CEI inspections are occurring for the WOSG and
FHSG to ensure that the required specifications for the State Inspections for elevators and escalators are met.
HART is continuing to coordinate with the AGS contractor and the E&E contractor to firm up required equipment installation dates.
At Pearlridge Station, Elevator #1 installation is complete and the station contractor will begin glazing in early April 2020. Elevator #2 installation is continuing with an estimated completion date in April 2020.
At Aloha Stadium, installation of Escalators #1 and #2 is continuing. Installation of Elevators #1 and #2 has begun.
The State has begun Pre-inspections for all of the equipment installed at the West O‘ahu Station Group and the Farrington Highway Station Group so that when the Final inspections are called in, the acceptance should go smoothly.
The State has completed the inspection at Ho‘opili Station and Leeward Community College and has provided a punch list for each. These punch lists have been shared with the station contractors so that these items can be addressed and corrected prior to the States final inspection and acceptance.
Look Ahead: The E&E substantial completion date for the
remaining eight east-side stations will be established once the contract is awarded for the CCGS and the schedule for this contract is accepted.
At Pearlridge Station, completion of Elevator #2 is anticipated in April 2020.
At Aloha Stadium Station, completion of Escalators #1 and #2 is anticipated in May 2020 and Elevators #1 and #2 in August 2020.
_______________________________________________________________________________________________________
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
None N/A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal
_______________________________________________________________________________________________________
KEY MILESTONES: Preventive maintenance requirements along with the required final testing is continuing for the elevators that
have been installed. Installation has started at Aloha Stadium Station for the final 2 elevators. State Pre-inspections on all of the equipment installed at WOSG and FHSG began in November 2019 and is
continuing. This will facilitate the State Final Inspections which are required to allow the public to use the installed equipment.
_______________________________________________________________________________________________________
QUALITY MANAGEMENT:
Elevators and Escalators NCR Log (Issued by Schindler)
Total NCRs Issued To Date Closed Open
0 0 0
Honolulu Rail Transit Project Monthly Progress Report March 2020
29 | P a g e
C. Fare Collection System CPP No.: MI-900 Contractor: INIT, Innovations in Transportation, Inc. Contract Start Date: April 2016 Projected Completion of Design-Build Work: December 2025
Project Description: The fare collection system is a joint HART and City and County of Honolulu [Department of Transportation Services (DTS), Department of Information Technology (DIT), Budget and Fiscal Services (BFS)] project that will consist of a multi-modal, closed loop, account based smart card system. The Fare System vendor, INIT Innovations in Transportation, Inc., is responsible for design, manufacture, testing, installation and operation of the entire system inclusive of hardware and software. The rail portion of the project will consist of Ticket Vending Machines (TVMs) and fare gates at stations that accept smart cards which can also be used for payment on board TheBus and facilitate a seamless transfer between modes. Equipment and software to be used by both HART and the City and County will include transaction processing, fare equipment monitoring, and customer service systems, as well as a Data Warehouse. TheBus equipment will consist of stand-alone smart card readers on board.
Progress Schedule Status
Percent Complete 46.6% 12 Months Behind Milestone Schedule
Payment** Early Plan* 83.9%
Late Plan* 78.0% *Data as of March 27, 2020. Planned information is being evaluated based on the current (full-alignment) scope versus the revised requirements of the Interim Revenue Service completion date. **Although the contract is 12 months behind schedule, it does not impact the Interim Opening or the RSD.
_______________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation: $0
DBE % Attained: 0%
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $444,026
None N/A ---
Cumulative Current Report $444,026
_______________________________________________________________________________________________________
SCHEDULE: Bus and Back Office System Acceptance Milestone March 31, 2020. HART awaits DTS concurrence to certify for
invoicing as of March 31, 2020, and intends to certify. Revised remote System Integration Testing (SIT) is scheduled for April 8- 20, 2020. Production Acceptance Test (PAT) is scheduled to be completed remotely April 20-21 for the faregates and, travel
permitting, June 3 for the TVMs.
Original Contract: $15,464,198 Incurred-to-Date: $6,382,428
Current Contract Value¹: $15,908,224 Incurred in March: $15,218
Outstanding Issues: 1 Contractor CP Amount: $616,124
1Current Contract Value = Original contract value with Design Allowance + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
30 | P a g e
WORK PROGRESS:
Activities this Month: Completed revisions and finalized Field Device Manuals,
Operations Plan with Appendices, per comments from DTS.
Confirmed Key Performance Indicators (KPIs) with DTS, calculations and contents.
Rolled out Customer Service Terminals to Kapolei and Pearl City Satellite City Hall (SCH).
Revised Sequencing Schedule per updated shipping dates and developed mitigation options schedule.
Completed Finding of Merit/No Merit (FOM) for Issue 16 Bank Boxes and DIN Rails and drafted FOM for Issue 17 Pilot User Changes.
Reviewed draft Bus and Back Office Final Acceptance Invoice with DTS.
Revised SIT Plans for a mix of remote and on-site testing.
Negotiated Rail Restart Claim (awaiting certified documents from the vendor to finalize).
Finalized Executive Decision Document (EDD) for redundant fiber connection.
Began review of 7 language translations for website and Interactive Voice Response (IVR).
Look Ahead:
Conduct SIT.
Confirm Schedule Mitigation approaches.
Reschedule SCH Customer Service Terminal Installations and training for remaining SCHs.
Schedule installation for remaining TIMES retail locations and test 7-Eleven locations.
Issue RFP for Redundant Fiber Connection between OCC and Fasi Municipal Building (FMB).
Finalize PAT Plans. Implement Pilot changes. Complete Amendment 8 for Pilot User Changes
and FDAS equipment within faregates. Confirm language translations for website and IVR
and release. Complete Functional Unit Testing (FUT).
_______________________________________________________________________________________________________________________________________
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
Rail Restart A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal _______________________________________________________________________________________________________________________________________
KEY MILESTONES: System Acceptance Bus and Back Office March 31, 2020.
Rail System Integration Testing April 2020. Production Acceptance Testing June 2020.
_______________________________________________________________________________________________________________________________________
QUALITY MANAGEMENT:
Fare Collection NCR Log (Issued by INIT)
Total NCRs Issued To Date Closed Open
0 0 0
Honolulu Rail Transit Project Monthly Progress Report March 2020
31 | P a g e
D. On-Call Construction IV CPP No.: MM-949 Contractor: Royal Contracting Co., Ltd. Contract Start Date: January 2018 Contract Substantial Completion: January 2023 Projected Completion of Work: January 2023 Project Description: This is an on-call contract to perform a variety of construction services by issuance of Task Orders. The construction services to be provided will include, but are not limited to, maintenance, renovations to existing privately owned properties, demolition of buildings/structures, repairs to existing HART facilities, temporary utilities installations, utilities relocation, new construction projects or services, maintenance of roadways inclusive of, filling potholes, removing dead animals, landscape maintenance, repairing/replacing signage, and other such activities to HDOT and/or City and County of Honolulu standards, work in support of HART’s ongoing construction activities, and work in support of other HART contractors.
Progress Schedule Status
Physical % Complete* 78.8%
On Time Early Plan* 100%
Late Plan* TBD *Data as of March 27, 2020.
__________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
DBE Participation Task Orders
Actual DBE Participation: $0
Number of Task Orders Issued
Amount ($)
DBE % Attained: 0% Task Orders Previously Issued 67 $45,403,506
Task Orders Issued this Month 3 $255,706
Amendments to Task Orders 6 ($359,993)
Total Task Orders Issued 70 $45,299,219
__________________________________________________________________________________________________________________________________________________________________________________________________________________________
SCHEDULE: The On-Call Contract is a Task Order based Indefinite Delivery/Indefinite Quantity (IDIQ) contract. The work
consists of meeting the objectivities of HART’s Joint Use and Occupancy Agreements (JUOA) requirements, maintaining HART properties, performing Cost to Cure activities, and performing permanent utility relocation work. Each Task Order has its own start and finish date, and as such, there is no overall schedule requirements for the On-Call contract proper. The contract NTP was issued on Jan. 8, 2018 and ends on Jan. 7, 2023 with two one-year options.
Original Contract: $46,000,000 Incurred-to-Date: $32,878,531
Current Contract Value¹: $46,000,000 Incurred in March: $1,831,454
1Current Contract Value = Original contract value + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
32 | P a g e
WORK PROGRESS: Activities this Month: Continued maintenance of the HDOT roadways along
Farrington Highway and Kamehameha Highway, per the JUOA.
Work on new sidewalk, new curb and gutter, and road widening at Cutter Dodge, Stuart Plaza and UH Urban Gardens is continuing. At approximately 98% complete.
Continued to complete HDOT elements of work as required by the HDOT agreements.
Continued to work on AGS HECO Zone’s 8A and 9. Completed work at Dillingham Plaza which is a cost to
cure activity. Work is 100% complete. Continued work at LCC on the Ka‘aahi Substation and
storage area for HECO vehicles. Work is at 88% complete.
Work continues for HECO Zone 6A – work is 85% complete.
Look Ahead: Continue to maintain HDOT roadways, as required
by the JUOA. Continue work on new sidewalk, new curb and
gutter, and road widening at Cutter Dodge, Stuart Plaza and UH Urban Gardens.
Continue to complete HDOT elements of work as required by the HDOT agreements.
Continue to work on Cost to Cure property’s located on Dillingham Boulevard.
The planned completion for HECO Zone 6A duct bank 1639 is scheduled for April 2020.
_______________________________________________________________________________________________________________________________________
KEY ISSUES (new issues are in bold font): Need to receive timely Right of Entry agreements.
Need to continue to have Maintenance of Traffic plans reviewed and accepted in a reasonable time frame. _______________________________________________________________________________________________________________________________________
KEY MILESTONES: The completion of the work at UH Urban Gardens – Cutter Dodge will provide the required road widening at this
section of Kamehameha Highway; April 2020 completion date. The completion of this work was severely hampered by inclement weather during the first quarter of 2020.
_______________________________________________________________________________________________________________________________________
QUALITY MANAGEMENT:
On-Call Construction IV NCR Log (Issued by Royal Contracting)
Total NCRs Issued To Date Closed Open
0 0 0
Honolulu Rail Transit Project Monthly Progress Report March 2020
33 | P a g e
4.2 Section I – West O'ahu/Farrington Highway: East Kapolei to Pearl Highlands
A. West O'ahu/Farrington Highway Guideway (WOFH) CPP No.: DB-120 DB Contractor: Kiewit Infrastructure West Company (KIWC) Contract Start Date: December 2009 Date of Substantial Completion Notification: December 13, 2018
Project Description: Design and construction of 6.8 miles of rail alignment, starting at the East Kapolei Station and ending at the Pearl Highlands Station.
Progress Schedule Status
Physical % Complete 100% Substantial Completion Obtained**
Early Plan* 100%
Late Plan* 100% *Data as of March 27, 2020. **Further explanation is provided in the Schedule section.
_______________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$17,119,976
DBE % Attained:
2.56%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $185,351,685
None N/A ---
Cumulative Current Report $185,351,685
_______________________________________________________________________________________________________
SCHEDULE: Acoustical Monitoring installation has been completed. Contract closeout – May 2020.
_______________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: Acoustical Monitoring installation completed.
Look Ahead: Route Contract Closeout Checklist for signature. Issue Final Acceptance letter, including the
Certificate and Release of Final Payment form.
Original Contract: $482,430,201 Incurred-to-Date: $667,781,886*
Current Contract Value¹: $667,781,886 Incurred in March: $0
*Contract closeout reconciliation resulted in a lower incurred-to-date
1Current Contract Value = Original contract value + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
34 | P a g e
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
None N/A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal _______________________________________________________________________________________________________
KEY MILESTONES: One-year project warranty period commenced on Jan. 14, 2019, per Contract Change Order (CCO) No. 00170. One-year project warranty period ended on Jan. 14, 2020.
_______________________________________________________________________________________________________
SUBSTANTIAL COMPLETION: Substantial Completion is Dec. 13, 2018.
_______________________________________________________________________________________________________
QUALITY MANAGEMENT:
WOFH NCR LOG (Issued by KIWC)
Total NCRs Issued to Date Closed Open
586 586 0
Honolulu Rail Transit Project Monthly Progress Report March 2020
35 | P a g e
B. University of Hawai‘i West O‘ahu (UHWO) Station Temporary Park-and-Ride & UHWO Campus Road “B” CPP No.: DBB-602 Contractor: Nan, Inc. Contract Start Date: December 2017 Contract Substantial Completion: July 2019 Completion of Work: January 2020 Project Description: The project consists of the construction of a temporary park & ride, Road “B” and associated site work in the vicinity of UH West O‘ahu Station. The project includes clearing, grubbing, erosion and dust control, grading and hauling, drainage, installation of underground and overhead utilities, installation of traffic signal, street lighting, and park & ride area electrical and communication systems, concrete curbs, sidewalks and wheelchair ramps, asphalt and concrete pavement structures, signing and striping, bus shelters, landscaping including installation of an irrigation system, and other appurtenances associated with roadway and park & ride facilities.
Progress Schedule Status
Physical % Complete 100% Work
Completed** Early Plan* 100%
Late Plan* 100% *Data as of March 27, 2020. NTP issued Dec. 15, 2017. **Pending contract actions will extend contract completion date.
_______________________________________________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$108,454
DBE % Attained: 0.82%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $1,611,930
None N/A ---
Cumulative Current Report $1,611,930
_______________________________________________________________________________________________________________________________________
SCHEDULE: Substantial completion date is Oct. 23, 2019, per substantial completion letter dated Dec. 13, 2019. Change Order (CO) for Communication Interface Cabinet (CIC) cabinet work is complete. Construction work on the
DBB-602 contract was completed in January 2020. Change Order pending to extend contract completion date.
Original Contract: $11,589,300 Incurred-to-Date: $12,193,721
Current Contract Value¹: $13,201,230 Incurred in March²: $0
Outstanding Issues: 3 Contractor CP Amount: $680,335
1Current Contract Value = Original contract value + executed Change Orders 2Work has progressed and incurred amounts will be reflected as invoices are approved in the City’s C2HERPS system
Honolulu Rail Transit Project Monthly Progress Report March 2020
36 | P a g e
WORK PROGRESS: Activities this Month: Worked on punchlist items. Conducted Temporary Park & Ride Lighting Electrical
Testing. Worked on closing NCR for crosswalk ponding issues at
Road B and Road D intersection. Completed lighting testing.
Look Ahead: Complete remaining punchlist items. Coordinate Board of Water Supply (BWS) meter
installation for Road B and Temporary Park & Ride.
_______________________________________________________________________________________________________________________________________
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
Survey Modeling Costs - RFI No. 00045 - Contour Grades and Driveway Profiles
Delete Traffic Signal Work at Road B (D. R. Horton to Complete)
Project Time Delay [establish new Contract Substantial Completion Date]
A A A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal _______________________________________________________________________________________________________________________________________
KEY MILESTONES:
Complete punchlist work – April 2020. _______________________________________________________________________________________________________________________________________
QUALITY MANAGEMENT:
UHWO Station Temporary Park-and-Ride & UHWO Campus Road “B” NCR Log
(Issued by Nan)
Total NCRs Issued to Date Closed Open
5 0 5
Honolulu Rail Transit Project Monthly Progress Report March 2020
37 | P a g e
C. West O'ahu Station Group (WOSG) CPP No.: DBB-171 Contractor: Nan, Inc. Contract Start Date: October 2015 Contract Substantial Completion: January 31, 2020 Date of Substantial Completion: January 31, 2020
Project Description: The West O'ahu Station Group construction contract includes services to build three (3) transit stations along Kualaka'i Parkway and Farrington Highway. The stations are East Kapolei (EKP), UH West O'ahu (UHWO), and Ho'opili (HOP) Stations. In addition to the transit stations, operational ancillary buildings, a traction power substation, and adjacent areas are included in this project.
Progress Schedule Status
Physical % Complete 98.5%** Substantial Completion
Obtained Early Plan* 100%
Late Plan* 100% *Data as of March 27, 2020. **Remaining work includes punchlist, contract change orders and closeout.
__________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$858,189
DBE % Attained: 0.98%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $31,810,294
None N/A --- ---
Cumulative Current Report $31,810,294
Original Contract: $56,088,470 Incurred-to-Date: $81,684,474
Current Contract Value¹: $87,898,764 Incurred in March: $467,582
Outstanding Issues: 4 Contractor CP Amount: $1,089,247 1Current Contract Value = Original contract value + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
38 | P a g e
SCHEDULE: Substantial Completion letter issued for Jan. 31, 2020. Coordinating with CSC and the contractor to meet HRH’s schedule for access turnover for functional testing and
interim service milestones. Change order work, base contract work impacted by pending change orders, and pending change order work to
be completed.
WORK PROGRESS: Activities this Month: East Kapolei
Apply graffiti-resistant coating station-wide. Installation of utility rooms shelving and/or cabinets. Flushing and chlorination of underground water lines. Continue station-wide correcting of work list, punchlist
items/issues, and clean up. Art wall curbs, per Architect Supplemental Information (ASI)
15, installation. Elevator/escalator cladding installation. Keahumoa Parkway sidewalk and water meter backfill work. COMM device correction of issues, per COMM Survey. Installation of interior signage brackets.
UH West O‘ahu Heating, Ventilation and Air Conditioning (HVAC) Testing and
Balance completed. Heating, Ventilation and Air Conditioning video training
completed. FM 200 System video training completed. Faregate wall installation, including tile work completed. Apply graffiti-resistant coating station-wide. Plumbing fixture testing completed. Water chlorination testing completed. Continue station-wide correcting of work list, punchlist
items/issues, and clean up. Ho‘opili
Apply graffiti-resistant coating station-wide. Landscaping continues. Finish concrete staining and floor tiles. Finish wall tiles. Canopy drain installation is ongoing. Utilities installation continues. Temporary sanitary tank installation.
Look Ahead: East Kapolei Complete site utility work. Complete site work and landscaping. Signage installation. Concrete staining/floor tiles. Art wall, per ASI 15, finish completion. Remaining punchlist completion. Fix canopy drains issue. Elevator opening for insect screen
installation. Lighting testing and operation.
UH West O‘ahu Landscaping. Concrete staining. Signage installation. Traffic signal installation. Canopy drain installation. Lighting testing and operation.
Ho‘opili Plumbing fixture testing. Signage installation. Landscaping continues. Final grading.
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
EKP 8" Sewer Line Conflict RFI 01135
Rev 4r1 Common Drawings Signage Revisions (Post CR)
EKP 24” Sewer Line Differing Site Condition - RFI 01207
Keone'ae Station (UHWO) 16-in Non-Potable Waterline Reconnection
A A A A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal
Honolulu Rail Transit Project Monthly Progress Report March 2020
39 | P a g e
KEY MILESTONES: UHWO Station:
HECO energization. EKP Station:
Site utility (24” and 8” sewer lines) installation.
QUALITY MANAGEMENT: Conducted bi-weekly Quality Task Force Meetings.
WOSG NCR Log (Issued by Nan)
NCRs Issued to Date
Closed Open
East Kapolei 14 13 1
UH West O‘ahu 42 37 5
Ho‘opili 31 28 3
Contract Wide 10 10 0
TOTAL 97 88 9
Honolulu Rail Transit Project Monthly Progress Report March 2020
40 | P a g e
D. Farrington Highway Station Group (FHSG) CPP No.: DBB-271 Contractor: Hawaiian Dredging Construction Company, Inc. (HDCC) Contract Start Date: August 2015 Contract Substantial Completion: January 2019 Projected Completion of Work: June 2020
Project Description: The Farrington Highway Station Group construction contract includes services to build three (3) transit stations along Farrington Highway. The stations are West Loch (WLO), Waipahu Transit Center (WTC), and Leeward Community College (LCC) Stations. The station work includes operational ancillary buildings, a traction power substation at WLO, and a Kiss-and-Ride lot at WLO.
Progress Schedule Status
Physical % Complete 95.8% 17 months behind**
Early Plan* 100%
Late Plan* 100% *Data as of March 27, 2020. **Further explanation is provided in the Schedule section.
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$4,292,728
DBE % Attained: 4.40%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $18,487,980
None N/A ---
Cumulative Current Report $18,487,980
Original Contract: $78,999,000 Incurred-to-Date: $90,354,186
Current Contract Value¹: $97,486,980 Incurred in March: $1,097,828
Outstanding Issues: 1 Contractor CP Amount: $20,802,899
1Current Contract Value = Original contract value + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
41 | P a g e
SCHEDULE:
HART directed HDCC to temporarily handover occupancy of WTC Makai platform for one week, beginning on March 10, so that HRH could complete Passenger Screen Gate testing. As a result of this action, HDCC passed on an opportunity to deploy fabric on March 11.
Due to COVID-19, the canopy fabric crew was recalled to its home country of Australia. HDCC mobilized a new crew from the mainland who arrived on island March 24 and will be quarantined through April 6. After quarantine, HDCC will resume with the canopy fabric installation.
Final faregate canopy fabric installation to be completed in June 2020, due to contractor delay in fabrication of faregate canopy steel.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: West Loch
● Pulled power cable to service posts. ● Installed CIC cabinets at platform level. ● Installed bipod struts and staged canopy fabric.
Leeward Community College ● Installed lifeline to complete canopy clamping/flashing scope. ● Completed 80% of punchlist items.
Waipahu Transit Center ● Prepared canopy fabric for deployment. ● Routed conduit to service posts.
All Stations ● Coordinated canopy fabric installation, train testing, NCRs,
change orders, and other closeout items. ● Faregate canopy fabrication (WLO/WTC). ● Signage fabrication.
Look Ahead: West Loch
● Deploy and tension fabric. ● Faregate canopy fabrication.
Leeward Community College ● Complete clamping and flashing
installation on canopy.
Waipahu Transit Center ● Moloalo sidewalk redesign. ● Deploy and tension fabric. ● Fare gate canopy.
All Stations ● Punchlist walk. ● Faregate canopy delivery. ● Signage delivery.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code ● Potential Consolidated Resolution C
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal ________________________________________________________________________________________________________________________________________________________________________________________________________________________
KEY MILESTONES: Platform canopy installation is scheduled to be completed May 2020. Faregate canopies are scheduled to be
complete by June 2020.
Honolulu Rail Transit Project Monthly Progress Report March 2020
42 | P a g e
QUALITY MANAGEMENT: The CEI team is working with HDCC to ensure required submittals are approved prior to related construction
activities.
FHSG NCR Log (Issued by HDCC)
NCRs Issued to Date
Closed Open
West Loch 33 31 2
Waipahu Transit Center 22 14 8
West Loch/Waipahu Transit Center 3 2 1
Leeward Community College 20 15 5
Contract Wide 19 17 2
Void 2 2 0
TOTAL 99 81 18
Honolulu Rail Transit Project Monthly Progress Report March 2020
43 | P a g e
E. Maintenance and Storage Facility (MSF) CPP No.: DB-200 Contractor: Kiewit/Kobayashi Joint Venture (KKJV) Contract Start Date: July 25, 2011 Contract Substantial Completion Date: July 2, 2016
Project Description: The MSF contract consists of the Operations and Servicing Building (OSB), Maintenance of Way (MOW), Train Wash Facility (TWF) and Wheel Truing Building (WTB). In addition to the four (4) facility buildings, MSF includes rail procurement, special trackwork, ties, third rail and other track material for the four guideway segments on the project.
Progress Schedule Status
Physical % Complete 100% Substantial Completion Obtained*
Early Plan 100%
Late Plan 100% *Further explanation is provided in the Schedule section.
_______________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation: $710,987
DBE % Attained: 0.25%
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $86,517,032
None N/A ---
Cumulative Current Report $86,517,032
______________________________________________________________________________________________________________________________________________________
SCHEDULE:
HART to close remaining issues second quarter 2020. ______________________________________________________________________________________________________________________________________________________
WORK PROGRESS:
Activities this Month: Final acceptance letter routing for signature.
Look Ahead: Final retention release. Final acceptance letter from HART. Process final payment.
MSF Construction Status 100% Complete Overall
Element % Complete*
OSB 100%
MOW Building 100%
WTB 100%
TWF 100%
Rail 100%
Paving 100% *Not including testing and commissioning.
Original Contract: $195,258,000 Incurred-to-Date: $281,775,032
Current Contract Value¹: $281,775,032 Incurred in March: $0
1Current Contract Value = Original contract value + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
44 | P a g e
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
None N/A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal _______________________________________________________________________________________________________
KEY MILESTONES:
None. _______________________________________________________________________________________________________
QUALITY MANAGEMENT: Overall quality of the contract is good.
MSF NCR Log (Issued by KKJV)
Total NCRs Issued to Date Closed Open
37 37 0
Honolulu Rail Transit Project Monthly Progress Report March 2020
45 | P a g e
4.3 Section II – Kamehameha Highway: Pearl Highlands to Aloha Stadium A. Kamehameha Highway Guideway (KHG)
CPP No.: DB-320 Contractor: Kiewit Infrastructure West Company (KIWC) Contract Start Date: June 2011 Date of Substantial Completion Notification: December 13, 2018
Project Description: Kamehameha Highway Guideway DB Contract (KHG) consists of 3.9 miles and starts 400 feet east of the Pearl Highlands Station and terminates 1,400 feet beyond the Aloha Stadium Station. KHG work scope is made up of utility relocations, traffic signal improvements, highway widening, drilled shaft foundations, columns, and aerial structure.
Progress Schedule Status
Physical % Complete 100% Substantial Completion Obtained**
Early Plan* 100%
Late Plan* 100% *Data as of March 27, 2020. **Further explanation is provided in the Schedule section.
_______________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$860,191
DBE % Attained: 0.21%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $31,405,774
None N/A ---
Cumulative Current Report $31,405,774
SCHEDULE: Close contract, pending signed Release and Certificate of Final Payment from KIWC.
_______________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: Processing retainage release.
Look Ahead: Receive the contractor’s signed Release and
Certificate of Final Payment. Payment of final retention release.
Original Contract: $372,150,000 Incurred-to-Date: $403,555,774*
Current Contract Value¹: $403,555,774 Incurred in March: $0
*Contract closeout reconciliation resulted in a lower incurred-to-date
1Current Contract Value = Original contract value + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
46 | P a g e
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
None N/A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal _______________________________________________________________________________________________________
KEY MILESTONES: One-year project warranty period commenced on Jan. 14, 2019, in accordance with CCO No. 00076. One-year project warranty ended on Jan. 14, 2020.
_______________________________________________________________________________________________________
SUBSTANTIAL COMPLETION: Substantial Completion was Dec. 13, 2018.
_______________________________________________________________________________________________________
QUALITY MANAGEMENT:
KHG NCR Log (Issued by KIWC)
Total NCRs Issued to Date Closed Open
252 252 0
Honolulu Rail Transit Project Monthly Progress Report March 2020
47 | P a g e
B. Kamehameha Highway Station Group (KHSG) CPP No.: DBB-371 Contractor: Nan, Inc. Contract Start Date:
Notice to Commence Administrative Work: April 2016 Notice to Commence Investigative/Pre-Construction Work at Pearl Highlands: July 2016 Full Notice to Proceed (NTP): October 3, 2016
Contract Substantial Completion: April 2020 Projected Completion of Work: July 2020
Project Description: The Kamehameha Highway Station Group construction contract includes services to build three (3) transit stations along Kamehameha Highway. The stations are Pearl Highlands Station (PHL), Pearlridge Station (PLR), and Aloha Stadium Station (ALS). Operational ancillary buildings, pedestrian crossing improvements, Train Control and Communications Rooms (TCCRs), and landscaping of the station sites are included in addition to the transit stations. The Pearl Highlands Station will include a transit center. The Pearl Highlands and Aloha Stadium Stations include both a Park-and-Ride lot and a Kiss-and-Ride lot.
Progress Schedule Status
Physical % Complete 91.2%
3 month behind** Early Plan* 100%
Late Plan* 99.9% *Data as of March 27, 2020. **Further explanation is provided in the Schedule section.
