Annual Report 2008-09 ENG

141
GOVERNMENT OF KARNATAKA WATER RESOURCES DEPARTMENT (MAJOR AND MEDIUM) ANNUAL REPORT 2008-09 JULY 2009

Transcript of Annual Report 2008-09 ENG

Page 1: Annual Report 2008-09 ENG

GOVERNMENT OF KARNATAKA

WATER RESOURCES DEPARTMENT

(MAJOR AND MEDIUM)

ANNUAL REPORT

2008-09

JULY 2009

Page 2: Annual Report 2008-09 ENG

2

INDEX

SL.

NO. CONTENTS

PAGE

NO.

1 INTRODUCTION 5

2 ORGANISATIONAL STRUCTURE 6

3 ACHIEVEMENTS OF WATER RESOURCES DEPARTMENT DURING 2008-09 7

4 ACCELERATED IRRIGATION BENEFIT PROGRAMME 9

5 SPECIAL REHABILITATION PACKAGE 15

6 WATER RESOURCES DEVELOPMENT ORGANISATION 16

7 CENTRAL MECHANICAL ORGANISATION 25

8 KARNATAKA ENGINEERING RESEARCH STATION 28

9 WATER AND LAND MANAGEMENT INSTITUTE (WALMI) 33

NIGAM

10 KRISHNA BHAGYA JALA NIGAM LIMITED 34

10.1 UPPER KRISHNA PROJECT 35

10.2 BAGALKOT TOWN DEVELOPMENT AUTHORITY, BAGALKOT 45

11 KARNATAKA NEERAVARI NIGAMA LIMITED 49

11.1 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, IRRIGATION (NORTH), BELGAUM

50

11.1.1 GHATAPRABHA PROJECT 51

11.1.2 HIPPARAGI IRRIGATION PROJECT 52

11.1.3 MARKANDEYA RESERVOIR PROJECT 53

11.1.4 DUDHGANGA IRRIGATION PROJECT 54

11.1.5 LIFTING OF HIRANYAKESHI WATERS INTO G.R.B.C CANAL 55

11.1.6 BELLARYNALA PROJECT 56

11.1.7 SRI RAMESHWARA L.I. SCHEME 57

11.2 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, MALAPRABHA PROJECT ZONE, DHARWAD.

58

11.2.1 MALAPRABHA PROJECT 59

11.2.2 HARINALA IRRIGATION PROJECT 60

11.2.3 KALASA NALA AND BANDHURNALA PROJECT 61

11.2.4 JAVALUHALLA L.I. SCHEME 62

11.2.5 BENNIHALLA L.I. SCHEME (5 NOS.) 63

11.2.6 KOLACHI L.I. SCHEME 64

11.2.7 KONNUR L.I. SCHEME 65

11.2.8 SHIGGAON L.I. SCHEME 66

11.3 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, IRRIGATION CENTRAL ZONE, MUNIRABAD

67

Page 3: Annual Report 2008-09 ENG

3

SL.

NO. CONTENTS

PAGE

NO.

11.3.1 SINGATALUR LIFT IRRIGATION SCHEME (SLIS) 67

11.4 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, UPPER TUNGA

PROJECT ZONE, SHIMOGA

68

11.4.1 UPPER TUNGA PROJECT 70

11.4.2 TUNGA LIFT IRRIGATION SCHEME 72

11.4.3 BASAPURA LIFT IRRIGATION SCHEME 73

11.4.4 ITAGI-SASALWAD LIS 74

11.4.5 GUDDADA MALLAPURA LIS 75

11.4.6 UPPER BHADRA PROJECT (STAGE 1 & 2) 76

11.4.7 UBRANI-AMRUTHAPURA MULTIPURPOSE LIS 77

11.4.8 SANYASIKOPPA LIS 78

11.4.9 KALLUVADDAHALLA NEW TANK 79

11.4.10 TILUVALLI LIFT IRRIGATION SCHEME 80

11.5 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, VARAHI PROJECT ZONE, SIDDAPURA.

81

11.5.1 VARAHI IRRIGATION PROJECT 81

11.6. AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, IRRIGATION PROJECTS ZONE, GULBARGA

83

11.6.1 BENNITHORA PROJECT 83

11.6.2 BHIMA LIFT IRRIGATION SCHEME 84

11.6.3 GANDORINALA PROJECT 86

11.6.4 LOWER MULLAMARI PROJECT 88

11.6.5 AMARJA PROJECT 89

12 CAUVERY NEERAVARI NIGAMA LIMITED 91

12.1 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, IRRIGATION (S) ZONE, MYSORE

92

12.1.1 D. DEVARAJA URS CANAL 93

12.1.2 KABINI RESERVOIR PROJECT 94

12.1.3 HARANGI PROJECT 96

12.1.4 TARAKA PROJECT 98

12.1.5 ARKAVATHY PROJECT 99

12.1.6 CHIKLIHOLE PROJECT 101

12.1.7 UDUTHOREHALLA PROJECT 102

12.1.8 IGGALUR BARRAGE PROJECT 103

12.1.9 MANCHANABELE PROJECT 105

12.1.10 MODERNISATION OF KRISHNARAJA SAGAR 106

Page 4: Annual Report 2008-09 ENG

4

SL.

NO. CONTENTS

PAGE

NO.

12.1.11 NANJAPURA LIFT IRRIGATION SCHEME 107

12.1.12 BANAHALLIHUNDI LIS 108

12.2 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, HEMAVATHY

CANAL ZONE, TUMKUR

109

12.2.1 HEMAVATHY CANAL ZONE, TUMKUR 109

12.3 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, HEMAVATHY RESERVOIR PROJECT, GORUR

112

12.3.1 HEMAVATHY PROJECT 112

12.3.2 YAGACHI PROJECT 114

12.3.3 HUCHANAKOPPALU LIS 115

12.3.4 KAMASAMUDRA LIS 116

12.3.5 KACHENAHALLI LIS 117

12.3.6 VOTEHOLE PROJECT 118

ZONES 119

13 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, IRRIGATION PROJECT ZONE, GULBARGA

120

13.1 KARANJA PROJECT 120

14 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, IRRIGATION CENTRAL ZONE, MUNIRABAD

121

14.1 TUNGABHADRA PROJECT 121

14.2 HIREHALLA POJECT 124

14.3 MASKINALA PROJECT 126

14.4 OTHER WORKS (NEW) 128

15 AN OVERVIEW OF PROJECTS UNDER THE ENGINEER-IN-CHIEF, UPPER TUNGA

PROJECT ZONE, SHIMOGA

129

15.1 BHADRA PROJECT 130

15.2 MODERNISATION OF CANAL SYSTEM OF TUNGA ANICUT 131

15.3 HODIRAYANAHALLA DIVERSION SCHEME 132

15.4 MODERNISATION OF CANAL SYSTEM OF AMBLIGOLA RESERVOIR 133

15.5 MADAGA –MASUR TANK 134

15.6 ERM OF BHEEMASAMUDRA TANK 135

15.7 MODERNISATION OF CANAL SYSTEM OF GONDI ANICUT (BHADRA) 136

15.8 KADUVINABYLU LIFT IRRIGATION SCHEME 136

15.9 THIMMAPURA LIFT IRRIGATION SCHEME 136

15.10 ANJANAPURA RESERVOIR PROJECT 136

16 COMMAND AREA DEVELOPMENT PROGRAMME 137

Page 5: Annual Report 2008-09 ENG

5

1. INTRODUCTION

The Annual Report is a document giving details of the annual Programme, Progress and important events

that have taken place during the year, in the Water Resources Department.

GEOGRAPHICAL AREA

The geographical area of Karnataka is 1,91,791 Sq. Km., accounting for 5.83% of the total area of the

country.

The cultivable command area of the State is 1, 40,598 sq. Km. The net sown area is 1,07,000 sq. Km and

the ultimate Irrigation Potential from Major and Medium Irrigation Projects has been estimated as 35,000 sq.

Km or 35.00 Lakh Ha.

PROGRESS IN BRIEF

Presently, the Irrigation Department is known as the Water Resources Department.

There are 133 Major and Medium Irrigation Projects in the State, out of which 47 projects are

completed, 76 are ongoing.

The Water Resources Department has established three special purpose vehicles, namely, Krishna

Bhagya Jala Nigama Limited (KBJNL), Karnataka Neeravari Nigama Limited (KNNL) and Cauvery Neeravari

Nigam Limited (CNNL), under the companies Act of 1956, to mobilize financial resources for speedy

completion of major and medium irrigation projects with-in the targeted period.

KRISHNA BHAGYA JALA NIGAM LIMITED (KBJNL):

“Krishna Bhagya Jala Nigam Limited” was formed vide G.O. No. ID/25/WBM/95, dated: 6-5-

94, to expedite the works of Upper Krishna Project (UKP). This Nigam is functioning since 19th August 1994.

KARNATAKA NEERAVARI NIGAMLIMITED (KNNL):

”Karnataka Neeravari Nigam Limited” was formed vide G.O. No. ID: 201: KBN: 98, dated: 26-11-98,

to expedite the works in Krishna Basin, except UKP. This Nigam is functioning since 9th December 1998.

CAUVERY NEERAVARI NIGAM LIMITED (CNNL):

”Cauvery Neeravari Nigam Limited” was formed vide G.O. No. WRD: 32: KBN: 2003, Dated:

12.05.2003, to expedite the works in Cauvery Basin. This Nigam is functioning since 3rd June 2003.

INDEX

Page 6: Annual Report 2008-09 ENG

6

1. ORGANISATIONAL STRUCTURE

WATER RESOURCES DEPARTMENT

CNNL BOARD OF

DIRECTORS

ADMINISTRATOR

BHADRA,

SHIMOGA

CE, CANAL ZONE-

1, UKP, B.GUDI

CE, O&M ZONE, UKP,

NARAYANPURA

HON’BLE MINISTER FOR WATER RESOURCES

ADMINISTRATOR

MALAPRABHA &

GHATAPRABHA, BELGAUM

SECRETARY

KNNL BOARD OF DIRECTORS

CE, IRRIGATION CENTRAL ZONE,

MUNIRABAD

C.E,

W.R.D.O KBJNL BOARD

OF DIRECTORS

CE,

HYDROLOGY

& CMO, BANGALORE

DIRECTOR, WALMI

CADA’S DIRECT FIELD

OFFICES

ADMINISTRATORTUNGABHADRA

PROJECT, MUNIRABAD

CE, UPPER TUNGA

PROJECT,

SHIMOGA

ADMINISTRATOR CAUVERY BASIN,

MYSORE

DIRECTOR,

K.E.R.S

CE, IRRIGATION PROJECT ZONE,

GULBARGA

PRINCIPAL SECRETARY

ADMINISTRATOR

UKP, B.GUDI

ADMINISTRATOR

IRRIGATION

PROJECT ZONE, GULBARGA

REGISTERED CORPORATE

OFFICE

FIELD OFFICES

CE, DAM ZONE,

UKP, ALMATTI

CE, CANAL ZONE-2, UKP,

KEMBHAVI

CE, UTP ZONE,

SHIMOGA

CE, VARAHI

ZONE,

SIDDAPURA

CE, IPZ,

GULBARGA

CE, H.P.Z,

GORUR

CE, IRRIGATION

(SOUTH),

MYSORE

CE,

IRRIGATION (NORTH),

BELGAUM

CE, H.C.Z,

TUMKUR

CE,

MALAPRABHA PROJECT

ZONE,

DHARWAD

CE, UPPER

BHADRA

PROJECT,

CHITRADURGA

C.E, I.S.W.D,

BANGALORE

REGISTERED

CORPORATE

OFFICE

FIELD OFFICES

REGISTERED CORPORATE

OFFICE

FIELD

OFFICES

Page 7: Annual Report 2008-09 ENG

7

3. ACHIEVEMENTS OF WATER RESOURCES DEPARTMENT DURING 2008-09

During 2008-09, 7 Major & medium irrigation projects are completed and irrigation potential of 47201 ha.

Is created.

The ultimate irrigation potential is 35 lakh Ha from Major & medium irrigation projects. Upto end of March

2009, cumulative irrigation potential of 24.28 lakh ha has been created.

Out of the targetted irrigation potential of 6.22 Lakh Ha under Upper Krishna Project, an irrigation potential

of 5.88 lakh Ha has been created so for. The balance works of Jewargi Branch Canal, Narayanapur Right

Bank Canal, Mulwad Lift Irrigation Scheme, Almatti Right Bank Canal and Almatti Left Bank Canal of

Upper Krishna Project are nearing completion.

To utilize Krishna waters under Upper Krishna Project, Ramthal (Marol) Lift Irrigation Scheme, Teggi-

Siddapura Lift Irrigation Scheme, Thimmapura Lift Irrigation Scheme, Sonna Lift Irrigation Scheme and

Rolli-Mannikeri Lift Irrigation Scheme are taken up in the backwaters of Almatti Reservoir and are in

progress.

During 2008-09, Central Assistance under A.I.B.P. to the tune of Rs. 214.94 Crores for 6 Major & medium

irrigation projects has been availed and an expenditure of Rs. 418.87 Crores has been incurred.

17 Major & Medium irrigation projects in six selected districts are posed for assistance under the Hon‟ble

Prime Minister‟s Special Rehabilitation Package out of which, 8 projects are dropped. Planning Commission

clearance in respect of three projects of Belgaum District is awaited. Up to end of March 2009 a sum of

Rs.278.77 Crores is released for 4 projects and total expenditure incurred on all 17 projects is Rs.1074.68

Crores and an irrigation potential of 59,815 Ha is created.

To utilize its share of Godavari waters resourcefully, the State has taken up the construction of series of

Barrages like Jigrihal, Manikeshwar, Halahalli and Chandapur barrages are in progress. These barrages are

being implemented by Krishna Bhagya Jala Nigam Limited.

Cauvery Neeravari Nigam Limited has activated the potential oriented works under Cauvery Basin. In order

to minimize the advert consequences of the Cauvery water dispute tribunal‟s award, it has been programmed

to develop 1252 minor irrigation tanks coming under the command area of major and medium irrigation

projects in Cauvery basin.

During 2008-09, Karnataka Neeravari Nigam Limited has incurred an expenditure of Rs. 1200.98 Crores

for implementing 37 major and medium irrigation projects/Components of projects against an annual

programme of Rs.611.36 Crores.

Upper Bhadra Project is proposed to utilise 21 .50 tmc of water to feed tank in drought prone districts of

Kolar, Tunkur and Chitradurga. Three packages amounting to Rs.825.00 crores has been taken up as per

Technical Report in Stage-I of the project. Office of the Chief Engineer is formed at Chitradurga at this

purpose.

Page 8: Annual Report 2008-09 ENG

8

For efficient Water management 12 package tenders amounting to Rs.702.00 Crores are invited for

Modernisation of the Main canal and 5 Branch canals of Bhadra Canal Network. Modernization works are

in progress.

For efficient & effective water management under the Command Areas of Major & medium irrigation

projects, Water Resources Department has established 2,392 Water Users Co-operative Societies.

The works of Kalasanala diversion scheme in non-forest regions have been taken up during the current year

for supplementing drinking water resources to the twin cities of Hubli and Dharwad.

The details of the targets and achievements in respect of the Major and Medium irrigation Projects for

the year 2008-09 up to end of March 2009 are as hereunder.

Sl.

No Project

Financial (Rs. In Crores) Physical (in Hectares)

Program Progress Program Progress

1 Krishna Bhagya Jala Nigama 1,014.21 946.90 10,386 4,668

2 Karnataka Neeravari Nigama 893.70 865.09 43,582 30,776

3 Cauvery Neeravari Nigama 652.76 532.60 21,032 11,757

4 Non Nigam Zones of WRD 165.19 83.17 214 0

Total 2,725.86 2,427.76 75,214 47,201

INDEX

Page 9: Annual Report 2008-09 ENG

9

4. ACCELERATED IRRIGATION BENEFIT PROGRAMME

For the early completion of some of the ongoing irrigation projects, which were lingering due to shortage

of funds for many years, the Government of India launched the Accelerated Irrigation benefit programme,

during 1996-97. Since then, eight projects in the State, namely, Upper Krishna project (UKP) Stage-I, Phase-III,

Malaprabha, Hirehalla, Ghataprabha, Karanja, Upper Krishna project (UKP) Stage-II, Maskinala, and

Gandhorinala have received Central Loan Assistance (CLA) / (CA) under Accelerated Irrigation benefit

programme (AIBP).

During 1996-97, at the end of 8th Five Year Plan, the Government of India launched the Accelerated

Irrigation Benefit Programme (A.I.B.P.) with the intention of completing those projects lingering due to

shortage of funds. From 1996-97 to 2002-03, the sharing between the centre and the state was in the ratio

of 50:50. Since 2002-03, the sharing is in the ratio of 2/3:1/3.

During 2008-09, UKP Stage I, Phase III, UKP Stage II, Malaprabha, Ghataparbha, Karanja and Varahi

are the 6 projects that have received / are receiving C.L.A. under A.I.B.P.

The cumulative C.L.A. (including grants) released upto end of March 2009 is Rs. 3,351.36 Crores. The

cumulative expenditure incurred on these projects up to the end of March 2009 is Rs. 4,797.53 Crores.

During 2004-05, loans along with grants were released to the projects in the ratio of 70: 30.

The Central Assistance released, during 2008-09, to 6 projects namely UKP Stage I Phase III, UKP Stage

II, Malaprabha, Ghataprabha-III, Karanja and Varahi is Rs. 214.94 Crores.

The expenditure incurred on these 6 projects during 2008-09 upto end of March 2009 is Rs.481.87

Crores.

STATEMENT SHOWING DETAILS OF C.L.A. UNDER A.I.B.P RELEASED TO MAJOR AND

MEDIUM IRRIGATION PROJECTS (SINCE 1996-97)

(Rs. in Crores)

PERIOD NO. OF

PROJECTS

CLA

PROPOSED /

SANCTIONED

CLA

RELEASED EXPENDITURE

1996-97 5 122.50 61.25 172.21

1997-98 5 175.00 90.50 160.49

1998-99 5 167.00 94.50 171.05

1999-00 5 190.64 157.14 190.61

2000-01 4 171.00 171.00 268.26

2001-02 7 545.00 492.50 911.38

2002-03 8 611.97 620.85 693.00

2003-04 8 266.48 266.48 440.57

2004-05 5 463.05 449.71 475.46

2005-06 5 336.70 291.23 473.24

Page 10: Annual Report 2008-09 ENG

10

2006-07 6 568.91 334.00 457.15

2007-08 5 410.22 322.20 350.59

2008-09 6 294.25 214.94 481.87

TOTAL UPTO MARCH 2009 4322.72 3566.30 5245.88

Details of Central Assistance (CA) under AIBP during 2008-09

(Rs. in Crores)

Sl. No. PROJECTS CLA

SANCTIONED

CLA

RELEASED

EXPENDITURE

incurred during 08-09

1 UKP Stage-I

Phase-III 102.14 91.92 139.36

2 UKP Stage-II 44.14 8.019 176.72

3 Ghataprabha 57.82 52.04 44.56

4 Malaprabha 33.94 30.54 27.72

5 Gandhorinala 18.02 0.00 17.97

6 Varahi 22.41 20.17 64.76

7 Karanja 15.78 12.25 10.78

Total 294.25 214.94 481.87

Page 11: Annual Report 2008-09 ENG

11

CUMULATIVE STATEMENT CLA Released

(Rs. in Crores)

Sl.

No

Project 1996-97 1997-98 1998-99 1999-

2000 2000-2001 2001-02 2002-03 2003-04 2004-05 2005-06 2006-07 2007-08 2008-09

CUMULA

TIVE

1 UKP Stage-I

Phase-III 57.00 50.00 50.00 100.00 100.00 200.00 181.00 - 115.85 - 71.638 71.23 91.92 1088.64

2 UKP Stage-II - - - - - 250.00 275.05 163.48 240.72 197.76 172.53 102.07 8.019 1409.63

3 Malaprabha 1.50 12.00 10.00 13.50 - 10.00 25.56 - 12.00 20.00 13.50 54.24 30.54 202.84

4 Hirehalla 2.75 6.00 6.00 8.00 8.00 10.00 8.78 14.71 - - - - 0.00 64.24

5 Ghataprabha - 15.00 12.50 20.00 45.00 5.00 75.00 13.02 62.09 65.00 30.805 72.61 52.04 468.06

6 Karanja - 7.50 16.00 15.64 18.00 10.00 34.37 75.27 - - - - 12.25 189.03

7 Gandhorinala - - - - - 7.50 17.87 - 19.05 8.47 45.53 - 0.00 98.42

8 Maskinala - - - - - - 3.22 - - - - - 0.00 3.22

9 Varahi - - - - - - - - - - - 22.05 20.17 42.22

TOTAL 61.25 90.50 94.50 157.14 171.00 492.50 620.85 266.48 449.71 291.23 334.00 322.20 214.94 3,566.30

Page 12: Annual Report 2008-09 ENG

12

Expenditure

Sl.

No Project 1996-97 1997-98 1998-99

1999-

2000

2000-

2001 2001-02 2002-03 2003-04 2004-05 2005-06 2006-07 2007-08 2008-09

CUMULAT

IVE

1 UKP Stage-I

Phase-III 155.74 92.30 77.58 116.40 187.80 235.33 214.69 94.19 92.18 61.13 46.19 49.30 139.36 1562.19

2 UKP Stage-II - - - - - 534.10 352.29 236.48 268.17 272.29 234.58 86.80 176.72 2161.43

3 Malaprabha 5.12 14.92 22.64 9.87 5.15 15.87 14.45 14.42 19.64 19.62 31.28 56.37 27.72 257.07

4 Hirehalla 11.35 17.12 12.06 15.82 22.68 11.41 11.69 9.94 18.45 - - - - 130.52

5 Ghataprabha - 20.47 28.82 20.04 26.96 72.77 57.57 55.45 64.68 92.47 77.29 76.90 44.56 637.98

6 Karanja - 15.68 29.95 28.48 25.67 26.55 23.62 18.64 - - - - 10.78 179.37

7 Gandhorinala - - - - - 15.35 16.82 10.09 12.34 27.73 34.96 - 17.97 135.26

8 Maskinala - - - - - - 1.87 1.36 - - - - - 3.23

9 Varahi - - - - - - - - - - 32.85 81.22 64.76 178.83

TOTAL 172.21 160.49 171.05 190.61 268.26 911.38 693.00 440.57 475.46 473.24 457.15 350.59 481.87 5245.88

Page 13: Annual Report 2008-09 ENG

13

DETAILS OF PROJECTS ASSISTED UNDER AIBP PROGRAMME (YEARLY)

(As on 31-3-2009)

(Rs. in Crores)

Sl.

No Project

1996-97 1997-98 1998-99 1999-2000 2000-01 2001-02

CLA

Sanctio

ned

CLA

Released

Expendit

ure

CLA

Sanctio

ned

CLA

Released

Expendi

ture

CLA

Sanctio

ned

CLA

Released

Expendi

ture

CLA

Sanctio

ned

CLA

Released

Expendi

ture

CLA

Sanctio

ned

CLA

Released

Expendi

ture

CLA

Sanctio

ned

CLA

Released

Expendi

ture

1 UKP Stage-I

Phase-III 114.00 57.00 155.74 100.00 50.00 92.30 100.00 50.00 77.58 100.00 100.00 116.40 100.00 100.00 187.80 200.00 200.00 235.33

2 UKP Stage-II - - - - - - - - - - - - - - - 250.00 250.00 534.10

3 Malaprabha 3.00 1.50 5.12 24.00 12.00 14.92 20.00 10.00 22.64 27.00 13.50 9.87 - - 5.15 20.00 10.00 15.87

4 Hirehalla 5.50 2.75 11.35 6.00 6.00 17.12 6.00 6.00 12.06 8.00 8.00 15.82 8.00 8.00 22.68 10.00 10.00 11.41

5 Ghataprabha - - - 30.00 15.00 20.47 25.00 12.50 28.82 40.00 20.00 20.04 45.00 45.00 26.96 30.00 5.00 72.77

6 Karanja - - - 15.00 7.50 15.68 16.00 16.00 29.95 15.64 15.64 28.48 18.00 18.00 25.67 20.00 10.00 26.55

7 Gandhorinala - - - - - - - - - - - - - - - 15.00 7.50 15.35

8 Maskinala - - - - - - - - - - - - - - - - - -

Total 122.50 61.25 172.21 175.00 90.50 160.49 167.00 94.50 171.05 190.64 157.14 190.61 171.00 171.00 268.26 545.00 492.50 911.38

Page 14: Annual Report 2008-09 ENG

14

Sl.

No Project

2002-03 2003-04 2004-05 2005-06 2006-07 2007-08

CLA

Sanctio

ned

CLA

Released

Expendit

ure

CLA

Sanctio

ned

CLA

Released

Expendit

ure

CLA

Sanction

ed

CLA

Release

d

Expend

iture

CLA

Sanctio

ned

CLA

Release

d

Expend

iture

CLA

Sanctioned

CLA

Release

d

Expend

iture

CLA

Sanctio

ned

CLA

Release

d

Expend

iture

1 UKP Stage-I

Phase-III 181.00 181.00 214.69 - - 94.19 115.85 115.85 92.18 39.01 - 61.13 74.87 71.64 46.19 94.46 71.23 49.30

2 UKP Stage-II 275.05 275.05 352.29 163.48 163.48 236.48 241.22 240.72 268.17 204.22 197.76 272.29 168.77 172.5 234.58 131.66 102.1 86.80

3 Malaprabha 25.56 25.56 14.45 - - 14.42 12.00 12.00 19.64 20.00 20.00 19.62 54.00 13.50 31.28 60.27 54.24 56.37

4 Hirehalla 9.90 8.78 11.69 14.71 14.71 9.94 12.84 - 18.45 - - - - - - - - -

5 Ghataprabha 75.00 75.00 57.57 13.01 13.015 55.45 62.09 62.09 64.68 65.00 65.00 92.47 123.21 30.81 77.29 99.33 72.61 76.90

6 Karanja 34.37 34.37 23.62 75.27 75.27 18.64 - - - - - - - - - - - -

7 Gandorinala 17.87 17.87 16.82 - - 10.09 19.05 19.05 12.34 8.47 8.47 27.73 55.87 45.53 34.96 - - -

8 Maskinala 3.22 3.22 1.87 - - 1.36 - - - - - - - - - - -

9 Varahi - - - - - - - - - - - - 18.25 - 32.85 24.50 22.05 81.22

Total 621.97 620.85 693.00 266.47 266.48 440.57 463.05 449.71 475.46 336.70 291.23 473.24 494.97 334.00 457.15 410.22 322.20 350.59

Sl.

No Project

2008-09 CUMULATIVE

CLA Sanctioned CLA Released Expenditure CLA Released Expenditure

1 UKP Stage-I Phase-III 102.14 91.92 139.36 1088.64 1562.19

2 UKP Stage-II 44.14 8.019 176.72 1409.63 2161.43

3 Malaprabha 33.94 30.54 27.72 202.84 257.07

4 Hirehalla - - - 64.24 130.52

5 Ghataprabha 57.82 52.04 44.56 468.06 637.98

6 Karanja 15.78 12.25 10.78 189.03 179.37

7 Gandorinala 18.02 - 17.97 98.42 135.26

8 Maskinala - - - 3.22 3.23

9 Varahi 22.41 20.17 64.76 42.22 178.83

Total 294.25 214.94 481.87 3566.30 5245.88

INDEX

Page 15: Annual Report 2008-09 ENG

15

5. SPECIAL REHABILITATION PACKAGE

During 2006-07, the Special Rehabilitation Package was launched by the Government of India to mitigate

the distress of farmers in selected 31 districts of the Country from where large numbers of Suicide cases by the

farmers were reported.

In Karnataka, the 6 districts viz Belgaum, Bijapur, Shimoga, Chikkamagalur, Chitradurga, Hassan and

Kodagu were identified as drought prone districts and 17 projects benefiting these 6 districts were identified and

proposals of the same have been submitted.

An allocation of Rs. 1208.71 Crores has been made towards major and medium Irrigation sector under

assured irrigation. Out of this the grant portion of Rs.725.24 Crores will be borne by the center and the loan

portion of Rs.483.47 Crores will be met-out of state funds. The funding proposed is as per revised AIBP norms.

The details of the 17 projects are as follows:

(Rs. In Crores)

SL.