_________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation: $0
DBE % Attained: 0%
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $15,219,828
None N/A ---
Cumulative Current Report $15,219,828
Original Contract: $115,805,845 Incurred-to-Date: $115,731,666
Current Contract Value¹: $131,025,673 Incurred in March: $3,172,816
Outstanding Issues: 1 Contractor CP Amount: $112,717
1Current Contract Value = Original contract value with Design Allowance + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
48 | P a g e
SCHEDULE: Ongoing coordination with CSC and the contractor to meet HRH’s schedule for access turnover and interim
opening. Schedule delayed by canopy and fabric delivery. Canopy fabric is scheduled to start in May at Pearl Highlands and
in June at Pearlridge. Aloha Stadium arm installation has moved to May with fabric installation starting in June. Working with the contractor to improve the schedule.
Working with the station and systems contractors to mitigate any impact on interim opening resulting from canopy design revisions in progress.
CCO 44 revised the contract substantial completion date to April 30, 2020. ________________________________________________________________________________________________________________________________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: Pearl Highlands
Completed rock slope protection installation near Waiawa Stream.
Completed Elevator 1 and 2 thermoplastic polyolefin (TPO) roofing installation.
Commenced and completed Variable Message Sign (VMS) support installation.
Continued painting of all steel. Commenced ceramic tile installation. Continued Articulated Concrete Block installation. Completed elevator door and window jamb
installation. Continued forming/reinforcement for beams and slabs
for entrance ramp and utility corridor. Completed cutting of box beam girder and patch
guideway clearance. Commenced and completed escalator cladding
installation. Pearlridge
Continued painting all steel. Continued lighting installation. Completed fiberglass conduit installation. Completed sidewalk and streetlight work. Completed escalator cladding installation. Commenced chain-link fence installation Commenced elevator TPO roofing installation. Commenced and completed installation of frame and
enclosure for Roll up door Emergency Management Panel (EMP).
Commenced and completed site grading work. Aloha Stadium
Continued driveway B rigid paving concrete pours. Continued subgrade preparation for driveway B. Completed ceramic tile installation. Completed Architectural fence installation. Continued lighting installation. Continued visual screen support and balustrade
installation. Commenced and completed highway sign footing
installation. Commenced elevator shaft roof and deck installation. Commenced parking lot landscape work.
Look Ahead: Pearl Highlands
Complete forming/reinforcement and concrete pour for beams and slabs for entrance ramp and utility corridor.
Complete Articulated Concrete Block Installation Complete ceramic tile installation. Commence bipod installation. Commence canopy fabric installation. Commence signage installation. Commence furniture installation. Commence Fire Protection Accessories and
cabinets installation. Commence installation of graffiti resistant
coating. Pearlridge
Commence mauka sewer line work and grinder pump installation.
Commence elevator glazing installation. Complete lighting installation. Commence installation of architectural fence
gates. Commence Faregate ceramic tile walls
installation. Commence installation of sheet metal wall panels
for EMP. Commence bipod installation. Commence canopy fabric installation. Commence signage installation. Commence furniture installation.
Aloha Stadium Complete driveway B ridged paving concrete
pours. Complete visual screen support and balustrade
installation. Commence highway sign structure installation. Commence installation of frame and enclosure
for Roll up door and EMP. Commence elevator glazing installation. Commence canopy fabric installation. Commence signage installation. Commence furniture installation. Complete parking lot landscape work.
Honolulu Rail Transit Project Monthly Progress Report March 2020
49 | P a g e
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
PLR Mauka Sewerline A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal
________________________________________________________________________________________________________________________________________________________________________________________________________________________
KEY MILESTONES:
Pearlridge Station TCCR and UPS Building – Pathway to guideway conduit installation is complete. TCCR and UPS rooms are now being shared with the Core Systems Contractor.
Aloha Stadium Station TCCR and UPS Rooms – Pathway to guideway conduits complete. TCCR and UPS rooms are now being shared with the Core Systems Contractor.
Canopy arms are erected at Pearl Highlands and Pearlridge. Energization of Pearl Highlands and Pearlridge – February 2020.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
QUALITY MANAGEMENT:
KHSG NCR Log (Issued by Nan)
NCRs Issued to Date
Closed Open
Pearl Highlands 28 25 3
Pearlridge 25 24 1
Aloha Stadium 6 3 3
Contract Wide 0 0 0
TOTAL 59 52 7
Honolulu Rail Transit Project Monthly Progress Report March 2020
50 | P a g e
C. Kamehameha Highway Resurfacing (KHR) CPP No.: DBB-701 Contractor: Road and Highway Builders, LLC (RHB) Contract Start Date: Notice to Proceed NTP #1: August 2018 Contract Substantial Completion: September 2019 Projected Completion of Work: April 2020
Project Description: The project consists of pavement resurfacing and other roadway reconstruction associated with completion of the Kamehameha Highway Guideway contract. Construction includes, but is not limited to, clearing, grubbing, erosion and dust control, grading and hauling, maintenance of traffic, pavement resurfacing, and installation of pavement markings and striping, roadway signs, curb ramps, drainage, waterlines, gas lines, traffic signal loop detectors, retaining wall, guard railing, fencing and bus shelters.
Progress Schedule Status
Physical % Complete 94.5% 7 months behind**
Early Plan* 100%
Late Plan* 100% *Data as of March 27, 2020. **Pending contract actions will extend contract completion date.
__________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation: $1,963,931
DBE % Attained: 6.98%
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $2,145,340
None N/A ---
Cumulative Current Report $2,145,340
__________________________________________________________________________________________________________________________________________________________________________________________________________________________
SCHEDULE: The contract completion date will be extended due to delays in road widening at Kaahumanu Street and
Construction Right-of-Entry (CROE) for construction of retaining wall #9. A time extension is pending. Completion of currently contracted work is April 2020. Developing additional change orders that will extend the completion date to October 2020.
_______________________________________________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: Held various meetings, such as pre-activity, progress,
environmental, traffic quality, safety, and public interface meetings.
Completed permanent striping work and lowering manholes between Kuleana Road to Aloha Stadium.
Completed pedestrian island concrete work, traffic signal work, and streetlight work at Kaonohi intersection.
Look Ahead: Complete streetlight work near Pearlridge
Station. Prepare Finding of Merit for RFCR 00011 KHR
Miscellaneous Changes (CROE, Bus Shelter, Electronic Vehicle Counter [EVC] Loops & others).
Prepare Finding of Merit for RFCR 00013 Pearl City Stream Median Guardrail.
Original Contract: $25,989,989 Incurred-to-Date: $26,740,810
Current Contract Value¹: $28,135,329 Incurred in March: $475,734
Outstanding Issues: 1 Contractor CP Amount: $285,562
1Current Contract Value = Original contract value + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
51 | P a g e
Activities this Month (continued): Completed installing traffic loops between Kuleana Road
and Aloha Stadium. Commenced and completed grouting of abandoned
utilities. Continued streetlight work near Pearlridge Station. Prepared Finding of Merit for Request for Change by
HART (RFCR) 00012 Left Turn into Kuala Street. _______________________________________________________________________________________________________________________________________
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
Gas Line Work A
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal _______________________________________________________________________________________________________________________________________
KEY MILESTONES: Completed mill and overlay paving from Kaonohi Street to ALS.
_______________________________________________________________________________________________________________________________________
QUALITY MANAGEMENT: KHR continues to follow established quality processes through quality monitoring and audits.
KHR NCR Log (Issued by Road and Highway Builders)
Total NCRs Issued to Date Closed Open
0 0 0
Honolulu Rail Transit Project Monthly Progress Report March 2020
52 | P a g e
D. Design Services for 138kV Utilities Relocation at KHG
CPP No.: FD-700 Contractor: R.M. Towill Corporation (RMTC) Contract Start Date: September 2018 Contract Substantial Completion: November 2021 Project Description: Architectural and Engineering Services for the final design to relocate the existing 138kV overhead electrical lines to underground lines at Kamehameha Highway Guideway and Stations.
Progress Schedule Status
Based on Expenditures* 46.6%
TBD Early Plan* 53.3%
Late Plan* 40.3% *Data as of March 27, 2020.
_______________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation: $0
DBE % Attained: 0%
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $0
None N/A ---
Cumulative Current Report $0
_____________________________________________________________________________________________________
SCHEDULE: An updated preliminary design submittal (to HECO), incorporating additional HECO review comments on the
previously updated preliminary design submittal, was made on Feb. 21, 2020. These updated preliminary design drawings are currently being used by HECO for sway calculations.
_______________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: The design consultant traffic counts for preliminary
Maintenance of Traffic (MOT) plans will be completed shortly. The design consultant completed additional topographic
survey work. The design consultant completed discussions with a local
contractor for constructability purposes. The design consultant will be providing HECO with
geotechnical engineering services. We will continue to follow our schedule; HECO to schedule a
meeting to discuss shortly.
Look Ahead: Continue periodic HECO meetings. Continue refining preliminary design work. Continue to meet with third party agencies
to discuss their comments/concerns on the preliminary submittal.
Perform geotechnical investigation for the purpose of HECO’s pole foundation design, per HECO request.
Provide administrative support to HECO for them to inspect the condition of a few of their existing steel pole base connections.
Original Contract: $8,766,327 Incurred-to-Date: $3,964,732
Current Contract Value¹: $8,766,327 Incurred in March: $143,546 1Current Contract Value = Original contract value with Design Allowance + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
53 | P a g e
Activities this Month (continued): HECO preliminary sway calculations are currently anticipated
by mid-April 2020, and finalized results are anticipated by mid-May 2020. The schedule of this work is controlled by HECO.
The preliminary design has been submitted to affected third party agencies, and the design consultant continues to schedule meetings with each agency to discuss third party agency comments.
_______________________________________________________________________________________________________
KEY ISSUES (new issues are in bold font): The design consultant needs to continue to coordinate with third party agencies to determine if the alignment
needs to be modified. _______________________________________________________________________________________________________
KEY MILESTONES:
Based on schedule information we currently have, key upcoming milestones are as follows: o Prefinal Design: Oct. 14, 2020. o Final Design: April 21, 2021.
Honolulu Rail Transit Project Monthly Progress Report March 2020
54 | P a g e
4.4 Section III – Airport: Aloha Stadium to Middle Street Transit Center Station A. Airport Section Guideway and Stations (AGS)
CPP No.: DB-450 Contractor: Shimmick/Traylor/Granite, JV (STG) Contract Start Date: December 2016
Contract Substantial Completion: May 2021
Projected Completion of Work: October 2021
Project Description: The Airport Guideway and Stations Design-Build contract consists of the design and construction of 5.2 miles of elevated guideway, four (4) stations, and associated facilities between Aloha Stadium and the Middle Street Transit Center. The contractor will begin by interfacing with design disciplines, third-party stakeholders, and construction contracts within the corridor of the project to coordinate and resolve utilities conflicts. Design field verification efforts (potholing and geotechnical exploration) will be followed by construction activities once design packages have been approved.
Progress Schedule Status
Physical % Complete* 63.2%
5 months behind** Early Plan* 87.5%
Late Plan 71.9% *Data as of March 27, 2020. **Further explanation is provided in the Schedule section.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$42,547,670
DBE % Attained:
4.80%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No.
Description Amount ($)
Cumulative Previously Reported $11,054,752
00029 RFCR 15 City Fiber Networks Traffic Signal Systems $630,000
Cumulative Current Report $11,684,752
Original Contract: $874,750,000 Incurred-to-Date: $561,582,240
Current Contract Value¹: $886,434,752 Incurred in March: $43,801,350
Outstanding Issues: 2 Contractor CP Amount: $2,812,125 1Current Contract Value = Original contract value + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
55 | P a g e
SCHEDULE: A series of schedule workshops were held in order to come to an agreed upon Oct. 31, 2021 completion date.
Additional workshops are continuing to further define station activities with resolution in April 2020. ________________________________________________________________________________________________________________________________________________________________________________________________________________________
WORK PROGRESS: AGS Construction Status as of 03/31/2020
Guideway Structure Element
Total to Date
Total Qty % Complete
Shafts 174 225 77.3%
Columns 158 232 68.1%
Segment Casting 2,501 2,708 92.4%
Spans Stressed 88 210** 41.4%
Spans Grouted 82 210** 39.0%
Trackwork 0 * 0.0%
Third Rail 0 * 0.0%
Mill & Overlay 0 * 0.0% * Amounts to be determined. **Amount has been corrected.
Activities this Month: Guideway, Rail and Utility Work
Gantry 1 crane continued; erected/stressed 2 spans at 484 and 485. Gantry 2 crane continued; erected/stressed 4 spans at 526 through 529.
Utilities – HECO Zones 8 and 9 continued. System Site (SS) #25 and SS#27 are ongoing.
57,920 linear feet (LF) of running rail has been transported to the AGS guideway from the welding yard near LCC.
Reach A: Traffic Signal (TS) continued on Kamehameha Highway at Kalaloa and Halawa Drive. Median restoration commenced from Piers 423-426.
Reach C: HDOT-A Comm infrastructure was completed and Hawaiian Telcom (HTI) construction has begun. Street Light (SL), fuel and wet utility relocations continued.
Reach D: Infrastructure for HTI / Oceanic Time Warner Cable (OTWC) Comm. is ongoing.
Continued assembly of Gantry 3 in Ke‘ehi Lagoon Park. Pearl Harbor Naval Base (PHNB) Station Initiated erection of platform girder forming system on
top of the guideway. Honolulu International Airport (HIA) Station Completed hammerhead for Pier 543. Poured elevator
pit slab and backfilled at Elevators 1-3 (Lot J). Lagoon Drive (LD) Station Completed structural steel erection for Mauka
Entrance. Middle Street Transit Center (MSTC) Station Completed 1 drilled shaft for the pedestrian bridge (1
out of 3 completed) and 2 drilled shafts for TCCR (4 out of 5 completed).
Look Ahead: Guideway, Rail and Utility Work Design Submittals Approved:
o Reach A, B and E – Civil and Composite Utilities Issued for Construction (IFC)
o Civil Common Drawings and Intelligent Transportation Systems (ITS) IFC
o MSTC Station IFC Form/rebar/pour Reaches C and E columns and
segment casting. Continue pouring C-Bents and Straddle Bents, and
columns in Reach B, Reach C and Reach E. Begin installation of rail work. Complete electrical relocation work in HECO Zones 6A,
8 and 9. Coordination taking place with third parties. Continue drilled shaft construction in Reach C and E. Continue assembly of Gantry 3 in Ke‘ehi Lagoon Park.
PHNB Station Continue erection of platform girder forming system.
Await fabrication and delivery of structural steel in June 2020.
HIA Station Continue construction of hammerhead for Pier 542. Start foundations for TCCR and Ancillary Building.
Form pit walls for Elevators 1-3. LD Station Install additional underground conduits from TCCR to
handhole on the Mauka side. MSTC Station Complete the final drilled shaft for the TCCR and 2
remaining drilled shafts for the pedestrian bridge.
Honolulu Rail Transit Project Monthly Progress Report March 2020
56 | P a g e
KEY ISSUES:
Key Issues with Contractor Proposal Title CPC Code
Lagoon Dr Station - Additional Infrastructure for Interim Opening Part II
HIA Site Redevelopment
Inefficient Utility Claim
B B C
LEGEND: A = less than $1 million; B = $1 million-$5 million; C = greater than $5 million; P = pending contractor submittal ________________________________________________________________________________________________________________________________________________________________________________________________________________________
KEY MILESTONES: Gantry 3 main girder was lifted on Span 3 on March 13, 2020. Span 527 (40% complete) was completed on March 13, 2020. MSTC Station Pedestrian Bridge (in the middle of Dillingham Boulevard) drilled shaft completed on March 16,
2020. HDOT-A Comm infrastructure (critical to clear shafts in front of CONRAC) was completed on March 24, 2020. Segment 2,500 (92% complete) was cast on March 31, 2020. Column 505 (linked to the critical path) was completed on March 31, 2020.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
QUALITY MANAGEMENT:
Pre-Activity Meetings continue.
AGS NCR Log (Issued by STG)
NCRs Issued to Date
Closed Open
Guideway 292 220 72 Pearl Harbor Naval Base Station 29 18 11 Honolulu International Airport Station 25 18 7 Lagoon Drive Station 12 9 3 Middle Street Transit Center Station 6 1 5 Contract Wide 15 15 0 TOTAL 379 281 98
Honolulu Rail Transit Project Monthly Progress Report March 2020
57 | P a g e
4.5 Section IV – City Center: Middle Street Transit Center Station to Ala Moana Center A. City Center Section Utilities and Guideway
CPP No.: FD-530 Contractor: AECOM Technical Services, Inc., Final Design Consultant (Engineer of Record) Contract Start Date: July 2012 Contract Substantial Completion: July 2020 Projected Completion of Work: July 2020
Project Description: The original City Center Section Utilities and Guideway (CCUG) final design contract consisted of utility relocations, roadway widening, and 4.12 miles of elevated transit guideway serving eight (8) passenger stations. The scope of the CCUG contract has been reduced to include only the design of utility relocations and roadway widening to facilitate future guideway design and construction by others. The remaining work is herein referred to as the City Center Utilities Relocation (CCUR) design.
Progress Schedule Status
Based on Expenditures* 97.7% On time (based on contract substantial completion date)**
Early Plan* 100%
Late Plan* 99.9% *Data as of March 27, 2020. **Further explanation is provided in the Schedule section.
_______________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$191,227
DBE % Attained: 0.33%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $13,941,087
None N/A ---
Cumulative Current Report $13,941,087
SCHEDULE: Due to changes to save cost and delays by third party reviews, CCUR final design is scheduled to conclude in early
third quarter 2020. The completion date is July 31, 2020. __________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: Coordination with City and utility third parties to address review
comments for Task Orders (TOs) within the review process: TO2B Draft Rev. 1 (2/26/20), TO23A Draft Rev. 0 (2/7/20), TO23B Rev. E (2/14/20), TO26 Rev. D (3/16/20), TO32 Draft Rev. 0 (2/11/20), TO24 Draft Rev. 0 (3/23/20), TO28 Draft Rev. 0 (3/16/20), and the Roadway Package Issued for Construction (IFC) V2 (2/19/20).
Look Ahead: Complete and submit final design
drawings for TOs 17, 22, 24, 23A, 23B, 32, 25, 28, 2 and 13.
Continue coordination with third parties on seeking variances to allow reduced spacing between utilities relative to preferred spacing requirements, especially on Dillingham.
Original Contract: $43,948,220 Incurred-to-Date: $57,489,264
Current Contract Value¹: $57,889,307 Incurred in March: $465,370 1Current Contract Value = Original contract value with Design Allowance + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
58 | P a g e
Activities this Month (continued): Design Package submittals/resubmittals this month included: TO22
DRAFT Rev. 0 V2 to DTS on 3/2/20. TO26 Rev. D to DTS, City agencies and utilities on 3/16/20. TO28 Draft Rev. 0 to DTS and utilities on 3/16/20. TO24 DRAFT Rev. 0 to DTS and utilities on 3/23/20.
Received official comments for TO2B Draft Rev. 1 from Hawai‘i Gas (3/23/20); TO22 Draft Rev. 0 V2 from AT&T Corp. (3/12/20), Hawaiian Telcom (HTI) (3/17/20), Charter (3/20/20), HECO (3/27/20) and DTS (3/30/20); TO23A Draft Rev. 0 from Charter (3/6/20), DTS (3/9/20), HECO (3/11/20), AT&T Public Sector Solutions (PSS) (3/11/20), HDOT (3/19/20) and HTI (3/31/20); TO23B Draft Rev. 0 from AT&T Corp. (3/4/20), DTS (3/11/20), Charter (3/9/20) and HTI (3/31/20); TO26 Rev. D from Charter (3/27/20); TO27 Draft Rev. 0 from Charter (3/6/20), HECO (3/9/20) and HDOT (3/19/20); TO32 Draft Rev. 0 from Charter (3/9/29), HECO (3/16/20), DTS (3/20/20); TO17 Draft Rev. 0 from HTI (3/4/20), Charter (3/9/20) and DTS (3/20/20); TO28 Draft Rev. 0 from HTI (3/24/20) and Charter (3/31/20); Traffic Signals/Street Lights – Dillingham 1 from DPP (3/13/20); Traffic Signals/Street Lights – Kakaako from DPP (3/24/20); Traffic Signals/Street Lights – Nimitz from HDOT (3/3/20) and Roadway IFC Rev. 3 from DTS (3/13/20).
Continuing coordination with HECO and other concerned third party utility agencies (i.e. Board of Water Supply [BWS], HTI, etc.) to finalize utility concerns and comments for pending design package submittal.
Continued coordination with other agencies with projects within City Center, as well as landowners and their consultants/contractors for development projects.
Continued support during construction via Request for Information (RFI) with CCUR contractors.
Continued coordination with utilities for all utility layouts for remaining dry utility task order packages, Traffic Signal and Street Light, as well as the final Roadway Packages.
Coordination with City and State agencies to process One-Time Review (OTR) and required permit approvals to allow construction to start.
Continued coordination with ROW team for ongoing negotiations for acquisitions.
Continued coordination and bi-weekly meetings with the DPP Director and staff for ongoing design task order packages review.
Look Ahead (continued): Third party review and comments for
Task Orders 27, 24, 17, 28, 2, 13, 26, 25, Street Lights and Traffic Signal, and Roadway Packages.
Finalize details for 138kV steel pole foundation design.
Finalize details for micropile needed for 138kV / BWS facilities crossing(s) on Dillingham Boulevard.
Finalize hydraulic/hydrology analysis for Kapalama Canal change order.
Fourteen submittals in the upcoming month are expected.
Negotiations for a change order to extend the contract to the end of CCUR for design services during construction, as well as final submittal packages.
____________________________________________________________________________________________________________________________________________________________________________________
KEY ISSUES (new issues are in bold font): Working through details and finalizing cost and schedule impact for the following proposals already submitted as a
change in scope: (1) 138kV pole foundation design, (2) micropile structure design for crossings of 138kV and 42” waterline facilities, (3) management scope, (4) repackaging of Task Orders and (5) Design Services During Construction (DSDC) work to date. These will be processed accordingly, per HART change procedures.
HART is working with third party utilities as well as City agencies to better streamline reviews to prevent further slippage in design schedules.
____________________________________________________________________________________________________________________________________________________________________________________
KEY MILESTONES: Submittal of TO22 DRAFT Rev. 0 V2, TO26 Rev. D, TO28 Draft Rev. 0 and TO24 DRAFT Rev. 0, as per schedule.
Honolulu Rail Transit Project Monthly Progress Report March 2020
59 | P a g e
B. City Center Utilities Relocation (CCUR) Indefinite Delivery/Indefinite Quantity (IDIQ) CPP No.: DBB-511 Contractor: Nan, Inc. Contract Start Date: May 2018 Contract Term Completion: May 2022 Projected Completion of Relocation Work: September 2022
Project Description: The CCUR contract is a unit priced, task order contract that relocates utilities in advance of the City Center Guideway and Stations construction work. It provides utility relocation construction services for a variety of utilities along the civil roadway construction throughout the City Center segment of the HRTP. The construction services to be provided will include, but are not limited to, permanent and temporary wet and dry utility relocation work which will include miscellaneous, as-needed site work, installation of permanent/temporary utility poles, duct bank construction, and other utility installation support structures.
Progress Schedule Status
Physical % Complete* 7.5%**
4 months behind*** Early Plan* 46.2%
Late Plan* 36.1% *Data as of March 27, 2020. **The % complete is for work in place and does not include eliminated scope. HART is currently reviewing the EAC submitted by CEI in March for all the work required prior to the P3 contractor commencing their work; budget and percent complete are subject to change. ***The Execution Plan has been updated to reflect the most current strategies to execute the work and status of progress.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
DBE Participation Task Orders
Actual DBE Participation: $0 Number of Task
Orders Issued Amount ($)
DBE % Attained: 0% Task Orders Previously Issued 14 $378,994,598
Task Orders Issued this Month 0 $0
Amendments to Task Orders 0 $0
Total Task Orders Issued 14 $378,994,598
Original Contract: $400,000,000 Incurred-to-Date: $22,789,550
Current Contract Value¹: $400,000,000 Incurred in March: $772,622 1Current Contract Value = Original contract value + executed Change Orders
Honolulu Rail Transit Project Monthly Progress Report March 2020
60 | P a g e
SCHEDULE: Mitigations have been incorporated into the schedule accounting for the Projected Completion of CCUR
Relocation Work to remain September 2022, including: o Allowance for concurrency of specific activities o Trenching permits based upon approved 90% design, ahead of IFC o Early long lead material procurements based on approved 90% design and bulk purchasing o Defined 138kV pole procurement – this is critical and impacting interim Area 1A completion, but has
not impacted the overall project completion o Temp connections o Descoping of certain civil improvements that would be more appropriately performed by the P3
contract. Interim completions of Areas 1A and 5 have moved out 29 calendar days and 8 calendar days respectively.
Explanations are included in the Key Issues section below. Cleared 22% of proposed shaft locations, based on current design decisions. All Traffic Signals and Street Lights 90% design submitted by April 2020. 90% design complete – mid-Q3 2020. All Wet Utility task orders under construction Q3 2020. All Dry Utility task orders under construction Q3 2020. HECO completes all electrical design requirements Q4 2020. Final roadway revision encompassing all changes Q2 2020.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: All Area 1: Dillingham Controlled Access Traffic Management
Plan (TMP) Technical Memorandum has been accepted conditionally allowing for implementation of the first phase in Area 1A, and the traffic control plans (TCPs) and temporary traffic signal plans (TTSPs) are in review for implementation of subsequent phases by HART, DTS and HDOT. 138kV pole procurement duration mitigation is critical. Expedited delivery is only possible if HECO places the order for 138kV poles through their ‘alliance agreement’. HECO has not agreed and the issue has been raised to HART management for further resolution.
Area 1A: Dillingham Controlled Access in place as planned on March 24, 2020. HECO has agreed to allow HART to work at risk starting in early April with the Draft Rev. 0, 90% design submittal plans dated Feb. 28, 2020. AT&T and HTI infrastructure work continues. AT&T temporary connection proposal submitted to AT&T March 24, 2020 for their review.
Area 1B: Kapalama Utility Bridge 90% comments received and being compiled. Kapalama Canal Stream construction access letter finalized Monday, March 30, 2020. Box culvert potholing and bypass plan to facilitate demolition is being reviewed. The Public Outreach Office is fully operational as of March 31, 2020.
Area 1C: Initial dry design plans (Rev. D) for TO-26 submitted as expected. TO-13 (wet) and TO-25 (dry) are delayed due to HECO ampacity and reinforcement details.
Look Ahead: All Area 1: HART will provide regular updates
and address with HDOT and DTS, the actions, progress and status of open comment resolution items outlined in the Dillingham Controlled Access TMP Technical Memo, including the implementation commitments of key management mitigation measures.
Area 1A: Obtain HECO approval of duct bank structural reinforcement near the columns. Hold HECO infrastructure Pre-Construction meeting prior to work commencing. AT&T temporary connection comments expected early-April. Begin HECO low-risk duct bank work.
Area 1B: Box culvert bypass and demolition plan to be accepted and work expected to begin by the end of April. Replacement box culvert shop drawings and procurement to commence in April. Wet and dry OTR requested by the end of April. Targeting June 2020 to start Kapalama Bridge construction.
Area 1C: Initial Rev. D design plans for TO-13 (wet) and TO-25 (dry) are expected. Rev. D Traffic Signal & Street Light package submittal to follow. HART to independently verify the arborist’s recommendation for the potential removal of mauka Kamani trees.
Honolulu Rail Transit Project Monthly Progress Report March 2020
61 | P a g e
Activities this Month (continued): Area 2: Contractor performing soil stabilization/
groundwater control through jet grouting to prepare for trenching of new duct lines and manholes below the water table. Manholes shipping to site for installation in the next month.
Area 3: Permitting in place to perform both day and nighttime operations. Demolition of existing sewer and waterline continues to clear future guideway foundations. Eight historic walls were discovered; Cultural Surveys of Hawai‘i, Inc. is handling the next steps to clear conflicting portions for new work, with removal approval already started. Obtained TO-27 (dry) OTR.
Area 4: Dry design (TO-24) Draft Rev. 0 design submittal received March 23, 2020, slipping 4-weeks due to service reconnection redesign and easement resolutions, with urgent design and easement discussions occurring with HECO. Obtained OTR for Kaka‘ako Traffic Signal & Street Light package on March 27, 2020.
Area 5: NTP was issued to commence work pending approved work plans, permitting and finalization of task order pricing for wet and dry utilities. Delay in obtaining TO-16 (dry) trenching permit, due to expired utility signatures, expected early next month.
Area 6: Contractor continuing waterline work and soil stabilization/jet grouting of trenches below water table and existing large drainage structures. HECO exposing the excess Fluidized Thermal Backfill surrounding the 138kV commenced on March 23, revealing dry utility conflicts. HART is analyzing the feasibility of shifting pier 798 due to insufficient headspace to cross above the 138kV duct bank as expected. TO-28 (dry) Draft Rev. 0 Infrastructure design submittal received on March 16, 2020, as anticipated.
Look Ahead (continued): Area 2: HECO manholes to begin installation in
April. Epoxy coating substitute to be finalized with HECO. Nan to be granted temporary access to DAGS as an equipment only storage area.
Area 3: TO-27 (dry) comment resolution cut sheets anticipated with IFC expected by the end of April. Draft Rev. 0 Traffic Signal (TS)/Street Light (SL) expected. Demolition/removal of existing and abandoned utilities and new infrastructure to continue. Finalization of Task Order 27 scoping and negotiations for at-risk work NTP to include soil stabilization jet grouting for trenching.
Area 4: Negotiation of Task Order scope of work to be scheduled for the work area between Richards and Cooke. Obtain TO-32 (dry) comment resolution cut sheets and OTR.
Area 5: Obtain TO-16 (dry) trenching permit. Commence wet and dry utility relocation and civil improvements.
Area 6: HART decision on pier 798 shift critical to progress of current waterline construction. Nan to continue waterline and commence communications duct work. Jet grout stabilization work anticipated to be complete no later than mid-April 2020. Contractor continues to work with Ala Moana Center property owners to extend their day construction work hours due to COVID-19 closings, and considerable reduction in traffic volumes.
__________________________________________________________________________________________________________________________________________________________
KEY ISSUES (new issues are in bold font):
Cost or schedule for the CCUR contract may be impacted significantly if these issues aren’t resolved: o Design Finalization: Completion of the dry utility plans by AECOM, and approval by the utilities. Design
decisions are being finalized and incorporated into plans and profiles for review and approval by utilities. CCUR Area Target Finish dates continue to be impacted by extended completion of IFC design due to ongoing and additional outstanding comment resolution items from the reviewing parties. Mitigations to the construction schedule have been incorporated to compensate and improve the projected completion, however final design approvals are critical to meeting the projected construction duration.
o Mitigation efforts: AECOM is scheduled to complete 90% submittals by Q3 2020. The review time is subject to the City and third parties’ review and interface. AECOM is coordinating with utility agencies to shorten the remaining design review process by holding informal comment resolution review sessions. HART is continuously strategizing with utility stakeholders on steps to shorten review and approval response time. In parallel, HART, CEI and Nan along with the utility stakeholders, are analyzing and agreeing on work scope that can start at limited risk based on current design levels to mitigate IFC design schedule extensions.
o HART Right-of-Way: Currently working to complete acquisition of property within CCUR. Current focus is on the following properties: Takara Printing, Bishop Estate – Club Cleopatra, Iwilei Station - HECO, General Services Administration (GSA) – Halekauwila St. by Mililani St., Howard Hughes and Ka’a Ltd Partnership.
Honolulu Rail Transit Project Monthly Progress Report March 2020
62 | P a g e
o Mitigation efforts: DAGS is considering allowing HART minimal early access for equipment only staging with a decision expected in early April. Honolulu Community College (HCC) anticipated acquisition to be completed by Q2 2020. Contractor provided the required Temporary Construction Easements (TCE’s) to incorporate into the final HCC agreement. Due to current COVID-19 economic circumstances, Takara is considering no longer relocating. HART is considering (3) options with a meeting anticipated in early April for temp access for front demo front and reface. Access to Kapalama Canal Utility Bridge easement transfer was finalized March 30, 2020, with utility bridge plans. IFC plans anticipated beginning Q3 2020. The opportunity of horizontal directional drilling (HDD) utilities across Kapalama Canal has passed. An ICE was requested by the contractor, however the timeframe to complete the necessary documents to determine if this is a feasible option have yet to be received.
o Permitting: Trenching and street usage permits are taking a significant amount of time and coordination to obtain. The contractor is doing what they can to respond to concerns and issues, however concerns such as controlled access along Dillingham require more time for planning and higher-level agreements. These efforts are currently underway in order to ensure a high degree of collaboration amongst all stakeholders.
o Mitigation efforts: Weekly meetings are held between HART and DTS to discuss and work through upcoming and expected issues. To assist in review and approvals, a third-party consultant authorization was finalized on March 31, 2020 to begin reviewing Traffic Control Plans in order to expedite permitting on behalf of the City.
o HECO Agreements: The Nov. 25, 2013 agreement with HECO allows HECO to complete the electrical design up to 2 years after receiving the final infrastructure design. Completion of relocation activities relies on more aggressive completion durations in order to meet the project’s needs. HART and HECO continue to work together to ensure the construction schedule is met. A general agreement was in place, as of Q4 2019, to expedite electrical design times to meet schedule needs.
o Mitigation efforts: HART and HECO meet bi-weekly to review schedule assumptions and requirements to maintain and improve the schedule based on the general agreement. Regular, informal communications occur on a daily basis. Based on the Feb. 24, 2020 meeting between HECO and HART, HECO agreed to allow HART to work at risk with true 90% design submittal plans.
o Long lead Material Procurement: Estimates for the duration of long lead materials have been adjusted in the schedule based on information provided by HECO for electrical equipment to be purchased under the CCUR contract. These corrected durations have contributed to the critical paths associated with CCUR Area Target Finish dates. The 138kV pole procurement cycle is driving the completion of Area 1A, which has moved out from 01OCT21 to 30OCT21 because the pole calculations from the supplier were not accepted by HECO and require an additional submittal cycle. The delivery duration Nan has been quoted by the supplier left zero float in the schedule prior to HECO’s rejection of the calculation submittal. HECO has required that HART and its contractors are solely responsible for all material procurement orders and there is currently no exception for this order. HECO receives preferred delivery durations (several months less than what Nan was quoted), when they order the poles under their alliance agreement with the supplier. Further delays may result in the requirement for an overlap agreement with HECO to allow the 138kV to remain aerial during the guideway build. Final review and acceptance by HECO of the 90% status for TO 17 dry utilities package in Area 5 is preventing the Long Lead Material Procurement from starting, impacting the Area 5 completion date, which has moved out from 01APR21 to 09APR21.
o Mitigation efforts: HART’s request for HECO to order long-lead 138kV poles on HART’s behalf has been raised to HART’s senior management. For all other electrical materials for this project, HART CEI will work with Nan who will expedite the orders timely and coordinate with HECO regularly to obtain the additional listings as HECO is provided the infrastructure designs necessary to begin their electrical design and develop the lists.
Honolulu Rail Transit Project Monthly Progress Report March 2020
63 | P a g e
KEY MILESTONES:
Construction Status1
NTP Target Finish2 Installed Complete3
Area 1A: Dillingham: Middle to Mokauea 20-Sep-19 30-Oct-21 3.1%
Area 1B: Dillingham: Mokauea to Waiakamilo 20-Sep-19 07-Sept-22 0.7%
Area 1C: Dillingham: Waiakamilo to Ka‘aahi 01-Feb-20 01-Aug-22 0.5%
Area 2: Ka‘aahi Street 02-Feb-19 12-Jan-21 23.0%
Area 3: Nimitz Highway 20-Sep-19 04-Aug-21 7.5%
Area 4: Halekauwila Street 24-Jan-20 28-Apr-22 0.4%
Area 5: Queen Street 01-Oct-18 09-Apr-21 2.4%
Area 6: Kona Street 01-Mar-19 01-Jul-21 10.0%
1 Based on 3/31/2020 data date. Multiple Design Packages are incorporated into each area. 2 Based on double shifts, 6 days per week, 10 hours per shift. 3 HART is currently reviewing the Estimated Cost at Completion submitted by CEI in March for all the work required prior to the P3 contractor commencing their work. The percentages shown are based on the current contracted amount. __________________________________________________________________________________________________________________________________________________________
QUALITY MANAGEMENT: No major quality issues identified this period.
CCUR NCR Log (Issued by Nan)
Total NCRs Issued to Date Closed Open
8 5 3
Honolulu Rail Transit Project Monthly Progress Report March 2020
64 | P a g e
4.6 Project-Wide A. Program Management Contractor Contract
CPP No.: MM-902 Contractor: HDR Engineering, Inc. Contract Start Date: January 1, 2017 Contract Completion Date: December 31, 2022 Description of Work: Oversee the successful design and construction of the full Honolulu Rail Transit Project (HRTP), which includes providing personnel with relevant transit design, construction and operations experience and leadership in the various areas, including construction management, design management, project controls, procurement and contracts, right of way, public and business outreach, safety and security, quality assurance, environmental planning, and federal programmatic compliance.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation: $201,339
DBE % Attained: 0.32%
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $0
None N/A ---
Cumulative Current Report $0
*Monthly actuals are based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS.
Jan
-17
Mar
-17
May
-17
Jul-
17
Sep
-17
No
v-1
7
Jan
-18
Mar
-18
May
-18
Jul-
18
Sep
-18
No
v-1
8
Jan
-19
Mar
-19
May
-19
Jul-
19
Sep
-19
No
v-1
9
Jan
-20
Mar
-20
May
-20
Jul-
20
Sep
-20
No
v-2
0
Jan
-21
Mar
-21
May
-21
Jul-
21
Sep
-21
No
v-2
1
Jan
-22
Mar
-22
May
-22
Jul-
22
Sep
-22
No
v-2
2
Actual $ Per Month Forecast $ Per Month Actual % Forecast %
Actual 60.0 %
03/2020
Original Contract: $63,522,953 Incurred-to-Date²: $37,501,959
Current Contract Value¹: $63,522,953 Incurred in March: $1,931,524
1Current Contract Value = Original contract value + executed Change Orders 2Incurred-to-Date based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS
Honolulu Rail Transit Project Monthly Progress Report March 2020
65 | P a g e
WORK PROGRESS: Activities this Month:
21 HDR staff contracted through HART. Look Ahead:
Continue to support the design and construction of the HRTP, including assessing management needs in Project Controls.
KEY ISSUES:
Based on the average monthly expenditure rate, the current contract total will be exhausted by June 2021.
Subcontractor charges paid to date (from beginning of contract) is $5,331,816.61.
Honolulu Rail Transit Project Monthly Progress Report March 2020
66 | P a g e
B. Construction Engineering and Inspection (CEI) West CPP No.: MM-290 Contractor: PGH Wong Engineering, Inc. Contract Start Date: January 9, 2014 Contract Completion Date: July 7, 2020 (Amendment #4) Note: West CEI and HART are in the process of implementing Amendment #5 to add staffing budget and extend West CEI Services through December 2020 to enable West CEI Services to complete station contracts closeout due to continuing delayed completion of the construction contract works. This Amendment was being routed for signature at the end of March. Description of Work: Provides construction, engineering, and inspection services for construction contract compliance, construction scheduling, construction cost estimating, support, on-site field oversight, project controls and related construction support for the west section of the project.
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$11,964,758
DBE % Attained:
13.26%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $36,000,000
None N/A ---
Cumulative Current Report $36,000,000
* Monthly actuals are based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS.
Jan
-14
Feb
-14
Mar
-14
Ap
r-1
4
May
-14
Jun
-14
Jul-
14
Au
g-1
4
Sep
-14
Oct
-14
No
v-1
4
Dec
-14
Jan
-15
Feb
-15
Mar
-15
Ap
r-1
5
May
-15
Jun
-15
Jul-
15
Au
g-1
5
Sep
-15
Oct
-15
No
v-1
5
Dec
-15
Jan
-16
Feb
-16
Mar
-16
Ap
r-1
6
May
-16
Jun
-16
Jul-
16
Au
g-1
6
Sep
-16
Oct
-16
No
v-1
6
Dec
-16
Jan
-17
Feb
-17
Mar
-17
Ap
r-1
7
May
-17
Jun
-17
Jul-
17
Au
g-1
7
Sep
-17
Oct
-17
No
v-1
7
Dec
-17
Jan
-18
Feb
-18
Mar
-18
Ap
r-1
8
May
-18
Jun
-18
Jul-
18
Au
g-1
8
Sep
-18
Oct
-18
No
v-1
8
Dec
-18
Jan
-19
Feb
-19
Mar
-19
Ap
r-1
9
May
-19
Jun
-19
Jul-
19
Au
g-1
9
Sep
-19
Oct
-19
No
v-1
9
Dec
-19
Jan
-20
Feb
-20
Mar
-20
Ap
r-2
0
May
-20
Jun
-20
Jul-
20
Actual $ Per Month Forecast $ Per Month Actual % Forecast %
Actual 97.0%
03/2020
Original Contract: $54,232,480 Incurred-to-Date²: $87,547,371
Current Contract Value¹: $90,232,480 Incurred in March: $497,036
1Current Contract Value = Original contract value + executed Change Orders 2Incurred-to-Date based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS
Honolulu Rail Transit Project Monthly Progress Report March 2020
67 | P a g e
WORK PROGRESS: Activities this Month: Resident Engineers (REs) provided the weekly project status and
issues briefings at the weekly HART Project Managers (PM) meetings.
RE’s managed assigned projects as the HART on-site field representatives for CEI, managing contract correspondence and contract change administrative processes, issuing Field Change Notices (FCNs) when required, and overseeing work.
Continued monitoring fabrication of Hālawa (Aloha Stadium) Station canopy supports and installation of the canopies at FHSG and KHSG stations.
Updated Monthly Progress Report Dashboards for all stations. Work-off of backlogged claims and changes progressed. Continue implementation of contract closeout processes for
WOSG and FHSG in anticipation of completion by the end of 2nd quarter 2020.
Look Ahead: Turning over infrastructure to allow
Core Systems to continue their installation.
Continue to monitor and track station canopy fabrication and installation activities.
Oversee construction of assigned projects.
Closeout the UH West O‘ahu Park and Ride & UHWO Campus Road “B” (UHPRB) contract.
Continue closeout processes for WOSG and FHSG contracts and start them for KHR.
Change Orders Processed
CONTRACT FOM NSM SON CCO
UHPRB 1 0 1 0
WOSG 0 0 1 2
FHSG 1 0 0 0
KHSG 1 1 0 0
KHR 1 0 0 0
_______________________________________________________________________________________________________
KEY ISSUES:
The COVID-19 pandemic is impacting delivery of the contracted station works; mitigation for which is not yet defined.
Completing Core Systems access requirements and balance of structures conduit for CSC follow on work.
Continuation and completion of canopy installations.
Continue working-off of backlog of outstanding claims/change issues.
Honolulu Rail Transit Project Monthly Progress Report March 2020
68 | P a g e
C. Construction Engineering and Inspection (CEI) East CPP No.: MM-596 Contractor: Stantec Consulting Services Inc. Contract Start Date: September 14, 2015 Contract Completion Date: December 31, 2021 Description of Work: Provides construction, engineering, and inspection services for construction contract compliance, construction scheduling, construction cost estimating, support, on-site field oversight, project controls and related construction support for the east section of the project.
_______________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$22,321,813
DBE % Attained:
21.88%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $47,000,000
None N/A ---
Cumulative Current Report $47,000,000
* Monthly actuals are based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS.
Sep
-15
No
v-1
5
Jan
-16
Mar
-16
May
-16
Jul-
16
Sep
-16
No
v-1
6
Jan
-17
Mar
-17
May
-17
Jul-
17
Sep
-17
No
v-1
7
Jan
-18
Mar
-18
May
-18
Jul-
18
Sep
-18
No
v-1
8
Jan
-19
Mar
-19
May
-19
Jul-
19
Sep
-19
No
v-1
9
Jan
-20
Mar
-20
May
-20
Jul-
20
Sep
-20
No
v-2
0
Jan
-21
Mar
-21
May
-21
Jul-
21
Sep
-21
No
v-2
1
Actual $ Per Month Forecast $ Per Month Actual % Forecast %
Actual 64.1 %
03/2020
Original Contract: $55,036,130 Incurred-to-Date²: $65,418,635
Current Contract Value¹: $102,036,130 Incurred in March: $2,866,318
1Current Contract Value = Original contract value + executed Change Orders 2Incurred-to-Date based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS
Honolulu Rail Transit Project Monthly Progress Report March 2020
69 | P a g e
WORK PROGRESS: Activities this Month: Current Stantec East CEI support for the HRTP is at
approximately 64.1% of total contract value. Performed CEI services for the AGS DB, On-Call III, On-Call
IV, CCGS DB/P3, and CCUR projects throughout the east section project limits.
Implemented COVID-19 safe work practices in the field and at all project office locations.
AGS DB overall construction progress is at 62% - Guideway progress is at approximately 65%, and Stations are at approximately 9%.
Station shaft progress is at approximately 85% and structural steel is under construction.
AGS rail transportation plan and schedule: STG hauled all strings from LCC to AGS.
Provided detailed schedules relating to multiple scenarios for the CCUR construction activity required in support of the P3 access dates.
Provided CEO consultant evaluation summary of Stantec contract for construction progress of ongoing projects along the East Section.
Look Ahead: Working with HART to monitor construction
progress in support of the current substantial completion dates for ongoing AGS DB and CCUR projects.
Continuing to monitor staff resources and overall East CEI II project budget with additional HART scope requests.
Continue to work with HART in support of construction completion to support the P3 planned activities.
Supporting HART with the potential addition of a second contractor for CCUR to include the review of phasing, CEI II staffing, and potential schedule improvements to support the P3 planned activities. Working with HART PM to update organizational structure to meet planned construction activities.
Continuing to identify a Public Involvement (PI) manager to replace the manager who left the project – interviews conducted and finalizing candidate selection.
_______________________________________________________________________________________________________
KEY ISSUES:
No current contractual issues.
Honolulu Rail Transit Project Monthly Progress Report March 2020
70 | P a g e
D. General Engineering Consultant CPP No.: MM-913 Contractor: CH2M Hill, Inc. Contract Start Date: December 5, 2013 Contract Completion Date: July 4, 2021 Description of Work: Task 01 – Scheduling and Estimating Support: Task Order 01 provides staff augmentation to support scheduling and cost estimating services through the design and construction phase of the Project.
Task 02 – Interface Management and Coordination: Provide oversight of technical coordination and Configuration Management.
Task 03 – Environmental and Planning: Provide environmental and planning support to ensure compliance with appropriate decision documents for the Project; integration with other applicable state or city entities for systems, station, land use, and operation planning.
Task 04 – Design Management Services: Engineering and architectural design management services for the duration of the project.
Task 05 – Program Management and Deliverables: Program Management services throughout the entire duration of the Project to include, but not limited to the Work Breakdown Structure, Budget Staffing Plan, Monthly Progress and Status Reports, and Contract Administration.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
Task Description Original Value Current Value Incurred-to-Date
1 Scheduling and Estimating Support $13,187,310 $22,556,723 $18,768,737
2 Interface Management and Coordination $5,644,829 $4,097,085 $3,441,971
3 Environmental and Planning $6,537,705 $20,303,965 $12,238,170
4 Design Management Services $16,986,250 $34,866,501 $29,068,178
5 Program Management and Deliverables $2,434,232 $1,565,057 $1,322,971
OD Other Direct Expenses $1,352,951 $1,339,444 $978,618
Total $46,143,277 $84,728,775 $65,818,643
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$7,644,864
DBE % Attained: 9.02%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $38,585,498
None N/A ---
Cumulative Current Report $38,585,498
Original Contract: $46,143,277 Incurred-to-Date²: $65,818,643
Current Contract Value¹: $84,728,775 Incurred in March: $581,232
1Current Contract Value = Original contract value + executed Change Orders 2Incurred-to-Date based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS
Honolulu Rail Transit Project Monthly Progress Report March 2020
71 | P a g e
* Monthly actuals are based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
WORK PROGRESS: Activities this Month: Look Ahead: Task 01: Produced February schedule updates for PMOC meetings. Outlined
schedule updates and progress. Maintained HART’s Master Project Integrated Schedule (MPIS);
December 2025 Substantial Completion with 104 days of contingency. Operation Readiness – Segment 1 Turnover date is Oct. 20, 2020.
Provided review and analysis of STG’s Over the Shoulder Mitigation Schedules.
Reviewed Elevators & Escalators schedule for coordination of installation activities in the station contracts.
Continued supporting Design and Construction with City Center Utility and Guideway/Station coordination of activity predecessors.
Provided Independent Cost Estimate (ICE) Cost to Complete for the following: o Kualakai Intersection Signage & Markings o Build Future Elevator Shafts at Stations o KHR Guardrail Extension Rev0 o KHR Guardrail Extension Rev1 o Waipahu Station Entrance Module Rev5
Produced Monthly Internal Schedule Progress Report. Report outlines progress on all ongoing projects.
Continued the implementation of existing HART projects into the Oracle Unifier system.
Continued validating previous CCUR vendor invoices to reconcile with the Oracle Unifier system.
Reviewed all Detail Forecast Worksheets for month-end reporting, updated variance report for the forecast sheets, and made notes as required. Completed monthly EAC requirements.
Reviewed request for payment for all Professional Services and Construction contracts – ensured proper coding.
Began to review all ROW transactions to ensure that Tax Map Keys (TMKs) and parcels completed encompass required/approved tasks. Data is compiled independent of the ROW Team and then checked for reasonableness versus the executed transaction.
Task 01: On-going support of ICE development or reviews of
cost estimates prepared by the CEI team for independent quality assessments. The following are projected ICE’s: o Update quantity takeoffs and Costs for CCUR
Wet/Dry Utility Task Orders o ICE for UH West O‘ahu Entrance Building and
UH West O‘ahu Park & Ride o Pearl Highlands Station Elevated Pedestrian
Walkway o ICE for Requests for Change from Contractor
(RFCC’s) and Requests for Change by HART (RFCR’s)
o Additional P3 Requirement Cost development o FOM/Negotiation Strategy Memo (NSM)
Review and Approval Continue updates of Monthly Schedule reports and
analysis. Evaluate the AGS mitigation schedule and added
schedule details on stations. If accepted, incorporate the update into the MPIS.
Research and audit projects around the review of all AECOM billing and On-Call construction projects to analyze and develop “benchmark pars” for material utilization, equipment, and manpower since inception.
Continue to refine ROW Asset Review Project to ensure that HART has all the confirmed, estimated and “pro forma” tasks listed for the entire 20-mile project.
Continue to implement the existing HART projects into the Oracle Unifier system.
Dec
-13
Jan
-14
Feb
-14
Mar
-14
Ap
r-1
4M
ay-1
4Ju
n-1
4Ju
l-1
4A
ug-
14
Sep
-14
Oct
-14
No
v-1
4D
ec-1
4Ja
n-1
5Fe
b-1
5M
ar-1
5A
pr-
15
May
-15
Jun
-15
Jul-
15
Au
g-1
5Se
p-1
5O
ct-1
5N
ov-
15
Dec
-15
Jan
-16
Feb
-16
Mar
-16
Ap
r-1
6M
ay-1
6Ju
n-1
6Ju
l-1
6A
ug-
16
Sep
-16
Oct
-16
No
v-1
6D
ec-1
6Ja
n-1
7Fe
b-1
7M
ar-1
7A
pr-
17
May
-17
Jun
-17
Jul-
17
Au
g-1
7Se
p-1
7O
ct-1
7N
ov-
17
Dec
-17
Jan
-18
Feb
-18
Mar
-18
Ap
r-1
8M
ay-1
8Ju
n-1
8Ju
l-1
8A
ug-
18
Sep
-18
Oct
-18
No
v-1
8D
ec-1
8Ja
n-1
9Fe
b-1
9M
ar-1
9A
pr-
19
May
-19
Jun
-19
Jul-
19
Au
g-1
9Se
p-1
9O
ct-1
9N
ov-
19
Dec
-19
Jan
-20
Feb
-20
Mar
-20
Ap
r-2
0M
ay-2
0Ju
n-2
0Ju
l-2
0A
ug-
20
Sep
-20
Oct
-20
No
v-2
0D
ec-2
0Ja
n-2
1Fe
b-2
1M
ar-2
1A
pr-
21
May
-21
Jun
-21
Jul-
21
Actual $ Per Month Forecast $ Per Month Actual % Forecast %
Actual 77.7 %
03/2020
Honolulu Rail Transit Project Monthly Progress Report March 2020
72 | P a g e
Activities this Month (continued): Task 02:
Configuration Management (CFM) and Closeout activities performed: o Prepared two draft checklists (detailed and abbreviated) of CFM
activities and documentation required of HRH for future verification assessment. Also, drafted a cover letter.
o Scheduled and chaired a meeting of the Configuration Control Committee. Also, wrote the meeting minutes and circulated to attendees for review.
o Had over 30 informal meetings, discussions or e-mail exchanges with various HART personnel to discuss strategies for development of a list of spare parts for the first two years of service; verifications of HRH’s compliance to CFM requirements; and closeout of the West Side Stations Groups (WSSG) contracts with special emphasis on the training being done by the contractors, and operations and maintenance manuals.
o Organized and chaired weekly Elevated Issues meetings for the WSSG contracts to address residual complex issues prior to closure.
Look Ahead (continued): Task 02:
CFM and WSSG Closeout activities that will be worked on are: o Provide further input on the list of spare parts for
the WSSG stations being prepared by HART. o Schedule, organize and chair meetings of the
HART Configuration Control Committee. o Attend Contract Change Committee meetings. o Continued refinement of the draft checklist for
verification assessment of the CFM activities and documentation being done by the Core Systems Contractor (HRH).
o Schedule, organize and chair weekly WSSG Elevated Issues meetings.
o Address review comments on the recent (2/2020) revision of the Configuration Management Plan.
Task 03: Permits – assisted in obtaining an extension of the 401 Water Quality
Certification for Waiawa Stream (to November 2024) and extension of the Stream Channel Alteration Permit (SCAP) for Kalihi Stream (to March 2025). Drafted a letter requesting an extension of the SCAP for Waiawa Stream (this request is being processed by the Commission on Water Resource Management).
Environmental Analyses and Documentation – submitted draft Environmental Review Documents for the Pouhala (Waipahu Transit Center) Station makai entrance and for a straddle bent pier in front of Kalihi Kai Elementary School on Dillingham Boulevard.
Programmatic Agreement (PA) Compliance – subconsultant HHF Planners submitted the final Cultural Landscape Report for Mother Waldron Park. The final report addressed 173 comments received from PA Consulting Parties and stakeholders
On-Call Support for Right of Way, Utilities, Environmental Planning – subconsultant Y. Ebisu & Associates reviewed a noise study commissioned by Blood Bank of Hawaii and validated noise levels reported in the project’s Final Environmental Impact Statement. Subconsultant Stephanie Chang Ink began developing brochures and other communication products to explain the project’s sustainability efforts, including the Sustainable Mobility (SuMo) Lab.
Task 03: Permits – complete stream-related permit applications
for the Kapalama Canal utility/pedestrian bridges, prepare SCAP application for AGS design changes in Kalihi Stream, and prepare WOFH community noise permit application.
Environmental Analyses & Documentation – complete draft 4(f) analysis for straddle bents affecting Mother Waldron Park. Prepare environmental review documents for straddle bents on Dillingham Boulevard in front of the six Quonset huts and for new staging areas known as “Iwilei Triangle” and “Ualena 5 Lots.”