NO. NAME OF THE PROJECT

BALANCE COST OF THE

PROJECT

MAJOR

1 Malaprabha 120.98

2 Ghataprabha-III 159.68

3 Hipparagi 934.92

4 Markandeya 56.41

5 ERM of Bhadra Reservoir project 400.00

6 Harangi 12.57

7 Hemavathy 64.54

8 Yagachi 127.78

9 Dudhganga 37.79

MEDIUM

10 Kamasamudra LIS 18.42

11 Huchanakoppalu LIS 14.00

12 Votehole 1.50

13 Kachenahalli LIS 79.88

14 Chiklihole 1.50

15 ERM of Bheemasamudra tank 4.00

16 Srirameshwara LIS 212.38

17 Bellarynala LIS 131.36

TOTAL 2530.05

Out of this, Malaprabha and Ghataprabha are already receiving Central Assistance under AIBP. Markandeya,

Chiklihole and Votehole projects are completed. Hippargi, Dudhganga and Modernisation of Bhadra projects

for availing Central Assistance and package sine 2007-08. Approval of Planning Commission is pending to 6

irrigation projects of Cauvery Basin. Approval in 3 irrigation projects in Krishna basin is awaited. Assistance

under package is extended upto 2012.

INDEX

Page 16: Annual Report 2008-09 ENG

16

6. WATER RESOURCES DEVELOPMENT ORGANISATION

ACTIVITIES:

This Organisation is incharge of Planning and Investigation of all Major and Medium Irrigation

Projects in the State and provides all the information to the Government in respect of Inter State Water Disputes

like Cauvery, Krishna, Godavari and Mahadayi. This Organisation acts as a data Bank for all

Hydrological details of Rivers and streams in the State by collecting and processing the raingauge and River

gauge data in a systematic manner. This Organisation provides information regarding completed, ongoing and

proposed irrigation projects of the state. This organisation prepares Catchment Area Maps indicating influencing

rain guage stations, digital maps of all hydro meteorological states of Karnataka state, command area maps of

completed, ongoing and proposed irrigation projects under Cauvery and Krishna river basin using the latest

software viz., GIS, Remote sensing and Autodesk map. The work of monitoring and evaluation of existing and

ongoing projects and safety aspects of dams are monitored by this organisation. In addition, the establishment

matter of Irrigation zones regarding postings, transfer of staff and Regularisation of Daily Wages Staff and

Monthly Rated Staff as per Supreme Court order is also attended to by this Organisation.

PLANNING AND INVESTIGATION UNIT

This Unit is attending to the work of Technical Scrutiny of New Major and Medium Irrigation Projects,

conducting survey and investigation of major & medium irrigation projects, preparing preliminary investigation

report and detailed project report of the same, replies to C.W.C. comments and arranging for clearance of

projects and correspondence between State and Central Governments regarding Irrigation Projects.

During 2008-09, 15 Projects under Krishna Basin and 5 Projects under West flowing River basin totally

20 Major and Medium Irrigation Projects are under different stages of investigation.

In addition to the above investigation works, the following works are also dealt with in this unit.

e– Governance in Water Resources Department:

Water Resources Development Organization is monitoring the e-Governance activities of entire Water

Resources Department in Karnataka. Short-term courses to use Computers for the Technical and Non-Technical

staff are being conducted regularly. This Unit manages the Website of Water Resources Department

“http://waterresources.kar.nic.in” which includes details of Nigams and the following data

a) Right to Information Act

b) Schedule of Rates

c) Preparation of material required for National Performance of dam

programme for Dam safety. d) Salient features of Major and Medium Irrigation Projects.

e) Hierarchy of Administration in Water Resources Department and

f) Tender Bulletins.

g) Overlay of projects on Google earth.

Page 17: Annual Report 2008-09 ENG

17

Right to Information Act: Requisitions from public regarding Water Resources Department are answered within a stipulated period of

one month and updated periodically in the Departmental Website.

Experts Committee for diversion projects and regarding availability of water in various River

basins:

To study the availability of water in various West Flowing River basins and also to conduct studies regarding

the projects, an Expert Committee in co-ordination with NRSA is formed. Survey works is in progress.

Neeravari Software:

Neeravari Software needs to be stabilized and rebuilt with new platform, architecture and software as

per the latest technology.

High Level Committee: The Government has constituted a High Level Committee under the Chairmanship of Sri. D.N. Desai

vide G.O. No. WRD /101/ MBI/ 2008 dated 11.12.2008 to prepare “Draft Water Policy” for

distribution of water to various sectors of the State. This committee held its first meeting on 11.03.2009.

The Chief Engineer, WRDO is the member secretary to this committee. At present this committee is

functioning and report is awaited.

Implementation of Irrigation Information System using GIS Technology:

Rs.250 crores was provided during 2007-08 in the budget for implementation of Irrigation Information

System using GIS Technology. It is proposed to have decision support system through GIS equation.

TAP meeting held on 18.12.2007 has permitted to procure digital data. Process of procurement of digital

data through Survey of India, Dehradun is in progress. Detailed architecture and request for proposal is to

be obtained from 3 private companies.

Other activities: This Unit corresponds with State & National level Organisations like Central Water Commission, Bureau

of Indian Standards, Indian National Committee for Irrigation & Drainage, Water & Power Consultancy

Services and Central Board of Irrigation and Power. This Unit attends to the Committee meetings conducted by

these Organisations and provides information requested by them.

This Unit provides information for attending the meetings of Subject Committee, Assurance Committee,

Estimate Committee and Petition committee.

This unit deputes officers of this organisation to various training programme, seminar, conference,

workshop etc. to update their knowledge regarding latest technology and development in the water resources

sector.

CAUVERY UNIT

Introduction:

Page 18: Annual Report 2008-09 ENG

18

The Cauvery unit of Water Resources Development Organisation, Bangalore deals with the matters

concerning sharing of waters of the River Cauvery with the other riparian States viz., Tamil Nadu, Kerala and

Union Territory of Pondicherry.

Organisation:

The Cauvery Unit was formed during 1990 with staff of W.R.D.O. It was functioning under the then

Chief Engineer, W.R.D.O. Bangalore.

Activities:

The Cauvery Water Disputes Tribunal was set up by the Ministry of water Resources, Government of India,

vide its order No. 21.1.90 WD dated: 2.6.1990 with Head quarters at New Delhi for adjudication of the

Cauvery Water Dispute.

To safe guard the interests of Karnataka and to substantiate the stand of the Government before the Supreme

Court/Cauvery water Disputes Tribunal a team of Advocates along with the Advocate General of Karnataka

is appointed and their services are being utilised.

The current team of Advocates appointed by the Government to represent Cauvery Water Disputes is as

under:

1 Advocate General of Karnataka

2 Sri. F.S.Nariman Senior Advocate

3 Sri. Anil B. Divan Senior Advocate

4 Sri. S.S.Javali Senior Advocate

5 Sri. Mohan V. Katarki Advocate

6 Sri. Shambhu Prasad Singh Advocate

7 Sri. Sanjay R. Hegde Advocate

8 Sri. S.C.Sharma Advocate

9 Sri. Ranvir Singh Advocate

10 Sri. Brijesh Kalappa Advocate

To get technical advise in Cauvery Water Disputes matter two Technical Advisors were appointed by

the Government and their services are being continued.

For effective participation and pleading the case of Karnataka before the Cauvery Water Dispute

Tribunal, Cauvery water Cell established in 1990 is now functioning in Karnataka Bhavan-III

(Bheema), Hudco Place, Andrews Ganj, New Delhi.

This unit renders technical assistance to the Advocates engaged by the state to appear before the

Cauvery water Dispute Tribunal and Supreme Court. This unit also prepares documents and other

required materials for the Technical Committee, All Party Meetings and other related meetings.

In addition, this unit also carries out the following works.

Collection and analysing data regarding Reservoir levels, inflow, etc., of the Cauvery Basin

Projects in the State.

Page 19: Annual Report 2008-09 ENG

19

Preparation of brief and draft replies in connection with the reactions from the public and other

State Governments, which appear in press.

Collection and updating of materials that are relevant to the Cauvery water Disputes etc.,

This unit also renders its views on the matters connected with the West Flowing River Development,

National & State Water Policy, National water Board and NWDA studies regarding Water balance whenever

such files are referred to.

Physical and Financial targets and Achievements:

The significant developments before the Cauvery Water Dispute Tribunal and Supreme Court

concerning the Cauvery water Dispute during the year 2008-09 are as follows:

Before the Cauvery Water Dispute Tribunal:

The Cauvery Water Disputes Tribunal announced its final verdict along with report on 05.02.2007. As

per the judgement the allocation of 740 tmc (available in Cauvery basin at 50% dependability) to the party States

is as under:

1 Kerala 30 tmc

2 Karnataka 270 tmc

3 Tamil Nadu 419 tmc

4 Union Territory of Pondicherry 7 tmc

5 Environmental protection 10 tmc

6 Inevitable escapages into sea 4 tmc

Total 740 tmc

Further it is ordered in the judgement that Karnataka should ensure 192 tmc at Biligundlu (gauging

station maintained by CWC) as under:

Month TMC Month TMC

June 10 December 8.00

July 34 January 3.00

August 50 February 2.50

September 40 March 2.50

October 22 April 2.50

November 15 May 2.50

Total 192.0 tmc

Aggravated by the final orders of the Tribunal Karnataka Government filed review petition under

Section 5(3) of Inter State Water Disputes Act on 03.05.2007 before the Cauvery Water Dispute Tribunal. All

other party States have also filed review petition under Section 5(3). In addition to review petition, State of

TamilNadu had filed CMP No.1/2007 before the Tribunal on 31.05.2007 praying to restrain the State of

Page 20: Annual Report 2008-09 ENG

20

Karnataka from execution or commissioning any new check dams or Irrigation works, L.I. Schemes and de-

silting of M.I. tanks.

The CWDT which met on 10.07.2007 accepting the petitions of all the party States and that of Central

Government ordered them to be listed for orders after disposal of the appeals by the Supreme Court. Further it

also disposed off the CMP No.1/2007 filed by Tamil Nadu.

Before the Supreme Court of India:

Aggrieved by the final orders of the Cauvery Water Disputes Tribunal dated 05.02.2007, Karnataka

filed Civil Appeal No. 2453/2007 (Vol. I to III – pages 1 to 1038) against the final orders of the Tribunal under

Article 136 of Constitution on 23.04.2007. Thereafter additional documents (Vol. IV to XXV – pages 1039 to

6759) have been filed between 04.05.2009 and 11.02.2009 in support of issues that are to be argued before the

Supreme Court.

Further, conferences in this respect were held both in Bangalore and ta New Delhi frequently

throughout the year with Senior Counsel Sri. F.S .Nariman and Sri. Anil.B.Divan in preparation for the ensuing

arguments.

I. A No. 3 of 2008 filed by Tamil Nadu in Civil Appeal No. 2453/2007:

Tamil Nadu filed the above I.A in Supreme Court regarding taking up of Shivanasamudram Hydro Electric

Project by the State of Karnataka. The State of Tamil Nadu insisted that the four Hydro Electric Schemes viz.,

Shivanasamudram, Mekedatu, Rasimalai and Hogenekal (the first two lie entirely in Karnataka area, whereas the

other two lie in the common reach between Karnataka and Tamil Nadu) be taken up as a joint venture by the

Government of India and that Shivanasamudram and Mekedatu should not be individually taken up by the

State of Karnataka.

The replies to the above I.A have been prepared and approved by the Government. The same is to be

finalized by the Senior Counsel Sri. F.S. Nariman and has to be filed before the Supreme Court.

Before the Cauvery River Authority:

After the Final Award of the CWDT on 05.02.2007 Karnataka is of the opinion that neither the Interim

Order nor the final order is under operation as the Tribunal in its interim order had stated that the interim order

will be in effect till the final order is pronounced but the final order has not yet been notified by the Government

of India, whereas Tamil Nadu is of the contention that the interim order dated: 25.06.1991 still survives.

The Government of India had indicated that till the final Order is notified, the interim order holds sway.

Karnataka has differed on this and has urged that the matter can only be resolved by CRA.

Under such circumstances, whether the regime of flows is to be regulated as per Interim order or as per

final order remained unresolved. As such during the year 2008-09 the regime of flows to be regulated to Tamil

Nadu under distress condition was requested for from the CRA. In this respect several letters were addressed to

Government of India to convene the CRA meeting at the earliest. But till to date it is not been convened.

Page 21: Annual Report 2008-09 ENG

21

During the year the gauging at Biligundlu have shown that a quantity of 199.96 tmc has flown to Tamil

Nadu to end of 3/2009. The computations of Tamil Nadu at Mettur indicate the flow reaching Mettur as 195.55

tmc during the corresponding period.

KRISHNA - GODAVARI UNIT

The Krishna Godavari Unit under the jurisdiction of the Water Resources Development Organisation, is

working on the following Inter-State Water Disputes:

1. Krishna Water Dispute

2. Mahadayi Diversion Scheme

3. Godavari Water Dispute

4. Palar and Pennar Basin

5. Inter-linking of rivers

KRISHNA WATER DISPUTES:

As per Bachawat Award under Scheme „A‟, the allocations are as follows:

Maharashtra 560 TMC

Karnataka 700 TMC

Andhra Pradesh 800 TMC

The Bachawat Tribunal had also devised the Scheme 'B' to allocate surplus waters available in the Krishna Basin.

As per this Scheme „B‟ the basin States were earmarked the shares, in the surplus waters available above 2130

tmc, as per the following percentages:

Maharashtra 25%

Karnataka 50%

Andhra Pradesh 25%

Karnataka filed a letter of Complaint for constituting a Water Dispute Tribunal in the matter of sharing

of surplus water of Krishna River Basin on 26.09.2002 before the Government of India. Considering

the complaints of the States, the Central Government issued a Notificat ion dated 02.04.2004

constituting the Krishna Water Disputes Tribunal Shri Justice Brijesh Kumar as Chairman with Shri

Justice S.P.Srivastava and Shri Justice D.K.Seth as Members. A Technical Committee and legal team

comprising of 11 Advocates including the Advocate General under the leadership of Sri F.S.Nariman

and Sri. Anil B. Divan, Senior Counsel to has been constituted by the Government.

MAHADAYI WATER DISPUTES: (DIVERSION SCHEME)

Malaprabha dam was constructed during 1972 across river Malaprabha at Naviluteertha, Belgaum

district. The utilisation contemplated was 44 tmc and it has a gross and live capacity of 37.7 tmc.

A draft counter statement opposing the request of Goa, in O.S.No.4/2006, to transfer the Mahadayi

Water Dispute to Tribunal, has been prepared by the Advocates and has been approved by the

Government. The same will be filed before.the Supreme Court shortly.

To meet the expenditure towards the above water disputes works a revised estimate amounting to Rs.

700.00 Lakh, for the year 2007-08, has been administration approvied by the Government. An

expenditure of Rs.630.00 lakhs has been incurred upto end of March, 2008. The main object of the

Page 22: Annual Report 2008-09 ENG

22

struggle is to mitigate the drought in the North Karnataka region in Krishna Basin by providing

good quality drinking water supply and [water for Irrigation.

GODAVARI WATER DISPUTE:

As per the final decision of Godavari Water Disputes Tribunal, 22.37 tmc of water is available in the

Godavari Basin to the State of Karnataka. Further, 23 tmc of additional water can be utilized by the State of

Karnataka in Krishna basin from the date of approval to polavaram Diversion Scheme is accorded by

Government of India. Government

HYDROLOGY UNIT:

To assess Water Resources in Karnataka State in a scientific manner, the studies of flow data at various

points in different river basins and rainfall data are most essential. As such, the Government of Karnataka has

established a separate Hydrology Unit under Water Resources Development Organisation, with the

responsibility to collect data from various gauging stations spread all over the State for analyzing and validation

of Hydrometric and Hydrometeorological data.

The following Meteorological stations are working under the Jurisdiction of WRDO:

A. Hydrological Stations:

1. Current Meter Gauging Stations - 42

2. Stage Discharge Stations - 12

3. Silt and Sedimentation observations stations - 31

B. Hydrometeorological Stations:

1. Fully Climatic Stations - 86

2. Autographic Rain gauge Stations - 165

3. Standard Rain gauge Stations - 758

The data obtained from these Hydrological and Hydrometeorological stations are scrutinized, analysed

and processed. The data of Rain gauge Stations maintained by Water Resources Development Organisation are

published by the Department of Economics and Statistics after obtaining the data from the concerned Tahasildar

office‟s of the respective Taluks. The monthly statement of daily inflow, outflow and utilization of water from

the major and medium reservoirs are being received from respective Project Authorities. The yield studies are

being carried out for the irrigation, drinking and power projects as and when proposed by the planning unit.

The Surface Water samples from various rivers are collected at 12 locations and analysed for 6

parameters namely colour, odour, temperature, electrical conductivity, dissolved oxygen and PH

value, at Level – I labs.

Further, analysis of surface water for chemical parameters (27 Nos) conducted once in 2 months

done at Level – II labs established at KERS and at Munirabad for 10 different locations from the

rivers of south and 7 different locations from the rivers of North Karnataka. The data are being

received at Surface water data centre, Bangalore.

ADDITIONAL WORK TAKEN: The National committee on Dam Safety has recommended to carry

out the Hydrological review of design flood of all the large dams in the state as per the guidelines issued by

Page 23: Annual Report 2008-09 ENG

23

CWC. The Hydrological review involves calculation of revised design flood and comparing the same with the

value adopted while designing the flood. This task of Hydrological review has been entrusted hydro unit of

WRDO. There are 236 dams identified for carrying on the Hydrology review.

Hydrology Project – Phase – I:

Government of India took up the Hydrology Project – I under the World Bank Aid, which envisaged

the setting up of reliable and well designed network in the country for the collection of Hydrological and

Hydrometeorological datas, both for Surface as well as Ground Water for quantity and quality. The data from

the above network of stations is being collected, validated and stored in the data centre of Hydrology Unit.

The project started on 10.12.1996 and closed on 31.12.2003.

During the current financial year of 2006-07, a budget grants of Rs.3.50 Crores has been allocated for

maintenance of Stations, Laboratory, Vehicles, Computers etc., established under the World Bank assisted

Hydrology Project-I and for payment of salaries of Staff created under this project. A total of Rs.2.69 Crores

expenditure is during 2006-07.

Hydrology Project-I was envisaged for setting up of data collection network only.

Hydrology Project Phase – II:

The Central Government has included the State of Karnataka for participating in the Hydrology Project

Phase – II. It has allocated a provision of Rs. 29.19 crores for this purpose. This has again been divided into

two components.

Surface Water Component - Rs11.54 Crores

Ground Water Component - Rs. 17.65 Crores

Total: - Rs. 29.19 Crores

A review of the various activities, which are proposed to be taken up under Hydrology Project – II

indicates that a majority of the expenditure is concentrated for development of software packages and trainings.

The Government in their order No.WRD/8/Rajyo/2004, Bangalore Dated 24.12.2004 has accorded

approval to the implementation of the project. The legal agreement and the project agreement for the Hydrology

Project – II has been signed with the Bank on 10.01.2006. The effectiveness date of the project is from

05.04.2006 and the project is to be completed by 30.06.2012. The project t is currently under implementation.

GEOMATICS CENTER

Projects taken up for Investigation by adopting the latest techniques through Geomatics Centre are as

follows.

Survey and Investigations of potentials flows from West to East and North Eastern part

of Karnataka, the work is entrusted to N.R.S.A., Hyderabad. Till date 13 thematic maps of 6 themes

each have been supplied. So far, the Executive Engineer, I.I.Division, Mysore have paid Rs.257.84

Lakhs to N.R.S.A., Hyderabad.

Page 24: Annual Report 2008-09 ENG

24

For implementation of State Water Policy Water Resources Data Center has to be established.

Geomatics lab has been equipped with 3 workstations and one plotter along with one P.C. with Auto

CAD, GIS and ERDAS software for water resources planning and investigations. Further the center has

been strengthened by procuring One A0 scanner. During the year 2008-09 two more Arc GIS 9.3

version software with 3D and spatial analyst extension have been procured for the Geomatics Center

along with upgrading of existing Arc GIS 9.0 to 9.3 version. Two more Hp work stations and One Hp

server has been procured for the center‟s use.

Different maps based on the available data in K.G., Cauvery and Hydrology Units and maps for Inter

State Tribunal have been generated and given for their use from time to time

Maps showing position of Hydrometerlogical Stations in Karnataka is under preparation.

Assisting Hydrology Unit of Central Office in preparation of Catchment area delineation indicating

the influencing rain gauges for all dams and M.I. Tanks under Dam Safety preparedness in Karnataka

State.

Web Enabled GIS based water Resources Information System pertaining to Karnataka State is to be

generated on 1:50,000 scale for 29 layers of information and furnished to the CWC as per the Central

Government request. Relevant date from all the Major and Medium Minor Irrigation Projects is being

asked by the concerned head of the zones of different projects.

Generation of Action plan for Dam safety/Technical preparedness for large /medium dams of the state

using the GIS technology is in progress.

INDEX

Page 25: Annual Report 2008-09 ENG

25

7. CENTRAL MECHANICAL ORGANISATION

Central Mechanical organization (CMO) has one circle office, three divisions, 14 sub-divisions and 36

Sections/Work shops under its jurisdiction.

I. The main duties and functions of the organization are briefly as follows:

a) Optimum utilization of Machinery/Equipment available in the department.

b) Stream lining the purchase of spare parts of Machinery/Equipments.

c) Centralization and Stream lining of purchase of new Machinery/Equipments.

d) Reduction in the inventory of the spare parts held in stock of various divisions.

e) Plugging the leakages of revenue.

f) Disposal of surplus and unserviceable machinery.

g) Inspection of sick machinery in the Public Works and Water Resources Department and scrutiny/sanction of

repair estimates.

h) Review of efficiency and performance of Machinery/Equipments.

i) Calculation of hire charges of machinery/equipment and recommendation to the Government for the

adoption of hire charges from time to time.

j) Rehabilitation of surplus Vehicles/ Machinery/Equipments.

PROGRESS ACHIEVED BY C.M.O DURING 2008-09:

In order to ensure optimum utilization of Machinery/Equipments, available in Public works and Water

Resources Department, the monthly returns of machinery of divisions are being obtained and reviewed regularly

for its various performance aspects such as

1) Fuel usage

2) Oil usage

3) Km run with reference to standards fixed.

4) Idleness, surplus ness and rehabilitation.

5) Sick vehicles/equipments identification and its speedy repairs

6) Disposal of unserviceable machinery is reviewed and follow up action ensured until their disposal.

Purchase of spare parts required for repairs to machinery is being streamlined and only such spares, which

are absolutely required and not available in the stock, are procured. The Chief Engineer, CMO is the Member-

Secretary of the Purchase Committee. Any new purchase of machinery is being screened thoroughly and

recommended to Government for approval.

CMO is making efforts in utilisation of the available spare parts in stock of several Divisions of PWD and

WRD thereby causing reduction in the inventory.

Every effort is being made by the CMO to check and plug the loss of revenue to the Government by the

utilisation and hiring of machinery to contractors, thus bringing revenue to Government.

Page 26: Annual Report 2008-09 ENG

26

Central Mechanical Organisation is also inspecting vehicles / equipment pertaining to Board, Corporations

and Central Government after levying inspection fees and remitting to the same to the Government Treasury.

DISPOSAL OF SURPLUS AND UNSERVICEABLE MACHINERY

Sl.

No.

No.of

Vehicle / equipment

declared unserviceable

No. of vehicle/

Equipment/

Machinery disposed off

Amount of revenue

through disposal

(Rs. In Lakhs)

Balance equipment/

machinery

(a) Water Resources Department:

1 245 174 6.83

75

(Disposal is under various

stages)

(b) Public work Department:

1 964 0 57.39

146

(Disposal is under various

stages)

Surplus Machinery Declared and their Rehabilitation

Sl.

No. Nigam / Zone No. Remarks

1 WRDO 5

Includes 8 Jeeps,24

Cars 3 Maruti vans

&1 Tipper

2 Hemavathy Project Zone 06

3 PWD 11

4 Other department 06

5 ZP 01

6 ISZ 02

7 M.I (N) 05

TOTAL 36

Disposal of unserviceable machinery in Water Resources & Public Works Department, which

have been recommended for scrap during routine course of inspection:

Sl.

No. Description No. Remarks

1 Unserviceable machinery identified for

disposal during 2008-09 159

Rs. 1,24,48,583.00

Revenue Realized 2 Disposed during 2008-09 155

Page 27: Annual Report 2008-09 ENG

27

ACHIEVEMENT OF CENTRAL MECHANICAL ORGANISATION DURING 2008-09

Sl.

No Subject

Achievements

(Numbers)

1 Repair of Machinery/Equipments (Major and Minor)

a) Opening Balance (01.04.2008) 252

b) Receipts 3398

c) Total 3650

d) Repaired & dispatched 71(includes major repairs) 3394

e) Closing balance 256

2 Inspection

a) Total General Inspection 236

b) Recommended for repair 77

c) Recommended for discard 159

3 Repairs Estimate

a) Initial Estimates ---

b) Estimates Inspected and granted 167

c) Amount of Inspected estimates Rs. 212.09 lakhs

d) Number of reports given by inspecting the estimates 24

e) Total amount of estimates after inspecting the reports Rs.17.20 lakhs

f) Amount of Granted Estimates 143

g) Granted amount of estimates Rs. 194.89 lakhs

4 Spare parts utilization

a) Cost of Identified Spare parts Rs. 30.96 lakhs

b) Cost of spare parts utilized on works Rs. 1.49 lakhs

c) Balance Rs. 29.47 lakhs

INDEX

Page 28: Annual Report 2008-09 ENG

28

8. KARNATAKA ENGINEERING RESEARCH STATION

Karnataka Engineering Research Station was started during 1944 as a small Research Unit. The

Research Station, which forms a wing of the State Water Resources Department, had a phenomenal growth and

today it is one of the oldest Research Organisations of its kind in the country. The main objectives of the

Research Station are to find solutions to various problems encountered by the field Engineers in Civil

engineering discipline. The Research Station has solved many intricate problems posed by Public Works

Department, Water Resources Department, other Civil Engineering Departments, other agencies etc. The

Research Station has well equipped laboratories supported with good Computer facilities and Library.

The Director of the rank of Chief Engineer heads the Research Station. He is assisted by the Joint

Director, who is also the Principal of Engineering Staff College, which is a wing of K.E.R.S.

The activities of the Research Station are grouped under 4 divisions as under.

Hydraulics Division

Technical Services Division

Soil Mechanics & Foundation Engineering Division

Coastal Engineering Division

Chief Research Officer of the rank of Executive Engineer heads each Division. There are 4 Chief

Research Officers (Executive Engineer), 19 Research Officers (Assistant Executive Engineer), 62 Assistant

Research Officers (Assistant Engineer), and 19 Junior Research Officers (Junior Engineer). Of these sanctioned

posts, 04 Chief Research Officers, 17 Research Officers, 45 Assistant Research Officers and 12 Junior Research

Officers are working at present.

HYDRAULICS DIVISION

Model studies of various components of Irrigation & Power Projects like spillway and energy dissipating

arrangements, Assessment of carrying capacity of canal system by backwater computation, Gauging of canals,

calibration of current meters, Capacity Evaluation of Reservoir by conventional Hydrographic survey as well as

remote sensing techniques are the studies entrusted to this division.

TECHNICAL SERVICES DIVISION

This division is entrusted with the work of conducting, non-destructive tests on cement, concrete, Mix

design, steel, sand coarse aggregate etc. Tests on water samples, cement mortar and cement concrete samples

for chemical analysis, collection of daily Rainfall and Hydrometerological data, maintenance of buildings and

quarters of KERS, maintenance of library are other works entrusted to this division.

Page 29: Annual Report 2008-09 ENG

29

SOIL MECHANICS & FOUNDATION DIVISION

This division deals with problems related to foundations, suitability of soils to embankments, foundations of

bridges and buildings and that related to MI tanks. This division also deals with problems related to rocks & its

properties, roads etc.

COASTAL ENGINEERING DIVISION

The main objective of this division is to investigate the causes of coastal erosion along coastal line of

Karnataka, to collect field data, to suggest remedial measures to contain coastal erosion and to conduct model

studies if necessary. Also pre-monsoon and Post-monsoon monitoring of Sea Walls, monthly monitoring of Sea

Walls being constructed by port authorities are being done by this Division. In addition, this division is also

conducting silt and sedimentation survey of Kabini reservoir.

Through the above Divisions, the Research Station has been playing a key role in solving many

Engineering problems in the field of Hydraulics, Concrete, Testing of building materials- concrete, Soils, Rock,

problems connected with roads, Sea Erosion etc.

DAM SAFETY CELL

A Dam Safety Cell is working in the Research Station under the direct control of the Director, K.E.R.S. The

Cell is headed by Assistant Executive Engineer supported by technical staff and deals with the safety aspects of

Dams as per the guidelines of Central Water Commission.

A proposal for creation of Dam Safety Organisation (DSO) headed by a Superintending Engineer is under

consideration by the Government.