PA Compliance – with subconsultants HACBED/Purple Maia, address comments on Stipulation VII educational products in response to review comments from the Consulting Parties.
On-Call Support for Right of Way, Utilities, Environmental Planning – assist with an application for a U.S. Department of Transportation (DOT) Better Utilizing Investments to Leverage Development (BUILD) Grant that seeks funding for the Waiawa (Pearl Highlands) Station pedestrian bridge and Pouhala (Waipahu Transit Center) Station makai entrance. The grant is being sought by the Department of Transportation Services. GEC is helping to assemble, summarize, and interpret data in the areas of safety, traffic, transit ridership, land use, and environmental impacts.
Task 04: Prepared a draft scope of work for corrective action to mitigate the erosion
at certain WOFH piers along Kaloi Channel and provided to the on-call contractor.
Coordinated work for the no-rise analysis of the proposed Waipahu Transit Center Station Makai Entrance Building to meet the City’s flood hazard ordinance.
Created Aesthetic Column station interpretive signage layouts, including the following tasks for each set: o Cleaned up Computer-Aided Design (CAD) drawings o Created Photoshop files for each sign to improve definition and detail o Vectorized each drawing in Illustrator for final layout of signage
Reviewed 13 design submittals, 37 NCRs, 7 Field Design Changes, and 6 Notice of Design Changes for the Airport Guideway and Stations contract. Attended Task Force Meetings, presubmittal workshops and comment resolution meetings.
Reviewed and commented on CCGS PLO Aesthetic Design Submittal and responded to RFI # 959, 998, 999, 1005.
Continuing designs on various scope gap items on the westside stations.
Task 04: Continue to provide engineering support to CCUR to
evaluate possible guideway configuration changes to minimize utility relocation costs.
Continue to provide technical support to the CEI team overseeing the Airport Guideway and Stations contract.
Continue participation in third-party coordination meetings (technical meetings and management meetings) for various contracts. Third parties include HECO, HDOT, Department of Health (DOH), Airport, Navy and UH West O‘ahu.
Continue to perform design reviews in support of the KHG 138kV undergrounding contract.
Continue to provide construction support for the Kamehameha Highway Resurfacing project.
Honolulu Rail Transit Project Monthly Progress Report March 2020
73 | P a g e
Activities this Month (continued): Task 05: Monitored contract labor and sub-consultant expenditures. Updated Monthly Estimate at Completion (EAC). Participated in preparation of monthly reports. Reviewed performance of all tasks based on attachments to invoice. Decided bi-weekly meetings would be telephonic. Received chart describing contract cost trends.
Look Ahead (continued): Task 05: Discuss five tasks. Continue to monitor contract labor and sub-consultant
expenditures. Update Monthly EAC. Participate in preparation of monthly reports. Discuss changes with scheduling staff.
________________________________________________________________________________________________________________________________________________________________________________________________________________________
KEY ISSUES: Task 01:
No current contractual issues. Task 02:
No current contractual issues. Task 03:
No current contractual issues. Task 04:
No current contractual issues. Task 05:
Contract extends through to July 4, 2021.
There is one option year remaining on the contract.
Honolulu Rail Transit Project Monthly Progress Report March 2020
74 | P a g e
E. Core Systems Support CPP No.: MM-962 Contractor: Lea+Elliott, Inc. Contract Start Date: February 11, 2014 Contract Completion Date: September 10, 2022
Description of Work: Provide design and construction management oversight for the Core System Design-Build-Operate-Maintain (CSDBOM) Contract, to include system commissioning, passenger services start-up, and pre-revenue operations and maintenance activities.
_______________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________
COST INFORMATION:
Disadvantaged Business Enterprise (DBE) Participation
Actual DBE Participation:
$1,657,513
DBE % Attained: 2.13%*
*Percentage has been adjusted to account for the
current contract value amount.
Contract Changes in March
Change No. Description Amount ($)
Cumulative Previously Reported $33,784,957
None N/A ---
Cumulative Current Report $33,784,957
* Monthly actuals are based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS.
WORK PROGRESS: Activities this Month: Project Management:
o Six (6) letters were received from HRH and reviewed. Nine (9) letters were finalized and issued by the Core Systems Oversight Consultant (CSOC).
o Worked on mobilizing additional resources.
Look Ahead: Continue to monitor, observe,
witness, and report on the Core Systems Contractor’s daily activities on-site and at the factories.
Feb
-14
Ap
r-1
4
Jun
-14
Au
g-1
4
Oct
-14
Dec
-14
Feb
-15
Ap
r-1
5
Jun
-15
Au
g-1
5
Oct
-15
Dec
-15
Feb
-16
Ap
r-1
6
Jun
-16
Au
g-1
6
Oct
-16
Dec
-16
Feb
-17
Ap
r-1
7
Jun
-17
Au
g-1
7
Oct
-17
Dec
-17
Feb
-18
Ap
r-1
8
Jun
-18
Au
g-1
8
Oct
-18
Dec
-18
Feb
-19
Ap
r-1
9
Jun
-19
Au
g-1
9
Oct
-19
Dec
-19
Feb
-20
Ap
r-2
0
Jun
-20
Au
g-2
0
Oct
-20
Dec
-20
Feb
-21
Ap
r-2
1
Jun
-21
Au
g-2
1
Oct
-21
Dec
-21
Feb
-22
Ap
r-2
2
Jun
-22
Au
g-2
2
Actual $ Per Month Forecast $ Per Month Actual % Forecast %
Actual 58.5 %
03/2020
Original Contract: $43,988,989 Incurred-to-Date²: $45,516,490
Current Contract Value¹: $77,773,946 Incurred in March: $25,453
1Current Contract Value = Original contract value + executed Change Orders 2Incurred-to-Date based on Pay App Verification values and are reconciled with the city’s C2HERPS system instead of CMS
Honolulu Rail Transit Project Monthly Progress Report March 2020
75 | P a g e
Activities this Month (continued): o Eight (8) RFIs were received and one (1) RFI was responded to this period. o The CSOC received 132 submittals and completed 57 submittal reviews during this
period. o Received and returned 10 Maintenance of Traffic (MOT) submittals. o Developed ICE for Issue 00205, Pouhala (Waipahu) Station Entrance. o Completed Negotiation Strategy Memo (NSM) Issue 226 – VMS Signs AGS End of
Platform. o Reviewed and validated HRH’s Request for Payment #99 for work reported by HRH
during February 2020. Interface Management:
o Supported HART with coordination of Core Systems work required at Honouliuli (Ho‘opili) Station temporary Park & Ride with D.R. Horton.
o Continued to support HART with the CSC’s planning and coordination for canopy device installation with Fixed Facility Contractors (FFCs).
o Supported HART with HRH and PAC Electric’s Interface for Traction Power Backup Generators.
o Supported HART with the contact rail repair work at Pearl Highlands due to STG’s rail hauling activities.
Manufacturing Oversight and Factory Inspection: o Completed receiving inspection of Train #8 at the MSF. o Commenced shipping inspection of Train #13 for transit to Honolulu. o Conducted Buy America Compliance Audit with HRH at the Passenger Vehicle Panel
supplier, Peabody Fleet Painting, in Sparks, Nevada. Installation Oversight:
o Continued oversight for MDS installation on guideway. 14 of 29 poles erected. o Continued oversight for Comms installation at HOP, WLO, WTC and LCC. o Continued oversight of FDAS installation at WLO. o Completed oversight of PSGS electrical installation at UHWO. o Continued oversight of PSGS electrical installation at EKP.
System Acceptance, Testing, and Commissioning: o Witnessing of the following testing activities:
Train #8 delivery and inspection Train #10 onboard ATC acceptance test Train #11 static & dynamic acceptance test Train #12 onboard COMM acceptance testing Train #9 static acceptance testing Onboard ATC VTP/CTP testing in the functional section extended to EKP ATC wayside testing in EKP, HOP, PLR and ALS stations PHL TPSS testing with SCADA OCC WTC PSGS commissioning EKP and HOP FDAS Test to OCC TES Loop Resistance Test for PHL TPSS and ALS TPSS Multiple Purpose Vehicle (MPV) Weighing ALS TPSS – A01 incoming breaker functionality test PHL UPS testing
Other Assignments: o Provided Data Room Update #7 for the P3. o Supported HART with P3 workshops, response to P3 RFIs and P3 Procurement
activities. o Reviewed technical submittals, schedule submittal, payment schedule submittal,
and other contractual documents for the Traction Power Backup Generator (TPBuGen) Contract.
o Continue to manage HART’s OP54 database for all stakeholders. o Provided WiFi Bid Technical Evaluation Report and Price Analysis Report in response
to bidders’ proposals to the HART procurement. o Prepared for HART Quality Assurance (QA) Audit.
Look Ahead (continued): Continue to assist HART with
resolution of change and claim issues. Continue to assist HART with the
Track Allocation Procedure. Continue to support HART to address
outstanding issues related to construction access at stations.
Continue to support HART to meet MSF Operational schedule objective and Interim Opening activities.
Continue to support HART to prepare the functional section to start integration testing on the mainline.
Support HART on P3 activities, as required.
Continue to support HART with HECO issues, including work on power quality and mitigation analysis.
Review final design, O&M, plans, and test procedures/report submittals.
Finalize PV design solution to add car shell ventilation holes.
Finalize PV design solution to add four additional CCTV cameras.
Continue to mobilize personnel to support additional tasks added to the CSOC’s scope.
_______________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________
KEY ISSUES: o No issues.
Honolulu Rail Transit Project Monthly Progress Report March 2020
76 | P a g e
4.7 Contract Status by Contract Packaging Plan (CPP) Number
Contract Summary by CPP
(data as of Mar 31, 2020) A B C = A + B D E = D / C
CPP # CPP Title
Original Contract
Value
Change
Orders
Current Contract
Value Incurred % Exp.
Award
Date
Original
Completion
Date
Revised
Completion
Date
DB-120 West Oahu/Farrington Hwy Guideway 482,430,201 185,351,685 667,781,886 667,781,886 100% Nov-2009 Oct-2013 Dec-2018
DB-122 Westside Bird Control 0 0 0 0 0% TBD TBD TBD
DB-172 DR Horton Parking / Interim PnR Ho'opili 0 0 0 0 0% TBD TBD TBD
DB-200 Maintenance & Storage Facility 195,258,000 86,517,032 281,775,032 281,775,032 100% Jun-2011 Dec-2014 Jul-2016
DB-275 Pearl Highlands Garage, Bus Terminal, H2 Ramp 0 0 0 0 0% TBD TBD TBD
DB-320 Kamehameha Hwy Guideway 372,150,000 31,405,774 403,555,774 403,555,774 100% Jun-2011 Oct-2014 Dec-2018
DB-450 Airport Section Guideway/Stations 874,750,000 11,684,752 886,434,752 561,582,240 63% Sep-2016 May-2021 May-2021
DB-550 City Center Guideway and Station (CCGS) 100,000 134,000 234,000 206,546 88% Jan-2018 Nov-2024 Nov-2024
DBB-121 WOFM Median Landscaping 0 0 0 0 0% TBD TBD TBD
DBB-171 West Oahu Station Group 56,088,470 31,810,294 87,898,764 81,684,474 93% Jul-2015 Mar-2018 Mar-2019
DBB-271 Farrington Highway Station Group 78,999,000 18,487,980 97,486,980 90,354,186 93% Jun-2015 Jan-2018 Jan-2019
DBB-272 Waipahu Makai Entrance 0 0 0 0 0% TBD TBD TBD
DBB-371 Kamehameha Hwy Station Group 115,805,845 15,219,828 131,025,673 115,731,666 88% Jan-2016 May-2019 May-2019
DBB-385 Ramp H2R2 5,203,646 332,250 5,535,896 5,535,896 100% May-2015 Oct-2016 Nov-2017
DBB-505 Airport Section Utilities Construction 27,993,290 726,200 28,719,489 28,719,489 100% Jun-2014 Feb-2016 Oct-2016
DBB-511 City Center Utilities Relocation Construction 400,000,000 0 400,000,000 22,789,550 6% May-2018 May-2020 May-2022
DBB-525 Airport Section Guideway 7-Pier 3,973,000 54,843 4,027,843 4,027,843 100% Sep-2014 Feb-2015 Apr-2015
DBB-551 Advanced Guideway Foundations in Kaka'ako 0 0 0 0 0% TBD TBD TBD
DBB-600 Park-and-ride Lots Construction 0 0 0 0 0% TBD TBD TBD
DBB-602 UHWO Temp PnR and Campus Rd B 11,589,300 1,611,930 13,201,230 12,193,721 92% Dec-2017 Jul-2019 Jul-2019
DBB-701 Kamehameha Highway Resurfacing 25,989,989 2,145,340 28,135,329 26,740,810 95% Jul-2018 Sep-2019 Sep-2019
DBB-921 WiFi Passenger Vehicles 0 0 0 0 0% TBD TBD TBD
DBOM-920 Core Systems Design Build O/M 573,782,793 209,736,373 783,519,166 418,468,833 53% Nov-2011 Mar-2019 Jan-2025
FD-140 West Oahu Station Group 7,789,000 6,442,995 14,231,995 13,215,801 93% Jun-2012 Nov-2016 May-2020
FD-145 Dillingham / Kaka'ako (Eastside) SG FD 0 0 0 0 0% TBD TBD TBD
FD-240 Farrington Highway Stations Group 9,300,696 7,697,120 16,997,816 16,304,123 96% Jan-2011 Nov-2016 Mar-2020
FD-340 Kamehameha Hwy Station Group 8,702,592 4,785,962 13,488,554 13,061,253 97% Nov-2012 Jun-2017 Nov-2019
FD-430 Airport Sect. Guideway/Util 38,840,960 4,111,440 42,952,400 42,371,374 99% Dec-2011 Aug-2013 Jun-2017
FD-440 Airport Station Group 10,177,365 (117,545) 10,059,820 10,059,820 100% Nov-2012 Jan-2014 Jul-2015
FD-530 City Center Guideway/Util 43,948,220 13,941,087 57,889,307 57,489,264 99% Jul-2012 Mar-2014 Jul-2020
FD-550 Dillingham and Kaka'ako Station Group 18,321,918 (6,020,837) 12,301,081 12,341,565 100% Aug-2013 Sep-2014 Aug-2016
FD-600 KHG 138kV Underground Design 0 0 0 0 0% TBD TBD TBD
FD-700 Design Services for 138kV Util. Reloc. at KHG 8,766,327 0 8,766,327 3,964,732 45% Aug-2018 Nov-2021 Nov-2021
FD-701 KH Civil Design 60,000 0 60,000 60,000 100% Jan-2018 Jan-2019 Jan-2019
MI-900 Fare Collection DFI 15,464,198 444,026 15,908,224 6,382,428 40% Mar-2016 Jan-2029 Jan-2029
MI-930 Elevators & Escalators Install/Maint 50,982,714 4,879,726 55,862,440 27,599,393 49% Jul-2013 May-2018 May-2021
MI-940 Core Systems Backup Generators 0 0 0 0 0% TBD TBD TBD
MI-950 Volt Ampere Reactive Equipment 0 0 0 0 0% TBD TBD TBD
MM-945 On-Call Construction I 1,000,000 1,000,000 2,000,000 1,999,983 100% Aug-2014 Jul-2019 Dec-2016
MM-947 On-Call Construction II 7,500,000 0 7,500,000 7,495,772 100% May-2015 May-2020 May-2020
MM-948 On-Call Construction III 20,000,000 6,000,000 26,000,000 25,582,690 98% May-2016 May-2023 May-2023
MM-949 On-Call Construction IV 46,000,000 0 46,000,000 32,878,531 72% Jan-2018 Nov-2024 Nov-2024
Honolulu Rail Transit Project Monthly Progress Report March 2020
77 | P a g e
Contract Summary by CPP
(data as of Mar 31, 2020) A B C = A + B D E = D / C
CPP # CPP Title
Original Contract
Value
Change
Orders
Current Contract
Value Incurred % Exp.
Award
Date
Original
Completion
Date
Revised
Completion
Date
MM-290 Construction Engrg & Insp CEI West 54,232,480 36,000,000 90,232,480 87,547,371 97% Jan-2014 Jan-2020 Jan-2020
MM-595 Construction Engrg & Insp CEI East I 63,083,417 (50,377,317) 12,706,100 12,711,366 100% Jan-2014 Jan-2019 Jan-2016
MM-596 Construction Engrg & Insp CEI East II 55,036,130 47,000,000 102,036,130 65,418,635 64% Sep-2015 Dec-2019 Dec-2021
MM-901 Program Mgt Support Conslt II 33,376,897 16,359,765 49,736,662 49,736,662 100% Feb-2012 Mar-2015 Mar-2017
MM-902 Program Mgt Support Conslt III 63,522,953 0 63,522,953 37,501,959 59% Jan-2017 Dec-2022 Dec-2022
MM-905 MM-905 Gen Engrg Conslt EIS/PE 0 75,995,982 75,995,982 75,995,982 100% Aug-2007 Feb-2010 Feb-2011
MM-910 MM-910 Gen Engrg Conslt FD-Construct 150,226,265 0 150,226,265 150,226,265 100% Jun-2011 Dec-2014 Dec-2014
MM-913 MM-913 Gen Engrg Recompete 46,143,277 38,585,498 84,728,775 65,818,643 78% Dec-2013 Apr-2019 Jul-2021
MM-915 HDOT Traffic Mgmt. Consult. 1,600,000 5,010,000 6,610,000 6,056,562 92% Jun-2012 Jun-2017 Jun-2019
MM-920 HDOT Coordination Conslt WOFH 3,000,000 6,500,000 9,500,000 9,483,733 100% Jun-2011 Jun-2016 Dec-2018
MM-921 HDOT Coordination Conslt KHG 16,138,390 (1,400,000) 14,738,390 7,892,827 54% Jun-2012 Feb-2025 Feb-2025
MM-922 HDOT Coordination Conslt. East 17,560,000 (7,631,360) 9,928,640 5,793,864 58% Jun-2012 Dec-2024 Dec-2024
MM-925 HDOT - WOFH/KHG Imprv Agreements 550,000 2,865,633 3,415,633 2,761,830 81% Oct-2010 Oct-2019 Oct-2019
MM-930 HDOT State SOA Manager & Consultant 1,272,400 583,142 1,855,542 990,437 53% Feb-2012 Aug-2017 Aug-2017
MM-940 Kako'o Consultant I 1,000,000 (3,106) 996,894 531,609 53% Mar-2012 Mar-2022 Mar-2022
MM-941 Kako'o Consultant II 200,000 400,000 600,000 350,000 58% Dec-2015 Jan-2018 Jan-2020
MM-946 On-Call Hazmat Assessment Consultant 12,006,227 2,075,000 14,081,227 6,962,839 49% Feb-2018 Feb-2023 Feb-2023
MM-950 OCIP Consultant I 1,250,000 0 1,250,000 1,250,000 100% May-2012 Jun-2017 May-2017
MM-951 Owner-Controlled Insurance Program 41,000,000 8,640,674 49,640,674 43,332,079 87% Apr-2014 Apr-2020 Mar-2019
MM-953 OCIP Consultant II 415,000 0 415,000 393,336 95% May-2017 May-2020 May-2020
MM-960 Archeological & Cultural Monitoring 2,489,748 0 2,489,748 2,930,584 118% Jan-2014 Jan-2019 Jan-2019
MM-962 Core Systems Support 43,988,989 33,784,957 77,773,946 45,516,490 59% Feb-2014 Sep-2019 Sep-2022
MM-964 Safety and Security Consultant 21,699,279 5,549,188 27,248,468 15,109,047 55% Apr-2014 Jan-2017 Jan-2019
MM-970 Fare Collection Consultant 1,178,300 640,620 1,818,920 866,104 48% Sep-2015 Dec-2019 Dec-2019
MM-975 LEED Commissioning Services for MSF 278,630 7,845 286,475 286,475 100% Oct-2010 Jan-2016 Aug-2017
PA-102 Programmatic Agreement HPC 667,275 (175,947) 491,329 274,585 56% Jul-2013 Jan-2019 Jan-2019
ART ART Contracts 2,139,500 10,000 2,149,500 606,250 28% Jan-2016 Jul-2019 Jul-2019
MM-935 Real Estate Consultant 3,000,000 5,077,665 8,077,665 7,504,910 93% Mar-2012 Mar-2017 Mar-2017
MM-936 Real Estate Consultant II 8,190,000 0 8,190,000 6,100,318 75% Sep-2016 Sep-2020 Sep-2020
MM-937 Real Estate Consultant - Maps/Surv. 2,998,000 1,130,000 4,128,000 2,974,656 72% May-2014 May-2017 May-2019
MM-981 Complex Real Property Nego. Lit. Sup 600,000 (21) 599,979 602,241 100% Sep-2016 Sep-2018 Sep-2018
MM-982 On Call Appraiser 4,000,000 0 4,000,000 538,645 14% Jun-2016 Dec-2022 Dec-2022
MM-983 Land Court Petition Services 1,200,000 0 1,200,000 89,188 7% Oct-2016 Oct-2019 Oct-2019
MM-985 On Call Appraisers II 1,261,308 0 1,261,308 354,144 28% Apr-2017 Apr-2022 Apr-2022
MM-986 Real Estate Legal Services 5,800,000 0 5,800,000 3,130,708 54% Oct-2017 Dec-2022 Dec-2022
MM-990 Design Review Consultant 4,027,781 0 4,027,781 388,041 10% Mar-2018 Dec-2024 Dec-2024
MM-991 P3 Financial Legal Services 4,282,333 5,007,500 9,289,833 7,126,414 77% Oct-2018 TBD TBD
UTIL Utility Contracts and Agreements 144,141,812 52,132,834 196,274,646 72,524,973 37% Dec-2009 Dec-2018 Jun-2018
HART-201 HART Expenses & ODCs 38,985,433 0 38,985,433 30,945,820 79% N/A N/A N/A
HART-202 Precast Yard Agreement 32,254,379 16,101,392 48,355,771 7,648,912 16% N/A N/A N/A
4,395,763,727 938,252,199 5,334,015,926 3,828,229,177
Source: HART CMS. Note: Excludes Right-of-Way transactions, debt financing costs, and City/HART contract packages, which are included in Appendix A. 2 Non-Contractual Expenses
(data as of Mar 31, 2020)
CPP # CPP Title
Current Contract
Value Incurred
ROW Real Estate Docs/ 3P Agreements 175,427,345
CCH-100 HART/CITY CCH
14,925,228
CCH-101 HART/ City Dept of BFS 0
CCH-102 HART/ City DDC Land Division
173,182
CCH-107 HART/ City Corporation Counsel (COR) 3,088,688
CCH-108 HART / Board of Water Supply (BWS)
928,325
HART-200 HART - Labor 80,892,140
HART-201 HART Expenses & ODCs
36,976,791
OTHER Debt Financing Costs 33,800,191
TOTAL 346,211,890
Source: HART CMS.
Honolulu Rail Transit Project Monthly Progress Report March 2020
78 | P a g e
5 OVERALL PROJECT-WIDE ACTIVITIES
5.1 Overall Key Issues
Overview
Experienced Personnel: Having experienced and qualified personnel from HRH to deal with all challenges between now and Interim Opening is being addressed as a top priority. This includes personnel in management, testing, commissioning, construction, quality and safety certification. HRH has recently brought in a number of subcontractors to help support the team. This has now been impacted by COVID-19 and will be addressed once there is stability in this area.
O&M Documentation: HRH has assigned prime responsibility for documentation development to Horizon Partners Ltd. (HPL). HRH completed a Health, Safety, Quality and Environment (HSQE) workshop in mid-February in collaboration with DTS, with appropriately revised documentation submitted in March conforming the HRH documents to the Agency Safety Plan.
O&M Training: HRH is scheduled to commence formal training classes during the first week of April. An assessment of future training is underway relative to the amount of training that can be undertaken remotely due to COVID-19 impacts. The result of this critical review will potentially impact the proposed rate of HRH hiring during April.
HRH’s development of the Maintenance Management Information System (MMIS) (Maximo) is critical for Interim Opening. The MMIS design documents are critical elements for the maintenance service plan (MSP) document development and HRH held a follow-up MMIS design workshop in March. Interface with DTS led maintenance activities remains open and will be addressed during April.
Automated Yard Operation: Closure of open design issues of the DBOM Core Systems contract are needed, particularly the communications system design and the integration with the vehicles and automated train control systems. HART has requested a recovery schedule to show how the critical goals missed are being re-sequenced to meet Interim Opening.
Functional Track Integration Testing: Completion of all equipment installation and testing in the Functional Section must take place on time prior to integration testing. Critical subsystems are Communications, PSG and SCADA. HART has requested a recovery schedule to show how critical goals missed are re-sequenced to meet Interim Opening. This recovery schedule must take into consideration issues related to COVID-19.
AGS integrated schedule: Currently, STG’s schedule for station construction needs more detail for Core Systems to plan installation and testing coordination. The first draft of the schedule shows a delay of turnover dates to the Core Systems Contractor. This would impact Interim Opening #2. Core Systems is working with the construction team to pull back these delays.
Procurement of materials by HRH has been delayed and caused schedule slippage. HRH management has added on-site procurement personnel and obtained additional support from headquarters. This issue is further amplified due to additional design changes and COVID-19.
Canopy arms are installed at all stations with the exception of Hālawa (Aloha Stadium) Station. Completion of the final canopy arm design and shop drawing development/approval for the Hālawa (Aloha Stadium) Station has delayed the completion and shipping of the canopy arms. They are now scheduled for installation in May 2020. Canopy fabric is installed at Kualaka‘i (East Kapolei), Keone‘ae (University of Hawai‘i West O‘ahu), Honouliuli (Ho‘opili) and Hālaulani (Leeward Community College). Due to travel restrictions, quarantine and weather, the Pouhala (Waipahu Transit Center) fabric is scheduled for April 2020. Hō‘ae‘ae (West Loch) and Waiawa (Pearl Highlands) fabric are scheduled to start in May 2020. Kalauao (Pearlridge) and Hālawa (Aloha Stadium) fabric is now scheduled for a June 2020 start. Coordinating canopy arm and fabric installation with Core Systems to lessen the impact on train testing.
HART is dependent on the electrical design prepared by HECO for the electrical power line relocation work that must be performed by HART’s CCUR contractor. As HART’s civil design becomes available, HECO begins their electrical design. HART is continuing to meet at all levels within HECO to coordinate the required designs for the CCUR contract.
The ability to meet the required CCUR construction access dates as put forth in the P3/DB solicitation is critical. HART is in the process of finalizing a solicitation package to bring on board additional contractors to facilitate construction, as this would provide additional resources and means and methods to prosecute the work.
Honolulu Rail Transit Project Monthly Progress Report March 2020
79 | P a g e
5.2 Permits Permits Submitted and In-Progress HART received the extension of the SCAP from the Department of Land and Natural Resources (DLNR) for work in
Kalihi Stream. HART submitted the request for an extension of the SCAP to DLNR for Phase 3 construction in Waiawa Stream. HART submitted and received the extension of the Clean Water Act Section 401 Water Quality Certification for
construction in Waiawa Stream. HART received the National Pollutant Discharge Elimination System (NPDES) permit for a construction staging area
at the Hertz lot at the airport. HART submitted a trenching permit for Task Order 16 in the City Center section.
Look Ahead HART will be submitting permit applications for the Kamehameha Highway 138kV activities, once design is 60%
complete.
5.3 Hawai'i Department of Transportation (HDOT) Agreements Activities this Month HDOT Attorney General is currently reviewing the WOFH Master Agreement and Joint Use and Occupancy
Agreement (JUOA) Amendment 1 draft amendments. Completion of review is expected in April 2020. Ongoing tracking of the progress of the projects for the Highway Improvement Agreement. Coordinating
documentation of the highway improvement projects with HDOT and Federal Highway Administration (FHWA) for reimbursement. FHWA is reviewing files for compliance on the solicitation of items that require a waiver to disburse funding for the Highway Improvements. A change order to the KHR project is being processed to perform the Kuala left-turn Highway Improvement project. Pupukahi right-turn and traffic signal approvals are being coordinated with HDOT and on-call.
Draft of the West O‘ahu Farrington Highway Joint Use and Occupancy Agreement Amendment 2, which includes maintenance agreements related to guideway related permanent Best Management Practices (BMPs) and traffic signal mounts on the pedestrian bridge at the UHWO Station, was sent to DTS for review in March 2020.
Look Ahead Route externally for execution of the West O‘ahu Farrington Highway Master Agreement and Joint Use and
Occupancy Agreement Amendment 1. Route to BFS, followed by final legal review, estimated second quarter 2020. Presentation to the Board and City Council to follow, estimated second quarter 2020.
The West O‘ahu Farrington Highway Joint Use and Occupancy Agreement Amendment 2 includes maintenance agreements related to guideway related permanent BMPs and traffic signal mounts on the pedestrian bridge at the UHWO Station. DTS coordination will continue in April 2020.
Honolulu Rail Transit Project Monthly Progress Report March 2020
80 | P a g e
5.4 Utility Agreements
Utility Agreements Status Matrix
Utility Owner Status WOFH KHG Airport City Center
ESA UCA ESA UCA UCA COMBINED ESA UCA
AT&T (Corporation)
Executed 05/11/11 12/20/11 5/18/12
Including with ESA
Not Required
12/26/13 05/03/17 NTP 05/12/11 12/21/11
Amd 01 07/01/11 HRS Ch. 104 11/22/16
AT&T Corp. (Public Sector)
Executed 12/26/13 08/27/18 12/26/13
NTP
Chevron
Executed 12/04/09
11/04/11
NTP 12/22/09 11/15/11
Amd 01 07/01/11
Hawaiian Telcom
Executed 05/20/10 11/17/14 05/10/12 12/31/14 05/28/15 09/27/13 04/06/17
NTP 06/14/10 11/18/14
Amd 01 07/01/11 04/13/15 05/11/17 11/19/18 09/20/19
Amd 02 05/10/12
HECO
Design
Services Construction
Services Design
Services Construction
Services Design
Services Construction
Services Design
Services Construction
Services
Executed 11/20/13 11/29/13 11/20/13 11/29/13 11/20/13
11/25/13
NTP 11/20/13 11/29/13 11/20/13 11/29/13 11/20/13 11/25/13
Executed 05/16/18
Change Order 01
06/30/17 11/13/19 02/22/18
Working on
Change Order 01
Change Order 02
02/22/18 11/13/19
Mem
ora
nd
um
s o
f
Un
der
stan
din
g
08/07/14 – Construction Drawings
05/01/15 – Access
05/15/15 – Derrick Truck
06/23/15 – Master Agreement
06/09/15 – MSF Advanced Construction
09/16/15 – Right of Entry
10/12/15 – Clearance (West) 11/10/15 – Dillingham Blvd Materials
07/13/16 – KHG Vertical Clearance
Power Quality MOU (Working on MOU)
08/16/18 - Airport Clearance Agreement
05/15/19 – Vehicle Storage MOU
Airport Energization MOU 08/13/19 - Executed
Charter Communications/Oceanic Time Warner Cable
Executed 12/08/09 12/21/11 01/09/12 06/02/14 12/19/14
04/03/13 9/22/16
NTP 12/22/09 04/04/13 9/30/16
Amd 01 07/01/11 02/27/14 HRS Ch. 104 07/06/18 Waiting for final design drawings.
Amd 02 10/07/13 HRS Ch. 104
Pacific Lightnet/ Wavecom
Executed 04/28/10 03/12/12 02/15/12
NTP 04/29/10 03/13/12 02/16/12
Amd 01 07/01/11 HRS Ch. 104
Honolulu Rail Transit Project Monthly Progress Report March 2020
81 | P a g e
Utility Agreements Status Matrix
Utility Owner Status WOFH KHG Airport City Center
ESA UCA ESA UCA UCA COMBINED ESA UCA
Sandwich Isle Communications
Executed 05/20/10 04/20/12
NTP 06/08/10
Amd 01 07/01/11
Hawai'i GAS
Executed 12/18/09 06/30/11 06/01/12 04/14/14
08/19/14 09/27/13
05/08/15
NTP 12/22/09 07/12/11 08/20/14 05/11/15
Amd 01 07/01/11 10/17/14 08/28/14 08/31/17 10/24/17
Amd 02 05/09/16 10/23/15 11/03/19
Amd 03 HRS Ch. 104
Level 3/TW Telecom
Executed 12/02/09
02/14/12 Oceanic to relocate for TW Telecom
10/11/12 Oceanic to relocate for TW Telecom NTP 12/22/09 02/16/12
Amd 01 07/01/11
Tesoro
Executed
02/15/12 09/12/13
08/27/13
NTP 02/16/12 09/03/13
Amd 01 09/12/14
Amd 02 05/13/15
Amd 03 HRS Ch. 104
Legend = Action this month COR = Corporation Counsel UCA = Utility Construction Agreement
= Not applicable ESA = Engineering Services Agreement
UFRCRA = Combined Engineering and Construction Utility Agreement
Overall Key Issues No key issues to report this month.
HECO
Ka‘aahi Substation near MSF area o Supplemental Agreement – HECO sent a letter to HART dated March 6, 2020 stating that based on the latest
power usage projections received from HART on Jan. 15, 2020, the service date for Ka‘aahi Substation cannot be deferred. HART plans to respond to HECO to ask clarifying questions.
Mitigation of Horizontal Working Clearance Requirements o KHG 138kV Relocation project: Refer to the Design Services for 138kV Utilities Relocation at KHG contract
page in Section 4.3 for the latest updates. o Specialized Vehicle Storage Yard at MSF: The security fencing is now targeted to be complete by the end of
April 2020. In the meantime, HECO has stored two of its older vehicles at the MSF while storing its new specialized vehicles at its own yard.
Honolulu Rail Transit Project Monthly Progress Report March 2020
82 | P a g e
5.5 Right-of-Way Key Issues ROW is engaging with property owners along the City Center Guideway and Stations (CCGS) Section to acquire the requisite property rights, via Right of Entry and Possession and Use Agreements (ROE/PUA) for Land Court properties pending final Grant of Easement or Deed. When acquisition by purchase is not reasonably available, ROW uses eminent domain to acquire the requisite property interests. HART’s counsel prosecutes its eminent domain actions and the respective motions for immediate possession of the property so that the construction access may be obtained. Current eminent domain actions:
o West O‘ahu/Farrington: Parcel Identification Number (PID) 102 R. Lee: HART has possession of the property, while the
Lees remediate contamination on the parcel. The judge overseeing this case has been serving as a mediator and facilitator, assisting the property owner in completing its obligations under the settlement. The judge holds biweekly status conferences with the parties and has engaged the Hawai‘i Department of Health (HDOH) in facilitating the completion of the remediation of the property. The HDOH has issued one “no further action” letter and there now remain three sections of the property to remediate.
o Airport: HART has possession of the subject property in the four cases filed with the court. For
PID 318 Masters, the parties are closing on a settlement. PID 306 SCI and PID 319 SCI were consolidated and mediation is scheduled for April 2020 and trial in July 2020.
o City Center: Eight cases are filed with the court and are active (PID 400 Blood Bank, PID 472A Desky, PID 439
Yamauchi, PID 485 Scott Shoe, Howard Hughes various parcels, PID 433 HECO Iwilei, PID 502 Yung Soon Tajima Trust, PID 503 JY Trading Co.). HART filed its eminent domain action and motion for order putting HART in possession of PID 433 HECO Iwilei. HECO filed a challenge to HART’s Order of Possession of the property for the HECO Dillingham Avenue property. The parties are completing negotiations to perform a Phase II environmental survey on this property and HECO downtown property on Ala Moana Boulevard. PID 439 Yamauchi executed a settlement agreement and counsel will formally dismiss this case once the Land Court process is completed. Possession has been granted for PID 400 Blood Bank, PID 472A Desky, PID 485 Scott Shoe, Howard Hughes various parcels, and PID 503 JY Trading Co.
During the month of May 2019, the FTA conducted a review of the relocation program and the FTA issued a report on Sept. 23, 2019 regarding its findings. The report details measures that must be taken to bring the closed relocation files into compliance, including interviewing the relocated parties. The FTA approved HART’s plan to bring the files into compliance, which was transmitted on Oct. 31, 2019. HART contracted with a team that met with the FTA in January 2020 to discuss the implementation of the plan. The corrective action plan team is now reviewing files and preparing to contact displaced parties.
Regular meetings between the CCUR team, Project Controls and ROW to track progress, identify opportunities and foresee obstacles to access for critically needed parcels are ongoing. Revisions in designs made necessary by guideway and utility redesigns will require revised and new acquisitions along Dillingham and Halekauwila Street, including acquisitions currently in negotiation.
The FTA agreed to the proposed multi-agency approach to the acquisition and tenant relocations for PID 493 Watumull which is the site for the Ala Moana Station. HART has partnered with the City and County of Honolulu’s DTS, Department of Design and Construction (DDC), and BFS to facilitate. Relocation assistance work is underway. An offer was transmitted to the owner.
HART recently entered into agreements with Latter Day Saints (LDS), Otani and General Growth Properties (GGP) Ala Moana to obtain necessary property rights; the properties are currently in escrow.
Honolulu Rail Transit Project Monthly Progress Report March 2020
83 | P a g e
Relocation assistance is being provided to the tenant and PID 404 Takara. HART is currently negotiating the acquisition with the owner.
ROW continues to monitor negotiations between Design and Construction and HECO regarding issues involving
clearance requirements due to maintenance equipment staging needs for 138kV poles and lines located next to the HART guideway system. These discussions will identify additional acquisitions of non-asset easements on behalf of HECO or other utility agencies and/or companies.
Negotiations are continuing with UH, including securing a construction ROE Agreement with the Honolulu
Community College.
Acquisitions Figure 7. Right-of-Way Status for the Parcels
Relocations Figure 8. Relocation Status for the Occupants
Honolulu Rail Transit Project Monthly Progress Report March 2020
84 | P a g e
Non-Right of Way Figure 9. Temporary Construction Easements and Utility
Status of Inter-Governmental Agreements Figure 10. Inter-Governmental Agreement Status The status of agreements between HART and other government entities. Objectives are:
1) Obtain Construction Right of Entry, Executive Orders, Set Asides, Jurisdiction Transfers, Joint Use Agreements, licenses, easements, Memorandum of Understanding (MOUs), Memorandum of Agreement (MOAs), etc. with impacted government agencies. Government agencies HART is working with include: Federal (GSA, Navy, USPS, Office of Interior), State (HDOT-Hwys & Air, DLNR, DAGS, HCDA, DOE, Aloha Stadium, UH), and County Agencies (DTS, DPP, DFM, BFS, DDC, Parks, DLM, ENV). Some government agencies may choose to issue the final documents after construction is substantially underway or near completion.
2) To help negotiate and/or obtain Rights of Entry for certain other construction-related activities as requested by Design and Construction. Such agreements may include: geotechnical borings, soil testing, environmental surveys, bus stop agreements, construction lay down surveys, and other construction-related needs. There may be other Rights of Entry and Agreements which may not involve ROW acquisition or relocation. ROW will assist other HART departments, should requests be authorized and funded.
3) Agreements to be executed are in white. Executed agreements are in grey at the end of the table, and while these parcels may be accessible at this time for construction, further documentation may also be required to complete the acquisition.
Inter-Governmental Agreements
Agency
Pending Agreements (Executed Agreements
are shaded grey)
Target
Section
Construction Right of Entry
(CROE) Obtained
Notes/Remarks
STATE AGREEMENTS
UH – University of Hawai‘i, West O‘ahu (UHWO-125)
Construction Right of Entry and Occupancy & Use Agreement for East Kapolei Park & Ride
TBD/ Estimate
2021
WOFH Yes Temporary park and ride completed.
3rd Amendment to CROE has been fully executed. It allows for
installation of electrical connections from Road B to
station area and subsequently into interim parking.
Honolulu Rail Transit Project Monthly Progress Report March 2020
85 | P a g e
Inter-Governmental Agreements
Agency
Pending Agreements (Executed Agreements
are shaded grey)
Target
Section
Construction Right of Entry
(CROE) Obtained
Notes/Remarks
UH – Urban Gardens (201A) Conveyance to HDOT (H) – Dept. of Transportation Highways
May 2020
KHG Yes
2nd Amendment to HART ROE fully executed. Based on final Phase II
results, HDOT has issued concurrence letter. Construction is
nearing completion. Quitclaim deed under review by
HDOT-Highways. Subdivision map completed.
UH – Honolulu Community College (HCC) (424A)
Construction Right of Entry for guideway & station
May 2020
City Center No Pending design finalization. Working with UH regarding ROE
Agreement. Draft ROE Agreement under review by COR. ROE will be broken down into phases starting
with least intrusive activity. Demolition and preliminary
construction activities completed under letter agreement with Royal
Construction.
DLNR – Dept of Land & Natural Resources (124)
Kapolei Easement Agreement for overhead guideway and for park and ride facility
May 2020
WOFH
Yes In process. DPP approved subdivision application.
Transmitted to DLNR for land court submittal. Discussions are
ongoing regarding language permitting guideway easement.
DLNR/C&C Wastewater Div (437B)
Easement Agreement May 2020
City Center In process. DLNR working with DAGS survey group to address
questions regarding final easement map. Ongoing
discussion with DLNR regarding easement agreement terms.
DOE - Waipahu H.S. (118) Permanent Easement (State owned portion)
May 2020
WOFH Yes
In process. Construction is not impacted as the ROE for right to access and construct is executed.
With DOE for review. Working with DLNR for permanent rights.
DOE – Waipahu H.S. (117) Permanent Easement (City portion)
May 2020
WOFH Yes Permanent easement from City in process. DLM has indicated they will delay the transfer of the City portion to the State until HART has permanent entitlements in
place. HART is revisiting this strategy. Construction is not
impacted as the Master/ Construction Agreement is
executed. Working with BFS for permanent rights.
Aloha Stadium / Dept. of Accounting & General Services (DAGS) (207A to C)
Easement Agreement May 2020
KHG Yes In process. Creating maps that are separating the parking area from
the station and guideway easements.
Honolulu Rail Transit Project Monthly Progress Report March 2020
86 | P a g e
Inter-Governmental Agreements
Agency
Pending Agreements (Executed Agreements
are shaded grey)
Target
Section
Construction Right of Entry
(CROE) Obtained
Notes/Remarks
Aloha Stadium/ DAGS (207B)
Ground Lease Agreement for bus interface and shared parking area
July 2020
KHG Yes In process. Agreement format may impact map approvals from
Stadium Authority, DAGS and DLNR. Construction is not
impacted as the ROE for right to access and construct is executed. Parking area rights will be granted
via long term lease. Relocation clause to accommodate TOD
development.
HDOT(H) – Dept. of Transportation Highways (100,100-A, 304, 400-A, 400-B)
Master Agreement Amendment
July 2020
WOFH Yes Construction is not impacted as the Joint Use & Occupancy (JU&O) Agreement for right to access and
construct is executed.
HDOT(H) and (A) – Dept of Transportation Highways & Airports (100,100-A, 301, 304, 304, 400-A, 400-B)
Master Agreement for KHG, Airport and City Center Amendment
July 2020
KHG, Airport,
City Center
Yes for KHG & Airport
Construction is not impacted as the JU&O for right to access and construct for City Center will be
executed when the Notice to Proceed (NTP) is issued.
HDOT(H) (100,100-A, 304, 400-A, 400-B)
JU&O Sub-agreement July 2020
WOFH Yes In process. Construction is not impacted as the JU&O for right to access and construct is executed.
HDOT(H) (100,100-A, 304, 400-A, 400-B)
JU&O Sub-agreement July 2020
City Center In process. Construction is not impacted as the JU&O will be executed when NTP is issued.
HCDA -HI Community Development Authority (444A, 450,463BE-5-B, 475)
Construction ROE, License Agreement, & Final Disposition
August 2020
City Center Coordination is ongoing. ROE for Royal Contracting pre-
construction activities extended. Final disposition pending revised
design.
DAGS (441-A) Construction Right of Entry July 2020
City Center A street is being designed substantially within the footprint of Easement U as requested by DAGS as a precondition to ROE.
The street will be provided as in-kind consideration for a staging yard for the 3rd party contractor.
Survey for staging area being conducted and street concept plan undergoing refinement.
Utility work descoped; will now be performed by P-3 contractor.
DAGS (441-A) Guideway and Utility Easement Agreement
August 2020
City Center In process. Stakeholder’s meeting the week of Feb. 17-21, 2020. Design plans for Kaaahi Street
extension completed.
DAGS (443-A) Utility, Guideway and TCE Agreement
June 2020
City Center No On-going negotiations with DAGS to secure right of entry.
DAGS (443-B) Utility, Guideway and TCE Agreement
June 2020
City Center No On-going negotiations with DAGS to secure right of entry.
Kalihi Kai Elementary (501) Right of Entry from DOE/DLNR
June 2020
City Center On hold pending design finalization.
Honolulu Rail Transit Project Monthly Progress Report March 2020
87 | P a g e
Inter-Governmental Agreements
Agency
Pending Agreements (Executed Agreements
are shaded grey)
Target
Section
Construction Right of Entry
(CROE) Obtained
Notes/Remarks
Kalihi Kai Elementary (501) Easement Agreement 2020 City Center On hold pending design finalization. Once ROE is in place, subdivision map to be completed
and submitted to DPP.
State of Hawaii - DOT (504) Easement Agreement Pending City Center HECO amending easement design and under review.
FEDERAL AGREEMENTS
USPS (301) Permanent Easement 2020 Airport Via GOE Construction is not impacted. Grant of Easements were
recorded in Regular System to facilitate entry onto property for
construction even though the property is registered in Land Court. Now petitions for Land
Court designation of easements are being developed for submittal
to Land Court.
U.S. Gov't/General Services Administration (GSA)/Federal Courthouse (443C)
Master Agreement, Security & Landscape License Agreement, Utility License Agreement, Guideway License Agreement
2020 City Center Master Agreement fully executed on 8/13/19.
Waiting for design changes,
propose to relocate guideway support onto GSA property.
GSA Federal Courthouse Quitclaim Easement Documents for Utility and Guideway Easements
2020 City Center Under review.
CITY AGREEMENTS
BFS – Dept. of Budget & Fiscal Svcs (204A)
Intra-Agency coordination which may take the form of a ROE, letter agreement, or license (Continental Investment)
2020 KHG Via intra-agency
coordination
In process.
DFM (423A) Work Permit (Kapalama Stream for Street, Bridge, and Guideway Improvements)
2020 City Center DFM/DLM granted entry.
DFM (423A) Easement Agreement for Utilities
2020 City Center Utility agreements on hold pending design finalization. Letter requesting access in draft form for
COR review and approval.
DTS – Dept. of Transportation Svcs (322)
Intra-Agency coordination which may take the form of a ROE, letter agreement, or license (Middle Street Station)
2020 Airport Via intra agency
coordination
In process.
OTHER AGREEMENTS
D.R. Horton (101B) MOU Construction Right of Entry Amendment – D.R. Horton & HART Easement Agreement – D.R. Horton & HECO
April 2020
WOFH Yes MOU draft circulating for comments. PH I environmental
survey in process. Received comments from D.R. Horton (DRH) counsel on license agreement and
being reviewed by COR.
Honolulu Rail Transit Project Monthly Progress Report March 2020
88 | P a g e
Inter-Governmental Agreements
Agency
Pending Agreements (Executed Agreements
are shaded grey)
Target
Section
Construction Right of Entry
(CROE) Obtained
Notes/Remarks
D.R. Horton Final Easement Agreement July 2020
WOFH Yes Construction is not impacted. D.R. Horton is completing further
subdivision of the property. Maps will be updated with new Tax Map
Key prior to submittal of application to DPP.
EXECUTED AGREEMENTS
CITY AGREEMENTS
BFS (205A) Jurisdictional transfer from DFM to HART of Kamehameha Hwy/Makalapa Manor
Airport Yes Jurisdictional Transfer from BFS Letter dated 8/26/11.
DPR - Dept. of Parks & Recreation (119)
Construction consent to construct for MSF drainage
WOFH Yes
BFS / DFM (Dept. of Facility & Maintenance) (437C)
Jurisdictional Transfer (Awa Triangle, N. Nimitz & Awa St.)
City Center Jurisdictional transfer completed July 9, 2018.
STATE AGREEMENTS
DLNR/C&C Wastewater Div (437B)
Construction Right of Entry
City Center Yes Construction ROE obtained from
DLNR 10/21/17. Subdivision submitted with DPP 1/1/18.
UH – University of Hawai‘i Master Agreement is not needed as the ROE for right to access and construct will be executed separately by each campus.
WOFH, KHG, City
Center
Will be executed by each campus
Construction is not impacted as the ROE for right to access and
construct will be executed by each campus.
UH Pre-Construction Right of Entry and Amendment
WOFH, KHG, City
Center
Yes
UH - West O‘ahu (UHWO) (125)
Construction Right of Entry for Station, Temporary Park & Ride, and Amendment for Construction of Road B
WOFH Yes
UH - Leeward Community College (LCC) (122)
Construction Right of Entry for Guideway
WOFH Yes
UH – LCC (122) Construction Right of Entry for Station
WOFH Yes
UH - Urban Gardens (201A)
Construction Right of Entry KHG Yes
DLNR – Dept. of Land and Natural Resources (124)
Kapolei Construction Right of Entry for overhead guideway and for park and ride facility
WOFH Yes CROE has been granted once a year by letter. Working on
permanent Easement with DLNR. Currently with DPP for
subdivision.
DLNR (320) Keehi Lagoon Construction Right of Entry
Airport Yes
DOE – Dept. of Education Waipahu H.S. (117, 118)
Master/Construction Agreement
WOFH Yes
DOE/DLNR for Waipahu H.S. (118)
Construction Right of Entry WOFH Yes Executed by DLNR with DOE concurrence.
Honolulu Rail Transit Project Monthly Progress Report March 2020
89 | P a g e
Inter-Governmental Agreements
Agency
Pending Agreements (Executed Agreements
are shaded grey)
Target
Section
Construction Right of Entry
(CROE) Obtained
Notes/Remarks
Aloha Stadium / Dept of Accounting & General Services (DAGS) (207)
MOU for guideway & station KHG Yes
Aloha Stadium/DAGS Construction Right of Entry for guideway
KHG Yes
Aloha Stadium/DAGS Construction Right of Entry for station park and ride
KHG Yes
HDOT(H) – Dept. of Transportation Highways (100)
Master Agreement for HDOT Highways for WOFH
WOFH Yes
HDOT(H) and (A) – Dept. of Transportation Highways & Airports
Master Agreement for HDOT Highways and Airports, for KHG, Airport and City Center Sections
KHG, Airport,
City Center
Yes except for City Center
whose JU&O will be
executed when the NTP
is issued
HDOT(H) JU&O Sub-agreement WOFH Yes
HDOT(H) JU&O Sub-agreement KHG Yes
HDOT(H) JU&O Sub-agreement Airport Yes
HDOT (A) - Dept. of Transportation Airports
Airport Special Provisions for Right of Entry
Airport Yes
HDOT(A) JU&O Sub-agreement for Airport Division parcels
Airport Yes
HDOT(A) (301A) Easement document for Airport Division parcel (Main guideway easement)
Airport Yes Ongoing intra-agency coordination. Construction is not
impacted as the Special Provisions and the JU&O for right to access
and construct is executed.
DHHL - Dept. of Hawaiian Home Lands (Exchange w/ Varona Village) (115A)
MOA, License/ROE from DHHL, City Council Resolution
WOFH, MSF Yes DLNR approves withdraw from GEO 571 7/14/17. DFM accepts
road widening and now City jurisdiction.
OCCC - Dept. of Public Safety, Oahu Community Correctional Center (400A)
MOU
City Center Yes
OCCC/DLNR Construction Right of Entry
City Center Yes
DLNR/OCCC Letter of Responsibility from City-DFM/Road
City Center Yes
HCDA -HI Community Development Authority (444A, 450, 463B, E-5-B, 475)
Pre-construction Right of Entry
City Center Yes, effective upon request
Verbal approval granted by the HCDA Board in 6/2016.
FEDERAL AGREEMENTS
U.S. Navy (116A) Grant of Easements for Maintenance & Storage Facility (MSF)/Rail Operations Center (ROC) offsite drainage and sewer easements
WOFH Yes Per Letter #N62478-12-RP00011 dated 6/28/12 confirming
easement from Navy.
Honolulu Rail Transit Project Monthly Progress Report March 2020
90 | P a g e
Inter-Governmental Agreements
Agency
Pending Agreements (Executed Agreements
are shaded grey)
Target
Section
Construction Right of Entry
(CROE) Obtained
Notes/Remarks
U.S. Navy (300) Licenses/Construction Right of Entry
WOFH, KHG,
Airport
Yes 6/22/15 – 5 Yrs. License ends in 2020. All utility work needs to be
completed by then.
U.S. Navy Easement Agreements WOFH, KHG,
Airport
Yes Grant of Easement executed. Grant of Easement 8/22/16.
U.S. Navy Pearl Harbor Station Acquisition of Fee Transfer
Airport Yes Quitclaim deed executed 2/25/16.
U.S. Post Office (USPS) (301)
Honolulu Processing Center acquisition
Airport Yes Acquisition completed in regular system. Need to process through Land Court to complete process. Funds already paid. USPS Land
Court share to complete process is in escrow.
OTHER AGREEMENTS
D.R. Horton Construction Right of Entry - D.R. Horton & HECO
WOFH Yes Executed 5/11/2018.
Honolulu Rail Transit Project Monthly Progress Report March 2020
91 | P a g e
6 MANAGEMENT AND ADMINISTRATIVE UPDATES
6.1 Safety and Security (S&S) Key Milestone Progress HART Safety works with the Core Systems Oversight Consultant (CSOC) to oversee HRH preparation for MSF
Attended Operations in the yard and the Functional Track Section. o Expected completion of HRH requirements for the Attended Operations Milestone is May 2020.
HART Safety conducts monthly certification meetings with each station group project team to close out safety and security critical Open Items in preparation for substantial completion.
HART Safety is working with Project Controls to ensure Safety and Security Certification Milestones and related activities are identified and updated on the Master Project Schedule.
The HART Safety and Security Management Plan (SSMP) Revision 9.0 was accepted by the Safety and Security Review Committee (SSRC).
The HART Safety and Security Certification Plan (SSCP) Revision 8.0 was accepted by the SSRC. Key Issues Scheduled certification milestones for Segment 1 may be delayed due to the following open requirements:
MSF Attended Operations Milestone (Hold Point) o HRH to complete open items in regards to ATC, COMM, SIT and SCADA.
Specification Testing Conformance Checklists (STCC) Open Items (58)
ATC – 8 Open out of 21
Communications – 35 Open out of 38
System Integration & Testing – 9 Open out of 22
SCADA – 6 Open out of 14 o HRH to complete 8 open items in regards to Operational Readiness o HRH to complete 26 STCC open items for PVs fleet design verification and individual certifications. o MSF Yard Control Bungalow (YCB) civil contract certification
Accepted in the March 2020 SSRC o MSF YCB Systems Contract Certification (5 STCC Open Items)
Inspection and Test Procedures for MSF YCB Communication Inspection and Test Report for MSF YCB Communication On-site Inspection and Test Report for MSF YCB Fire Detection Alarm System (FDAS) On-site Inspection and Test Report for MSF YCB Uninterruptible Power Supply (UPS) Panel Distribution Unit Low Voltage (LV) Schematic Drawing for MSF YCB UPS
o Maintenance of Way vehicles certification – pending approved specification testing documentation for vehicle acceptance.