PROGRESS ACHIEVED BY KERS DURING 2008-09:

During the year 2008-09, up to end of March 2009, 85 Nos. of studies covering Hydraulic studies,

Rating of current meters (40 Nos), Gauging of canals, Capacity evaluation of reservoirs, Testing of Building

Materials, Soils, Water quality testing, etc., referred by different agencies have been completed and reports sent

to concerned authorities and 26 studies are under progress. Major studies undertaken at the Research Station

during the current year are as follows.

1. As per the request of Tungabhadra Board and directions from Government, the Hydrographic survey of

T.B. Reservoir was completed during the current year. The draft report has been prepared which will be

finalized in consultation with Andhra Pradesh Engineering Research Laboratory (APERL) authorities.

2. Gate operation studies of Yagachi Reservoir have been completed and report submitted to concerned

project authorities.

3. Gate operation studies of Uduthorehalla Reservoir project has been completed and report submitted to

concerned project authorities.

4. Current meter gauging was conducted at chainage 102.83 kms of Hemavathi Left bank canal and report

sent to concerned project authorities.

Page 30: Annual Report 2008-09 ENG

30

5. The test result data collected at the level-II Water quality Lab at K.R.Sagar from year 2001-2006 in

respect of Cauvery River at Krisharajasagara dam site was analysed and a report on analysis of water

quality has been sent to concerned authorities.

6. The study report on analysis of regionalization of Cauvery river basin in Karnataka by flood frequency

analysis was prepared and sent to various institutions for their expert comments.

7. Report on sedimentation of Kabini Reservoir using inflow and outflow method has been prepared. As

it is proposed to conduct the Hydrographic survey of Kabini Reservoir using Hitech Boat & IBS

equipments, a proposal has been submitted to Government to shift the Head Quarter of Silt and

sedimentation sub division Kabini from Kabini colony to Krishnarajasagara.

Also the Coastal Engineering Division has been conducting monthly monitoring sea walls being

constructed by port authorities and submitting monthly reports to the concerned. Also the monitoring of

emergency sea protection works carried out under D C grants are also being undertaken by this division at

Dakshina Kannada and Udupi District.

Under Hydrology project, two Level II Water Quality laboratories have been setup at K.R.Sagara &

Munirabad. The laboratory is made functional by using the services of regular Assistant Engineers and Water

Quality studies have been commenced during the current year. In the lab at K.R.Sagara, studies have been

completed on the 35 samples received. In the lab at Munirabad 11 studies have been completed on the stipulated

27 parameters.

Important events during the year:

During 2008-09. tests on 130 samples have been completed and reports sent to concerned authorities

and 09 studies are under progress/Reports to be sent

1. The Karnataka Engineering Research station has entered

into and MoU with Administrative Training Institute

(ATI) Mysore as a Third party agency for conducting the

quality control tests on the materials used for

development works taken up under the grants allotted

under 12th finance commission.

2. Similarly proposals have been initiated by KERS to

utilize the services of Research Institute as a Third party

agency for quality control of works being undertaken by

various agencies viz Mysore University, Mysore city

corporation, Karnataka police housing corporation,

Karnataka Health system development improvement

project, Bangalore etc.

Page 31: Annual Report 2008-09 ENG

31

3. The KERS has been enrolled as a life member of the

prestigious International commission on Large Dams,

India (INCOLD) during the current year.

4. A training workshop for Policemen, Police officers(civil),

Police officers(armed), Engineers and Technical staff on

„Water Resources Infrastructure Protection‟ was

conducted at K.E.R.S., K.R.Sagara from Date:05.02.2009

to 07.02.2009 organized jointly by vigilance wing of

Water Resources Department, CNNL and KERS.,

K.R.Sagara.

5. One day training programme on the tests to be conducted

on the road construction materials and test to be

conducted during the construction of the road was

conducted at the Research Station for the Engineers of

Pradana Manthri Gram Sadak Yojana (PMGSY).

6. As per the request of Department of Water Shed

development, one day laboratory training was conducted

at the KERS for the Officers of Mysore Division on 10-

02-2009.

7. As per the request of Department of Water Shed

development, one day laboratory training was conducted

at the KERS for the Officers of Mysore Division on 06-

03-2009.

Strengthening of Research Station:

A Grant of Rs. 250.00 lakhs has been released for the year 2008-09 under the plan Head in connection

with strengthening of the Research Station.

Action was taken by KERS to implement the programme approved by Government in respect of the

above.

Accordingly necessary equipments like Hand held GPS, Core drilling Machine with diamond drill bits,

Digital camera, 1000 KN UTM, 2000 KN capacity digital compression testing machine, Rebar locator, Spilt air

conditioner, Universal triaxial testing machine, Total station equipment etc., have been procured. Also solar

lamps have been installed in view of safety and solar heater has been installed at Engineering Staff College

hostel.

Also the following civil works have been undertaken.

1. Renovation of existing open shed into seminar hall at Brindavan area of KERS.

2. Renovation of existing office building of Hydraulics Division in Brindavan area of KERS.

3. Construction of additional Rating tank in Brindavan area for carry out rating of current meters.

4. Providing Rain water harvesting to Main Building of KERS.

Page 32: Annual Report 2008-09 ENG

32

5. Renovation of existing hostel building of KERS.

The balance works/procurement of equipments yet to be commenced as per the approved

programme will be taken up during 2009-10 as spill over works and completed.

Since the objective of K.E.R.S. is to find solution to various incidental Civil Engineering

problems referred by Government, Quasi Government and other agencies etc., accordingly the same are

being attended to as and when refer by the said Departments/ agencies and will also be continued in future.

Activities:-

The Engineering Staff College conducts mainly three types of training Courses.

(i) Orientation course for newly appointed Asst. Executive Engineers/Asst. Engineers/Junior

Engineers (Duration - 6 weeks for Asst. Executive Engineers and 4 weeks for Asst. Engineers

and Junior Engineers)

(ii) Refresher courses for in - service Engineers and others in different subjects (Duration – 5 to 6

days). On special circumstances these courses will be extended upto 10 days.

(iii) Short term courses under Continuing Education Programme (C.E.P) (Duration - 5 days).

Besides, Basic Computer Course of 12 days duration are also being conducted by the College for the

benefit of Engineers & other staff working in the Department.

PROGRESS ACHIEVED BY ENGINEERING STAFF COLLEGE DURING 2008-09:

The details of training Programmes conducted during 2008-09 are given below.

Sl.

No. Category of training programme

No. of

courses

proposed

No. of

courses

conducted

No. of

persons

trained

1 Institutional Courses 26 11 596

2 C.E.P Courses 35 35 556

Total 61 46 1152

During 2008-09, upto end of March 2008, 46 different training Programmes have been conducted and

1152 officers/Staff has been trained.

In all, since inception of Staff College up to end of March 2009, the college has successfully conducted

1188 training programmes and has trained 24261 Officers/Staff of the Government Departments.

INDEX

Page 33: Annual Report 2008-09 ENG

33

9. WATER AND LAND MANAGEMENT INSTITUTE (WALMI)

Introduction:

To maximize returns from investments made in irrigation projects in the State, it is necessary to manage

water and land in a systematic and scientific way. This requires capacity building of Government Staff as well

Water Users. To meet these capacity building needs, Water and Land Management Institute (WALMI) started

functioning at Dharwad on 12-5-1986 and was later registered as a Society under the Karnataka Societies

Registration Act, 1960 on 16.06.1986. WALMI: imparts training; renders technical assistance, advises

Government on legal, policy, organizational and procedural changes; organizes demonstrations in collaboration

with other organizations; conducts special studies and brings out publications.

Training:

WALMIs training activities focused on the training required for implementation of the State Water

Policy and the Irrigation Sector Reforms. Special emphasis was laid on training on Participatory Irrigation

Management, Water Management and Land Development. Office bearers of Water Users Cooperative Societies

throughout the State as well as some farmers were also trained by WALMI. As against a target of 1200 persons

to be trained, 1806 persons were trained during 2008-09.

Technical Assistance:

WALMI rendered technical assistance to the Water Resources Department and organizations coming

under the Department on implementation of State Water Policy, Participatory Irrigation Management and

necessary legal and policy changes.

Demonstrations in Collaboration with the University of Agricultural Sciences, Dharwad:

Demonstrations pertaining to irrigation methods for different crops- Cotton, Soyabean, Paddy,

Sunflower, Wheat, Maize, Groundnut, Guava, Mango, Sapota and vegetable crops were laid. Water saving

technolgies like drip, sprinkler and Raingun were demonstrated in the WALMI Farm to support training

activities.

Financial Progress:

During the year, WALMI received Grant-in-aid of Rs. 27.66 lakhs under 2705-00-800-1-03

Command Area Development. Total expenditure of Rs. 106.17 lakhs was incurred during the year.

INDEX

Page 34: Annual Report 2008-09 ENG

34

PROJECTS UNDER

KRISHNA BHAGYA JALA NIGAM

LIMITED

Page 35: Annual Report 2008-09 ENG

35

10.1 UPPER KRISHNA PROJECT

(A) BRIEF DESCRIPTION:

In order to speed up the implementation of the Upper Krishna Project (UKP) in the State of Karnataka,

by mobilising resources from the capital markets, KBJNL was incorporated on 19th August 1994 under the

Companies Act, 1956 as a Company, wholly owned by the Government of Karnataka for planning,

investigation, estimation, execution, operation and maintenance of all irrigation projects coming under the UKP.

The Company is funding the rehabilitation and resettlement of the people affected by the Project. The company

is authorised to let-out water and recover revenues from individuals, groups of farmers including Water Users

Co-operative Societies, towns, city municipalities and industries.

(B) ADMINISTRATIVELY APPROVED COST AND THE YEAR OF APPROVAL ALONG WITH

REVISED COST DETAILS:

(a) Stage-1 work of UKP has been approved by Planning commission vide letter No.2 (10) /88-

I&CAD/ dated 24.09.90 for Rs. 1214.97 Crores. The revised project cost approved by the

Nigam‟s Board is Rs.6003.19 Crores as on 30th September-2005.

(b) Stage-II work of UKP has been approved by Planning commission vide letter no: 2 (10) /99-

WR/ dated 13.12.2000 for Rs. 2358.86 Crores. The revised project cost approved by the

Nigam‟s Board is Rs.3476.40 Crores as on 30th September-2005.The revised updated cost

submitted to CWC for Rs.3618.96 crores includes escalations.

(C) EXPENDITURE INCURRED / POTENTIAL CREATED ON THE PROJECT :

So far a sum of Rs.10545.00 Crores has been spent on the project upto March 2009 and an amount of

Rs. 4869.06 Crores is spent towards payment of interest to bond holders / term Loan. Out of contemplated 6.22

lakh Ha. of command area under UKP potential of 5.99 lakh Ha. has been created upto March 2009.

(D) BARRAGES ACROSS RIVER BHIMA , KRISHNA & MANJRA RIVER:

Krishna Bhagya Jala Nigam Limited is implementing the following barrages across River Bhima,

Krishna (Krishna basin) and across River Manjra (Godavari basin).

(a) Across River Bhima (Krishna Basin)

Sl.

No. Barrage Status of work

1 Ghattarga Barrage Completed

2 Kallur „B‟ Barrage Completed

3 Yadgir Barrage Completed

4 Joladagi - Gudur Barrage Completed

5 Modified Sonthi Barrage LI

Scheme

Civil work of barrage almost completed.

Fabrication and erection of 37 vertical gates is in

progress. Also, construction of head work including

intake channel, providing pumping machinery, sub-

station, raising main, etc. awarded on turnkey basis

is in progress.

(b) Across River Krishna (Krishna Basin)

Sl.

No. Barrage Status of work

1. Gugal Barrage Civil work of barrage completed. Fabrication and

erection of 70 vertical gate work is in progress.

Page 36: Annual Report 2008-09 ENG

36

(c) Across River Manjra (Godavari Basin)

Sl.

No. Barrage Status of work

1. Jirgihal Barrage Construction of four series of barrages taken up across river Manjra in Bidar district of Godavari basin to utilize allocated

4.80 TMC.

The civil works of all four barrages and works of providing

automatic tilting Godbole gates are under progress.

2. Manikeshwar Barrage

3. Halhalli Barrage

4. Chandapur Barrage

KBJNL, DAM ZONE, ALMATTI

Dam Zone Almatti was established on 30.01.1977. One Circle Office, Six Division offices with 20 Sub

divisions, One Senior Health Office (Class-I) with its 4 Anti-Malaria Units and Deputy Conservation of Forest

with its 3 Sub-Divisions are working under this zone.

The works of Almatti Dam, Lift Irrigation Schemes of UKP such as ALBC, ARBC and Mulwad LIS,

other LI Schemes such as Marol, Timmapur, Teggi-Siddapur, Sonna and Rolli-Mannikeri LI Schemes, filling up

of MI Tanks in Bijapur & Bagalkot and landscape and garden development works at downstream of Almatti

Dam are coming under the jurisdiction of this Zone. Status of projects under KBJNL Dam Zone is as under:

1) Almatti Dam:

The work is already completed and Gates are also erected. The water is being stored upto FRL 519.60

m and being utilized for irrigation and generation of electric power.

2) Almatti Left Bank Canal : Head work already commissioned. The total length of Main Canal is 85.00 Kms out of which 67.00

Kms is completed. Further the works from KM 67.00 to 85.00 is also completed except the reach in Km 72. The

distributaries 1 to 27 are completed and the works of distributary No.28 to 40 are also almost completed.

An area of 18,784 ha. is notified for for Rabi 2008-09 and water has been let out for irrigation.

3) Almatti Right Bank Canal :

Head work already commissioned. The Main Canal of 67.50 Km is completed including Distributary

No.1 to 24. Out of 9,900 ha, area of 8,859 ha. is notified for Rabi 2008-09 and water has been let out for irrigation.

About 6,200 Ha. of ARBC command beyond Malaprabha River is included in Marol Lift Irrigation

Scheme.

4) Mulwad Lift Irrigation Scheme:

The water will be lifted in two stages under this scheme. Two head works viz; Baluti and Hanumapur

head works were already commissioned. The lead off canal from Km 0.00 to 5.00 which leads water from 1st jackwell to 2nd jackwell completed.

East Canal is of total 17.40 Km length and is completed. Out of 6 No. distributaries on East Canal

Distry.No.1 to 5 are completed and Distry.No.6 is nearing completion. West Canal is of total 78.00 Km length

and is completed. All 43 Distributaries under West Canal are also completed except certain balance works

under Distry.No.7 & 11 which are in progress.

Page 37: Annual Report 2008-09 ENG

37

Out of contemplated 30,850 ha of command area, potential of 21,346 ha is already created and 16,280

ha is notified for Rabi 2008-09 and water has been let out for irrigation.

5) Ramthal (Marol) Lift Irrigation Scheme:

This LI Scheme is taken up on the foreshore of Narayanapur Reservoir. The Scheme contemplates

providing irrigation to 26,200 ha. of command area of Hunagund Taluk of Bagalkot District. Estimated cost of

this project is Rs.218.00 Crores.

Construction of 1st jackwell and its allied works is almost completed. Further the work of construction

of 1st Stage West Main Canal KM 0.00 to 8.00 awarded on package tender is in progress. Construction of 2nd

Jackwell including intake channel, providing pumping machinery, sub-station, raising main etc, on turn key

basis was awarded on turn key tender basis is under progress. Tenders for 1st stage West Main Canal KM 8.00

21.00 and Disty.No.1, 2, 3, 5 & 6 are invited. Further, the survey investigation and preparation of estimates for

further canal network is under progress.

6) Thimmapur Lift Irrigation Scheme:

This LI Scheme takes off at KM 5.40 of main canal of ARBC. The Scheme contemplates providing

irrigation to 20,100 ha. of command area of Bagalkot Taluk.

The work of construction of Jackwell, providing pumping machinery, sub-station, raising main,

delivery chamber etc, entrusted on turn key tender basis is under progress. Tenders for Main Canal Km 0.00 to

10.00 from Delivery Chamber-1 are invited. Detailed survey and investigation of canal network is under

progress.

7) Teggi-Siddapur Lift Irrigation Scheme :

This Lift Irrigation Scheme is taken up on the foreshore of Almatti Reservoir, near Teggi village of

Bilgi Tq. to provide irrigation benefits to about 3,000 ha area of Bilgi Taluk.

For the construction of balance works of Jackwell (civil works) & for providing pumping machinery,

substation, rising main, delivery chamber etc, turn key tenders invited. Further, for the Main Canal from Km.

0.00 to 12.00, tenders in two packages are re-invited as the tenders invited earlier were cancelled.

8) Sonna and Rolli-Mannikeri Lift Irrigation Schemes: These LI Schemes are taken up on the foreshore of Almatti Reservoir. Sonna and Rolli-Mannikeri LI

Schemes provide irrigation benefits to about 3,000 ha area in Bilgi Taluk.

For Sonna LI scheme construction of Jackwell, providing pumping machinery, sub-station, raising

main, delivery chamber etc, entrusted on turn key tender basis is under progress. For Rolli- Mannikeri LI

Scheme, work of construction of Jackwell, providing pumping machinery, sub-station, raising main, delivery

chamber etc, tenders on turn key basis re-invited as the agency to whom the work was awarded earlier has not

commenced the work and tender agreement rescinded duly forfeiting the EMD amount.

9) Landscape and Garden works on D/s of Almatti Reservoir:

Landscape Development of Almatti Dam environs have been taken up to create the avenues for

economic development of project area by attracting the tourist. A Committee is formed under the Chairmanship

of the Commissioner, R&R, Bagalkot to monitor and supervise the landscape and garden works.

The project has been phased out in multiple stages and development of 77 Acres of land along the left

bank on the D/s of Dam is taken under Phase-I. The works of providing illumination and commissioning of musical fountains are under progress. In the later phase of landscape development works of providing water

theme parks, courts etc., are planned in about 220 Acres.

Page 38: Annual Report 2008-09 ENG

38

10) Filling up of M.I.Tanks of Bagalkot and Bijapur District :

The work of filling up of 16 MI tanks and 5 bandaras of Bijapur District and 7 MI tanks of Bagalkot

district, awarded on turnkey basis during Janauary 2009 and the work commenced. Period of completion of

work is 36 months.

11) SCP-TSP Works:

Under this programme, it is proposed to provide Sprinkler irrigation facilities to the SC/ST

beneficiaries coming under ALBC, ARBC and MLIS command area. Totally 22 works are taken up under the

scheme and out of which 21 No. of works are completed and commissioned. 1 work is under progress.

DETAILS OF IRRIGATION POTENTIAL:

( Area in Ha)

Sl.

No Name of District Planned

Created

upto

March

2008

Programm

e 2008-09

Prgoress

2008-09

Programme

for 2009-10

1 2 3 4 5 6 7

1 Almatti Left Bank Canal (

KM 0 to 85) 20235 21406 728 484 244

2 Almatti Right Bank Canal

(KM to 67 KM) 9900 9037 258 100 85

3 Mulwad Lift Irrigation

Scheme 30850 20970 1285 471 814

TOTAL 60985 51413 2271 1055 1143

KBJNL, OPERATION & MAINTENANCE ZONE, NARAYANPUR :

Considering the vast area that is already notified and the place of development of irrigation in the

subsequent phases, the Government has accorded sanction for creation of separate Zone to look after Operation

and Maintenance activities of UKP vide G.O. No.ID/115/WBM/91 Dated: 14/10/1991. Owing to the

Government order, the office of the Chief Engineer, O&M Zone, UKP Narayanpur came into existence on

03.01.1992. This Zone is working under Krishna Bhagya Jala Nigam Limited with effect from 15.11.1995. One Circle, four Divisions and Twelve Sub-Divisions are working under the control of Zone.

This Zone has the responsibility to monitor the water management for an irrigated area of 4.25 lakhs

hectares under Stage-I of UKP. As the project work is under progress, the irrigable area under this zone is

increasing year by year. This year an area of 98,964 ha. has been declared as notified are for irrigation during

Kharif and Rabi season respectively. The canal wise details of Notified area as under:

Sl.

No Canal Kharif 2008-09 Rabi 2008-09

1 Narayanpur Left Bank Canal 27,961 27,961

2 Hunasagi Branch Canal 22,172 22,172

3 Rampur Lift Irrigation Scheme 19,271 19,271

4 Narayanpur Right Bank Canal 30,224 30,224

Total 99,269 99,269

The Maintenance of following irrigation camps in the project area also come within the preview of this

zone.

Page 39: Annual Report 2008-09 ENG

39

1) Narayanpur 2) Kodekal 3) Rajankollur 4) Kakkera 5) Hunasagi 6) Devapur

7) Devatkal 8) Mudunoor 9) Rodalabanda 10) Amarapur Camp

The Maintenance of 108.00 Km length of Major District road 247.32 Km of other roads, 16 VHF

wireless stations, etc., are the other works which are being looked into by this Zone.

Apart from Operation and Maintenance of canal network in NLBC from Km. 0.00 to 78.00, NRBC

Km. 0.00 to 82.00 & Rampur Lift Irrigation Scheme, this Zone is also looking after the following works:

1) Rajan-Kollur Lift Irrigation Scheme:

The Scheme takes off from the D/s of Rajan-kollur Tunnel at Km 40.06 of NLBC. The scheme

contemplates to provide irrigation for 1,295 ha of command area in Shorapur taluk. The construction of

head work including intake channel, providing pumping machinery, sub-station, rising main etc, awarded on turnkey basis and also work of Distributary network awarded on tender basis are in

progress.

2) Bonal Lift Irrigation Scheme:

This scheme contemplates providing irrigation to about 2,500 ha of the suffering achcut under SBC

Distry.No.6 by lifting water on the D/s of Bonal Mini Hydel Scheme near Bonal tank of Surpur taluk.

The tender invited on turnkey basis is under process.

DETAILS OF IRRIGATION POTENTIAL (Area in Ha.)

Sl.

No

Name of the

District

Planned

potential in Ha

Created upto

March-

08(Notified)

Additional

creation during

2008-09

Progress of

creation

during

2008-09

1 Bijapur 27 27 - -

2 Gulbarga 47196 50106 - -

3 Raichur 50325 49331 2061 535

TOTAL 97548 99464 2061 535

Page 40: Annual Report 2008-09 ENG

40

KBJNL, CANAL ZONE NO. 1, BHEEMARAYANAGUDI:

1. CONTEMPLATED IRRIGATION POTENTIAL:

The irrigable command areas contemplated under various canals of this Zone are as under:

Name of the Canal ICA envisaged (i) Shahapur Branch Canal. : 1,22,120 Ha.

(ii) Mudbal Branch Canal. : 51,000 Ha.

(iii) Jewargi Branch Canal : 57,098 Ha. (iv) Narayanapur Right Bank Canal : 53,997 Ha.

(KM 82.00 to 95.00 & Dy.No.15 to 18)

Total : 2,84,215 Ha.

The command areas of Shorapur, Shahapur and Jewargi Taluks of Gulbarga district and Deodurga

Taluks of Raichur district will be covered in the above mentioned canal networks.

2. PRESENT STATUS OF WORKS UPTO END OF MARCH 2009:

Shahapur Branch Canal and Mudbal Branch Canal works are completed and are in the Operation & Maintenance stage.

Jewargi Branch Canal:

The works of this canal come under UKP Stage-I, Phase-III. The earth work of Jewargi Branch Canal

from 0.00 to 13.00 Km was first started during 1992-93, under famine works programme. But brisk activities of

the works on this canal started during the year 1995-96 with the formation of KBJNL.

All the works of Main Canal (Km0.00 to86.36) and Distrys. 1 to 18, including lining, are completed.

Works of only an aqueduct on Lateral-1 of Distry No.16 and some additional lateral works taken up on Disty.No.12(A), 12(A1) are yet to be completed and are programmed for completion during 2009-10.

The irrigation potential created under the canal upto March 2009 since inception is 58224 Ha as

against the contemplated potential of 57,098 Ha. It was programmed to create additional potential of 1400 Ha

during 2008-09 and only potential of 488 Ha has been created during 2008-09 since some of the additional

works proposed could not be taken up due to the court cases. Out of the total created command area of 58224 ha

to the end of March-2009, 52,140 Ha. area is notified for Rabi 2008-09 and water letout for irrigation including

in the balance area wherever the basic infrastructure for irrigation potential has been created.

The cumulative financial progress achieved on the works of this canal since inception is Rs. 406.11

Crores to the end of 31-03-2009.

The balance works, (including FICs) will be completed during 2009-10.

Narayanapur Right Bank Canal:

The works of this canal were taken up under UKP Stage-II, with the Nigam funds, during the year

1995-96. The jurisdiction of NRBC from KM 82.00 to 95.00 and Dity.No.15 to 18 comes under this Zone. The

jurisdiction of NRBC from KM 0.00 to 82.00 and Disty.No.1 to 14 comes under the jurisdiction of O&M Zone,

Narayanapur.

All the works of Main Canal from Km 82.00 to 95.00 and Distry.No.15 to 18 are completed. Works of

only some additional laterals on D-15,16 & D-16 are being taken up and will be completed during 2009-10.

The total contemplated irrigation potential of 84,000 Ha has been already created on the canal. Out of

the total created command area of 84,000 ha to the end of March-2009, 75,736 Ha area is notified for Rabi 2008-

09 and water has been let out for irrigation including in the in the balance area wherever the basic infrastructure

for irrigation potential has been created.

Page 41: Annual Report 2008-09 ENG

41

The cumulative financial progress achieved on the works of this canal since inception is Rs.1058.30

Crores to the end of 31-03-2009.

All the balance works (including FICs) will be completed during 2009-10.

Bridge Cum Barrage Works:

The works of construction of one Bridge cum Barrage across River Krishna, three Barrages across

River Bhima, and four Barrages across River Manjra come under this Zone.

The work of construction of two Bridge cum Barrages (i.e. Yadgir & Joldadgi-Gudur Barrages) are

completed.

The civil portion of modified Sonthi Bridge cum Barrage across River Bhima (near village Sonthi) is

almost completed. The work of fabrication and erection of 37 vertical gates is in the advanced stage of progress.

Further, the Head work including electro-mechanical works of Sonthi LI Scheme awarded on turnkey basis is in

progress and programmed for completion by Decemebr 2009. Tenders for feeder canal KM 0.00 to 1.75 invited.

The work of construction of Bridge cum Barrage near Gugal village on River Krishna is also completed

to the extent of civil portion. However, the work of providing 70 vertical gates is under progress.

Also the works of construction four barrages across River Manjra of Godavari Basin in Bidar Dist.

including the works of providing Godbole gates are under progress. Chandapur & Manikeshwar Barrages are programmed for completion during 2009-10.

Total expenditure incurred during 2007-08 on all the Barrage works coming under this Zone to the end

of March-2009 is Rs.10223.63 Lakhs as against the annual target of Rs.4070.00 Lakhs.

PROGRAMME AND PROGRESS DURING 2008-09:

The annual financial programme of this zone for the year 2008-09 was Rs. 123.56 Crores and the

programme of creation of irrigation potential was 4,888 Ha.

Against the programme, the financial progress achieved to the end of March-09 is Rs. 141.36 Cr and

an irrigation potential of 3,716 Ha has been created.

DETAILS OF IRRIGATION POTENTIAL (Areas: In Ha)

Sl

No

Name of the canal Planned Programme for

2008-09

Progress during

2008-09

1 Shahapur Branch Canal 1,22,120 350 304

2 Mudbal Branch Canal 51,000 - -

3 Jewargi Branch Canal 57,098 1400 488

4 Narayanapur Branch Canal 53,997 3138 2924

Total 2,84,215 4888 3716

DETAILS OF FINANCIAL ESTIMATES (Rs.in lakhs)

Sl

No Activity

Actuals

2007-08

Budget

Estimate

2008-09

Progress

during

2008-09

1 Dam and appurtenant &

Reh. Works 7757.51 7291.00 10239.59

2 Canal: Branches/Dys/Lats. 3094.40 3015.84 1784.72

3 Roads. 235.82 - 9.92

4 Buildings. 162.06 125.00 165.73

5 Others. 1552.84 1924.16 1936.43

Total 12802.63 12356.00 14136.39

Page 42: Annual Report 2008-09 ENG

42

KBJNL, CANAL ZONE NO. 2, KEMBHAVI

The UKP Canal Zone No.2 Kembhavi is functioning with effect from 1.10.1986 vide G.O.No. PWD 60

PCO 86, Dated. 29.9.1986, for the construction of Indi Branch Canal and Mudbal Branch Canal. Subsequently,

the Mudbal Branch Canal works were transferred to the jurisdiction of UKP Canal Zone No.1

Bheemarayanagudi. Ayacut Road works were transferred to this Zone vide G.O.No. PWD 60 PCO 86, dated 15.6.1987.

At present this Zone is in-charge of the works of Indi Branch Canal from Km 0.00 to 172.00 including

Distry.No.1 to 46, Indi Lift Canal works from Km 0.00 to 147 and Ayacut Road within the Ayacut of Indi

Branch Canal. The works of IBC from Km 1 to 172, Disty.No.1 to 46 including laterals and FICs are already

completed and irrigation potential of 1,31,293 Ha. is created. Water letout for irrigation in the completed canal

network and is under operation maintenance.