HART Safety and CSOC are following up with HRH to close the following STCC open items (3):
Multiple Purpose Vehicle (MPV) (HNL-23015 Accepted as Noted –Resubmit [ANR]: O&M Manual)
Grinder (HNL-23043 ANR: O&M Manual)
Enclosed Trailer (HNL-23105 ANR: O&M Manual)
Honolulu Rail Transit Project Monthly Progress Report March 2020
92 | P a g e
6.1.1 Project Overall Certification Status
Overall Certification Status - Progress Total Items
Total Verified 1/1/20
Total Verified 3/31/20
Total Remaining
Δ YTD
% Complete
% Remaining
Segment 1 Revenue Service 23,805 20,095 20,634 3,171 539 87% 13%
Segment 2 Revenue Service 10,055 4,951 5,074 4,981 123 50% 50%
Segment 3 Revenue Service 7,652 4 4 7,648 0 0% 100%
Final Overall 41,512 25,050 25,712 15,800 662 62% 38%
6.1.2 Segment 1 Revenue Service Date Certification Status
Segment 1 Certification Status - Progress
Anticipated Completion Total
Items
Total Verified 1/1/20
Total Verified 3/31/20
Total Remaining Δ YTD
% Complete
% Remaining
MSF (Civil & Systems) MAY 2020 740 725 725 15 0 98% 2%
Guideway (Civil & Systems) CLOSED 7,368 7,368 7,368 0 - 100% 0%
Stations & Parking (Civil & Systems) MAY 2020 7,235 6,884 7,045 190 161 97% 3%
Passenger Vehicle (PT 8-13) and Fleet Requirements NOV 2020 1,419 519 886 533 367 62% 38%
MOW Vehicles MAR 2020 458 454 455 3 1 99% 1%
Traction Electrification System (TES) APR 2020 270 204 207 63 3 77% 23%
Automatic Train Control (ATC) JUN 2020 346 301 301 45 0 87% 13%
Supervisory Control and Data Acquisition (SCADA) JUN 2020 84 56 56 28 0 67% 33%
Communication JUN 2020 983 676 677 306 1 69% 31%
System Integration Testing (SIT) AUG 2020 138 71 71 67 0 51% 49%
Platform Screen Gate System (PSGS) JUN 2020 96 66 67 29 1 70% 30%
Elevators / Escalators AUG 2020 508 295 295 213 0 58% 42%
Fare Collection System AUG 2020 78 28 28 50 0 36% 64%
Arts in Transit AUG 2020 168 14 14 154 0 8% 92%
Operational Readiness NOV 2020 756 123 123 633 0 16% 84%
Risk Management NOV 2020 3,158 2,311 2,316 842 5 73% 27%
Honolulu Rail Transit Project Monthly Progress Report March 2020
93 | P a g e
6.1.3 Segment 2 Revenue Service Date Certification Status
Segment 2 Certification Status - Progress Total Items
Total Verified 1/1/20
Total Verified 3/31/20
Total Remaining
Δ YTD % Complete
Guideway (Civil & Systems) 3,039 1624 1,734 1,305 110 57%
Stations & Parking (Civil & Systems) 1,990 1525 1,525 465 0 77%
Passenger Vehicles (1-7 & 14-20) 2,354 676 684 1,670 8 29%
Traction Electrification System (TES) 54 4 4 50 0 7%
Automatic Train Control (ATC) 29 12 12 17 0 41%
Supervisory Control and Data Acquisition (SCADA) 47 8 8 39 0 17%
Communication 32 0 0 32 0 0%
Platform Screen Gate System (PSGS) 8 0 0 8 0 0%
System Integration Testing (SIT) 44 0 0 44 0 0%
Elevators / Escalators 33 0 0 33 0 0%
Fare Collection System 50 0 0 50 0 0%
Arts in Transit 63 0 0 63 0 0%
Operational Readiness 555 0 0 555 0 0%
Risk Management 1,757 1,102 1,107 650 5 63%
6.1.4 Segment 3 Revenue Service Date Certification Status
Segment 3 Certification Status - Progress Total Items
Total Verified 1/1/20
Total Verified 3/31/20
Total Remaining
Δ YTD % Complete
Guideway (Civil & Systems) 1,772 0 0 1,772 0 0%
Stations & Parking (Civil & Systems) 4,908 0 0 4,908 0 0%
Traction Electrification System (TES) 39 0 4 35 4 10%
Automatic Train Control (ATC) 29 0 0 29 0 0%
Supervisory Control and Data Acquisition (SCADA) 47 0 0 47 0 0%
Communication 47 0 0 47 0 0%
Passenger Screen Gate System (PSGS) 16 0 0 16 0 0%
System Integration Testing (SIT) 44 0 0 44 0 0%
Elevators / Escalators 33 0 0 33 0 0%
Fare Collection System 50 0 0 50 0 0%
Arts in Transit 112 0 0 112 0 0%
Operational Readiness 555 0 0 555 0 0%
Risk Management 0 0 0 0 0 0%
6.1.5 Construction Safety and Security: Safety and Security Incidents Incidents for March 1-31, 2020:
Recordable Safety Incidents (Medical Treatment/Loss Time): o NAN - CCUR: An employee was making pieces of rubber for steel plates with a utility knife, which slipped
and cut the inside of his left forearm with a 1" laceration; the employee was taken to Kaiser ER for 4 stitches.
o STG - AGS: An employee received a mouth laceration after being struck by a section of PVC conduit he was pulling from a hand hole box inside a trench; the employee was taken to Queens ER for sutures and antibiotics.
Honolulu Rail Transit Project Monthly Progress Report March 2020
94 | P a g e
o STG - AGS: An employee was grinding a piece of form work when he thought he felt a foreign object enter his eye. The employee was taken to Queens ER where it was determined that there was no foreign object, but he had sustained a scratched cornea; it was treated and he was released.
Security Incidents: o Hitachi - Aloha Stadium TPSS Commissioning: The Substation fence lock was struck with a hammer during
an attempted unsuccessful break-in. No property theft was reported.
Honolulu Rail Transit Project Monthly Progress Report March 2020
95 | P a g e
6.2 Quality Management Key Issues
HART NCR Log
Total NCRs Issued To Date Closed Open
101 (Audits) 97 4
2 (Construction) 2 0 Note: HART Issued NCRs for Construction are shown on each respective contract.
Resolution of major NCRs that need to be addressed and corrected to prevent recurrence, and to mitigate impact on the overall progress of the project. The major NCRs are described below: o Retrofit of Eight (8) Car Shells under frame to rectify aluminum extrusion defects continues. Retrofit of car shell
underframe to rectify aluminum extrusion defects continues in Italy. Five (5) out of six (6) retrofitted car shells have been received in Pittsburg, CA. HRI opted out to manufacture two (2) new Carbody for Train #1 and Train #2. Therefore, the defective two (2) Carbody will be scrapped.
o Cracks in Canopy Structural Steel Members. Cracks on the Canopy Structural Steel members were found in the WOSG and FHSG station groups. HART is in the process of finding the “root cause” of the defects, the disposition, and appropriate corrective action to prevent recurrence. All lower portions of the canopy arms (grade 100 steel) will be replaced at WOSG, FHSG and KHSG. Please see Section 5.1 Overall Key Issues, for the latest status on the canopies.
o Train #12. End Car 1 of Train #12 was damaged (about 2.0 ft. long x ¾ in. wide x ¼ in. deep gouge on the left side, which did not penetrate the aluminum extrusion skin, and about ½ in. diameter penetration in the first set of the Door Panel on the right side of End Car 1) during transit from Pittsburg, CA to Honolulu, HI. HRI determined that cosmetic repairs will be required. A qualified and certified surface finisher repair crew is scheduled to be in Honolulu to fix the damage using an approved repair procedure once it is available.
o KHSG Platforms. The platforms of the PHL, PLR and ALS will require shaving to attain dynamic clearances required by the train. The work on PHL and PLR is completed. The ALS is scheduled to be completed by the end of April 2020.
Audit Look Ahead
Prepared and issued (Revision 2) the Project Combined Management Systems Audit Schedule for 2020 to HART and all contractors, consultants and suppliers.
Planning for the audits to be performed in May 2020: Audit No. 20-003 AGS (Casting Facility) Combined QA, Buy America (BA) and Environmental Compliance (EC) Audit of STG, Audit No. 20-004 Core System Support Consultant (CSSC) QA Audit of Lea + Elliott (L+E), and Audit No. 20-005 CCUR Combined QA, BA and EC Audit of Nan Inc. Due to the COVID-19 pandemic, all audits scheduled for April 2020 were postponed until May 2020.
Issued Audit Report on Audit No. 20-001 AGS (Construction) Combined QA, BA and EC Audit of STG held on Feb. 27-28, 2020. The Audit Team found eight (8) Positive Findings (5-QA/3-EC), seven (7) Observations (4-QA/3-EC), and five (5) EC Suggestions.
Issued Audit Report on Audit No. 20-016 Internal QA Audit of HART 5.CA-11 Contract Changes Procedure. The Audit Team found three (3) Positive Findings, three (3) Observations and two (2) Suggestions.
Issued Audit Closeout Letter on Audit No. 19-018 CEI (West) to PGH Wong on Jan. 14, 2020. The Audit Team found two (2) Positive Findings and three (3) Observations (2-QA/1-EC).
Issued Audit Report on Audit No. 19-019 HART Combined QA, Safety and Security (S&S) and EC Internal Audit of HART on Jan. 17. 2020. The Audit Team found: three (3) Positives, three (3) NCRs, nine (9) Observations, and three (3) Suggestions on QA; two (2) Observations, and two (2) Suggestions on S&S; and one (1) Positive on EC.
Issued Audit Report on Audit No. 20-002 AGS (Surveying) QA Audit of STG held on March 5, 2020. The Audit found two (2) NCRs.
Oversight and Monitoring
Attended and participated in Pre-activity meetings, Inspections and Testing on the project o FHSG: Best Management Practice (BMP)/Environmental Inspections. o KHSG: BMP/Environmental Inspection. o WOSG: BMP/Environmental Inspections. o AGS: BMP/Environmental Inspections. o CCUR: BMP/Environmental Inspection.
Prepared and issued Project NCRs Trend Analysis from July 2019 to March 2020 (Revision 50). The trend for this month: Trains: went up 17 from 25 to 42; Core System: went down one (1) from two (2) to one (1); Fixed Facilities: went up 26 from 21 to 47. The trend went up unexpectedly during the month of March 2020. See the next page for the Project NCRs Trend Analysis.
Honolulu Rail Transit Project Monthly Progress Report March 2020
96 | P a g e
Honolulu Rail Transit Project Monthly Progress Report March 2020
97 | P a g e
6.3 Buy America Compliance (49 CFR 661 and 49 CFR 663) Overview and Key Issues
HRH continues to execute the corrective action plan to meet the PV Buy America requirements. The implementation of all required corrective action identified in the Post-Delivery Report has not yet been completed on all previously delivered trains. The CSC will be updating the monthly Buy America compliance report with the Buy America retrofit status of each train to demonstrate compliance with the Corrective Action Plan. An Interim Opening (I/O) documentation audit for the compliance of the I/O fleet will need to be conducted when the last train for I/O #1 is delivered and commissioned, then a final Buy America (BA) report must be issued for full opening.
A Buy America Compliance Audit was conducted on the passenger vehicles panels at Peabody Fleet Painting facility by HRH and the CSOC on March 10 thru 12. The Hitachi Buy America Corrective Action Plan is being implemented with no issue.
Train # Anticipated Date for BA Compliance
Open Issues
1 TBD Carshell structural retrofit, fire resistivity retrofit, and BA retrofit.
2 TBD Carshell structural retrofit, fire resistivity retrofit, and BA retrofit.
3 TBD Interior panels in M-Cars requires replacement for BA compliance.
4 TBD Requires M-car interior panel and Auxiliary Power Supply (APS) retrofit in accordance with BA Corrective Action Plan.
5 Completed Requires fire resistivity retrofit.
6 Completed Requires fire resistivity retrofit.
7 December 2020 Requires fire resistivity retrofit.
8 (I/O Fleet) Completed No issue and delivered to MSF on March 27, 2020.
9 (I/O Fleet) Completed No issue and delivered to MSF on Feb. 14, 2020.
10 (I/O Fleet) Completed No issue and delivered to MSF on Dec. 9, 2019.
11 (I/O Fleet) Completed No issue and delivered to MSF on Jan. 9, 2020.
12 (I/O Fleet) Completed No issue and delivered to MSF on Oct. 26, 2019.
13 (I/O Fleet) April 2020 Manufacturing activities ongoing.
14 December 2020 Manufacturing activities ongoing.
15 December 2020 Manufacturing activities ongoing.
16 December 2020 Manufacturing activities ongoing.
17 December 2020 Manufacturing activities ongoing.
18 December 2020 Manufacturing activities ongoing.
19 TBD Manufacturing activities ongoing.
20 TBD Manufacturing activities ongoing.
6.4 Disadvantaged Business Enterprise (DBE) Activities this Month
$147,125,184 = total dollar participation for all DBEs on all HART contracts from 9/24/07 to 3/31/20 o 18.25% = DBE utilization on total disbursed FTA funds received to date ($147,125,184 divided by
$806,258,734) o 8.34% = DBE utilization to date on total Project FTA funds ($147,125,184 divided by $1,763,903,901) o 9.49% = DBE utilization to date on 5309 Project FTA funds ($147,125,184 divided by $1,550,000,000)
6.5 Art-in-Transit (AIT) Program The Honolulu Rail Transit Project's December 2012 FFGA grant (Sitework and Special Conditions) includes a public art program. In addition, the Revised Ordinances of Honolulu (ROH) Section 3-2.7, "Art in City Buildings," provides for the inclusion of art in city-owned buildings frequented by the public. For the rail project, the AIT staff negotiates and manages contracts for the west-side stations and AGS. AIT contracts are managed in five NTP phases:
Honolulu Rail Transit Project Monthly Progress Report March 2020
98 | P a g e
NTP1 - Conceptual design NTP2 - Design development, final design, and construction documents NTP3 - Mobilization NTP4 - Fabrication, transportation, and installation NTP5 - Final acceptance
Conceptual and final designs are presented to the Mayor's Commission on Culture and the Arts for review and comment. The Transit Art Committee (TAC) evaluates and makes the final recommendation and approval.
Station / Facility Name Artist Name NTP Phase Comments
East Kapolei Station Robert Flint NTP4
Safety & Security conducted Design Criteria Conformance Checklist (DCCC) review and certified final design and Material Safety Data Sheet (MSDS) information. Artist moved to NTP4 (construction, fabrication, transportation, shipping and installation). Waiting for the station contractor to implement changes to the art wall for final dimensions and finishes to commence fabrication of ceramic mural.
University of Hawai‘i West O‘ahu Station
Satoru Abe NTP3
Assisting the artist with DCCC submittal documents. Artistʻs team is working on MSDS information for Safety. Received the fabricator’s full-scale mock up for Safety and Security Certification DCCC review and approval.
Ho‘opili Station Karen Lucas NTP3
Working with the fabricator and artist on high resolution digital scaled maquette to refine color selections and to create custom colored glass tesserae to accurately replicate the details of the original drawings. Waiting for temporary holding tank system to be installed to drain water from art locations so algae can be cleaned and dimensions and directional placement of artworks can be verified before fabrication.
West Loch Station Hans Ladislaus NTP3
Working with the artist on required technical documentation and MSDS information for Safety & Security Design Criteria Conformance Checklist review. Artist is working on scaled depth and texture studies to prepare maquette. Station contractor to implement changes to art wall.
Waipahu Transit Center Station
John Koga NTP1 The TAC reviewed conceptual design submittal #5; revisions recommended.
Rail Operations Center – Operations & Servicing Building
Shigeru Miyamoto
NTP3
Working with the artist on required technical documentation and MSDS information for Safety & Security Design Criteria Conformance Checklist review. The artist needs to submit color samples during NTP3 and NTP4.
Leeward Community College
Donald Lipski NTP4
Safety & Security conducted DCCC review and certified final design and MSDS information. Artist moved to NTP4 (construction, fabrication, transportation, shipping and installation). Received material sample from artist.
Pearlridge Station Robert Kushner NTP4
Artist is working with the fabricator on the production of two 7’x 20’ glass and stone mosaic murals. Received digital images of work in progress. Awaiting the station contractor’s implementation of changes to art wall and paving area to integrate artwork.
Honolulu Rail Transit Project Monthly Progress Report March 2020
99 | P a g e
Station / Facility Name Artist Name NTP Phase Comments
Aloha Stadium Station Jay Wilson NTP1 Revising conceptual design.
Pearl Harbor Naval Base Station
Carol Bennett NTP2 Conceptual design accepted, moved to NTP2.
Honolulu International Airport Station
Mamoru Sato NTP1
Artist submitted revised conceptual designs for the Mauka and Makai artworks. Mayor's Commission on Culture and the Arts review of new design postponed until further notice due to COVID-19 orders. Design work is pending refinement of mullion system used for artwork installation.
Lagoon Drive Station Carol Yotsuda NTP1 Revising conceptual design.
6.6 Planning and Environment Activities this Month
Environmental Compliance o Environmental Due Diligence: Staff received approval from the DOH for the Phase II Work Plan for the Civic
Center. Remediation of the Lee Property, near Pearl Highlands Transit Center is continuing. Staff assisted construction crews to manage contamination encountered at the Middle Street Transit Center. Staff provided DOH with requested disposal and sampling data for soil excavated from the airport. Staff notified DOH of Stormwater discharges, due to a waterline strike and gas line strike.
o Reporting: Staff began reviewing the Mitigation Monitoring Plan to identify any needed updates. o Environmental Review Documentation: On March 3, 2020, staff formally submitted an amendment to the
Ka‘aahi Substation and Specialized Vehicle Parking Environmental Re-Evaluation to the FTA for review and concurrence in order to accommodate a proposed new antenna pole.
Project Mitigation Commitments o Historic Resource Documentation: The pre-draft Historic American Buildings Survey (HABS) documentation
for Chinatown and the pre-draft of the Chinatown Historic District National Register (NR) Update are still under review. Additional peer review comments were received for chapters 8-9 of the pre-draft of the Historic Context Studies (HHM) and additional comments are in preparation for the appendices. Staff completed reviews of the pre-draft National Register of Historic Places (NRHP) nominations for Holau Market and Wo Fat Chop Sui House and prepared a comment review matrices for both nominations. Work continued on the Historic Preservation Certification Application (HPCA) Part II for the Wo Fat Chop Sui House as well. Draft nominations for Waimalu Stream, Kalauao Springs and Kalauao Stream Bridges as well as Nu‘uanu Stream (Queen Street) Bridge, O'ahu Rail & Land Co. Terminal Building, and Wood Tenement Buildings were submitted to the State Historic Preservation Division (SHPD) on March 6, 2020 for public hearing by the Hawai‘i Historic Places Review Board on July 30, 2020.
o Cultural Landscape Reports: Helber Hastert & Fee completed responses for the Mother Waldron Park and Playground Cultural Landscape Report (CLR) and the Walker Park CLR and transmitted them to HART staff to add comments. Revisions to the Walker Park CLR are still in preparation.
o Historic Preservation Fund: Staff continued planning efforts for the public meetings for round 2 of the Historic Preservation Fund, including potential topics and speakers.
o Interpretive and Educational Materials: Staff are reviewing comments on the prototype Stipulation VII educational materials and are working to finalize the comment response matrix.
o Historic Properties: On March 6, 9, 11 and 12, historic properties were encountered during CCUR work along Nimitz Highway between Bethel and Bishop Streets. These properties included historic basalt cables, concrete foundation and fauna deposits. All encounters were sufficiently documented and will be included in the final archaeological monitoring report.
o Section 106 Programmatic Agreement: The FTA Annual Programmatic Agreement (PA) meeting took place on March 10, 2020. The February PA report has been finalized and will be distributed.
Honolulu Rail Transit Project Monthly Progress Report March 2020
100 | P a g e
Sustainable Mobility o Sustainability: Throughout the month of March, staff coordinated with partners, such as Malama Pu‘uloa, to
continue collaborations through increasing uncertainty and ongoing event cancellations. Activities for projects such as the community placemaking arts collaboration with Waipahu High School and HI SOUP have been placed on hold, but are actively being discussed and adapted. One of the primary strategies for integration is information gathering about community response to the COVID-19 crisis to fit community collaborations such as these into recovery plans. The Sustainable Mobility Lab (SuMoLab) is also continuing its work to facilitate collective learning experiences with community members of all ages. In partnership with HawaiiKidsCAN and the Sierra Club of Hawai‘i, staff have participated in a series of online, youth facilitated Community Change Fora. These Fora will continue through April leading up to Earth Day. The SuMoLab is providing facilitation expertise and subject area expertise in livable communities and sustainable transportation. Staff kicked off a project to develop printed materials for the SuMoLab to interface with partners and illustrate the project’s approach to sustainability. This work will be ongoing over the coming months leading up to the opening of interim service. One of the SuMoLab’s key partners, the Sustainable Transportation Coalition of Hawai‘i, was redesignated as a member of the U.S. Department of Energy (USDOE) Clean Cities Coalition. This redesignation is effectively an audit of coalition activities and confirmation of continued alignment with the USDOE’s goals. Rail technology and multimodal integration were among their key opportunities identified for future success of the coalition.
o Transportation Planning: Staff supported DTS in preparing a BUILD grant application, coordinating station planning, design, and construction status with DTS’s multimodal access program. DTS is seeking resources to construct two features providing pedestrian safety and access benefits to several rail stations.
Look Ahead
Preparation of Post-Record of Decision (ROD) and other environmental documentation: o Intelligent Transportation Systems (ITS): SHPD continues to review documentation for an amendment of the
Project Area of Potential Effect (APE) to cover ITS work. o East Kapolei Park-and-Ride Lot: Staff continue to prepare documentation for the relocation and
reconfiguration of the 900-stall park-and-ride lot at the Kualaka‘i (East Kapolei) Station. o City Center/Pearl Highlands: Any project final design refinements or new right-of-way takes will be assessed
and submitted to the FTA, as appropriate. o Kamehameha 138kV Relocation: Overhead 138kV lines are to be relocated between the Waiau Power Plant
and Aloha Stadium in order to provide the required working clearances around the guideway. Analysis is pending development of the preliminary design drawings.
o Right-of-Way and APE Updates: Staff will be documenting project design changes and adjustments to right-of-way acquisitions to date.
6.7 Risk Management Following is a progress report highlighting top risks and mitigation efforts from the March 2020 monthly risk update.
6.7.1 Top Risk Summary
Top Cost Risks
ROW
CCUR: difficult underground conditions
AGS Time Impact Analysis (TIA) for HECO Zone 8 Delay
Procurement Extension (due to COVID-19 impacts)
Opportunities for Cost Savings
P3 competitiveness, innovation for CCGS
CCUR to eliminate unnecessary utility relocations with guideway shift
Top Schedule Risks: Critical or Near Critical Path
CCUR: difficult underground conditions
Delay in City Agency Permitting
Honolulu Rail Transit Project Monthly Progress Report March 2020
101 | P a g e
Top Cost Risks (continued)
Core Systems (until assigned to P3)
Environmental for CCGS (risk sharing)
Delay in obtaining City Agency permitting
Utilities: misidentified and unidentified
ROW: Mauka entrance to Kuloloia Station (at Downtown)
Affordability Cap being exceeded
Possible revocation of noise variance
ROW: Makai entrance to Kuloloia Station (at Downtown)
Utility/Pedestrian bridges over stream (risk should be transferred to budget)
P3 and CCUR interface impacts
CCUR Access Dates if not met for P3
CCUR non-standard work hours
Core Systems, incomplete interface details
ROW – numerous small property acquisitions for straddle bent foundations
Fare Collection Systems: delay if station electrical systems not ready (applies to interim RSD)
Archaeological: unanticipated finds could delay CCGS work
See additional low risks highlighted in green in the table below
Watch List Risks
Coronavirus Concerns. Risk impacts are beginning to be reported in the March 2020 report including the procurement extension due to COVID-19 impacts on the PLO’s ability to price the work. The Risk Manager will continue to status this risk topic with project teams and HART management in ongoing monthly risk updates considering potential impacts to project schedules; availability of labor, equipment and materials; contingency; project funding.
Top Schedule Risks: Critical or Near Critical Path (continued)
Affordability Cap being exceeded (time to resolve)
Procurement Extension (due to COVID-19 impacts)
Environmental for CCGS (risk sharing with P3)
Possible Revocation of Noise Variance
Utilities: misidentified and unidentified
P3 and CCUR interface impacts
CCUR Access Dates if not met for P3
Core Systems, incomplete interface details
ROW – numerous small property acquisitions for straddle bent foundations (currently not critical, but could become critical if delays occur)
Archaeological: unanticipated finds could delay CCGS work
Opportunities for Maintaining Schedule
CCUR opportunity to save time by eliminating unnecessary utility relocations, particularly the 42” water main along Dillingham
Aggressive CEI oversight of CCUR with fully qualified field staff
ROW to maintain schedule for new acquisitions based on final CCGS alignment, through appropriate staff and consultant support
Fill vacant staff positions with existing staff and consultant support
6.7.2 Top Risk Threats and Mitigations
Risk ID Risk Description Risk Threat Score
Risk Mitigation
ROW 60.01_01
ROW: Value of property acquisitions necessary for Rail could increase.
18 1. HART continues to negotiate in good faith with property owners. 2. Appraisals and due diligence through the courts have been supporting HART’s position in obtaining necessary ROW at a reasonable cost.
DBB511 SIT 40.02_02
CCUR: Cost to deal with underground conditions could exceed contract allowances.
18 1. CCUR team continues to explore the most cost-effective ways of dealing with the geotechnical conditions along Dillingham.
DB450 SIT 40.02_11
AGS: HECO Zone 8 Delay. 15 HART is evaluating the TIA for concurrent delays.
Honolulu Rail Transit Project Monthly Progress Report March 2020
102 | P a g e
Risk ID Risk Description Risk Threat Score
Risk Mitigation
P3-DB550 PRO 80.01_06
P3 for CCGS and PH: Risk of Delay of Procurement due to more time requested by P3 PLO’s to prepare their proposals (due to COVID-19 impacts)
15 1. HART has recently extended the procurement timeframe for the P3 PLO’s, in response to the PLO request, to allow sufficient time to price the work given the impacts of COVID-19. This is viewed as an acceptable mitigation under the current circumstances.
DBOM920 SYS 50.01_12
Core Systems: Risk of additional work by Core Systems Contractor following recent settlement, until assigned to P3.
12 1. HART is troubleshooting systems interface issues with West stations work to avoid further cost due to changed conditions. 2. Plan for 2-phase testing at platforms has allowed more time for canopy arm installation, followed by Core Systems devices and testing.
P3-DB550 SIT 40.03_03 (schedule) and 40.03_02 (cost)
P3 for CCGS and PH: Environmental Cleanup, Cost and Schedule Impacts to HART (2 separate risks, but combined here for scoring). The Risk Management System (RMS) adjusted the cost portion of this risk slightly downward based on the expectation that CCUR work will uncover most, if not all, pockets of contamination. There is a risk sharing arrangement in the P3 RFP for environmental cleanup responsibilities.
12 1. Although HART would be responsible for the cost and schedule impact for cleanup of undisclosed contamination, the P3 would be responsible for the schedule risk associated with the cleanup of disclosed contamination. Some cleanup activities could be non-critical path delays depending upon where they occur in the project. 2. HART will handle the cleanup with on-call contractors familiar with this work and who can execute the work most efficiently.
DBB511 SIT 40.08_01
CCUR: Delay in obtaining City Agency Permitting had been forecast and continues to result in delays to critical utility relocation work.
12 HART continues to coordinate with City permitting agencies to provide any further design information that is needed, and to reduce the timeframes for review and permitting of utility relocation work.
DBB511 SIT 40.02_07
CCUR: Scope and schedule of construction could be impacted by the discovery of misidentified and unidentified utilities
12 HART will pay for differences in quantities of utility relocations based on as-bid unit rates.
ROW 60.01_17
ROW: Parcel Scope changes for Mauka Entrance to Kuloloia Station (at Downtown)
12 HART and DTS are evaluating the preferred Mauka station entrance location for the Kuloloia Station (at Downtown). The preferred location is within the courtyard of the existing Pacific Guardian Center (PGC). Initial discussions with the Property Manager have taken place.
P3-DB550 PRO 80.01_07
P3 for CCGS and PH: Risk of Affordability Cap being exceeded for the capital construction and/or the future O&M.
10 1. The Affordability Cap for Capital as well as O&M were provided to the P3 PLO(s) on 26JUL2019 in order to allow HART sufficient time to respond in case concerns are expressed by the PLO(s). 2. HART’s ICE estimate was reviewed and received concurrence from E&Y and from HART’s Project Execution Consultant.
P3-DB550 SIT 40.04_09
P3 for CCGS and PH: Revocation of Noise Variance which allows night and weekend work. This could have a cost and schedule impact to the CCGS project. This is a new risk added in the Feb. 2020 Risk Refresh.
9 HART will pursue greater involvement with the community to inform them of construction activities and be more responsive to their concerns. HART can mitigate by compensating the contractor to utilize noise mitigation strategies and by maintaining open communication with DOH who controls the noise variance.
ROW 60.01_10
ROW: HECO Kuloloia Station (at Downtown) Makai Parcel Scope Changes. Late agreement with HECO for Kuloloia Station (at Downtown) Makai parcel, currently an old power plant, could impact DB contract requirements.
9 Get agreement with HECO and perform early subsurface investigations. Include report in bid documents.
DBB511 SIT 40.06_01
CCUR: Design Build of utility & pedestrian bridges over Kapalama Stream.
9 The alternative to use utility and pedestrian bridges has been reviewed and is believed to be the appropriate solution meeting utility company and environmental requirements. Some portion of this risk may be in the base CCUR cost which will be reviewed with Project Controls.
P3-DB550 SYS 50.03_01
P3 for CCGS and PH: Interface impacts between CCGS and other contracts including CCUR and Core Systems Contractor.
9 While this risk value increased in the November 2019 Risk Refresh, HART is working to make sure CCUR work is completed as expeditiously as possible, and that achievable access dates to the P3 (area by area in the CCGS corridor) are included in the P3 RFP.
Honolulu Rail Transit Project Monthly Progress Report March 2020
103 | P a g e
Risk ID Risk Description Risk Threat Score
Risk Mitigation
P3-DB550 SIT 40.05_02
P3 for CCGS and PH: Potential for CCUR work to extend beyond Access Dates committed to the P3 for CCGS. If committed access dates are not met, then the P3's start of work in those areas could potentially be delayed, placing HART at risk of having to compensate the P3 for owner-caused delay.
9 The P3 Procurement Documents include a list of Access Dates that HART is committing to meet. This risk pertains to HART's guarantee to the P3 that CCUR work will be completed by certain committed dates area by area through the CCGS project.
DBB511 SIT 40.08_07
CCUR: Requirement for Non-standard Work Hours on CCUR work.
9 HART will work with the contractor and approving agencies to mitigate the extent of non-standard work hours potentially being required on the project, which can increase contract costs significantly.
DBOM920 SYS 50.01_01
Core Systems: Incomplete Interface Details (Stations & Guideway).
9 Final interface details are being worked out as West Stations progress much closer to final completion.
ROW 60.01_19
ROW: Cost and time impacts for numerous small property acquisitions necessary for foundations to support straddle bents along Dillingham Blvd and elsewhere.
9 HART Management has begun meetings with affected property owners to advise of the need for straddle bent foundations at specific locations and to attempt to minimize the impacts to the property owners and to seek their cooperation with HART's plan.
MI900 SYS 50.06_11
Fare Collection: Rail Station installation of Fare Systems equipment could be delayed if Stations’ electrical systems are not ready in time for Revenue Service.
9 Coordinate with station contractors to develop and share station as-builts with the Fare System Vendor. Coordinate schedules as well to allow sufficient time for testing and installation at each of the stations.
P3-DB550 GUI 10.04_01
P3 for CCGS and PH: Discovery of unanticipated archaeological findings could result in added cost and schedule impact to HART.
8 The HART Procurement and technical team for the P3 has been working on an appropriate level of risk for the P3 to undertake in dealing appropriately with archaeological finds. HART will be responsible for finds that cause undue cost and schedule delay.
DBOM920 SIT 40.04_01
Core Systems: Operating Noise Exceeds Environmental Impact Statement (EIS) Defined Limits.
6 Tangent track noise test compliant with Technical Provision (TP) requirements. Noise testing in curves still required. Evaluation against EIS noise levels outstanding. Mitigation may require installation of track lubricators along the alignment, implementation of a rail engineer grinding program, and/or noise absorption panels.
ROW 60.01_18
ROW: Net cost to HART for Land Trade for Rail Operations Center.
6 HART is working with the City on this land exchange. The City needs to approve this exchange once it is worked out by the Dept. of Hawaiian Homelands (DHHL).
DBB271 STA 20.05_04
FHSGC: Consolidated Resolution, capturing numerous risks into one agreement with the contractor.
6 HART is continuing to negotiate with the contractor for a fair settlement of all remaining issues through final closeout of the project.
DBB271 STA 20.01_26
FHSGC: Plan B Canopy Redesign Delay Claim.
6 HART is continuing to negotiate with the contractor for a fair settlement of all remaining issues through final closeout of the project.
DBB371 STA 20.02_05
KHSGC: HART Open Changes. 6 HART is continuing to negotiate with the contractor for a fair settlement of all remaining issues through final closeout of the project.
DBB600 SUP 30.01_01
Park-and-Ride Lots: Contingency for Park-and-Ride Lots construction.
6 HART is holding a contingency value until the final park-and-ride locations are determined, designs are complete, and construction is underway.
MI900 SYS 50.06_20
Fare Systems Vendor could experience additional costs.
6 Negotiate change orders with the proper contractor and/or award separate contract as needed for Fare Systems requirements. These requirements pertain to startup and rollout costs that are not included in the scopes of work for the Fare Systems Contractor or Technical Consultant.
UTIL68 SIT 40.02_08
Private Utilities: Construction sequencing for City Center creates additional work for utility companies.
6 HART is working with utility companies to understand the requirement for additional inspectors as the sequence of the CCUR work becomes more apparent through schedule coordination with the contractors involved.
Honolulu Rail Transit Project Monthly Progress Report March 2020
104 | P a g e
Risk ID Risk Description Risk Threat Score
Risk Mitigation
UTIL68 SYS 50.03_01
Private Utilities: HECO Substation needed on land from UH adjacent to MSF, for reliable power for train operations.
6 The substation will need to be tested in June 2020 in time for Interim Revenue of Service in Dec. 2020; otherwise, the frequency of trains passing through this area will need to be reduced until the substation is on line. The substation requires PUC approval which HECO is now applying for.
UTIL68 SIT 40.02_09
HECO KHG 138 kV Relocation to provide adequate separation from guideway.
6 HART will coordinate with the design firm (RM Towill) to guide the scope to remain within reasonable limits, while meeting all necessary HECO requirements. A potholing program is underway to determine the locations of existing utilities along the route, and the reasonableness of undergrounding the 138kV along the highway. The project is in the concept design phase.
MI930 STA 20.07_03
Elevators/Escalators: Increase in Elevator and Escalator Quantity Requirements
6 The final number of additional escalators on all east stations have been determined to be two for AGS, and 11 additional for CCGS. Still need to negotiate a favorable resolution with E&E contractor for CCGS. This risk will be revisited after award of the City Center DB contract.
DBB371 STA 20.02_22
KHSGC: Potential Electrical and Structural Canopy Design Issues.
4 HART is continuing to negotiate with the contractor for a fair settlement of all remaining issues through final closeout of the project.
DB450 SIT 40.02_04
AGS: Conflict Resolution – Costs for Utility Relocations.
4 HART is coordinating with the contractor and utility agencies to mitigate any utility delay risks that could result in cost or schedule impact to the project.
Risk Scoring for Risk Threats The following risk scoring table (used in the calculation of the risk threat scores shown above) is in accordance with FTA guidelines for summarizing the overall severity of project risks. HART has adjusted the cost and schedule ranges shown below in order to scale to the HART Project size.
Risk Scoring for Risk Threats
Impact Scores Legend
Low 1
Medium 2
High 3
(P) Probability <10% >10% <50% >50%
(C) Cost Impact <$10 M >$10 M <$50 M >$50 M
(S) Schedule Impact <1 month >1 month <4 months >4 months
Rating <6 7 - 12 13 - 18
Score = (Cost + Schedule) * Probability
Risks are assessed based on the probability of occurrence, potential (and most likely) cost impact, and potential (and most likely) schedule delay. The total score is arrived at by adding the cost and schedule impact scores, multiplied by the probability score. For example:
40% Probability = 2; A $60 million Cost Impact = 3; A five month Schedule Impact = 3 Resulting Score = 3 + 3 = 6 x 2 = 12; a Medium Risk.
6.7.3 Top Risk Opportunities
Risk ID Risk Description Risk Opportunity Score
Risk Mitigation
P3-550 SIT 40.05_01
P3 for CCGS: Opportunities for P3 innovation through Alternative Technical Concepts (ATC’s).
15 1. HART plans to evaluate and approve ATC’s that are beneficial to the Project. 2. There were ATC’s that were received for previous HART projects, so there is precedence for this possible savings.
DB511 SIT 40.02_15
CCUR: Continue to find opportunities to eliminate unnecessary utility relocations based on results of potholing which is identifying specific utility locations, and ability to shift planned locations of guideway foundations (shafts).
10 1. The CCUR team has identified significant savings to date. 2. There is a reasonable probability that additional savings can be realized which should provide sufficient contingency with the CCUR contract to address further unknowns that will need to be dealt with as City Center utility relocations continue.
Honolulu Rail Transit Project Monthly Progress Report March 2020
105 | P a g e
Risk ID Risk Description Risk Opportunity Score
Risk Mitigation
275 PRO 80.01_01
P3-PHPTR: Opportunity for P3 to present a modest cost reduction for construction of the Pearl Highlands Garage and Transit Center.
9 HART has been working to make the RFP as performance-based as possible so that it allows creativity from the P3 team(s).
P3-DB550 PRO 80.01_02
P3 for CCGS: Opportunity for P3 to present a modest cost reduction for construction of City Center Guideway and Stations, and remaining Core Systems work.
6 HART has been working to make the RFP as performance-based as possible so that it allows creativity from the P3 team(s).
Risk Scoring for Risk Opportunities
Risk Scoring for Risk Opportunities
Impact Scores Legend
Low 1
Medium 2
High 3
(P) Probability <10% >10% <50% >50%
(C) Cost Impact <$10 M >$10 M <$50 M >$50 M
(S) Schedule Impact <1 month >1 month <4 months >4 months
Rating <6 7 - 12 13 - 18
Score = (Cost + Schedule) * Probability
Similar to the legend for scoring of Risk Threats, Risk Opportunities are assessed based on the probability of occurrence, potential (and most likely) cost impact, and potential (and most likely) schedule delay. The total score is arrived at by adding the cost and schedule impact scores, multiplied by the probability score. The scoring calculation for Risk Opportunities is the same as for Risk Threats; however, in the Opportunities scoring table above, high opportunity scores are colored green (versus red), low opportunity scores are colored blue (versus green), and medium opportunity scores are still colored yellow. 6.7.4. Recent Risk Updates
The most recent monthly risk update occurred in March 2020, the results of which are discussed herein. These results will be summarized in the meeting with FTA and the PMOC at the next Monthly Progress Meeting on April 8, 2020. The P65 results now place the projected forecast at $8.246 billion, which is $81 million above HART’s budget goal of $8.165 billion, and $53 million below the overall budget goal of $8.299 billion as recommended by PMOC and FTA.
At the most recent quarterly update held in February 2020, the Risk Refresh was facilitated by the Risk Manager. This involved face to face meetings with project team members to review each risk, discuss their validity and if any adjustments are needed to the post-mitigated responses, discuss if any new risks are necessary, and to explore ongoing risk mitigation efforts. The results of the February 2020 Risk Refresh were reflected in HART’s Monthly Report for February 2020. The next quarterly Risk Refresh will be held in mid-May 2020.
The most significant risk adjustment in the March 2020 risk update included: 1. P3 for CCGS and PH: Risk of Delay of Procurement due to more time requested by P3 PLO’s to prepare
their proposals due to COVID-19 impacts. HART has recently extended the procurement timeframe for the P3 PLO’s, in response to the PLO request, to allow sufficient time to price the work given the impacts of COVID-19. This is viewed as an acceptable mitigation under the current circumstances.
Two significant adjustments in the February 2020 Risk Refresh included: P3 for CCGS and PHPTR: 1. New Risk: Revocation of Noise Variance which allows night and weekend work. This risk poses a modest
direct cost impact, and a potential schedule impact. The Risk Manager added this new risk and its associated value based on meetings and conversations with HART Environmental and construction oversight staff.
Honolulu Rail Transit Project Monthly Progress Report March 2020
106 | P a g e
2. Environmental Risk adjustment, due to risk sharing between HART and the P3. This means HART will have cost and some schedule responsibility for environmental cleanup which has the potential to delay the P3 for CCGS. Adjusted this risk based on meetings and conversations with HART Environmental and construction oversight staff.
6.7.5. Cost and Schedule Probability Curves from March 2020 Risk Update Figure 11. Cost Probability Curve, March 2020 Risk Data
The update shown in Figure 11 resulted in a $24 million increase to the P65 risk expected value when comparing the March 2020 update (shown above) to the February 2020 update (shown in the prior report). This increase is due to risk adjustments over the last month as outlined above, which will be discussed in detail with HART Management, the FTA and the PMOC at the Monthly Progress Meeting on April 8, 2020. The P65 for the overall HART project is now $8.246 billion, which is $81 million above HART’s budget goal of $8.165 billion, and is $53 million below FTA/PMOC’s recommended budget of $8.299 billion.
Honolulu Rail Transit Project Monthly Progress Report March 2020
107 | P a g e
Figure 12. Schedule Probability Curve, March 2020 Risk Data
The schedule update shown in Figure 12 resulted in a 2-month extension in the P65 schedule risk assessment when comparing the March 2020 update (October 2026 shown above) to the February 2020 update (August 2026 shown in the prior report). Schedule risks will be discussed in detail with HART Management, the FTA and the PMOC at the Monthly Progress Meeting on April 8, 2020. The P65 for the overall HART project is now October 2026, which is 10 months beyond HART’s stated schedule goal of December 2025, and 1 month beyond the PMOC recommended target date of September 2026 for meeting final revenue service. 6.7.6. Ongoing Risk Mitigation Efforts The P65 schedule extension to October 2026 from the March 2020 risk update (formerly August 2026 from the February 2020 risk update, and July 2026 from the January 2020 and December 2019 risk updates) is a significant concern to HART. The project delivery timeframe for CCGS to still accomplish the full RSD by December 2025 had been a significant HART goal, which is now overshadowed by the expanding threat of the COVID-19 pandemic on not only the HART Project, but on the state of Hawai‘i, as well as nearly all populations and countries around the world. Nevertheless, HART will maintain particular focus on the following risk areas in order to complete the Project as expeditiously as possible once the threat of the Coronavirus has passed:
1. Expedite the ROW acquisition schedule for necessary acquisitions to accommodate utility relocations (CCUR) and necessary space for straddle bent foundations along the CCGS route. Ensure qualified ROW staff are in place and necessary support is received from HART’s Real Estate Consultant. All necessary ROW must be acquired in time for P3 Access Dates to be met.
2. Expedite the City Center Utilities Relocations and Road work (CCUR) in time to meet area by area Access Dates being committed to the P3 PLO’s in the procurement documents. This can be accomplished by securing all third party agreements and permits in advance, and maintaining the right level of qualified CEI staff for design oversight and field construction oversight. Ensure that the CCUR contractor is executing the work as proactively as possible with qualified construction staff, equipment selections, and effective maintenance-of-traffic planning. HART is preparing a procurement for a second CCUR contractor to expedite the work. The base estimate update for CCUR is being reviewed, as of March 2020, the results of which will be incorporated into the next risk update as soon as the results are reported.
Honolulu Rail Transit Project Monthly Progress Report March 2020
108 | P a g e
3. Ensure that the approach to dealing with both identified and unidentified environmental contamination, and/or archaeological finds, are agreed with DOH and other oversight agencies in advance, in order to deal with the impacts encountered during construction appropriately and as expeditiously as possible. HART will need to set aside adequate contingency to pay for this cleanup work due to the risk transfers from the P3 to HART, which HART believes can be effectively managed by HART’s on-call environmental cleanup contractors.
4. Incentivize the future P3 contractor to complete the CCGS and Pearl Highlands Garage, Transit Center and Ramps work in the most reasonable timeframe that can be forecast, for final RSD as close as possible to the FTA stipulated target of September 2026.
5. Ensure all necessary procurement procedures are being followed correctly. Minimize the possibility of a protest over procedural issues related to this important procurement. A time extension to the P3 procurement was recently granted due to the COVID-19 concerns, which was a reasonable response by HART to the PLO(s) request for more time given the difficult current circumstance of pricing the work until the virus threat has passed.
6. Ensure final completion and closeout of the west station projects by mid-2020, in order to obtain Interim Revenue Service as soon as is reasonable in late 2020 or early 2021 (given the COVID-19 concerns), and to have this west section fully functional and ready for turnover to the P3 at the appropriate date to be clarified in the P3 RFP.
As reflected above, the current schedule risk forecast identifies potential concerns with risks in the categories of Right-of-Way, Utilities Relocations, Environmental, Archaeological, and Procurement, some of which are exacerbated by the increasing COVID-19 impacts on the HART Project. The schedule risk forecast suggests if ongoing mitigation efforts related to these risks fail, or if problems related to the COVID-19 pandemic worsen, the delay consequences could be severe.
6.8 Construction Claims Pursuant to FTA Circular 4220.1F, HART is obligated to notify the FTA and PMOC about third-party claims and litigation with which it is involved. HART considers a “claim” to arise when a third-party contractor submits a request for a final written decision by the Contracting Officer. Pursuant to Hawai‘i Revised Statutes Section 103D-711 and Hawai‘i Administrative Rules Section 3-126-28, the Contracting Officer’s decision is deemed final and the basis on which the aggrieved party can initiate an action in Circuit Court within six (6) months of receipt of the Contracting Officer’s decision.
HART is tracking the following claims:
Contract Contractor Claim Description Claim Amount Status
FHSG Hawaiian Dredging
Construction Co.
HDCC seeks compensation for premium costs to furnish manpower from out-of-state for the period from April 2017 through August 2017 due to the unavailability of local manpower.
$103,167 HDCC submitted a request for a final written decision by the Contracting Officer on Jan. 22, 2019. This matter has been taken under consideration.
FHSG Hawaiian Dredging
Construction Co.
HDCC seeks compensation for additional staffing and resources from Notice to Proceed through January 2018.
$3,438,061 HDCC submitted a request for a final written decision by the Contracting Officer on Feb. 12, 2019. This matter has been taken under consideration.
FHSG Hawaiian Dredging
Construction Co.
HDCC seeks compensation for providing NEMA Type 4X, stainless steel electrical enclosures.
$194,360 HDCC submitted a request for a final written decision by the Contracting Officer on Jan. 22, 2019. This matter has been taken under consideration.
FHSG Hawaiian Dredging
Construction Co.
HDCC seeks compensation for shoring for the Waipahu Transit Center platform box girder construction.
$670,060 HDCC submitted a request for a final written decision by the Contracting Officer on Jan. 22, 2019. This matter has been taken under consideration.
Honolulu Rail Transit Project Monthly Progress Report March 2020
109 | P a g e
6.9 Community Outreach Overview
Since the inception of HART, the outreach team has participated in: o 1,506 Public Presentations and Events
The HART Public Involvement (PI) team participated in a total of 6 events and presentations in March 2020. Due to the COVID-19 pandemic, many public events and meetings – which HART was supposed to present or participate as part of its public outreach activities – were cancelled or postponed.
Community outreach events in March included a construction safety presentation to more than 800 students and faculty at Kalakaua Middle School, a community meeting for construction mobilization for CCUR Dillingham Boulevard Section 1A at Kalihi Kai Elementary School, and general project update speaker’s bureau presentations at Central Pacific Bank and the Executive Network Council of Honolulu. HART also presented one train tour at the Rail Operations Center for the Pacific Century Fellows Hawai‘i.
The agency also soft-opened its HART Business and Community Outreach Center at City Square on Monday, March 30, 2020. The center currently is staffed with 2-3 HART business and construction outreach staff members and will be open weekly for appointments only from 10 a.m. – 2 p.m. on Monday, Wednesday and Friday. The center also serves as a location in the community where staff can deploy into the community for construction emergencies or access issues that may affect residents or businesses that need assistance. HART will present a formal media launch and public opening of the center, once the City’s COVID-19 Work at Home/Shelter in Place Order is lifted.
o 888 Neighborhood Board Meetings HART attended or presented written reports for 9 Neighborhood Board Meetings in March 2020.
Community Input HART's public outreach team responded to 73 public inquiries and comments via the 24-hour project hotline (34
inquiries) and project email ([email protected] with 39 inquiries), during the month of March 2020. Inquiries were generally related to construction inquiries for Dillingham Boulevard and Kaka‘ako/Ala Moana, and HART-presented community meetings.
6.10 Staffing Overview
Organization: The latest organizational chart is dated Jan. 29, 2020. Please see Appendix D. Project Staffing:
o Target (Allocated) City Positions: 135 Full-Time Equivalent (FTE) City Staff. Does not include Project Management Support consultants below.
o Filled City Positions: 118 Employees: (100) Personal Services Contract [PSC] Employees, (1) Civil Service, (5) Appointees, (4) 89-day contract, (8) Interns
Vacancy Rate 2020
January February March April May June
17.03% 13.3% 13.3% - - -
July August September October November December
- - - - - -
o Project Management Support Consultant (HDR) Staff Total: 18 HDR employees embedded in the HART
organization directly participating in the management of the project, 2 HDR employees working for the State Historic Preservation Division (SHPD) providing support services, and 1 HDR employee assisting HART on a part-time basis with risk modeling (statistical analysis and risk report production).
Honolulu Rail Transit Project Monthly Progress Report March 2020
110 | P a g e
Positions Filled in March: o Secretary I o Accountant V o Computer Programmer III
Projected Position Fills: o Deputy Director of Administrative Services, Administrative Services – May o Accountant I - April o Accountant II – April o Right of Way Specialist – April o Information Specialist I - April o Internal Controls Analyst III – May o Fixed Asset Specialist – May o Secretary III - April
March Departures: o Secretary III o Human Resources Specialist V
Projected Departures: o N/A
Figure 13. Staffing Activities
Staffing Activities
Title Group
New/Existing HART
Position (City or PMC)
Position Status* Start Month
P3 , Core Systems, and Readiness and Activation
Engineer Core Systems Existing (City) Recruiting - PSC
Engineer Readiness and Activation New (City) Recruiting - PSC
Secretary III Core Systems Existing (City) Selected – PSC April
Design & Construction
Program Manager Production East Area Construction Existing (City) Recruiting - PSC
Assistant Area Manager East Area Construction Existing (City) Recruiting - PSC
Secretary I Design & Construction Existing (City) Filled – PSC March
Transportation Planner Third Party and Traffic Engineering
New (City) Recruiting - PSC
Transit Property Acquisition & Relocation
Right of Way Specialist Transit Property Acquisition & Relocation
Existing (City) Selected - PSC April
Right of Way Specialist Transit Property Acquisition & Relocation
Existing (City) Recruiting - PSC
Planning
Planner (Land Use) Planning Existing (City) Recruiting – PSC
Hazmat Planner Planning Existing (City) Recruiting - PSC
Transportation Planner Planning Existing (City) Recruiting - PSC
Budget & Finance
Financial Services Manager Budget & Finance Existing (City) Filled Temp Agency
Accountant I Budget & Finance Existing (City) Selected – PSC April
Accountant II Budget & Finance Existing (City) Selected – PSC April
Accountant V Budget & Finance Existing (City) Filled – PSC March
Internal Controls Analyst III Budget & Accounting Existing (City) Selected – PSC May
Financial Analyst/Management Analyst
Budget & Finance Existing (City) Filled Temp Agency
Financial/Management Analyst (Financing)
Budget & Finance Existing (City) Filled Temp Agency
OCIP/Risk Compliance Budget & Finance Existing (City) Filled Temp Agency
Project Controls
Financial Analyst Project Controls Existing (City) Recruiting – PSC
Honolulu Rail Transit Project Monthly Progress Report March 2020
111 | P a g e
Staffing Activities
Title Group
New/Existing HART
Position (City or PMC)
Position Status* Start Month
Computer Programmer Project Controls Existing (City) Filled – PSC March
Procurement, Contracts & Construction Claims
Director Procurement, Contracts, and Construction Claims
Procurement, Contracts and Construction Claims
Existing (City) Recruiting – PSC
Procurement & Specifications Specialist
Procurement & Consultant Contracts
Existing (City) Recruiting - PSC
Procurement & Specifications Specialist
Procurement & Consultant Contracts
Existing (City) Recruiting - PSC
Contracts Manager Contract Administration Existing (City) Recruiting – PSC
Construction Claims Manager Construction Claims Existing (City) Recruiting - PSC
Administrative Services
Deputy Director of Administrative Services
Administrative Services New (City) Selected – PSC May
Human Resources Specialist V Administrative Services Existing (City) Recruiting - PSC
Public Involvement
Public Involvement Officer Public Involvement Existing (City) Recruiting - PSC
Information Specialist Public Involvement Existing (City) Selected - PSC April
System Safety and Security
System Safety Engineer Safety Existing (City) Recruiting - PSC
Asset Management
Fixed Asset Specialist Executive Management New (City) Selected – PSC May
*Personal Services Contracts are limited to one year per the Revised Charter of the City and County of Honolulu, Sec. 6-1103(g).