The works of Head Regulator and intake canal of Indi Lift Scheme and Canal works from Km 0.225 to

97.30 are completed including Disty.No.1 to 40 except Disty.No.22 for which tenders for balance work invited

as the original tender agreement was rescinded at the risk and cost of contractor due to non completion of the

work. Irrigation potential of 41,813 Ha. created upto March 2009 and water has been out for irrigation in Indi Lift Canal. Further, the works of Indi Lift Canal from Km 97.300 to 102.000 taken up on tender basis are under

progress. Tenders invited for Main Canal from KM 102.00 to 110.00 and Disty.No.41 and 42. Further, the

survey investigation and preparation of estimates for Indi Lift Canal from Km 110.000 to 147.000 are under

progress.

ORGANISATION :

This Zone is functioning with one circle ie., O&M Circle No.2 Rampur. Details of works taken up

under this Zone are as under.

INDI BRANCH CANAL :

The Indi Branch Canal takes off at Km 77.52 of Narayanpur Left Bank Canal, which is situated about 1

Km away from Kembhavi village of Shorapur taluka in Gulbarga District and traverses for a length of 172 Km

with a head discharge of 2,943 cusecs (83.49 cumecs) through the districts of Gulbarga and Bijapur irrigating an area of 30,831 Ha. and 1,00,464 Ha. respectively (Total 1,31,295 Ha.)

The works of construction of Indi Branch Canal from Km 0.00 to 64.00 are tackled and completed

under Stage-I, Phase-II of UKP creating an irrigation potential of 60,721 Ha. The works of construction of Indi

Branch Canal from Km 65.00 to 172.00 are tackled and completed under Phase-III of Stage-I to create the

balance irrigation potential of 70,574 Ha. Up to March 2009 an area of 1,31,293 Ha Irrigation Potential has

been created.

On the works of Indi Branch Canal from KM 1 to 64, the expenditure incurred to end of March 2009 is

Rs.48582.23 lakhs.

The works of Indi Branch Canal from KM 65 to 172 and Distributaries 14 to 46 have been taken up on tender as well as entrustment basis. The works are completed. The details of works taken up and completed are

as under:

(i) The works of IBC from KM 65 to 80, 101 to 113, 120, 122 to 125 and 151 to 172 are taken up

on tender basis and the works are completed.

(ii) The works of IBC from KM 81 to 88, 90 to 100, 114 to 119, 121, and 126 to 150 are taken up

on direct entrustment basis and the works are completed.

(iii) The works of Distributaries 14 to 24 and laterals coming under IBC from KM 65 to 120 are

also taken up on direct entrustment basis and the works are completed.

Page 43: Annual Report 2008-09 ENG

43

(iv) The works of distributaries 25, 26 to 34, 35 to 37, 38 to 45A and 46 are made into packages

and the works were taken up on tender basis. The works are completed.

(v) The works of providing CC lining to IBC from KM 65 to 172 also have been made into

packages and these works were taken up on tender basis. The works are completed.

INDI LIFT CANAL : The works of Indi Lift Irrigation Scheme viz., Head Regulator, pump house, transmission line, sub-

station, ETC. and Intake Canal with structure taken up on tender basis are completed. Works of Indi lift canal

from Km 0.225 to 97.30 taken up on tender basis are almost completed. Works of Distry.No.1 to 40B & laterals

there under except Distry.No.22 of ILC are also completed. Tenders for balance works of Disty.No.22 invited.

Out of contemplated irrigation potential of 41,900 Ha. upto end of March 2009 irrigation potential of 41,813 Ha.

has been created. Notified area for Rabi 2008-09 is 32,470 Ha and water has been letout for irrigation under

Indi Lift Canal.

Further, Indi Lift Main Canal KM 97.30 to 102.00 taken up on tender basis are in progress. For Main

Canal from KM 102.00 to 110.00 & Distributary No.41 & 42 package tenders invited. Work of survey

investigation and preparation of estimates for further canal network entrusted on tender basis is in progress.

AYACUT ROADS: Stage-I, Phase-I:

Construction of Ayacut Roads under Phase-I was of 611 kms length and all these works are completed.

Stage-I, Phase-II:

It was proposed to tackle 942 Kms of Ayacut Roads under Phase-II of Stage-I of UKP. Out of these

942 Kms, construction of 307 Kms of Ayacut Roads were handed over to CADA as per the orders of G.o.No.ID

95 Dt: 15-11-1995. Hence, 635 Kms of Ayacut Roads come under the jurisdiction of this zone. These works are

completed except the works of AR-04 Package. The contractor of AR-04 package has stopped the works for

non-finalization of workable rates. The roads coming under this package are included in the rehabilitation of

Ayacut Roads package and the works are in progress.

The amount spent on Ayacut Road works upto March 2009 is Rs. 2311.37 lakhs including

maintenance. (Excluding World Bank works which are completed).

Under this zone 10 Nos of Ayacut Roads in two packages have been taken under Rehabilitation & Resettlement programme and these works are in progress.

BUILDINGS:

The buildings were constructed in various colonies of this zone for accommodation for staff and office.

Rs.1904.37 lakhs expenditure is incurred towards these works to end of March 2009. Two building packages

one at Rampur with bid cost of Rs.296.51 lakhs and another at Almel with bid cost of Rs.140.48 lakhs are

completed. The expenditure incurred upto end of December 2006 on the above works is as under:

1. Buildings at Rampur Package B2-01 Rs. 370.07 lakhs

2. Buildings at Almel Package B2-02 Rs. 182.76 lakhs

SCP-TSP WORKS :

Under this Zone totally 42 works on SCP-TSP is taken up during 2008-09 and all works are almost

completed.

Page 44: Annual Report 2008-09 ENG

44

DETAILS OF IRRIGATION POTENTIAL

(Areas: In Ha)

Name of the District,

Bijapur and

Gulbarga

Total ICA Potential created

to end of 3/08

Programme

during the year

2008-09

Progress up to

March 2009

Indi Branch Canal. 131261 131295 -- --

Indi Lift Canal 41900 41813 2263 --

INDEX

Page 45: Annual Report 2008-09 ENG

45

10.2 BAGALKOT TOWN DEVELOPMENT AUTHORITY, BAGALKOT

1. SALIENT FEATURES OF BAGALKOT TOWN :

Bagalkot Town is historically famous from the glory and one of the largest town in the northern parts of

Karnataka which is situated on the right bank of Ghataprabha River at Long 75o12‟ E and Lat 16 o12‟ N.

Bagalkot Town is getting submerged under back waters of Almatti reservoir when the Almatti Dam

height reaches RL.524.256 mtrs resulting submersion of 3/4th of the town. Bagalkot Town Development

Authority has acquired 4,500 Acre of land for rehabilitation and resettlement of old Bagalkot town. During

2000-01 when water was stored at Almatti upto RL 519.60 mtrs, its backwater spread up to RL 520.10 mtrs. at

Bagalkot. The following are the submergence details at different elevations.

Sl.

No

Height

RL Mtrs

No. of

Structures

Present acquisition of Structures. Total Difference Population

Authorized Un-authorized

1 2 3 4 5 6 7 8

1. 517.00 615 781 206 987 372 3760

2. 521.00 2337 2524 1208 3732 1395 18860

Total 2952 3305 1414 4719 1767 22620

3. 521 to 525 4225 2525 498 3023 1202 28376

4. 525 to 526 1872 -- -- 1872 -- 7021

5. 526 to 527 1482 -- -- 1482 -- 4238

Total 10531 15815 4686 62255

6. Above 527 22000 91596

Note: The figures at Sl.No.1 and 2 are as per 6(i) Notification. The figures indicated at Sl.No.3, 4 and 5 are as

per survey conducted in1986.

2. ORGAINSATION STRUCTURE:

For efficient and systematic implementation of R&R of Bagalkot Town, Govt. of Karnataka has

constituted BTDA under an Amendment to K.I.B Act functioning from 1984. BTDA is formed with one Chief

Engineer Office, 2 Divisions, 8 Sub Divisional Offices, Special Land Acquisition Office and Rehabilitation

Office.

3. AIBP PROGRAMME:

Estimated cost of Rehabilitation and Resettlement of Bagalkot Town

Sl.

No. Details of Component Rs.in lakh

1 Structural compensation in old Bagalkot Town. 39539.06

2 Land Acquisition for new township and others etc. 2952.50

3 R&R Packages. 3000.00

4 Construction of Roads and parks etc., 6231.50

5 Providing Water Supply 4445.00

6 Providing U.G.D. 2200.00

7 Providing Electrification. 2000.00

Page 46: Annual Report 2008-09 ENG

46

8 Construction of Public Building 2200.00

9 Telecom facilities 400.00

10 Construction of Railway 1000.00

11 Maintenance of BTDA Colony and Navangar. 800.00

12 New Supply Machinery and Maintenance 250.00

13 Consultancy and training charges 90.00

14 Establishment 2591.94

Total:- 67700.00

An amount of Rs.342.70 crores towards AIBP works components has been included in the above

estimated cost. In addition to above an amount of Rs.360.49 crores is towards Special Package and the works are

being executed by BTDA. Thus, the total cost of the project works out to Rs.1037.49 crores.

The works taken up under Stage-I Phase-I & II are completed and the works under Phase-III are

nearing completion. Structures up to RL 521.00 contour have been evaluated and compensation paid. Plots for

the PDFs below RL 521.00 Mtr. Contour have been allotted in New township of Bagalkot. Most of the PDFs

constructed their houses in the allotted sites.

4. SPECIAL PACKAGE SCHEME:

Considering the problems due to backwater effect, Govt. has announced the special package of

Rs.638.00 Crores (Rs.500 Cr for Bagalkot town + Rs.138.00 Cr for R&R) Vide G.O.NO.RD1/124/REH/2002/

Dt.16.11.2002 to improve the existing conditions of Bagalkot Town. The details of special package are as

under.

Sl.

No. Details of components

Rs. in

Crores

1 Structural compensation between RL.521.00 to 523.00, and development of 35

sectors of unit 2 of Navangar with all infrastructures facilities like roads. 414.00

2 Providing UGD for Non submergence of Bagalkot Town. 29.12

3 Providing Water Supply for non-submergence of Bagalkot Town. 11.70

4 Construction of link roads. 20.00

5 Development of parks in old town. 2.00

6 Construction of building under Ashraya Scheme for slum dwellers. 12.00

7 Construction of building for site less and below poverty line people. 5.00

8 Construction of 50 bedded hospital in old town. 2.00

9 Income and employment generating scheme. 4.18

Total 500.00

I. a) For Acquisition of structures between RL.521 to 523 mtrs, 6(i) Notification is published.

b) The fixing boundary stones and demarcation of various sizes of plots in 42 sectors of unit 2

are completed.

c) The estimate for infrastructures facilities like, main peripheral roads, UGD, Water supply

etc. for Unit-II of Navanagar etc. are to be prepared.

II. The U.G.D. Network in old Town for Non-submersible portion of Bagalkot is nearing

completion.

III. The work of providing water supply system including revamping of existing pipeline for non-

submersible portion of Bagalkot town is completed and is functioning.

IV. The road works in Old Bagalkot Town for 3 link roads, 5 main roads, 7 internal roads in slum

area of Bagalkot Town were taken up on tender basis and all are completed.

Page 47: Annual Report 2008-09 ENG

47

V. Development of 4 parks in old Bagalkot town are taken up. Out of which 3 garden works are

completed and one is nearing completion.

VI. Construction of 50 bedded hospitals building in old Bagalkot Town is under progress.

5) FINANCIAL PROGRESS ACHIEVED UPTO MARCH-2009 SINCE INCEPTION:

The cumulative expenditure incurred since inception (1983-84) upto March 2008 is Rs.484.39 Crores.

The expenditure incurred during 2008-09 upto end of March 2009 is Rs.142.15 Crores.

6) FINANCIAL PROGRESS ACHIVED UPTO 31-03-2009 SINCE 1996-97 FOR A.I.B.P WORKS.

The cumulative expenditure incurred on AIBP works since inception 1996-97 upto March 2008 is

Rs.16961.64 lakhs. The expenditure incurred during 2008-09 upto end of March 2009 is Rs.11465.00 lakhs.

7) DETAILS BUDGETARY PROVISIONS FOR 2008-09:

(Rs. In Lakhs)

Sl. No. Details of Component. Approved. Revised.

1 2 3 4

I Under A.I.B.P.

i) Compensation & Lok Adalat. 10661.04 9231.37

(ii) R & R Package. 10.50 5.00

(iii) Development Civil works.

(a) Roads. 2854.44 2926.29

(b) Water Supply. 394.82 423.39

© U.G.D. 191.45 191.45

(d) Electrification. 214.86 214.62

(e) Buildings. 201.76 201.70

(f) Gardens. 97.16 87.16

II Maintenance of Civil Works, & Vehicles. 100.00 327.48

III SCP & TSP Works. 70.12 70.00

IV Special Package works (Roads, Water Supply, UGD,

Electrification, and Buildings & Garden. 374.00 2491.14

V Establishment charges. 425.00 425.00

Total: 15595.00 16595.00

Page 48: Annual Report 2008-09 ENG

48

8) DETAILS OF PROGRESS ACHEIVED DURING 2008-09 (UP TO 31-03-2009)

a) Compensation of Rs. 594.65 lakhs have been paid to 184 authorised structures coming below

521.00 Mtr. contour and Rs. 7893.51 lakhs have been paid towards compensation for 173

structures as per court award (Under Lok Adalat cases).

b) Totally 56 sectors for PDF's and 8 Sectors for Non-PDF's are developed in unit-1 at Navanagar.

During this year 4260 plots are allotted to P.D.F‟s., Non-PDFs & others. For 700 PDF‟s and 65

Non PDF‟s permission have been given to construct their houses.

c) Rs.1.32 lakhs have been paid as a house grants in the form of ex-gratia for 6 PDF‟s who are

coming below powerty line.

10) FINANCIAL PROGRESS:

Financial programme for the year 2008-09 is Rs.165.95 crores out of which an expenditure of Rs.

142.15 Crores has been made up to end of March-2009. The total expenditure incurred since inception is Rs. 598.15 Crores. The Details are as under:

(Rs. in Crores)

Sl.N

o. Programme

Progress

(upto 1/09)

A

Under A.I.B.P. Works:

i) Development works

ii) Lok Adalat Compensation

4045

92.36

33.48

81.18

B Revenue Head 3.28 3.69

C For Special Package 24.91 19.78

C SCP & TSP Works 0.70 0.67

D Establishment 4.25 3.35

Total 165.95 142.15

INDEX

Page 49: Annual Report 2008-09 ENG

49

PROJECTS UNDER

KARNATAKA NEERAVARI NIGAM

LIMITED

Page 50: Annual Report 2008-09 ENG

50

11. KARNATAKA NEERAVARI NIGAMA LIMITED

11.1 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, IRRIGATION

(NORTH), BELGAUM

Irrigation (North) Zone was formed on 10.8.67 in pursuance of the Government order

No.PWD.114.PCO.67, dated: 24.7.1967 with a view to increase the tempo of construction work in the Irrigation

Projects as a result of increased provision of the plan allocation in the state.

Irrigation (North) Zone is incharge of the following projects.

On-going Schemes

1 Ghataprabha Project

2 Hipparagi Irrigation Project

3 Markandeya Reservoir Project

4 Dudhaganga Irrigation Project

5 Lifting of Hiranyakeshi waters into GRB Canal.

6 Bellary Nala Project

7 Sri Rameshwara L.I.S

(*) To irrigate suffering atchkat of tail end distributaries of MRBC / NBC, under Malaprabha Project

So far, an irrigation potential of 3,14,693 Ha, has been created under the above projects. An

expenditure of Rs.1945.44 Crores has been incurred under the above schemes to end of 3/2009.

Out of the above schemes, Markandeya Project is completed during 2006-07 and the remaining schemes

are under different stages of progress.

INDEX

Page 51: Annual Report 2008-09 ENG

51

11.1.1 GHATAPRABHA PROJECT

NAME OF THE PROJECT GHATAPRABHA PROJECT

Location Hidkal

Year of Inception 1972

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Original Estimated cost-Rs. 90.54 Crores

Administrative approval: GO No.PWD. 147.MGP. B‟lore

Dated: 16.12.76-Rs.90.54 Crores

Latest Estimated cost-Rs.1435.00 Crores vide GO. No. WRD 66 NIN 2006 dated 28.07.2007

Length of Canal G.R.B.C. G.L.B.C

a) Main Canal, 199 Km. 109 Km.

b) Branch Canal 88 Km 197 Km

c) Distributories 994 Km 494 Km

Length of ayacut roads/ I.T.roads 600.35 km

Districts benefited Belgaum, Bagalkot

Number of villages and Taluks Benefitted Athani, Chikodi, Gokak, Hukkeri, Raibag, Ramadurg, Saundatti,

Badami, Bagalkot, Bilagi, Hungund, Jamakhandi, Mudhol

taluks.

Number of W.U.C.S:

a) Formed 302

b) Registered 302

c) Handed over 285

Programme during 2008-09 Physical Financial

2271 Ha Rs. 153.00 Crores.

Progress achieved upto End of March 2007 - Rs. 55.49 Crores

Programme for 2009-10 (Physical & Financial). 2271 ha Rs.202.00Crores.

Cumulative progress upto End of March 2009 299777 Ha (including Stage-I,

II & III) Rs.1208.90 crores.

INDEX

Page 52: Annual Report 2008-09 ENG

52

11.1.2 HIPPARAGI IRRIGATION PROJECT

NAME OF THE PROJECT HIPPARAGI IRRIGATION PROJECT

Location Hipparagi village

Year of Inception 1973

Original and Latest estimated cost

(Rs. in Crores), including administrative/

approval number & Date.

Original Estimated cost- Rs.186.70 Crores

Latest Estimated cost-Rs. 1521.78 Crores

Administrative approval: GO No. WRD / 21/ MBI/2008

dated 26.02.2008.

Length of Canal

a) Main Canal 289 Km

Districts benefited Belgaum, Bagalkot

Number of villages and Taluks Benefitted Athani, Chikodi, Jamakhandi taluks.

Physical Financial

Programme during 2008-09 2000 Rs. 237.00 Crores.

Progress achieved upto End of March 2009 - Rs. 80.87 Crores.

Programme for 2009-10 (Physical & Financial). 21,469 Rs. 220.50 Crores.

Cumulative progress upto End of March 2009 - Rs. 351.09Crores.

Brief description Central assistance under AIBP to this project is availed from

2007-08. CA received till date is Rs.140.99 crores. Barrage

works including erection of gates is completed. Water is

being imponded since 2004. Four LIS viz., Haliyal, Ainapur,

Karimasuti and Savalgi-Tungal are components of this

project. Out of these, Haliyal LIS Stage I & II, Ainapur LIS

are executed on turn key basis

Ainapur LIS: The works of pumphouse, rising main and delivery chamber are completed. Works of East canal of 27

Km. length and West canal of 52 Km.length are at various

stages of progress.

Haliyal LIS: The works of pumphouse, jackwell, rising main

and delivery chamber under Stage I & II are completed.

Works of intake canal is nearing completion. Modified tender

is invited for combined canal. Works of East canal of 39 Km.

length and West canal of 32 Km.length are at various stages

of progress.

Karimasuthi & Savalgi-Tungal LIS: Works in these LIS are

in progress.

INDEX

Page 53: Annual Report 2008-09 ENG

53

11.1.3 MARKANDEYA RESERVOIR PROJECT

NAME OF THE PROJECT MARKANDEYA RESERVOIR PROJECT

Location Shirur village

Year of Inception 1998

Original and Latest estimated cost

(Rs. in Crores), including administrative/

approval number & Date.

Original Estimated cost-Rs.120.00 Crores

Latest estimated cost- Rs.341.94 Crores

Administrative approval No. WRD 08 VEBYAMA 2003

dated 28.07.2007.

Length of Canal R.B.C. L.B.C.

a) Main Canal 71 Km 15 Km

b) Distributories 183 Km -

Districts benefited Belgaum

Number of villages and Taluks Benefitted Belgam, Hukkeri, Gokak, Saundatti taluks.

Physical Financial

Programme during 2008-09 - Rs. 10.00 Crores.

Progress achieved up to end of March 2009 - Rs. 2.89 Crores.

Programme for 2009-10 (Physical & Financial). 65 Ha Rs. 7.00 Crores

Cumulative progress upto End of March 2008 14383 Ha Rs. 305.64 Crores

Brief description R & R works of 7 villages affecting 833 farmers is taken up in

2 rehabilitation centres. Shifting of PAF is completed. Third

rehabilitation centre has been identified, shifting of balance

PAF will be after completion of development works.

Chicholi-Murgod LIS is planned in balance works of this

project at estimated cost of Rs.47.13 crores to benefit 2718 ha.

and 1939 ha. Of land respectively.

INDEX

Page 54: Annual Report 2008-09 ENG

54

11.1.4 DUDHGANGA IRRIGATION PROJECT

NAME OF THE PROJECT DUDHGANGA IRRIGATION PROJECT

Location Asangaon village (Maharashtra State)

Year of Inception 1992 (Canal in Karnataka State)

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Original Estimated cost-Rs.124.00 Crores

Latest Estimated cost –Rs. 124.00 Crores

Administrative approval. Ja.SAM: E-1: (VI.DN: GAM: 2000(P-2)

Dated.17/4-2002 (For Rs.-124.00 Crores)

Technical sanction. : (Yet to be accorded for Karnataka works).

Length of Canal Nidhori Branch

Canal Bidri Branch canal

Dattawad Branch Canal

a) Branch Canal 21.57 Km 25.155 Km 30.00 Km

Districts benefited Belgaum

Number of villages and Taluks Benefitted Chikkodi taluk.

Physical Financial

Programme during 2008-09 - Rs. 18.00 Crores

Progress achieved up to end of March 2009 - Rs. 11.68 Crores.

Programme for 2009-10 500 Ha Rs. 14.00 Crores.

Cumulative progress up to end of March 2009 3800 Ha. Rs. 115.68 Crores. (Karnataka‟s

share)

Brief description This project is being assisted under Hon‟ble PM‟s Special

Rehabilitation Package.

INDEX

Page 55: Annual Report 2008-09 ENG

55

11.1.5 LIFTING OF HIRANYAKESHI WATERS INTO G.R.B. CANAL.

NAME OF THE PROJECT LIFTING OF HIRANYAKESHI WATERS INTO G.R.B.

CANAL.

Location Ghodageri village

Year of Inception 2005

Year of completion (in case of

Completed Projects) Under progress.

Original and Latest estimated cost including

administrative/Technical sanction approval number &

Date.

Estimated cost - Rs. 30.00 Crores. Administratrive approval

WRD:03:NIN: 1995: Bangalore dated 23.8.2003Technical

sanction CIN.109. For June 2005.

Length of Canal

a) Main Canal

Detailed survey is taken up. b) Branch Canal

c) Distributories

d) F.I.C.

Districts benefited Belgaum

Number of villages and Taluks Benefitted Hukkeri

Physical Financial

Programme during 2008-09 - Rs. 6.00 Crores

Progress achieved up to end of March 2009 - Rs. 0.40 Crores

Programme for 2009-10 (Physical & Financial). - Rs. 4.00 Crores.

Cumulative progress up to end of March 2009 - Rs. 12.72 Crores.

INDEX

Page 56: Annual Report 2008-09 ENG

56

11.1.6 BELLARYNALA PROJECT

NAME OF THE PROJECT BELLARYNALA PROJECT

Location Kardikolla village

Year of Inception 2005

Year of completion (in case of Completed Projects) Under progress

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Approval number & Date.

Estimated cost: Rs. 143.55 Crores

Administrative approval: No. WRD 02 VEBYAMA 2005

dated28.07.2007

Length of Canal

a. Main Canal

Detailed survey is taken up b. Branch Canal

c. Distributories

d. F.I.C.

Districts benefited Belgaum

Number of villages and Taluks Benefitted Gokak, Saundatti.

Physical Financial

Programme during 2008-09 - Rs. 45.00 Crores

Progress achieved up to end of March 2009 - Rs. 13.56 Crores

Programme for 2009-10 (Physical & Financial). - Rs. 45.00 Crores

Cumulative progress upto End of March 2009 - Rs. 124.86 Crores

INDEX

Page 57: Annual Report 2008-09 ENG

57

11.1.7 SRI RAMESHWAR L.I. SCHEME

NAME OF THE PROJECT SRI RAMESHWAR L.I. SCHEME

Location Dhavaleshwar village

Year of Inception 2005

Year of completion (in case of Completed Projects) Under progress

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Original cost: Rs. 218.42 Crores

Administrative approval No: JaSamE: 14: NIN: 2001:

Bangalore: Dated.23.8.2003.

Technical sanction: CEI (N) Reg. No. 110 for June 2005

Length of Canal

a) Main Canal

Detailed Survey is taken up. b) Branch Canal

c) Distributories

d) F.I.C.

Districts benefited Belgaum

Number of villages and Taluks Benefitted Gokak

Physical Financial

Programme during 2008-09 - Rs. 27.00 Crores

Progress achieved up to end of March 2009 - Rs. 10.09 Crores

Programme for 2008-09 (Physical & Financial). - Rs. 14.96 Crores

Cumulative progress up to end of March 2008 Rs. 65.23 Crores

INDEX

Page 58: Annual Report 2008-09 ENG

58

11.2 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, MALAPRABHA

PROJECT ZONE, DHARWAD

Malaprabha Project Zone, Dharwad was formed on 07.09.2007 in pursuance of the Government order

No.WRD.137.SeASu:2007, dated: 04.09.2007 with a view to increase the tempo of construction work in the

Irrigation Projects as a result of increased provision of the plan allocation in the state.

Malaprabha Project Zone is incharge of the following projects.

On-going Schemes

1 Malaprabha Project

2 Harinala Irrigation Project

3 Kalasa Nala & Bandhur Nala Diversion Schemes.

4 Javaluhalla L.I.S. *

5 Bennihalla L.I.S. *

6 Kolachi L.I.S. *

7 Konnur L.I.S. *

8 Shiggaon L.I.S

(*) To irrigate suffering atchkat of tail end distributaries of MRBC / NBC, under Malaprabha Project

So far, an irrigation potential of 2,14,841 Ha, has been created under the above projects. An

expenditure of Rs.1107.25 Crores has been incurred under the above schemes to end of 3/2009.

Out of the above schemes Harinala Project has been completed during 2006-07 and the remaining

schemes are under different stages of progress.

INDEX

Page 59: Annual Report 2008-09 ENG

59

11.2.1 MALAPRABHA PROJECT

NAME OF THE PROJECT MALAPRABHA PROJECT

Location Naviluteertha

Year of Inception 1960

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Original Estimated cost Rs.20.00 Crores

Administrative approval: GO No.PWD. 59. GMP. 77, B‟lore

Dated: 4.2.1980 Rs.162.09 Crores

Technical sanction No.: CE, I(N), BGM Reg.No.CIN.7.for June

1980 Rs.162.09 Crores

Latest Estimated cost Rs. 1275.20 Crores vide G. O. No. WRD /78/ MPS/ 2003 dated 28.07.2007

Length of Canal M.L.B.C. M.R.B.C

a) Main Canal, 150 Km. 142 Km.

b) Branch Canal 26 Km. 42 Km.

c) Distributories 280 Km 677 Km.

Length of ayacut roads/I.T.roads 282.62 Km

Districts benefited Belgaum, Dharwad, Gadag, Bagalkot

Number of villages and Taluks

Benefitted

Bailhongal, Ramadurg, Saundatti, Badami, Navalgund, Hubli,

Naragund, Ron, Gadag taluks.

Number of W.U.C.S:

a) Formed 266

b) Registered 231

c) Handed over 208

Programme during 2008-09 Physical Financial

4956 Ha Rs.59.00 Crores.

Progress achieved up to end of March 2009 2611 Ha Rs. 55.07 Crores.

Programme for 2009-10 (Physical & Financial). 2167 Ha Rs.125.00 Crores.

Cumulative progress up to End of March 2009 211361Ha Rs. 998.32 Crores.

Brief description This project is being assisted under AIBP. Central assistance

availed during 2008-09 is Rs.49.44 crores and cumulative

central assistance availed is Rs.257.07 crores.

Page 60: Annual Report 2008-09 ENG

60

11.2.2 HARINALA IRRIGATION PROJECT

NAME OF THE PROJECT HARINALA IRRIGATION PROJECT

Location Tigadi Village

Year of Inception 1998

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Original Estimated cost - Rs. 0.83 Crores

Latest Estimated cost-Rs.69.78 Crores

Administrative Approval No: CE: 114:MPS: 92

Dated.11/14/9/98 (Rs.-26.95 Crores).