6.11 HART Baseline Plans and Procedures Status List The status of the Baseline Plans and Procedures is shown below (NOTE: changes, if any, are in bold font):
Owner Plan/Procedure Revision Level Date Approved Status
Project Management (Sam Carnaggio)
Project Management Plan (PMP)
7.0 December 10, 2018 Approved/Baselined
Safety and Security (Ralph McKinney)
Construction Safety and Security Plan (CSSP)
5.0 March 5, 2019 Approved/Baselined
Safety and Security Certification Plan (SSCP)
7.0 January 30, 2019 Approved/Baselined
Safety and Security Management Plan (SSMP)
8.0 February 11, 2019 Approved/Baselined
Sensitive Safety Information Plan
1.0 December 13, 2017 Approved/Baselined
Preliminary Hazard Analysis (PHA)
4.0 July 3, 2019 Approved/Baselined
Threat and Vulnerability Assessment (TVA)
2.0 January 12, 2018 Approved/Baselined
Incident Investigation Procedure
0.0 February 28, 2019 Approved/Baselined
Honolulu Rail Transit Project Monthly Progress Report March 2020
112 | P a g e
Owner Plan/Procedure Revision Level Date Approved Status
Quality Assurance (Alberto Bonifacio)
1.PP-02, Project Procedure and Plan Revision and Control Procedure
4.0 February 22, 2019 Approved/Baselined
1.PP-03, Standard Terms, Definitions, and Acronyms Procedure
3.0 February 21, 2019 Approved/Baselined
3.PM-05, Meeting Minutes Procedure
4.0 January 28, 2019 Approved/Baselined
6.CM-01, Submittal Processing Procedure
4.0 January 28, 2019 Approved/Baselined
Quality Management Plan (QMP)
4.0 November 9, 2018 Approved/Baselined
Procurement, Contracts, and Construction
2.PA-09, Procurement Standards of Conduct Procedure
2.0 March 6, 2019 Approved/Baselined
Claims (David Ha)
2.PA-10, Procurement Methods Procedure
1.0 February 13, 2019 Approved/Baselined
2.PA-11, Procurement Full and Open Competition Procedure
1.0 February 13, 2019 Approved/Baselined
2.PA-12, Procurement Federal Compliance Procedure
1.0 March 5, 2019 Approved/Baselined
2.PA-13, Procurement Protests Procedure
2.0 February 13, 2019 Approved/Baselined
2.PA-14, Procurement Record-keeping Procedure
1.0 April 2, 2019 Approved/Baselined
2.PA-15, Stipend Payment Procedure
1.0 February 11, 2019 Approved/Baselined
2.PA-16 Executive Decision Document (EDD) Procedure
0.0 January 24, 2019 Approved/Baselined
5.CA-06, Project Closeout Procedure
3.0 April 23, 2019 Approved/Baselined
5.CA-11, Contract Changes Procedure
5.0 April 25, 2019 Approved/Baselined
5.CA-12 Professional Services and Utility Engineering Services Agreement Contract Closeout Procedure
0.0 November 4, 2019 Approved/Baselined
Buy America Plan (BAP) 3.0 April 9, 2019 Approved/Baselined
HART Procurement Manual
1.0 April 25, 2019 Approved/Baselined
(David Uchiyama) 5.CA-13 Consultant Performance Milestone Evaluation Procedure
0.0 February 24, 2020 Approved/Baselined
Honolulu Rail Transit Project Monthly Progress Report March 2020
113 | P a g e
Owner Plan/Procedure Revision Level Date Approved Status
5.CA-14 Consultant Performance Evaluation Procedure
0.0 February 24, 2020 Approved/Baselined
Project Controls (Nate Meddings)
2.PA-04, Project-wide Document Control and Project Library Procedure
4.0 November 25, 2019 Approved/Baselined
3.PM-01, Contract Management System Procedure
3.0 March 13, 2019 Approved/Baselined
4.PC-03, Project Progress Report Procedure
3.0 March 19, 2019 Approved/Baselined
4.PC-04, Project Scheduling Procedure
4.0 August 15, 2018 Approved/Baselined
4.PC-06, Cost Estimating Procedure
3.0 December 13, 2017 Approved/Baselined
4.PC-07, Cost Control Procedure
3.0 March 25, 2019 Approved/Baselined
4.PC-09, Contingency Management Procedure
2.0 March 5, 2019 Approved/Baselined
Contract Packaging Plan (CPP)
6.0 October 4, 2018 Approved/Baselined
Budget and Finance (Ruth Lohr)
5.CA-03, Contractor Payment Application Procedure
3.0 March 22, 2019 Approved/Baselined
5.CA-10, Consultant Invoice Payment Procedure
1.0 March 27, 2019 Approved/Baselined
7.GA-04, Petty Cash Procedure
3.0 January 9, 2019 Approved/Baselined
7.GA-06, Travel Procedure
3.0 March 29, 2019 Approved/Baselined
Project Financial Plan (PFP): Revised Recovery Plan
1.0 November 19, 2018 Approved/Baselined
Planning and Permitting (Ryan Tam)
6.CM-08, Environmental Procedure
1.0 April 1, 2019 Approved/Baselined
Before-and-After Study Plan
1.0 March 25, 2019 Approved/Baselined
Bus Fleet Management Plan (BFMP)
5.0 April 15, 2019 Approved/Baselined
Mitigation Monitoring Plan (MMP)
3.0 March 7, 2019 Approved/Baselined
Right-of-Way (Dylan Jones)
Real Estate Acquisition Management Plan (RAMP)
7.0 January 23, 2019 Approved/Baselined
Honolulu Rail Transit Project Monthly Progress Report March 2020
114 | P a g e
Owner Plan/Procedure Revision Level Date Approved Status
Public Information (Joyce Oliveira)
2.PA-06, Community Relations and Media Contacts Procedure
3.0 March 6, 2019 Approved/Baselined
3.PM-04, Public Involvement Communications Procedure
3.0 March 6, 2019 Approved/Baselined
Public Involvement Plan (PIP)
2.0 March 4, 2019 Approved/Baselined
Design and Construction (Frank Kosich)
6.CM-02, Request for Information (RFI) Processing Procedure
3.0 March 15, 2019 Approved/Baselined
CADD Procedures 2.0 March 19, 2019 Approved/Baselined
Configuration Management Plan (CFMP)
4.0 March 27, 2019 Approved/Baselined
Construction Management Plan (CMP)
4.0 March 25, 2019 Approved/Baselined
Operation and Maintenance (Robert Good/DTS)
Interface Management Plan (IMP)
4.0 March 6, 2019 Approved/Baselined
System Integration and Test Plan (SITP)
2.0 March 1, 2019 Approved/Baselined
Rail Fleet Management Plan (RFMP)
2.0 March 28, 2019 Approved/Baselined
Operation and Management Plan (OMP)
2.0 March 28, 2019 Approved/Baselined
Rail Activation Plan 2.0 February 11, 2019 Approved/Baselined
2. PA-17 DTS – HART Communication Procedure
0.0 July 15, 2019 Approved/Baselined
Administrative Services (Dexter Suzuki)
1.PP-05, Identification Badge Procedure
3.0 January 24, 2019 Approved/Baselined
2.PA-03, Email Management Procedure
3.0 January 31, 2019 Approved/Baselined
2.PA-07, Training Procedure
3.0 January 31, 2019 Approved/Baselined
Staffing and Succession Plan
6.0 March 20, 2019 Approved/Baselined
Risk Management (Paul Johnson)
4.PC-08, Risk Management Procedure
3.0 March 8, 2019 Approved/Baselined
Risk and Contingency Management Plan (RCMP)
3.0 March 8, 2019 Approved/Baselined
Honolulu Rail Transit Project Monthly Progress Report March 2020
115 | P a g e
6.12 Readiness and Activation
Overview of Key Responsibilities Oversight of the Core System Contractor’s Operations and Maintenance (O&M) development and mobilization. Review and support of HART project activities with an emphasis on O&M impact assessment. Collaborating with DTS to ensure readiness for O&M responsibilities.
Ongoing Activities Supporting P3 procurement process. Updated March HART Board Meeting on readiness and activation status. Key HRH Mobilization Activities
o Document Development HSQE documents are being finalized with stakeholders. O&M Management and Staffing Plan and Trial Run Plan are under formal review. Developing Trial Run Scenarios and Test Cases. O&M Mobilization Team is supported by up to 30 FTE experienced rail consultants.
o O&M Training is on schedule to start April 6. Training course development continues to progress on schedule.
o HRH continues to actively recruit key positions and experienced rail transit personnel. HRH Head of O&M – Americas is currently supporting the on-site mobilization effort. HRH
proposed a candidate for permanent O&M Director. HRH proposed a candidate for Operations Director. Mass recruitment efforts met the March hiring target.
o Maintenance Activities Asset Management and Maintenance Management Plans officially submitted for review. Maintenance document suite drafted and under review. MMIS final design workshop completed March 3-12.
Module development and implementation “Sprints”.
Prototyping preventative maintenance workflow. Continued oversight and auditing of the HRH maintenance program and Key Performance
Indicators (KPIs). o Ongoing COVID-19 program impact assessment.
DTS and project stakeholder coordination o Facilitate Interim Opening Task Force Meeting with DTS, BFS, and City Stakeholders. o Supporting document reviews per HART Charter Amendment 4 MOU procedure. o Facilitating negotiations for Amendment 1 and 2 to the HDOT West O‘ahu Farrington Highway Master
Agreement, and Joint Use and Occupancy Agreement. o Supporting development of joint HART-DTS schedule and identification of critical path items for
Intermediate Operations and Maintenance Period (IOMP) 1. o Transit Agency Rail Safety Plan submitted to HDOT. System Security Plan in final preparation for
submission. HRH revised and submitted supporting documentation. Supporting HART Safety revisions of Operational Readiness Conformance Checklist (ORCC) to correspond with
HRH Training Program Structure. Actively recruiting the HART position to support HRH Mobilization oversight, technical reviews, and asset
management program development. Also recruiting a summer engineering intern to assist the Facility Maintenance Manager and Fare Systems Manager.
Fare Systems (see Fare Systems section of report).
Look Ahead
Continued development of a COVID-19 Mitigation Plan for HRH Hiring and Training.
O&M Rule Book Workshop (April).
HRH and HART developing a consolidated Hazard Log, target completion by end of April.
Oversight Procedure (OP) 54 discussion with HDOT is scheduled for May/June. o FTA review is scheduled for July.
Honolulu Rail Transit Project Monthly Progress Report March 2020
116 | P a g e
APPENDICES
Ho
no
lulu
Rai
l Tra
nsi
t P
roje
ct M
on
thly
Pro
gre
ss R
ep
ort
M
arch
20
20
11
7 |
Pa
ge
A
pp
en
dix
A.
Pro
ject
Co
sts
by
SCC
– L
eve
l 2 (d
ata
as o
f M
arch
31
, 20
20
)
Co
st r
epo
rts
are
run
fro
m t
he
HA
RT
Co
ntr
act
Man
agem
ent
Syst
em
(C
MS)
SCC
De
scri
pti
on
Bas
e C
ost
Co
nti
nge
ncy
Tota
lB
ase
Co
stC
on
tin
gen
cyTo
tal
Incu
rre
d
10
GU
IDEW
AY
& T
RA
CK
ELE
MEN
TS1
,38
5,6
13
,35
0
22
2,8
68
,32
5
1
,60
8,4
81
,67
5
1,4
76
,10
6,1
92
1
32
,37
5,4
84
1,6
08
,48
1,6
76
8
94
,38
6,8
30
10
.02
Gu
idew
ay:
At-
gra
de
sem
i-ex
clu
sive
17
,37
8
-
1
7,3
78
17
,37
8
-
1
7,3
78
17
,37
8
1
0.0
4G
uid
ewa
y: A
eria
l st
ruct
ure
1,2
43
,17
0,3
39
2
14
,66
8,3
25
1,4
57
,83
8,6
64
1
,33
3,6
63
,18
1
12
4,1
75
,48
4
1
,45
7,8
38
,66
5
80
6,4
27
,30
4
1
0.0
5G
uid
ewa
y: B
uil
t-u
p f
ill
-
-
-
-
-
-
5,0
54
,74
4
1
0.0
6G
uid
ewa
y: U
nd
ergr
ou
nd
Cu
t &
Cvr
-
-
-
-
-
-
(1,2
28
,00
0)
1
0.0
8G
uid
ewa
y: R
eta
ined
cu
t o
r fi
ll1
42
,42
5,6
33
8,2
00
,00
0
1
50
,62
5,6
33
14
2,4
25
,63
3
8
,20
0,0
00
15
0,6
25
,63
3
-
1
0.0
9Tr
ack
: Dir
ect
fixa
tio
n-
-
-
-
-
-
8
0,1
90
,15
5
10
.11
Tra
ck: B
all
ast
ed-
-
-
-
-
-
2
,39
4,3
73
10
.12
Tra
ck: S
pec
ial
(sw
itch
es, t
urn
ou
ts)
-
-
-
-
-
-
1,5
30
,87
6
2
0ST
ATI
ON
S, S
TOP
S, T
ERM
INA
LS, I
NTE
RM
OD
A7
40
,27
8,8
79
91
,42
3,1
95
8
31
,70
2,0
74
81
6,0
80
,14
7
1
6,5
30
,80
0
83
2,6
10
,94
7
2
59
,51
8,1
34
20
.01
At-
gra
de
sta
tio
n, s
top
, sh
elte
r, m
all
, ter
min
al,
pla
tfo
rm4
,95
6,1
81
8,5
05
,32
5
1
3,4
61
,50
6
4,9
56
,18
1
8
,50
5,3
25
13
,46
1,5
06
2
24
,87
5
20
.02
Aer
ial
sta
tio
n, s
top
, sh
elte
r, m
all
, ter
min
al,
pla
tfo
rm5
48
,21
9,0
08
54
,49
6,4
53
6
02
,71
5,4
61
63
0,3
40
,02
9
(2
6,7
15
,69
5)
60
3,6
24
,33
4
2
42
,23
4,3
69
20
.04
Oth
er s
tati
on
s, l
an
din
gs, t
erm
ina
l-
-
-
-
-
-
-
2
0.0
6A
uto
mo
bil
e p
ark
ing
mu
lti-
sto
ry s
tru
ctu
re1
21
,60
9,4
73
26
,63
2,4
75
1
48
,24
1,9
48
12
3,2
59
,47
3
2
4,9
82
,47
5
14
8,2
41
,94
8
-
2
0.0
7El
eva
tors
, esc
ala
tors
65
,49
4,2
17
1
,78
8,9
42
67
,28
3,1
59
5
7,5
24
,46
4
9,7
58
,69
5
6
7,2
83
,15
9
17
,05
8,8
90
3
0SU
PP
OR
T FA
CIL
ITIE
S: Y
AR
DS,
SH
OP
S, A
DM
IN. B
LDG
S1
00
,80
6,8
54
-
10
0,8
06
,85
4
1
00
,80
6,8
54
-
10
0,8
06
,85
4
1
22
,26
7,6
92
30
.01
Ad
min
istr
ati
on
Bu
ild
ing:
Off
ice,
Sa
les
-
-
-
-
-
-
23
1,2
50
3
0.0
2Li
ght
Ma
inte
na
nce
Fa
cili
ty
3,0
57
,24
0
-
3
,05
7,2
40
3,0
57
,24
0
-
3
,05
7,2
40
7,5
82
,70
4
3
0.0
3H
eavy
Ma
inte
na
nce
Fa
cili
ty6
4,4
79
,55
6
-
64
,47
9,5
56
6
4,4
79
,55
6
-
64
,47
9,5
56
4
6,2
95
,36
6
30
.04
Sto
rage
or
Ma
inte
na
nce
of
Wa
y B
uil
din
g8
,61
9,2
30
-
8,6
19
,23
0
8
,61
9,2
30
-
8,6
19
,23
0
8
,89
2,7
39
30
.05
Yard
an
d Y
ard
Tra
ck2
4,6
50
,82
8
-
24
,65
0,8
28
2
4,6
50
,82
8
-
24
,65
0,8
28
5
9,2
65
,63
3
40
SITE
WO
RK
& S
PEC
IAL
CO
ND
ITIO
NS
2,3
15
,29
4,4
90
2
30
,44
2,9
32
2,5
45
,73
7,4
22
2
,18
6,1
79
,96
1
35
3,6
35
,81
9
2
,53
9,8
15
,78
0
1,0
35
,60
4,0
14
4
0.0
1D
emo
liti
on
, Cle
ari
ng,
Ea
rth
wo
rk3
3,4
46
,02
9
1,0
38
,00
0
3
4,4
84
,02
9
33
,44
6,0
29
1
,03
8,0
00
34
,48
4,0
29
6
,12
0,7
53
40
.02
Site
Uti
liti
es, U
tili
ty R
elo
cati
on
78
4,9
93
,47
4
9
7,1
26
,87
4
88
2,1
20
,34
8
7
75
,37
3,6
21
99
,74
0,0
85
8
75
,11
3,7
06
21
7,7
95
,92
1
4
0.0
3H
az.
Ma
t’l,
co
nta
m’d
so
il r
emo
val/
mit
iga
tio
n, g
rou
nd
wa
ter
trea
tmen
ts3
3,8
29
,68
3
51
5,0
00
3
4,3
44
,68
3
33
,82
9,6
83
5
15
,00
0
34
,34
4,6
83
2
0,8
91
,73
8
40
.04
Envi
ron
men
tal
mit
iga
tio
n, e
.g. w
etla
nd
s, h
isto
ric/
arc
heo
logi
c, p
ark
s5
,51
8,8
64
-
5,5
18
,86
4
8
,41
7,8
64
(2,8
99
,00
0)
5
,51
8,8
64
15
,47
8,6
42
4
0.0
5Si
te s
tru
ctu
res
incl
ud
ing
reta
inin
g w
all
s, s
ou
nd
wa
lls
21
,76
4,9
85
6
,88
4,5
11
28
,64
9,4
96
2
1,7
64
,98
5
6,8
84
,51
1
2
8,6
49
,49
6
13
,12
5,0
42
4
0.0
6P
edes
tria
n /
bik
e a
cces
s a
nd
acc
om
mo
da
tio
n, l
an
dsc
ap
ing
14
,74
4,2
76
5
00
,00
0
15
,24
4,2
76
1
4,7
44
,27
6
50
0,0
00
1
5,2
44
,27
6
2,1
33
,60
6
4
0.0
7A
uto
mo
bil
e, b
us,
va
n a
cces
swa
ys i
ncl
ud
ing
roa
ds,
pa
rkin
g lo
ts2
64
,58
0,5
24
29
,23
7,5
68
2
93
,81
8,0
92
27
5,7
06
,52
5
1
8,1
11
,56
7
29
3,8
18
,09
2
8
9,4
78
,00
0
40
.08
Tem
po
rary
Fa
cili
ties
an
d o
ther
in
dir
ect
cost
s d
uri
ng
con
stru
ctio
n1
,15
6,4
16
,65
5
95
,14
0,9
79
1
,25
1,5
57
,63
4
1,0
22
,89
6,9
78
2
29
,74
5,6
56
1,2
52
,64
2,6
34
6
70
,58
0,3
11
50
SYST
EMS
31
3,9
83
,93
9
1
6,0
33
,66
8
33
0,0
17
,60
7
3
27
,92
5,1
71
6,5
45
,20
4
3
34
,47
0,3
75
15
8,7
54
,55
2
5
0.0
1Tr
ain
co
ntr
ol
an
d s
ign
als
15
7,0
77
,73
2
7
,75
6,5
22
16
4,8
34
,25
4
1
70
,24
4,1
95
(95
7,1
73
)
1
69
,28
7,0
22
68
,39
0,8
62
5
0.0
2Tr
aff
ic s
ign
als
an
d c
ross
ing
pro
tect
ion
3,1
72
,13
1
5
98
,72
5
3,7
70
,85
6
3
,17
2,1
31
59
8,7
25
3
,77
0,8
56
98
,00
0
5
0.0
3Tr
act
ion
po
wer
su
pp
ly: s
ub
sta
tio
ns
32
,39
6,8
08
-
3
2,3
96
,80
8
32
,39
6,8
08
-
3
2,3
96
,80
8
4,3
70
,15
9
5
0.0
4Tr
act
ion
po
wer
dis
trib
uti
on
: ca
ten
ary
an
d t
hir
d r
ail
37
,12
0,9
77
-
3
7,1
20
,97
7
37
,12
0,9
77
-
3
7,1
20
,97
7
41
,61
5,3
80
5
0.0
5C
om
mu
nic
ati
on
s6
5,3
90
,74
2
-
65
,39
0,7
42
6
5,3
90
,74
2
-
65
,39
0,7
42
3
5,2
60
,02
7
50
.06
Fare
co
llec
tio
n s
yste
m a
nd
eq
uip
men
t1
5,0
15
,20
6
7,6
78
,42
1
2
2,6
93
,62
7
15
,78
9,9
75
6
,90
3,6
52
22
,69
3,6
27
5
,67
0,9
27
50
.07
Cen
tra
l C
on
tro
l3
,81
0,3
43
-
3,8
10
,34
3
3
,81
0,3
43
-
3,8
10
,34
3
3
,34
9,1
97
Co
nst
ruct
ion
Su
bto
tal (
10
– 5
0)
4,8
55
,97
7,5
12
5
60
,76
8,1
20
5,4
16
,74
5,6
32
4
,90
7,0
98
,32
5
50
9,0
87
,30
7
5
,41
6,1
85
,63
2
2,4
70
,53
1,2
22
Re
cove
ry P
lan
Bu
dge
tEs
tim
ate
At
Co
mp
leti
on
Ho
no
lulu
Rai
l Tra
nsi
t P
roje
ct M
on
thly
Pro
gre
ss R
ep
ort
M
arch
20
20
11
8 |
Pa
ge
SCC
De
scri
pti
on
Bas
e C
ost
Co
nti
nge
ncy
Tota
lB
ase
Co
stC
on
tin
gen
cyTo
tal
Incu
rre
d
60
RO
W, L
AN
D, E
XIS
TIN
G IM
PR
OV
EMEN
TS2
54
,83
5,5
74
10
6,7
89
,89
0
3
61
,62
5,4
64
28
8,1
96
,60
8
7
3,4
28
,85
6
36
1,6
25
,46
4
1
94
,19
3,0
79
60
.01
Pu
rch
ase
or
lea
se o
f re
al
esta
te
17
1,4
00
,00
0
1
01
,50
0,0
00
27
2,9
00
,00
0
2
04
,76
1,0
34
68
,13
8,9
66
2
72
,90
0,0
00
19
3,9
15
,27
9
6
0.0
2R
elo
cati
on
of
exis
tin
g h
ou
seh
old
s a
nd
bu
sin
esse
s8
3,4
35
,57
4
5,2
89
,89
0
8
8,7
25
,46
4
83
,43
5,5
74
5
,28
9,8
90
88
,72
5,4
64
2
77
,80
0
70
VEH
ICLE
S2
11
,38
9,9
52
-
21
1,3
89
,95
2
2
11
,38
9,9
52
-
21
1,3
89
,95
2
1
30
,78
6,6
42
70
.01
Ligh
t R
ail
19
0,3
83
,69
4
-
1
90
,38
3,6
94
19
0,3
83
,69
4
-
1
90
,38
3,6
94
11
8,2
61
,88
4
7
0.0
2H
eavy
Ra
il-
-
-
-
-
-
-
7
0.0
5O
ther
12
8,7
00
-
1
28
,70
0
12
8,7
00
-
1
28
,70
0
49
3,7
00
7
0.0
6N
on
-rev
enu
e ve
hic
les
14
,37
1,3
44
-
1
4,3
71
,34
4
14
,37
1,3
44
-
1
4,3
71
,34
4
12
,03
1,0
58
7
0.0
7Sp
are
pa
rts
6,5
06
,21
4
-
6
,50
6,2
14
6,5
06
,21
4
-
6
,50
6,2
14
-
80
PR
OFE
SSIO
NA
L SE
RV
ICES
1,9
89
,87
0,7
25
9
7,6
30
,13
9
2,0
87
,50
0,8
64
2
,00
6,0
98
,45
5
81
,96
2,4
09
2
,08
8,0
60
,86
4
1,3
45
,12
9,9
34
8
0.0
1P
reli
min
ary
En
gin
eeri
ng
54
,75
3,8
40
-
5
4,7
53
,84
0
54
,75
3,8
40
-
5
4,7
53
,84
0
18
0,7
05
,91
6
8
0.0
2Fi
na
l D
esig
n5
84
,14
9,8
99
31
,51
2,6
97
6
15
,66
2,5
96
58
6,4
77
,62
9
2
9,1
84
,96
7
61
5,6
62
,59
6
3
67
,24
8,4
65
80
.03
Pro
ject
Ma
na
gem
ent
for
Des
ign
an
d C
on
stru
ctio
n6
68
,55
7,9
25
29
,85
1,8
33
6
98
,40
9,7
58
66
8,5
57
,92
5
2
9,8
51
,83
3
69
8,4
09
,75
8
4
88
,99
5,0
37
80
.04
Co
nst
ruct
ion
Ad
min
istr
ati
on
& M
an
age
men
t 2
78
,64
0,4
20
28
,22
0,0
08
3
06
,86
0,4
28
29
2,5
40
,42
0
1
4,3
20
,00
8
30
6,8
60
,42
8
2
23
,47
5,7
35
80
.05
Pro
fess
ion
al
Lia
bil
ity
an
d o
ther
No
n-C
on
stru
ctio
n I
nsu
ran
ce
99
,34
0,0
00
4
,00
0,0
00
10
3,3
40
,00
0
9
9,3
40
,00
0
4,0
00
,00
0
1
03
,34
0,0
00
45
,67
5,9
15
8
0.0
6Le
gal;
Per
mit
s; R
evie
w F
ees
by
oth
er a
gen
cies
, cit
ies,
etc
.9
9,9
28
,69
8
3,7
68
,43
9
1
03
,69
7,1
37
99
,92
8,6
98
3
,76
8,4
39
10
3,6
97
,13
7
3
3,3
67
,29
4
80
.07
Surv
eys,
Tes
tin
g, I
nve
stig
ati
on
, In
spec
tio
n1
41
,68
6,6
22
27
7,1
62
1
41
,96
3,7
84
14
1,6
86
,62
2
2
77
,16
2
14
1,9
63
,78
4
4
,05
2,7
00
80
.08
Sta
rt u
p6
2,8
13
,32
1
-
62
,81
3,3
21
6
2,8
13
,32
1
56
0,0
00
6
3,3
73
,32
1
1,6
08
,87
3
9
0Su
bto
tal (
10
– 8
0)
7,3
12
,07
3,7
63
7
65
,18
8,1
49
8,0
77
,26
1,9
12
7
,41
2,7
83
,34
0
66
4,4
78
,57
2
8
,07
7,2
61
,91
2
4,1
40
,64
0,8
76
U
NA
LLO
CA
TED
CO
NTI
NG
ENC
Y-
2
21
,73
8,0
87
22
1,7
38
,08
7
-
8
7,7
92
,27
9
87
,79
2,2
79
1
00
Sub
tota
l (1
0 –
90
)7
,31
2,0
73
,76
3
98
6,9
26
,23
6
8
,29
8,9
99
,99
9
7,4
12
,78
3,3
40
7
52
,27
0,8
51
8,1
65
,05
4,1
91
4
,14
0,6
40
,87
6
FIN
AN
CE
CH
AR
GES
60
9,0
00
,00
0
-
6
09
,00
0,0
00
54
7,0
00
,00
0
-
5
47
,00
0,0
00
33
,80
0,1
91
To
tal P
roje
ct C
ost
(1
0 –
10
0)
7,9
21
,07
3,7
63
9
86
,92
6,2
36
8,9
07
,99
9,9
99
7
,95
9,7
83
,34
0
75
2,2
70
,85
1
8
,71
2,0
54
,19
1
4,1
74
,44
1,0
68
Tota
l FFG
A P
roje
ct C
ost
(1
0 –
10
0)
7,9
21
,07
3,7
63
9
86
,92
6,2
36
8,9
07
,99
9,9
99
7
,95
9,7
83
,34
0
75
2,2
70
,85
1
8
,71
2,0
54
,19
1
4,1
74
,44
1,0
68
Esti
mat
e A
t C
om
ple
tio
nR
eco
very
Pla
n B
ud
get
Honolulu Rail Transit Project Monthly Progress Report March 2020
119 | P a g e
Appendix B. Core Accountability Items Including Major Issues
Core Accountability Items Including Major Issues – March 2020 Note that HART’s Recovery Plan, with revised budget and RSD, was approved by the FTA on Sept. 5, 2019; however, HART intends to continue to manage the project to its current EAC of December 2025.
Project Status: ($ are in millions) Original Budget
at FFGA HART
Current EAC Recovery Plan
Cost Base Cost w/o Contingency
$4,305 $7,413 $7,312
Contingency
Allocated $542 $664 $765
Unallocated Contingency $102 $88 $222
FFGA Finance Charges
$173 $547 $609
Post RSD Finance Charges
$42 $293 $231
Total Project Costs
$5,164 $9,005 $9,139
Schedule Revenue Service Date (RSD) January 31, 2020 December 2025 September 2026
Project Status: ($ are in millions) Amount ($) Percent
(as % of total)
Planned Value to Date $3,003 60.6%
Earned Value to Date $2,807 56.6%
Actual cost* $4,174 56.3%
Contracts
Total Contracts Awarded to Date $5,436 73.3%
Total Construction Contract Awarded** (Construction Contracts Only)
$2,949 70.6%
Physical Construction Work Completed*** (Amount of Construction Actually Completed)
$2,119 50.8%
Date of Next Quarterly Meeting May 13, 2020
*Percentage calculated by taking Actual Cost divided by Base Cost w/o Contingency **Percentage calculated by taking Construction Contracts Only divided by Actual Cost ***Percentage calculated by taking Physical Construction Work divided by Actual Cost
Honolulu Rail Transit Project Monthly Progress Report March 2020
120 | P a g e
Appendix C. Construction Progress Interim Opening
Honolulu Rail Transit Project Monthly Progress Report March 2020
121 | P a g e
Appendix D. Project Organization Chart