Technical sanction: CEI (N): BGM: Reg.No.CIN –17 for

May 1999 (Rs.26.95 Crores).

Length of Canal Left Bank Right Bank

a) Main Canal 9.00 Km 10.72 Km

Districts benefited Belgaum.

Number of villages and Taluks Benefitted Bailhongal taluk.

Physical Financial

Programme during 2008-09 - Rs.3.00 Crores

Progress achieved up to end of March 2009 - Rs. 0.86 Crores

Programme for 2009-10 (Physical & Financial). - Rs. 2.00 Crores

Cumulative progress up to end of March 2009 3480 Ha Rs. 70.46 Crores

INDEX

Page 61: Annual Report 2008-09 ENG

61

11.2.3 KALASA NALA AND BANDHUR NALA PROJECT

NAME OF THE PROJECT KALASA NALA AND BANDHUR NALA PROJECT

Location

Kanakumbi – Kalasa Nala Project

Nerse village - Bhandur Nala Project

Year of Inception 2006

Year of completion (in case of Completed Projects) Under progress (Kalasa only)

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Original Estimated Cost

Kalasa Nala - Rs. 44.78 Crores

Bhandur Nala - Rs. 49.20 Crores

Administrative approval No.

a) Kalasa nala: ID.37.WBT. 2000: Dated.22.8.2000

b) Bhandur nala:-.ID-4.WBT:2000: dated.22.8.2000.

Technical sanction No:

a) Kalasa nala - CIN.Reg.No.270, March 2002

b) Bhandur nala - CIN.Reg.No.269, March 2002.

Districts Benefited Belgaum, Dharwad, Gadag and Bagalkot

Number of villages and Taluks

Benefited Hubli-Dharwad & other villages (Drinking water supply)

Programme during 2008-09 Physical Financial

- Rs.3.00Crores for KalasaNala

Progress achieved upto End of March 2009 - Rs. 12.19Crores for KalasaNala

Rs.0.07 Crores for BhandurNala

Programme for 2009-10 (Physical & Financial). - Rs. 10.00Crores for KalasaNala

Cumulative progress upto End of March 2009 Rs.16.06 Crores under KalasaNala & Rs. 0.41

Crores under BhandurNala

Brief description: Clearance from MoWR, Planning Commission and MoEF is

awaited.

INDEX

Page 62: Annual Report 2008-09 ENG

62

11.2.4 JAVALUHALLA L. I. SCHEME

NAME OF THE PROJECT JAVALUHALLA L.I. SCHEME

Location: Kittur village

Year of Inception: 2005

Year of completion (in case of Completed Projects) Under progress

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Original Estimated: cost. Rs. 4.21 Crores

Administrative approval: WRD: 03:NIN:95 dated:

23.08.03

Technical sanction: CE, I (N), BGM

Reg.No.CIN.10.for April – 2003

Length of Canal:

a) Main Canal

Detailed survey is taken up. b) Branch Canal

c) Distributories

d) F.I.C.

Districts benefited Belgaum

Number of villages and Taluks Benefitted Ramdurg

Physical Financial

Programme during 2008-09 - Rs. 1.00 Crores

Progress achieved upto End of March 2009 - Rs. 0.04 Crores

Programme for 2009-10 (Physical & Financial). - Rs. 1.00 Crores.

Cumulative progress up to end of March 2009 Rs. 3.98 Crores.

INDEX

Page 63: Annual Report 2008-09 ENG

63

11.2.5 BENNIHALLA L.I. SCHEME (5 NOS.)

NAME OF THE PROJECT BENNIHALLA L.I. SCHEME (5 NOS.)

Location Banahatti, Kurlageri, Surkod,Khanapur, Reddar Naganur

Year of Inception 2005

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Original Estimated cost: Rs. 17.33 Crores

Administrative approval: WRD/ 58/MPS/1999 (P), B‟lore

dated: 23.08.03

Technical Sanction: CE I (N) Reg.No.163 for August 2005.

Length of Canal

a) Main Canal

Detailed survey is taken up.

b) Branch Canal

c) Distributories

d) F.I.C.

Districts benefited Gadag

Number of villages and Taluks Benefitted Nargund

INDEX

Page 64: Annual Report 2008-09 ENG

64

11.2.6 KOLACHI L.I. SCHEME

Name of the Project KOLACHI L.I. SCHEME

Location: Asooti village

Year of Inception: 2005

Year of completion (in case of Completed Projects) Under progress

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Original Estimated cost: Rs. 2.25 Crores

Administrative approval: WRD. 58.MPS.1999 (P) (K),

Bangalore dated: 23.08.03.

Technical Sanction: CEI (N). Reg.No.162 for August 2005.

Length of Canal

a) Main Canal

Detailed survey is taken up. b) Branch Canal

c) Distributories

d) F.I.C.

Districts benefited Gadag

Number of villages and Taluks Benefitted Ron

INDEX

Page 65: Annual Report 2008-09 ENG

65

11.2.7 KONNUR L.I. SCHEME

NAME OF THE PROJECT: KONNUR L.I. SCHEME

Location: Konnur village

Year of Inception: 2005

Year of completion (in case of Completed Projects) Under progress.

Original and Latest estimated cost

(Rs. in Crores), including administrative/ Technical sanction approval number & Date.

Original Estimated cost: Rs. 6.15 Crores

Administrative approval: WRD. 58.MPS.1999 (P), B‟lore

dated: 23.08.03 Technical sanction No: CE I (N) Reg.No.161 for August

2005.

Length of Canal:

a) Main Canal

Detailed survey is taken up b) Branch Canal

c) Distributories

d) F.I.C.

Districts benefited Gadag

Number of villages and Taluks Benefitted Nargund

FOR BENNIHALLA, KONNUR L.I.S & KOLCHI LIS

Physical Financial

Programme during 2008-09 - Rs. 6.00 Crores

Progress achieved upto End of March 2009 - Rs. 5.216 Crores

Programme for 2009-10 (Physical & Financial). - Rs. 5.00Crores

Cumulative progress upto End of March 2009 Rs. 17.84 Crores

INDEX

Page 66: Annual Report 2008-09 ENG

66

11.2.8 SHIGGAON L.I. SCHEME

NAME OF THE PROJECT: SHIGGAON L.I. SCHEME

Location: Near Halasur village of Savanur taluk in Haveri district.

Year of Inception:

Year of completion (in case of Completed Projects) Under progress.

Original and Latest estimated cost

(Rs. in Crores), including administrative/

Technical sanction approval number & Date.

Rs. 238.00 Crores

Administrative approval: No. WRD / 98 / MMB / 2008,

Bangalore dated 13.01.2009.

Planned irrigation potential 9900 Ha.

Districts benefited Haveri

Number of villages and Taluks Benefitted Shiggaon, Hanagal and Savanur taluks

No. of MI tanks for stabilization 5

No. of bandaras 6

INDEX

Page 67: Annual Report 2008-09 ENG

67

11.3. AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, MUNIRABAD

11.3.1 SINGATALUR LIFT IRRIGATION SCHEME (SLIS)

The project comprises of construction of barrage across River Tungabhadra near Hammige village of

Mundargi taluk in Gadag District to provide irrigation facility to an extent of 1,20,236Acres (1,40,677Acres of

cropped area in Bellary, Koppal and Gadag districts by utilising 18.55 TMC of water.

Stage-I comprises of utilising 7.64TMC to irrigate 76181acres and stage-II of utilising 4.39TMC to irrigate

44055acres. Government has accorded administrative approval to implement this scheme with the utilization of

12.03TMC of water vide G.O. No. WRD 115 WBP 2003 Dt.29-6-2006.

BARRAGE:. Out of 26 blocks concreting in all the blocks has reached up to crest level except in block no.6

and 7.Fabrication of 26 nos of gates is completed. Erection works are to be taken up.

The Barrage and allied works are under progress. Out of 25Nos of piers 14 Nos of piers have been concreted

up to the bearing level of Spillway Bridge. Casting of RCC pre cast beams and piers are under progress.

CANAL WORKS ON LEFT SIDE:

Intake canal: Earth work excavation of intake canal from 0 to 6.71Km is under progress.

The tenders are invited to take up the works of Mundwada & Hammige Lift and of the Left side 1st Lift, on

turn key basis. The preparation of estimates and DTP are under progress for obtaining technical sanction.

Land acquisition works on left side are under progress.

The cumulative expenditure incurred on the project since inception upto end of March 2009 is Rs.

263.34 Crores. During 2008-09 an expenditure of Rs. 14.12 crores has been incurred against a budget allocation

of Rs. 64.00 Crores.

Page 68: Annual Report 2008-09 ENG

68

AN OVER VIEW OF THE SINGATALUR LIFT IRRIGATION SCHEME:

1 NAME OF PROJECT SINGATALUR LIFT IRRIGATION SCHEME

2 Location

Across River Tungabhadra near Hammige village

Mundaragi Taluk, Gadag District.

Longitude: 70 0 50‟ E

Lattitude: 15 0 02‟ N

3 Year of inception March 1998

4

Original and latest estimated cost in Crores

Including administrative approval no. and date

Original estimate-Rs. 595.00 Crores vide G.O. No.

ID/ 90/ MTP /98 and 29-12-2000.

Technically sanctioned by Chief Engineer Vide CER

No. 28/2001-02

Latest cost Rs. 657.00 Crores.

5

Length of canal

a) Main canal LBC 207.34 km

b) Branch canal 31.70 Km

6 District benefited Bellary, Gadag and Koppal

7 Number of village and Tq benefited

70 villages of Mundargi and Gadag Tq.

09 villages of Koppal Taluk.

20 villages of Huvina Hadagali Taluk

Programme during 2008-09 Physical Financial

- Rs. 64.00 Crores

Progress achieved up to end of March 2009 - Rs. 14.11 Crores

Cumulative progress up to end of March 2009 Rs. 263.34Crores

INDEX

Page 69: Annual Report 2008-09 ENG

69

11.4. AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER,

UPPER TUNGA PROJECT ZONE, SHIMOGA

The following are the projects under the jurisdiction and control of Upper Tunga Project circle,

Shimoga.

1) The Upper Tunga Project

2) The Tunga Lift Irrigation Scheme

3) Basapur Lift Irrigation Scheme

4) Itagi-Sasalwad Lift Irrigation Scheme

5) Guddada Mallapura Lift Irrigation Scheme

6) Upper Bhadra Project

7) Ubrani-Amrutapura Lift Irrigation Scheme

8) Sanyasikoppa Lift Irrigation Scheme

Page 70: Annual Report 2008-09 ENG

70

11.4.1 UPPER TUNGA PROJECT

The river Tunga is a major tributary of river Tunga Bhadra rises in Western Ghats and joins mother

tributary Bhadra at Kudli about 14.50KM from Shimoga. Upper Tunga project envisages construction of new

dam across Tunga River at 100.00 meter down stream of existing Tunga Anicut near Gajanur in Shimoga Taluk

and construction of Upper Tunga Main Canal; for a length of 339.50 km. It includes construction of tunnel of

4.00 km length and also distributary net work.

It is envisaged to create an irrigation potential of 80,494 hectares in Shimoga, Davanagere and Haveri

Districts by utilising 12.24 TMC of water from River Tunga.

The Government of Karnataka has accorded administrative approval for this project vide No.ID: 25:

MMM: 91: Bangalore dated: 3-10-1991 for Rs. 271.41 Crores and vide No.WRD: 38:WBP: 2005 (P):Bangalore

dated: 21.11.2006 for Rs. 1,052.33 Crores and the Revised Cost of the project is Rs. 1,644.11 Crores. The

project is under the control of Karnataka Neeravari Nigama, Bangalore since 14.6.1999.

DAM AND ALLIED WORKS: - Dam work including parapet wearing coat and asphalting works are

completed. Electrification work is completed. The major work on crest gate including fixing of switch gears is

completed. Power block portion of mini hydel project is completed. Earthwork excavation for construction of

power house and tail race channel is under progress.

Head resulator: Construction of regulator at Km.0145 is completed except for providing hoisting arrangement

for three gates out of five gates.

CANAL AND DISTRIBUTARY NETWORK: - Upper Tunga Project includes construction of 329.50 Km

lengths of Main Canal including CD works, lining and Distributory Network. At present main canal alignment is

approved up to 270 Km. Canal work up to Km 195 including tunnel work from Km 168.50 to 174.00 is under

Page 71: Annual Report 2008-09 ENG

71

different stages of progress. Estimates are being prepared for works from Km. 192 to 244. Works are under

different stages of progress in distributary No. 1 to 3 of main canals.

Main canals: Main canal works from Km.0 to 162 are almost completed except following up of bottlenecks.

Km. 0.172 to 10.00: Earth work is completed slips are occurring of both sides of the canal, 300 mtrs.

cut and cover and balance lining works are in progress.

Road bridge at Km.12.96: Cut & cover technology is adopted for road bridge. Tenders are at

evaluation stage.

Km. 19 to 20.00: Cut & cover road duct is proposed now instead of framed structures. Tenders are at

evaluation stage.

Km.74, 75 & 103: Original contract is recall and fresh agency is being entrusted.

Km.139, 163,164 to 168.50: Original contract is rescinded and fresh tender invited.

Km.168.50 to 174: Earth work excavation is completed. Tunnel lining is nearly completion and

grouting is in progress.

Distributory

Dist.No.1: Off-take point at Km108.35. Total length is 20.58 Km. Works are completed.

Dist.No.2: Off-take point at Km166.267. Total length is 62.50 Km. Works are completed from 0 Km. to

20 Km. Works from Km.20 to 62.50 is lingering due to rescinding of contract, Railway crossing and forest

clearance. Necessary deposits are made to railway and national highways for carrying out the work.

Dist.No.3: Off-take point at Km176.83. Total length is 23.00 Km. Works are under progress.

R & R works: Three villages of Thirthahalli taluk and two villages of N.R.Pura taluk have been

affected due to construction of Upper Tunga Project. 208 structures are affected. Necessary deposits are

paid to SUDA for formation of lay-out and site to PAF. Also, Rs.20.475 crores of ex-gratia is provided as

per the decision of R&R Committee.

During the year 2008-09 the grant allotted is Rs. 104.00 Crores and the expenditure incurred up to end

of March 2009 is Rs. 96.32 Crores. Since inception of project, cumulative expenditure to the tune of Rs. 918.32

Crores has been incurred.

INDEX

Page 72: Annual Report 2008-09 ENG

72

11.4.2 TUNGA LIFT IRRIGATION SCHEME

Tunga lift irrigation scheme is proposed at Sakrebailu village near Gajanur in Shimoga district. This

project envisages lifting of water from the backwater of UTP Reservoir to feed the suffering atchkat of 5162

Acres of Aihole, Barehalla and Gowdanakere Tanks of Shimoga Taluk. It is proposed to utilise 1.428 TMC of

water from Tunga Reservoir. For this project Government has accorded administration approval vide No. ID 68:

MMM: 95: Bangalore dated 27-2-99 for Rs. 24.12 Crores and Technical sanction was accorded for the same

amount on 30-3-99.

The Main Canal of the project runs in Sakrebylu wild life forest. Necessary proposal for Diversion of

forest Land has been made with forest authorities and this project will be implemented soon after obtaining

necessary clearance from the Government. In the meantime survey is under progress for alternative means for

avoiding forest area.

During the year 2008-09 the grant allotted is Rs. 50.00 lakhs and an expenditure of Rs. 8.89 lakhs has

been incurred during the current year. The project is yet to be started. Cumulative expenditure of Rs. 8.89 lakhs

has been incurred till date.

INDEX

Page 73: Annual Report 2008-09 ENG

73

11.4.3 BASAPURA LIFT IRRIGATION SCHEME

This project envisages lifting of water from River Varada near Basapura village in 2 stages to irrigate

5600 Acres of Land, pertaining to 13 villages of Hangal Taluk, Haveri District. An allocation of 0.60 TMC of

water for utilisation in provided for this project by the Krishna Water Tribunal. Administrative approval has

been accorded for this project vides G.O. No. ID 20/MMM/96-97 dated.9-4-96 for Rs. 936.00 Lakhs. CE, UTP

Zone, Shimoga has accorded technical sanction for Rs. 936.00 Lakhs on 31-6-1996. Latest estimated cost of the

project is Rs. 26.96 crores.

The project is transferred to KNNL during August-03. Presently, Stage I work of Electro-Mechanical

Components & other head works have been entrusted on turnkey basis and are ready for commissioning. Main

Canal work of Stage I, in the reach Km 0.00 to 0.56 & Km. 5.00 to 5.35 & Aqueduct in Ch.0.56 to 1.87 Km is

completed. Balance canal works are under different stages of progress. Distributory works are also entrusted on

tender basis, which are under different stages of progress. The estimates of Stage II are prepared and Tenders are

being invited to take up the work on Turnkey basis.

During the year 2008-09 the grant allotted is Rs. 500.00 Lakhs and the expenditure incurred is Rs. 111.13

Lakhs. Since inception up to end of March 2009, cumulative expenditure of Rs. 1218.66 Lakhs has been

incurred on the project.

INDEX

Page 74: Annual Report 2008-09 ENG

74

11.4.4 ITAGI-SASALWAD LIS

This project envisage lifting of water from River Tungabhadra near Itagi village, Shirahatti Taluk, Gadag

Distrist, in one stage to cater the irrigation requirements of Khariff & semi dry crops to an extent of 4900 acres

belonging to Shirahatti, Mundargi and Haveri Taluk. The Government accorded Administration approval for

Rs. 427.00 Lakhs on 21-09-1992 and subsequently revised administrative approval was accorded for Rs. 800

lakhs on 24-4-96. Chief Engineer, UTP Zone, Shimoga accorded technical sanction for Rs. 800 Lakhs to the

Project, on 5-6-96. An allocation of 0.55 TMC of water for utilization is provided for this project by the Krishna

water Tribunal. Latest estimated cost of the project is Rs. 18.55 crores.

The project was transferred to KNNL during August 2003. Presently the Headwork like Jack well, In-

take arrangements, Raising Main, Pump house, pumping Machineries etc., has been entrusted on Turnkey basis

and the works are nearing completion. Right bank canal to length of 25.52 Km, left bank canal to a length of

10.90 Km and its distributary network were entrusted to different agencies and are completed.

During the year 2008-09 the grant allotted is Rs. 600.00 Lakh and the expenditure incurred up to end of

March 2009 is Rs. 127.69 Lakhs. Since inception of the project an amount of Rs. 1849.47 Lakhs has been spent.

INDEX

Page 75: Annual Report 2008-09 ENG

75

11.4.5 GUDDADA MALLAPURA LIS

The lift irrigation scheme is proposed near Kusnur village in Hanagal taluk of Haveri district. This

Project envisages creation of Irrigation potential of 5263 Ha of Byadagi Taluk with an ultimate utilization of

1.00 TMC of water from River Varada. The Estimated cost of this project is Rs. 60.00 Crores.

Technical sanction is accorded for Rs. 56.16 Crores and work is taken up on turnkey basis. Presently the

agency has stopped the work and tender rescinding is under progress.

During the year 2008-09 the grant alloted is Rs. 100.00 Lakhs and no expenditure has been incurred

during the current year. Since inception, cumulative expenditure of Rs. 1563.78 Lakhs has been incurred for this

project.

INDEX

Page 76: Annual Report 2008-09 ENG

76

11.4.6 UPPER BHADRA PROJECT (STAGE 1 & 2)

This project envisages to lift 15 TMC of water from Tunga river to Bhadra reservoir, in two stages, and

lifting of 21.5 TMC of water from Bhadra reservoir to delivery chamber near Ajjampur in three stages.

Thereafter by gravity flow through canal, irrigation will be provided to 1,04,989 Ha. of land in Hosadurga,

Hiriyur, Chitradurga and Challekere taluks and 2276 Ha. of land in Kadur and Tarikere taluks, totaling to

1,07,265 Ha. by utilizing 15.9 TMC of water.

It is also proposed for restoration of 119 tanks of Tumkur and Kolar districts and 37 tanks in

Chickmagalur and Chitradurga districts and providing water to an extent of 75% of live capacity by utilizing 5.6

TMC of water to recharge the ground water table to facilitate drinking water.

Estimated cost of the projects is Rs. 5985.00 crores. 21.5 TMC of water is allocated to this project under

Scheme – A.

Modified cost of the project as per SR of 2007-08 of Rs.5985.00 crores, out of which, Rs.3388.00 crores

is for irrigation component and Rs.2597.00 crores is for drinking water component.

Tender for the following package of Upper Bhadra Project are finalized and survey works are under

progress.

Diverting 15 tmc of water from Tunga to Bhadra reservoir – Package (I).

Lifting 21.50 tmc of water for Bhadra reservoir to delivery chamber near Ajjampura (proposed

new tunnel) – Package (II).

Construction of tunnel at 6.90 km length near Ajjampura (Package-III).

During the year 2008-09 the grant allotted is Rs. 100.00 Crores and the expenditure incurred up to end of

March 2009 is Rs. 54.30 Lakhs.

INDEX

Page 77: Annual Report 2008-09 ENG

77

11.4.7 UBRANI-AMRUTHAPURA MULTIPURPOSE LIS

This scheme was a part of Upper Bhadra Project Stage-1, which was separated as per Government order.

The Main aim of this project is (a) drinking water purpose and (b) Filling of Tanks of Ubrani and Kasaba hobli

of Tarikere Taluk.

This project comprises of 3 stages costing Rs. 92.40 Crores. It is planned to lift water from Bhadra River

to Gangur in Ist Stage and is technically sanctioned for Rs. 36.00 Crores and work is taken up on turnkey basis.

The work is under different stages of progress. In 2nd Stage, water is pumped from a storage cistern at Gangur to

Mahalal valley and part to Guddadamalladevanakere and is technically sanctioned for Rs. 56.40 Crores and

work is taken up on turnkey basis. The works are nearing completion. In 3rd stage, water is directly lifted from

Guddadamalladevanakere tank to feed water to Medikere tank.

During the year 2008-09 the grant allotted is Rs. 2600.00 lakhs and the expenditure incurred up to end of

March 2009 is Rs. 2684.16 lakhs. Since inception upto end of March 2009, cumulative expenditure of Rs.

5668.10 lakhs has been incurred for this project.

INDEX

Page 78: Annual Report 2008-09 ENG

78

11.4.8 SANYASIKOPPA LIS

Sanyasikoppa lift irrigation scheme envisages construction of anicut across Kumudavathi River near

Sanyasikoppa village in Shikaripura Taluk, Shimoga District to irrigate 1791 hectares. The Government has

accorded administrative approval Vide G.O.No.ID/ 161/MMI/2003 dated: 25-3-2006 for Rs.10.00 Crores for

this Project. Technical sanction is accorded for Rs. 9.97 Crores. Agency is fixed to take up works on turnkey

basis and works are under different stages of progress.

During the year 2008-09 the grant allotted is Rs. 800.00 lakhs and the expenditure incurred is Rs.101.49

lakhs up to end of March 2009.

INDEX

Page 79: Annual Report 2008-09 ENG

79

11.4.9 KALLU VADDAHALLA NEW TANK

This project envisages construction of new tank across Kalluvaddahalla in Shikaripura taluk of Shimoga district

to irrigate 1450 hectares of land. Project estimated cost of Rs. 33.42 crores has been prepared and placed before

Technical Sub Committee for approval.

Page 80: Annual Report 2008-09 ENG

80

11.4.10 TILUVALLI LIFT IRRIGATION SCHEME

This project envisages lifting of 0.26 TMC of water from Varada River to provide irrigation facilities to 2500

acres of land in Iangal taluk.. Project estimated cost of Rs. 42.50 crores has

been prepared and placed before Technical Sub Committee for approval.

INDEX

Page 81: Annual Report 2008-09 ENG

81

11.5. AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, VARAHI

PROJECT ZONE, SIDDAPURA.

11.5.1 VARAHI IRRIGATION PROJECT

BREIF DESCRIPTION:

The Varahi Irrigation Project envisages Construction of Diversion Weir across Varahi River at Horriabbe

near Siddapura Village, Udupi District to create irrigation potential to an extent of 15,702 Ha. (38,800 acres) in

Kundapura and Udupi taluks of Udupi District, by utilizing the daily release of 1100 Cusecs of tail race water

from Varahi underground hydro electric project situated in the upstream of the river at Hosangadi.

The Varahi Irrigation Project is administratively approved by the Government of Karnataka vide G.O.No.

PWD 71 GIP 76, Bangalore dated 27-3-1979 for Rs. 943.00 lakhs. Later administrative approval was accorded

to the re-revised estimate cost of Rs. 569.00 crores.

For speedy implementation, the Project was transferred to Karnataka Neeravari Nigam Ltd. Vide G.O. No.

WRD 1 MMM 2003, Bangalore dated 6-11-2003.

VARAHI DIVERSION WEIR:

A concrete diversion weir 145 meters long and 17.50 meters high above the deepest foundation level is

proposed to be constructed at Horriabbe site near Siddapura Village, Udupi District. Administrative approval

for the Construction of Diversion Weir has been accorded by the Government of Karnataka vide G.O.No. WRD

30 MMM 2001 dated 3-2-2003 for Rs. 2900.00 lakhs and technical sanction has been accorded on 27-2-2003.

Due to Construction of Diversion Weir, 121.58 Ha. of land will be submerged along with two villages which

will be submerged partially. Works are entrusted on tender basis and are under progress.

Page 82: Annual Report 2008-09 ENG

82

CANALS:

Varahi Right Bank Canal takes off from the Dam and runs for a length of 42.8 Km. A branch canal

takes off from Right Bank Canal at Km 19 and crosses the River Varahi through an aqueduct. The Left Bank

Canal takes off from this aqueduct and runs for a length of 44.35 Km. The Lift Canal takes off from the Left

Bank Canal at Km 7 and runs for a length of 33 Km.

The proposed atchkat to be covered in Udupi District is as detailed below:

Sl.

No Canal details Length, Km Irrigable area,

Ha

1 Varahi Right Bank Canal 42.80 1992

2. Varahi left bank canal

(From off-take at 20th Km of Right Bank Canal) 44.350 10987

3 Lift canal (From off-take at 7th Km of Left Bank Canal) 33.00 2723

Total 15702

Villages benefited:

1 Kundapura Taluk 33 villages 8324

2 Udupi Taluk 35 villages 7378

Total 68 villages 15702

This project is received central assistance under AIBP since 2007-08.

PROGRESS DURING 2008-09:

The total estimated cost of the project is Rs. 569.53 Crores. Cumulative expenditure incurred on the

project up to end of March 2009 is Rs. 273.02 Crores.

During 2008-09, against the programme of Rs. 10100.00 lakhs, expenditure of Rs. 6502.81 lakhs has

been incurred up to end of March 2009.

The Varahi Left bank works from 0 to 21 Km are nearing completion further 22 to 30 Km works are started

Tender for Construction of Aqueduct across Varahi river connecting Varahi Right bank Canal and Varahi

Left Bank Canal is under progress. Works of Varahi right bank canal from Km. 0 to 8.40 is under progress.

Works from Km. 8.40 to 14.00 are in the stage of tender approval. The project is proposed to be completed

during 2012.

INDEX

Page 83: Annual Report 2008-09 ENG

83

11.6. AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, IRRIGATION

PROJECTS ZONE, GULBARGA

11.6.1 BENNITHORA PROJECT

Bennithora project is a major irrigation project, which comprises of construction of dam across River

Bennithora near Heroor village, Chittapur taluk, Gulbarga District. There are two canals covering an Irrigable

area of 20,234 Ha in Gulbarga District. The utilisation for the project is 5.75 TMC.

The works of dam embankment and spillway are completed and water is being stored in reservoir since

2001 and works of right bank canal are completed except CD laterals and 2 sub distributories which are under

progress. Works of left bank canal are completed except 4 distributories which are under progress.

The revised estimate cost of this project is 355.00 Crores. Cumulative expenditure upto end of March

2009 is Rs. 332.35 Crores. A dry potential of 19978 Ha has been created to end of 3/2009.

The details of target and achievement of the project for 2007-08 and 2008-09 are as follows:

Sl.

No. Year

Financial (Rs. in Crores) Physical (In hectares)

Target Achievement Target Achievement

1 2007-08 5.00 14.74 1427 1118

2 2008-09 21.00 16.05 309 309

INDEX

Page 84: Annual Report 2008-09 ENG

84

11.6.2 BHIMA LIFT IRRIGATION SCHEME

Bhima Lift Irrigation envisages construction of Earthen Dam with central concrete spillway with crest

gates to discharge 9.00 Lakh Cusecs of water. The Dam site is proposed near Sonna (K) village of Afzalpur

Taluk in Gulbarga District and providing two lift irrigation points to draw water from the Reservoir, for creation

of 24,292 hectares of irrigation Potential.

The Project is administratively approved for Rs. 94.17 Crores by the Government vide Govt. Order No. ID 39

MMM 92, dated 18-4-1992, and technically sanctioned for Rs.107.70 Crores by the Chief Engineer, WRD,

I.P.Zone, Gulbarga vide CER No. 5/93-94 dated13-01-1994. The Revised Estimate costing Rs. 592.50 Crore is

submitted for approval. This project is under Karnataka Neeravari Nigam Ltd., since 1999.

Stage of the project as on March 2009:

I. Earthen Dam:

The length of barrage is 2250 meters including the central over flow section (spillway) of 418 meters

with earthen flanks on either side. The length of left earthen flank is 612 meter and length of right flank is 1183

meter. Both the earthen embankments are completed.

II. Barrage:

The work of construction of the barrage is awarded to M/s G.J. Fernandez, Class-I Contractor on 21-02-

2003 for Rs. 25.93 crores. The total cost for completion is Rs. 46.30 Crores and works are under progress. The

foundation of Barrage is completed including left abutment. The spillway body wall comprises of 30-blocks are

completed (crest level 396.40). All 28 piers are completed. Casting of girders and launching of girders and slabs

are completed. The work of MHS on right flank is in progress. The financial progress achieved up to end of

March-2009 is Rs. 42.52 Crores.

Page 85: Annual Report 2008-09 ENG

85

III. Gates:

The fabrication of 29 Nos. of vertical gates is entrusted to Karnataka State Construction Corporation

and work order is issued on 06-07-2005. The fabrication and erection of embedded parts for service gates, stop

log gates is completed. The financial progress achieved up to end of March-2009 is Rs. 47.10 Crores.

HEAD WORKS:

I. Balundagi Lift:

The construction of Balundagi Lift is entrusted to Kirloskar Brothers Limited for Rs. 12.39 Crores. The

work order is issued on 27-07-2005 and works are under progress.

The excavation of jack well portion is completed and construction of jackwell is nearing completion.

Delivery chamber is completed. Excavation for raising main is completed. Pumps, motors and transformers are

supplied. Erection of pumps and motors are completed. The supply and laying of PSC pipes for rising main is

nearing completion. The financial progress achieved up to end of March-2009 is Rs. 8.50 Crores.

II. Allagi (B) Lift:

The construction of Allagi (B) lift is entrusted to Laxmi Civil Engineering Pvt. Ltd. for Rs. 691.25

Lakhs. The work order is issued on 29.07.005 and works are under progress.

The excavation of jack well portion is completed and construction of jackwell is nearing completion.

Delivery chamber is complete. Excavation for raising main is completed. Pumps, motors and transformers are

supplied. Erection of pumps and motors are completed. The supply and laying of PSC pipes for rising main is

nearing completion. The financial progress achieved up to end of March-2009 is Rs. 4.71 Crores.

The construction of intake channel is taken up and is in progress.

CANALS – Length of Balundagi Lift canal is 61.02 Km. & Allagi Lift Canal is 34.40. Works are under

progress.

Revised estimated cost of the project is Rs.275.53 crores and cumulative expenditure incurred upto end of

March 2009 is Rs.154.03 crores.

During the year 2008-09, budget allocation made is Rs.32.00 crores and expenditure incurred upto March

2009 is Rs.21.23 crores.

The details of target and achievement of the project for 2007-08 and 2008-09 are as follows: -

Sl.

No. Year

Financial (Rs. in Crores) Physical (In hectares)

Target Achievement Target Achievement

1. 2007-08 30.00 29.31 - -

2. 2008-09 32.00 21.23 - -

INDEX

Page 86: Annual Report 2008-09 ENG

86

11.6.3. GANDORINALA PROJECT

Gandorinala project is a medium irrigation project in Gulbarga District. This project envisages

construction of dam near Belkota village in Gulbarga taluk, across River Gandorinala, a tributary to River

Bennithora, which in turn joins River Bhima of Krishna Basin. The utilisation under this project is 1.97 TMC.

The area covered for irrigation under this project is 8094 Hectares.

The project is administratively approved vide Government Order No. ID 110 MTZ 85, Bangalore dated

23.05.1992 for Rs. 66.00 crores. The revised estimate of the project is Rs. 239.00 Crores and

expenditure upto March 2009 is Rs. 209.79 Crores. The dry irrigation potential of 7943 Ha has been created upto

March 2009.

DAM: Earthen dam, embankment and spillway works are completed, and water is stored in the Reservoir.

CANAL:

Main Canal : Total length of Right bank canal is 7 km, which is completed and total length of left bank canal

is 90 km., out of which works in km.0.00 to 23.00 are completed. Works of Km. 24 & 25 are nearing

completion. Works of remaining length are under progress.

Distributary: There are 3 number of Distributary under RBC and works of all the 3 distributaries are

completed. No. of distributaries under LBC is 40, of which works of 17 are completed, 19 are under progress

and 4 are under initial stage.

FIC: Out of contemplated atchkat of 8094 Ha. FIC provided up to end of March 2009 is 4037 Ha. It is

programmed to complete FIC for balance area of 4057 Ha. during 2009-10

The details of target and achievement of the project for 2007-08 and 2008-09 are as follows

Sl. Year Financial (Rs. in Crores) Physical (in hectares)

Page 87: Annual Report 2008-09 ENG

87

No. Target Achievement Target Achievement

1) 2007-08 25.00 15.92 1831 716

2) 2008-09 16.00 17.97 1115 964

INDEX

Page 88: Annual Report 2008-09 ENG

88

11.5.4. LOWER MULLAMARI PROJECT.

Lower Mullamari Project envisages construction of a dam across the River Mullamari a tributary to

River Bhima in Krishna basin. The project is located near Nagaral village in Chincholi Taluk of Gulbarga

District. The utilisation under this project is 2.61 TMC and it is planned to provide irrigation facilities to 9713

Ha. of land in Chincholi taluk.

The project has been originally estimated for Rs. 45.00 crores at 1990-91 schedule of rates. The latest

estimated cost of the project is Rs. 210.00 Crores and expenditure to end of March 2009 is Rs. 174.74 Crores.

DAM: Earthen dam including spillway is completed and water is being stored since August 2001.

CANAL: The total length of Right Bank canal is 80 Kms. And all these works are completed. The improvement

and protection works to right bank canal from Km. 0 to 40 are nearing completion. Strengthening works of main

canal from Km. 40 to 80 are under approval stage. Total number of distributaries are 66, out of which 65 are

completed and Work of remaining 1 distributary is nearing completion.

R & R WORKS: 7 rehabilitation centers are formed, out of which 6 are completed and the villages are shifted.

Work of remaining 1 centre is nearing completion.

The irrigation potential of 9000 Ha has been created up to March 2009 and it is programmed to create

balance irrigation potential of 713 Ha. during 2008-09.

The details of target and achievement during 2007-08 and target during 2008-09 is as under:

Sl.

No. Year

Financial (Rs.in Crores) Physical (in hectares)

Target Achievement Target Achievement

1) 2007-08 5.00 7.47 264 -

2) 2008-09 9.00 7.13 264 1164

INDEX

Page 89: Annual Report 2008-09 ENG

89

11.6.5. AMARJA PROJECT

Amarja irrigation project envisages construction of a dam across the River Amarja, a tributary to River

Bhima in Krishna Basin, near Sangolgi village in Aland Taluk of Gulbarga District with canals on both banks to

provide irrigation facilities to an extent of 8903 Ha. The utilisation proposed under this project is 1.554 TMC.

As per 1975-76 schedules of rates, the original cost of the project is Rs. 5.70 crores. The project was

technically sanctioned for Rs. 82.50 crores by the Chief Engineer, Irrigation Project Zone, Gulbarga vide order

dated 24.07.1992. The present cost of the project is Rs. 214.00 Crores.

DAM: The 960 m long and 31.85 m high earthen dam with a storage capacity of 43.87 Mcum will submerge

641 ha of land, affecting 3 villages and a population of 4,500. Dam works are completed and water is being

stored since 2001.

CANALS: The 54.784 Km long Left Bank Canal and the 42.48 Km long Right Bank Canal will irrigate 4,856

Ha. and 4,047 Ha. of land, respectively. The total length of right bank canal is 42.48 kms. and left bank Canal is

54.784 kms. Total number of distributaries under RBC are 29 Nos. and 20 Nos. and under LBC are 33 Nos. &

19 Nos. are respectively.

The work for the rectification of existing canal system comprising of main canal and distributaries

including construction of new FIC‟s from Km.0.00 to 7.00 of RBC of Amarja project for Rs. 538.30 Lakhs is

under progress. Further works from Km.7 to 20 is withdrawn from KLAC and fresh tenders are called for;

tenders accepted and works is entrusted to Venkob Yadav; works are under progress. Works from 20 to 42.48

kms is entrusted on tender basis for Rs. 26.00 crores, and works are under progress.

The work for the rectification of existing canal system comprising of main canal and

distributaries including construction of new FIC‟s from Km.0.00 to 30.00 of LBC of Amarja project is entrusted

on tender basis for Rs. 35.00 crores and work is in progress.

Page 90: Annual Report 2008-09 ENG

90

The details of the target and achievement of the project for 2007-08 and 2008-09 is as follows:

Sl.

No. Year

Financial (Rs. in Crores) Physical (in hectares)

Target Achievement Target Achievement

1) 2007-08 10.00 11.43 2000 350

2) 2008-09 13.00 11.04 1650 850

INDEX

Page 91: Annual Report 2008-09 ENG

91

PROJECTS UNDER

CAUVERY NEERAVARI NIGAM LIMITED

Page 92: Annual Report 2008-09 ENG

92

12 CAUVERY NEERAVARI NIGAMA LIMITED

12.1 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, IRRIGATION (S) ZONE,

MYSORE

The Cauvery Neeravari Nigama Limited (CNNL) is established by the Government of Karnataka in

03.06.2003 under Company Act 1956 as a special purpose to accelerate the implimentation of Cauvery Basin

Projects in Karnataka. The Cauvery basin in Karnataka is 34,273 Sq.Kms which constitutes about 17.99% of the

geographical area of 1,91,791Sq.Km in Karnataka Major Rivers flowing in this basin are Harangi (50 KM),

Hemavathy (245 KM), Lakshmanatheertha (131 KM), Kabini (230 KM), Shimsha (221 KM), Suvarnvathi (88

KM), Arkavathy (161 KM) and the main river Cauvery (381 KM). The Cauvery Basin has spread in 11 districts.

Main Objective of the CNNL are: to complete the works of the ongoing Irrigation projects including

Lift Irrigation works, and such works of Minor Irrigation and CADA (Command Area Development Authority).

Also to maintain, operate, improve or modernize the irrigation projects including Lift Irrigation works and such

works of Minor Irrigation and CADA in the Cauvery Basin entrusted to it by the Government of Karnataka.

Three zones viz., Irrigation (S) zone, Mysore, Hemavathy Canal Zone, Tumkur and Hemavathy Project

Zone, Gorur are coming under the jurisdiction of CNNL. The details of on going projects coming under

each zone are as below:

Sl.

No Name of the Project

A Irrigation (S), Mysore.

1 D.D. Urs Canal

2 Kabini Project

3 Harangi Project

4 Taraka Project

5 Arkavathy

6 Chiklihole Project

7 Uduthorehalla Project

8 Iggalur Project

9 Manchanabele Project

10 K.R.S. Modernisation

11 Nanjapura LIS

12 Bannahallyhundi LIS

B. Hemavathy Canal Zone, Tumkur

13 Hemavathy Canal Project

C Hemavathy Project Zone, Gorur

14 Hemavathy Project

15 Yagachi Project

16 Huchanakoppalu LIS

17 Kamasamudra LIS

18 Kachenahally LIS

19 Votehole Project

Page 93: Annual Report 2008-09 ENG

93

12.1. 1. D.DEVARAJA URS CANAL

D. Devaraja Urs Canal project envisages construction of 126 km long Right Bank Canal from

Krishnarajasagar reservoir. Administrative approval has been accorded to the Original estimate amounting to

Rs.18.50 Crores. vide G.O. No.PWD/145/MKS/77, dtd: 23.04.1979. The work was started during 1979.

Administrative approval has been accorded to the revised estimate amounting to Rs.58.10 Crores. vide G.O.

No.PWD/145/MMR/86 dtd: 08.08.1988.

The planned utilization from this project is 10.5 TMC to create an ultimate potential of 80000 acres

(32375 ha.) with a cropping area of Khariff semidry 80000 acres and Rabi semidry 59500 acres totalling to

139500 acres. The taluks benefited by this project are Nanjangud, T. Narasipur & H.D. Kote of Mysore district

and Srirangapatna taluk of Mandya district.

The main canal work has been completed upto 126 km and the work of distributaries completed in all

respects. The water allowed upto the tail end on trail basis.

The total irrigation potential created is / 78432 acres (31741 ha.) as against the contemplated potential of

80000 acres (32375 ha.) A balance potential of 1568 acres (634 ha.) has not been created due to Urban

and industrial development and high mounds.

During 2008-09, a grant of Rs.5.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.12.14 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2008 is

Rs.449.64 Crores.

INDEX

Page 94: Annual Report 2008-09 ENG

94

12.1.2. KABINI RESERVOIR PROJECT

This project envisages the construction of a composite dam across kabini River near Beechanahally

village in H.D. Kote Taluk of Mysore District. Administrative approval has been accorded to the Original

estimate amounting to Rs.3.20 Crores. vide G.O. No. PWD/1/KRS/57 dated: 02.02.1959. The work was started

during 1960. Administrative approval has been accorded to the revised estimate amounting to Rs.390.00 Crores.

vide G.O. No.PWD/22/MMR/86 dtd: 24.02.1986

This project comprises of both flow and lift irrigation schemes. The planned utilization is 59.65 TMC

which comprises of 32.350 TMC in flow and 27.300 TMC in lift to create the ultimate potential of 233347 acres

(94434 ha.), which comprises of 110000 acres (44516 ha.) in flow and 123347 acres (49918 ha.) in Lift. The

taluks benefited by this project are H.D.Kote, Nanjangudu and T. Narasipura of Mysore District and Gundlupet,

Chamarajanagara, Yalandhuru and Kollegala of Chamarajanagara District.

FLOW: The Dam and allied works are completed. The Length of LBC is 26 Km. and of RBC is 202 Km. and

the potential to be created is 3000 acres (1214 ha.) and 107000 acres (43302 ha.) respectively.

The works of entire length of 26 Km. of LBC are completed. The works of entire length of 202 Km. of

RBC are completed. The lining works in vulnerable reaches to a length of 67 Km are completed. The C.C. lining

works of KRBC from Ch: 0.00 to 40.00 Km are in progress.

Page 95: Annual Report 2008-09 ENG

95

The total irrigation potential created under flow from this project since inception to the end of March

2009 is 109273 acres (44222 ha.) as against the contemplated potential of 110000 acres (44516 ha.) under flow.

A balance potential of 727 acres (294 ha.) has not been created due to mounds and village limits.

During 2008-09, a grant of Rs.40.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.17.02 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is

Rs.578.82 Crores.

LIFT IRRIGATION SCHEME: Survey works of Kabini Lift irrigation scheme are completed.

INDEX

Page 96: Annual Report 2008-09 ENG

96

12.1.3 HARANGI PROJECT

This project envisages the construction of a composite dam across Harangi River near Hulugunda village

in Somawarpet Taluk of Kodagu District. Administrative approval has been accorded to the Original estimate

amounting to Rs.11.00 Crores. vide G.O. No.PWD/02/GHK/63 dtd: 14.11.1969. The work was started during

1964. Administrative approval has been accorded to the revised estimate amounting to Rs.230.00 Crores. vide

G.O. No.PWD/23/MMH/91 dtd: 19.06.1992. Further, Administrative approval has been accorded to the Re-

revised estimate amounting to Rs.545.00 Crores. vide G.O. No.PWD/14/MMH/2007 dtd: 30.07.2007.

This project comprises of both flow and lift irrigation schemes. The planned utilization is 18.00 TMC

which includes of 11.38 TMC in flow and 6.62 TMC in lift to create. The details of ultimate potential to be

created are as below.

Type Canals Length of

Canal in Km.

Ultimate Potential to be

created in acres (ha.)

Flow

1 LBC 153.00 29472 (11927)

2 RBC 138.50 71323 (28863)

3 MI tanks - 2600 (1053)

Lift

1 Somwarapet LIS 10.00 1500 (607)

2 Periyapatana LIS 50.00 30000 (12141)

Total 134895 (54591)

Page 97: Annual Report 2008-09 ENG

97

The taluks benefited by this project are Hunsur, K.R. Nagara, Periyapatna of Mysore District :

Arkalgudu of Hassan District and Somawarpet of Kodagu District.

It was proposed to create an irrigation potential of 30000 acres (12141 ha) under Periyapatna LIS, 1500

acres (607 ha) under Somwarpet lift irrigation scheme and 2600 acres (1,053 ha) under Minor Irrigation. The

total potential created after the completion of these schemes is 134895 acres (54,591 ha).

FLOW: The Dam and allied works are completed. The works of entire length of 153 Km. of LBC are completed

and the works of entire length of 138.5 Km. of RBC are completed.

LIFT IRRIGATION SCHEMES: Somawarpete LIS and Piriyapatana LIS are coming under this project.

1. Somawarpete LIS: it is proposed to lift 0.800 TMC of water at 12.20 Km of LBC to create a potential of

1500 acres (607 ha.).

The head works including 10 Km long canal works are completed and commissioned.

2. Periyapatana LIS: It is proposed to lift 324.00 Cusecs of water from Karadilakkanakere tank to create a

potential of 30000 acres (12141 ha.). The utilization under this scheme is 5.82 TMC.

The head works and alied works are completed. The total length of the canal is 50 Km and the canal

works are completed. The works of Distributory 1 to 37 excluding D-16, D-17 (A) and D-26 (A) are almost

completed. The Earth work excavation and CD works of distributary 38 are nearing completion.

The total irrigation potential created including flow and lift under this project since inception to the end of

March 2009 is 131934 acres (53393 ha.) as against the contemplated potential of 134895 acres (54591 ha.). A

potential of 1891 acres (765 ha.) has not been created due to Mounds and village limits. A Balance potential of

1070 acres (433 ha.) under Periyapatana LIS is programmed to be created during 2009-10.

During 2008-09, a grant of Rs.35.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.36.12 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is

Rs.528.52 Crores.

Page 98: Annual Report 2008-09 ENG

98

12.1.4 TARAKA

This project envisages the construction of a composite dam across Taraka River near Penjahally village in

H.D. Kote Taluk of Mysore District. Administrative approval has been accorded to the Original estimate

amounting to Rs.1.70 Crores. vide G.O. No.PWD/23/GIP/67 dtd: 12.04.1970. The work was started during 1970.

Administrative approval has been accorded to the Revised estimate amounting to Rs.51.00 Crores. vide G.O.

No.PWD/36/MMF dtd: 15.04.1996.

The planned utilization from this project is 3.94 TMC to create an ultimate potential of 17396 acres

(7040 ha.). H.D. Kote taluk of Mysore District is benefited by this project.

The Dam and allied works are completed. The Length of LBC is 50 Km. and of RBC is 38.50 Km. and

the potential to be created is 6000 acres (2428 ha.) and 11400 acres (4612 ha.) respectively. To augument

the short supplies in the reservoir, lifiting of 2.04 TMC water from foreshore of Kabini is done through Taraka

Lift irrigation Scheme which is completed and trail run has been conducted.

The total irrigation potential created under this project since inception to the end of March 2009 is

17396 acres (7040 ha.).

During 2008-09, a grant of Rs.1.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.2.16 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs.59.26

Crores.

INDEX

Page 99: Annual Report 2008-09 ENG

99

12.1.5. ARKAVATHY PROJECT

This project envisages the construction of a composite dam across Arkavathy River a tributary to River

Cauvery near Arobele village in Kanakapura Taluk of Ramanagara District. Administrative approval has been

accorded to the Original estimate amounting to Rs.22.25 Crores. vide G.O. No.PWD/126/MMK/83 dtd:

27.06.1984. The work was started during 1983-84.

This project comprises of both flow and lift irrigation schemes. The total planned utilization from flow

and lift is 3.10 TMC.The planned potential to be creatrd is 15400 acres (6232 Ha) which includes 7500 acres

(3035 Ha) in Flow and 7900 acres (3197 Ha) in Lift. Kanakapura taluk of Ramanagara District is benefited by

this project.

FLOW: The Dam and allied works are completed. The Length of LBC is 23 Km. and of RBC is 22 Km. and the

potential to be created is 4500 acres (1821 ha) and 3000 acres (1214 Ha) respectively totaling to 7500 acres

(3035 Ha). The works for entire length of 23 Km of LBC and 22 Km of RBC are completed. Potential creatrd is

7490 acres(3031 Ha).

LIFT IRRIGATION SCHEMES: Arkavathy LBLC LIS and Arkavathy RBLC LIS are coming under this

project.

1. Arkavathy LBLC, it is proposed to lift 32.98 Cusecs of water on the foreshore of the Arkavathy reservoir

to create a potential of 3600 acres (1457 Ha) Kanakapura Taluk of Ramanagara District is benefited by this

Page 100: Annual Report 2008-09 ENG

100

project. The head works and lift canals are completed. The total length of LBLC is 21 Km. The canal works

from 0.00 Km to 10.00 Km are completed and the worksof 10.00 Km to 21.00 Km are in progress.

2. Arkavathy RBLC, it is proposed to lift 39.98 Cusecs of water on the foreshore of the Arkavathy reservoir

to create a potential of 4300 acres (1740 Ha) Kanakapura Taluk of Ramanagara District is benefited by this

project.

The total length of the RBLC is 34 Km. From 0.00 to 22.00 Km the canal works are in different stages

of progress. The process of land aquisition is in progress from 23rd Km to 32th Km. The canal from 29.00 to 30.6

Km and from 31.7 Km to 34.475 Km are coming in the forest area. The works for head works, Jack well, process

of VT Pump, Rising main, supply and erection of transformer are under tendering progress.

The total irrigation potential created under this project since inception to the end of March 2009 is 9535

acres, (3859 Ha) from flow as against the total contemplated potential of 15400 acres (6232 Ha) A balance

potential of 5865 acres (2373 Ha) is programmed to be completed during 2009-10.

During 2008-09, a grant of Rs.20.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.11.35 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is

Rs.150.70 Crores.

INDEX

Page 101: Annual Report 2008-09 ENG

101

12.1.6. CHIKLIHOLE PROJECT

This project envisages the construction of a composite dam across Chiklihole River, a tributary of River

Cauvery near Rangasamudra village in Somawarpet Taluk of Kodagu District. Administrative approval has been

accorded to the Original estimate amounting to Rs.3.40 Crores. vide G.O. No.PWD/25/GIP/71 dtd26.08.1977.

The work was started during 1978. Administrative approval has been accorded to the revised estimate amounting

to Rs.19.20 Crores.

The planned utilization from this project is 0.45 TMC to create an ultimate potential of (2137 acres) 865

ha. Somawarapet taluk of Kodagu District is benefited by this project.

The Dam and allied works are completed.

The works of new LBC for a length of 29 Km are completed including CD works.

The total irrigation potential created under this project since inception to the end of March 2007 is 2138

acres (865 ha.)

The cumulative expenditure incurred since inception upto end of 3/2007 is Rs. 19.20

Crores.

INDEX

Page 102: Annual Report 2008-09 ENG

102

12.1.7. UDUTHOREHALLA PROJECT

This project envisages the construction of a composite dam across Uduthorehalla River near Ajjipura

village in Kollegal Taluk of Chamarajanagara District. Administrative approval has been accorded to the

Original estimate amounting to Rs.7.55 Crores. vide G.O. No.PWD/60/GIP/71 dtd: 30.11.1979. The work was

started during 1979. Administrative approval has been accorded to the revised estimate amounting to Rs.32.30

Crores. vide G.O. No.PWD/134/MMK/85 dtd: 25.11.1985.

The planned utilization from this project is 1.23 TMC to create an ultimate potential of 16314 acres

(6602 ha.). Kollegala taluk of Chamarajanagara District is benefited by this project.

The Dam and allied works are completed. The Length of LBC is 10.20 Km. and of RBC is 9.10 Km.

and the potential to be created is 6200 acres (2509 ha.) and 10114 acres (4093 ha.) respectively.

The works of entire length of LBC and RBC are completed.

The total irrigation potential created under this project since inception to the end of March 2009 is

15352 acres (6213 ha.) as against the contemplated potential of 16314 acres (6602 ha.). A balance potential of

962 acres (389 ha.) has not been created due to hillocks and villages.

During 2008-09, a grant of Rs.5.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.4.88 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs.225.70

Crores.

Page 103: Annual Report 2008-09 ENG

103

12.1.8. IGGALUR BARRAGE PROJECT

This project envisages the construction of a Barrage across Shimsha River near Iggalur village in

Channapattana Taluk of Ramanagara District. Administrative approval has been accorded to the Original

estimate amounting to Rs.3.42 Crores. vide G.O. No.PWD/17/GIP/71 dtd: 06.12.1977. The work was started

during 1977. Administrative approval has been accorded to the revised estimate amounting to Rs.10.75 Crores.

vide G.O. No.PWD/33/MMH/86/ dtd: 23.12.1986.

This project comprises of both flow and lift irrigation schemes. The planned utilization is 1.80 TMC.

The ultimate potential to be created is 10532 acres (4263 ha.) which comprises of 3650 acres (1477 ha.) in flow

and 6882 acres (2786 ha.) in Lift. The taluks benefited by this project are Channapatana of Ramanagara District

: Maddur and Malavally of Mandya District.

FLOW: The Barrage and flow works are completed. The Length of LBC is 35 Km. and the works for the entire

length of LBC is completed. The potential created is 3650 acres (1477 ha.)

LIFT IRRIGATION SCHEMES: 8 No. of LIS schemes are coming under this project. Out of this 5 LIS Viz.,

Point A, Point C, Point C-2, Point D and Hulikere LIS are used for lifting water on the foreshore to irrigate 6882

acres (2786 ha.).

Page 104: Annual Report 2008-09 ENG

104

In balance of 3 LIS Viz., Point B LIS is used to provide water to the atchkat of point –A where as Nittur

LIS and Garkahalli LIS are for tank feeding.

The details of 5 LIS used for irrigation pupose are as under:

Sl.

No. Name of LIS

Ultimate Potential to

be created in acres.

(ha)

Potential created

in acres. (ha)

1 Point A 2243 (908) 2204 (892)

2 Point C 1255 (508) 1255 (508)

3 Point C-2 1000 (405) 1000 (405)

4 Point D 1890 (765) 1890 (765)

5 Hulikere 494 (200) 371 (150)

Total 6882 (2786) 6719 (2719)

In LIFT Components: Point A, C, C-2, D LIS are completed. Potential Created is 6719 acres (2719 ha.)

The total irrigation potential created including flow and lift under this project since inception to the end

of March 2009 is 10368 acres (4196 ha.). The balance potential of 164 acre (66 ha.) has not been created due to

Mounts and village limits.

During 2008-09, a grant of Rs.5.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.2.31 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs.79.35

Crores.

INDEX

Page 105: Annual Report 2008-09 ENG

105

12.1.9. MANCHANABELE PROJECT

This project envisages the construction of a composite dam across Arkavathy River near Manchanabele

village in Magadi Taluk of Ramanagara District. Administrative approval has been accorded to the Original

estimate amounting to Rs.2.37 Crores vide G.O.No. PWD/12/GIP/64 dated: 30.09.1969. The work was started

during 1969. Administrative approval has been accorded to the Revised estimate amounting to Rs.5.00 Crores

vide G.O.No. PWD/28/GIP/71, dated: 05.01.77. Administrative approval has been accorded to the Re-Revised

estimate amounting to Rs.18.50 Crores vide G.O.No. PWD/14/MMK, dated: 25.08.86.

The planned utilization from this project is 0.80 TMC to create an ultimate potential of 6012 acres

(2433 ha.). The taluks benefited by this project are Magadi and Ramanagara of Ramanagara District.

The Dam and allied works are completed. The Length of LBC is 35.00 Km. and of RBC is 36.00 Km.

and the potential to be created from these canals are 2768 acres (1120 ha.) and 3244 acres (1313 ha.)

respectively.

The works for the entire length of LBC and RBC are completed. The project is physically completed.

The total irrigation potential created under this project since inception to the end of March 2009 is 6009

acres (2432 ha.).

During 2008-09, a grant of Rs.0.10 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.0.63 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs.84.93

Crores.

INDEX

Page 106: Annual Report 2008-09 ENG

106

12.1.10 KRS MODERNISATION

The Krishnarajasagar Reservoir is constructed across the River Cauvery near Kannambaadi village in

Srirangapattana Taluk of Mandya District, with Canals on both the flanks for providing irrigation to an extent of

196000 acres (79312 Hectares) to Mandya and Mysore District. The Left Bank High Level Canal, which is

named as Vishweshvaraya Canal was originally proposed for providing Irrigation to an extent of 120000 Acres

(48,564 Hectares). However, due to various factors like construction of pickup channels, lowering of local

mounds in the command area, subsequent extension of certain branch canals etc., there has been considerable

increase in the command area of Vishweshvaraya Canal. This has resulted in increased withdrawal in various

branches, causing a strain on the canal system.

Due to this the supply of water to the atchkat in the tail end reaches was inadequate. The condition of the

existing canal does not lend itself to higher discharges being drawn. Also two major Aqueducts along the canal

were not able to carry discharges beyond 67 Cumecs (2366 Cusecs). In order to limit the excess utilisation of

water in the atchkat it was programmed to modernise the Vishweshvaraya Canal and also to create fresh atchkat

of 5250 Acres (2125 Hectares).

Administrative approval has been accorded to the Original estimate amounting to Rs.14.80 Crores. The

work was started during 1987. Administrative approval has been accorded to the Revised estimate amounting to

Rs.55.00 Crores vide G.O.No. PWD/13/MMG/86, dated: 06.03.1987.

Modernization works are completed. The total additional irrigation potential created under this project

since inception to the end of March 2009 is 5250acres (2125 Ha.).

During 2008-09, a grant of Rs. 5.00 Crores has been allocated. Upto end of 3/2009, an expenditure of

Rs.6.11 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs. 420.13

Crores.

Page 107: Annual Report 2008-09 ENG

107

12.1.11. NANJAPURA LIFT IRRIGATION SCHEME

This project envisages to lift 119 Cusecs of water from Cauvery River near Nanjapura village in

T.Narasipura taluk (Bannur Town) of Mysore District to feed Turuganur Branch of Vishveshwaraia Canal.

Administrative approval has been accorded to the Original estimate amounting to Rs.28.00 Crores. vide G.O.

No.PWD/197/MMK/1996 dtd: 27.05.1997. The work was started during 1997. Administrative approval has been

accorded to the Revised estimate amounting to Rs.31.60 Crores. and technically sanctioned vide CER

No:119/1998-99.

The ultimate potential to be created is 10000 acres (4049 ha.) which comprises of the (New Potential

Created is 8000 acres (3239 ha.) and Suffering atchkat of 2000 acres (810 ha.)) The taluks benefited by this

project are T.Narsipura of Mysore District and Mallavali of Mandya District.

The scheme is completed in all respects. This Scheme is commissioned during March 2009.

The total irrigation potential created under this project since inception to the end of March 2009 is 10000

acres (4049 ha.) as against the contemplated potential of 10000 acres (4049 ha.).

During 2008-09, a grant of Rs.5.00 Crores has been allocated. Upto end of 3/2009, an expenditure of

Rs.4.03 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs.55.23

Crores.

INDEX

Page 108: Annual Report 2008-09 ENG

108

12.1.12. BANNAHALLYHUNDI LIS

This project envisages to lift 0.50 TMC of water from Right Bank of Kabini River near Tayur Village in

Nanjangudu Taluk of Mysore District. Administrative approval has been accorded to the Original estimate

amounting to Rs.16.25 Crores. vide G.O. No.ID 272/MMK/97 dtd: 2.02.2001. The work was started during

2000-01.

The ultimate potential to be created is 4384 acres (1774 ha.). The taluks benefited by this project are

T.Narasipura of Mysore District and Chamarajanagara of Chamarajanagara District.

The works for Ridge Cistern, secondary Cistern and feeder Canal are completed. The works for pump

house, intake channel, forebay, Raising main and inlet canal are completed. The total length of canal is 14.86

Km. The Canal works are almost completed. This project is physical completed.

The total irrigation potential created under this project since inception to the end of Mar 2009 is 4384

acres (1774 ha.) as against the contemplated potential of 4384 acres (1774 ha.).

During 2008-09, a grant of Rs.15.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.5.66 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs.13.94

Crores.

INDEX

Page 109: Annual Report 2008-09 ENG

109

12.2 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER,

HEMAVATHY CANAL ZONE, TUMKUR

12.2.1 HEMAVATHY CANAL ZONE, TUMKUR

Hemavathy Canal Zone, Tumkur, was formed as per Government order No. PWD 11 PCO 87 Bangalore,

dated 14-1-1987, for execution of canal works in Tumkur, Mandya and Hassan Districts and is functioning since

23-04-1987.This is a part of Hemavathy project for the execution of canal works viz., Y-Alignment, Tumkur

Branch canal, Nagamangala Branch Canal and Lift irrigation scheme at the exit of Baggur – Navile tunnel and

providing water supply to Tumkur and Tiptur town from Hemavathy left Bank Canal. Administrative approval

has been accorded to the Original estimate amounting to Rs.16.30 Crores. vide G.O. No.PWD/1/GKH/63 dtd:

18.09.1967 for Hemavathy Project. The work was started during 1967. Administrative approval has been

accorded to the Revised estimate amounting to Rs.3877.00 Crores. vide G.O. No.WRD/46/NHP/2007 dtd:

30.07.2007. This amount comprises of Rs.1751.00 crores towards Hemavathy Project Zone- Gorur and Rs.

2126.00 crores towards Hemavathy Canal Zone, Tumkur.

Page 110: Annual Report 2008-09 ENG

110

The canal details are as under :

Sl.

No. Canal Details

Total

length in

Km.

Ultimate

Potential to be

created in

acres (Ha)

Planned

utilization in

TMC /

Remarks

Taluks Benefited

a) „Y‟ -Alignment. 5.50 Km - -

b) Tumkur Branch Canal. 240.00

Km

236990

(95,909)

18.07

Turuvekere, Tiptur, Gubbi,

Tumkur, Kunigal of Tumkur

Distrcit

c) Nagamangala Branch Canal. 78.325

Km

146994

(59,488) 11.19

Turuvekere, Tiptur, Gubbi,

Kunigal of Tumkur Distrcitl

& Nagamangala in Mandya

District

d) Lift Irrigation Scheme at the exit of

Bagur – Navile Tunnel

13.97

(RBC)

16.25 (LBC)

5828

(2,358) 0.29

C.R. Patna, in Hassan District

and Tiputur taluk in Tumkur

District

e) Providing Water Supply to Tumkur &

Tiptur Town. - - 1.44.

Total 389812

(1,57,755) 30.99

FLOW:

Y- alignment: The total length of Y alignment is 5.50 Km. Earth work and CD works completed. 2.80 Km

lining works are completed.

Tumkur Branch Canal (0-240 Km):

The total Length of Tumkur Branch Canal is 240 Km and the potential to be created is 236990 acres

(95909 ha). Out of this 240 Km., the canal alignment has been approved 200 Km. The earth work excavation &

C.D.works are completed upto 187 Km and the earth work excavation from 188Km to 194Km is under progress.

The lining works of main canal for about 175 Km is completed and further lining works are under progress.

There are 44 Distributaries. Out of which, the works of 9 Distributaries are completed and the works of

24 Distributaries are almost completed. The Distributary works from 23 to 27A (8 Nos.) are under different

stages of progress. The works of remaining 3 distributaries are yet to be started.

Page 111: Annual Report 2008-09 ENG

111

NAGAMANGALA BRANCH CANAL (0 TO 78.325 Km)

The total Length of Nagamangala Branch Canal is 78.325 Km and the potential to be created is 146994

acres (59488 ha). Out of this 78.325 Km., the earth work excavation & CD works are completed for the entire

length of 78.325 Km. except for aqueduct in KM 65 & 66 which is near in completion. The lining works of

main canal for about 29.40 KM is completed.

There are 22 Distributaries. Out of which, works of Distributary 1 to 14 (16 Nos.) are completed. The

works of Distributary 15 to 20 (6 Nos.) are under different stages of progress.

LIFT IRRIGATION SCHEME AT EXIT OF BAGUR – NAVILE TUNNEL:

It is proposed to lift 0.345 TMC of water to create a potential of 5828 acres (2358 ha.) from Y-

alignment canal at exit of Bagur- Navile tunnel near Navile village in C.R. Patna Taluk of Hassan District. The

Taluks benefited are Tiptur of Tumkur district and C.R. Patna of Hassan District.

The work of raising main, distribution chamber and jack well cum pump house are completed and this

scheme has been commissioned during February –2004.

The total length of LBC is 13.97 Km. and the works for entire length is completed. The total length of

RBC is 16.25 Km. out of which upto 9 Km. the works are completed. The works from 9 Km to 16.25 Km are

under progress and the balance works are programmed to be completed during 2009-10.

The total irrigation potential created including flow and lift under this project since inception to the end

of March 2009 is 290241 acres (117459 ha.) as against the contemplated potential of 389812 acres (157755 ha.)

and a potential of 5221 acres (2113 ha.) is programmed to be created during 2009-10.

During 2008-09, a grant of Rs. 100.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.79.92 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is

Rs.1240.75 Crores.

INDEX

Page 112: Annual Report 2008-09 ENG

112

12.3 AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER,

HEMAVATHY RESERVOIR PROJECT, GORUR

12.3.1 HEMAVATHY PROJECT – GORUR

This project envisages the construction of a composite dam across Hemavathy River near Gorur village in

Hassan taluk of Hassan District. Administrative approval has been accorded to the Original estimate amounting

to Rs.16.30 Crores. vide G.O. No.PWD/1/GKH/63 dtd: 18.09.1967. The work was started during 1967.

Administrative approval has been accorded to the revised estimate amounting to Rs.3877.00 Crores. vide G.O.

No.WRD/46/NHP/2007 dtd: 30.07.2007. This amount comprises of Rs.1751.00 crores towards Hemavathy

Project Zone- Gorur and Rs. 2126.00 crores towards Hemavathy Canal Zone, Tumkur.

The planned utilization from this project is 56.67 TMC which includes the planned utilization of 30.99

TMC to Hemavathy Canal Zone, Tumkur. The balance planned utilisation available to Gorur Zone is 25.68

TMC. The ultimate potential to be created under this project are 310943 acres (125837 ha.) which comprises of

271000 acres (109672 ha.) under flow and 39743 acres (16165 ha.) under lift. The taluks benefited by this

project are Hassan, Alur, Arkalagud, Holenarsipura, Channarayapatna of Hassan District : Mandya, K.R.Pet,

Pandavapura, Nagamangala of Mandya District : K.R.Nagara of Mysore District and Somwarapete of Kodagu

District.

The Dam and allied works are completed.

Page 113: Annual Report 2008-09 ENG

113

FLOW:

The Details of Canals coming under this project are as below.

Sl.

No. Name of the Canal Length

Atchkat in Acres

(Hectares)

1 Hemavathy Left Bank Canal 214 Km. 195000 ( 78,915)

2 Hemavathy Right Bank Canal 91 Km

(Full length) 20000 (8,094)

3 Hemavathy Right Bank High Level Canal

106 Km (Full length)

56000 (22,663)

Sub-Total 2,71,000 (1,09,672)

4 LIS Schemes - 39,943 (16,179)

Total - 3,10,943 (1,25,837)

Out of 214 Km of Left Bank Canal, Earthwork excavation & C.D. works upto 212 Km are completed.

Works of all distributories are completed. The lining work is under progress.

Out of 91 Km of Right Bank Canal, Earthwork excavation & C.D. works upto 91 km are completed. The

lining work is under progress.

Out of 106 Km of Right Bank High level Canal, Earthwork excavation, C.D.works and distributaries to a

length 96 km are completed. Lining works for bed upto a length of 60 km bed and lining for sides to a length

upto 50 km are completed.

Out of the 14 LIS, 3 Lift Irrigation Schemes Viz., Ganjigere, Ramenahalli, and BNT Approach are

commissioned. LIS at the exit of Bagur-Navile tunnel has been taken up under Hemavathy Canal Zone-Tumkur.

Balance 10 LIS are in different stages of progress.

The total irrigation potential created is 307104 acres (124283 ha.) from flow and lift as against the

contemplated potential of 310943 acres (125837 ha.) It is programmed to complete all the balance works

including LIS schemes by the end of 2010-11.

During 2008-09, a grant of Rs.60.00 Crores has been allocated. Upto end of 3/2009, an expenditure of

Rs.90.41 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is

Rs.1482.64 Crores.

INDEX

Page 114: Annual Report 2008-09 ENG

114

12.3.2. YAGACHI PROJECT

This project envisages the construction of a composite dam across Yagachi River a tributary of

Hemavathy near Chikkabyadagere village in Belur Taluk of Hassan District. Administrative approval has been

accorded to the Original estimate amounting to Rs.35.38 Crores. vide G.O. No.PWD/91/NHP/83 dtd:

27.06.1984. The work was started during 1984-85. Administrative approval has been accorded to the revised

estimate amounting to Rs.440.00 Crores. vide G.O. No.WRD/40/NHP/2007 dtd: 30.07.2007.

The planned utilisation from this project is 5.74 TMC to creat an ultimate potential of 37000 acres

(14973 ha.).

The details of canals coming under this project are as under:

Sl.

No. Name of the Canal

Length in

Km

Potential to be created

in acres(Ha)

1 Yagachi Left Bank Canal 100 29085 (11832)

2 Mosale Branch Canal 10 2500 (950)

3 Kamasamudra Branch Canal 35 5415 (2191)

Total 37000 (14973)

The taluks benefited by this project are Hassan, Belur and Alur of Hassan District.

Flow: The Dam and allied works are completed

Out of 100 Km. in YLBC, the works of Earth work excavation are completed upto 82.5 Km. and EWE

from 83rd Km to 100.00 Km is under progress. The CD works upto 83rd Km are completed except for the

aqueduct work in 61 - 64Km which is under progress. The lining works are completed upto 24th Km and lining

works in other reachs are in progress. Out of 61 Distributaries D1 to D33 are completed. The works of balance of

28 distributaries are in different stages of progress.

Works of Mosale Branch Canal and Kamasamudra Branch Canal at the exit of the tunnel is yet to be

started. The tunnel work is under progress.

The irrigation potential created under this project since inception to the end of March 2009 is 7528

acres (3047 Ha) as against the total contemplated potential of 37000 acres (14973 Ha) A potential of 19029 acres

(7701 Ha) is programmed to be created during 2009-10.

During 2008-09, a grant of Rs.35.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.18.68 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is

Rs.262.50 Crores.

INDEX

Page 115: Annual Report 2008-09 ENG

115

12.3.3. HUCHANAKOPPALU LIS

This project envisages to lift 0.936 TMC of water in II stages from Hemavathy River near

Huchanakoppalu Village in Holenarasipura taluk of Hassan District. Administrative approval has been accorded

to the Original estimate amounting to Rs.6.90 Crores. vide G.O. No.LIS/86 dtd: 14.07.1986. The work was

started during 1985-86. Administrative approval has been accorded to the revised estimate amounting to

Rs.50.00 Crores. vide G.O. No.WRD/38/NHP/2007 dtd: 30.07.2007.

The ultimate potential to be created is 8305 acres (3361 ha.) which comprises of 3785 acres (1532 ha.)

from Ist stage and 4520 acres (1829 ha.) from IInd stage respectively. The taluks benefited by this project are

Holenarasipura and Arkalgudu taluk of Hassan District.

The works of Stage I are completed and commissioned. Regarding Stage II, the canal networks are

under progress and the head works are yet to be taken up. The project is programmed to be completed during

2009-10.

The total irrigation potential created under this project since inception to the end of March 2009 is 3788

acres (1533 ha.) as against the contemplated potential of 8305 acres (3361 ha.) A Balance potential of 4517

acres (1828 ha.) is programmed to be completed during 2009-10.

During 2008-09, a grant of Rs.15.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.1.70 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs.39.47

Crores.

INDEX

Page 116: Annual Report 2008-09 ENG

116

12.3.4. KAMASAMUDRA LIS

This project envisages to lift 1.451 TMC of water in III stages from Hemavathy River near Kamasamudra

Village in Holenarasipura taluk of Hassan District. Administrative approval has been accorded to the Original

estimate amounting to Rs.0.995 Crores. vide G.O. No.PWD/180/LIS/84 dtd: 12.06.1984. The work was started

during 1984-85. Administrative approval has been accorded to the Revised estimate amounting to Rs.70.00

Crores. vide G.O. No.WRD/39/NHP/2007 dtd: 30.07.2007. Approval accorded with a condition to complete I &

II stage LIS on priority and to take up III stage LIS depending on the availability of water.

The ultimate potential to be created is 12670 acres (5128 ha.) which comprises of 2450 acres (992 ha.)

from Ist stage, 7220 acres (2922 ha.) from IInd stage and 3000 acres (1214 ha.) from III stage. The taluks

benefited by this project are Hassan and Holenarasipura taluks of Hassan District.

The details of the Canal system are as under.

Sl.

No Stage Name of the Canal

Length of Canal

in Km. Atchkat in acres (ha.)

1 1st stage LBC 14.20 1820.00 (737)

RBC 7.00 630.00 (255)

2 2nd Stage Mallali Branch Canal 54.00 5220.00 (2113)

Nagenahalli Branch Canal 12.40 2000.00 (809)

3 3rd stage Heragu Canal & RBC 11.00 3000.00 (1214)

Total 12670 acres (5128)

The works of Stage I are completed and commissioned. In Stage II, Head works are completed and

commissioned. The Canal works of Malalli and Nagenahalli Branch Canal are in progress.

The total irrigation potential created under this project since inception to the end of March 2009 is 8048

acres (3257 ha.) as against the contemplated potential of 12670 acres (5128 ha.) A potential of 1656 acres (670

ha.) is programmed to be created during 2009-10.

During 2008-09, a grant of Rs.8.05 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.3.09 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs.51.12

Crores.

INDEX

Page 117: Annual Report 2008-09 ENG

117

12.3.5. KACHENAHALLY LIS

This project envisages to lift 0.73 TMC of water in III stages from Hemavathy River near Kachenahalli

Village in Channarayapatna taluk of Hassan District. Administrative approval has been accorded to the Original

estimate amounting to Rs.8.90 Crores. vide G.O. No.PWD/1/NHP/92 dtd:27.12.1991. The work was started

during 1991. Administrative approval has been accorded during 2002 to the revised estimate amounting to

Rs.68.30 Crores. Further, Administrative approval has been accorded to the Re-revised estimate amounting to

Rs.165.00 Crores. vide G.O. No.WRD/37/NHP/2007 dtd: 30.07.2007. Approval accorded with a condition to

complete I & II stage LI Schemes on priority and to take up III stage LIS depending on the availability of water.

The ultimate potential to be created is 12600 acres (5100 ha.) which comprises of 1390 acres (563 ha.)

from Ist stage, 6610 acres (2675 ha.) from IInd stage and 4600 acres (1862 ha.) from III stage respectively. The

taluks benefited by this project are Holenarasipura, Hassan, Arasikere and Channarayapatna of Hassan District.

The details of the Canal system are as under.

Sl.

No Stage Name of the Canal

Length of Canal

in Km.

Atchkat in

acres (ha.)

1 1st Stage Samudravalli Main Canal 1.875 1390 (563)

2 2nd Stage Dandiganahalli Branch Canal 22.50 5385 (2179)

Bijamaranahalli Branch Canal 8.00 1225 (496)

3 3rd Stage Gandsi Branch Canal 32.00 4600 (1862)

Total 12600 (5100)

In stage I the Earth work excavation of Samudravalli Main Canal is partially completed. Head works viz.,

intake canal, pump and jack well cum pump house are in progress. In stage II earth work excavation for

Dandiganahalli and Bijamaranahalli are partially completed. In III stage, survey works are completed. A

potential of 1236 acres (500 ha.) is programmed to be created during 2009-10.

During 2008-09, a grant of Rs.20.00 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.0.86 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs. 9.44

Crores.

INDEX

Page 118: Annual Report 2008-09 ENG

118

12.3.6. VOTEHOLE PROJECT

This project envisages the construction of a composite dam across Votehole River near Lakkenahally

village in Belur Taluk of Hassan District. Administrative approval has been accorded to the Original estimate

amounting to Rs.2.05 Crores. vide G.O. No. 5/GIP/64, dtd: 15.12.1971. The work was started during -1971.

Administrative approval has been accorded during 22.02.1996 to the Revised estimate amounting to Rs.38.00

Crores. Further, Administrative approval has been accorded to the Re-revised estimate amounting to Rs.59.75

Crores. vide G.O. No.WRD/47/NHP/2007 dtd: 30.07.2007.

The planned utilization from this project is 2.40 TMC to create an ultimate potential of 18500 acres

(7487 ha.). The details of Canals coming under this project are as below.

Sl.

No. Name of the Canal Length in Km

Atchkat in Acres

(Hectares)

1 Left Bank Canal 10 500 (202)

2 Right Branch Canal 45 10582 (4283)

3 Nakalgud Branch Canal 15 7418 (3002)

Total 18500 (7487)

The taluks benefited by this project are Belur and Alur of Hassan District.

The Dam and allied works are completed. The Canal works are also completed physically.

The total irrigation potential created under this project since inception to the end of March 2009 is

18500 acres (7487 ha.).

During 2008-09, a grant of Rs.0.10 Crores has been allocated. Upto end of 3/2009 an expenditure of

Rs.0.66 Crores is incurred. The cumulative expenditure incurred since inception upto end of 3/2009 is Rs.60.48

Crores.

INDEX

Page 119: Annual Report 2008-09 ENG

119

PROJECTS UNDER

ZONES OF WATER RESOURCES

DEPARTMENT

Page 120: Annual Report 2008-09 ENG

120

13. AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER,

IRRIGATION PROJECT ZONE, GULBARGA

13.1. KARANJA PROJECT

Karanja Irrigation project envisages construction of storage reservoir across River Karanja, tributary of

River Manjra in Godavari Basin near Byalhalli village, Bhalki Taluk of Bidar District. The gross storage

capacity of the reservoir is 7.691 TMC. The utilisation under this project is 9.27 TMC. The area covered for

irrigation under this project is 35,614 hectares.

The Revised estimated cost of the project is Rs. 522.00 Crores as per the schedule rates of 2008-09.

The Dam works comprising of earthen dam, C. C. Spillway, R.C.C. Sluices and parapet wall are

completed. Construction of is also completed.

Works of LIS in the backwaters of the dam like rising main, intake canal , pump house, cistern,

delivery chamber are completed.

CANALS: Works of left bank canal upto 31.00 kms. And right bank canal upto 124.00 km. are completed.

Works in Km. 3.00 are under progress.

The details of target and achievement of the project for 2007-08 and the target 2008-09 are as follows:

Sl.

No Year

Financial (Rs. in Crores) Physical (in hectares)

Target Achievement Target Achievement

1) 2007-08 11.23 10.92 - -

2) 2008-09 11.57 10.78 - -

During 2008-09, central assistance of Rs.12.25 crores is availed under AIBP. Cumulative central assistance

availed for the project is Rs.189.03 crores.

INDEX

Page 121: Annual Report 2008-09 ENG

121

14. AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER,

IRRIGATION CENTRAL ZONE, MUNIRABAD

Tungabhadra Project, Hirehalla Project, Maskinala Project, Singatalur Lift Irrigation Scheme,

Kanakanala Project, Narihalla Project, Hagaribommanahalli Project, Rajolibanda Diversion Scheme,

Vijayanagar Canals and other LIS comes under the Irrigation Central Zone, Munirabad. Hirehalla Project,

Maskinala Project, Singatalur Lift Irrigation Scheme projects are on-going projects. The original works of

Tungabhadra Project have been completed. But improvement/Modernisation works of Left bank canal are to be

completed.

14.1. TUNGABHADRA PROJECT

The Tungabhadra Project comprises of reservoir across the River Tungabhadra, a tributary to River

Krishna, near Mallapuram in Hospet taluk, Bellary District, with canals on both banks to provide irrigation to an

extent of 3,62,715 Ha in Bellary, Koppal and Raichur Districts. The utilisation is 3736 M.cum (133.00 TMC).

This is an inter-state multipurpose project started in 1945 as a joint venture of the then Governments of Madras

and Hyderabad. After reorganisation of States, the project became a joint venture of Mysore (Now Karnataka)

and Andhra Pradesh. The irrigation and utilisation indicated above pertain to Karnataka only.

The Dam and Canal works are completed. Originally most of the reaches of Tungabhadra Left Bank

Canal have been constructed out of available soil in the adjoining borrow areas. For the embankment sections,

since Zonal section is not provided breaches and bongas were occurring. In order to avoid frequent breaches and

bongas in the canal. Government constituted an expert committee to advice regarding strengthening of the canal.

As per the Expert Committee Report I.S. works have been taken up in stages from 1982 to 2007 with an

expenditure of Rs.205.34 Crores.

During 2008-09, an amount of Rs.50.00 crores is allocated for modernization works. Due to elections in

May 2009, modernization works were not taken up only urgent repair works were taken up. An expenditure of

Rs.208.84 crores is incurred upto end of March 2009.

MODERNISATION OF DISTRIBUTARIES OF TBLBC, TBRBLLC AND TBRBHLC

Modernisation of distributaries of Tungabhadra Project (L/S & R/S) is being taken up from 2005 to 2007

the expenditure is Rs. 40.00 crores. During 2008-09 grants of Rs. 30.00 crores was allocated for modernization

of distributaries.

Due to the election in May 2008 works could taken up but only emergent works to a tune of Rs. 3.60 crores

were taken up. Total expenditure from 2005 to 2008 is Rs. 43.63 crores. During 2009-10 grants of Rs. 70.00

crores has been allocated modernization of distributaries.

Balancing reservoir at Mile 109 of TLBC has been constructed and water is being stored in order to

supplement the tail end ayacut and to supply drinking water to Raichur city.

During 2008 closure period Govt. has allocated Rs. 50.00crores for modernization works. But due to

election held during May 2008 the works were not taken up. Hence only emergent nature of works for smooth

flow of water were taken up. The Modernisation of distributaries of TBP is being taken up from 2005 to 2007.

Page 122: Annual Report 2008-09 ENG

122

All the distributories of RB HLC have completed including Sub Distributory 16 A and Hagari bridge and

related works. From the TLBC, Irrigation potential has been created to an extent of 2,44,668 Ha, & there is no

balance to be created. From RB HLC Irrigation potential has been created to an extent of 72,443 Ha. Since

creation of Irrigation Potential is restricted to Railway line Irrigation Potential is not created beyond Railway

line. From RBHLC 37503 Ha Irrigation Potential has been created. (Total 3,54,615 Ha)

From the Tungabhadra project, an Irrigation Potential of 3,54,615 Ha. has been created up to 3/2008.

EXPENDITURE:-

Upto end of 3/2009 an expenditure of Rs.393.48 Crores has been incurred comprising Rs. 310.47 Crores

on the Left Bank High Level and Low Level Canals, Rs. 6.15 Crores on the Right Bank Low Level Canal and

Rs.76.86 Crores on the Right Bank High Level Canal. The above amount includes the expenditure of Dam also.

AN OVER VIEW OF THE TUNGABHADRA PROJECT

TUNGABHADRA LEFT BANK CANAL

1. Name of Project TUNGABHADRA LEFT BANK CANAL

2. Location Left Bank of T.B.Dam

3. Year of inception 1945

4. Year of completion Completed in stages upto 1968 (Original works)

5. Original and latest estimated cost in Crores Including administrative approval no. and

date/Technical Sanction.

Original cost: Rs. 17.44 Crores (Sanctioned by Nizam

Government in 1951) Revised Cost: Rs. 194.40 Crores (ID 122 MTP 92 Dated:

05-06-1996)

Latest cost: Rs. 302.00 Crores

6.

Length of canal

a) Main canal 226.00 km

b) Distributaries 707.00 km

7. Length of ayacut roads 1150 Km

8. District benefited Raichur and Koppal

9. Number of village and Tq benefited Gangavathi Tq, Sidhnoor Tq, Manvi Tq, Devadurga &

Raichur Taluk

10.

No of WUCS

a) Formed 585

b) Registered 244

c) Handed over 46

11. Programme during 2008-09 Rs. 357.00 lakhs

12. Progress achieved during 2008-09 Rs. 48.43 Lakhs

TUNGABHADRA RIGHT BANK HIGH LEVEL CANAL

1. Name of Project TUNGABHADRA RIGHT BANK HIGH LEVEL CANAL

2. Location Right Bank of T.B. Dam

3. Year of inception 1959

4. Year of completion 1999-2000

Page 123: Annual Report 2008-09 ENG

123

5.

Original and latest estimated cost in

Crores

Including administrative approval no.

and date/Technical Sanction.

Original cost

1) Rs. 2.20 Crores (Administrative approval PWD 83 TBP

57 Dated: 14-8-59)

2) PWD 22 NTP 65 Dated: 18-9-65 For Rs.3.00 Crores

(Stage-I and II)

3) Stage-I Technical approved No. CER 72 Dated: 16-11-

1996 for Rs. 1.80 Crores

4) Stage-II Technical approved No. CER/10/72 Dated: 8-8-

1972; Rs.1.20 Crores

Revised Cost: Rs. 26.00 Crores

(PWD 149 Dated: 2-3-89) Latest Cost: Rs. 153.60 Crores. (Submitted to Government for

approval)

6.

Length of canal

a) Main canal 196.34 km

b) Distributaries 171.66 km

7. Length of ayacut roads 294.55 km

8. District benefited Bellary

9. Number of village and Tq benefited Siruguppa and Bellary Tq.

10.

No of WUCS

a) Formed 126

b) Registered 81

c) Handed over 39

11. Programme during 2008-09 Rs. 70.99 lakhs

12. Progress achieved during 2008-09 Rs. 68.15 Lakhs

INDEX

Page 124: Annual Report 2008-09 ENG

124

14.2. HIREHALLA POJECT

The Hirehalla Project comprises of a reservoir across the Hirehalla, a tributary to the River Tungabhadra

near Kinnal village in Koppal Taluk of Koppal District, with canals on both banks, to provide irrigation to an

extent of 8330 Ha in Koppal Taluk. The proposed utilisation is 64.24 M.Cum (2.27TMC). Administrative

approval to the project amounting to Rs. 6.35 Crores has been accorded vide G.O.No.PWD 164 MTP 73, dated:

24-5-1979 and the latest estimated cost of the project for Rs. 272.00 Crores is under preparation.

DAM AND CANALS

DAM: The length of the dam is 3.6 Km, with a height of 15mtr having a storage capacity of 47.23 M.Cum. The

submergence area is 1247 Ha, affecting Arakera village with a population of 1500 and rehabilitation work is

taken up.

CANALS: 24.60 Km. long Left Bank Canal and a 25.00 Km. long Right Bank Canal will provide irrigation to

5000 Ha and 3330 Ha, respectively.

COST: The project had been originally estimated at a cost of Rs.635.00 lakhs at 1977-78 levels of rates. The

latest cost of project is Rs.272.00 Crores.

STAGE OF WORK

DAM: Earthen embankment is completed. Spillway work including installation of 6 radial gates is completed.

Water is stored to the full capacity. The project was dedicated to the nation on 26-12-2001 by the then Hon‟ble

Chief Minister of Karnataka.

CANALS AND DISTRIBUTARIES:

1) RBC: Out of a total length of 25Km, works in respect of 22.30 Km are completed. Out of 37 distributaries,

33 Nos are completed and balance of 4 Nos is under progress.

2) LBC: Works of the entire canal length of 24.60 Km are completed. Out of 27 Distributaries, 26 Nos are

completed and balance 1 is under progress.

National Highway crossing under Dy. No. 17 are yet to be taken up by the concerned department.

REHABILITATION WORKS: Rehabilitation work of Arakera village is completed. For rehabilitation for

Mudlapur, Veerapur, Sirur and Muttal, an amount of Rs. 12.78 crores is deposited to Revenue Department, land

acquisition is under process.

So far an irrigation potential of 8116 Ha. has been created, out of total atchkat of 8330 Ha. Balance 214

Ha. is planned to be created during this year.

EXPENDITURE: Expenditure incurred during 2008-09 is Rs. 353.80 Lakhs. Cumulative expenditure upto

3/2009 is Rs. 23074.65 Lakhs.

Page 125: Annual Report 2008-09 ENG

125

AN OVER VIEW OF THE HIREHALLA PROJECT

1 Name of Project Hirehalla Project

2 Location Across Hirehall and Veerpurhalla 4 Km U/s of Kinnal

village.

3 Year of inception 1979

4.

Original and latest estimated cost in Crores.

Including administrative approval no. and

date

Original cost: Rs. 6.35 Crores.

PWD 164 MTC 73 Dated 24-5-1979

Revised cost: Rs. 272.00 Crores.

(Administrative approval to be obtained from

Government)

5.

Length of canal

a) Main canal LB- 24.60 Km;

RB- 25 Km

b) Distributaries 63 Km

c) Branch canal 15 Km

d) FIC Under progress

6. Length of ayacut roads 65 Km

7. District benefitted Koppal

8. Number of village and Tq benefited Kinnal

9.

No of WUCS

a) Formed 7

b) Registered 3

10. Programme during 2008-09 Rs. 383.73lakhs

11. Progress achieved during 2008-09 upto

3/2009. Rs. 376.93lakhs

Details of Irrigation Potential in Ha

Sl.

No

Name of

District

On full

development

Programme during

2008-09

Created during

2008-09

Total potential created

upto 3/2009

1. Koppal 8330 214 0 8116

INDEX

Page 126: Annual Report 2008-09 ENG

126

14.3. MASKINALA PROJECT

BRIEF DESCRIPTION:

The Maskinala Project comprises of a reservoir across the Maskinala, a tributary to River Tungabhadra,

near Maraladinni Village in Lingasugur taluk of Raichur District, with canals on both banks, to provide

irrigation to an extent of 3001 Ha in Lingasugur taluk. Administrative approval has been accorded to the Project

for Rs.311.00 lakhs. Revised administrative approval has accorded for Rs. 2357.00 lakhs. The latest revised cost

of the project is Rs. 4835.00 lakhs.

DAM & CANALS

DAM: Dam is 814 m long (spillway length being 57 m) and 23.74 m high above the nala bed level with a gross

storage capacity of 13.11 M.cum with submergence to an extent of 173 Ha without affecting any village.

CANALS: All the works of main canals on either side are completed. Irrigation potential capacity is 1940 Ha

under LBC and 1061 Ha under RBC, total from the project being 3001 Ha

COST: The project had been originally estimated to Rs. 311 lakhs at 1975-76 level of rate. The revised cost of

the project is has been administratively approved for Rs. 2357.00 lakhs and the latest revised cost of the project

is Rs. 4835.00 lakhs.

EXPENDITURE: Expenditure incurred during 2008-09 is Rs. 102.89 Lakhs. Cumulative Expenditure up to

3/2009 is Rs. 4968.66 Lakhs.

The project is completed. Contemplated irrigation potential of 3001 ha.is already created.

Expenditure

Upto 03/2008 Rs.4865.77 lakhs

During 2008-09 Rs.102.89 lakhs

Cum. Exp. Upto 3/2009 Rs.4968.66 lakhs

INDEX

Page 127: Annual Report 2008-09 ENG

127

AN OVER VIEW OF MASKINALA PROJECT

1 Name of Project MASKINALA PROJECT

2 Location Near Maraladinni village of Lingasugur Tq.

3 Year of inception 1976

4

Original and latest estimated cost in

Crores.

Including administrative approval no.

and date

Original cost: Rs. 3.11 Crores.

G.O. No.PWD 52 GIP 78 Dated: 22-01-1979

Revised cost: Rs. 48.35 Crores. (Administrative approval to

be obtained from Government)

5

Length of canal LBC RBC

a) Main canal 10 Km 11.50 Km

b) Distributaries 27 Km

c) FIC Under progress

6 Length of ayacut roads 1 Km

7 District benefited Raichur

8 Number of village and Tq benefited 1 No. Lingasugur

9

No of WUCS

a) Formed 5

b) Registered 5

10 Programme during 2008-09 Rs. 123.24lakhs

11 Progress achieved during 2008-09 up to

3/2009. Rs. 102.89Lakhs

The project has been completed

INDEX

Page 128: Annual Report 2008-09 ENG

128

14.4 OTHER WORKS (NEW)

(Rs. in Lakhs.)

Sl.

No.

Name of the

Project

Latest

Cost

Grant for

2008-09

Expendi

ture

during

2008-09

Cumula

tive

Expendi

ture

upto

March

2009

Likely date of

completion Irrigation Potential in Ha

Present Stage of

Project

1 2 3 4 5 6 7 8 9

1 Kolur (D-13) LIS 74.00 24.37 18.42 86.99 Completed Stabilization of 324 Ha of Kolur branch of D-13 of RBHLC

Completed

2 T.S. Kadlur LIS 135.00 40.49 30.49 143.89 Completed Stabilization of 410 Ha of 8 TE

of T.S. distributory of RBHLC Completed

3 Raravi LIS 67.00 47.54 6.27 56.27 Completed Stabiilization of 210 Ha of 7 TE-

1 of Kote hall distri. of RBHLC Completed

4 Kolur (D-7) LIS 394.00 43.52 47.77 213.50 Completed Stabilization of 1518 Ha of tail end of distry No. 7 of RBHLC

Completed

5 Hagari D/S (D-

16) LIS 90.00 72.54 110.99 124.60 Completed

Stabilization of 1214 Ha of tail end of Hagari Aqueduct D/S of

D- 16 A Completed

6 Katharaki LIS 58.00 12.91 9.25 59.63 Completed Stabilization of 182 Ha Sub distributory 89/8/1&2 of TLBC

Completed and yet to be commissioned

7 Boylmerched

LIS 73.00 12.91 8.71 37.09 Completed Stabilization of 479 Ha Sub distri.

89/7 of TLBC Completed

8 Y Kaggal LIS 1167.00 46.00 16.74 271.72 - 6643 Ha

Jackwell, transition completed. Balance

work estimates & DTP are to be approved by

TAC

9 Wala Bellary LIS 594.00 350.00 - - - 2541 Ha Modified drainwall DTP submitted to Govt. for

approval.

10 Jalibenchi LI Scheme

245.00 214.86 163.02 163.02 - Stabilisation of 123 Ha of tail end of DP-36 of RBHLC

Work under progress

INDEX

Page 129: Annual Report 2008-09 ENG

129

15. AN OVERVIEW OF PROJECTS UNDER THE CHIEF ENGINEER, UPPER

TUNGA PROJECT ZONE, SHIMOGA

15.1 BHADRA PROJECT CIRCLE

Bhadra Project Circle is functioning at B.R.Project in Bhadravathi taluk, since 07.11.1969. This Circle

is under the control of the Engineer-in-Chief, KNNL, Upper Tunga Project Zone, Shimoga

Three Divisions, namely Executive Engineer, No.3, Canal Division Malebennur; No.4 BRLBC Division,

Bhadravathi & No.5 Canal Division, Davanagere and fifteen Sub-Divisions comes under the Jurisdiction of this

Circle.

The following Projects come under the Jurisdiction of this Circle.

I. Major Irrigation Project

1) Bhadra Reservoir Project

2) Vanivilas Sagar Project

II. Medium Irrigation Project

1) Gondi Anicut Project {Bhadra Anicut}

2) Jambadahalla Reservoir Project

3) Feeder Canal to Ranikere Tank Project

4) Gayathri Reservoir Project

5) Ambligola Reservoir Project

6) Thimmapura Lift Irrigation Scheme

7) Anjanapura Project

8) Dharma Project

9) Tunga Anicut Project

10) Kaduvinabylu Project

11) D.B.Kere Pickup

III. TANKS

1) Sulekere tank (Shanti Sagar).

2) Bheemasamudra tank

3) Asundi tank

4) Madaga Masur tank

INDEX

Page 130: Annual Report 2008-09 ENG

130

15.1. BHADRA RESERVOIR PROJECT

Bhadra Dam is constructed across River Bhadra near Lakkavalli village, Tarikere Taluk, Chikamagalur

District. This project is a Multi-purpose Project providing Irrigation facility to an extent of 1,05,570 Ha and a

power generation capacity of 39.20 M.W.

The major works under the Bhadra reservoir project are completed. The water is allowed through the

both canals since 1965 and irrigation facility to the total extent of 1, 05,570 Ha. is already achieved.

The details of canals coming under this project is as follows.

Sl. No. Canal Length in Km Atchkat in Ha

1. Bhadra Right Bank Canal 103.00 17109

2. Bhadra Left Bank Canal 77.00 8270

3. Anveri Branch Canal 67.00 6514

4. Malebennur Branch Canal 48.00 23774

5. Davanagere Branch Canal 90.00 30286

6. Harihara Branch Canal 20.40 15337

7. Devarabelakere Pickup Canal 59.20 4280

Total: 464.60 1,05,570

Bhadra Project is allocated 61.70 TMC of water as per KWDT. Under the Project, Irrigation potential of

1,05,570 Ha has been achieved in 1989. The revised cost of the project was 33.53 Crores and Re-revised cost

of estimate is Rs. 170.00 Crores.

Modernisation of Bhadra Reservoir Project Canals: -

Modernisation of canal system of Bhadra reservoir project comprises of providing CC lining to sides and

bed of main canal, distributaries and minors. It also includes strengthening / reconstruction of the structures like

aquaducts, super passages, bridges cover ducts and other structures coming in main canal and distributaries.

The Bhadra modernisation works were taken up in 25 packages during 2007. The administrative

approval for the modernisation of canal systems of Bhadra reservoir amounting to Rs. 951.00 crores was

accorded by Government vide G.O. No. WRD 20 MBI 2008, Bangalore dated 26.02.2008. The DPR was

submitted to Central Water Commission and approval has been obtained from Planning Commission,

Government of India.

Modernisation of canal systems of Bhadra reservoir is receiving central assistance under Hon‟ble Prime

Ministers Special Rehabilitation package.

Grant allocated for modernisation of Bhadra canal during the year 2008-09 is Rs.27121.00 and an

expenditure of Rs. 18385.00 lakhs has been incurred upto the end of March-2009.

INDEX

Page 131: Annual Report 2008-09 ENG

131

15.2. MODERNISATION OF CANAL SYSTEM OF TUNGA ANICUT

Modernisation of Tunga canals amounting to Rs. 211.00 crores is prepared and submitted for

administrative approval. Modernisation works of Tunga canal systems has been entrusted by Government to

Karnataka Neeravari Nigam during 2007-08. No grant has been allotted for Modernisation of Canal system of

Tunga Anicut Project during the year 2008-09. The cumulative expenditure incurred on this project up to end of

March 2009 is Rs. 443.65 Lakhs.

Page 132: Annual Report 2008-09 ENG

132

15.3. HODIRAYANAHALLA DIVERSION SCHEME

Jambadahalla Reservoir is located near Duglapura village, Tarikere Taluk, Chikkamagalore district. This

project was contemplated to provide irrigation to 2428 Ha.

But due to less flow only 1133 Ha of land under right bank is being irrigated. Remaining 1295 Ha of

land is to be irrigated by diverting supplement water from Hodirayanahalla, an adjacent valley to Jambadahalla.

Addition to this, 243 Ha Land will also be benefited by this scheme. Administrative approval for the above said

Hodirayanahalla diversion Scheme is accorded by the Government dated: 10.08.1987 for Rs. 248.00 lakhs.

About 12.98 Ha of land comes under the jurisdiction of forestland. Clearance has been obtained by Central

Forest & Environment Ministry.

Survey and investigation of Hodirayanahalla diversion scheme has been conducted on tender basis

through private consultancy services as per the administrative approval obtained from the Government

amounting to Rs. 35.00 lakhs.

During 2008-09, a grant of Rs. 78.00 Lakhs is allocated. The expenditure incurred up to the end of

3/2009 is Rs. 15.71 lakhs. The expenditure incurred on the project for preliminary survey and investigation

including payment made to Forest Department for release of forest land up to the end of March 2009 is Rs.

152.90 lakhs.

INDEX

Page 133: Annual Report 2008-09 ENG

133

15.4. MODERNISATION OF CANAL SYSTEM OF AMBLIGOLA RESERVOIR

During 2008-09, Government has allotted Rs. 335.00 Lakhs grants for this project for improvements and

modernization of canal system. The works includes improvements, strengthening, and reconstruction of canal

structures and lining of canals. An expenditure of Rs. 335.00 lakhs has been incurred during 2008-09 up to end

of March 2009.

A grant of Rs. 20.00 lakhs has been allotted during 2008-09 for improvements of 7 tanks coming under

this project. The works include strengthening of tank bund, silt removal, providing revetment, lining to canals

and repairs to sluice. An expenditure of Rs. 116.22 lakhs has been incurred up to end of March 2009.

INDEX

Page 134: Annual Report 2008-09 ENG

134

15.5. MADAGA –MASUR TANK

Madaga Masur Tank is a very old tank located in Haveri District in Hirekerur Taluk, across River

Kumudvathi. 2855 Ha of Land is irrigated under this tank. This tank is very old constructed during

Vijayanagara dynasty. LBC of this tank is 14.00 Km long and RBC is 37.00 Km Long. Improvements and

repairs to embankment, canal works, and removal of silt have to be taken up. Rs. 100.00 Lakhs is allotted in the

budget during 2008-09 for improvements of this tank. Modernisation of Madaga Masur Tank canal systems are

taken up on tender basis and works are under progress. The expenditure incurred during the year 2008-09 up to

the end of 3/2009 is Rs. 119.00 Lakhs. Cumulative expenditure incurred up to end of March 2009 is Rs. 470.85

lakhs.

INDEX

Page 135: Annual Report 2008-09 ENG

135

15.6. ERM OF BHEEMASAMUDRA TANK

Bheemasamudra tank has been constructed 500 years ago in Bheemasamudra village, Chitradurga Taluk,

Chitradurga district. The storage capacity of the tank is 0.905 TMC. The Irrigation potential created under this

tank is 1235 Ha (3050 Acres). The tank has left Bank canal and right Bank canal and distributary system. The

total length of canal is 68 Km.

At present the Bheemasamudra tank is filled up with silt since the tank is 500 year old. Due to this, the

storage capacity of tank is reduced to 0.18 TMC. The catchment area of tank has scanty rainfall.

In order to augument the inflow in to the tank it is proposed to construct feeder canal from

Bettadanagenahalli and Jogerahalla dams by constructing pickup. Works are entrusted on tender basis and are

under progress. The grant allotted for the year 2008-09 for this project was Rs. 50.00 Lakhs. The project is

included under Prime Minister‟s special rehabilitation package and Government has accorded administrative

approval for Rs. 400.00 lakhs and technical sanction to the estimate is awaited.

INDEX

Page 136: Annual Report 2008-09 ENG

136

15.7. MODERNISATION OF CANAL SYSTEM OF GONDI ANICUT (BHADRA)

Modernisation of Gondi canals amounting to Rs. 84.50 crores is prepared and submitted for

administrative approval. Modernisation works of Gondi canal systems has been entrusted by Government to

Karnataka Neeravari Nigam during 2007-08. No grant has been allotted for Modernization of canal system of

Gondi Anicut during 2008-09. The cumulative expenditure incurred on this project up to end of 3/2009 is Rs.

378.02 Lakhs.

15.8. KADUVINABYLU LIFT IRRIGATION SCHEME

Kaduvinabylu Lift irrigation Scheme is located in N.R.Pura taluk, Chikkamagalore District. The Project

has been administratively approved by the State Government vide G.O.No.WRD 223 MMB 2004 Bangalore

dated 10.5.2005 for Rs. 690.00 Lakhs. The Master plan committee has allocated 0.21 TMC of water to this

project under Krishna scheme- A. The Chief Engineer, KNNL, Upper Tunga Project Zone Shimoga,

technically sanctioned the estimate amounting to Rs.690.00 Lakhs, Vide CER No.83/2005-06 dated. 29.9.2005.

During the year 2008-09, a grant of Rs. 156.00 Lakhs has been allotted and no expenditure is incurred

till date.

15.9. THIMMAPURA LIFT IRRIGATION SCHEME

The scheme envisages providing irrigation facility to an extent of 4176 Acres (1691 Ha) of land

coming under the villages of Kanavelli, Bharadi, Kurugunda and Basapura of Haveri taluk (this includes 159.00

Acres of suffering atchkat under Kannavalli tank). The revised estimated cost is Rs.2313.00 Lakhs. Grant of

Rs. 90.00 Lakhs is allotted in the year 2008-09 and no expenditure is been incurred during the current year.

NABARD assistance to this project has been rejected.

15.10. ANJANAPURA RESERVOIR PROJECT

Anjanapura Reservoir project is constructed across Kumudawathi River in Anjanapura village in

Shikaripura taluk, Shimoga District. The area irrigated is 6736 Ha. The original estimated cost of the project

was Rs. 27.68 Lakhs. The right bank canal runs for a length of 45.00 Km. and has an irrigation potential of

5919 Ha The Left bank canal runs for a length of 14.00 Km. and has an irrigation potential of 817 Ha.

Erection of automatic godbole gates on the spillway of the reservoir has been completed during 2006 and

water in the reservoir is stored for extra height of 1 meter.

Improvements to canal system:

NABARD grant of Rs. 1500.00 Lakhs is allotted during 2008-09. Works are taken up on tender basis.

The expenditure incurred upto end of 3/08 is Rs. 681.98 Lakhs. Additional grant allotted is Rs.10.00 crores.

Tender process is under progress.

Improvements of 13 tanks under the atchkat Anjanapura project:

Grant of Rs. 150.00 Lakhs is allotted during 2008-09 for improvement of 13 tanks coming under this

Project. Works are taken up on Tender basis. The expenditure incurred upto the end of 3/2009 is Rs. 535.24

Lakhs.

INDEX

Page 137: Annual Report 2008-09 ENG

137

16. COMMAND AREA DEVELOPMENT PROGRAMME

Agriculture is the backbone of Indian Economy and it is the pillar of the Economic development. At the

commencement of the Fifth Five Year Plan (1974-80), in pursuance of the policy of the Government of India,

the Command Area Development Programme was launched in the State for integrated and comprehensive

development of the Command Areas of Major and Medium Irrigation Projects. As per the objectives laid down

by the National Commission on Irrigation, 1971 and the National Commission on Agriculture, 1976, the CADP

ensures rapid and optimum utilization of Irrigation Potential created under Major and Medium Irrigation

Projects thereby increasing the agriculture production as also reducing the gap between the potential area

created and the actual area utilised.

THE OBJECTIVES

Irrigation Management is a multi-disciplinary activity involving major department like Irrigation,

Agriculture, Cooperation and other organization engaged in training and research activities. Against this

perspective, CADA was constituted in the year 1970 to work as a catalyst between the various organizations to

reduce the gap between irrigation potential created and utilized, to increase production per unit of water and

land, to reduce the loss of irrigation water in the conveyance system, to improve its efficiency at the farm level

and to ensure equitable distribution of water. The objectives of the CADA, as envisaged under section 10 of the

Karnataka Command Areas Development (K.C.A.D.) Act 1980, are listed below:

To formulate and implement schemes for the Comprehensive Development of the Command Area;

To prevent land erosion and water logging;

To improve soil fertility and regulation of cropping pattern;

To ensure the efficient maintenance of Field channels and Field Drains by the Farmers within the

Command Area;

Localisation and de-localisation of lands for various crops;

Ensuring supply of all inputs and services;

Promotion and setting up of rural growth centres for integrated development of the Command Area;

Development of marketing, processing and storage facilities and adequate communication system;

Arranging for credit facilities to the farmers and artisans;

Organizing agricultural Co-operatives and Associations;

Construction of Field channels and connected drains;

To borrow and lend money necessary for the due discharge of its functions;

Conjunctive use of surface and ground water;

To determine the payment of compensation as provided in sub section [4] of section 12 of KCAD Act

1980;

Page 138: Annual Report 2008-09 ENG

138

To setup agricultural demonstrations farms and promote extension activities; and

To execute such other acts, consistent with the provisions of this Act.

The Six CADA’S that are established in Karnataka are:

Malaprabha and Ghataprabha Projects, Belgaum

Tungabhadra project, Munirabad

Upper Krishna projects, Bheemarayanagudi

Cauvery basin projects, Mysore

Bhadra project, Shimoga

Irrigation Project Zone, Gulbarga

BRIEF DETAILS OF CADA

Sl.

No.

Name of CADA with

headquarters

Year of

Starting

Irrigation

Projects Districts covered

1

Malaprabha and

Ghataprabha Projects, Belgaum

1974 Malaprabha &

Ghataprabha

Belgaum, Dharwad,

Bagalkot, Gadag

2

Tungabhadra Project,

Munirabad

1974

12.11.1979

Tungabhadra, Hirehalla,

Maskinala

Bellary, Raichur &

Koppal.

3

Upper Krishna Projects,

Bheemarayanagudi

1977

11-12-1979 Upper Krishna

Gulbarga, Bijapur,

Raichur & Bagalkot.

4 Cauvery Basin Projects, Mysore

1974 1.3.1974

Kabini, Harangi, Hemavathy,

KRS. , Nugu, Taraka, Gundal, Votehole, Marconahally,

Manchanabele, Kanva and

Byramangala.

Mysore, Kodagu,

Chamarajnagar, Hassan, Mandya,

Tumkur,

Bangalore(Rural)

5

Bhadra Reservoir Project,

Shimoga 1979 Tunga, Bhadra & Gondi

Shimoga,

Chikkamagalore, Davangere.

6 Irrigation Project Zone,

Gulbarga 2000

Chandrampalli, Hattiguni,

Soudagar, Upper Mullamari,

Amarja, Bennethora, Bhima,

Gondorinala, Kagna, Karanja

Gulbarga, Bidar

Page 139: Annual Report 2008-09 ENG

139

MALAPRABHA AND GHATAPRABHA PROJECTS, BELGAUM

Command Area Development Authority, Malaprabha and Ghataprabha projects, Belgaum, came into

existence during 1974-75.

During 2008-09, the budget allocation is Rs. 1401.67 lakhs (under head 2705 & 4705) out of which an

expenditure of Rs. 709.55 lakhs has been incurred.

TUNGABHADRA PROJECT, MUNIRABAD

Command Area Development Authority, Tungabhadra project, Munirabad, came into existence during

1974.

During 2008-09, the budget allocation is Rs. 1243.50 lakhs (under head 2705 & 4705) out of which an

expenditure of Rs. 1015.99 lakhs has been incurred.

UPPER KRISHNA PROJECTS, BHEEMARAYANAGUDI

Command Area Development Authority, Upper Krishna projects, Bheemarayanagudi, has come into

force since 11-12-1979.

During 2008-09, the budget allocation is Rs. 1300.91 lakhs (under head 2705 & 4705) out of which an

expenditure of Rs. 639.20 lakhs has been incurred.

CAUVERY BASIN PROJECTS, MYSORE

Command Area Development Authority, Cauvery basin projects, Mysore, came into existence during

1974-75.

During 2008-09, the budget allocation is Rs. 1402.95 lakhs (under head 2705 & 4705) out of which an

expenditure of Rs. 941.63 lakhs has been incurred.

BHADRA PROJECT, SHIMOGA

Command Area Development Authority, Bhadra project, Shimoga, came into existence during 1979.

During 2008-09, the budget allocation is Rs. 1556.10 lakhs (under head 2705 & 4705) out of which an

expenditure of Rs. 952.99 lakhs has been incurred.

IRRIGATION PROJECT ZONE, GULBARGA

Command Area Development Authority, Irrigation Project Zone, Gulbarga, came into existence during

2000-01.

During 2008-09, the budget allocation is Rs. 1281.20 lakhs (under head 2705 & 4705) out of which an

expenditure of Rs. 1123.11 lakhs has been incurred.

Page 140: Annual Report 2008-09 ENG

140

The details of the Physical programme & Progress and Financial Programme & progress for

the year 2008-09 up to the end of 3/2009

(Physical in hectares) (Financial Rs. in Lakhs)

Sl.

No. Name of the CADA’s

Field

Irrigation channels Field Drains Warabandi

Program Progress Program Progress Program Progress

H/A 2705

1 Tungabhadra Project,

Munirabad

P 1320 1622 1250 2021 - -

F 132.00 103.59 50.00 73.22 - -

2

Malaprabha and

Ghataprabha Projects,

Belgaum

P 13301 1865 6700 5448 - -

F 1995.24 251.89 268.00 141.20 - -

3 Upper Krishna Projects,

Bheemarayanagudi

P 20000 18366 5000 1148 22667 7987

F 3000.00 2548.06 200.00 45.94 68.00 23.96

4 Cauvery Basin Projects,

Mysore

P - - 1000 523 500 200

F - - 40.00 20.91 2.00 0.80

5 Bhadra Reservoir

Project, Shimoga

P 24670 4518 5000 4021 - -

F 3700.50 451.79 200.00 160.77 - -

6 Irrigation Project Zone,

Gulbarga

P 8553 757 10859 10859 - -

F 761.00 100.89 434.36 434.36 - -

H/A 4705 (Special Development Plan)

1 Tungabhadra Project,

Munirabad

P - - 2495 1067 - -

F - - 99.78 17.69 - -

2

Malaprabha and

Ghataprabha Projects,

Belgaum

P - - 1899 - - -

F - - 76.00 - - -

3 Upper Krishna Projects,

Bheemarayanagudi

P - - 6205 800 - -

F - - 248.21 31.08 - -

4 Cauvery Basin Projects,

Mysore

P 1785 65 750 450 - -

F 134.02 4.70 30.00 17.98 - -

5 Bhadra Reservoir

Project, Shimoga

P 940 - 1575 - - -

F 94.00 - 63.00 - - -

Page 141: Annual Report 2008-09 ENG

141

6 Irrigation Project Zone,

Gulbarga

P - - 9500 8067 - -

F - - 380.00 322.67 - -

INDEX